10-Q 1 p69848e10vq.htm 10-Q e10vq
Table of Contents

UNITED STATES
SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

FORM 10-Q

QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE
SECURITIES EXCHANGE ACT OF 1934

For the quarterly period ended September 30, 2004
Commission File No 0-25428

MEADOW VALLEY CORPORATION

(Exact name of registrant as specified in its charter)
     
Nevada
(State or other Jurisdiction of
incorporation or organization)
  88-0328443
(I.R.S. Employer Identification Number)

4411 South 40th Street, Suite D-11
Phoenix, Arizona 85040
(602) 437-5400

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities and Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filings requirements for the past 90 days.   Yes [X]   No [  ]

Indicate by check mark whether the registrant is an accelerated filer (as defined in Rule 12b-2 of the Act).    Yes [  ]   No [X]

     Number of shares outstanding of each of the registrant’s classes of common stock as of November 11, 2004:

Common Stock, $.001 par value
3,601,250 shares

 


MEADOW VALLEY CORPORATION
INDEX
REPORT ON FORM 10-Q
FOR THE QUARTER ENDED SEPTEMBER 30, 2004

         
       
       
    3  
    4  
    5  
    6  
    8  
    16  
    21  
    21  
       
    21  
    23  
    23  
    23  
    23  
    23  
 Exhibit 31.11
 Exhibit 31.12
 Exhibit 32.6

2


Table of Contents

PART I — FINANCIAL INFORMATION

Item 1. Financial Statements

MEADOW VALLEY CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF OPERATIONS
(Unaudited)
                 
    Nine Months Ended
    September 30,
    2004
  2003
Revenue:
               
Construction Services
  $ 80,320,938     $ 84,053,359  
Construction Materials
    44,659,716       32,957,202  
 
   
 
     
 
 
Total revenue
    124,980,654       117,010,561  
 
   
 
     
 
 
Cost of revenue:
               
Construction Services
    80,194,016       81,571,237  
Construction Materials
    39,783,334       29,845,344  
 
   
 
     
 
 
Total cost of revenue
    119,977,350       111,416,581  
 
   
 
     
 
 
Gross profit
    5,003,304       5,593,980  
General and administrative expenses
    4,686,023       4,981,158  
 
   
 
     
 
 
Income from operations
    317,281       612,822  
 
   
 
     
 
 
Other income (expense):
               
Interest income
    48,038       46,962  
Interest expense
    (259,700 )     (382,622 )
Other income (expense)
    (28,795 )     433,019  
 
   
 
     
 
 
 
    (240,457 )     97,359  
 
   
 
     
 
 
Income before income taxes
    76,824       710,181  
Income tax expense
    (28,809 )     (266,318 )
 
   
 
     
 
 
Net income
  $ 48,015     $ 443,863  
 
   
 
     
 
 
Basic net income per common share
  $ 0.01     $ 0.12  
 
   
 
     
 
 
Diluted net income per common share
  $ 0.01     $ 0.12  
 
   
 
     
 
 
Basic weighted average common shares outstanding
    3,601,250       3,590,386  
 
   
 
     
 
 
Diluted weighted average common shares outstanding
    3,744,830       3,590,386  
 
   
 
     
 
 

The accompanying notes are an integral part of these condensed consolidated financial statements.

3


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF OPERATIONS
(Unaudited)
                 
    Three Months Ended
    September 30,
    2004
  2003
Revenue:
               
Construction Services
  $ 25,885,201     $ 31,824,143  
Construction Materials
    16,218,601       11,021,958  
 
   
 
     
 
 
Total revenue
    42,103,802       42,846,101  
 
   
 
     
 
 
Cost of revenue:
               
Construction Services
    26,970,562       31,323,580  
Construction Materials
    14,196,433       10,121,591  
 
   
 
     
 
 
Total cost of revenue
    41,166,995       41,445,171  
 
   
 
     
 
 
Gross profit
    936,807       1,400,930  
General and administrative expenses
    1,593,967       1,870,717  
 
   
 
     
 
 
Loss from operations
    (657,160 )     (469,787 )
 
   
 
     
 
 
Other income (expense):
               
Interest income
    2,059       13,311  
Interest expense
    (64,386 )     (120,849 )
Other income
    37,769       421,975  
 
   
 
     
 
 
 
    (24,558 )     314,437  
 
   
 
     
 
 
Loss before income taxes
    (681,718 )     (155,350 )
Income tax benefit
    254,633       58,256  
 
   
 
     
 
 
Net loss
  $ (427,085 )   $ (97,094 )
 
   
 
     
 
 
Basic net loss per common share
  $ (0.12 )   $ (0.03 )
 
   
 
     
 
 
Diluted net loss per common share
  $ (0.12 )   $ (0.03 )
 
   
 
     
 
 
Basic weighted average common shares outstanding
    3,601,250       3,601,250  
 
   
 
     
 
 
Diluted weighted average common shares outstanding
    3,754,801       3,601,250  
 
   
 
     
 
 

The accompanying notes are an integral part of these condensed consolidated financial statements.

4


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATED BALANCE SHEETS
                 
    September 30,   December 31,
    2004
  2003
    (Unaudited)  
Assets:
           
Current Assets:
               
Cash and cash equivalents
  $ 7,028,667     $ 4,738,388  
Restricted cash
    1,710,917       1,844,891  
Accounts receivable, net
    19,148,415       20,664,022  
Claims receivable
          4,101,898  
Prepaid expenses and other
    2,941,418       2,196,899  
Inventory, net
    830,186       1,249,118  
Land held for sale
          264,738  
Costs and estimated earnings in excess of billings on uncompleted contracts
    667,257       1,463,309  
Deferred tax asset
    1,253,767       1,243,896  
 
   
 
     
 
 
Total Current Assets
    33,580,627       37,767,159  
Property and equipment, net
    17,903,426       13,127,675  
Refundable deposits
    33,947       94,299  
Mineral rights and pit development, net
    266,310       309,110  
Claims receivable
    3,521,080       3,521,080  
 
   
 
     
 
 
Total Assets
  $ 55,305,390     $ 54,819,323  
 
   
 
     
 
 
Liabilities and Stockholders’ Equity:
               
Current Liabilities:
               
Accounts payable
  $ 16,748,914     $ 18,646,857  
Accrued liabilities
    5,724,779       4,563,816  
Notes payable
    4,489,919       3,512,286  
Obligations under capital leases
    536,632       878,280  
Billings in excess of costs and estimated earnings on uncompleted contracts
    4,368,639       4,955,454  
 
   
 
     
 
 
Total Current Liabilities
    31,868,883       32,556,693  
Deferred tax liability
    2,643,055       2,604,652  
Notes payable, less current portion
    8,058,922       6,999,729  
Obligations under capital leases, less current portion
    1,113,330       1,085,064  
 
   
 
     
 
 
Total Liabilities
    43,684,190       43,246,138  
 
   
 
     
 
 
Commitments and contingencies
               
Stockholders’ Equity:
               
Preferred stock - $.001 par value; 1,000,000 shares authorized, none issued and outstanding
           
Common stock - $.001 par value; 15,000,000 shares authorized, 3,601,250 issued and outstanding
    3,601       3,601  
Additional paid-in capital
    10,943,569       10,943,569  
Capital adjustments
    (799,147 )     (799,147 )
Retained earnings
    1,473,177       1,425,162  
 
   
 
     
 
 
Total Stockholders’ Equity
    11,621,200       11,573,185  
 
   
 
     
 
 
Total Liabilities and Stockholders’ Equity
  $ 55,305,390     $ 54,819,323  
 
   
 
     
 
 

The accompanying notes are an integral part of these condensed consolidated financial statements.

5


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS
(Unaudited)
                 
    Nine Months Ended
    September 30,
    2004
  2003
Increase (Decrease) in Cash and Cash Equivalents:
               
Cash flows from operating activities:
               
Cash received from customers
  $ 130,934,797     $ 116,149,475  
Cash paid to suppliers and employees
    (123,131,370 )     (113,464,432 )
Interest received
    48,038       46,962  
Interest paid
    (259,700 )     (382,622 )
Income taxes received (paid)
    (276 )     54,641  
 
   
 
     
 
 
Net cash provided by operating activities
    7,591,489       2,404,024  
 
   
 
     
 
 
Cash flows from investing activities:
               
Decrease in restricted cash
    133,974       114,800  
Proceeds from sale of property and equipment
    1,220,080       433,512  
Purchase of property and equipment
    (2,928,808 )     (413,101 )
Decrease in land held for sale
          942,701  
 
   
 
     
 
 
Net cash provided by (used in) investing activities
    (1,574,754 )     1,077,912  
 
   
 
     
 
 
Cash flows from financing activities:
               
Proceeds from notes payable
    181,070        
Repayment of notes payable
    (3,136,353 )     (3,132,853 )
Repayment of capital lease obligations
    (771,173 )     (812,025 )
 
   
 
     
 
 
Net cash used in financing activities
    (3,726,456 )     (3,944,878 )
 
   
 
     
 
 
Net increase (decrease) in cash and cash equivalents
    2,290,279       (462,942 )
Cash and cash equivalents at beginning of period
    4,738,388       3,289,535  
 
   
 
     
 
 
Cash and cash equivalents at end of period
  $ 7,028,667     $ 2,826,593  
 
   
 
     
 
 

The accompanying notes are an integral part of these condensed consolidated financial statements.

6


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES
CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS (Continued)
(Unaudited)

                 
    Nine Months Ended
    September 30,
    2004
  2003
Increase (Decrease) in Cash and Cash Equivalents (Continued):
               
Reconciliation of Net Income to Net Cash Provided by Operating Activities:
               
Net Income
  $ 48,015     $ 443,863  
Adjustments to reconcile net income to net cash provided by operating activities:
               
Depreciation and amortization
    2,290,450       2,058,353  
Loss (gain) on sale of property, equipment and land
    17,175       (293,210 )
Deferred taxes, net
    28,533       320,959  
Allowance for doubtful accounts
    (139,021 )     387,080  
Allowance for slow moving inventory
    193,104        
Changes in Operating Assets and Liabilities:
               
Accounts receivable
    1,654,628       (2,426,958 )
Prepaid expenses and other
    (361,730 )     (620,815 )
Inventory
    225,828       459,663  
Costs and estimated earnings in excess of billings on uncompleted contracts
    796,052       (335,696 )
Refundable deposits
    60,352       (45,008 )
Claims receivable
    4,101,898       726,007  
Other assets
          32,223  
Accounts payable
    (1,897,943 )     (976,921 )
Accrued liabilities
    1,160,963       1,638,732  
Billings in excess of costs and estimated earnings on uncompleted contracts
    (586,815 )     1,035,752  
 
   
 
     
 
 
Net cash provided by operating activities
  $ 7,591,489     $ 2,404,024  
 
   
 
     
 
 

The accompanying notes are an integral part of these condensed consolidated financial statements.

7


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

1.   Summary of Significant Accounting Policies and Use of Estimates:

     Presentation of Interim Information:

          The condensed consolidated financial statements included herein have been prepared by Meadow Valley Corporation (“we”, “us”, “our” or “Company”) without audit, pursuant to the rules and regulations of the United States Securities and Exchange Commission (“SEC”) and should be read in conjunction with our Annual Report on Form 10-K for the year ended December 31, 2003 as filed with the SEC under the Securities and Exchange Act of 1934. Certain information and footnote disclosures normally included in financial statements prepared in accordance with accounting principles generally accepted in the United States of America have been condensed or omitted, as permitted by the SEC, although we believe the disclosures, which are made are adequate to make the information presented not misleading. Further, the consolidated financial statements reflect, in the opinion of management, all normal recurring adjustments necessary to present fairly our financial position at September 30, 2004 and the results of our operations and cash flows for the periods presented. The December 31, 2003 consolidated balance sheet data was derived from audited consolidated financial statements, but does not include all disclosures required by accounting principles generally accepted in the United States of America.

          Interim results are subject to significant seasonal variations and the results of operations for the nine months ended September 30, 2004 are not necessarily indicative of the results to be expected for the full year.

     Nature of Corporation:

          Meadow Valley Corporation (the “Company”) was organized under the laws of the State of Nevada on September 15, 1994. The principal business purpose of the Company is to operate as the holding company of Meadow Valley Contractors, Inc. (“MVCI”) and Ready Mix, Inc. (“RMI”). MVCI is a general contractor, primarily engaged in the construction of structural concrete highway bridges and overpasses, and the paving of highways and airport runways for various governmental authorities and municipalities in the states of Nevada, Arizona and Utah. RMI manufactures and distributes ready mix concrete in the Las Vegas, Nevada and Phoenix, Arizona metropolitan areas.

     Revenue and Cost Recognition:

          Revenues and costs from fixed-price and modified fixed-price construction contracts are recognized for each contract on the percentage-of-completion method, measured by the percentage of costs incurred to date to the estimated total direct costs. Direct costs include, among other things, direct labor, field labor, equipment rent, subcontract, direct materials and direct overhead. General and administrative expenses are accounted for as period costs and are, therefore, not included in the calculation of the estimates to complete construction contracts in progress. Project losses are provided for in the period in which such losses are determined, without reference to the percentage-of-completion. As contracts can extend over one or more accounting periods, revisions in costs and earnings estimated during the course of the work are reflected during the accounting period in which the facts that required such revision become known.

     Claims Receivable:

          Claims for additional contract revenue are recognized only to the extent that contract costs relating to the claim have been incurred and evidence provides a legal basis for the claim. As of September 30, 2004, the total amount of contract claims filed by the Company with various public entities was $18,835,979. Of that sum, the Company’s portion was $10,548,878 and the balance of $8,287,101 pertains to a prime contractor or subcontractors’ claims.

          Total claim amounts reported by the Company in its filings are approximate and are subject to revision as final documentation, resolution of issues, settlements progress and/or payments are made. Relative to the aforementioned claims, the Company has recorded $3,521,080 in cumulative claim receivable as of September 30, 2004 to offset a portion of costs incurred to-date on the claims. The claims receivable as of September 30, 2004 and December 31, 2003 are comprised of a long-term portion of $3,521,080 and $3,521,080 and a current portion of $0 and $4,101,898, respectively.

8


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)

1. Summary of Significant Accounting Policies and Use of Estimates (Continued):

     Claims Receivable (Continued):

          The Company has not accrued a liability related to the prime contractor or subcontractors’ claims as no liability would be deemed payable if their portion of the claims did not receive a favorable outcome, correspondingly, no receivable has been recorded for overhead and profit included in their portion of the claims on the Company’s behalf.

          Although the Company believes these amounts represent a reasonably conservative posture, any claims proceeds and payments ultimately paid to the Company less than the aggregate amount recorded on the balance sheet of $3,521,080 will result in decreased earnings. Conversely, a payment for those same items in excess of $3,521,080 will result in increased income.

          A common and customary practice in construction contracts is the owner’s withholding of a portion of the contract in the form of retention. Retention practices vary from contract to contract, but in general, retention (usually somewhere between 5% and 10% of the contract) is withheld from each progress payment by the owner and then paid upon satisfactory completion of the contract. Contract proceeds comprising retention are included in the Company’s balance sheet in accounts receivable. The portion of accounts receivable pertaining to retention withheld on the contracts for which claims have been filed amounts to $880,763 as of September 30, 2004. The degree to which the Company is successful in recouping its costs from the claims may also impact the amount of retention paid by the owner.

          The Company believes that all retention amounts currently being held by the owners on the contracts with outstanding claims will be paid in full in accordance with the contract terms. Therefore, no allowance has been made to reduce the receivables due from the retention on the disputed contracts.

     Stock Option Plan:

          In November 1994, the Company adopted a Stock Option Plan providing for the granting of both qualified incentive stock options and non-qualified stock options. The Company has reserved 1,200,000 shares of its common stock for issuance under the Plan. Granting of the options is at the discretion of the Board of Directors and may be awarded to employees and consultants. Consultants may receive only non-qualified stock options. The maximum term of the stock options are 10 years and may be exercised as follows: 33.3% after one year of continuous service, 66.6% after two years of continuous service and 100% after three years of continuous service.

          All stock options issued have an exercise price not less than the fair market value of the Company’s Common Stock on the date of grant. In accordance with accounting for such options utilizing the intrinsic value method, there is no related compensation expense recorded in the Company’s financial statements for the nine months ended September 30, 2004 and 2003. Had compensation cost for stock-based compensation been determined based on the fair value of the options at the grant dates consistent with the method of SFAS 123, the Company’s net income and earnings per share for the nine months ended September 30, 2004 and 2003 would have been reduced to the pro forma amounts presented on the next page.

9


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)

1.   Summary of Significant Accounting Policies and Use of Estimates (Continued):
 
    Stock Option Plan (Continued):

                 
    Nine Months Ended   Nine Months Ended
    September 30, 2004
  September 30, 2003
Net income, as reported
  $ 48,015     $ 443,863  
Add: Stock-based Employee compensation expense included in reported income, net of related tax effects
           
Deduct: Total stock-based Employee compensation expense determined under fair value based methods for all awards, net of related tax effects
    (49,688 )     (58,604 )
 
   
 
     
 
 
Pro forma net income (loss)
  $ (1,673 )   $ 385,259  
 
   
 
     
 
 
Basic net income (loss) per common share
               
As reported
  $ 0.01     $ 0.12  
Pro forma
    (0.00 )     0.11  
Diluted net income (loss) per common share
               
As reported
  $ 0.01     $ 0.12  
Pro forma
    (0.00 )     0.11  

     The fair value of option grants is estimated as of the date of grant utilizing the Black-Scholes option-pricing model with the following weighted average assumptions for grants in 2003: expected life of options of 3 years, expected volatility of 82.23%, risk-free interest rates of 5%, and a 0% dividend yield. The weighted average fair value at date of grant for options granted during 2003 was approximately $.82.

     The fair value of option grants is estimated as of the date of grant utilizing the Black-Scholes option-pricing model with the following weighted average assumptions for grants in 2001: expected life of options of 5 years, expected volatility of 60.85%, risk-free interest rates of 8%, and a 0% dividend yield. The weighted average fair value at date of grant for options granted during 2001 was approximately $.97.

10


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)

2.   Notes Payable:

Summary of third quarter additions to notes payable and its balance at September 30, 2004:

         
Note payable, interest rate at 5.99%, with monthly payments of $382, due August 19, 2009, collateralized by a vehicle
  $ 19,457  
Note payable, interest rate at 6.50%, with monthly principal payments of $7,342 plus interest, due September 3, 2008, collateralized by equipment
    345,070  
Note payable, interest rate at 6.50%, with monthly principal payments of $1,259 plus interest, due September 3, 2008, collateralized by equipment
    59,183  
Note payable, non-interest bearing, with monthly payments of $4,758, due July 23, 2007 (less unamortized discount of $14,107, — effective rate of 6%), collateralized by equipment
    166,547  
Note payable, interest rate at 6.70% with monthly payments of $35,976, due August 1, 2005, collateralized by the Company’s umbrella insurance policy
    348,951  
Note payable, interest rate at 5.75%, with monthly payments of $59,149, due April 20, 2006, collateralized by equipment
    1,071,748  
Note payable, interest rate at 7.05%, with monthly payments of $2,930 and a principal payment of $254,742, due August 27, 2009, collateralized by land
    323,764  
 
   
 
 
 
    2,334,720  
Less: current portion
    (1,191,030 )
 
   
 
 
 
  $ 1,143,690  
 
   
 
 

Following are maturities of the above long-term debt for each of the next five years:

         
2005
  $ 1,191,030  
2006
    583,920  
2007
    174,163  
2008
    114,529  
2009
    271,078  
 
   
 
 
 
  $ 2,334,720  
 
   
 
 

11


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)

3.   Commitments:

     During the quarter ended September 30, 2004, the Company purchased equipment under two capital lease agreements expiring August 1, 2007 and June 9, 2008. The asset and liability under each capital lease is initially recorded at the lower of the present value of the minimum lease payments or the fair value of the asset. The asset is depreciated over its expected useful life.

     Minimum future lease payments under the above-mentioned capital leases as of September 30, 2004 for each of the next four years are:

         
2005
  $ 81,348  
2006
    81,348  
2007
    75,080  
2008
    79,128  
 
   
 
 
Total minimum lease payments
    316,904  
Less: amount representing interest
    (31,649 )
 
   
 
 
Present value of net minimum lease payment
    285,255  
Less: current portion
    (67,610 )
 
   
 
 
 
  $ 217,645  
 
   
 
 

     The Company has agreed to indemnify its officers and directors for certain events or occurrences arising as a result of the officer or director’s serving in such capacity. The term of the indemnification period is for the officers’ or directors’ lifetime. The maximum potential amount of future payments the Company could be required to make under these indemnification agreements is unlimited. However, the Company has a directors and officer liability insurance policy that enables it to recover a portion of any future amounts paid. As a result of its insurance policy coverage, the Company believes the estimated fair value of these indemnification agreements is minimal and has no liabilities recorded for these agreements as of September 30, 2004.

     The Company enters into indemnification provisions under its agreements with other companies in its ordinary course of business, typically with surety companies, business partners, contractors, customers, landlords, lenders and lessors. Under these provisions the Company generally indemnifies and holds harmless the indemnified party for losses suffered or incurred by the indemnified party as a result of the Company’s activities or, in some cases, as a result of the indemnified party’s activities under the agreement. The maximum potential amount of future payments the Company could be required to make under these indemnification provisions is unlimited. The Company has not incurred material costs to defend lawsuits or settle claims related to these indemnification agreements. As a result, the Company believes the estimated fair value of these agreements is minimal. Accordingly, the Company has no liabilities recorded for these agreements as of September 30, 2004.

     As is common in the construction industry, we have entered into certain construction contracts with third parties through joint ventures. As a result of our adoption of FIN 46, we have determined that there are no Variable Interest Entities (“VIEs”) in which we need to consolidate in our financial statements as of September 30, 2004. We will account for all other such joint ventures in accordance with Emerging Issues Task Force Issue 00-01, “Investor Balance Sheet and Income Statement Display under the Equity Method for Investments in Certain Partnerships and Other Ventures.”

12


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)

4.   Statement of Cash Flows:

     Non-Cash Investing and Financing Activities:

          The Company recognized investing and financing activities that affected assets, but did not result in cash receipts or payments. These non-cash activities are as follows:

          During the nine months ended September 30, 2004 and 2003, the Company financed the purchase of equipment in the amount of $5,067,110 and $1,025,669, respectively. The Company also financed the purchase of insurance policies in the amount of $382,789 and $237,800, respectively.

          During the nine months the Company refinanced a capital lease obligation in the amount of $ 1,131,515.

5.   Litigation and Claim Matters:

          The Company is a party to legal proceedings in the ordinary course of its business. With the exception of those matters detailed below, we believe that the nature of these proceedings (which generally relate to disputes between our subcontractors, material suppliers or customers regarding payment for work performed or materials supplied) are typical for a construction firm of our size and scope, and no other pending proceedings are material to our financial condition.

          The following proceedings represent matters that may become material and have already been referred to legal counsel for further action:

Requests for Equitable Adjustment to Construction Contracts. The Company has made claims as described below on the following contracts:

  (1)   Two contracts with the New Mexico State Highway and Transportation Department – The total value of claims on these projects is $12,002,782 of which $8,336,931 is on behalf of the Company and the balance of $3,665,851 is on behalf of the prime contractor or subcontractors. The primary issues are changed conditions, plan errors and omissions, contract modifications and associated delay costs. In addition, the projects were not completed within the adjusted contract time because of events giving rise to the claims. The prosecution of the claims will include the appropriate extensions of contract time to offset any potential liquidated damages.
 
  (2)   Clark County, Nevada – A final ruling on November 1, 2004 by the three-member arbitration panel awarded MVCI approximately $5,460,000 of which $2,090,000 is due the Company and the balance of $3,370,000 is due a subcontractor. The approximate total value of the claims ruled on above was $6,833,197 of which $2,211,947 was on behalf of the Company and the balance of $4,621,250 was on behalf of a subcontractor. The Company has not recognized any additional claim receivable related to this ruling. A Previously reported partial ruling by the three-member arbitration panel rejected a significant portion of the original claim that was primarily asserted by another subcontractor on the project. The Company has filed with the District Court a Notice of and Motion to Vacate Arbitration Award on the Shoring Entitlement. The primary issues were changed conditions, constructive changes, contract modifications and associated delay costs.

          The combined total of all outstanding claims is $18,835,979. The Company’s portion of the total claims is $10,548,878 and the balance pertaining to a prime contractor or subcontractors’ claims is $8,287,101. Total claim amounts reported by the Company are approximate and are subject to revision as final documentation progresses and as issues are resolved and/or payments made. Claim amounts do not include any prejudgment interest, if applicable. Relative to the aforementioned claims, the Company has recorded $3,521,080 in cumulative claim receivable to offset a portion of costs incurred to date on the claims.

13


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)

5.   Litigation and Claim Matters (Continued):

          The Company has not accrued a liability related to the prime contractor or subcontractors’ claims as no liability would be deemed payable if their portion of the claims did not receive a favorable outcome. Correspondingly, no receivable has been recorded for overhead and profit included in their portion of the claims on the Company’s behalf.

          Although the Company believes these amounts represent a reasonably conservative posture, any claims proceeds and payments for previously unpaid quantities, unpaid change orders and pending change orders ultimately paid to the Company less than $3,521,080 will reduce income. Conversely, a payment for those same items in excess of $3,521,080 will result in increased income.

          The portion of accounts receivable pertaining to retention withheld on the contracts for which claims have been filed amounts to $880,763 as of September 30, 2004. The degree to which the Company is successful in recovering its costs from the claims may also impact the amount of retention paid by the owner. The Company believes that all retention amounts currently being held by the owners on the contracts with outstanding claims will be paid in full in accordance with the contract terms. Therefore, no allowance has been made to reduce the receivables due from the retention on the disputed contracts.

Lawsuits Filed Against Meadow Valley Contractors, Inc.

  (1)   Innovative Construction Systems, Inc. (“ICS”), District Court, Clark County, NV – ICS was a subcontractor to Meadow Valley Contractors, Inc. (MVCI) on several projects, including the Clark County project currently being arbitrated. ICS failed to make payments of payroll, pension fund contributions and other taxes for which the Internal Revenue Service garnished any future payments due ICS on MVCI’s projects. As a result, ICS failed to supply labor to perform its work and defaulted on its subcontracts. MVCI terminated the ICS subcontracts and performed the work with MVCI’s personnel. ICS alleges it was wrongfully terminated and is asserting numerous claims for damages. ICS’ claims against MVCI total approximately $15,000,000. The Company does not believe ICS’ claims have merit and intends to vigorously defend against these claims and MVCI has filed counter-claims for approximately $3,200,000 seeking to recover the damages ICS has caused MVCI through its failure to perform. MVCI and ICS have agreed to stay all actions until after the conclusion of the Clark County arbitration at which time all remaining items between MVCI and ICS will be heard before a three-person binding arbitration panel.
 
  (2)   Progressive Contracting Inc. (“PCI”), District Court, Clark County, NV – PCI was a subcontractor to MVCI on the Clark County project currently being arbitrated. PCI claims they were damaged by delays in an amount in excess of $300,000. In July 2003, PCI filed a notice of dismissal without prejudice and in February 2004 MVCI and PCI agreed to a settlement wherein PCI agrees to accept the award of damages, if any, as determined by the arbitrators in the above mentioned arbitration with Clark County. The arbitration hearing regarding MVCI’s and PCI’s claims concluded on July 30, 2004. On November 1, 2004 a final award was rendered which orders Clark County to pay damages to MVCI on behalf of PCI in the amount of approximately $3,370,000. No liability or receivable was recorded as of September 30, 2004.
 
  (3)   MVCI is defending against a claimed preference, in the Third Judicial Court of Salt Lake County, in connection with a payment made to it by an insurance company, Southern America Insurance Company, in the approximate amount of $100,000. MVCI believes that the payment is not a preference, and is vigorously defending the action.

14


Table of Contents

MEADOW VALLEY CORPORATION AND SUBSIDIARIES
NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS (Continued)

6.   Subsequent Events:

     In October 2004, the Company financed the purchase of equipment in the amount of $61,359. The note payable obligation has an interest rate of 6.5%, with a monthly payment of $1,870, and is due September 10, 2007.

     In October 2004, the Company entered into a note payable obligation in the amount of $1,100,500. The note payable obligation has an interest rate of 6.5%, with a monthly payment of $14,732, is due November 11, 2009 and is secured by equipment.

     On November 1, 2004 a final award was rendered which orders Clark County to pay damages to the Company approximately $5,460,000 of which $2,090,000 is due the Company and the balance of $3,370,000 is due a subcontractor. No liability or receivable was recorded as of September 30, 2004.

7.   Segment Information:

     The Company manages and operates two segments, construction services and construction materials. The construction services segment provides construction services to a broad range of public and some private customers primarily in the western states of Arizona, Nevada and Utah. Through this segment, the Company performs heavy civil construction such as the construction of bridges and overpasses, channels, roadways, highways and airport runways. The construction materials segment manufactures and distributes ready mix concrete and sand and gravel products in the Las Vegas, Nevada and Phoenix, Arizona metropolitan areas. Material customers include concrete subcontractors, prime contractors, homebuilders, commercial and industrial property developers, pool builders and homeowners. The construction materials segment operates out of two locations in the Las Vegas, Nevada vicinity, one location in the Moapa, Nevada vicinity and two locations in the Phoenix, Arizona vicinity.

                                 
    Nine Months Ended September 30,
    2004
  2003
    Construction
  Construction
(dollars in thousands)
  Services
  Materials
  Services
  Materials
Gross revenue
  $ 80,321     $ 44,758     $ 84,053     $ 33,091  
Intercompany revenue
          98             134  
Cost of revenue
    80,194       39,881       81,571       29,979  
Interest income
    32       16       41       6  
Interest expense
    (153 )     (106 )     (216 )     (167 )
Depreciation and amortization
    1,168       1,123       1,130       928  
Income (loss) before taxes
    (2,803 )     2,880       (496 )     1,206  
Income tax benefit (expense)
    1,051       (1,080 )     186       (452 )
Net income (loss)
    (1,752 )     1,800       (310 )     754  
Total assets
    34,902       20,403       40,263       15,056  

     There are no differences in accounting principles between the segments. All costs related to the holding company and centrally incurred costs are allocated to the construction services segment. Intercompany revenue is eliminated at cost to arrive at consolidated revenue and cost of revenue.

15


Table of Contents

Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

Forward-Looking Disclosure

     This Quarterly Report on Form 10-Q contains “forward-looking statements” within the meaning of the “safe harbor” provision of the Private Securities Litigation Reform Act of 1995 regarding future events and the future results of Meadow Valley Corporation that are based on current expectations, estimates, forecasts, and projects as well as the beliefs and assumptions of Meadow Valley’s management. Words such as “outlook”, “believes”, “expects”, “appears”, “may”, “will”, “should”, “anticipates” or the negative thereof or comparable terminology, are intended to identify such forward-looking statements. These forward-looking statements are only predictions and are subject to risks, uncertainties and assumptions that are difficult to predict. Therefore, actual results may differ materially and adversely from those expressed in any forward-looking statements. Factors that might cause or contribute to such differences include, but are not limited to those discussed in our Annual Report on Form 10-K under the section entitled “Risk Factors”. You should not place undue reliance on these forward-looking statements, which speak only as of the date of this Quarterly Report. Meadow Valley Corporation undertakes no obligation to revise or update publicly any forward-looking statements for any reason.

General

     The following is management’s discussion and analysis of certain significant factors affecting the Company’s financial position and operating results during the periods included in the accompanying condensed consolidated financial statements.

     Except for the historical information contained herein, the matters set forth in this report are forward-looking statements.

     Revenue on uncompleted fixed price contracts is recorded under the percentage-of-completion method of accounting. We begin to recognize revenue on our contracts when we first accrue direct costs. Contracts often involve work periods in excess of one year and revisions in cost and profit estimates during construction are reflected in the accounting period in which the facts that require the revisions become known. Losses on contracts, if any, are provided for in total when determined, regardless of the percent complete.

     In general, labor, equipment and disposable materials tend to be the types of costs with the greatest uncertainty, and, therefore, have the greatest risk of variation from budgeted costs. Permanent materials and subcontract costs tend to be more predictable and, to a greater degree, can be fixed for the duration of the contract, thus have less risk of variation from the original estimate. In recent months, however, nearly the entire United States construction industry has been impacted by materials shortages and rising costs of key commodities such as steel, cement and petroleum-based products. To-date we have managed to avoid material deterioration of profit margins due to untimely delivery of important construction materials or from rapidly rising costs of the same, but have not escaped constrained revenue from the construction materials segment caused by cement powder allocations or from minor cost overruns due to rising costs of raw materials in our construction services segment. Certainly, a significant and unforeseen rise in the cost of crude oil could negatively impact our performance. Likewise, prolonged shortages of raw materials could delay progress on projects, cause cost overruns and potentially erode profit margins.

Overview

     We have accomplished many positive results to-date this year. Our construction materials segment has had continued growth without sacrificing profitability. We have secured a site in Southwest Las Vegas to expand our footprint in that market. We have acquired the parcel of land on which our Southeast Phoenix operation resides, thereby securing, for the long term, our facility location in that market. Our construction services segment recognized a recovery of costs, previously recognized as a loss, on the settlement with New Mexico of approximately $1,770,000. Our construction services segment has also had improvements in its overall profitability of new work, which is currently being overshadowed by one project in Utah, the Gooseberry Project. We have recognized additional losses year-to-date of approximately $3,760,000 related to this project. We believe that we have recognized the total anticipated loss on the Gooseberry Project, but we can not assure that there may not be additional future losses. This project is scheduled for completion, weather permitting, in 2004.

16


Table of Contents

     Our backlog (anticipated revenue from the uncompleted portions of awarded projects) was approximately $103.6 million at September 30, 2004, compared to approximately $71.7 million at September 30, 2003. At September 30, 2004, our backlog includes approximately $27.0 million of work that is scheduled for completion during 2004.

     As of September 30, 2004, the total amount of contract claims filed by us with various public entities was $18,835,979. Of that sum, our portion is $10,548,878 and the balance of $8,287,101 pertains to other parties relating to the various contracts. Total claim amounts reported in our filings are approximate and are subject to revision as final documentation, resolution of issues, settlements progress and/or payments are made. Relative to the aforementioned claims, we have recorded $3,521,080 in cumulative claim receivable to offset a portion of the costs incurred to-date on the claims. We segregate our claims receivable between current and long-term assets based on the resolution of specific claims, or portion of claims, and as collection of funds is determined. In the accompanying balance sheets, the current and the long-term portion of the claims receivable were in the amounts of $0 and $3,521,080 as of September 30, 2004 and $4,101,898 and $3,521,080 as of December 31, 2003.

     Although we believe that the claims receivable amounts represent a reasonably conservative posture, any claims proceeds ultimately paid to us less than the aggregate amount recorded on the balance sheet of $3,521,080, will decrease earnings. Conversely, a payment for those same items in excess of $3,521,080 will result in increased income.

     As of September 30, 2004, the portion of accounts receivable pertaining to retention withheld on the contracts for which claims have been filed amounts to $880,763. The degree to which we are successful in recouping our costs from the claims may also impact the amount of retention paid by the owner. We believe that all retention amounts currently being held by the owners on the contracts with outstanding claims will be paid in full in accordance with the contract terms. Therefore, no allowance has been made to reduce the receivables due from the retention on the disputed contract.

Critical Accounting Policies, Estimates and Judgments

     Significant accounting policies are described in the audited consolidated financial statements and notes thereto included in our Annual Report on Form 10-K for the year ended December 31, 2003. We believe our most critical accounting policies are the revenue recognition and cost estimation on certain contracts for which we use a percentage-of-completion accounting method, our allowance for doubtful accounts and the allowance for slow moving inventory. The revenue recognition and cost estimation accounting method is applied by our construction services segment to heavy construction projects executed under multi-year contracts with various customers.

     Revenues and costs from fixed-price and modified fixed-price construction contracts are recognized for each contract on the percentage-of-completion method, measured by the percentage of costs incurred to date to the estimated total of direct costs. Direct costs include, among other things, direct labor, field labor, equipment rent, subcontracting, direct materials, and direct overhead. General and administrative expenses are accounted for as period costs and are, therefore, not included in the calculation of the estimates to complete construction contracts in progress. Project losses are provided for in the period in which such losses are determined, without reference to the percentage-of-completion. As contracts can extend over one or more accounting periods, revisions in costs and earnings estimated during the course of the work are reflected during the accounting period in which the facts that required such revisions become known.

     The asset “costs and estimated earnings in excess of billings on uncompleted contracts” represents revenue recognized in excess of amounts billed. The liability “billings in excess of costs and estimated earnings on uncompleted contracts” represents billings in excess of revenues recognized.

     The complexity of the estimation process and all issues related to the assumptions, risks and uncertainties inherent with the application of the percentage-of-completion method of accounting affects the amounts reported in our financial statements. A number of internal and external factors affect our percentage-of-completion estimates, including labor rate and efficiency variances, estimated future material prices and customer specification changes. If our business conditions were different, or if we used different assumptions in the application of this accounting policy, it is likely that materially different amounts would be reported in our financial statements.

17


Table of Contents

     We are also required to estimate the collectibility of our account receivables. A considerable amount of judgment is required in assessing the realization of these receivables, including the current creditworthiness of each customer and the related aging of the past due balances. Our provision for bad debts at September 30, 2004 and December 31, 2003 amounted to $571,132 and $710,153, respectively. We determine our reserve by using percentages applied to certain aged receivable categories, percentages of certain types of revenue generated and identification of any receivable in which management deems collection is not probable.

     In addition, we are required to state our inventories at the lower of cost or market. In assessing the ultimate realization of inventories, we are required to make judgments as to the future demand requirements and compare these with the current inventory levels. Our reserve requirements generally increase as our projected demand requirements decrease due to market conditions and longer than expected usage periods. At September 30, 2004 and December 31, 2003, inventories of $830,186 and $1,249,118, are net of reserves of $1,379,301 and $1,186,197, respectively. It is possible that significant changes in required inventory reserves may continue to occur in the future if there is a further change in market conditions and our ability to market and sell our inventory.

     As discussed elsewhere in this filing, we have disclosed various litigation and claims matters. These issues involve significant estimates and judgments, which may materially change in future periods due to changes in circumstances.

Results of Operations

     The following table sets forth, for the nine months and the three months ended September 30, 2004 and 2003, certain items derived from our condensed consolidated statements of operations expressed as a percentage of revenue.

                                 
    Nine Months Ended   Three Months Ended
    September 30,
  September 30,
    2004
  2003
  2004
  2003
Revenue
    100.0 %     100.0 %     100.0 %     100.0 %
Gross Profit
    4.0 %     4.8 %     2.2 %     3.3 %
General and administrative expenses
    3.7 %     4.3 %     3.8 %     4.4 %
Interest income
    0.0 %     0.0 %     0.0 %     0.0 %
Interest expense
    -0.2 %     -0.3 %     -0.1 %     -0.3 %
Other income
    0.0 %     0.4 %     0.1 %     1.0 %
Income (loss) before income taxes
    0.1 %     0.6 %     -1.6 %     -0.4 %
Income tax benefit (expense)
    0.0 %     -0.2 %     0.6 %     0.2 %
Net income (loss)
    0.1 %     0.4 %     -1.0 %     -0.2 %

Nine Months Ended September 30, 2004 Compared to Nine Months Ended September 30, 2003

     Revenue and Backlog. Consolidated revenue for the nine months ended September 30, 2004 (“interim 2004”) was $125.0 million compared to $117.0 million for the nine months ended September 30, 2003 (“interim 2003”). The increase in revenue was the result of a $11.7 million increase in revenue from the construction materials segment, offset by a $3.7 million decrease in the construction services segment. The increase in the construction materials segment was due primarily to an increase in unit volume sales. Volume increased by approximately 27% in interim 2004 from interim 2003; in addition the average unit sales price increased approximately 5.9% in interim 2004 from interim 2003. The primary reason for the increased volume was the addition of 10 ready mix trucks in the first quarter and our ability to utilize our equipment to a greater extent. The average unit sales price increase was due largely to our ability to pass along an increase in the cost of cement. The construction services segment revenue was impacted less by the amount of the beginning backlog and more so by the progress schedules and nature of the contracts contained in the backlog at the beginning of interim 2004, and the favorable outcome of the New Mexico settlement. As previously mentioned we have recognized additional losses of approximately $3,760,000 related to the Gooseberry Project, which in effect reduces the revenue of the construction services segment. Backlog as of September 30, 2004 was $103.6 million compared to $71.7 million at September 30, 2003. Because so much of our business stems from competitively bid public works, backlog will fluctuate

18


Table of Contents

depending upon the amount and type of contracts that we bid on and win. Bid bonds provided by our surety company are required on most of the contracts that we bid, therefore, any restrictions or limitations in the extension of surety credit can impact the amount and type of contracts available to be bid.

     Gross Profit. Consolidated gross profit decreased to $5.0 million for interim 2004 from $5.6 million for interim 2003 and consolidated gross margin, as a percent of revenue, decreased to 4.0% in interim 2004 from 4.8% in interim 2003. Gross profit from construction services decreased to $.1 million in interim 2004 from $2.5 million in interim 2003, the gross profit margin decreased to .2% compared to 3.0% in the respective periods. The decrease in gross profit in the construction services segment was primarily due to the Gooseberry Project, by recognizing an additional estimated loss at completion of approximately $3.8 million, otherwise the gross profit margin would have improved significantly. Gross profit margins are affected by a variety of factors including construction delays and difficulties due to weather conditions, availability of materials, the timing of work performed by other subcontractors and the physical and geological condition of the construction site, therefore the gross profit margin in interim 2004 may not be indicative of the annual gross profit margin. Gross profit from construction materials increased to $4.9 million in interim 2004 from $3.1 million in interim 2003 and the gross profit margin increased to 10.9% from 9.4% in the respective periods. The increase in the gross profit margin in the construction materials segment during interim 2004 is the result of the average unit sales price increasing approximately 5.9% in interim 2004 from interim 2003. The increase in the average unit price is our ability to pass on additional costs to our customers, such as raw materials and transportation of those materials, and our ability to increase our unit volume of sales.

     General and Administrative Expenses. General and administrative expenses decreased to $4.7 million for interim 2004 from $5.0 million for interim 2003. The decrease resulted primarily from a $.2 million decrease in bad debt expense and a $.1 million decrease in outside consulting expense.

     Interest Income and Expense. Interest income for interim 2004 remained flat at $.05 million as compared to interim 2003. Interest expense for interim 2004 decreased to $.26 million from $.38 million for interim 2003 as a result of the reduction of our non-equipment related debt. Interest expense directly related to equipment is expensed as a cost of the equipment and is included in the cost of revenue.

Three Months Ended September 30, 2004 Compared to Three Months Ended September 30, 2003

     Revenue and Backlog. Consolidated revenue for the three months ended September 30, 2004 (“interim 2004”) was $42.1 million compared to $42.8 million for the three months ended September 30, 2003 (“interim 2003”). The decrease in revenue was the result of a $5.2 million increase in revenue from the construction materials segment, offset by a $5.9 million decrease in revenue from the construction services segment. The increase in the construction materials segment was due primarily to an increase in volume sales. Volume increased by approximately 37% in interim 2004 from interim 2003; the average unit sales price increased approximately 8.6% in interim 2004 from interim 2003. The primary reason for the increased volume was the addition of 10 ready mix trucks in the first quarter of 2004. The average unit sales price increase was due largely to our ability to pass along to our customers an increase in the cost of cement. The construction services segment revenue was impacted less by the amount of the beginning backlog and more so by the progress schedules and nature of the contracts contained in the backlog at the beginning of interim 2004 and also affected by the recognition of approximately $2.6 million of additional losses on the Gooseberry project during the quarter.

     Gross Profit. Consolidated gross profit decreased to $.9 million for interim 2004 from $1.4 million for interim 2003 and consolidated gross margin, as a percent of revenue, decreased to 2.2% in interim 2004 from 3.3% in interim 2003. Gross profit from construction services decreased to a loss of $1.1 million in interim 2004 compared to $.5 million in interim 2003 and the gross profit margin decreased to -4.2% from 1.6% in the respective periods. The decrease in the gross profit margin during the quarter was due to additional losses recognized on the Gooseberry project in the amount of approximately $2.6 million. Gross profit margins are affected by a variety of factors including construction delays and difficulties due to weather conditions, availability of materials, the timing of work performed by other subcontractors and the physical and geological condition of the construction site, therefore the gross profit in interim 2004 may not be indicative of the annual gross profit margin. Gross profit from construction materials increased to $2.0 million in interim 2004 from $.9 million in interim 2003 and the gross profit margin increased to 12.5% from 8.2% in the respective periods. The increase in the gross profit margin in the

19


Table of Contents

construction materials segment during interim 2004 is the result of our ability to pass on the additional costs, such as raw materials and transportation of those materials, to our customers and increased unit volume sales.

     General and Administrative Expenses. General and administrative expenses decreased to $1.6 million for interim 2004 from $1.9 million for interim 2003. A decrease of $.2 million in bad debt expense represents a significant portion of the decrease.

     Interest Income and Expense. Interest income for interim 2004 decreased to $.00 million from $.01 million for interim 2003 as a result of less cash reserves during the interim 2004 as compared to interim 2003. Interest expense for interim 2004 decreased to $.06 million from $.12 million for interim 2003 as a result of the reduction of our non-equipment related debt. Interest expense directly related to equipment is expensed as a cost of the equipment and is included in the cost of revenue.

Liquidity and Capital Resources

     Low levels of working capital make our financial well being sensitive to even small changes in profitability. As of September 30, 2004 and December 31, 2003 working capital was $1,711,744 and $5,210,466, respectively. Working capital will remain limited until such time that the claims receivable are collected. The Company continues efforts to improve working capital through judicious use of long term debt to make needed capital expenditures.

     Currently our primary need for capital is to finance the expansion and support the growth of our construction materials business. During the quarter we acquired a parcel of land in the Southeast Phoenix metropolitan area where we had previously leased a batch plant site. We are continuing our investigation into alternative sites in the Southwest Phoenix metropolitan area to eventually locate a third ready mix facility. Our expansion plan in the Southwest Las Vegas metropolitan area should break ground by year end. Historically, our primary source of cash has been from operations, however, we are also inquiring into the availability of a credit facility which will aid in this expansion and general business operations.

     The following table sets forth for the nine months ended September 30, 2004 and 2003, certain items from the condensed consolidated statements of cash flows.

                 
    Nine Months Ended
    September 30,
    2004
  2003
Cash Flows Provided by Operating Activities
  $ 7,591,489     $ 2,404,024  
Cash Flows Provided by (Used in) Investing Activities
    (1,574,754 )     1,077,912  
Cash Flows Used in Financing Activities
    (3,726,456 )     (3,944,878 )

     Cash provided by operating activities during interim 2004 of $7.6 million represents a $5.2 million increase from the amount provided by operating activities during interim 2003. The change was primarily due to the increased collection of our claim receivable in the amount of $3.4 million and an increase in our accounts receivable collections.

     Cash used in investing activities during interim 2004 of $1.6 million represents a $2.7 decrease from the amount provided by investing activates during interim 2003. Investing activities during interim 2004 was due primarily to capital expenditures of $2.9 million, offset by cash received from the disposal of assets of $1.2 million and a reduction of $.1 million in restricted cash. Investing activities during interim 2003 included cash received from the disposal of assets of $.4 million, a reduction of $.1 million in restricted cash and proceeds of $.9 million from the disposal of land held for sale, offset by capital expenditures of $.4 million.

     Cash used in financing activities during interim 2004 of $3.7 million represents a $.2 million decrease from the amount used in financing activities during interim 2003. Financing activities during interim 2004 was due to the receipt of $.2 million in loan proceeds and the repayment of notes payable and capital lease obligations of $3.9 million. Financing activities during interim 2003 included the repayment of notes payable and capital lease obligation of $3.9 million.

20


Table of Contents

Website Access

     Our website address is www.meadowvalley.com. On our website we make available, free of charge, our annual report on Form 10-K, our most recent quarterly reports on Form 10-Q, current reports on Form 8-K, Forms 3, 4, and 5 related to Beneficial Ownership of Securities, and all amendments to those reports as soon as reasonably practicable after such material is electronically filed with or furnished to the United States Securities and Exchange Commission. In addition, we have a copy of our code of ethics. The information on our website is not incorporated into, and is not part of, this report.

Item 3. Quantitative and Qualitative Disclosure About Market Risk

     There was no significant change in our exposure to market risk during the nine months ended September 30, 2004.

Item 4. Controls and Procedures

     We carried out an evaluation, under the supervision of and with the participation of management, including our Chief Executive Officer and our Principal Accounting Officer, of the design and operation of our disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934, as amended as of September 30, 2004. Based on this evaluation, our Chief Executive Officer and Principal Accounting Officer concluded that our disclosure controls and procedures were effective as of the end of the period covered by this report.

     There was no change in our internal control over financial reporting during the quarter ended September 30, 2004 that materially affected, or is reasonably likely to materially affect our internal control over financial reporting.

PART II – OTHER INFORMATION

Item 1. Legal Proceedings

     We are a party to legal proceedings in the ordinary course of our business. With the exception of those matters detailed below, we believe that the nature of these proceedings (which generally relate to disputes between our subcontractors, material suppliers or customers regarding payment for work performed or materials supplied) are typical for a construction firm of our size and scope, and no other pending proceedings are material to our financial condition.

     The following proceedings represent matters that may become material and have already been referred to legal counsel for further action:

Requests for Equitable Adjustment to Construction Contracts. We have made claims as described below on the following contracts:

  (1)   Two contracts with the New Mexico State Highway and Transportation Department – The total value of claims on these projects is $12,002,782 of which $8,336,931 is on our behalf and the balance of $3,665,851 is on behalf of the prime contractor or subcontractors. The primary issues are changed conditions, plan errors and omissions, contract modifications and associated delay costs. In addition, the projects were not completed within the adjusted contract time because of events giving rise to the claims. The prosecution of the claims will include the appropriate extensions of contract time to offset any potential liquidated damages.
 
  (2)   Clark County, Nevada – A final ruling on November 1, 2004 by the three-member arbitration panel awarded us approximately $5,460,000 of which $2,090,000 is due and the balance of $3,370,000 is due a subcontractor. The approximate total value of the claims ruled on above was $6,833,197 of which $2,211,947 was on our behalf and the balance of $4,621,250 was on behalf of a subcontractor. We

21


Table of Contents

have not recognized any additional claim receivable related to this ruling. A previously reported partial ruling by the three-member arbitration panel rejected a significant portion of the original claim that was primarily asserted by another subcontractor on the project. We have filed with the District Court a Notice of and Motion to Vacate Arbitration Award on the Shoring Entitlement. The primary issues were changed conditions, constructive changes, contract modifications and associated delay costs.

     The combined total of all outstanding claims is $18,835,979. Our portion of the total claims is $10,548,878 and the balance pertaining to a prime contractor or subcontractors’ claims is $8,287,101. Total claim amounts we reported are approximate and are subject to revision as final documentation progresses and as issues are resolved and/or payments made. Claim amounts do not include any prejudgment interest, if applicable. Relative to the aforementioned claims, we have recorded $3,521,080 in cumulative claim receivable to offset a portion of costs incurred to date on the claims.

     We have not accrued a liability related to the prime contractor or subcontractors’ claims as no liability would be deemed payable if their portion of the claims did not receive a favorable outcome. Correspondingly, no receivable has been recorded for overhead and profit included in their portion of the claims on our behalf.

     Although we believe these amounts represent a reasonably conservative posture, any claims proceeds and payments for previously unpaid quantities, unpaid change orders and pending change orders ultimately paid to us less than $3,521,080 will reduce income. Conversely, a payment for those same items in excess of $3,521,080 will result in increased income.

     The portion of accounts receivable pertaining to retention withheld on the contracts for which claims have been filed amounts to $880,763 as of September 30, 2004. The degree to which we are successful in recovering our costs from the claims may also impact the amount of retention paid by the owner. We believe that all retention amounts currently being held by the owners on the contracts with outstanding claims will be paid in full in accordance with the contract terms. Therefore, no allowance has been made to reduce the receivables due from the retention on the disputed contracts.

Lawsuits Filed Against Meadow Valley Contractors, Inc.

  (1)   Innovative Construction Systems, Inc. (“ICS”), District Court, Clark County, NV – ICS was a subcontractor to Meadow Valley Contractors, Inc. (MVCI) on several projects, including the Clark County project currently being arbitrated. ICS failed to make payments of payroll, pension fund contributions and other taxes for which the Internal Revenue Service garnished any future payments due ICS on MVCI’s projects. As a result, ICS failed to supply labor to perform its work and defaulted on its subcontracts. MVCI terminated the ICS subcontracts and performed the work with MVCI’s personnel. ICS alleges it was wrongfully terminated and is asserting numerous claims for damages. ICS’ claims against MVCI total approximately $15,000,000. The Company does not believe ICS’ claims have merit and intends to vigorously defend against these claims and MVCI has filed counter-claims for approximately $3,200,000 seeking to recover the damages ICS has caused MVCI through its failure to perform. MVCI and ICS have agreed to stay all actions until after the conclusion of the Clark County arbitration at which time all remaining items between MVCI and ICS will be heard before a three-person binding arbitration panel.
 
  (2)   Progressive Contracting Inc. (“PCI”), District Court, Clark County, NV – PCI was a subcontractor to MVCI on the Clark County project currently being arbitrated. PCI claims they were damaged by delays in an amount in excess of $300,000. In July 2003, PCI filed a notice of dismissal without prejudice and in February 2004 MVCI and PCI agreed to a settlement wherein PCI agrees to accept the award of damages, if any, as determined by the arbitrators in the above mentioned arbitration with Clark County. The arbitration hearing regarding MVCI’s and PCI’s claims concluded on July 30, 2004. On November 1, 2004 a final award was rendered which orders Clark County to pay damages to MVCI on behalf of PCI in the amount of approximately $3,370,000. No liability or receivable was recorded as of September 30, 2004.

22


Table of Contents

  (3)   MVCI is defending against a claimed preference, in the Third Judicial Court of Salt Lake County, in connection with a payment made to it by an insurance company, Southern America Insurance Company, in the approximate amount of $100,000. MVCI believes that the payment is not a preference, and is vigorously defending the action.

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds

None

Item 3. Defaults Upon Senior Securities

None

Item 4. Submission of Matters to a Vote of Security Holders

None

Item 5. Other Information

None

Item 6. Exhibits

  a.   Exhibits:

       
 
31.11
  Certification of Chief Executive Officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
 
   
 
31.12
  Certification of Principal Accounting Officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
 
   
 
32.6
  Certifications of Chief Executive Officer and Principal Accounting Officer pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.

SIGNATURE

Pursuant to the requirements of the Securities and Exchange Act as of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned thereunto duly authorized.
         
  MEADOW VALLEY CORPORATION
(Registrant)
 
 
  By /s/ Bradley E. Larson    
  Bradley E. Larson   
  President and Chief Executive Officer   
 
         
     
  By /s/ Clint Tryon    
  Clint Tryon   
  Principal Accounting Officer   
 

23