XML 43 R11.htm IDEA: XBRL DOCUMENT v3.8.0.1
Contingencies and Regulatory Matters
3 Months Ended
Mar. 31, 2018
Commitments and Contingencies Disclosure [Abstract]  
CONTINGENCIES AND REGULATORY MATTERS
CONTINGENCIES AND REGULATORY MATTERS
See Note 3 to the financial statements of the registrants in Item 8 of the Form 10-K for information relating to various lawsuits, other contingencies, and regulatory matters.
General Litigation Matters
Each registrant is subject to certain claims and legal actions arising in the ordinary course of business. In addition, the business activities of Southern Company's subsidiaries are subject to extensive governmental regulation related to public health and the environment, such as regulation of air emissions and water discharges. Litigation over environmental issues and claims of various types, including property damage, personal injury, common law nuisance, and citizen enforcement of environmental requirements such as air quality and water standards, has occurred throughout the U.S. This litigation has included claims for damages alleged to have been caused by CO2 and other emissions, CCR, and alleged exposure to hazardous materials, and/or requests for injunctive relief in connection with such matters.
The ultimate outcome of such pending or potential litigation against each registrant and any subsidiaries cannot be predicted at this time; however, for current proceedings not specifically reported herein, management does not anticipate that the ultimate liabilities, if any, arising from such current proceedings would have a material effect on such registrant's financial statements.
On March 2, 2018, the Alabama Department of Environmental Management (ADEM) issued proposed administrative orders assessing a penalty of $1.25 million to Alabama Power for unpermitted discharge of fluids and/or pollutants to groundwater at five electric generating plants. The proposed orders also require the submission to the ADEM of a plan with a schedule for implementation of a comprehensive groundwater investigation, including an assessment of corrective measures, a report evaluating any deficiencies at the facilities that may have led to the unpermitted discharges, and quarterly progress reports. Alabama Power is awaiting finalization of the orders. The ultimate outcome of this matter cannot be determined at this time.
Southern Company
In January 2017, a purported securities class action complaint was filed against Southern Company, certain of its officers, and certain former Mississippi Power officers in the U.S. District Court for the Northern District of Georgia, Atlanta Division, by Monroe County Employees' Retirement System on behalf of all persons who purchased shares of Southern Company's common stock between April 25, 2012 and October 29, 2013. The complaint alleges that Southern Company, certain of its officers, and certain former Mississippi Power officers made materially false and misleading statements regarding the Kemper County energy facility in violation of certain provisions under the Securities Exchange Act of 1934, as amended. The complaint seeks, among other things, compensatory damages and litigation costs and attorneys' fees. In June 2017, the plaintiffs filed an amended complaint that provided additional detail about their claims, increased the purported class period by one day, and added certain other former Mississippi Power officers as defendants. In July 2017, the defendants filed a motion to dismiss the plaintiffs' amended complaint with prejudice, to which the plaintiffs filed an opposition in September 2017. On March 29, 2018, the U.S. District Court for the Northern District of Georgia, Atlanta Division, issued an order granting, in part, the defendants' motion to dismiss. The court dismissed certain claims against certain officers of Southern Company and Mississippi Power and dismissed the allegations related to a number of the statements that plaintiffs challenged as being false or misleading. On April 26, 2018, the defendants filed a motion for reconsideration of the court's order, seeking the dismissal of the remaining claims in the lawsuit.
In February 2017, Jean Vineyard filed a shareholder derivative lawsuit and, in May 2017, Judy Mesirov filed a shareholder derivative lawsuit, each in the U.S. District Court for the Northern District of Georgia. Each of these lawsuits names as defendants Southern Company, certain of its directors, certain of its officers, and certain former Mississippi Power officers. In August 2017, these two shareholder derivative lawsuits were consolidated in the U.S. District Court for the Northern District of Georgia and the court has deferred the consolidated case until after certain further action in the purported securities class action complaint discussed above. The complaints allege that the defendants caused Southern Company to make false or misleading statements regarding the Kemper County energy facility cost and schedule. Further, the complaints allege that the defendants were unjustly enriched and caused the waste of corporate assets and also allege that the individual defendants violated their fiduciary duties. Each plaintiff seeks to recover, on behalf of Southern Company, unspecified actual damages and, on each plaintiff's own behalf, attorneys' fees and costs in bringing the lawsuit. Each plaintiff also seeks certain changes to Southern Company's corporate governance and internal processes.
In May 2017, Helen E. Piper Survivor's Trust filed a shareholder derivative lawsuit in the Superior Court of Gwinnett County, State of Georgia that names as defendants Southern Company, certain of its directors, certain of its officers, and certain former Mississippi Power officers. The complaint alleges that the individual defendants, among other things, breached their fiduciary duties in connection with schedule delays and cost overruns associated with the construction of the Kemper County energy facility. The complaint further alleges that the individual defendants authorized or failed to correct false and misleading statements regarding the Kemper County energy facility schedule and cost and failed to implement necessary internal controls to prevent harm to Southern Company. The plaintiff seeks to recover, on behalf of Southern Company, unspecified actual damages and disgorgement of profits and, on its behalf, attorneys' fees and costs in bringing the lawsuit. The plaintiff also seeks certain unspecified changes to Southern Company's corporate governance and internal processes. The court has deferred the lawsuit until after certain further action in the purported securities class action complaint discussed above.
Southern Company believes these legal challenges have no merit; however, an adverse outcome in any of these proceedings could have an impact on Southern Company's results of operations, financial condition, and liquidity. Southern Company will vigorously defend itself in these matters, the ultimate outcome of which cannot be determined at this time.
Georgia Power
In 2011, plaintiffs filed a putative class action against Georgia Power in the Superior Court of Fulton County, Georgia alleging that Georgia Power's collection in rates of municipal franchise fees (all of which are remitted to municipalities) exceeded the amounts allowed in orders of the Georgia PSC and alleging certain state tort law claims. In 2016, the Georgia Court of Appeals reversed the trial court's previous dismissal of the case and remanded the case to the trial court for further proceedings. Georgia Power filed a petition for writ of certiorari with the Georgia Supreme Court, which was granted in August 2017. A decision from the Georgia Supreme Court is expected in late 2018. Georgia Power believes the plaintiffs' claims have no merit and intends to vigorously defend itself in this matter. The ultimate outcome of this matter cannot be determined at this time.
Mississippi Power
In 2016, a complaint against Mississippi Power was filed in Harrison County Circuit Court (Circuit Court) by Biloxi Freezing & Processing Inc., Gulfside Casino Partnership, and John Carlton Dean, which was amended and refiled to include, among other things, Southern Company as a defendant. The individual plaintiff alleges that Mississippi Power and Southern Company violated the Mississippi Unfair Trade Practices Act. All plaintiffs have alleged that Mississippi Power and Southern Company concealed, falsely represented, and failed to fully disclose important facts concerning the cost and schedule of the Kemper County energy facility and that these alleged breaches have unjustly enriched Mississippi Power and Southern Company. The plaintiffs seek unspecified actual damages and punitive damages; ask the Circuit Court to appoint a receiver to oversee, operate, manage, and otherwise control all affairs relating to the Kemper County energy facility; ask the Circuit Court to revoke any licenses or certificates authorizing Mississippi Power or Southern Company to engage in any business related to the Kemper County energy facility in Mississippi; and seek attorney's fees, costs, and interest. The plaintiffs also seek an injunction to prevent any Kemper County energy facility costs from being charged to customers through electric rates. In June 2017, the Circuit Court ruled in favor of motions by Southern Company and Mississippi Power and dismissed the case. In July 2017, the plaintiffs filed notice of an appeal.
Southern Company and Mississippi Power believe this legal challenge has no merit; however, an adverse outcome in this proceeding could have a material impact on Southern Company's and Mississippi Power's results of operations, financial condition, and liquidity. Southern Company and Mississippi Power will vigorously defend itself in this matter, the ultimate outcome of which cannot be determined at this time.
Southern Power
During 2015, Southern Power indirectly acquired a 51% membership interest in RE Roserock LLC (Roserock), the owner of the Roserock facility in Pecos County, Texas, which was under construction by Recurrent Energy, LLC and was subsequently placed in service in November 2016. Prior to placing the facility in service, certain solar panels were damaged during installation. While the facility currently is generating energy consistent with operational expectations and PPA obligations, Southern Power is pursuing remedies under its insurance policies and other contracts to repair or replace these solar panels. In connection therewith, Southern Power is withholding payments of approximately $26 million from the construction contractor, who has placed a lien on the Roserock facility for the same amount. The amounts withheld are included in other accounts and notes payable and other current liabilities on Southern Company's consolidated balance sheets and other accounts payable and other current liabilities on Southern Power's consolidated balance sheets. In May 2017, Roserock filed a lawsuit in the state district court in Pecos County, Texas, against XL Insurance America, Inc. (XL) and North American Elite Insurance Company (North American Elite) seeking recovery from an insurance policy for damages resulting from a hail storm and certain installation practices by the construction contractor, McCarthy Building Companies, Inc. (McCarthy). Also in May 2017, Roserock filed a separate lawsuit against McCarthy in the state district court in Travis County, Texas alleging breach of contract and breach of warranty for the damages sustained at the Roserock facility, which has since been moved to the U.S. District Court for the Western District of Texas. Additionally in May 2017, McCarthy filed a counter lawsuit against Roserock, Array Technologies, Inc., Canadian Solar (USA), Inc., XL, and North American Elite in the U.S. District Court for the Western District of Texas alleging, among other things, breach of contract, and requesting foreclosure of mechanic's liens against Roserock. In July 2017, the U.S. District Court for the Western District of Texas consolidated the two pending lawsuits. In December 2017, the U.S. District Court for the Western District of Texas dismissed McCarthy's claims against Canadian Solar (USA), Inc. and dismissed cross-claims that XL and North American Elite had sought to bring against Roserock. Southern Power intends to vigorously pursue and defend these matters, the ultimate outcome of which cannot be determined at this time.
Environmental Matters
Environmental Remediation
The Southern Company system must comply with environmental laws and regulations governing the handling and disposal of waste and releases of hazardous substances. Under these various laws and regulations, the Southern Company system could incur substantial costs to clean up affected sites. The traditional electric operating companies and the natural gas distribution utilities in Illinois, New Jersey, Georgia, and Florida have all received authority from their respective state PSCs or other applicable state regulatory agencies to recover approved environmental compliance costs through regulatory mechanisms. These regulatory mechanisms are adjusted annually or as necessary within limits approved by the state PSCs or other applicable state regulatory agencies.
Georgia Power's environmental remediation liability was $22 million as of both March 31, 2018 and December 31, 2017. Georgia Power has been designated or identified as a potentially responsible party at sites governed by the Georgia Hazardous Site Response Act and/or by the federal Comprehensive Environmental Response, Compensation, and Liability Act, and assessment and potential cleanup of such sites is expected.
Gulf Power's environmental remediation liability includes estimated costs of environmental remediation projects of approximately $49 million and $52 million as of March 31, 2018 and December 31, 2017, respectively. These estimated costs primarily relate to site closure criteria by the Florida Department of Environmental Protection (FDEP) for potential impacts to soil and groundwater from herbicide applications at Gulf Power's substations. The schedule for completion of the remediation projects is subject to FDEP approval.
Southern Company Gas' environmental remediation liability was $369 million and $388 million as of March 31, 2018 and December 31, 2017, respectively, based on the estimated cost of environmental investigation and remediation associated with known current and former manufactured gas plant operating sites. These environmental remediation expenditures are recoverable from customers through rate mechanisms approved by the applicable state regulatory agencies of the natural gas distribution utilities, with the exception of one site representing $2 million of the total accrued remediation costs.
The ultimate outcome of these matters cannot be determined at this time; however, as a result of the regulatory treatment for environmental remediation expenses described above, the final disposition of these matters is not expected to have a material impact on the financial statements of Southern Company, Georgia Power, Gulf Power, or Southern Company Gas.
FERC Matters
Market-Based Rate Authority
The traditional electric operating companies and Southern Power have authority from the FERC to sell electricity at market-based rates. Since 2008, that authority, for certain balancing authority areas, has been conditioned on compliance with the requirements of an energy auction, which the FERC found to be tailored mitigation that addresses potential market power concerns. In accordance with FERC regulations governing such authority, the traditional electric operating companies and Southern Power filed a triennial market power analysis in 2014, which included continued reliance on the energy auction as tailored mitigation. In 2015, the FERC issued an order finding that the traditional electric operating companies' and Southern Power's existing tailored mitigation may not effectively mitigate the potential to exert market power in certain areas served by the traditional electric operating companies and in some adjacent areas. The FERC directed the traditional electric operating companies and Southern Power to show why market-based rate authority should not be revoked in these areas or to provide a mitigation plan to further address market power concerns. The traditional electric operating companies and Southern Power filed a request for rehearing and filed their response with the FERC in 2015.
In 2016, the traditional electric operating companies and Southern Power filed an amendment to their market-based rate tariff that proposed certain changes to the energy auction, as well as several non-tariff changes. In February 2017, the FERC issued an order accepting all such changes subject to an additional condition of cost-based price caps for certain sales outside of the energy auction, finding that all of these changes would provide adequate alternative mitigation for the traditional electric operating companies' and Southern Power's potential to exert market power in certain areas served by the traditional electric operating companies and in some adjacent areas. In May 2017, the FERC accepted the traditional electric operating companies' and Southern Power's compliance filing accepting the terms of the order. While the FERC's February 2017 order references the market power proceeding discussed above, it remains a separate, ongoing matter.
In October 2017, the FERC issued an order in response to the traditional electric operating companies' and Southern Power's June 29, 2017 triennial updated market power analysis. The FERC directed the traditional electric operating companies and Southern Power to show cause within 60 days why market-based rate authority should not be revoked in certain areas adjacent to the area presently under mitigation in accordance with the February 2017 order or to provide a mitigation plan to further address market power concerns. In November 2017, the traditional electric operating companies and Southern Power responded to the FERC and proposed to resolve matters by applying the alternative mitigation authorized by the February 2017 order to the adjacent areas made the subject of the October 2017 order.
The ultimate outcome of these matters cannot be determined at this time.
Cooperative Energy Power Supply Agreement
See Note 3 to the financial statements of Mississippi Power under "FERC Matters – Cooperative Energy Power Supply Agreement" in Item 8 of the Form 10-K for additional information regarding Cooperative Energy's network integration transmission service agreement (NITSA) with SCS.
On March 23, 2018, the FERC accepted the amendment to the NITSA between Cooperative Energy and SCS, effective April 1, 2018.
Regulatory Matters
Alabama Power
See Note 3 to the financial statements of Southern Company and Alabama Power under "Regulatory Matters Alabama Power" and "Retail Regulatory Matters," respectively, in Item 8 of the Form 10-K for additional information regarding Alabama Power's recovery of retail costs through various regulatory clauses and accounting orders. The balance of each regulatory clause recovery on the balance sheet follows:
Regulatory Clause
Balance Sheet Line Item
March 31,
2018
December 31,
2017
 
 
(in millions)
Rate CNP Compliance
Deferred under recovered regulatory clause revenues
$
15

$
17

Rate CNP PPA
Deferred under recovered regulatory clause revenues
8

12

Retail Energy Cost Recovery
Deferred under recovered regulatory clause revenues
78

25

Natural Disaster Reserve
Other regulatory liabilities, deferred
38

38


On May 1, 2018, the Alabama PSC approved modifications to Rate RSE and other commitments designed to position Alabama Power to address the growing pressure on its credit quality resulting from the Tax Reform Legislation, without increasing retail rates under Rate RSE in the near term. Alabama Power plans to reduce growth in total debt by increasing equity, with corresponding reductions in debt issuances, thereby de-leveraging its capital structure. Alabama Power's goal is to achieve an equity ratio of approximately 55% by the end of 2025.
Rate RSE
The approved modifications to Rate RSE are effective June 2018 and applicable for January 2019 billings and thereafter. The modifications include reducing the top of the allowed weighted common equity return (WCER) range from 6.21% to 6.15% and modifications to the refund mechanism applicable to prior year actual results. The modifications to the refund mechanism allow Alabama Power to retain a portion of the revenue that causes the actual WCER for a given year to exceed the allowed range.
Generally, if Alabama Power's actual WCER range is between 6.15% and 7.65%, customers will receive 25% of the amount between 6.15% and 6.65%, 40% of the amount between 6.65% and 7.15%, and 75% of the amount between 7.15% and 7.65%. Customers will receive all amounts in excess of an actual WCER of 7.65%.
In conjunction with these modifications to Rate RSE, Alabama Power committed to a moratorium on any upward adjustments under Rate RSE for 2019 and 2020. Additionally, Alabama Power will return $50 million to customers through bill credits in 2019. Alabama Power typically has three to five business days to indicate its acceptance of the Alabama PSC's actions following issuance of the related Alabama PSC order. The ultimate outcome of this matter cannot be determined at this time.
In accordance with an established retail tariff that provides for an interim adjustment to customer billings to recognize the impact of a change in the statutory income tax rate, Alabama Power will also return approximately $257 million to retail customers through bill credits in the second half of 2018 as a result of the change in the federal income tax rate under the Tax Reform Legislation.
Rate ECR
On May 1, 2018, the Alabama PSC approved an increase to Rate ECR from 2.015 cents per KWH to 2.353 cents per KWH effective July 2018 which is expected to result in additional collections of approximately $100 million through December 31, 2018. The approved increase in the Rate ECR factor will have no significant effect on Alabama Power's net income, but will increase operating cash flows related to fuel cost recovery in 2018. The rate will return to 5.910 cents per KWH in 2019, absent a further order from the Alabama PSC. Alabama Power typically has three to five business days to indicate its acceptance of the Alabama PSC's actions following issuance of the related Alabama PSC order. The ultimate outcome of this matter cannot be determined at this time.
Accounting Order
On May 1, 2018, the Alabama PSC approved an accounting order that authorizes Alabama Power to defer the benefits of federal excess deferred income taxes associated with the Tax Reform Legislation for the year ending December 31, 2018 as a regulatory liability. Up to $30 million of such deferrals may be used to offset under-recovered amounts under Rate ECR, with any remaining amounts to be used for the benefit of customers as determined by the Alabama PSC. Alabama Power expects the benefits deferred to total approximately $30 million to $50 million. The ultimate outcome of this matter cannot be determined at this time. See Note 5 to the financial statements of Southern Company and Alabama Power under "Federal Tax Reform Legislation" and of Alabama Power under "Current and Deferred Income Taxes" in Item 8 of the Form 10-K for additional information.
Georgia Power
Georgia Power's revenues from regulated retail operations are collected through various rate mechanisms subject to the oversight of the Georgia PSC. Georgia Power currently recovers its costs from the regulated retail business through the 2013 ARP, which includes traditional base tariff rates, Demand-Side Management tariffs, Environmental Compliance Cost Recovery tariffs, and Municipal Franchise Fee tariffs. In addition, financing costs related to certified construction costs of Plant Vogtle Units 3 and 4 are being collected through the NCCR tariff and fuel costs are collected through a separate fuel cost recovery tariff. See "Nuclear Construction" herein and Note 3 to the financial statements of Southern Company under "Nuclear Construction" and Georgia Power under "Retail Regulatory Matters – Nuclear Construction" in Item 8 of the Form 10-K for additional information regarding the NCCR tariff. Also see "Fuel Cost Recovery" herein and Note 3 to the financial statements of Southern Company under "Regulatory Matters – Georgia Power – Fuel Cost Recovery" and Georgia Power under "Retail Regulatory Matters – Fuel Cost Recovery" in Item 8 of the Form 10-K for additional information regarding fuel cost recovery.
Rate Plans
See Note 3 to the financial statements of Southern Company and Georgia Power under "Regulatory Matters – Georgia Power – Rate Plans" and "Retail Regulatory Matters – Rate Plans," respectively, in Item 8 of the Form 10-K for additional information regarding Georgia Power's 2013 ARP and the Georgia PSC's 2018 order related to the Tax Reform Legislation.
On April 3, 2018, the Georgia PSC approved a settlement agreement between Georgia Power and the staff of the Georgia PSC regarding the retail rate impact of the Tax Reform Legislation (Georgia Power Tax Reform Settlement Agreement). Pursuant to the Georgia Power Tax Reform Settlement Agreement, to reflect the federal income tax rate reduction impact of the Tax Reform Legislation, Georgia Power will refund to customers a total of $330 million through bill credits of $131 million in October 2018, $96 million in June 2019, and $103 million in February 2020. In addition, Georgia Power is deferring as a regulatory liability (i) the revenue equivalent of the tax expense reduction resulting from legislation lowering the Georgia state income tax rate from 6.00% to 5.75% in 2019 and (ii) the entire benefit of approximately $700 million in federal and state excess accumulated deferred income taxes. The amortization of these regulatory liabilities is expected to be addressed in Georgia Power's next base rate case, which is scheduled to be filed by July 1, 2019. If there is not a base rate case in 2019, customers will receive $185 million in annual bill credits beginning in 2020, with any additional federal and state income tax savings deferred as a regulatory liability, until Georgia Power's next base rate case.
To address the negative cash flow and credit metric impacts of the Tax Reform Legislation, the Georgia PSC also approved an increase in Georgia Power's retail equity ratio to the lower of (i) Georgia Power's actual common equity weight in its capital structure or (ii) 55%, until Georgia Power's next base rate case. Benefits from reduced federal income tax rates in excess of the amounts refunded to customers will be retained by Georgia Power to cover the carrying costs of the incremental equity in 2018 and 2019.
Fuel Cost Recovery
As of March 31, 2018 and December 31, 2017, Georgia Power's under recovered fuel balance totaled $156 million and $165 million, respectively, and is included in current assets on Southern Company's and Georgia Power's condensed balance sheets. The Georgia PSC will review Georgia Power's cumulative over or under recovered fuel balance no later than September 1, 2018 and evaluate the need to file a fuel case. Georgia Power continues to be allowed to adjust its fuel cost recovery rates under an interim fuel rider prior to the next fuel case if the under or over recovered fuel balance exceeds $200 million.
Fuel cost recovery revenues are adjusted for differences in actual recoverable fuel costs and amounts billed in current regulated rates. Accordingly, changes in the billing factor will not have a significant effect on Southern Company's or Georgia Power's revenues or net income, but will affect cash flow.
Gulf Power
See Note 3 to the financial statements of Gulf Power under "Retail Regulatory Matters" in Item 8 of the Form 10-K for additional information regarding Gulf Power's rates and charges for service to retail customers.
Retail Base Rate Case
See Note 3 to the financial statements of Southern Company and Gulf Power under "Regulatory Matters – Gulf Power – Retail Base Rate Cases" and "Retail Regulatory Matters – Retail Base Rate Cases," respectively, in Item 8 of the Form 10-K for additional information.
As a continuation of a settlement agreement approved by the Florida PSC in April 2017 (2017 Gulf Power Rate Case Settlement Agreement), on March 26, 2018, the Florida PSC approved a stipulation and settlement agreement among Gulf Power and three intervenors addressing the retail revenue requirement effects of the Tax Reform Legislation (Gulf Power Tax Reform Settlement Agreement).
The Gulf Power Tax Reform Settlement Agreement results in annual reductions to Gulf Power's revenues of $18.2 million from base rates and $15.6 million from environmental cost recovery rates, implemented April 1, 2018, and also provides for a one-time refund of $69.4 million for the retail portion of unprotected (not subject to normalization) deferred tax liabilities through Gulf Power's fuel cost recovery rate over the remainder of 2018. As a result of the Gulf Power Tax Reform Settlement Agreement, the Florida PSC also approved an increase in Gulf Power's maximum equity ratio from 52.5% to 53.5% for all retail regulatory purposes.
As part of the Gulf Power Tax Reform Settlement Agreement, a limited scope proceeding to address protected deferred tax liabilities consistent with IRS normalization principles was initiated on April 30, 2018. Pending resolution of this proceeding, Gulf Power is deferring the related amounts for 2018 as a regulatory liability. Unless otherwise agreed to by the parties to the Gulf Power Tax Reform Settlement Agreement, amounts recorded in this regulatory liability will be refunded to retail customers in 2019 through Gulf Power's fuel cost recovery rates. The ultimate outcome of this matter cannot be determined at this time.
Cost Recovery Clauses
See Note 3 to the financial statements of Gulf Power under "Retail Regulatory Matters – Cost Recovery Clauses" in Item 8 of the Form 10-K for additional information regarding Gulf Power's recovery of retail costs through various regulatory clauses and accounting orders, as approved by the Florida PSC. Regulatory clause recovery balances included in the balance sheets are as follows:
Regulatory Clause
Balance Sheet Line Item
March 31,
2018
December 31,
2017
 
 
(in millions)
Fuel Cost Recovery
Under recovered regulatory clause revenues
$
4

$
22

Purchased Power Capacity Recovery
Under recovered regulatory clause revenues
4

2

Environmental Cost Recovery(*)
Under recovered regulatory clause revenues
2

2

(*)
At March 31, 2018 and December 31, 2017, the under recovered balance included in the balance sheets represents the current portion of the regulatory assets associated with projected environmental expenditures of approximately $12 million and $13 million, respectively, partially offset by the over recovered environmental cost recovery balance of approximately $10 million and $11 million, respectively.
Mississippi Power
See Note 3 to the financial statements of Mississippi Power under "Retail Regulatory Matters" in Item 8 of the Form 10-K for additional information.
On April 10, 2018, the Mississippi PSC stated its intent to begin an operations review process for investor-owned utilities in Mississippi and instructed its legal staff and the Mississippi Public Utilities Staff to prepare an order and request for proposals for a review of Mississippi Power. Mississippi Power expects that the review will include its cost recovery framework and an analysis of potential participation in a regional transmission organization. The ultimate outcome of this matter cannot be determined at this time.
Performance Evaluation Plan
In 2014, 2015, 2016, and 2017, Mississippi Power submitted its annual PEP lookback filings for the prior years, which for 2013 and 2014 each indicated no surcharge or refund and for each of 2015 and 2016 indicated a $5 million surcharge. Additionally, in July 2016, in November 2016, and on November 15, 2017, Mississippi Power submitted its annual projected PEP filings for 2016, 2017, and 2018, respectively, which for 2016 and 2017 indicated no change in rates and for 2018 indicated a rate increase of 4%, or $38 million in annual revenues. The Mississippi PSC suspended each of these filings to allow more time for review.
On February 7, 2018, Mississippi Power revised its annual projected PEP filing for 2018 to reflect the impacts of the Tax Reform Legislation. The revised filing requests an increase of $26 million in annual revenues, based on a performance adjusted ROE of 9.33% and an increased equity ratio of 55%. The Mississippi PSC is expected to rule on this request in mid-2018.
On March 22, 2018, Mississippi Power submitted its annual PEP lookback filing for 2017, which reflected no surcharge or refund.
The ultimate outcome of these matters cannot be determined at this time.
Environmental Compliance Overview Plan
On February 14, 2018, Mississippi Power submitted its ECO Plan filing for 2018, including the effects of the Tax Reform Legislation, which requested the maximum 2% annual increase in revenues, or approximately $17 million, primarily related to the carryforward from the prior year. Approximately $13 million of related revenue requirements in excess of the 2% maximum, along with related carrying costs, remains deferred for inclusion in the 2019 filing. The Mississippi PSC is expected to rule on this request in mid-2018. The ultimate outcome of this matter cannot be determined at this time.
Fuel Cost Recovery
At March 31, 2018, the amount of over-recovered retail fuel costs included in other regulatory liabilities, current on the condensed balance sheet was approximately $3 million compared to an approximately $6 million under-recovered balance in other accounts and notes receivable at December 31, 2017.
Ad Valorem Tax Adjustment
On March 23, 2018, Mississippi Power submitted its annual ad valorem tax adjustment factor filing for 2018, which included an annual rate increase of 0.8%, or $7 million in annual retail revenues, primarily due to increased assessments. The ultimate outcome of this matter cannot be determined at this time.
Southern Company Gas
See Note 3 to the financial statements of Southern Company and Southern Company Gas under "Regulatory Matters – Southern Company Gas" and "Regulatory Matters," respectively, in Item 8 of the Form 10-K for additional information regarding Southern Company Gas' regulatory matters.
Riders
On April 19, 2018, the Illinois Commission approved Nicor Gas' variable income tax adjustment rider. This rider provides for refund or recovery of changes in income tax expense that result from income tax rates that differ from those used in Nicor Gas' last rate case. Customer refunds related to the 2018 impacts are expected to begin in July 2018.
Natural Gas Cost Recovery
Southern Company Gas has established natural gas cost recovery rates approved by the relevant state regulatory agencies in the states in which it serves. Natural gas cost recovery revenues are adjusted for differences in actual recoverable natural gas costs and amounts billed in current regulated rates. Changes in the billing factor will not have a significant effect on Southern Company's or Southern Company Gas' revenues or net income, but will affect cash flows.
Base Rate Cases
Settled Base Rate Case
In October 2017, Florida City Gas filed a general base rate case with the Florida PSC requesting an annual revenue increase of $19 million, which included an interim rate increase of $5 million annually that was approved and became effective January 12, 2018, subject to refund. On March 26, 2018, the Florida PSC approved a settlement that, after including the impact of the Tax Reform Legislation, provides for an $11.5 million increase in annual base rate revenues, effective June 1, 2018, based on a ROE of 10.19%. Under the terms of the settlement, Florida City Gas agreed not to file a new base rate case with an effective date prior to June 1, 2022 and will receive full recovery of the costs related to its LNG facility to be constructed through additional increases in annual base rate revenues of $2.5 million on June 1, 2019 or the in-service date, whichever is later, and $1.3 million on December 1, 2019. If the facility is placed in service after December 1, 2019, the entire additional $3.8 million increase will take effect upon the in-service date of the LNG facility.
Pending Base Rate Cases
On February 15, 2018, Chattanooga Gas filed a general base rate case with the Tennessee Public Utility Commission (PUC) requesting a $7 million increase in annual base rate revenues. The requested increase, which, in accordance with a Tennessee PUC order, incorporated the effects of the Tax Reform Legislation, was based on a projected test year ending June 30, 2019 and a ROE of 11.25%. The Tennessee PUC is expected to rule on the requested increase in the third quarter 2018.
In December 2017, Atlanta Gas Light filed its 2018 annual rate adjustment with the Georgia PSC, which, if approved, would have increased annual base rate revenues by $22 million, effective June 1, 2018. On February 23, 2018, Atlanta Gas Light revised its filing to reflect the impacts of the Tax Reform Legislation. The revised request replaced the $22 million rate increase with a $16 million rate reduction for customers in 2018. The revised request maintains the previously authorized earnings band based on a return on equity between 10.55% and 10.95% and proposes to increase the equity ratio by 3% to an equity ratio of 54% to address the negative cash flow and credit metric impacts of the Tax Reform Legislation. Atlanta Gas Light also notified the Georgia PSC that it intends to seek a further equity ratio increase of 2% to an equity ratio of 56% in its 2019 filing. The Georgia PSC is expected to rule on the revised request in the second quarter 2018.
In accordance with an Illinois Commission order and pursuant to its rehearing request, on April 13, 2018, Nicor Gas filed for revised base rates with the Illinois Commission, which would result in a decrease of approximately $44 million in annual base rate revenues effective in the second quarter 2018 to incorporate the reduction in the federal income tax rate as a result of the Tax Reform Legislation. Nicor Gas' previously-authorized capital structure and ROE of 9.8% were not addressed in the rehearing and remain unchanged. The Illinois Commission is expected to rule on the request on May 2, 2018.
The ultimate outcome of these matters cannot be determined at this time.
Other
The New Jersey BPU, Maryland PSC, and Virginia Commission each issued an order effective January 1, 2018 that requires utilities in their respective states to defer as a regulatory liability the impact of the Tax Reform Legislation, including the reduction in the corporate income tax rate to 21% and the impact of excess deferred income taxes. On March 26, 2018, the New Jersey BPU approved an $11 million reduction in Elizabethtown Gas' annual base rate revenues effective April 1, 2018 on an interim basis, subject to refund, pending final approval. On March 28, 2018, the Maryland PSC approved a $0.1 million reduction in Elkton Gas' annual base rate revenues effective April 1, 2018. Credits will be issued to customers in New Jersey and Maryland later in 2018 for the impact of the Tax Reform Legislation on the January 2018 through March 2018 billing periods. On April 25, 2018, the Virginia Commission issued an order indicating that any proposal beyond a proposed base rate reduction to reflect the cost savings from the Tax Reform Legislation must be made through a general base rate case. Virginia Natural Gas expects to finalize its strategy to address the impacts of the Tax Reform Legislation on or before July 1, 2018.
The ultimate outcome of these matters cannot be determined at this time.
Regulatory Infrastructure Programs
Southern Company Gas is engaged in various infrastructure programs that update or expand its gas distribution systems to improve reliability and ensure the safety of its utility infrastructure, and recovers in rates its investment and a return associated with these infrastructure programs. See Note 3 to the financial statements of Southern Company and Southern Company Gas under "Regulatory Matters – Southern Company Gas – Regulatory Infrastructure Programs" and "Regulatory Matters – Regulatory Infrastructure Programs," respectively, in Item 8 of the Form 10-K for additional information.
Nuclear Construction
See Note 3 to the financial statements of Southern Company and Georgia Power under "Nuclear Construction" and "Retail Regulatory Matters – Nuclear Construction," respectively, in Item 8 of the Form 10-K for additional information regarding Georgia Power's construction of Plant Vogtle Units 3 and 4, VCM reports, and the NCCR tariff.
Project Status
In 2009, the Georgia PSC certified construction of Plant Vogtle Units 3 and 4. In 2012, the NRC issued the related combined construction and operating licenses, which allowed full construction of the two AP1000 nuclear units (with electric generating capacity of approximately 1,100 MWs each) and related facilities to begin. Until March 2017, construction on Plant Vogtle Units 3 and 4 continued under the Vogtle 3 and 4 Agreement, which was a substantially fixed price agreement. In March 2017, the EPC Contractor filed for bankruptcy protection under Chapter 11 of the U.S. Bankruptcy Code.
In connection with the EPC Contractor's bankruptcy filing, Georgia Power, acting for itself and as agent for the Vogtle Owners, entered into the Interim Assessment Agreement with the EPC Contractor to allow construction to continue. The Interim Assessment Agreement expired in July 2017 when the Vogtle Services Agreement became effective. In August 2017, following completion of comprehensive cost to complete and cancellation cost assessments, Georgia Power filed its seventeenth VCM report with the Georgia PSC, which included a recommendation to continue construction of Plant Vogtle Units 3 and 4, with Southern Nuclear serving as project manager and Bechtel serving as the primary construction contractor. In December 2017, the Georgia PSC approved Georgia Power's recommendation to continue construction.
Georgia Power expects Plant Vogtle Units 3 and 4 to be placed in service by November 2021 and November 2022, respectively. Georgia Power's capital cost forecast for its 45.7% proportionate share of Plant Vogtle Units 3 and 4 is $8.8 billion ($7.3 billion after reflecting $1.7 billion received from Toshiba in 2017 under the Guarantee Settlement Agreement and $188 million in Customer Refunds recognized as a regulatory liability in 2017). Georgia Power's CWIP balance for Plant Vogtle Units 3 and 4 was $3.6 billion at March 31, 2018, which is net of the Guarantee Settlement Agreement payments less the Customer Refunds. Georgia Power estimates that its financing costs for construction of Plant Vogtle Units 3 and 4 will total approximately $3.1 billion, of which $1.6 billion had been incurred through March 31, 2018.
Vogtle 3 and 4 Contracts
Effective in July 2017, Georgia Power, acting for itself and as agent for the other Vogtle Owners, and the EPC Contractor entered into the Vogtle Services Agreement, whereby Westinghouse will provide facility design and engineering services, procurement and technical support, and staff augmentation on a time and materials cost basis. The Vogtle Services Agreement will continue until the start-up and testing of Plant Vogtle Units 3 and 4 are complete and electricity is generated and sold from both units. The Vogtle Services Agreement is terminable by the Vogtle Owners upon 30 days' written notice.
In October 2017, Georgia Power, acting for itself and as agent for the other Vogtle Owners, entered into a construction completion agreement with Bechtel, whereby Bechtel will serve as the primary contractor for the remaining construction activities for Plant Vogtle Units 3 and 4 (Bechtel Agreement). The Bechtel Agreement is a cost reimbursable plus fee arrangement, whereby Bechtel is reimbursed for actual costs plus a base fee and an at-risk fee, which is subject to adjustment based on Bechtel's performance against cost and schedule targets. Each Vogtle Owner is severally (not jointly) liable for its proportionate share, based on its ownership interest, of all amounts owed to Bechtel under the Bechtel Agreement. The Vogtle Owners may terminate the Bechtel Agreement at any time for their convenience, provided that the Vogtle Owners will be required to pay amounts related to work performed prior to the termination (including the applicable portion of the base fee), certain termination-related costs, and, at certain stages of the work, the applicable portion of the at-risk fee. Bechtel may terminate the Bechtel Agreement under certain circumstances, including certain Vogtle Owner suspensions of work, certain breaches of the Bechtel Agreement by the Vogtle Owners, Vogtle Owner insolvency, and certain other events. Pursuant to the Loan Guarantee Agreement between Georgia Power and the DOE, Georgia Power is required to obtain the DOE's approval of the Bechtel Agreement prior to obtaining any further advances under the Loan Guarantee Agreement.
In November 2017, the Vogtle Owners entered into an amendment to their joint ownership agreements for Plant Vogtle Units 3 and 4 (as amended, Vogtle Joint Ownership Agreements) to provide for, among other conditions, additional Vogtle Owner approval requirements. Pursuant to the Vogtle Joint Ownership Agreements, the holders of at least 90% of the ownership interests in Plant Vogtle Units 3 and 4 must vote to continue construction if certain adverse events occur, including (i) the bankruptcy of Toshiba; (ii) termination or rejection in bankruptcy of certain agreements, including the Vogtle Services Agreement or the Bechtel Agreement; (iii) the Georgia PSC or Georgia Power determines that any of Georgia Power's costs relating to the construction of Plant Vogtle Units 3 and 4 will not be recovered in retail rates because such costs are deemed unreasonable or imprudent; or (iv) an increase in the construction budget contained in the seventeenth VCM report of more than $1 billion or extension of the project schedule contained in the seventeenth VCM report of more than one year. In addition, pursuant to the Vogtle Joint Ownership Agreements, the required approval of holders of ownership interests in Plant Vogtle Units 3 and 4 is at least (i) 90% for a change of the primary construction contractor and (ii) 67% for material amendments to the Vogtle Services Agreement or agreements with Southern Nuclear or the primary construction contractor, including the Bechtel Agreement. The Vogtle Joint Ownership Agreements also confirm that the Vogtle Owners' sole recourse against Georgia Power or Southern Nuclear for any action or inaction in connection with their performance as agent for the Vogtle Owners is limited to removal of Georgia Power and/or Southern Nuclear as agent, except in cases of willful misconduct.
Regulatory Matters
In 2009, the Georgia PSC voted to certify construction of Plant Vogtle Units 3 and 4 with a certified capital cost of $4.418 billion. In addition, in 2009 the Georgia PSC approved inclusion of the Plant Vogtle Units 3 and 4 related CWIP accounts in rate base, and the State of Georgia enacted the Georgia Nuclear Energy Financing Act, which allows Georgia Power to recover financing costs for Plant Vogtle Units 3 and 4. Financing costs are recovered on all applicable certified costs through annual adjustments to the NCCR tariff up to the certified capital cost of $4.418 billion. As of March 31, 2018, Georgia Power had recovered approximately $1.6 billion of financing costs. On March 20, 2018, the Georgia PSC approved a decrease to the NCCR tariff of approximately $50 million, effective April 1, 2018.
Georgia Power is required to file semi-annual VCM reports with the Georgia PSC by February 28 and August 31 each year. In 2013, in connection with the eighth VCM report, the Georgia PSC approved a stipulation between Georgia Power and the staff of the Georgia PSC to waive the requirement to amend the Plant Vogtle Units 3 and 4 certificate in accordance with the 2009 certification order until the completion of Plant Vogtle Unit 3, or earlier if deemed appropriate by the Georgia PSC and Georgia Power.
In 2016, the Georgia PSC voted to approve a settlement agreement (Vogtle Cost Settlement Agreement) resolving certain prudency matters in connection with the fifteenth VCM report. In December 2017, the Georgia PSC voted to approve (and issued its related order on January 11, 2018) certain recommendations made by Georgia Power in the seventeenth VCM report and modifying the Vogtle Cost Settlement Agreement. The Vogtle Cost Settlement Agreement, as modified by the January 11, 2018 order, resolved the following regulatory matters related to Plant Vogtle Units 3 and 4: (i) none of the $3.3 billion of costs incurred through December 31, 2015 and reflected in the fourteenth VCM report should be disallowed from rate base on the basis of imprudence; (ii) the Contractor Settlement Agreement was reasonable and prudent and none of the amounts paid pursuant to the Contractor Settlement Agreement should be disallowed from rate base on the basis of imprudence; (iii) (a) capital costs incurred up to $5.68 billion would be presumed to be reasonable and prudent with the burden of proof on any party challenging such costs, (b) Georgia Power would have the burden to show that any capital costs above $5.68 billion were prudent, and (c) a revised capital cost forecast of $7.3 billion (after reflecting the impact of payments received under the Guarantee Settlement Agreement and Customer Refunds) was found reasonable; (iv) construction of Plant Vogtle Units 3 and 4 should be completed, with Southern Nuclear serving as project manager and Bechtel as primary contractor; (v) approved and deemed reasonable Georgia Power's revised schedule placing Plant Vogtle Units 3 and 4 in service in November 2021 and November 2022, respectively; (vi) confirmed that the revised cost forecast does not represent a cost cap and that prudence decisions on cost recovery will be made at a later date, consistent with applicable Georgia law; (vii) reduced the ROE used to calculate the NCCR tariff (a) from 10.95% (the ROE rate setting point authorized by the Georgia PSC in the 2013 ARP) to 10.00% effective January 1, 2016, (b) from 10.00% to 8.30%, effective January 1, 2020, and (c) from 8.30% to 5.30%, effective January 1, 2021 (provided that the ROE in no case will be less than Georgia Power's average cost of long-term debt); (viii) reduced the ROE used for AFUDC equity for Plant Vogtle Units 3 and 4 from 10.00% to Georgia Power's average cost of long-term debt, effective January 1, 2018; and (ix) agreed that upon Unit 3 reaching commercial operation, retail base rates would be adjusted to include carrying costs on those capital costs deemed prudent in the Vogtle Cost Settlement Agreement. The January 11, 2018 order also stated that if Plant Vogtle Units 3 and 4 are not commercially operational by June 1, 2021 and June 1, 2022, respectively, the ROE used to calculate the NCCR tariff will be further reduced by 10 basis points each month (but not lower than Georgia Power's average cost of long-term debt) until the respective unit is commercially operational. The ROE reductions negatively impacted earnings by approximately $25 million in 2017 and are estimated to have negative earnings impacts of approximately $100 million in 2018 and an aggregate of $585 million from 2019 to 2022. In its January 11, 2018 order, the Georgia PSC stated if other certain conditions and assumptions upon which Georgia Power's seventeenth VCM report are based do not materialize, both Georgia Power and the Georgia PSC reserve the right to reconsider the decision to continue construction.
On February 12, 2018, Georgia Interfaith Power & Light, Inc. and Partnership for Southern Equity, Inc. filed a petition appealing the Georgia PSC's January 11, 2018 order with the Fulton County Superior Court. On March 8, 2018, Georgia Watch filed a similar appeal to the Fulton County Superior Court for judicial review of the Georgia PSC's final decision and denial of Georgia Watch's motion for reconsideration. Georgia Power believes the two appeals have no merit; however, an adverse outcome in either appeal could have a material impact on Southern Company's and Georgia Power's results of operations, financial condition, and liquidity.
The IRS has allocated PTCs to each of Plant Vogtle Units 3 and 4. The nominal value of Georgia Power's portion of the PTCs is approximately $500 million per unit.
The Georgia PSC has approved seventeen VCM reports covering the periods through June 30, 2017, including total construction capital costs incurred through that date of $4.4 billion. Georgia Power filed its eighteenth VCM report on February 28, 2018 requesting approval of $448 million of construction capital costs (excluding the $1.7 billion received from Toshiba under the Guarantee Settlement Agreement and the $188 million in Customer Refunds recognized as a regulatory liability) incurred from July 1, 2017 through December 31, 2017.
The ultimate outcome of these matters cannot be determined at this time.
Cost and Schedule
Georgia Power's approximate proportionate share of the remaining estimated capital cost to complete Plant Vogtle Units 3 and 4 with in-service dates of November 2021 and November 2022, respectively, is as follows:
 
(in billions)
Project capital cost forecast
$
7.3

Net investment as of March 31, 2018
(3.7
)
Remaining estimate to complete
$
3.6

Note: Excludes financing costs capitalized through AFUDC and is net of $1.7 billion received from Toshiba in 2017 under the Guarantee Settlement Agreement and $188 million in Customer Refunds recognized as a regulatory liability in 2017.
Georgia Power estimates that its financing costs for construction of Plant Vogtle Units 3 and 4 will total approximately $3.1 billion, of which $1.6 billion had been incurred through March 31, 2018.
Subsequent to the EPC Contractor bankruptcy filing, a number of subcontractors to the EPC Contractor alleged non-payment by the EPC Contractor for amounts owed for work performed on Plant Vogtle Units 3 and 4. Georgia Power, acting for itself and as agent for the Vogtle Owners, has taken actions to remove liens filed by these subcontractors through the posting of surety bonds. Related to such liens, certain subcontractors have filed, and additional subcontractors may file, lawsuits against the EPC Contractor and the Vogtle Owners to preserve their payment rights with respect to such claims. All amounts associated with the removal of subcontractor liens and other EPC Contractor pre-petition accounts payable have been paid or accrued as of March 31, 2018.
As construction continues, challenges with management of contractors, subcontractors, and vendors, labor productivity and availability, fabrication, delivery, assembly, and installation of plant systems, structures, and components (some of which are based on new technology and have not yet operated in the global nuclear industry at this scale), or other issues could arise and change the projected schedule and estimated cost.
There have been technical and procedural challenges to the construction and licensing of Plant Vogtle Units 3 and 4 at the federal and state level and additional challenges may arise. Processes are in place that are designed to assure compliance with the requirements specified in the Westinghouse Design Control Document and the combined construction and operating licenses, including inspections by Southern Nuclear and the NRC that occur throughout construction. As a result of such compliance processes, certain license amendment requests have been filed and approved or are pending before the NRC. Various design and other licensing-based compliance matters, including the timely resolution of Inspections, Tests, Analyses, and Acceptance Criteria and the related approvals by the NRC, may arise, which may result in additional license amendments or require other resolution. If any license amendment requests or other licensing-based compliance issues are not resolved in a timely manner, there may be delays in the project schedule that could result in increased costs.
The ultimate outcome of these matters cannot be determined at this time.
DOE Financing
As of March 31, 2018, Georgia Power had borrowed $2.6 billion related to Plant Vogtle Units 3 and 4 costs through the Loan Guarantee Agreement and a multi-advance credit facility among Georgia Power, the DOE, and the FFB, which provides for borrowings of up to $3.46 billion, subject to the satisfaction of certain conditions. In September 2017, the DOE issued a conditional commitment to Georgia Power for up to approximately $1.67 billion in additional guaranteed loans under the Loan Guarantee Agreement. This conditional commitment expires on June 30, 2018, subject to any further extension approved by the DOE. Final approval and issuance of these additional loan guarantees by the DOE cannot be assured and are subject to the negotiation of definitive agreements, completion of due diligence by the DOE, receipt of any necessary regulatory approvals, and satisfaction of other conditions. See Note 6 to the financial statements of Southern Company and Georgia Power under "DOE Loan Guarantee Borrowings" in Item 8 of the Form 10-K for additional information, including applicable covenants, events of default, mandatory prepayment events, and conditions to borrowing.
The ultimate outcome of these matters cannot be determined at this time.
Kemper County Energy Facility
For additional information on the Kemper County energy facility, see Note 3 to the financial statements of Southern Company and Mississippi Power under "Kemper County Energy Facility" in Item 8 of the Form 10-K.
As the mining permit holder for the Kemper County energy facility, Liberty Fuels Company, LLC has a legal obligation to perform mine reclamation, and Mississippi Power has a contractual obligation to fund all reclamation activities. Mine reclamation began in the first quarter 2018. See Note 1 to the financial statements of Southern Company and Mississippi Power under "Asset Retirement Obligations and Other Costs of Removal" and of Mississippi Power under "Variable Interest Entities" in Item 8 of the Form 10-K for additional information.
During the first quarter 2018, Mississippi Power recorded charges to income of $44 million ($33 million after tax), primarily resulting from the abandonment and related closure activities for the mine and gasifier-related assets at the Kemper County energy facility. Additional closure costs for the mine and gasifier-related assets, including ash disposal, currently estimated to cost up to $50 million pre-tax (excluding salvage), are expected to be incurred during the remainder of 2018 and 2019. In addition, period costs, including, but not limited to, costs for compliance and safety, ARO accretion, and property taxes for the mine and gasifier-related assets, are estimated at $4 million for the remainder of 2018, $4 million in 2019, and $1 million annually beginning in 2020. The ultimate outcome of this matter cannot be determined at this time.
Other Matters
Investments in Leveraged Leases
See Note 1 to the financial statements of Southern Company under "Leveraged Leases" in Item 8 of the Form 10-K for additional information regarding a Southern Company Holdings Inc. (Southern Holdings) subsidiary's leveraged lease agreements and concerns about the financial and operational performance of one of the lessees and the associated generation assets.
The ability of the lessees to make required payments to the Southern Holdings subsidiary is dependent on the operational performance of the assets. As a result of operational improvements in the first quarter 2018, the June 2018 lease payment is currently expected to be paid in full. However, operational issues and resulting cash liquidity challenges persist and significant concerns continue regarding the lessee's ability to make the remaining semi-annual lease payments, including the lease payment due in December 2018. These operational challenges may also impact the expected residual value of the assets at the end of the lease term in 2047. If any future lease payment is not paid in full, the Southern Holdings subsidiary may be unable to make its corresponding payment to the holders of the underlying non-recourse debt related to the generation assets. Failure to make the required payment to the debtholders would represent an event of default that would give the debtholders the right to foreclose on, and take ownership of, the generation assets from the Southern Holdings subsidiary, in effect terminating the lease and resulting in the write-off of the related lease receivable which had a balance of approximately $86 million as of March 31, 2018. Southern Company has evaluated the recoverability of the lease receivable and the expected residual value of the generation assets at the end of the lease under various scenarios and has concluded that its investment in the leveraged lease is not impaired as of March 31, 2018. Southern Company will continue to monitor the operational performance of the underlying assets and evaluate the ability of the lessee to continue to make the required lease payments. The ultimate outcome of this matter cannot be determined at this time.
Natural Gas Storage
A wholly-owned subsidiary of Southern Company Gas owns and operates a natural gas storage facility consisting of two salt dome caverns in Louisiana. Periodic integrity tests are required in accordance with rules of the Louisiana Department of Natural Resources (DNR). In August 2017, in connection with an ongoing integrity project, updated seismic mapping indicated the proximity of one of the caverns to the edge of the salt dome may be less than the required minimum and could result in Southern Company Gas retiring the cavern early. At March 31, 2018, the facility's property, plant, and equipment had a net book value of $111 million, of which the cavern itself represents approximately 20%. A potential early retirement of this cavern is dependent upon several factors including compliance with an order from the Louisiana DNR detailing the requirements to place the cavern back in service, which includes, among other things, obtaining core samples to determine the composition of the sheath surrounding the edge of the salt dome.
The cavern continues to maintain its pressures and overall structural integrity. Southern Company Gas intends to monitor the cavern and comply with the Louisiana DNR order through 2020 and place the cavern back in service in 2021. These events were considered in connection with Southern Company Gas' 2017 long-lived asset impairment analysis, which determined there was no impairment. Any future changes in results of monitoring activities, rates at which expiring capacity contracts are re-contracted, timing of placing the cavern back in service, or Louisiana DNR requirements could trigger impairment. Further, early retirement of the cavern could trigger impairment of other long-lived assets associated with the natural gas storage facility. The ultimate outcome of this matter cannot be determined at this time, but could have a significant impact on Southern Company's financial statements and a material impact on Southern Company Gas' financial statements.