-----BEGIN PRIVACY-ENHANCED MESSAGE----- Proc-Type: 2001,MIC-CLEAR Originator-Name: webmaster@www.sec.gov Originator-Key-Asymmetric: MFgwCgYEVQgBAQICAf8DSgAwRwJAW2sNKK9AVtBzYZmr6aGjlWyK3XmZv3dTINen TWSM7vrzLADbmYQaionwg5sDW3P6oaM5D3tdezXMm7z1T+B+twIDAQAB MIC-Info: RSA-MD5,RSA, Fbn58bsYTcd3YSpGLAW76bDg4KT840cR3WF1Ad61MNlIRco+TKic0Hp+ysEvGHAb 0V3cJpTmIboey431rixQmQ== 0000913778-00-000001.txt : 20000203 0000913778-00-000001.hdr.sgml : 20000203 ACCESSION NUMBER: 0000913778-00-000001 CONFORMED SUBMISSION TYPE: 8-K PUBLIC DOCUMENT COUNT: 6 CONFORMED PERIOD OF REPORT: 19981015 ITEM INFORMATION: FILED AS OF DATE: 20000126 FILER: COMPANY DATA: COMPANY CONFORMED NAME: BOSTON CAPITAL TAX CREDIT FUND IV LP CENTRAL INDEX KEY: 0000913778 STANDARD INDUSTRIAL CLASSIFICATION: OPERATORS OF APARTMENT BUILDINGS [6513] IRS NUMBER: 043208648 STATE OF INCORPORATION: DE FISCAL YEAR END: 0331 FILING VALUES: FORM TYPE: 8-K SEC ACT: SEC FILE NUMBER: 000-26200 FILM NUMBER: 513100 BUSINESS ADDRESS: STREET 1: ONE BOSTON PLACE STREET 2: STE 2100 CITY: BOSTON STATE: MA ZIP: 02210-1232 BUSINESS PHONE: 6176248900 MAIL ADDRESS: STREET 1: ONE BOSTON PLACE STREET 2: STE 2100 CITY: BOSTON STATE: MA ZIP: 02108-4406 8-K 1 SECURITIES AND EXCHANGE COMMISSION Washington, D.C. 20549 F O R M 8-K Current Report Pursuant to Section 13 or 15(d) of The Securities Exchange Act of 1934 Date of Report (Date of earliest event reported) October 15, 1998 BOSTON CAPITAL TAX CREDIT FUND IV L.P. (Exact name of registrant as specified in its charter) Massachusetts (State or other jurisdiction of incorporation) 0-26200 04-3208648 (Commission File Number) (IRS Employer Identification No.) c/o Boston Capital Partners, Inc., One Boston Place, Boston, Massachusetts 02108-4406 (Address of principal executive offices) (Zip Code) Registrant's telephone number, including area code (617) 624-8900 None (Former name or former address, if changed since last report) Item 5. Other Events As of October 15, 1998, Boston Capital Tax Credit Fund IV L.P., a Massachusetts limited partnership, specifically Series 29 thereof (the "Partnership") entered into various agreements relating to Lombard Partners, L.P., a Missouri limited partnership (the "Operating Partnership"), including the First Amended and Restated Agreement of Limited Partnership of the Operating Partnership dated as of October 15, 1998 (the "Operating Partnership Agreement"), pursuant to which the Partnership acquired a limited partner interest in the Operating Partnership. Capitalized terms used and not otherwise defined herein have their meanings set forth in the Operating Partnership Agreement, a copy of which is attached hereto as Exhibit (2)(a). The Operating Partnership owns a twenty four (24) unit apartment complex located on 305 East Lombard Street in Springfield, Missouri, which is known as Lombard Heights Apartments (the "Apartment Complex"). The Apartment Complex consists of two (2) buildings containing (2) 1-bedroom units, ten (10) 2-bedroom units and twelve (12) 3-bedroom units. Amenities include the use of a pool at the adjacent Catalpa East Apartments and two (2) common laundry rooms. Construction of the Apartment Complex was completed in May, 1998 and 100% Occupancy was achieved in December, 1998. The Operating Partnership received construction financing in the amount of $1,762,852 (the "Construction Loan") from the City of Springfield, Missouri and KBMH Capital. The Construction Loan carried interest at 11% per annum, had an eighteen (18) - month term, and has now been repaid. The Operating Partnership received permanent financing in the amount of $800,000 (the "Permanent First Mortgage") from the City of Springfield, Missouri, which was funded from the proceeds of an Industrial Revenue Bond. The Permanent First Mortgage commenced in May 1998, has a thirty (30) year term and amortization, and bears an interest rate of 6.89%. It is believed that 100% of the rental apartment units in the Apartment Complex will qualify for the low-income housing tax credit (the "Tax Credits") under Section 42 of the Internal Revenue Code of 1986, as amended (the "Code"). The general partner of the Operating Partnership is Cunningham-Warren Properties, LLC, a Kansas limited liability company (the "General Partner"). Hollis O. Cunningham is the controlling Member and Manager of the General Partner. Mr. Cunningham is also a principal of Cunningham Development Co., Inc., which is the Builder of the Apartment Complex, and of Cunningham Properties, a sole proprietorship, which is the Management Agent of the Apartment Complex. Cunningham-Warren Properties, LLC also served as a the Developer of the Apartment Complex. Cunningham-Warren Properties, LLC has significant experience in the design, construction, and management of multi- family housing. As of August, 1998, the Management Agent was managing 36 low-income housing tax credit apartment units in Kansas, and the Builder had constructed or renovated more than 360 low income housing tax credit units. The Partnership acquired its interest in the Operating Partnership directly from the Operating Partnership in consideration of an agreement to make a Capital Contribution of $359,958 to the Operating Partnership in four (4) installments as follows: (1) $233,973 (the "First Installment") on the Admission Date, of which $75,000 was applied to the repayment of a pre-development loan advanced by the Partnership to the Operating Partnership prior to the effective date of the Operating Partnership Agreement; (2) $89,990 (the "Second Installment") on the latest to occur of (A) Cost Certification, (B) receipt of an updated title insurance policy satisfactory to the Special Limited Partner, (C) Initial 100% Occupancy Date, (D) State Designation, (E) receipt of a payoff letter from the Contractor stating that all amounts payable to the Contractor have been paid in full and that the Operating Partnership is not in violation of the Construction Contract, (F) Substantial Completion, (G) receipt of a valid and recorded Extended Use Commitment, (H) receipt of updated insurance certificates relating to the Apartment Complex satisfactory to the Special Limited Partner or, (I) satisfaction of all of the conditions to the payment of the First Installment; (3) $30,995 (the "Third Installment") on the latest to occur of (A) Rental Achievement or (B) satisfaction of all of the conditions to the payment of the First and Second Installments; and (4) $5,000 (the "Fourth Installment") on the latest to occur of (A) the receipt by the Partnership of the Operating Partnership's federal income tax return and an audited financial statement for the year in which Rental Achievement occurred or (B) satisfaction of all of the conditions to the payment of the First, Second and Third Installments. The First, Second, and Third Installments have been paid by the Partnership. The total Capital Contribution of the Partnership to the Operating Partnership is based on the Operating Partnership receiving $479,990 Tax Credits during the 10-year period commencing in 1999 of which 99.99% ($479,940) will be allocated to the Partnership as the Investment Limited Partner of the Operating Partnership. The Partnership believes that the Apartment Complex is adequately insured. Ownership interests in the Operating Partnership are as follows, subject in each case to certain priority allocations and distributions as set forth in the Operating Partnership Agreement: Profits, Losses and Tax Credits Credits from Normal Capital Cash from Normal Operations Transactions Flow General Partner .01% 75% 85% Partnership 99.9 25% 5% Special Limited Partner 0% 0% The Special Limited Partner of the Operating Partnership is BCTC 94, Inc., an affiliate of the Partnership. The Partnership used funds obtained from the payments of the holders of its beneficial assignee certificates to make the acquisition of its interest in the Operating Partnership. Boston Capital, or an Affiliate thereof, is receiving an annual Asset Management Fee (which commenced in 1999) from the Operating Partnership for services in connection with the Operating Partnership's accounting matters and the preparation of tax returns and reports to the Partnership in the annual amount of $1,800. The Asset Management Fee for each Fiscal Year will be payable from Cash Flow in the manner and priority set forth in Section 11.03 of the Operating Partnership Agreement; provided, however, that if in any fiscal year, Cash Flow is insufficient to pay all or any portion of the Asset Management Fee, the General Partner shall make a Subordinated Loan to the Operating Partnership in an amount not to exceed the lesser of $1,800 per annum or that amount necessary to pay the unpaid portion of such fee. Any unpaid portion of said Asset Management Fee, to the extent the General Partner defaults in its obligation to make a Subordinated Loan, shall accrue, without interest, and shall be payable on a cumulative basis in the first year in which there is sufficient Cash Flow available for the payment of such fee, or, in the first year in which the proceeds of a Capital Transaction are available. The Operating Partnership is paying the General Partner a fee (the "Incentive Partnership Management Fee") (which commenced in 1999) for services in connection with the administration of the day-to-day business of the Operating Partnership in an annual amount equal to $1,800. The Incentive Partnership Management Fee for each fiscal year of the Operating Partnership shall be payable from Cash Flow or Proceeds from Capital Transactions in the manner and priority set forth in Sections 11.03 and 11.04(a) of the Operating Partnership Agreement. Such fee shall not be cumulative from year to year and shall only be paid to the extent that Cash Flow or Proceeds from Capital Transactions are sufficient to make all or a portion of the then-due payments. In consideration of its consultation, advice and other services in connection with the construction and development of the Apartment Complex, the Operating Partnership will pay the Developer a fee (the "Development Fee") in the principal amount of $198,626. The Development Fee, all of which has been deferred, shall be due and payable only in accordance with Section 11.03 of the Operating Partnership Agreement and, if not sooner paid, the total amount then outstanding will be payable on October 1, 2008. The Builder of the Apartment Complex will receive a total compensation of $926,658, which includes Builder's profit of $147,951. The Management Agent will receive a Management Fee equal to 5% of collected rental receipts. Item 7. Exhibits. (c) Exhibits. Page (1) (a)* Form of Dealer-Manager Agreement between Boston Capital Services, Inc. and the Registrant (including, as an exhibit thereto, the form of Soliciting Dealer Agreement) (2) (a) First Amended and Restated Agreement of Limited Partnership of Lombard Partners, L.P. (2) (b) Certification and Agreement for Lombard Partners, L.P. (2) (c) Partnership Management Services Agreement (2) (d) Lombard Heights Apartments Development Agreement (2) (e) Guaranty by Cunningham-Warren Properties, LLC, in favor of Lombard Partners, L.P. (4) (a)** Agreement of Limited Partnership of the Partnership (16) None (17) None (20) None (23) None (24) None (27) None * Incorporated by reference to Exhibit (1) to Registration Statement No. 33-70564 on Form S-11, as filed with the Securities and Exchange Commission. ** Incorporated by reference to Exhibit (4) to Registration Statement No. 33-70564 on Form S-11, as filed with the Securities and Exchange Commission. SIGNATURES Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned hereto duly authorized. Dated: January 21, 2000 BOSTON CAPITAL TAX CREDIT FUND IV L.P. By: Boston Capital Associates IV L.P., its General Partner By: C&M Associates, d/b/a Boston Capital Associates, its General Partner By: /s/ Herbert F. Collins Herbert F. Collins, Partner EX-4 2 LOMBARD PARTNERS, L.P. AMENDED AND RESTATED AGREEMENT OF LIMITED PARTNERSHIP As of October 15, 1998 LOMBARD PARTNERS, L.P. AMENDED AND RESTATED AGREEMENT OF LIMITED PARTNERSHIP This Amended and Restated Agreement of Limited Partnership is made and entered into as of October 15, 1998, by and among the undersigned parties. RECITALS A. As of January 9, 1997, Cunningham -Warren Properties, L.L.C., a Kansas limited liability company, (the "General Partner"), and Carolyn Cunningham, as initial limited partner (the "Initial Limited Partner"), executed an Agreement of Limited Partnership of Lombard Partners, L.P., a Missouri limited partnership (the "Initial Agreement") for the formation of Lombard Partners, L.P. (the "Partnership") pursuant to the Missouri Uniform Limited Partnership Act Chapter 359 R.S.Mo. (the "Act"); B. A Certificate of Limited Partnership was subsequently filed with the Secretary of State for Missouri on April 1, 1997; C. The Partnership has been formed to acquire, rehabilitate, construct, own, maintain and operate the hereinafter defined Apartment Complex; D. The parties hereto now desire to enter into this Amended and Restated Agreement of Limited Partnership to (i) continue the Partnership; (ii) admit Boston Capital Tax Credit Fund IV, L.P., a Massachusetts limited partnership, to the Partnership as a Limited Partner, and BCTC 94, Inc., a Massachusetts corporation, to the Partnership as the Special Limited Partner; (iii) withdraw the Initial Limited Partner from the Partnership; (v) reassign Interests in the Partnership; (vi) supercede all provisions of the Initial Agreement; and (vii) set forth all of the provisions governing the Partnership. NOW, THEREFORE, in consideration of the foregoing, of mutual promises of the parties hereto and of other good and valuable consideration, the receipt and sufficiency of which hereby are acknowledged, the parties hereby agree to continue the Partnership pursuant to the Act, as set forth in this Amended and Restated Agreement of Limited Partnership, which reads in its entirety as follows: ARTICLE I CONTINUATION OF PARTNERSHIP TC "ARTICLE I - CONTINUATION OF PARTNERSHIP"\l1 1.01. Continuation TC "1.01. Continuation"\l2 . The undersigned hereby continue the Partnership as a limited partnership under the Act. 1.02. Name TC "1.02. Name"\l2 . The name of the Partnership is Lombard Partners, L.P., a Missouri Limited Partnership. 1.03. Principal Executive Offices; Agent for Service of Process TC "1.03. Principal Executive Offices; Agent for Service of Process"\l2 . The principal executive and record office of the Partnership is 420 South Avenue, Springfield, Missouri 65806. The Partnership may change the location of its principal executive office to such other place or places as may hereafter be determined by the General Partner. The General Partner shall promptly notify all other Partners of any change in the principal executive office. The Partnership may maintain such other offices at such other place or places as the General Partner may from time to time deem advisable. The resident agent in Missouri for the Partnership for service of process is G. Windsor Warren, 420 South Avenue, Springfield, Missouri. 1.04. Term TC "1.04. Term"\l2 . The term of the Partnership commenced as of April 1, 1997 and shall continue until December 31, 2051, unless the Partnership is sooner dissolved in accordance with the provisions of this Agreement. 1.05. Recording TC "1.05. Recording"\l2 . Upon the execution of this Amended and Restated Agreement of Limited Partnership by the parties hereto, the General Partner shall take all necessary action required by law to perfect and maintain the Partnership as a limited partnership under the laws of the State; and to effectuate the admission of the Investment Partnership and the Special Limited Partner as Limited Partners and the withdrawal of the Initial Limited Partner hereunder. ARTICLE II DEFINED TERMS TC "ARTICLE II - DEFINED TERMS"\L1 In addition to the abbreviations of the parties set forth in the preamble to this Agreement, the following defined terms used in this Agreement shall have the meanings specified below: "Accountants" means such firm of independent certified public accountants as may be engaged by the General Partner, with the Consent of the Special Limited Partner, to prepare the Partnership income tax returns and to be responsible for the Partnership's audit and tax matters reporting obligations under Section 13.04 hereof. "Act" means the Missouri Uniform Limited Partnership Act, as cited in the recitals, as amended from time to time during the term of the Partnership. "Actual Credit" means as of any point in time, the total amount of the Tax Credits actually allocated by the Partnership to the Investment Partnership representing ninety-nine and ninety-eight hundredths percent (99.98%) of the Tax Credits actually received by the Partnership, as shown on the applicable tax return of the Partnership. "Admission Date" means the date upon which the Investment Partnership is admitted to the Partnership by execution and delivery of this Agreement by all signatories hereto and the filing of any such Certificates as may be required by the State to effectuate the admission of the Investment Partnership. "Affiliate" means any Person that directly or indirectly, through one or more intermediaries, controls or is controlled by or is under common control with a General Partner, or with another designated Person, as the context may require. "Affiliated Limited Partnership" means any limited partnership, other than the Partnership, in which the General Partner or an Affiliate of a General Partner is a general partner and the Investment Partnership or an Affiliate of the Investment Partnership is a limited partner. "Agency" means the Missouri Housing Development Commission in its capacity as the designated agency of the State to allocate Low-Income Housing Tax Credits, acting through any authorized representative. "Agreement" means this Amended and Restated Agreement of Limited Partnership, as amended from time to time. "Apartment Complex" means the land owned by the Partnership located at 3601 East Lombard, Springfield, Missouri and the 24- unit rental housing development and other improvements constructed thereon, and to be owned and operated therein by the Partnership, and known as Lombard Heights Apartments. "Applicable Percentage" has the meaning given to it in Section 42(b) of the Code. "Asset Management Fee" means the fee payable by the Partnership to Boston Capital, or an Affiliate thereof, pursuant to Section 8.11.1. "Bankruptcy" or "Bankrupt" as to any Person means (a) the entry of an order for relief (or similar court order) against such Person which authorizes a case brought under Chapter 7, 11 or 13 of Title 11 of the United States Code to proceed; (b) the commencement of a federal, state or foreign bankruptcy, insolvency, reorganization, arrangement or liquidation proceeding by such Person; (c) the commencement of a federal, state or foreign bankruptcy, insolvency, reorganization, arrangement or liquidation proceeding against such Person if such proceeding is not dismissed within sixty (60) days after the commencement thereof; (d) the entry of a court decree or court order which remains unstayed and in effect for a period of thirty (30) consecutive days: (i) adjudging such Person insolvent under any federal, state or foreign law relating to bankruptcy, insolvency, reorganization, arrangement, liquidation, receivership or the like; (ii) approving as properly filed a petition seeking reorganization, arrangement, adjustment or composition of, or in respect of, such Person or his properties under any federal, state or foreign law relating to insolvency, reorganization, arrangement, liquidation, receivership or the like; (iii) appointing a receiver, liquidator, assignee, trustee, conservator, or sequester (or other similar official) of such Person, or of all, or of a substantial part, of such Person's properties; or (iv) ordering the winding up, dissolution or liquidation of the affairs of such Person; (e) the written consent by such Person to the institution against it of any proceeding of the type described in subsection (a), (b), (c) and (d); (f) the written consent by such Person to the appointment of a receiver, liquidator, assignee, trustee, conservator or sequester (or other similar official) of such Person, or of all, or of a substantial part, of its properties; (g) the making by such Person of an assignment for the benefit of creditors; (h) the admission in writing by such Person of its inability to pay its debts generally as they come due; (i) the taking of any corporate or other action by such Person in furtherance of any of the foregoing; or (j) if such Person becomes insolvent by the making of any act or the making of any transfer, or otherwise, as "insolvency" is or may be defined pursuant to the Federal Bankruptcy Code, the Federal Bankruptcy Act, the Uniform Fraudulent Conveyances Act, any state or federal act or the ruling of any court. "Book Depreciation" has the meaning set forth in Section 11.12C. "Book Profits and Losses" means the Taxable Income or Tax Losses of the Partnership, adjusted for purposes of determining and maintaining the Partners' Capital Accounts as provided in Section 11.12. "Boston Capital" means Boston Capital Partners, Inc., a Massachusetts corporation. "Capital Account" means the capital account of a Partner as described in Section 11.12. "Capital Contribution" with respect to any Partner, means the total amount of money and the initial Gross Asset Value of any property (other than money) contributed or agreed to be contributed, as the context requires, to the Partnership by each Partner pursuant to the terms of this Agreement. Any reference to the Capital Contribution of a Partner shall include the Capital Contribution made by a predecessor holder of the Interest of such Partner. "Capital Transaction" means the sale, exchange or disposition (other than leasing in the ordinary course of business) of any Partnership property that is not in the ordinary course of business, or casualty damage to or condemnation of any Partnership property, or any substantial interest therein or portion thereof. "Carryover Certification" means the date upon which the Investment Partnership shall have received, in a form and in substance satisfactory to the Investment Partnership, the certification of the Accountants that as of a date no later than December 31, 1999, the Partnership shall have incurred capitalizable costs with respect to the Apartment Complex of at least ten percent (10%) of the Partnership's reasonably expected basis in the Apartment Complex as of December 31, 1999, so that each building in the Apartment Complex will constitute a "qualified building" for the purposes of Section 42(h)(1)(E)(ii) of the Code. "Cash Flow" means, with respect to any year or other applicable period, (a) all Revenues received by the Partnership during such period, plus (b) any amounts which the General Partner, acting jointly with the Special Limited Partner, releases from the Reserve Fund for Replacements as being no longer necessary to hold as part of the Reserve Fund for Replacements, less (i) all operating expenses and obligations of the Partnership paid or payable (on a thirty-day current basis) during the applicable period, including without limitation escrow deposits for taxes and insurance, maintenance and repairs, (ii) all sums due or currently required to be paid under the terms of the Mortgage Loan or any other third-party indebtedness of the Partnership, and (iii) all amounts from Revenues, if any, added or required to be added to the Reserve Fund for Replacements during such period. In no event will deductions in determining Cash Flow pursuant to clauses (i) and (ii) above include payments made on account of, the Asset Management Fee, amounts due on any Subordinated Loans, the Incentive Partnership Management Fee and/or the Deferred Development Fee, if any. Cash Flow shall be determined separately for each fiscal year and shall not be cumulative. "Certificate" means the Certificate of Limited Partnership for Lombard Partners, L.P., filed with the Secretary of State of Missouri on April 1, 1997, or any certificate of limited partnership or any other instrument or document which is required under the law of the State to be signed and/or sworn to by the Partners of the Partnership and filed in the appropriate public offices within the State to perfect or maintain the Partnership as a limited partnership under the laws of the State, to effect the admission, withdrawal or substitution of any Partner of the Partnership, or to protect the limited liability of the Limited Partners as limited partners under the laws of the State. "Code" means the Internal Revenue Code of 1986, as amended from time to time, or any corresponding provision or provisions of succeeding law. "Compliance Period" has the meaning ascribed to such term in Section 42 of the Code. "Consent" means the prior written consent or approval of the Special Limited Partner and/or the Investment Partnership and/or any other Partner, as the context may require, to do the act or thing for which the consent is solicited. "Construction Contract" means that certain construction contract (including all exhibits and attachments thereto) between the Partnership and the Contractor pursuant to which the Apartment Complex is being rehabilitated. "Contractor" means Cunningham Development Co., Inc., in its capacity as the general construction contractor for the Apartment Complex. "Cost Certification" means the date upon which each Limited Partner shall have received the written certification of the Accountants, in a form and in substance satisfactory to Boston Capital, as to the itemized amounts of the rehabilitation and development costs of the Apartment Complex and the Eligible Basis and Applicable Percentage (in each case, as defined in Section 42(d) of the Code), pertaining to each building in the Apartment Complex. "Counsel" or "Counsel for the Partnership" shall mean James M. Ramsey, Esq. or such other attorney or law firm upon which the Investment Partnership and the General Partner shall agree; provided, however, that if any section of this Agreement either (i) designates particular counsel for the purpose described therein, or (ii) provides that counsel for the purpose described therein shall be chosen by another method or by another Person, then such designation or provision shall prevail over this general definition. The Limited Partners have been, and will continue to be, separately represented by Burns & Levinson LLP or such other counsel as they may choose in connection with all Partnership matters. "Credit Recovery Loan" has the meaning set forth in Section 5.01(d)(iii). "Credit Shortfall" means the amount by which the Actual Credit is less than the Projected Credit (or Revised Projected Credit) for any year or portion thereof. "Debt Service" means scheduled principal and interest payments on indebtedness under the Mortgage Loan determined on an annual basis for each year of Partnership operations, but excluding (i) principal and interest due on acceleration of the Mortgage Loan upon occurrence of an event of default and (ii) balloon payments of principal and interest due upon expiration of the term of the Mortgage Loan "Developer" means Cunningham-Warren Properties, L.L.C. "Deferred Development Fee" means any portion of the Development Fee not actually paid to and received by the Developer from the Installments, the payment of which is deferred and payable only in accordance with Sections 5.01(a), 11.03 and 11.04(A) hereof. "Development Fee" means the fee payable by the Partnership to the Developer pursuant to Section 8.10 of this Agreement. "Development Sources" means the aggregate of: (a) the Capital Contributions of the General Partner, as set forth in Section 5.01(a) of this Agreement (including the Special Construction Capital Contribution referred to therein); (b) the Capital Contributions of the Investment Partnership, as set forth in Section 5.01(a) of this Agreement, less the amount of the non- Deferred Development Fee; (c) the proceeds of the Permanent Loan; and (d) any rental income of the Partnership for the period prior to Final Closing. "Distributable Proceeds from Capital Transactions" means the excess of all cash receipts and other consideration arising from the sale or other disposition of all or any portion of the Apartment Complex or any proceeds realized from condemnation, casualty, or title defect, but excluding proceeds, if any, from rental interruption insurance or a temporary condemnation in the nature of a lease, over the sum of the following, to the extent paid out of such cash receipts or other consideration: (i) the amount of cash disbursed or to be disbursed in connection with or as an expense of such sale or other disposition, (ii) the amount necessary for the payment of all debts and obligations of the Partnership arising from or otherwise related to such sale or other disposition or to which the Apartment Complex is subject and which are otherwise then due (other than debts and obligations owed to the Partners and their Affiliates, which shall be satisfied in the order set forth in Section 11.04), and (iii) any amounts set aside by the General Partner for reserves which the General Partner deems reasonably necessary for contingent, unmatured or unforeseen liabilities of the Partnership. "Distributable Proceeds from Refinancings" means the excess of the gross proceeds of any borrowing by the Partnership over the sum of the following, to the extent paid out of such gross proceeds: (i) any amounts disbursed to repay then existing loans of the Partnership and to pay and provide for all debts and obligations of the Partnership then to be paid or which are otherwise then due (other than debts and obligations owed to the Partners and their Affiliates, which shall be satisfied in the order set forth in Section 11.04), (ii) all reasonable expenses of such borrowings, including, without limitation, all commitment fees, brokers' commissions, and attorneys' fees, (iii) all amounts paid to improve the Apartment Complex or for any other purpose in order to satisfy conditions to or established in connection with such borrowings, and (iv) any amounts used to meet the operating expenses of the Apartment Complex or set aside by the General Partner for reserves which the General Partner deems reasonably necessary for contingent, unmatured, or unforeseen liabilities of the Partnership. "Eligible Basis" has the meaning given to it in Section 42(d) of the Code. "Excess Development Costs" means all funds in excess of the Development Sources which are required to (i) complete rehabilitation and/or construction, as applicable, of the Apartment Complex, (ii) achieve Substantial Completion, (iii) achieve Final Closing and satisfy any escrow deposit requirements which are conditions to the Final Closing, including without limitation, any amounts necessary for local taxes, utilities, insurance premiums and other amounts which are required, (iv) pay any applicable loan assessment fees, discounts or other costs and expenses incurred by the Partnership as a result of the occurrence of the Final Closing, (v) make the required deposit into the Operating Deficit Reserve, (vi) make the required deposit into the Reserve Fund for Replacements and (vii) pay any Operating Deficits incurred by the Partnership prior to the occurrence of Rental Achievement. Excess Development Costs shall not include any amounts paid or to be paid in respect of the Development Fee. "Extended Use Commitment" means the agreement between the Partnership and the Agency, which is intended to meet the definition of a "long term commitment to low-income housing" as required by Section 42(h)(6) of the Code and the requirements of the Agency's Low-Income Housing Tax Credit Program. "Final Closing" means the occurrence of both of the following: (i) Substantial Completion, and (ii) the closing of the Permanent Loan pursuant to the terms of the Permanent Loan Documents and upon satisfaction or waiver of all conditions to such closing set forth therein. "40-60 Set-Aside Test" means the Minimum Set-Aside Test whereby at least 40% of the units in the Apartment Complex must be occupied by individuals, with incomes of 60% or less of area median income, as adjusted for family size. "General Partner" means Cunningham-Warren Properties, L.L.C., a Kansas Limited Liability Company, and any other Person or entity admitted as a general partner pursuant to this Agreement, and their respective successors pursuant to this Agreement, including particularly the provisions of Section 6.03 and 8.13. "General Partner's Special Capital Contribution" has the meaning ascribed to such term in Section 5.01 of this Agreement. "Gross Asset Value" means, with respect to any asset, the asset's adjusted basis for federal income tax purposes, except as adjusted pursuant to Section 11.12B. The initial Gross Asset Value of any asset contributed by a Partner to the Partnership shall be the gross fair market value of such asset, as determined by the contributing Partners and the Partnership. "Guarantor" means collectively, Hollis O. Cunningham, G. Windsor Warren and G. Windsor Warren, as trustee of the Revocable Trust Agreement of G. Windsor Warren u/d/t dated July 19, 1991. "Incentive Partnership Management Fee" means the fee payable by the Partnership to the General Partner pursuant to Section 8.11 of this Agreement. "Initial 100% Occupancy Date" means the first date, after the completion of construction, upon which 100% of the low-income apartment units in the Apartment Complex have been leased to and are occupied by, qualified tenants under executed Agency approved leases, if any such approval is applicable. "Installment" means an Installment of the Investment Partnership's Capital Contribution paid or payable to the Partnership pursuant to Section 5.01. "Interest" or "Partnership Interest" means the ownership interest of a Partner in the Partnership at any particular time, including the right of such Partner to any and all benefits to which such Partner may be entitled as provided in this Agreement and in the Act, together with the obligations of such Partner to comply with all the terms and provisions of this Agreement and of said Act. Such Interest of each Partner shall, except as otherwise specifically provided herein, be that percentage of the aggregate of such benefit or obligation specified by Section 5.01 as such Partner's Percentage Interest. "Invested Amount" means (i) as to the Investment Partnership, an amount equal to the paid-in Capital Contribution of the Investment Partnership divided by .87 and (ii) as to any other Partner, an amount equal to its paid-in Capital Contribution. "Investment Partnership" means Boston Capital Tax Credit Fund IV, L.P., a Massachusetts limited partnership, which is a Limited Partner of the Partnership. "Issuer" means The Industrial Development Authority of the City of Springfield, Missouri as issuer of the Permanent Loan. "Land" means the real property which the Partnership owns or expects to own, upon which the Apartment Complex is or will be located. "Lender" means the Permanent Lender, or each of its successors and assigns in such capacity, including any substitute Lender permitted pursuant to Section 8.02(b)(v) hereof, each acting through any authorized representative. "Limited Partners" means the Investment Partnership and/or the Special Limited Partner, or any other Limited Partner in such Person's capacity as a limited partner of the Partnership. "Liquidator" means the General Partner or, if there is none at the time in question, such other Person who may be appointed in accordance with applicable law and who shall be responsible for taking all action necessary or appropriate to wind up the affairs of, and distribute the assets of, the Partnership upon its dissolution. "Loan Documents" means, collectively, all documents entered into by the Partnership in connection with the Permanent Loan. "Low-Income Housing Tax Credit" means the low-income housing tax credit allowed for low-income housing projects pursuant to Section 42 of the Code. "Low-Income Unit" shall have the meaning set forth in Section 42(i)(3) of the Code. "Management Agent" means the management and rental agent for the Apartment Complex and/or its successors and/or assigns, as described in Section 8.05 hereof. "Management Agreement" means the agreement between the Partnership and the Management Agent providing for the management of the Apartment Complex, approved as to form by the Investment Partnership. "Minimum Gain" means the amount determined by computing, with respect to each non-recourse liability of the Partnership, the amount of Taxable Income, if any, that would be realized by the Partnership if it disposed of (in a taxable transaction) the property subject to such liability in full satisfaction thereof, and by then aggregating the amounts so computed, in accordance with Treasury Regulation 1.704-2(d). For purposes of determining the amount of such Taxable Income with respect to a liability, the adjusted basis, for federal income tax purposes, of the asset subject to the liability shall be allocated among all the liabilities that the asset secures in the manner set forth in Treasury Regulation 1.704-2(d)(2) (or successor provisions). If Partnership property subject to one or more non-recourse liabilities of the Partnership is, under Treasury Regulation 1.704-1(b)(2)(iv)(d),(f), or (r), properly reflected on the books of the Partnership at a book value that differs from the adjusted tax basis of such property, then the determination of Minimum Gain shall be made with reference to such book value. "Minimum Set-Aside Test" means the set-aside test selected by the Partnership pursuant to Section 42(g) of the Code with respect to the percentage of units in its Apartment Complex to be occupied by tenants with incomes equal to no more than a certain percentage of area median income. The Partnership has selected or will select the 40-60 Set-Aside Test as the Minimum Set-Aside Test. "Mortgage" means, collectively, the Mortgage Deeds and/or or Deeds of Trust given by the Partnership to any Lender securing the Mortgage Loan. The term "mortgage" means any mortgage, mortgage deed, deed of trust, deed to secure debt, or any other similar security instrument, and "foreclose" and words of like import include the exercise of a power of sale under a mortgage or comparable remedies. "Mortgage Loan" means the Permanent Loan. "Net Capital Contribution" means an amount equal to a Partner's paid-in Capital Contribution, less the aggregate amount of cash distributions, if any, made to such Partner hereunder. "Nonrecourse Deductions" has the meaning set forth in Section 1.704-2(c) of the Treasury Regulations. The amount of Nonrecourse Deductions for a Fiscal Year of the Partnership equals the net increase, if any, in the amount of Minimum Gain during that Fiscal Year, determined according to the provisions of Treasury Regulation Section 1.704-2(c). "Notice" means a writing containing the information required by this Agreement to be communicated to a Partner and sent by registered or certified mail, postage prepaid, return receipt requested, to such Partner at the last known address of such Partner, the date of registry thereof or the date of the certification receipt therefor being deemed the date of such Notice; provided, however, that any written communication containing such information sent to such Partner actually received by such Partner shall constitute Notice for all purposes of this agreement. "Operating Deficit " means the amount by which (i) the income of the Partnership from rental payments made by tenants of the Apartment Complex and all other income of the Partnership, including unrestricted earnings on reserve or escrow funds (other than proceeds of any loans to the Partnership and investment earnings on funds on deposit in the Reserve Fund for Replacements) for a particular period of time, is exceeded by (ii) the sum of all the operating expenses, including all Debt Service payments, operating and maintenance expenses, deposits into the Reserve Fund for Replacements, any Lender fee payments, and all other Partnership obligations or expenditures, excluding payments for rehabilitation of the Apartment Complex and fees and other expenses and obligations of the Partnership to be paid from the Capital Contributions of the Investment Partnership to the Partnership pursuant to this Agreement, during the same period of time. For the purposes of this definition, all expenses shall be paid on a thirty (30) day current basis. In no event will deductions in determining Operating Deficits pursuant to clause (ii) above include payments made on account of the Asset Management Fee (unless guaranteed), amounts due on Subordinated Loans and/or the Deferred Development Fee. "Operating Deficit Loan" means a loan made pursuant to Section 8.09(b). "Operating Deficit Reserve" means the operating deficit reserve account established pursuant to the provisions of Section 8.18(b) of this Agreement. "Partner" means any General Partner or any Limited Partner. "Partner Nonrecourse Debt Minimum Gain" has the meaning attributed to "partner loan nonrecourse debt minimum gain" in Treasury Regulation 1.704-2(i)(3). "Partner Loan Nonrecourse Deductions" means any deductions of the Partnership that are attributable to a nonrecourse liability for which a Partner bears the risk of loss within the meaning of Treasury Regulation Section 1.704-2(i). "Partnership" means Lombard Partners, L.P., a Missouri limited partnership. "Partnership Agreement" means this Amended and Restated Agreement of Limited Partnership, as amended from time to time. "Percentage Interest" means the percentage Interest of each Partner as set forth in Section 5.01. "Permanent Lender" means the Issuer. "Permanent Loan" means the $800,000 The Industrial Development Authority of the City of Springfield, Missouri Multifamily Housing Revenue Bonds (Lombard Heights Apartment Project) Series 1998 issue, dated May 1, 1998. "Permanent Loan Documents" mean collectively all documents executed and/or delivered in connection with the Permanent Loan. "Person" means any individual, partnership, corporation, trust or other entity. "Plans and Specifications" means the plans and specifications for rehabilitation of the Apartment Complex, referred to in the Construction Contract and any changes thereto made in accordance with the terms of this Agreement. "Project Documents" means and includes the Loan Documents, the Extended Use Commitment, the Regulatory Agreement, if any, the Management Agreement and all other instruments delivered to (or required by) the Lender or the Agency and all other documents relating to the Apartment Complex and by which the Partnership is bound, as amended or supplemented from time to time. "Projected Credit" means Low-Income Housing Tax Credits in the amount of $47,994 per year for each of the years 1999 through 2008, constituting ninety-nine and ninety-nine one hundredths percent (99.99%) of the Tax Credits which the General Partner has projected to be available to the Partnership. "Regulatory Agreement" means the Land Use Restriction Agreement dated as of May 1, 1998 among the Partnership, the Issuer and State Street Bank and Trust Company, as trustee setting forth certain terms and conditions under which the Apartment Complex is to be operated. "Rent Restriction Test" means the test pursuant to Section 42 of the Code whereby the gross rent charged to tenants of the Low-Income Units in the Apartment Complex cannot exceed 30% of the qualifying income levels of those units under Section 42. "Rental Achievement" means the first time, based upon three (3) consecutive full calendar months of operation after Final Closing, with each month taken individually, that Cash Available for Debt Service Requirements (as defined below) equals or exceeds 1.15 times Debt Service requirements. "Cash Available for Debt Service Requirements" for any period means the excess of (i) all cash actually received by the Partnership on a cash basis from normal operations during such period, but specifically excluding the proceeds of insurance (other than business or rental interruption insurance), loans, Capital Transactions or Capital Contributions over (ii) all cash requirements of the Partnership properly allocable to such period of time on an accrual basis (not including distributions to Partners out of Cash Flow of the Partnership or fees payable from Cash Flow) and, on an annualized basis, all projected expenditures, including those of a seasonal nature, which might reasonably be expected to be incurred on an unequal basis during a full annual period of operation, but specifically excluding Debt Service requirements. For purposes of this definition, cash requirements of the Partnership shall include to the extent not otherwise covered above, full funding of all Partnership reserves, normal repairs, real estate taxes at fully assessed levels assuming a fully improved property, and necessary capital improvements. "Reserve Fund for Replacements" means the reserve fund for replacements with respect to the Apartment Complex as established pursuant to the provisions of Section 8.18(a) of this Agreement. "Revenues" means all cash receipts of the Partnership during any period except for Capital Contributions, proceeds from the liquidation, sale or refinancing of Partnership property or of a Capital Transaction, or the proceeds of any loan to the Partnership. "Revised Projected Credit" has the meaning set forth in Section 5.01(d)(i). "Share of Minimum Gain" means for each Partner, the excess of (1) the sum of (a) the aggregate Non-Recourse Deductions allocated to such Partner (and such Partner's predecessors in interest) up to that time and (b) the aggregate distributions to such Partner (and such Partner's predecessors in interest) up to that time of proceeds of a non-recourse liability that are allocable to an increase in Partnership Minimum Gain over (2) the sum of (a) such Partner's (and such Partner's predecessors in interest) aggregate share of the net decrease in Partnership Minimum Gain up to that time and (b) such Partner's (and such Partner's predecessors in interest) aggregate share of the decreases up to that time in Partnership Minimum Gain resulting from revaluations of Partnership Property subject to one or more non-recourse liabilities of the Partnership, as more fully set forth in Treasury Regulation 1.704-2(g). "Special Limited Partner" means BCTC 94, Inc., a Massachusetts corporation, which is the Special Limited Partner of the Partnership. "State" means Missouri. "State Designation" means, with respect to the Apartment Complex, the final allocation by the Agency of Low-Income Housing Tax Credits, as evidenced by the receipt by the Partnership of IRS Form 8609 executed by the Agency as to all buildings in the Apartment Complex. "Subordinated Loan" means any loan made by the General Partner to the Partnership pursuant to Section 8.17. "Substantial Completion" means the date upon which the Partnership has received (a) both a certificate of substantial completion from the applicable inspecting architect certifying that the construction has been completed in accordance with the Plans and Specifications and (b), if applicable, certificates of substantial completion or certificates of occupancy from the applicable governmental jurisdiction(s) or authority(ies) for one hundred percent (100%) of the apartment units in the Apartment Complex; provided, however, that Substantial Completion shall not be deemed to have occurred if on such date any liens or other encumbrances as to title to the Land and the Apartment Complex exist, other than those securing the Mortgage Loan and/or those Consented to by the Investment Partnership. "Substitute Limited Partner" means any Person admitted to the Partnership as a Limited Partner pursuant to Section 9.03. "Syndication Expenses" means all expenditures classified as syndication expenses pursuant to Treasury Regulation Section 1.709-2(B). Syndication Expenses shall be taken into account in determining and maintaining Capital Accounts pursuant to Section 11.12 of this Agreement at the time they would be taken into account under the Partnership's method of accounting if they were deductible expenses. "Taxable Income" and "Tax Losses" means the Partnership's taxable income or tax losses, respectively, for each fiscal year (or part thereof) as determined for federal income tax purposes, including, where the context requires, all items of income, gain, loss, deduction and credit which enter into the computation thereof. "Tax Credit" means the Low-Income Housing Tax Credit. "Tax Credit Set-Aside" means the date upon which the Partnership received a reservation for an allocation of Tax Credit, by the Agency in an annual dollar amount of not less than $47,999, which reservation shall not have expired or been revoked prior to the date on which the First Installment is paid. ARTICLE III PURPOSE AND BUSINESS OF THE PARTNERSHIP TC "ARTICLE III - PURPOSE OF BUSINESS OF THE PARTNERSHIP"\l1 3.01. Purpose of the Partnership TC "3.01. Purpose of the Partnership"\l2 . The Partnership has been organized to acquire the Land and to construct the Apartment Complex located and to develop, finance, own, construct, rehabilitate, maintain, operate and sell or otherwise dispose of the Apartment Complex, in order to obtain long-term appreciation, cash income, Tax Credits and tax losses and to manage the Apartment Complex in a manner that provides and preserves safe, decent, affordable housing and needed supportive services. 3.02. Authority of the Partnership TC"3.02. Authority of the Partnership"\2 . In order to carry out its purpose, the Partnership is empowered and authorized to do any and all acts and things necessary, appropriate, proper, advisable, incidental to or convenient for the furtherance and accomplishment of its purpose, and for the protection and benefit of the Partnership, including but not limited to the following: (a) acquire ownership of the Land and construct the Apartment Complex to be located thereon; (b) rehabilitate, operate, maintain, improve, buy, own, sell, convey, assign, mortgage, rent or lease any real estate and any personal property necessary to the operation of the Apartment Complex; (c) provide housing, subject to the Minimum Set-Aside Test and the Rent Restriction Test and consistent with the requirements of the Project Documents so long as any Project Documents remain(s) in force; (d) enter into any kind of activity, and perform and carry out contracts of any kind necessary to, or in connection with, or incidental to, the accomplishment of the purposes of the Partnership; (e) borrow money and issue evidences of indebtedness in furtherance of the Partnership business and secure any such indebtedness by mortgage, pledge, or other lien; (f) maintain and operate the Apartment Complex, including hiring the Management Agent (which Management Agent may be any of the Partners or an Affiliate thereof) and entering into any agreement for the management of the Apartment Complex during its rent-up and after its rent-up period; (g) subject to the approval of the Agency and/or the Lender, if required, and to other limitations expressly set forth elsewhere in this Agreement, negotiate for and conclude agreements for the sale, exchange, lease or other disposition of all or substantially all of the property of the Partnership, or for the refinancing of any mortgage loan on the property of the Partnership; (h) enter into the Loan Documents with the Lender and grant the Mortgage, enter into the Mortgage Loan and all other documents required by the Lender with respect to the Mortgage Loan, and the Extended Use Commitment and Regulatory Agreement, if any, with the Agency, providing for regulations with respect to rents, profits, dividends and the disposition of the Apartment Complex and the long-term use of the Apartment Complex for low- income housing; (i) rent dwelling units in the Apartment Complex from time to time, in accordance with the provisions of the Code applicable to Low-Income Housing Tax Credits and in accordance with applicable federal, state and local regulations, collecting the rents therefrom, paying the expenses incurred in connection with the Apartment Complex, and distributing the net proceeds to the Partners, subject to any requirements which may be imposed by the Extended Use Commitment, the Regulatory Agreement, if any, and the Loan Documents; and (j) do any and all other acts and things necessary or proper in furtherance of the Partnership business. ARTICLE IV REPRESENTATIONS, WARRANTIES AND COVENANTS; DUTIES AND OBLIGATIONS TC "ARTICLE IV - REPRESENTATIONS, WARRANTIES AND COVENANTS, DUTIES AND OBLIGATIONS"\L1 4.01. Representations, Warranties and Covenants Relating to the Apartment Complex and the Partnership TC "4.01. Representations, Warranties and Covenants Relating to the Apartment Complex and the Partnership"\L2 . As of the date hereof, the General Partner hereby represents, warrants and covenants to the Partnership and to the Partners that: (a) the construction, rehabilitation and development of the Apartment Complex shall be completed in a timely and workmanlike manner in accordance with (i) all applicable requirements of the Construction Contract and the Project Documents, (ii) all applicable requirements of all appropriate governmental entities, and (iii) the Plans and Specifications of the Apartment Complex that have been or shall be hereafter approved by the Lender and any applicable governmental entities, as such Plans and Specifications may be changed from time to time with the approval of the Lender and any applicable governmental entities, if such approval shall be required; (b) at the commencement of construction or rehabilitation, and as of the date hereof, the Land is and will be properly zoned for the Apartment Complex, all consents, permissions and licenses required by all applicable governmental entities have been obtained (excepting however any certificates of occupancy which must be obtained prior to the occupancy of the Apartment Complex, which such certificates will be obtained by the General Partner on behalf of the Partnership), and the Apartment Complex conformed and conforms to all applicable federal, state and local land use, zoning, environmental and other governmental laws and regulations; (c) all appropriate public utilities, including sanitary and storm sewers, water, gas and electricity, are currently available and will be operating properly for all units in the Apartment Complex at the time of first occupancy of such units; (d) as of the date hereof, at the Final Closing, good and marketable fee simple title to the Apartment Complex is and will be held by the Partnership, and title insurance policies of a financially-responsible institution acceptable to the Special Limited Partner, in the amount of the replacement cost of the Apartment Complex, which amount (as to the Partnership) shall not be less than the aggregate of the Invested Amount of the General Partner and the Investment Partnership plus the principal amount of the Mortgage Loan, in favor of the Partnership were issued, and remain in full force and effect, subject only to such easements, covenants, restrictions and such other standard exceptions as are normally included in owner's or mortgagee's title insurance policies and which are acceptable to the Special Limited Partner and shall contain a non-imputation endorsement and such other endorsements as deemed reasonably necessary by the Special Limited Partner; (e) the General Partner is not aware of any default under any agreement, contract, lease, or other commitment, or of any claim, demand, litigation, proceedings or governmental investigation pending or threatened against it, the Apartment Complex or the Partnership, or related to the business or assets of the Partnership or of the Apartment Complex, which claim, demand, litigation, proceeding or governmental investigation could result in any judgment, order, decree, or settlement which would materially and adversely affect the business or assets of the Partnership, the General Partner, or of the Apartment Complex; (f) except for the commitment fees paid to the Lender, neither the General Partner nor any Affiliate of the General Partner or the Partnership, has entered, or shall enter into any agreement or contract for the payment of any Mortgage Loan discounts, additional interest, yield maintenance or other interest charges or financing fees or any agreement providing for the guarantee of payment of any such interest charges or financing fees relating to the Mortgage Loan. (g) the execution of this Agreement, the incurrence of the obligations set forth in this Agreement, and the consummation of the transactions contemplated by this Agreement do not violate any provision of law, any order, judgment or decree of any court binding on the Partnership, the General Partner or any of them or their Affiliates, any provision of any indenture, agreement, or other instrument to which the Partnership or they or either of them is a party or by which the Partnership or the Apartment Complex is affected, and is not in conflict with, and will not result in a breach of or constitute a default under any such indenture, agreement, or other instrument or result in creating or imposing any lien, charge, or encumbrance of any nature whatsoever upon the Apartment Complex; (h) the Construction Contract will be entered into between the Partnership and the Contractor; no other consideration or fee shall be paid to the Contractor, in its capacity as the Contractor, other than the amounts set forth in the Construction Contract or as evidenced by change orders approved by the Lender or as otherwise disclosed in writing to and approved by the Investment Partnership; and all change orders that have been submitted by the Contractor to date have been paid in full; (i) as of the date hereof, the General Partner, on behalf of the Partnership, will maintain liability insurance covering the Land and the Apartment Complex in an amount equal to the full replacement value thereof; The term "full replacement value" as used herein shall mean and include the total cost of replacement of the Apartment Complex at each respective stage of construction or rehabilitation, as applicable, thereof up to completion; (j) neither the General Partner nor the Partnership has incurred any financial responsibility with respect to the Apartment Complex prior to the date of execution of this Agreement, other than that disclosed to the Investment Partnership; (k) at the time of execution of this Agreement, at the time of Final Closing, and at Substantial Completion, the Partnership was, is and will continue to be a valid limited partnership, duly organized under the laws of the State, (and, if the Apartment Complex is located in a state other than the State, the Partnership has been duly registered as a foreign limited partnership in such state) had, has and shall continue to have full power and authority to acquire the Land and to rehabilitate, develop, operate and maintain the Apartment Complex in accordance with the terms of this Agreement, and has taken and shall continue to take all action under the laws of the State and any other applicable jurisdiction that is necessary to protect the limited liability of the Limited Partners and to enable the Partnership to engage in its business; (l) no restrictions on the sale or refinancing of the Apartment Complex, other than the restrictions set forth in the Loan Documents, in the Extended Use Commitment, the Regulatory Agreement, if any, and as set forth in this Agreement, exist as of the date hereof, and no such restrictions shall, at any time while the Investment Partnership is a Limited Partner, be placed upon the sale or refinancing of the Apartment Complex; (m) the Apartment Complex is being developed in a manner which satisfies, and shall continue to satisfy, all restrictions, including tenant income and rent restrictions, applicable to projects generating Low-Income Housing Tax Credits under Section 42 of the Code; (n) the Tax Credits projected to be applicable to the Apartment Complex are the Projected Credits; (o) the General Partner shall obtain from the Agency, not later than December 31, 1998 a duly authorized, valid and binding carryover allocation of Low-Income Housing Tax Credits in the name of the Partnership and as to the Apartment Complex in an amount not less than $47,999 per year should the Apartment Complex not be complete and placed in service, each determined by the Investment Partnership, by October 1, l998; (p) to the best of its knowledge after due inquiry, at the time of the execution of this Agreement, the General Partner has fully complied with all applicable material provisions and requirements of any and all purchase and/or lease agreements, loan agreements, Project Documents and other agreements with respect to the acquisition, development, financing, rehabilitation and operation of the Apartment Complex; it shall take, and/or cause the Partnership to take, all actions as shall be necessary to achieve and maintain continued compliance with the provisions, and fulfill all applicable requirements, of such agreements; (q) the obligations of the General Partner will be guaranteed by the Guarantors pursuant to the terms of an unlimited guaranty of even date by and between the Partnership and the Guarantor(s); and (r) the Partnership shall satisfy all conditions to the Agency's allocation of Tax Credits set forth in the Carryover Allocation Agreement and all other documents entered into with the Agency within the time periods specified in each such document, and, in each case, to the extent required to be satisfied as of the date hereof and shall remain in full compliance with the Agency's requirements. (s) the Partnership is not in default under either of the Mortgage Loan and knows of no event that with the passage of time, would constitute an event of default under either of the Mortgage Loan. 4.02. Duties and Obligations Relating to the Apartment Complex and the Partnership TC "4.02. Duties and Obligations Relating to the Apartment Complex and the Partnership"\L2 . The General Partner shall have the following duties and obligations with respect to the Apartment Complex and the Partnership: (a) all requirements shall be met which are necessary to obtain or achieve (i) compliance with the Minimum Set-Aside Test, the Rent Restriction Test, and any other requirements necessary for the Apartment Complex to initially qualify, and to continue to qualify, for Tax Credits, including all requirements set forth in the Extended Use Commitment, (ii) issuance of all necessary certificates of occupancy, including all governmental approvals required to permit occupancy of all of the apartment units in the Apartment Complex, (iii) Final Closing and (iv) compliance with all provisions of the Project Documents; (b) while conducting the business of the Partnership, the General Partner shall not act in any manner which it knows or should have known after due inquiry will (i) cause the termination of the Partnership for federal income tax purposes without the Consent of the Investment Partnership, or (ii) cause the Partnership to be treated for federal income tax purposes as an association taxable as a corporation; (c) the Apartment Complex shall be managed upon Substantial Completion so that (i) not less than eighty per cent (80%) of the gross income from the Apartment Complex in every year is rental income from dwelling units in the Apartment Complex used to provide living accommodations not on a transient basis, (ii) the rental of all units in the Apartment Complex complies with the tenant income limitations and other restrictions under the Rent Restriction Test and as set forth in the Extended Use Commitment and all applicable documents entered into in connection with the Mortgage Loan, and (iii) one hundred percent (100%) of the Low- Income Units in the Apartment Complex are occupied or held for occupancy by individuals with incomes of sixty percent (60%) or less of area median income as adjusted for family size; (d) the General Partner shall exercise good faith in all activities relating to the conduct of the business of the Partnership, including the development, operation and maintenance of the Apartment Complex, and shall take no action with respect to the business and property of the Partnership which is not reasonably related to the achievement of the purpose of the Partnership; (e) all of (i) the fixtures, maintenance supplies, tools, equipment and the like now and to be owned by the Partnership or to be appurtenant to, or to be used in the operation of the Apartment Complex, as well as (ii) the rents, revenues and profits earned from the operation of the Apartment Complex, will be free and clear of all security interests and encumbrances except for the Mortgage Loan and the Mortgage, and any additional security agreements executed in connection therewith; (f) the General Partner will execute on behalf of the Partnership all documents necessary to elect, pursuant to Sections 732, 743 and 754 of the Code, to adjust the basis of the Partnership's property upon the request of the Special Limited Partner, if, in the sole opinion of the Investment Partnership, such election would be advantageous to the Special Limited Partner and any such elections (including elections made at the direction or with the consent of the Special Limited Partner) shall not reduce the obligations of the General Partner pursuant to Section 5.01(d); (g) the General Partner guarantees payment by the Partnership of any Credit Recovery Loan, the Asset Management Fee, and Excess Development Costs, as more fully provided herein and in the Guaranty; (h) the General Partner shall comply and cause the Partnership to comply with the provisions of all applicable governmental and contractual obligations; (i) the General Partner shall be responsible for the payment of any fines or penalties imposed by the Agency or the Lender pursuant to the Project Documents and any documents executed in connection with obtaining Tax Credits (other than with respect to payments of principal or interest under the Mortgage Loan from and after Final Closing); (j) the General Partner shall promptly notify the Investment Partnership of any written or oral notice of (i) any default or failure of compliance with respect to the Mortgage Loan or any other financial, contractual or governmental obligation of the Partnership or the General Partner (in the case of the General Partner, if such default or failure of compliance may have a material adverse impact on the Partnership or its operations), or (ii) any Internal Revenue Service proceeding regarding the Apartment Complex or the Partnership; (k) the General Partner shall provide the Investment Partnership with such information and sign such documents as are necessary for the Partnership to make timely, accurate and complete submissions of federal and state income tax returns; (l) within thirty (30) days following the Admission Date, the General Partner shall submit to Boston Capital evidence of the Partnership's engagement of Accountants, who have been approved by the Special Limited Partner, to be responsible for the Partnership's audit and tax matter reporting obligations under Section 13.04 hereof; (m) the General Partner shall provide to Special Limited Partner, for its approval and Consent, prior to execution, a copy of the Extended Use Commitment to be entered into between the Partnership and the Agency and shall ensure that such Extended Use Commitment is executed and ensure that all Lenders subordinate to same and recorded no later than the end of the first taxable year in which any Tax Credit is claimed by the Partnership with respect to any building in the Apartment Complex; and (n) the General Partner shall establish and maintain all reserve accounts required by the Lender pursuant to the Loan Documents. ARTICLE V PARTNERS, PARTNERSHIP INTERESTS AND OBLIGATIONS OF THE PARTNERSHIP TC "ARTICLE V - PARTNERS, PARTNERSHIP INTERESTS AND OBLIGATIONS OF THE PARTNERSHIP"\l1 5.01. Partners, Capital Contributions and Partnership Interests TC "5.01. Partners, Capital Contributions and Partnership Interests"\l2 . (a) The General Partner, its principal address or place of business, its Capital Contribution and Percentage Interest are as follows: Cunningham-Warren Properties, LLC $164,227 .01% 11260 W. 155th Terrace Overland Park, KS 66221 In the event that the Partnership has not paid all or part of the Deferred Development Fee when the final payment is due pursuant to the Development Agreement and Section 8.10 hereof, the General Partner shall contribute to the Partnership an amount equal to any such remaining principal balance (the "General Partner's Special Capital Contribution") and the Partnership shall thereupon make a payment in an equal amount to pay off the balance due under the Development Agreement. The capital contribution of the General Partner reflects, in part, an amount equal to $164,217 which constitutes an amount contributed by the General Partner to the Partnership necessary to fund additional project costs. (the "General Partner's Special Capital Construction Contribution"). (b)(i) The Investment Partnership, its principal office or place of business, its Capital Contribution and its Percentage Interest is as follows: Boston Capital Tax Credit Fund IV, $359,958 99.98% L.P. c/o Boston Capital Partners, Inc. One Boston Place as more Boston, MA 02108 specifically set forth in sub- paragraph (c)(i) immediately below (ii) The Special Limited Partner, its principal office or place of business, its Capital Contribution and its Percentage Interest is as follows: BCTC 94, Inc. $10.00 0.01% c/o Boston Capital Partners, Inc. One Boston Place, 21st Floor Boston, MA 02210 (c) Subject to the provisions of this Agreement, including, without limitation, the provisions of Sections 5.01(d) and 5.03, the Investment Partnership shall be obligated to make Capital Contributions to the Partnership in the aggregate amount of $359,958 in four (4) installments (the "Installments"), which Installments shall be due and payable in cash by the Investment Partnership within twenty-one (21) days after the Investment Partnership shall have received evidence, reasonably satisfactory to them, of the occurrence of each of the conditions set forth below as to the applicable Installment, as follows: (i) $233,973 on the Admission Date, which shall not occur prior to confirmation by Boston Capital that outstanding due diligence items have been completed by the General Partner to the reasonable satisfaction of Boston Capital (the "First Installment") of which $75,000will be deducted to reflect the repayment of a pre-development loan advanced by the Investment Partnership to the Partnership prior to the effective date of this Agreement. (ii) $89,990 on the latest to occur of (A) Cost Certification, (B) receipt of an updated title insurance policy satisfactory to the Special Limited Partner, (C) Initial 100% Occupancy Date, (D) State Designation, (E) receipt of a payoff letter from the Contractor stating that all amounts payable to the Contractor have been paid in full and that the Partnership is not in violation of the Construction Contract, (F) Substantial Completion, (G) receipt of a valid and recorded Extended Use Commitment and receipt of a subordination agreement subordinating the Mortgage Loan to the Extended Use Commitment, (H) receipt of updated insurance certificates relating to the Apartment Complex satisfactory to the Special Limited Partnership or (I) satisfaction of all of the conditions to the payment of the First Installment (the "Second Installment"); and (iii) $30,995 on the latest to occur of (A) Rental Achievement or (B) satisfaction of all of the conditions to the payment of the First and Second Installment (the "Third Installment"); and (iv) $5,000 on the latest to occur of (A) the receipt by the Investment Partnership of the Partnership's federal income tax return and an audited financial statement for the year in which Rental Achievement occurred or (B) satisfaction of all of the conditions to the payment of the First, Second and Third Installments (the "Fourth Installment"). As a condition precedent to each payment set forth above other than the First Installment, the General Partner shall, not less than twenty (20) days nor more than thirty (30) days prior to the time such Installment is due, give the Investment Partnership Notice in the form of a written certification that: (A) all conditions precedent to such Installment have been satisfied, (B) the representations, warranties and covenants given by the General Partner in Section 4.01 are valid and accurate, where still applicable, with respect to the General Partner, the Partnership and/or the Apartment Complex, as of the date of such certificate, and (C) to the best of its knowledge, after due inquiry, no condition exists which would, pursuant to Section 5.03, entitle the Investment Partnership to withhold the payment of such Installment. Based upon the giving of such Notice, such Installment shall be made on the due date therefor, or if such Notice is not timely given, then within twenty-one (21) days after receipt of such Notice. (d) (i) Upon the occurrence of Cost Certification or State Designation, if ninety-nine and ninety-nine hundredths percent (99.99%) of the aggregate amount of Tax Credits: (A) for which the Partnership would be eligible with respect to the Apartment Complex based upon the Cost Certification, and/or (B) allocated by the Agency with respect to the Apartment Complex, is less than the aggregate amount of the Projected Credit over the ten-year credit period (the "Allocation Differential"), then the Capital Contribution of the Investment Partnership shall be reduced by the "Adjustment Amount". The Adjustment Amount shall be equal to the Allocation Differential multiplied by .75. Any such reduction in Capital Contribution shall first be applied to reduce the Installment next due to be paid by the Investment Partnership, and any portion of such reduction in excess of such Installment shall be applied to reduce succeeding Installments. If no further Installments are due to be paid, then the entire amount of such reduction shall be repaid by the Partnership to the Investment Partnership promptly after demand is made therefor. The General Partner is obligated to provide such funds to the Partnership as shall be necessary to cause the aforesaid payment to be made by the Partnership to the Investment Partnership. In the event that there is a reduction in Capital Contributions equal to the Adjustment Amount, then the amount of the Projected Credit shall be proportionately reduced to reflect the Allocation Differential, and thereafter shall be referred to as the "Revised Projected Credit". (ii) If at any time the Accountants determine that, for any fiscal year or portion thereof during the Partnership's operation, ending on the date five (5) years from and after the date of Substantial Completion (the "Reduction Period"), the Actual Credit for such fiscal year or portion thereof is less than the Projected Credit (or Revised Projected Credit) applicable to such fiscal year or portion thereof, then the Capital Contribution of the Investment Partnership shall be reduced by the Reduction Amount. The "Reduction Amount" shall be equal to the sum of (A) the Credit Shortfall multiplied by .882 and (B) the amount of any recapture, interest or penalty payable by the limited partners of the Investment Partnership (assuming pass through of all such liability in the year incurred and a tax rate equal to the maximum individual rate applicable in such year) as a result of the Credit Shortfall for such year. Any such reduction in Capital Contribution shall first be applied to reduce the Installment next due to be paid by the Investment Partnership, and any portion of such reduction in excess of such Installment shall be applied to reduce succeeding Installments. If no further Installments are due to be paid, then the entire amount of such reduction shall be repaid by the Partnership to the Investment Partnership promptly after demand is made therefor. The General Partner is obligated to provide such funds to the Partnership as shall be necessary to cause the aforesaid payment to be made by the Partnership to the Investment Partnership. (iii) In the event that, for any reason, at any time after the Reduction Period, there is a Credit Shortfall with respect to any fiscal year during the Partnership's operation, the Investment Partnership shall be treated as having made a constructive advance to the Partnership with respect to such year (a "Credit Recovery Loan"), which shall be deemed to have been made on January 1 of such year, in an amount equal to the sum of (A) the Credit Shortfall for such year, plus (B) the amount of any recapture, interest or penalty payable by the limited partners of the Investment Partnership (assuming pass-through of all such liability in the year incurred and a tax rate equal to the maximum individual rate applicable in such year) as a result of the Credit Shortfall for such year. Credit Recovery Loans shall be deemed to bear simple (not compounded) interest, from the respective dates on which such principal advances are deemed to have been made under this Section 5.01(d) (iii) at 9% per annum. Credit Recovery Loans shall be repayable by the Partnership as provided in Section 11.04(A). (iv) Permanent Increase in Credit. In the event that, as a result of an increase in the qualified basis and the Eligible Basis of the Apartment Complex for purposes of Tax Credits (which increase is verified by the Accountants to the reasonable satisfaction of the Investment Partnership), the Partnership receives a duly-authorized, valid and binding allocation, from the Agency, of an additional amount of Tax Credits with respect to the Apartment Complex (the "Additional Credits"), the Investment Partnership agrees that it will either, in its sole and absolute discretion: (A) make additional Capital Contributions to the Partnership in an amount determined on the same terms and conditions as are applicable to the investment being made by the Investment Partnership pursuant to this Agreement in an aggregate amount not in excess of $5,000, applied to the increase in the amount of the Projected Low-Income Tax Credit resulting from the Additional Credits (the "Additional Capital Contributions"); or (B) reduce its allocation of profits, losses and credits from the Partnership, pursuant to Section 11.01, to such percentage as shall permit it to realize its proportionate share of the full amount of the Projected Credit, but no portion of the Additional Credits. Any Additional Capital Contributions payable as aforesaid shall be included ratably over the remaining Installments due to be paid by the Investment Partnership, unless otherwise determined by the Investment Partnership in its sole discretion; provided, however, that if no further Installments remain to be paid, then the entire amount of such Additional Capital Contributions shall be paid by the Investment Partnership to the Partnership within thirty (30) days after the determination of the amount thereof by the Investment Partnership as aforesaid. The General Partner agrees that, in the situation described above in this Section 5.01(d)(iv), it shall pay all costs associated with the preparation of documents necessary or desirable to implement the foregoing provisions of this Section 5.01(d)(iv), including the reasonable fees and expenses of Burns & Levinson LLP, as counsel to the Investment Partnership. (e) Without the Consent of the General Partner and the Investment Partnership, no additional Persons may be admitted as additional Limited Partners and Capital Contributions may be accepted only as and to the extent expressly provided for in this Article V. 5.02. Return of Capital Contribution TC "5.02. Return of Capital Contribution"\l2 . Except as provided in this Agreement, no Partner shall be entitled to demand or receive the return of his Capital Contribution. 5.03. Withholding of Capital Contribution Upon Default TC "5.03. Withholding of Capital Contribution Upon Default"\l2 . In the event that: (a) the General Partner, or any successor General Partner, shall not have substantially complied with any material provisions under this Agreement, after Notice from the Investment Partnership of such noncompliance and failure to cure such noncompliance within a period of thirty (30) days from and after the date of such Notice, or (b) the Partnership is in default under the Project Documents and such default has continued uncured beyond any applicable cure or grace period, or (c) foreclosure proceedings shall have been commenced against the Apartment Complex, or (d) the Partnership shall not have satisfied the post-closing conditions described on Exhibit A attached hereto within the time frames designated therein, then the Partnership and the Investment Partnership, at its sole election, may cause the withholding of payment of any Installment otherwise payable to the Partnership. Notwithstanding the provisions herein, in the event that an Installment payment becomes due during any cure period stated in this Section 5.03, the Investment Partnership, at its sole election, may cause the withholding of any payment of any such Installment otherwise payable to the Partnership until the termination of such cure period, and then, according to the provisions herein. All amounts so withheld by the Investment Partnership under this Section 5.03 shall be promptly released to the Partnership only after the General Partner or the Partnership has cured the default justifying the withholding, as demonstrated by evidence reasonably acceptable to the Investment Partnership. 5.04. Legal Opinions TC "5.04. Legal Opinions"\l2 . As a condition precedent to payment of the First Installment, the Investment Partnership shall have received the opinions of James M. Ramsey, Esq., which opinions shall be in form and substance satisfactory to the Investment Partnership and shall explicitly state that Burns & Levinson LLP, of Boston, Massachusetts, counsel to the Limited Partner, may explicitly rely upon them. 5.05. Repurchase Obligation TC "5.05. Repurchase Obligation"\l2 . (a) If (i) the building(s) comprising the Apartment Complex is/are not placed in service by December 31, 1998; (ii) the Partnership has not received State Designation by (a) December 31, 1998, or (b) by such later date demonstrated by the General Partner satisfactory to the Investment Partnership as customary with Agency practice, in either instance for the year or years that the Apartment Complex is placed in service; (iii) Rental Achievement does not occur within 12 months from and after the occurrence of Substantial Completion; (iv) the Partnership fails to initially meet the Minimum Set-Aside Test or the Rent Restriction Test within 12 months of the date that the Apartment Complex is placed in service; (v) the Partnership fails to meet the Minimum Set-Aside Test or the Rent Restriction Test at anytime during the first 60 months after initial achievement of the Minimum Set Aside and Rent Restriction Tests; (vi) an event of default described in Section 5.03 shall exist and shall not have been cured within the applicable cure or grace period; (vii) the buildings comprising the Apartment Complex are not placed in service prior to December 31 in the year in which State Designation has occurred; (viii) the General Partner fails to make Subordinated Loans as required by this Agreement; then (A) the General Partner shall, within 30 days of the occurrence thereof, send to the Investment Partnership Notice of such event and of its obligation to purchase the Interest of the Investment Partnership hereunder and pay to the Investment Partnership its Invested Amount in the event the Investment Partnership in its sole discretion requires such purchase of its Interest or (B) failing any such required Notice by the General Partner to the Investment Partnership and upon the Investment Partnership gaining knowledge of any of the foregoing repurchase events, the Investment Partnership will promptly notify the General Partner of its obligation to repurchase the Interest of the Investment Partnership. Thereafter, the General Partner, within 30 days of receipt of Notice from the Investment Partnership of such election, shall acquire the entire Interest of the Investment Partnership in the Partnership by making payment to the Investment Partnership, in cash, of an amount equal to its Invested Amount. (b) If the Agency shall disapprove the Investment Partnership as a Partner hereunder within 180 days of its admission to the Partnership, then the Investment Partnership shall, effective as of such time (or such other time as may be specified by the Agency in its disapproval), cease to be a Limited Partner. The General Partner shall, within 10 days of the effective date of such termination, purchase the Interest of the Investment Partnership in the Partnership and pay to the Investment Partnership an amount equal to its Net Capital Contribution. (c) Upon receipt by the Investment Partnership of any such payment of its Net Capital Contribution or the Invested Amount, as applicable, the Interest of the Investment Partnership shall terminate, the Investment Partnership shall execute, acknowledge and deliver such documents of assignment as the General Partner shall require and effectuate termination or transfer of its Interest, and the General Partner shall indemnify and hold harmless the Investment Partnership from any losses, damages, and/or liabilities to which the Investment Partnership (as a result of its participation hereunder) may be subject, except as and to the extent of any losses, damages and/or liabilities arising from the Investment Partnership's own negligence, misconduct or fraud. ARTICLE VI CHANGES IN PARTNERS TC "ARTICLE VI - - CHANGES IN PARTNERS"\l1 6.01. Withdrawal of a General Partner TC "6.01. Withdrawal of a General Partner"\L2 . (a) A General Partner may withdraw from the Partnership or sell, transfer or assign his or its Interest as General Partner only with the prior Consent of the Special Limited Partner, and only after being given written approval by the necessary parties as provided in Section 6.02, and by the General Partner(s) to be substituted for him or it or to receive all or part of his or its Interest as General Partner. (b) In the event that a General Partner withdraws from the Partnership or sells, transfers or assigns his or its entire Interest pursuant to Section 6.01(a), he or it shall be and shall remain liable for all obligations and liabilities incurred by him or it as General Partner, or arising out of any events occurring before such withdrawal, sale, transfer or assignment shall have become effective, but shall be free of any obligation or liability incurred on account of the activities of the Partnership from and after the time such withdrawal, sale, transfer or assignment shall have become effective; provided that if the withdrawal is in breach of this Agreement, the General Partner shall be liable to the Partnership and/or the Limited Partners for all damage, loss, cost or expense incurred by the Partnership or the Limited Partners as a result of such unauthorized withdrawal. 6.02. Admission of a Successor or Additional General Partner TC "6.02. Admission of a Successor or Additional General Partner"\L2 . A Person shall be admitted as a General Partner of the Partnership only if the following terms and conditions are satisfied: (a) the withdrawal of any withdrawing General Partner and the admission of such Person shall have been Consented to by the remaining General Partner or its successors and the Investment Partnership; (b) the successor or additional Person shall have accepted and agreed to be bound by (i) all the terms and provisions of this Agreement, by executing a counterpart hereof, and (ii) all the terms and provisions of the Loan Documents, including by executing a counterpart thereof to the extent required by a Lender, and (iii) all the terms and provisions of such other documents or instruments as may be required or appropriate in order to effect the admission of such Person as a General Partner, and an amendment to this Agreement and/or the Certificate, as applicable, evidencing the admission of such Person as a General Partner shall have been filed and all other actions required by Section 1.05 in connection with such admission shall have been performed; (c) if the successor or additional Person is a corporation or a limited liability company, it shall have provided the Partnership with evidence satisfactory to counsel for the Partnership of its authority to become a General Partner, to do business in the State and to be bound by the terms and provisions of this Agreement; and (d) counsel for the Partnership shall have rendered an opinion that the admission of the successor or additional Person is in conformity with the Act and that none of the actions taken in connection with the admission of the successor Person will cause the termination or dissolution of the Partnership or will cause it to be classified other than as a partnership for federal income tax purposes. 6.03. Effect of Bankruptcy, Death, Withdrawal, Dissolution or Incompetence of a General Partner TC "6.03. Effect of Bankruptcy, Death, Withdrawal, Dissolution or Incompetence of a General Partner"\l2 . (a) In the event of the Bankruptcy of a General Partner or the withdrawal, death or dissolution of a General Partner or an adjudication that a General Partner is incompetent (which term shall include, but not be limited to, insanity) the business of the Partnership shall be continued by the other General Partner, if any, (and the other General Partner, by execution of this Agreement, expressly so agrees to continue the business of the Partnership); provided, however, that if the withdrawn, Bankrupt, deceased, dissolved or incompetent General Partner is then the sole General Partner, unless the Limited Partners within ninety (90) days after receiving Notice of such Bankruptcy, withdrawal, death, dissolution or adjudication of incompetence elect to designate a successor General Partner and continue the Partnership upon the admission of such successor General Partner to the Partnership, the Partnership shall be terminated. (b) Upon the Bankruptcy, death, dissolution or adjudication of incompetence of a General Partner, such General Partner shall immediately cease to be a General Partner and his or its Interest shall without further action be converted to a Limited Partner Interest; provided, however, that if such Bankrupt, dissolved, incompetent or deceased General Partner is the sole remaining General Partner, such General Partner shall cease to be a General Partner only upon the expiration of ninety (90) days after Notice to the Special Limited Partner of the Bankruptcy, death, dissolution or declaration of incompetence of such General Partner; and provided further that if such Bankrupt, dissolved, incompetent or deceased General Partner is the sole remaining General Partner, the converted Partnership Interest of such replaced General Partner shall be ratably reduced to the extent necessary to insure that the substitute General Partner holds a 1% Percentage Interest (as set forth in Section 5.01) and will receive such percentage interest distribution of the General Partner's percentage pursuant to Section 11.04A(f), as is deemed reasonable by the Limited Partners as a result of good faith negotiations with such substitute General Partner; such replaced General Partner whose Interest has been converted to that of a Limited Partner shall remain entitled to his or its proportionate share of the remainder of the distribution pursuant to Section 11.04A(f). Except as set forth above, such conversion of a General Partner Interest to a Limited Partner Interest shall not affect any rights, obligations or liabilities (including without limitation, any of the General Partner's obligations under Section 8.09 herein) of the Bankrupt, deceased, dissolved or incompetent General Partner existing prior to the Bankruptcy, death, dissolution or incompetence of such person as a General Partner (whether or not such rights, obligations or liabilities were known or had matured). (c) If, at the time of the withdrawal, Bankruptcy, death, dissolution or adjudication of incompetence of a General Partner, the Bankrupt, deceased, dissolved or incompetent General Partner was not the sole General Partner of the Partnership, the remaining General Partner or General Partners shall promptly (i) give Notice to the Special Limited Partner of such Bankruptcy, death, dissolution or adjudication of incompetence, and (ii) make such amendments to this Agreement and execute and file such amendments or documents or other instruments as are necessary to reflect the conversion of the Interest of the Bankrupt, deceased, dissolved or incompetent General Partner and his having ceased to be a General Partner. The remaining General Partner or General Partners are hereby granted an irrevocable power of attorney to execute any or all documents on behalf of the Partners and the Partnership and to file such documents as may be required to effectuate the provisions of this Section 6.03. ARTICLE VII ASSIGNMENT TO THE PARTNERSHIP TC "ARTICLE VII - ASSIGNMENT TO THE PARTNERSHIP"\l1 7.01. Assignment of Contracts, etc TC "7.01. Assignment of Contracts, etc."\l2 . The General Partner hereby transfers and assigns to the Partnership all of its right, title and interest in and to the Apartment Complex, including the following: (i) all contracts with architects, engineers, contractors, developers, supervising architects and all other professionals or service providers with respect to the rehabilitation or development of the Apartment Complex; (ii) all plans, specifications, appraisals, reports and working drawings, heretofore prepared or obtained in connection with the Apartment Complex and all governmental approvals obtained, including planning, zoning and building permits; (iii) any and all commitments with respect to the Mortgage Loan; and (iv) any other work product related to the Apartment Complex. ARTICLE VIII RIGHTS, OBLIGATIONS AND POWERS OF THE GENERAL PARTNER TC "ARTICLE VIII - RIGHTS, OBLIGATIONS AND POWERS OF THE GENERAL PARTNER"\l1 8.01. Management of the Partnership TC "8.01. Management of the Partnership"\l2 . (a) Except as otherwise set forth in this Agreement, the General Partner, within the authority granted to it under this Agreement, shall have full, complete and exclusive discretion to manage and control the business of the Partnership for the purposes stated in Article III, shall make all decisions affecting the business of the Partnership and shall manage and control the affairs of the Partnership to the best of its ability and use its best efforts to carry out the purpose of the Partnership. In so doing, the General Partner shall take all actions necessary or appropriate to protect the interests of the Limited Partner and of the Partnership. The General Partner shall devote such of its time as is necessary to the affairs of the Partnership. (b) Except as otherwise set forth in this Agreement and subject to the applicable provisions of the Project Documents, the General Partner (acting for and on behalf of the Partnership), in extension and not in limitation of the rights and powers given by law or by the other provisions of this Agreement, shall, in its sole discretion, have the full and entire right, power and authority in the management of the Partnership business to do any and all acts and things necessary, proper, convenient or advisable to effectuate the purpose of the Partnership. In furtherance and not in limitation of the foregoing provisions, the General Partner is specifically authorized and empowered to execute and deliver, on behalf of the Partnership, the Project Documents and to execute any and all other instruments and documents, and amendments thereto, as shall be required in connection with the Mortgage Loan, including, but not limited to, executing any mortgage, note, contract, building loan agreement, bank resolution and signature card, release, discharge, or any other document or instrument in any way related thereto or necessary or appropriate in connection therewith; provided, however, that copies of all applications for advances of Mortgage Loan proceeds which occur after the Admission Date shall be provided to the Special Limited Partner for its Consent thereto prior to the disbursement of any funds pursuant thereto. All decisions made for and on behalf of the Partnership by the General Partner shall be binding upon the Partnership. No person dealing with the General Partner shall be required to determine its authority to make any undertaking on behalf of the Partnership, nor to determine any facts or circumstances bearing upon the existence of such authority. (c) Subject to the terms of this Partnership Agreement, the General Partners shall be responsible for the management and administration of the Partnership business and shall have all rights and authority generally conferred by law or necessary, advisable or consistent with accomplishing the purpose of the Partnership. Subject to the consent of the Special Limited Partner, the General Partner shall have the power to assign duties and may delegate any of its powers, rights and obligations hereunder and may appoint, employ, contract or otherwise deal with any person for the transaction of business of the Partnership, which person may, but only under the supervision of the General Partner, perform any acts or services for the Partnership as the General Partner may approve. (e) Notwithstanding anything to the contrary contained herein, the Limited Partners reserve the right, at their option to conduct an audit on twenty five (25%) percent of the initial leases or occupancy agreements executed in connection with the Apartment Complex in order to ensure compliance with the applicable Rent Restriction Test, Minimum Set Aside Test, or any other applicable tenant restriction test ("Occupancy Agreement Audit"). The Limited Partners shall select at their option, any combination of occupancy agreements which shall comprise the Occupancy Agreement Audit (the "Selected Occupancy Agreements"). The Occupancy Agreement Audit shall consist of a review of the complete tenant files in connection with the Selected Occupancy Agreements, including but not limited to any tenant financial information. Further, the Occupancy Agreement Audit shall be conducted with the cooperation of, and at the sole cost and expense of the General Partner if the Occupancy Agreement Audit reveals a material noncompliance. A material noncompliance shall be deemed to exist if at least five (5) occupancy agreements reveal noncompliance or violations of any applicable tenant restriction test. If the Occupancy Agreement Audit does not reveal a material noncompliance the Limited Partners shall bear the cost of such audit. Notwithstanding anything to the contrary contained herein or in the Project Documents, the General Partner or any affiliate thereof, commencing subsequent to the Admission Date, shall in all instances submit to the Special Limited Partner for review all relevant financial information and underlying tenant qualification certifications with respect to any proposed tenant prior to execution of any lease or similar occupancy agreement. Neither the General Partner, nor any affiliate thereof, shall be authorized to enter into any lease or occupancy agreement with any proposed tenant without the prior written consent of the Special Limited Partner. 8.02. Limitations Upon the Authority of the General Partners TC "8.02. Limitations Upon the Authority of the General Partners"\l2 . (a) The General Partner shall not have any authority to: (i) perform any act in violation of any applicable law or regulation thereunder; (ii) perform any act in violation of the provisions of the Extended Use Commitment, the Loan Documents, or any other Project Documents; (iii) do any act required to be approved or ratified in writing by all Limited Partners under the Act unless the right to do so is expressly otherwise given in this Agreement; (iv) rent apartments in the Apartment Complex such that the Apartment Complex would not meet the requirements of the Rent Restriction Test or Minimum Set-Aside Test or to rent Low Income Units to any individuals where income exceeds 60% of area median income, as adjusted for family size; or (v) borrow from the Partnership or commingle Partnership funds with funds of any other Person. (b) The General Partner shall not, without the Consent of the Special Limited Partner have any authority to: (i) sell or otherwise dispose of, at any time, all or substantially all of the assets of the Partnership; (ii) borrow in excess of $10,000 in the aggregate at any one time outstanding on the general credit of the Partnership, except borrowings constituting Subordinated Loans or Credit Recovery Loans; (iii) following Substantial Completion, construct any new or replacement capital improvements on the Apartment Complex which substantially alter the Apartment Complex or its use or which are at a cost in excess of $10,000 in a single Partnership fiscal year, except (a) replacements and remodeling in the ordinary course of business or under emergency conditions or (b) construction paid for from insurance proceeds; (iv) acquire any real property in addition to the Apartment Complex; or (v) refinance the Mortgage Loan with the Lender. 8.03. Management Purposes TC "8.03. Management Purposes"\l2 . In conducting the business of the Partnership, the General Partner shall be bound by the Partnership's purpose(s) set forth in Article III. 8.04. Delegation of Authority TC"8.04. Delegation of Authority"\l2 . Subject to Section 8.05 hereof, the General Partner may employ, contract, or otherwise deal with any Person in connection with the performance of its management responsibilities hereunder, provided such Person acts only under the supervision of the General Partner. 8.05. General Partner or Affiliates Dealing with Partnership TC "8.05. General Partner or Affiliates Dealing with Partnership"\l2 . (a) The General Partner or any Affiliate may act as Management Agent on such terms and conditions permitted by the Agency, and may receive compensation at the highest rates approved and permitted by the Agency at any time; provided that notwithstanding the foregoing, the Management Agent may not receive compensation in excess of 5% of gross rental receipts received from tenants of the Apartment Complex without the prior approval of the Special Limited Partner. (b) The General Partner or any Affiliates thereof shall have the right to contract or otherwise deal with the Partnership for the sale of goods or services to the Partnership in addition to those set forth herein, if (A) compensation paid or promised for such goods or services is reasonable (i.e., at fair market value) and is paid only for goods or services actually furnished to the Partnership, (B) the goods or services to be furnished shall be reasonable for and necessary to the Partnership, (C) the fees, terms and conditions of such transaction are at least as favorable to the Partnership as would be obtainable in an arm's-length transaction, (D) no agent, attorney, accountant or other independent consultant or contractor who also is employed on a full-time basis by the General Partner or any Affiliate shall be compensated by the Partnership for his services. Any contract covering such transactions shall be in writing and shall be terminable without penalty on sixty (60) days Notice. Any payment made to the General Partner or any Affiliate for such goods or services shall be fully disclosed to all Limited Partners in the reports required under Section 13.04. Neither the General Partner nor any Affiliate shall, by the making of lump-sum payments to any other Person for disbursement by such other Person, circumvent the provisions of this Section 8.05(b). 8.06. Other Activities TC "8.06. Other Activities"\l2 . The General Partner and any Affiliates thereof may engage in or possess interests in other business ventures of every kind and description for their own account, including, without limitation, serving as general partner of other partnerships which own, either directly or through interests in other partnerships, government-assisted housing projects similar to the Apartment Complex. Neither the Partnership nor any of the Partners shall have any rights by virtue of this Agreement in or to such other business ventures or to the income or profits derived therefrom. 8.07. Liability for Acts and Omissions TC "8.07. Liability for Acts and Omissions"\l2 . No General Partner shall be liable, responsible or accountable in damages or otherwise to any of the Partners for any act or omission performed or omitted by him or it, or any of them, in good faith on behalf of the Partnership and in a manner reasonably believed by him or it or any of them to be within the scope of the authority granted to him or it or any of them by this Agreement and in the best interest of the Partnership, except for negligence, willful misconduct, fraud or any material breach of his or its or their fiduciary duty as General Partner with respect to such acts or omissions. Any loss or damage incurred by any General Partner by reason of any act or omission performed or omitted by him or it or any of them in good faith on behalf of the Partnership and in a manner reasonably believed by him or it or any of them to be within the scope of the authority granted to him or it by this Agreement and in the best interests of the Partnership (but not, in any event, any loss or damage incurred by any General Partner by reason of negligence, willful misconduct, fraud or any material breach of his or its or their fiduciary duty as General Partner with respect to such acts or omissions, or liabilities of the Partners chargeable to the General Partner) shall be paid from Partnership assets to the extent available, but the Limited Partners shall not have any personal liability to the General Partner under any circumstances on account of any such loss or damage incurred by the General Partner or on account of the payment thereof. 8.08. Partnership Status TC "8.08. Partnership Status"\l2 . The Partners intend that the Partnership will be classified as a partnership for federal income tax purposes. The General Partner will undertake any and all actions necessary under the Code and the regulations promulgated thereunder, including any future amendments to such regulations, to ensure that the Partnership will be classified as a partnership for federal income tax purposes. The General Partner will file or cause to be filed any elections that may be required (but only if required) under the Code and the regulations promulgated thereunder, including any future amendments to such regulations, in order to ensure that the Partnership will be classified as a partnership for federal income tax purposes. The General Partner will not change its classification status or election without the consent of the Special Limited Partner. 8.09. Construction/Rehabilitation of the Apartment Complex, Construction Cost Overruns, Operating Deficits TC "8.09. Construction/Rehabilitation of the Apartment Complex, Construction Cost Overruns, Operating Deficits"\l2 . (a) (i) The Partnership has entered into the Construction Contract. The General Partner shall be responsible for: (A) achieving completion of construction or rehabilitation of the Apartment Complex on a timely basis in accordance with the Plans and Specifications, this Agreement and the Project Documents; (B) meeting all requirements for obtaining all necessary permanent, unconditional certificates of occupancy for all the apartment units in the Apartment Complex; (C) fulfilling all actions required of the Partnership to assure that the Apartment Complex satisfies the Minimum Set- Aside Test and the Rent Restriction Test; and (D) causing the making of the Mortgage Loan by the Lender, the achievement of Final Closing, to the extent applicable as of the Admission Date. (ii) The General Partner hereby is obligated to pay all Excess Development Costs; the Partnership shall have no obligation to pay any Excess Development Costs. (iii) In the event that the General Partner shall fail to pay any such Excess Development Costs as required in this Section 8.09(a), an amount not in excess of such Excess Development Costs shall be applied by the Partnership against the Development Fee due to the Developer as an offset against such obligations of the General Partner. Any such direction and application of funds otherwise payable to the Developer as aforesaid shall be deemed to have been paid by the Partnership to the Developer and then applied to reduce the amount of the Excess Development Costs, and the Partnership's obligation to make installment payments to the Developer pursuant to Section 8.10, as well as the Investment Partnership's obligation to make future Installments, shall be deemed satisfied to the extent of the funds applied to reduce the General Partner's obligation to fund Excess Development Costs, and the obligations of the General Partner pursuant to Sections 8.09(a) (i) or 8.09(a) (ii) shall be deemed satisfied to the extent of the funds applied. (b) In the event that, at any time, prior to the day which is on the anniversary date five years following the date of Rental Achievement, an Operating Deficit shall exist, the General Partner shall provide such funds to the Partnership as shall be necessary to pay such Operating Deficit(s) in the form of a loan to the Partnership (the "Operating Deficit Loan(s)"). An Operating Deficit Loan shall be a Subordinated Loan payable in accordance with the provisions of Section 8.17; provided that Operating Deficit Loans shall bear no interest shall, on a cumulative basis, represent a maximum financing obligation of the part of the General Partner not in excess of $250,000. In the event that the General Partner shall fail to make any such Operating Deficit Loan as aforesaid, an amount not in excess of the required Operating Deficit Loan shall be applied by the Partnership against the Development Fee then due and payable to the Developer under Section 11.03 (if funds are then available in accordance with said Section) as an offset against the obligations of the General Partner pursuant to this Section 8.09(b). Any such direction and application of funds otherwise payable to the Developer as aforesaid shall be deemed to have been paid by the Partnership to the Developer and then applied to reduce the amount of the Operating Deficit Loan, and the Partnership's obligation to make installment payments to the Developer pursuant to Section 8.10, as well as the Investment Partnership's obligation to make future Installments, shall be deemed satisfied to the extent of the funds applied to reduce the General Partner's obligation to make such Operating Deficit Loan, and the obligations of the General Partner pursuant to Sections 8.09(a) (i) or 8.09(a) (ii) shall be deemed satisfied to the extent of the funds applied. 8.10. Development Fee TC "8.10. Development Fee"\l2 . The Partnership has entered into a Development Agreement of even date herewith with the Developer for its services in connection with the development and rehabilitation of the Apartment Complex. In consideration for such services, a Development Fee in the total amount of $198,626 shall be payable by the Partnership to the Developer. The Development Fee, all of which shall be deferred, shall be due and payable only in accordance with Section 11.03 and, if not sooner paid, the total amount then outstanding will be payable on October 1, 2008. 8.11. Incentive Partnership Management Fee TC "8.11. Incentive Partnership Management Fee"\l2 . The Partnership has entered into a Partnership Management Services Agreement with the General Partner of even date herewith for its services in managing the business of the Partnership for the period from the date hereof throughout the term of the Partnership, commencing in 1999. Such agreement includes provisions to the effect that in return for its services in administering and directing the business of the Partnership, maintaining appropriate books and records relating to all financial affairs of the Partnership, and reporting periodically to the Partners and the Agency with respect to the financial and administrative affairs of the Partnership and the Apartment Complex, the Partnership shall pay to the General Partner, from the Cash Flow and/or from Proceeds of Capital Transactions of the Partnership available for distribution and in accordance with Section 11.03 and 11.04(A) an annual Incentive Partnership Management Fee. Such fee shall be payable in accordance with the provisions of any applicable regulations of or the Agency and of the Project Documents and shall be in an amount equal to $1,800 per year, commencing in 1999 and payable from Cash Flow. Such fee shall not be cumulative from year to year and shall only be paid to the extent that Cash Flow or Proceeds of Capital Transaction are sufficient to make all or a portion of the then-due payments. 8.11.1 Asset Management Fee TC "8.11.1 Asset Management Fee"\l2 . The Partnership shall pay to Boston Capital, or an Affiliate thereof, an annual Asset Management Fee in the amount of $1,800 per annum, commencing in 1999, for its services in assisting with the preparation of the reports required pursuant to Section 13.04, which fee shall be payable from Cash Flow; provided, however, that if in any fiscal year, Cash Flow is insufficient to pay all or any portion of the Asset Management Fee, the General Partner shall make a Subordinated Loan to the Partnership in an amount not to exceed the lesser of $1,800 per annum or that amount necessary to pay the unpaid portion of such fee. Any unpaid portion of said Asset Management Fee, to the extent the General Partner defaults in its obligation to make a Subordinated Loan, shall accrue, without interest, and shall be payable on a cumulative basis in the first year in which there is sufficient Cash Flow available for the payment of such fee, or, in the first year in which proceeds of a Capital Transaction are available. 8.12. Withholding of Fee Payments TC "8.12. Withholding of Fee Payments"\l2 . In the event that: (a) a General Partner or any successor General Partner shall not have substantially complied with any material provisions under this Agreement, after Notice from the Investment Partnership of such noncompliance and failure to cure such noncompliance within a period of thirty (30) days from and after the date of such Notice, or (b) the Partnership is in default under any of the Project Documents, or (c) foreclosure proceedings shall have been commenced against the Apartment Complex, or (d) the Partnership shall not have satisfied the post-closing conditions described on Exhibit A attached hereto within the time frames designated therein, then (i) then the Investment Partnership, at its sole election, may cause the withholding of payment of any installment of fees payable pursuant to Sections 8.10 and 8.11, and (ii) the General Partner shall be liable for the Partnership's payment of any and all installments of the Development Fee payable pursuant to Section 8.10, to the extent that the Investment Partnership has withheld any Installment(s) pursuant to Section 5.03 as a result of the above-described default. All amounts so withheld by the Partnership under this Section 8.12 shall be promptly released only after the General Partner has cured the default justifying the withholding, as demonstrated by evidence reasonably acceptable to the Investment Partnership. 8.13. Removal of the General Partner TC "8.13. Removal of the General Partner"\l2 . (a) the Special Limited Partner, acting on behalf of the Investment Partnership, so long as the Investment Partnership is a Partner, shall have the right to remove any or all General Partners (i) for any intentional misconduct or gross negligence in the discharge of its duties and obligations as a General Partner, or (ii) upon the occurrence of any of the following: (A) such General Partner shall have violated any of the material provisions of the Extended Use Commitment, the Loan Documents, or any provisions of any other Project Document or other document required in connection with the Mortgage Loan, or any provisions of the Agency regulations applicable to the Apartment Complex; (B) such General Partner shall have violated any material provision of this Agreement or any provision of applicable law, which violations shall include, without limitation (i) withdrawal of the General Partner without the Consent of the Investment Partnership pursuant to the Section 6.01(a), (ii) the failure of the General Partner to make Subordinated Loans required under this Agreement or (iii) the failure of a sole General Partner which is a corporation to satisfy the requirements of Section 8.08; (C) such General Partner shall have caused the Mortgage Loan to go into default; or (D) such General Partner shall have conducted its own affairs or the affairs of the Partnership in such manner as would: (1) cause the termination of the Partnership for federal income tax purposes; or (2) cause the Partnership to be treated for federal income tax purposes as an association, taxable as a corporation. (b) the Special Limited Partner shall give Notice to all Partners of its determination that any such General Partner shall be removed. The General Partner shall have thirty (30) days after receipt of such Notice to cure any default or other reason for such removal, in which event it shall remain as General Partner. If, at the end of such cure period such General Partner has not cured any default or other reason for such removal, (i) without any further action by any Partner, the Special Limited Partner or its designee shall automatically become a General Partner and acquire in consideration of a cash payment such portion of the Interest of the removed General Partner as counsel to the Investment Partnership shall determine is the minimum appropriate interest in order to assure the continued status of the Partnership as a partnership under the Code and under the Act, (ii) the remaining portion of the economic Interest of the removed General Partner shall automatically be converted to an equal economic Interest as an Additional Limited Partner, (iii) the economic Interest of the Special Limited Partner as the Special Limited Partner shall continue unaffected by the new status of the Special Limited Partner or its designee as a General Partner, and (iv) the new General Partner shall automatically be irrevocably delegated all of the powers and duties of the General Partners hereunder. (c) the Special Limited Partner or any successor General Partner proposed by the Special Limited Partner shall have the option, exercisable in its sole discretion, to acquire the Additional Limited Partner Interest, or any portion thereof, of any removed General Partner upon payment of the agreed or then present fair market value of such Interest or portion thereof. Any dispute as to the value of the Interest or portion thereof to be acquired pursuant to the immediately preceding sentence shall be submitted to a committee composed of three qualified real estate appraisers, one chosen by the removed General Partner, one chosen by the successor General Partner, and the third chosen by the two so chosen. The proceedings of such committee shall conform to the rules of the American Arbitration Association, as far as appropriate, and its decision shall be final and binding. The expense of arbitration shall be born equally by the removed General Partner and the Partnership. The method of payment will be deemed presumptively fair where it provides for a promissory note bearing simple interest at eight percent (8%) per annum coming due in no less than five (5) years with equal installments each year. (d) Upon removal, no General Partner or any Affiliate thereof shall be entitled to receive any fee, compensation or other remuneration from the Partnership, other than the above- described payment for the Interest, or portion thereof, of the Removed General Partner. The Partnership is not authorized to enter into any arrangement whereby any fee, compensation or other remuneration could be payable directly or indirectly to any General Partner or Affiliate thereof in a manner inconsistent with the immediately preceding sentence unless the prior written consent of the Special Limited Partner shall have been obtained to such particular arrangement. The Partnership may offset against any payments to a General Partner removed under this Section 8.13 any damages suffered by the Partnership as a result of any breach of the obligations of such General Partner hereunder. A General Partner so removed will not be liable as a general partner for any obligations of the Partnership incurred after the effective date of its removal, but shall be and remain liable for all obligations and liabilities incurred by it as General Partner before such removal became effective, including, but not limited to, its obligations set forth in Section 8.09 hereof. (e) The General Partner hereby grants to each of the Investment Partnership and the Special Limited Partner an irrevocable power of attorney, coupled with an interest, to execute any and all documents on behalf of the Partners and the Partnership as shall be legally necessary and sufficient to effect all of the foregoing provisions of this Section 8.13. The election by the Special Limited Partner to remove such General Partner under this Section shall not limit or restrict the availability and use of any other remedy which the Special Limited Partner or any other Partner might have with respect to the General Partner in connection with its undertakings and responsibilities under this Agreement. 8.14. Selection of Management Agent TC "8.14. Selection of Management Agent"\l2 . The Partnership, with the approval of the Agency, if required, shall engage such person, firm or company as the General Partner may select, and as the Special Limited Partner may approve, which approval shall not be unreasonably withheld (hereinafter referred to as "Management Agent") to manage the operation of the Apartment Complex during the rent-up period and following Substantial Completion for a period of one year, and thereafter such management contract may be extended on an annual basis unless terminated for cause. The Management Agent shall be paid a management fee subject to the approval of the Agency, if required. The contract between the Partnership and the Management Agent and the management plan for the Apartment Complex shall be in a form acceptable to the Investment Partnership or Special Limited Partner and the Agency, if required. Cunningham Properties is hereby approved by the parties hereto as the initial Management Agent. 8.15. Removal of the Management Agent TC"8.15. Removal of the Management Agent"\l2 . The General Partner, (i) may, upon receiving any required approval of the Agency, dismiss the Management Agent as the entity responsible for the management of the Apartment Complex under the terms of the contract between the Partnership and the Management Agent, and (ii) at the request of the Special Limited Partner, shall remove the Management Agent in the event that (A) the Special Limited Partner, in its reasonable discretion, determines that the Management Agent does not possess the necessary experience to properly manage the Apartment Complex or (B) the Management Agent is declared Bankrupt, is dissolved, or makes an assignment for the benefit of its creditors, or for any intentional misconduct by the Management Agent or gross negligence in the discharge of its duties and obligations as Management Agent, including, without limitation, for any action or failure to take any action which: (1) violates in any material respect any provision of the Management Agreement entered into with the Partnership and approved by the Lender, and/or any provision of the Extended Use Commitment and/or the Loan Documents applicable to the Apartment Complex, or (2) violates in any material respect any provision of this Agreement or provision of applicable law. . 8.16 Replacement of the Management Agent TC "8.16 Replacement of the Management Agent"\l2 . Upon the removal of the Management Agent as the entity responsible for the management of the Apartment Complex, a substitute Management Agent, which may be an Affiliate of the General Partner, shall be named by the General Partner, subject to the Consent of the Special Limited Partner. 8.17. Subordinated Loans to the Partnership TC "8.17. Subordinated Loans to the Partnership"\l2 . In the event that additional funds are required by the Partnership for any purpose relating to the business of the Partnership or for any of its obligations, expenses, costs or expenditures, the Partnership may borrow such funds as are needed from any Partners or other Person or organization, including the General Partner, for such period of time and on such terms as the General Partner and the Special Limited Partner may agree and at the rate of interest then prevailing for comparable loans (except for Operating Deficit Loans made pursuant to Section 8.09(b), which shall bear interest only as provided in Section 8.09(b)); provided however, that no such additional loans shall be secured by any mortgage or other encumbrance on the property of the Partnership without the Consent of the Special Limited Partner. Loans made under this Section shall be repaid as set forth in Section 11.04A. The General Partner is obligated to make Subordinated Loans in accordance with Section 8.09 and Section 8.11.1. 8.18. Reserve Fund for Replacements; Operating Deficit Reserve TC "8.18. Reserve Fund for Replacements; Operating Deficit Reserve"\l2 . (a) Reserve Fund for Replacements. The Partnership shall establish a Reserve Fund for Replacements with respect to the Apartment Complex, as required by the Special Limited Partner The Partnership shall make an initial deposit into the Reserve Fund for Replacements equal to $1,600 from the proceeds of the First Installment funded under Section 5.01(c)(i) and shall make subsequent deposits into the Reserve Fund for Replacements equal to $4,800 annually commencing in 1999; such deposits may be suspended only as approved by the Special Limited Partner. Funds in the Reserve Fund for Replacements are intended to be employed for the replacement as needed of fixtures, equipment, structural elements and other components of the Apartment Complex of a capital nature. All interest earnings on funds on deposit in the Reserve Fund for Replacements shall be retained therein for the aforesaid purposes. The Reserve Fund for Replacements shall remain under the control of the Special Limited Partner. Withdrawals from the Reserve Fund for Replacements shall be made only upon the direction of the General Partner and the Special Limited Partner. (b) Operating Deficit Reserve. The Partnership shall establish the Operating Deficit Reserve as a separate, interest bearing account with a financial institution acceptable to the Special Limited Partner and shall deposit therein funds in the amount of $36,000 from the Second Installment funded under Section 5.01(c)(ii). Funds in the Operating Deficit Reserve are intended to be employed solely for the payment of Operating Deficits (including, without limitation, debt service, taxes and insurance), unless otherwise released from escrow by the Special Limited Partner All interest earnings on funds on deposit in the Operating Deficit Reserve shall be retained therein for the aforesaid purposes. Withdrawals from the Operating Deficit Reserve shall be made only upon the direction of the Special Limited Partner and shall not be required to be replenished by the Partnership. The Operating Deficit Reserve shall be maintained for a period of the later of (i) five (5) years commencing on the first day of the month in which Rental Achievement is recognized by the Special Limited Partner to have occurred with respect to the Apartment Complex, or (ii) the last day of the month which represents, in the opinion of the Special Limited Partner, the last of twelve (12) consecutive months in which (a) the Apartment Complex has continuously maintained rental occupancy of at least 93%, and (b) Cash Available for Debt Service Requirements (as defined within the term "Rental Achievement") equals or exceeds 1.15 times the debt service requirements relating to all permanent loans associated with the Apartment Complex, including the Mortgage Loan. ARTICLE IX TRANSFERS OF, AND RESTRICTIONS ON TRANSFERS OF INTERESTS OF LIMITED PARTNERS TC "ARTICLE IX - TRANSFERS OF, AND RESTRICTIONS ON TRANSFERS OF INTERESTS OF LIMITED PARTNERS"\l1 9.01. Purchase for Investment TC "9.01. Purchase for Investment"\l2 . (a) The Investment Partnership hereby represents and warrants to the General Partner and to the Partnership that the acquisition of its Interests is made as principal for its respective account for investment purposes only and not with a view to the resale or distribution of such Interests, except insofar as the Securities Act of 1933 and any applicable securities law of any state or other jurisdiction permit such acquisitions to be made for the account of others or with a view to the resale or distribution of such Interests without requiring that such Interests, or the acquisition, resale or distribution thereof, be registered under the Securities Act of 1933 or any applicable securities law of any state or other jurisdiction. (b) The Investment Partnership agrees that it will not sell, assign or otherwise transfer its Interest or any fraction thereof to any Person who does not similarly represent and warrant and similarly agree not to sell, assign or transfer such Interest or fraction thereof to any Person who does not similarly represent and warrant and agree. (c) The Investment Partnership shall not sell, assign or otherwise transfer its Interest or any fraction thereof to any Person until the Investment Partnership has provided the Partnership with a legal opinion, reasonably satisfactory to the General Partner, that such sale, assignment or other transfer does not violate any state or federal securities laws or require the Interest to be registered under any such laws. 9.02. Restrictions on Transfer of Limited Partner's Interests TC"9.02. Restrictions on Transfer of Limited Partner's Interests"\l2 . (a) Under no circumstances will any offer, sale, transfer, assignment, hypothecation or pledge of any Limited Partner Interest (other than to an Affiliate of any Limited Partner) be permitted unless the General Partner, in its sole discretion, shall have Consented. (b) The Limited Partner whose interest is being transferred shall pay such reasonable expenses as may be incurred by the Partnership in connection with such transfer. 9.03. Admission of Substitute Limited Partners TC "9.03. Admission of Substitute Limited Partners"\l2 . (a) Subject to the other provisions of this Article IX, an assignee of the Interest of a Limited Partner (which shall be understood to include any purchaser, transferee, donee, or other recipient of any disposition of such Interest) shall be admitted as a Substitute Limited Partner of the Partnership only upon the satisfactory completion of the following: (i) Except with respect to an Affiliate of any Limited Partner, consent of the General Partner (which may be withheld in its sole discretion) shall have been given, which Consent of the General Partners may be evidenced by the execution by the General Partners of an amended Agreement and/or Certificate evidencing the admission of such Person as a Limited Partner pursuant to the requirements to the Act; (ii) the assignee shall have accepted and agreed to be bound by the terms and provisions of this Agreement by executing a counterpart thereof or an appropriate amendment hereto, and such other documents or instruments as the General Partner may require in order to effect the admission of such Person as a Limited Partner; (iii) an amended Agreement and/or Certificate evidencing the admission of such Person as a Limited Partner shall have been filed for recording pursuant to the requirements of the Act to the extent required in order to effectuate the admission of such Person as a Limited Partner; (iv) the assignee shall have represented and agreed in writing as required by Section 9.01; (v) if the assignee is a corporation, the assignee shall have provided the General Partner with evidence satisfactory to counsel for the Partnership of its authority to become a Limited Partner under the terms and provisions of this Agreement; and (vi) the assignee or the assignor shall have reimbursed the Partnership for all reasonable expenses, including all reasonable legal fees and recording charges, incurred by the Partnership in connection with such assignment. (b) For the purpose of allocation of Taxable Income, Tax Losses, Tax Credits, and for the purpose of distributing cash of the Partnership, a Substitute Limited Partner shall be treated as having become, and as appearing in, the records of the Partnership as a Partner upon its signing of an amendment to this Agreement, agreeing to be bound hereby. (c) The General Partner shall cooperate with the Person seeking to become a Substitute Limited Partner by preparing the documentation required by this Section and making all official filings and publications. The Partnership shall take all such action, including the filing of any amended Agreement and/or Certificate evidencing the admission of any Person as a Limited Partner, and the making of any other official filings and publications, as promptly as practicable after the satisfaction by the assignee of the Interest of a Limited Partner of the conditions contained in this Article IX to the admission of such Person as a Limited Partner of the Partnership. Any cost or expense incurred in connection with such admission shall be borne by the Partnership to the extent of available Partnership assets, and otherwise by such assignee. 9.04. Rights of Assignee of Partnership Interest TC "9.04. Rights of Assignee of Partnership Interest"\l2 . (a) Except as provided in this Article and as required by operation of law, the Partnership shall not be obligated for any purpose whatsoever to recognize the assignment by any Limited Partner of his (its) Interest until the Partnership has received actual Notice thereof. (b) Any Person who is the assignee of all or any portion of a Limited Partner's Interest, but does not become a Substitute Limited Partner and desires to make a further assignment of such Interest, shall be subject to all the provisions of this Article IX to the same extent and in the same manner as any Limited Partner desiring to make an assignment of his its Interest. ARTICLE X RIGHTS AND OBLIGATIONS OF LIMITED PARTNERS TC "ARTICLE X - RIGHTS AND OBLIGATIONS OF LIMITED PARTNERS"\l1 10.01. Management of the Partnership TC "10.01. Management of the Partnership"\l2 . No Limited Partner shall take part in the management or control of the business of the Partnership nor transact any business in the name of the Partnership. Except as otherwise expressly provided in this Agreement, no Limited Partner shall have the power or authority to bind the Partnership or to sign any agreement or document in the name of the Partnership. No Limited Partner shall have any power or authority with respect to the Partnership except insofar as the consent of any Limited Partner shall be expressly required and except as otherwise expressly provided in this Agreement. 10.02. Limitation on Liability of Limited Partners TC "10.02. Limitation on Liability of Limited Partners"\l2 . The liability of each Limited Partner shall be limited to its Capital Contribution as and when payable under the provisions of this Agreement. No Limited Partner shall have any other liability to contribute money to, or in respect of the liabilities or obligations of, the Partnership, nor shall any Limited Partner be personally liable for any obligations of the Partnership. No Limited Partner shall be obligated to make loans to the Partnership. 10.03. Other Activities TC "10.03. Other Activities"\l2 . Any Limited Partner may engage in or possess interests in other business ventures of every kind and description for its own account, including without limitation, serving as general or limited partner of other partnerships which own, either directly or through interests in other partnerships, government-assisted housing projects similar to the Apartment Complex. Neither the Partnership nor any of the Partners shall have any right by virtue of this Agreement in or to such other business ventures to the income or profits derived therefrom. 10.04. Ownership by Limited Partner of Corporate General Partners or Affiliate TC "10.04. Ownership by Limited Partner of Corporate General Partners or Affiliate"\l2 . No Limited Partner shall, at any time, either directly or indirectly, own any stock or other interest in any corporate General Partner if such ownership by itself or in conjunction with other stock or other interests owned by other Limited Partners would, in the opinion of Burns & Levinson, LLP or other tax counsel to the Investment Partnership, jeopardize the classification of the Partnership as a partnership for federal income tax purposes. In the event of any violation of the provisions of this Section by any one or more Limited Partners, such Limited Partner or Limited Partners shall either dispose of their Interests in the Partnership (subject to and in compliance with the provisions of Article IX) or of their stock or other interest in the corporate General Partner or Affiliates to the extent necessary so that, in the opinion of counsel for the Partnership, the classification of the Partnership as a partnership for federal income tax purposes is no longer in jeopardy. The obligation of any such disposition required of more than one Limited Partner shall be shared among them on an equitable basis. Notwithstanding the foregoing, neither the General Partner nor any Limited Partner shall be liable in damages to the Partnership or to any Partner by reason of any violation of this Section, except for damages arising (a) out of any material misrepresentation by any Limited Partner relating to the ownership of stock or other interest in a corporate General Partner or any affiliate by him or by any member of his family (within the meaning of the attribution rules set forth in Section 318 of the Code), or (b) out of any failure by any Limited Partner to dispose of his Interest in the Partnership or of his stock or other interest in a corporate General Partner or Affiliate within a reasonable time after Notice to such Limited Partner by the Partnership of the obligations to make such disposition. ARTICLE XI ALLOCATION OF TAXABLE INCOME, TAX LOSSES, TAX CREDITS AND CASH DISTRIBUTIONS TC "ARTICLE XI - ALLOCATION OF TAXABLE INCOME, TAX LOSSES, TAX CREDITS AND CASH DISTRIBUTIONS"\L1 Section 11.01. Allocation of Taxable Income, Tax Losses and Tax Credits TC "Section 11.01. Allocation of Taxable Income, Tax Losses and Tax Credits"\L2 . A. General. Subject to the special allocations set forth in this Article XI, Taxable Income, Tax Credits and Tax Losses for each fiscal year of the Partnership (or part thereof) other than those to be allocated pursuant to Section 11.01B or Section 11.02 hereof, shall be allocated 99.99% to the Investment Partnership and .01% to the General Partner. B. Nonrecourse Deductions. Nonrecourse Deductions for any fiscal year or other period shall be specially allocated 99.99% to the Investment Partnership and .01% to the General Partner. C. Partner Loan Nonrecourse Deductions. Any Partner Loan Nonrecourse Deductions for any Fiscal Year or other period shall be specially allocated to the Partner who bears the economic risk of loss with respect to the loan to which such Partner Loan Nonrecourse Deductions are attributable in accordance with Treasury Regulations Section 1.704-2(i). Section 11.02. Allocation of Taxable Income and Tax Losses from Capital Transactions TC "Section 11.02. Allocation of Taxable Income and Tax Losses from Capital Transactions"\L2 . Subject to the special allocations set forth in this Article XI, Taxable Income and Tax Losses from Capital Transactions shall be allocated to the Partners as follows: (i) Taxable Income from Capital Transactions shall be allocated: (a) first, to the Partners with negative Capital Accounts pro rata in such amounts as will result in the elimination of the negative Capital Accounts of such Partners; provided, however, that if Taxable Income to be allocated pursuant to this Section 11.02(i)(a) is insufficient to eliminate all negative Capital Accounts, such Taxable Income will be allocated to Partners with negative Capital Accounts in the proportion that each such Partner's negative Capital Account bears to the total of all such Negative Capital Accounts; (b) second, in the amount and to the extent necessary to increase the Partners' respective Capital Accounts to equal the amounts distributable under Sections 11.04(d), then 11.04(e); (c) then, the balance, if any, of such Taxable Income shall be allocated 75% to the General Partner and 25% to the Investment Partnership. (ii) Tax Losses from Capital Transactions shall be allocated: (a) first, to the extent of the respective positive balances in the Partners' Capital Accounts; and (b) any balance, 25% to the Investment Partnership and 75% to the General Partner. (iii) Notwithstanding the foregoing provisions, if Taxable Income to be allocated includes income treated as ordinary income for federal income tax purposes because such Taxable Income is attributable to the recapture of depreciation under Section 1245 or 1250 of the Code, such Taxable Income, to the extent treated as ordinary income, shall be allocated to and reported by the Partners in proportion to their accumulated depreciation allocations. The Partnership shall keep records of such allocations of depreciation to the Partners. In determining the accumulated depreciation allocations of the Partners, depreciation deductions for each taxable year shall be deemed allocated to the Partners in the same proportion as the Taxable Income or Tax Losses in that particular taxable year were allocated to the Partners. 11.03. Distribution of Cash Flow TC "11.03. Distribution of Cash Flow"\L2 . Cash Flow shall be determined for each fiscal year and shall be applied or distributed at such time or times as the General Partner deems appropriate, but in no event less than once in each fiscal year, in the following order of priority: (a) First, to payment of the Asset Management Fee currently due; (b) Second, to pay an accrued but unpaid Asset Management Fees; (c) Third, to payment to the Developer of the Deferred Development Fee; (d) [Reserved]; (e) Fifth, to repayment of any amounts due with respect to any Subordinated Loans (including, without limitation, Operating Deficit Loans made under Section 8.09); (f) Sixth, to payment of any Partnership Incentive Management Fee currently due; (g) Seventh, to the repayment, in whole or in part, of the General Partner's Special Capital Construction Contribution; and (h) Any balance, 85% to the General Partner and 15% to the Investment Partnership. Section 11.04. Distributions of Distributable Proceeds from Capital Transactions and Distributable Proceeds from Refinancings TC "Section 11.04. Distributions of Distributable Proceeds from Capital Transactions and Distributable Proceeds from Refinancings"\l2 . A. Distributable Proceeds from Capital Transactions and Distributable Proceeds from Refinancings (other than liquidating distributions pursuant to Section 12.02) shall be distributed in the following order of priority: (a) First, to the payment of any debts and liabilities (including unpaid fees but excluding any debts, liabilities and/or fees owed to any Partners) and to the establishment of any required reserves; (b) Second, to the payment of the Asset Management Fees currently due, if any, together with any accrued and unpaid Asset Management Fees; (c) Third, the repayment to the Investment Partnership of any Reduction Amount pursuant to Section 5.01(d)(ii) together with any accrued or unpaid interest or Credit Recovery Loan Pursuant to Section 5.01(d)(iii) together with any accrued or unpaid interest; (d) Fourth, the repayment of any Subordinated Loans to the General Partner; (e) Fifth, any other debts and liabilities owed to the Partners; provided, however, that all such other debts and liabilities owed to the Investment Partnership shall be paid prior to any such debts and liabilities owed to the General Partner; (f) Sixth, to the Investment Partnership in an amount equal to its Investment Amount; (g) Seventh, to the General Partner in an amount equal to its Investment Amount; and (h) The balance, if any, 75% to the General Partner and 25% to the Investment Partnership. B. Distributable Proceeds from Capital Transactions and Distributable Proceeds from Refinancings shall be distributed within 90 days after the end of the fiscal quarter in which such Capital Transaction or Refinancing occurs. Distributions of Distributable Proceeds from Capital Transactions and Distributable Proceeds from Refinancings to the Partners shall be made only after Capital Accounts have been adjusted to reflect all previous allocations of Taxable Income and Tax losses to the Partners, for distributions of Cash Flow, and for any other distributions of Distributable Proceeds form Capital Transactions or Distributable Proceeds from Refinancings. Section 11.05. Allocations Among Partners TC "Section 11.05. Allocations Among Partners"\l2 . A. For purposes of determining the Taxable Income (or Tax Losses) or any other items allocable to any period, Taxable Income (or Tax Losses) and any such other items shall be determined on a daily, monthly, or other basis, as determined by the General Partner using any permissible method under Code Section 706 and the Treasury Regulations thereunder. B. Taxable Income, Tax Losses, and Tax Credits for all purposes of this Agreement shall be determined in accordance with the accrual accounting method. Except as otherwise provided in this Agreement, all items of Partnership income, gain, loss, deduction, and any other allocations, including allocation of Book Profits and Losses, shall be divided among the Partners in the same proportions as they share Taxable Income, Tax Credits, and Taxable Losses, as the case may be, for such fiscal year. C. In any year in which a Partner sells, assigns or transfers all or any portion of an Interest to any Person who during such year is admitted as a substitute Partner, the share of all Taxable Income, Tax Losses, and Tax Credits, allocated to and of all Cash Flow and all cash proceeds distributable under Section 11.04 distributed to, all Partners which is attributable to the Interest sold, assigned or transferred shall be divided between the assignor and the assignee using any one of the following methods as determined by agreement between the assignor and assignee: (i) ratably on the basis of the number of days in such year before, and the number of days on and after, the execution by the assignee of this Agreement, or (ii) by dividing the Partnership fiscal year into two segments, the first segment being the time period in such year before the execution by the assignee of this Agreement and the second segment being the time period in such year beginning on the date of execution of this Agreement, and allocating Taxable Income, Tax Losses, Tax Credits, Cash Flow, and all cash proceeds distributable in each such segment among the persons who were Partners during that segment, or (iii) using such other method as provided by the Code or regulations thereunder. D. In the event that there is a determination that there is any original issue discount or imputed interest attributable to the Capital Contribution of any Partner, or any loan between a Partner and the Partnership, any income or deduction of the Partnership attributable to such imputed interest or original issue discount on such Capital Contribution or loan (whether stated or unstated) shall be allocated solely to such Partner. E. If a taxing authority ignores the characterization of any amounts (other than the receipt of a profits interest in the Partnership by a Partner) paid to a Partner (or an Affiliate thereof) as salaries, management fees, commissions or other compensation for services, including interest ("Compensation"), and refuses to treat such payments as either guaranteed payments within the meaning of Code Section 707(c) or payments made to such Partner other than in such Partner's capacity as a Partner within the meaning of Code Section 707(a), and such taxing authority ultimately treats such amounts paid to a partner (or an Affiliate thereto) as a distribution to such Partner for federal income tax purposes which reduces such Partner's Capital Account, then the Compensation shall be offset to the extent possible by a special allocation of item of income or gain of the Partnership to the recipient Partner so that, consistent with the intent of the Partners, the Compensation shall not be treated as a distribution which reduces the recipient Partner's Capital Account without an offsetting allocation of income or gain. Accordingly, such Partner shall be allocated the first available items of Partnership income and gain (including in a succeeding year) in an amount equal to the Compensation. F. If any Partner's Interest in the Partnership is reduced but not eliminated because of the admission of new Partners or otherwise, or if any Partner is treated as receiving any items of property described in Section 751(a) of the Code, the Partner's Interest in such items of Section 751(a) property that was property of the Partnership while such Person was a Partner shall not be reduced, but shall be retained by the Partner so long as the Partner has an Interest in the Partnership and so long as the Partnership has an Interest in such property. G. The Partners are aware of the income tax consequences of the allocations made by this Article XI and hereby agree to be bound by the provisions of this Article XI in reporting their shares of Partnership income and loss for income tax purposes. Section 11.06. Qualified Income Offset TC "Section 11.06. Qualified Income Offset"\l2 . (i) Notwithstanding any other provision of this Article XI, in the event any Partner unexpectedly receives (a) an adjustment to the Capital Account balance of such Partner as described in Section 1.704-1(b)(2)(ii)(d)(4) of the Treasury Regulations, (b) an allocation to such Partner of loss or deduction of the type described in Section 1.704- 1(b)(2)(ii)(d)(5) of the Treasury Regulations, or (c) a distribution to such Partner in excess of any offsetting increase in the Partner's Capital Account balance during or prior to the year of distribution, items of Partnership Taxable Income and of income that constitute a credit to such Partner's Capital Account shall be specially allocated to such Partner in an amount and manner sufficient to eliminate, to the extent required by the Treasury Regulations under Code Section 704(b), the Qualified Income Offset Amount (defined in Section 11.06(ii)) created by such adjustments, allocations, or distributions as quickly as possible, provided that an allocation pursuant to this Section 11.06(i) shall be made only if and to the extent that such Partner would have a Qualified Income Offset Amount after all other allocations provided for in this Article have been tentatively made as if this Section 11.06(i) were not in this Agreement. (ii) Notwithstanding anything to the contrary contained in this Agreement, in no event shall Tax Losses of the Partnership be allocated to a Partner if such allocation would result in such Partner having a "Qualified Income Offset Amount" (as defined below). As used herein, the term "Qualified Income Offset Amount" for a Partner means the deficit balance, if any, in such Partner's Capital Account as of the end of the relevant fiscal year after giving effect to the following adjustments: (i) credit to such Capital Account an amount equal to (a) the Partner's Share of Minimum Gain immediately prior to the allocation or distribution and (b) the sum of such Partner's allocable share of any recourse indebtedness of the Partnership as determined under Section 752 of the Code and any unconditional obligation of such Partner to contribute additional amounts to the capital of the Partnership in the future (to the extent not previously taken into account in determining such Partner's share of recourse liabilities of the Partnership) and (ii) debit to such Capital Account the allocations or distributions described in Section 11.06(i) that, as of the end of the taxable year, are reasonably expected to be made to such Partner. All Tax Losses in excess of the limitation set forth in this Section 11.06(ii) shall be allocated to the General Partner. Section 11.07. Minimum Gain Allocations TC "Section 11.07. Minimum Gain Allocations"\l2 . A. Notwithstanding any other provisions of this Article XI, if in any year there is a net decrease in the amount of the Partnership's Minimum Gain, each Partner will be allocated items of Taxable Income and gain for such year equal to that Partner's share of the net decrease in Minimum Gain, within the meaning of Treasury Regulation 1.704-2(g)(2), and subject to the exceptions set forth in Treasury Regulation 1.704-2(f). Allocations of Taxable Income and gain (hereinafter referred to as a "Minimum Gain Chargeback") required pursuant to this Section 11.07 shall consist first of gains recognized from the disposition of items of Partnership property subject to one or more nonrecourse liabilities of the Partnership to the extent of the decrease in Minimum Gain attributable to the disposition of such items of property (or if such gains exceed the amount of the Minimum Gain Chargeback required for such taxable year, the Minimum Gain Chargeback shall consist of a proportionate share of each such gain), and the remainder of such Minimum Gain Chargeback shall consist of a pro-rata portion of the other items of Taxable Income and gain of the Partnership for that year. If the amount of the Minimum Gain Chargeback requirement exceeds the Partnership's Taxable Income and gains for the taxable year, the excess shall carry over to subsequent years. B. If in any year there is a net decrease (within the meaning of Treasury Regulations Section 1.704-2(i)(3) in Partner Nonrecourse Debt Minimum Gain, any Partner with a share of that Member Nonrecourse Debt Minimum Gain (determined under Treasury Regulation 1.704-2(i)(5)) as of the beginning of the year shall be allocated items of profits and gains for that year (and if necessary, subsequent years) equal to that Partner's share of the net decrease in Member Nonrecourse Debt Minimum Gain in accordance with Treasury Regulation Section 1.704-2(i)(4). Section 11.08. Regulatory Allocations TC "Section 11.08. Regulatory Allocations"\l2 . The allocations set forth in Sections 11.01B, 11.01C, 11.06 and 11.07 (the "Regulatory Allocations") are intended to comply with certain requirements of Treasury Regulation Section 1.704-1(b). It is the intent of the Partners that, to the extent possible, all Regulatory Allocations shall be offset either with other Regulatory Allocations or with special allocations of other items of Taxable Income, Tax Losses and items of income, gain, loss, or deduction pursuant to this Section 11.08. Therefore, notwithstanding any other provision of this Article (other than the Regulatory Allocations), the General Partners shall make such offsetting special allocations of Taxable Income, Tax Losses, and items of income, gain, loss, or deduction in whatever manner it determines appropriate so that, after such offsetting allocations are made, each Capital Account balance is, to the extent possible, equal to the Capital Account balance such Partner would have had if the Regulatory Allocations were not part of the Agreement and all items were allocated pursuant to Sections 11.01A and 11.02. In exercising its discretion under this Section 11.08, the General Partners shall take into account future Regulatory Allocations under Section 11.07 that, although not yet made, are likely to offset other Regulatory Allocations previously made under Sections 11.01B and 11.01C. Section 11.09. Partners' Partnership Non-recourse Liabilities TC "Section 11.09. Partners' Partnership Non- recourse Liabilities"\l2 . For purposes of Code Section 752, each Partner's share of Partnership non-recourse liabilities shall be determined in accordance with Treasury Regulation 1.752- 3(a) or successor regulation. In this connection, for purposes of determining each Partner's proportionate share of the excess non-recourse liabilities of the Partnership pursuant to Treasury Regulation 1.752-3(a), the Investment Partnership shall have a 99.99% interest in Partnership Taxable Income or profits and the General Partner shall have a .01% interest in Partnership Taxable Income or profits. Section 11.10. Tax Allocations: Code Section 704(c) TC "Section 11.10. Tax Allocations: Code Section 704(c)"\l2 . In accordance with Code Section 704(c) and the Treasury Regulations thereunder, income, gain, loss, and deduction with respect to any property contributed to the capital of the Partnership shall be allocated among the Partners so as to take account of any variation between the adjusted basis of such property to the Partnership for federal income tax purposes and its initial Gross Asset Value (computed in accordance with Section 11.12 hereof). In the event the Gross Asset Value of any Partnership prop- erties is adjusted pursuant to Section 11.12 hereof, subsequent allocations of income, gain, loss, and deduction with respect to such asset shall take into account any variation between the adjusted basis of such asset for federal income tax purposes and its Gross Asset Value in the same manner as under Code Section 704(c) and the Treasury Regulations thereunder. Any elections or other decisions relating to such allocations shall be made by the Managing General Partner with the Consent of the Limited Partner, in any manner that reasonably reflects the purpose and intention of this Agreement. Allocations pursuant to this Section are solely for purposes of federal, state, and local taxes and shall not affect, or in any way be taken into account in computing, any Partner's Capital Account or share of Book Profits and Losses, other items, or distributions pursuant to any provision of this Agreement. 11.11. Tax Matters Partner TC "11.11. Tax Matters Partner"\l2 . A. Subject to Section 11.11 C, the General Partner is hereby designated as Tax Matters Partner of the Partnership, and shall engage in such undertakings as are required of the Tax Matters Partner of the Partnership, as provided in regulations pursuant to Section 6231 of the Code. Each Partner, by its execution of this Agreement, Consents to such designation of the Tax Matters Partner and agrees to execute, certify, acknowledge, deliver, swear to, file and record at the appropriate public offices such documents as may be necessary or appropriate to evidence such Consent. B. The Tax Matters Partner is hereby authorized, but not required: (a) to enter into any settlement with the Internal Revenue Service or the Secretary with respect to any tax audit or judicial review, in which agreement the Tax Matters Partner may expressly state that such agreement shall bind the other Partners, except that such settlement agreement shall not bind any Partner who (within the time prescribed pursuant to the Code and regulations thereunder) files a statement with the Secretary providing that the Tax Matters Partner shall not have the authority to enter into a settlement agreement on behalf of such Partner; (b) in the event that a notice of a final administrative adjustment at the Partnership level of any item required to be taken into account by a Partner for tax purposes (a "final adjustment") is mailed to the Tax Matters Partner, to seek judicial review of such final adjustment, including the filing of a petition for readjustment with the Tax Court, the District Court of the United States for the district in which the Partnership's principal place of business is located, or the United States Claims Court; (c) to intervene in any action brought by any other Partner for judicial review of a final adjustment; (d) to file a request for an administrative adjustment with the Internal Revenue Service at any time and, if any part of such request is not allowed by the Internal Revenue Service, to file a petition for judicial review with respect to such request; (e) to enter into an agreement with the Internal Revenue Service to extend the period for assessing any tax which is attributable to any item required to be taken into account by a Partner for tax purposes, or an item affected by such item; and (f) to take any other action on behalf of the Partners or the Partnership in connection with any administrative or judicial tax proceeding to the extent permitted by applicable law or regulations. C. The Tax Matters Partner agrees to promptly notify the Special Limited Partner upon receipt of any correspondence from federal, state, or local authorities relating to any examination of the Partnership's affairs and to permit the Special Limited Partner to participate in the development of the Tax Matters Partner's position and to Consent to the Tax Matter Partner's proposed response to any matter arising in connection with such examination. The Tax Matters Partner shall not enter into any settlement or arrangement on behalf of the Partnership with respect to any federal, state or local tax authorities without the Consent of the Special Limited Partner. D. The Partnership shall indemnify and reimburse the Tax Matters Partner for all expenses, including legal and accounting fees, claims, liabilities, losses and damages incurred in connection with any administrative or judicial proceeding with respect to the tax liability of the Partners. The payment of all such expenses (including any reimbursement of the Tax Matters Partner for expenses that it may incur under the following sentence) shall be made before any distributions are made or any discretionary reserves are set aside by the General Partner. In the event that funds are not available from the Partnership for such expenses, the General Partner shall have the obligation to provide funds for such purpose. The taking of any action and the incurring of any expense by the Tax Matters Partner in connection with any such proceeding, except to the extent required by law, is a matter in the sole discretion of the Tax Matters Partner and the provisions on limitations of liability of the General Partner and indemnification set forth in Section 8.07 of this Agreement shall be fully applicable to the Tax Matters Partner in its capacity as such. 11.12. Capital Accounts TC "11.12. Capital Accounts"\l2 . A. A Capital Account shall be maintained on the books of the Partnership for each Partner, which shall be (i) credited with its Capital Contributions and the amount of any Partnership liabilities that are assumed by such Partner or that are secured by any Partnership property distributed to such Partner; (ii) credited with its distributive share of Taxable Income and any income of the Partnership that is exempt from federal income tax and not otherwise taken into account in computing Taxable Income; (iii) charged with its distributive share of Tax Losses and any nondeductible expenditures of the Partnership (including Syndication Expenses) described in Code Section 705(a)(2)(B) or treated as Code Section 705(a)(2)(B) expenditures pursuant to Treasury Regulation Section 1.704-1(b)(2)(iv)(i) and not otherwise taken into account under this Section 11.12; and (iv) charged with any distributions to it and with the amount of any liabilities of such Partner that are assumed by the Partnership or that are secured by any property contributed by such Partner to the Partnership. In the case of property other than cash contributed to the Partnership or distributed to a Partner, each Partner's Capital Account will be credited with the Gross Asset Value of property contributed to the Partnership (net of liabilities assumed by the Partnership and liabilities to which such contributed property is subject) and shall be debited with the cash and the Gross Asset Value of property distributed to it (net of liabilities assumed by such Partner and liabilities to which such distributed property is subject). In the event the Gross Asset Values of Partnership assets are adjusted pursuant to Section 11.12B hereof, the Capital Accounts of all Partners shall be adjusted simultaneously to reflect the aggregate net adjustment as if the Partnership recognized gain or loss equal to the amount of such aggregate net adjustment. Upon the sale, exchange or other transfer of an Interest, or the assignment of such Interest to a new Partner, the Capital Account of the transferor Partner shall carry over to the transferee Partner. B. For purposes of determining and maintaining the Partners' Capital Accounts, the Gross Asset Value of Partnership assets shall be adjusted as follows: (i) The initial Gross Asset Value of any asset contributed by a Partner to the Partnership shall be the gross fair market value of such asset, as determined by the contributing Partner and the Partnership; (ii) The Gross Asset Values of all Partnership assets shall be adjusted to equal their respective gross fair market values, as determined by the General Partners, as of the following times: (a) the acquisition of an additional Interest in the Partnership by any new or existing Partner in exchange for more than a de minimis Capital Contribution; (b) upon liquidation of the Partnership, or upon the distribution by the Partnership to a Partner of more than a de minimis amount of money or other Partnership property to a retiring or continuing Partner as consideration for an Interest in the Partnership; or (c) under generally accepted industry accounting practices, provided substantially all of the Partnership's property (excluding money) consists of stock, securities, commodities, options, warrants, futures, or similar instruments that are readily tradeable on an established securities market; and (iii) If the Gross Asset Value of an asset has been determined or adjusted pursuant to subsection (i) or (ii) of this Section 11.12B, such Gross Asset Value shall thereafter be adjusted by the Book Depreciation taken into account with respect to such asset for purposes of computing Book Profits and Losses, as set forth in Section 11.12B. C. For purposes of determining and maintaining the Partners' Capital Accounts and the computation of Book Profits and Losses only, the following adjustments shall be made to the calculation of Taxable Income and Tax Losses reflected in the Partners' Capital Accounts: (i) Gain or loss resulting from any disposition of Partnership property with respect to which gain or loss is recognized for federal income tax purposes shall be computed by reference to the Gross Asset Value of the property disposed of, notwithstanding that the adjusted tax basis of such property differs from its Gross Asset Value; (ii) In lieu of the depreciation, amortization, and other cost recovery deductions taken into account in computing such Taxable Income or Tax Losses, there shall be taken into account Book Depreciation for such fiscal year or other period, computed as hereinafter set forth; (iii) For this purpose, "Book Depreciation" means, for each fiscal year or other period, an amount equal to the depreciation, amortization, or other cost recovery deduction allowable with respect to an asset for such year or other period, except that if the Gross Asset Value of an asset differs from its adjusted basis for federal income tax purposes at the beginning of such year or other period, Book Depreciation shall be an amount which bears the same ratio to such beginning Gross Asset Value as the federal income tax depreciation, amortization, or other cost recovery deductions for such year or other period bears to such beginning adjusted tax basis; and (iv) Allocations of Book Profits and Losses among the Partners shall be made in accordance with the provisions of this Article XI respecting allocations of Taxable Income and Tax Losses among the Partners. 11.13. Authority of General Partner to Vary Allocations to Preserve and Protect Partner's Intent TC "11.13. Authority of General Partner to Vary Allocations to Preserve and Protect Partner's Intent"\l2 . (a) It is the intent of the Partners that each Partner's distributive share of income, gain, loss, deduction, or credit (or item thereof) shall be determined and allocated in accordance with this Article XI to the fullest extent permitted by Section 704(b) of the Code. In order to preserve and protect the determinations and allocations provided for in this Article XI, the General Partner, acting on the advice of the Accountants and the Special Limited Partner's accountants (identified in Section 13.03) and with the Consent of the Special Limited Partner hereby is authorized and directed to allocate income, gain, loss, deduction, or credit (or item thereof) arising in any year differently than otherwise provided for in this Article XI to the extent that allocating income, gain, loss, deduction or credit (or item thereof) in the manner provided for in Article XI would cause the determinations and allocations of each Partner's distributive share of income, gain, loss, deduction, or credit (or item thereof) not to be permitted by Section 704 (b) of the Code and Treasury Regulations promulgated thereunder. Any allocation made pursuant to this Section 11.13 shall be deemed to be a complete substitute for any allocation otherwise provided for in this Article XI and no amendment of this Agreement shall be required. (b) In making any allocation (the "new allocation") under Section 11.13(a), the General Partner is authorized to act only after having been advised by the Accountants that, under Section 704(b) of the Code and the Treasury Regulations thereunder, (i) the new allocation is necessary, and (ii) the new allocation is the minimum modification of the allocations otherwise provided for in this Article XI necessary in order to assure that, either in the then current year or in any preceding year, each Partner's distributive share of income, gain, loss, deduction, or credit (or item thereof) is determined and allocated in accordance with this Article XI to the fullest extent permitted by Section 704(b) of the Code and the Treasury Regulations thereunder. (c) If the General Partner is required by Section 11.13(a) to make any new allocation in a manner less favorable to any Partner than is otherwise provided for in this Article XI, then the General Partner is authorized and directed, only after having been advised by the Accountants that it is permitted by Section 704(b) of the Code, to allocate income, gain, loss, deduction, or credit (or item thereof) arising in later years in such manner so as to bring the allocations of income, gain, loss, deduction, or credit (or item thereof) to such Partner as nearly as possible to the allocations thereof otherwise contemplated by this Article XI. (d) New allocations made by the General Partner under Section 11.13(a) and Section 11.13(c) in reliance upon the advice of the Accountants shall be deemed to be made pursuant to the fiduciary obligation of the General Partner to the Partnership and the Limited Partners, and no such allocation shall give rise to any claim or cause of action by any Limited Partner. ARTICLE XII SALE, DISSOLUTION AND LIQUIDATION TC "ARTICLE XII - SALE, DISSOLUTION AND LIQUIDATION'\l1 12.01. Dissolution of the Partnership TC "12.01. Dissolution of the Partnership"\l2 . The Partnership shall be dissolved upon the earlier of the expiration of the term of the Partnership, or upon: (a) subject to Section 6.03, the withdrawal, Bankruptcy, death, dissolution or adjudication of incompetency of a General Partner who is at that time the sole General Partner; (b) the sale or other disposition of all or substantially all of the assets of the Partnership; (c) the election by the General Partner, with the Consent of the Special Limited Partner; (d) the election of the Special Limited Partner, without the Consent of the General Partner; or (e) any other event causing the dissolution of the Partnership under the laws of the State. 12.02. Winding Up and Distribution TC "12.02. Winding Up and Distribution"\l2 . (a) In the event of dissolution and termination of the Partnership, a full accounting of the assets and liabilities shall be taken, and the assets shall be distributed in accordance with this Section 12.02 as follows, after taking into account all other allocations and distributions under this Agreement for the Fiscal Year, including, without limitation, the allocations under Article XI hereof: (A) To the payment of all debts and liabilities of the Partnership then due (including fees and loans payable to Partners); (B) To the setting up of any reserves that the Liquidator may deem reasonably necessary for any contingent or unforeseen liabilities or obligations of the Partnership; and (C) To the Partners, in an amount equal to the positive balances in their Capital Accounts. If any General Partner has a negative Capital Account balance following the liquidation of the Partnership or of the General Partner's Interest in the Partnership within the meaning of Treasury Regulation Section 1.704-1(b)(ii)(g), excluding from such General Partner's negative Capital Account balance, (a) such General Partner's Share of Minimum Gain, and (b) any other amount that such General Partner is deemed to be obligated to restore to the Partnerships under Treasury Regulation Section 1.704- 1(b)(2)(ii)(c) or otherwise under the Treasury Regulations promulgated under Code Section 704(b), and after taking into account all Capital Account adjustments (including adjustments arising from the liquidation) for the Partnership taxable year during which such liquidation occurs, other than those made pursuant to this Section, such General Partner shall be unconditionally obligated to restore the amount of such negative Capital Account balance to the Partnership by the end of such taxable year (or, if later, within 90 days after the date of liquidation). Amounts contributed to the Partnership in respect of such General Partner's obligation to restore negative Capital Account balances shall be paid to creditors of the Partnership or distributed to the other Partners in accordance with their positive Capital Account balances, if any, as of the date of liquidation. (b) The Liquidator shall file all certificates and notices of the dissolution of the Partnership required by law. The Liquidator shall proceed without any unnecessary delay to sell and otherwise liquidate the Partnership's property and assets; provided, however, that if the Liquidator shall determine that an immediate sale of part or all of the Partnership property would cause undue loss to the Partners, then in order to avoid such loss, the Liquidator may, except to the extent provided by the Act, defer the liquidation as may be necessary to satisfy the debts and liabilities of the Partnership to Persons other than the Partners. Upon the complete liquidation and distribution of the Partnership assets, the Partners shall cease to be Partners of the Partnership, and the Liquidator shall execute, acknowledge and cause to be filed all certificates and notices required by the law to terminate the Partnership. (c) Upon the dissolution of the Partnership pursuant to Section 12.01, the Accountants shall promptly prepare, and the Liquidator shall furnish to each Partner, a statement setting forth the assets and liabilities of the Partnership upon its dissolution. Promptly following the complete liquidation and distribution of the Partnership property and assets, the Accountants shall prepare, and the Liquidator shall furnish to each Partner, a statement showing the manner in which the Partnership assets were liquidated and distributed. ARTICLE XIII BOOKS AND RECORDS, ACCOUNTING TAX ELECTIONS, ETC. TC "ARTICLE XIII - BOOKS AND RECORDS, ACCOUNTING TAX ELECTIONS, ETC."\l1 13.01. Books and Records TC "13.01. Books and Records"\l2 . The books and records of the Partnership shall be maintained on an accrual basis in accordance with sound federal income tax accounting principles. These and all other records of the Partnership, including information relating to the status of the Apartment Complex, information with respect to the sale by the General Partner or any Affiliate of goods or services to the Partnership, and any information required to be maintained by the Act or any governmental agencies having jurisdiction, shall be kept at the principal office of the Partnership and shall be available for examination there by any Partner, or his duly authorized representative, at any and all reasonable times. Any Partner, or his duly authorized representative, upon paying the costs of collection, duplication and mailing, shall be entitled to a copy of the list of names and addresses of the Limited Partners and of any of the books and records of the Partnership. The General Partner shall maintain and store all original tenant files in fire-proof file cabinets in a secure location. Microfiche or other similar storage technologies may also be used provided that the General Partner obtains the Consent of the Investment Partnership with respect to such alternate storage technology. 13.02. Bank Accounts TC "13.02. Bank Accounts"\l2 . All funds of the Partnership not otherwise invested shall be deposited in one or more accounts maintained in such banking institutions as the General Partner shall determine, and withdrawals shall be made only in the regular course of Partnership business on such signature or signatures as the General Partner may, from time to time, determine. No funds of the Partnership shall be deposited in any financial institution in which any Partner is an officer, director or holder of any proprietary interest. 13.03. Accountants TC "13.03. Accountants"\l2 . The Accountants shall annually prepare for execution by the General Partner all tax returns of the Partnership, shall annually audit the books of the Partnership, and shall certify, in accordance with generally accepted accounting principles, a balance sheet, a profit and loss statement, and a cash flow statement. With respect to each fiscal year during the Partnership's operations, at such time as the Accountants shall have prepared the proposed tax return for such year, the Accountants shall provide copies of such proposed tax return to the Investment Partnership and to its accountants, Reznick, Fedder & Silverman, of Bethesda, Maryland, for their review and comment. Any comments and/or changes in such proposed tax return reasonably recommended by the Investment Partnership's accountants shall be taken into account and made by the Accountants prior to the completion of such tax return for execution by the General Partner. The Partnership shall reimburse Boston Capital Communications Limited Partnership, an affiliate of the Investment Partnership, for its expenses incurred in causing the Partnership's proposed tax return to be reviewed by the Investment Partnership's accountants, if and to the extent that such review results in material modifications to such proposed tax return. A full detailed statement shall be furnished to all Partners, showing such assets, properties, and net worth and the profits and losses of the Partnership for the preceding fiscal year. All Partners shall have the right and power to examine and copy, at any and all reasonable times, the books, records and accounts of the Partnership. 13.04. Reports to Partners TC "13.04. Reports to Partners"\l2 . (a) Within thirty (30) days of the date of Substantial Completion, the General Partner shall cause to be prepared and distributed to the Investment Partnership, a Credit Basis Worksheet for each building, and in the form specified by Boston Capital. (b) By December 1 of each year, the General Partner shall caused to be prepared and distributed to the Investment Partnership the projected annual operating budget for the Apartment Complex for the next year. (c) The General Partner shall cause to be prepared and distributed to all persons who were Partners at any time during a fiscal year of the Partnership: (i) By March 1 of the year after the end of each fiscal year of the Partnership, (A) an audited financial statement which includes a balance sheet as of the end of such fiscal year and statements of income, Partners' equity, and changes in financial position and a Cash Flow statement, for the year then ended, all of which, except the Cash Flow statement, shall be prepared in accordance with generally accepted accounting principles and accompanied by an auditor's report containing an opinion of the Accountants, and (B) a report of the activities of the Partnership during the period covered by the report. Such report shall set forth distributions to Limited Partners for the period covered thereby and shall separately identify distributions from: (1) Cash Flow from operations during the period, (2) Cash Flow from operations during a prior period which had been held as reserves, (3) proceeds from disposition of the Apartment Complex or any other investments of the Partnership, (4) lease payments on net leases with builders and sellers, and (5) reserves. With respect to any distribution to the Investment Partnership, the report called for shall separately identify distributions from (A) Cash Flow from operations during the period, (B) Cash Flow from operations during a prior period which had been held as reserves, (C) proceeds from disposition of property and investments, (D) lease payments on net leases with builders and sellers, (E) reserves from the gross proceeds of the offering originally obtained from the Investment Partnership, (F) borrowed monies, (G) loans or contributions from the Investment Partnership, and (H) transactions outside of the ordinary course of business with a description thereof. If the Completion Date had not yet occurred as of December 31 in the year which is the subject of the report, then this Section 13.04(a)(i) shall require only the balance sheet for the year then ended. (ii) By February 1 of the year after the end of each fiscal year of the Partnership, all information necessary for the preparation of the Limited Partners' federal income tax returns, together with a draft of the Partnership's federal income tax return for such fiscal year. (iii) Within thirty (30) days after the end of each calendar quarter of a fiscal year of the Partnership, a report containing: (A) A balance sheet, which may be unaudited; and (B) a statement of income for the quarter then ended, which may be unaudited; and (C) A Low Income Housing Credit Monitoring form, Rent Rolls, Statement of Income and Expenses, Operating Statement and Occupancy Rental Report, all in the form specified by Boston Capital; and (D) A certification that the Apartment Complex and its tenants are in compliance with all applicable federal and state laws and regulation; and (E) other pertinent information regarding the Partnership and its activities during the quarter covered by the report. (d) Within ninety (90) days after the end of each fiscal year of the Partnership the General Partner shall provide to the Investment Partnership: (i) A certification by the General Partner that (A) all Mortgage Loan payments and taxes and insurance payments with respect to the Apartment Complex are current as of the date of the year-end report, (B) to the best of the General Partner's knowledge and belief there is no default under the Project Documents or this Agreement, or if there is any default, a description thereof, and (C) to the best of the General Partner's knowledge and belief there is no building, health or fire code violation or similar violation of a governmental law, ordinance or regulation against the Apartment Complex or, if there is any violation, a description thereof; (ii) the information specified in Section 13.04(b); (iii) to the extent not previously disclosed in a report required hereunder a descriptive statement of all transactions during the fiscal year between the Partnership and the General Partner and/or any Affiliates, including the nature of the transaction and the payments involved (including accrued cash or other payments); (iv) a Cash Flow statement; and (v) if required, a copy of the annual report to be filed with the United States Treasury concerning the status of the Apartment Complex as low income housing and, if required, a certificate to the Agency concerning the same. (e) Upon the written request of the Investment Partnership for further information with respect to any matter covered in items (a) or (b) above, the General Partner shall utilize its best efforts to furnish such information within thirty (30) days of receipt of such request. (f) Prior to November 1 of each year commencing in 1998, the General Partner, on behalf of and at the expense of the Partnership, shall send to the Investment Partnership an estimate of the Investment Partnership's share of the Tax Credits, identified by building, and of Taxable Income and Tax Losses of the Partnership for federal income tax purposes for the current fiscal year, all in the form specified by Boston Capital. Such estimate shall be prepared by the General Partner and the Accountants. (g) Within fifteen (15) days after the end of any calendar month during which (i) there is a material default by the Partnership under the Project Documents or in payment of any mortgage, taxes, interest or other obligation on secured or unsecured debt, (ii) any reserve has been reduced or terminated by application of funds therein for purposes materially different from those for which such reserve was established, (iii) the General Partner has received any notice of a material fact which may substantially affect further distributions, or (iv) any Partner has pledged or collateralized his Interest in the Partnership, the General Partner shall send the Investment Partnership a detailed report of such event. (h) On or before the Admission Date, the General Partner, on behalf of the Partnership, shall send to the Investment Partnership a copy of all requests for disbursements or other extensions of credit under the Mortgage Loan which have been submitted to the Lender prior to the Admission Date. After the Admission Date, the General Partner, on behalf of the Partnership, shall send to the Investment Partnership, on or before the tenth day of each month, a copy of (i) all reports required by the Agency, filed the previous month and covering the status of project operations and (ii) each request for a disbursement or other extensions of credit under the Mortgage Loan submitted to the Lender during the previous month. In addition, within thirty (30) days after the occurrence of Substantial Completion, the General Partner, on behalf of the Partnership, shall prepare and send to the Investment Partnership a Credit Basis Worksheet for each building within the Apartment Complex, in the format provided by Boston Capital. The General Partner shall provide to the Investment Partnership such other reports from time to time as may be reasonably required by the Investment Partnership with the reasonable consent of the General Partner or by federal or state agencies having jurisdiction. (i) (i) In the event that the reports or information provided for in Sections 13.04 (b)(i) and/or 13.04(b)(ii) above are, at any time, not provided within the time period(s) specified in such Sections, the General Partner shall be obligated to pay to the Investment Partnership the sum of $25 per day, as liquidated damages, for each day from the date upon which such reports or information is(are) due pursuant to the provisions of the aforesaid Sections until the date upon which such reports or information is (are) provided. This penalty, however, may be waived by the Investment Partnership in the event such failure is due to circumstances not within the General Partner's control. (ii) In the event that the reporting requirements set forth in any of the above provisions of this Section 13.04 are not met, the Investment Partnership, in its reasonable discretion, may direct the General Partner to dismiss the Accountants, and to designate successor Accountants, subject to the approval of the Investment Partnership; provided however, that if the General Partner and the Investment Partnership cannot agree on the designation of successor Accountants, the successor Accountants shall be designated by the Investment Partnership in its sole discretion. These costs shall not exceed the average of three bids from qualified Accountants obtained by the General Partner. The Special Limited Partner may change the reporting requirements at any time if required to do so by the Investment Partnership's limited partners to make changes reasonably required by the Special Limited Partner to permit it to adequately monitor its investment. The Investment Partnership shall give the General Partner at least sixty (60 ) days' Notice of any material change in the reporting requirements set forth herein. 13.05. Section 754 Elections TC "13.05. Section 754 Elections"\l2 . In the event of a transfer of all or any part of the Interest of a General Partner or of a Limited Partner, the Partnership may elect, pursuant to Sections 743 and 754 of the Code (or any corresponding provision of succeeding law), to adjust the basis of the Partnership property if, in the opinion of the Special Limited Partner, based upon the advice of the Accountants, such election would be most advantageous to the Investment Partnership. Each Partner agrees to furnish the Partnership with all information necessary to give effect to such election. 13.06. Fiscal Year and Accounting Method TC "13.06. Fiscal Year and Accounting Method"\l2 . The fiscal year of the Partnership shall be the calendar year. All Partnership accounts shall be determined on the accrual basis. ARTICLE XIV AMENDMENTS TC "ARTICLE XIV - AMENDMENTS"\l1 14.01 Amendments. This Agreement may be amended, after giving 20 days' Notice to the Partners hereunder (a) by the General Partner with the Consent of the Investment Partnership or (b) by the Investment Partnership without the Consent of the General Partner (except in the case of any proposed amendment which the General Partner reasonably determines to be adverse to its interest as Partner, and if such Consent is required by the foregoing, which Consent shall not be unreasonably withheld or delayed). In determining whether or not to give its Consent to an amendment prepared by the Investment Partnership, the General Partner agrees to take into account the investment objectives of the Investment Partnership. ARTICLE XV CONSENTS, VOTING AND MEETINGS TC "ARTICLE XV - CONSENTS, VOTING AND MEETINGS"\L1 15.01. Method of Giving Consent TC "15.01. Method of Giving Consent"\L1 . Any Consent required by this Agreement may be given by a written Consent given by the consenting Partner and received by the General Partner at or prior to the doing of the act or thing for which the Consent is solicited. 15.02. Submissions to Limited Partners TC "15.02. Submissions to Limited Partners"\L2 . The General Partner shall give the Limited Partners Notice of any proposal or other matter required by any provision of this Agreement or by law to be submitted for consideration and approval of the Limited Partners. Such Notice shall include any information required by the relevant provision or by law. 15.03. Meetings; Submission of Matter for Voting TC "15.03. Meetings; Submission of Matter for Voting"\L2 . Subject to the provisions of Section 10.01, a majority in Interest of the Limited Partners shall have the authority to convene meetings of the Partnership and to submit matters to a vote of the Partners. ARTICLE XVI GENERAL PROVISIONS TC "ARTICLE XVI - GENERAL PROVISIONS"\l1 16.01. Burden and Benefit TC "16.01. Burden and Benefit"\l2 . The covenants and agreements contained herein shall be binding upon and inure to the benefit of the heirs, executors, administrators, successors and assigns of the respective parties hereto. 16.02. Applicable Law TC "16.02. Applicable Law"\l2 . This Agreement shall be construed and enforced in accordance with the laws of the State. 16.03. Counterparts TC "16.03. Counterparts"\l2 . This Agreement may be executed in several counterparts, each of which shall be deemed to be an original copy and all of which together shall constitute one agreement binding on all parties hereto, notwithstanding that all the parties shall not have signed the same counterpart. 16.04. Separability of Provisions TC "16.04. Separability of Provisions"\l2 . Each provision of this Agreement shall be considered separable and if for any reason any provision which is not essential to the effectuation of the basic purposes of this Agreement is determined to be invalid and contrary to any existing or future law, such invalidity shall not impair the operation of or affect those provisions of this Agreement which are valid. 16.05. Entire Agreement TC "16.05. Entire Agreement"\l2 . This Agreement and the ancillary agreements executed in connection herewith set forth all (and is intended by all parties to be an integration of all) of the representations, promises, agreements and understandings among the parties hereto with respect to the Partnership, the Partnership business and the property of the Partnership, and there are no representations, promises, agreements or understandings, oral or written, express or implied, among them other than as set forth or incorporated herein. 16.06. Liability of the Investment Partnership TC "16.06. Liability of the Investment Partnership"\l2 . Notwithstanding anything to the contrary contained herein, neither the Investment Partnership nor any of its partners, general or limited, shall have any personal liability to any of the parties to this Agreement with regard to the representations and covenants extended, or the obligations undertaken, by the Investment Partnership under this Agreement. In the event that the Investment Partnership shall be in default under any of the terms of this Agreement, the sole recourse of any party hereto for any indebtedness due hereunder, or for any damages resulting from any such default by the Investment Partnership, shall be against the capital contributions of the investor limited partners of the Investment Partnership allocated to, and remaining for investment in, the Partnership; provided however, that under no circumstances shall the liability of the Investment Partnership for any such default be in excess of the aggregate of: (a) the amount of Capital Contribution payable by the Investment Partnership to the Partnership, under the terms of this Agreement, at the time of such default, and (b) an amount equal to reasonable attorneys' fees reasonably and necessarily incurred by the General Partners in obtaining payment of any Installment(s) not made by the Investment Partnership when due and payable pursuant to the provisions of this Agreement. 16.07. Environmental Protection TC "16.07. Environmental Protection"\l2 . (a) The General Partner represents and warrants that (i) it has no actual knowledge of any deposit, storage, disposal, burial, discharge, spillage, uncontrolled loss, seepage or filtration of any Hazardous Substances at, upon, under or within the Land or any contiguous real estate, and (ii) it has not caused or permitted to occur, and shall not permit to exist, any condition which may cause a discharge of any Hazardous Substances at, upon, under or within the Land or on any contiguous real estate. (b) The General Partner further represents and warrants that neither it nor any of its Affiliates (i) has been, or will be involved in operations at or, pursuant to its best efforts, near the Land, which operations could lead to (A) the imposition of liability under the Hazardous Waste Laws on the Partnership or on any other subsequent or former owner of the Land or (B) the creation of a lien on the Land under the Hazardous Waste Laws or under any similar laws or regulations; and (ii) has permitted, or will permit, any tenant or occupant of the Apartment Complex to engage in any activity that could impose liability under the Hazardous Waste Laws on such tenant or occupant, on the Land or on any other owner of the Apartment Complex. (c) The General Partner shall comply strictly and in all respects with the requirements of the Hazardous Waste Laws and related regulations and with all similar laws and regulations. (d) The General Partner, shall at all times indemnify and hold harmless the Investment Partnership against and from any and all claims, suits, actions, debts, damages, costs, charges, losses, obligations, judgments, and expenses, of any nature whatsoever, suffered or incurred by the Investment Partnership, under or on account of the Hazardous Waste Laws or any similar laws or regulations, including the assertion of any lien thereunder, except for claims, suits, actions, debts, damages, costs, charges, losses, obligations, judgments, or expenses arising from the Investment Partnership's own gross negligence, willful misconduct or fraud. (e) For purposes of this Section 16.07, "Hazardous Substances" means oil, petroleum or chemical liquids or solids, liquid or gaseous products or any hazardous wastes or hazardous substances, as those terms are used in the Hazardous Waste Laws; and "Hazardous Waste Laws" means the Comprehensive Environmental Response, Compensation, and Liability Act of 1980, and any other federal, state or local law governing Hazardous Substances, as such laws may be amended from time to time. 16.08. Notices to the Investment Partnership TC "16.08. Notices to the Investment Partnership"\l2 . Any Notice required by the provisions of this Agreement to be given to the Investment Partnership shall be addressed as follows: Boston Capital Tax Credit Fund, IV, LP c/o Boston Capital Partners, Inc. One Boston Place, 21st Floor Boston, Massachusetts 02210 ATTN: Richard D. Mazzocchi, Jr. And a copy to: Burns & Levinson LLP 125 Summer Street Boston, MA 02110 ATTN: Richard J. Tetrault, Esq. 16.09. Notices to the General Partner TC "16.09. Notices to the General Partner"\l2 . Any Notice required by the provisions of this Agreement to be given to the General Partner shall be addressed as follows: Cunningham-Warren Properties, LLC 11260 W. 155th Terrace Overland Park, Kansas 66221 16.10. Withdrawal of Initial Limited Partner TC "16.10. Withdrawal of Initial Limited Partner"\l2 . The Initial Limited Partner hereby withdraws as the Initial Limited Partner of the Partnership and shall have no further right, title and interest in the Partnership. The Initial Limited Partner acknowledges that it has received the return of any Capital Contribution or other amount to which it is entitled from the Partnership and represents and warrants to the Partnership, which representation and warranty shall survive its withdrawal, that, as of the date hereof, its interest as limited partner is free and clear of any liens and encumbrances 16.11. Postponement and Waiver TC "16.11. Postponement and Waiver"\l2 . No failure or delay on the part of any party in exercising any right, power or privilege under this Agreement shall operate as a waiver thereof nor shall any single or partial exercise of any right, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, power or privilege. The rights and remedies expressly specified in this Agreement are cumulative and are not exclusive of any rights or remedies which any party would otherwise have. [SIGNATURES APPEAR ON NEXT PAGE] IN WITNESS WHEREOF, the parties have affixed their signatures and seals to this Amended and Restated Agreement of Limited Partnership of Lombard Properties, L.P. as of the date first written above. GENERAL PARTNER: Cunningham-Warren Properties, L.L.C. ____________________________ By:/s/Hollis O. Cunningham Witness Hollis O. Cunningham, Manager INVESTMENT PARTNERSHIP: BOSTON CAPITAL TAX CREDIT FUND IV, L.P. By: Boston Capital Associates IV, L.P., its General Partner By: C & M Associates d/b/a Boston Capital Associates, its General Partner ____________________________ By: /s/ Bonnie Kate Fox Witness Bonnie Kate Fox, Attorney-in-fact for John P. Manning, General Partner SPECIAL LIMITED PARTNER: BCTC 94, Inc. ____________________________ By: /s/Bonnie Kate Fox Witness Bonnie Kate Fox, Attorney-in- fact for John P. Manning, President INITIAL LIMITED PARTNER: Cunningham-Warren Properties, L.L.C. ____________________________ By:/s/ Carolyn Cunningham Witness Carolyn Cunningham EXHIBIT A Post-Closing Conditions [Refer to that certain Post-Closing Letter dated as of the date hereof, which is incorporated herein by reference] EX-10 3 BOSTON CAPITAL TAX CREDIT FUND IV, L.P. CERTIFICATE AND AGREEMENT FOR LEVEL CREEK PARTNERS, L.P. LOMBARD PARTNERS, L.P. _______________________________________ CERTIFICATION AND AGREEMENT for LOMBARD PARTNERS, L.P. _______________________________________ This CERTIFICATION AND AGREEMENT is made as of October 23, 1998 by Lombard Partners, L.P., a Missouri limited partnership (the "Operating Partnership"); Cunningham-Warren Properties, L.L.C., a Kansas limited liability company, as General Partner of the Operating Partnership; for the benefit of Boston Capital Tax Credit Fund IV, L.P., a Massachusetts limited partnership (the "Investment Partnership"); BCTC 94, Inc., a Massachusetts corporation (the "Special Limited Partner"); Burns & Levinson LLP and certain other persons, counsel or entities described herein. The Investment Partnership and the Special Limited Partner shall hereinafter be referred to collectively as the "Limited Partners". The General Partners, if more than one, shall hereinafter be referred to collectively, jointly and severally, as the General Partner. WHEREAS, the Operating Partnership proposes to admit the Limited Partners as the limited partners thereof pursuant to the Lombard Partners, L.P. Amended and Restated Agreement of Limited Partnership of the Operating Partnership dated as of October 20, 1998 (the "Operating Partnership Agreement"), in accordance with which the Special Limited Partner will make a capital contribution to the Operating Partnership and the Investment Partnership will make certain capital contributions to the Operating Partnership; WHEREAS, the Limited Partners have relied upon certain information and representations described herein in evaluating the merits of investment by the Limited Partners in the Operating Partnership; WHEREAS, Burns & Levinson LLP, as counsel for the Limited Partners, will rely upon such information and representations in connection with its delivery of certain opinions with respect to this transaction; and WHEREAS, James M. Ramsey, Esq., as counsel for the Operating Partnership and the General Partner, will rely upon such information and representations in connection with its delivery of certain opinions with respect to this transaction. NOW, THEREFORE, to induce the Limited Partners to enter into the Operating Partnership Agreement and become the limited partners of the Operating Partnership, and for $1.00 and other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, the Operating Partnership and the General Partner hereby agree as follows for the benefit of the Limited Partners, Burns & Levinson LLP, James Ramsey, Esq. and certain other persons hereinafter described. Terms defined in the Operating Partnership Agreement but not otherwise defined herein shall have the meanings given them in the Operating Partnership Agreement. 1. Representations, Warranties and Covenants of the Operating Partnership, and the General Partner The Operating Partnership and the General Partner jointly and severally represent, warrant and certify to the Limited Partners, Burns & Levinson LLP and James Ramsey, Esq., that, with respect to the Operating Partnership, as of the date hereof: 1.01 The Operating Partnership is duly organized and in good standing as a limited partnership pursuant to the laws of the state of its formation with full power and authority to own the 24-unit rental housing project located in Springfield, Missouri known as Lombard Heights Apartments (the "Apartment Complex") and conduct its business; each of the Operating Partnership and General Partner have the power and authority to enter into and perform this Certification and Agreement; the execution and delivery of this Certification and Agreement by the Operating Partnership and the General Partner have been duly and validly authorized by all necessary action; the execution and delivery of this Certification and Agreement, the fulfillment of its terms and consummation of the transactions contemplated hereunder do not and will not conflict with or result in a violation, breach or termination of or constitute a default under (or would not result in such a conflict, violation, breach, termination or default with the giving of notice or passage of time or both) any other agreement, indenture or instrument by which the Operating Partnership or the General Partner is bound or any law, regulation, judgment, decree or order applicable to the Operating Partnership, or the General Partner or any of their respective properties; and this Certification and Agreement constitutes the valid and binding agreement of the Operating Partnership and the General Partner enforceable against each of them in accordance with its terms. 1.02 All factual information, including without limitation the information set forth in Exhibit A hereto, provided to the Limited Partners or their affiliates either in writing or orally, did not, at the time given, and does not, on the date hereof, contain any untrue statement of a material fact or omit to state a material fact required to be stated therein or necessary to make the statements therein not misleading in light of the circumstances under which they are made. The General Partner has also delivered to the Limited Partners or their affiliates all documents and other information which has been requested by such parties. Since the date of the financial statements for the General Partner previously delivered, there has been no material adverse change in the financial position of the General Partner. The estimates of occupancy rates, rental rates, operating expenses and tax credits set forth on Exhibit A are reasonable in light of the knowledge and experience of the General Partner. 1.03 As of the date hereof, each of the representations contained in Exhibit B attached hereto is true, accurate and complete as to the Operating Partnership, and the General Partner and as to any of their affiliates, any of their predecessors and their affiliates' predecessors, any of their directors, officers, general partners and/or beneficial owners of ten percent (10%) or more of any class of their equity securities (beneficial ownership meaning the power to vote or direct the vote and/or the power to dispose or direct the disposition of such securities), as the case may be, and any promoters presently connected with them in any capacity. 1.04 Each of the representations and warranties con- tained in the Operating Partnership Agreement is true and correct as of the date hereof. 1.05 Each of the covenants and agreements of the Operating Partnership and the General Partner contained in the Operating Partnership Agreement has been duly performed to the extent that performance of any covenant or agreement is required on or prior to the date hereof. 1.06 All conditions to admission of the Limited Part- ners as limited partners of the Operating Partnership contained in the Operating Partnership Agreement have been satisfied. 1.07 No default by the Operating Partnership or the General Partner has occurred and is continuing under the Operating Partnership Agreement or any of the Project Documents (as such term is defined in the Operating Partnership Agreement). 1.08 The General Partner agrees to take all actions necessary to claim the Projected Credit, including, without limitation, the filing of Form 8609 with the Internal Revenue Service in a timely manner. 1.09 No person or entity other than the Operating Partnership holds any legal or equity interest in the Apartment Complex. 1.10 The Operating Partnership has the sole responsi- bility to pay all maintenance and operating costs, including all taxes levied and all insurance costs, attributable to the Apartment Complex. 1.11 The Operating Partnership, except to the extent it is protected by insurance and excluding any risk borne by lenders, bears the sole risk of loss if the Apartment Complex is destroyed or condemned or there is a diminution in the value of the Apartment Complex. 1.12 No person or entity except the Operating Part- nership has the right to any proceeds, after payment of all indebtedness, from the sale, refinancing, or leasing of the Apartment Complex. 1.13 The General Partner is not related in any manner to either of the Limited Partners, nor is the General Partner acting as an agent of the Limited Partners. 1.14 To the best of the undersigned's knowledge after due inquiry the Apartment Complex does not contain in a level above that deemed safe by all applicable governmental agencies, any substance known to be hazardous, such as hazardous waste, lead-based paint, asbestos, methane gas, urea formaldehyde insulation, oil, toxic substances, underground storage tanks, polychlorinated biphenals (PCBs), and radon; the Apartment Complex is not affected by the presence of oil, toxic substances, or other pollutants that could be a detriment to the Apartment Complex nor is the Operating Partnership in violation of any local, state, or federal law or regulation; and no violation of the Clean Air Act, Clean Water Act, Resource Conservation and Recovery Act, Toxic Substance Control Act, Safe Drinking Water Control Act, Comprehensive Environmental Resource Compensation and Liability Act, or Occupational Safety and Health Act has occurred or is continuing. Neither the Operating Partnership nor the General Partner has received any notice from any source whatsoever of the existence of any such hazardous condition relating to the Apartment Complex or of any violation of any local, state or federal law or regulation with respect to the Apartment Complex. 1.15 Based on the undersigned's knowledge of property values in the area where the Apartment Complex is located, and based upon the level of permanent debt financing for the Apartment Complex, there is a reasonable expectation that the fair market value of the Apartment Complex, taking into account value attributable to the Low Income Housing Tax Credits and/or below market financing, as well as the use restrictions imposed on the Apartment Complex, will be greater than the total amount of the Operating Partnership's liabilities at the date of closing. 1.16 None of the partners of the Operating Partnership or of the General Partner is a tax-exempt entity. 1.17 Cunningham-Warren Properties, L.L.C. is a Kansas limited liability company, the sole members of which are Hollis O. Cunningham and G. Windsor Warren. 1.18 If any member or other affiliate of the General Partner is a tax-exempt entity and the General Partner is a "controlled entity" in relation to such tax-exempt entity, a timely election will be made under Code Section 168(h)(6)(F) so that no portion of the Apartment Complex will be treated as "tax exempt use property" as defined in Code Section 168(h). 1.19 All representations made by the General Partner in the Operating Partnership Agreement are incorporated herein by reference and are confirmed. 1.20 It is reasonable to expect that the Operating Partnership will be able to repay, as and when due, the principal and interest on the projected loans to the Operating Partnership based on the projected value of the Operating Partnership's property and building(s) and the projection of rental income and expense from operations set forth in Exhibit A, assuming a rate of inflation of operating income and expense during the term of the Loans that is reasonable for the area in which the Apartment Complex is located. 1.21 An Extended Use Commitment (as defined in the Operating Partnership Agreement) within the meaning of Code Sec- tion 42(h)(6) will be in effect and recorded in the appropriate land evidence records with respect to the building(s) in the Apartment Complex not later than the end of the first taxable year in which any Tax Credit is taken with respect to any building. If not in effect as of the date hereof, the General Partner agrees (i) to deliver a valid and binding Extended Use Agreement and evidence that it has been recorded no later than the end of the first taxable year in which any Tax Credit is taken with regarding to any building and (ii) to ensure that all Partnership lenders subordinate their mortgage liens on the Apartment Complex to the Extended Use Agreement at or prior to the time it is recorded. 1.25 The amounts payable in development and property management fees to the General Partner, Management Agent and the Developer are fair in light of the value and magnitude of the services rendered in consideration for such fees, and the services performed in consideration for the development fees relate solely to the acquisition, construction or renovation of the Apartment Complex. 1.26 To the best of the General Partner's knowledge, the Low-Income Housing Tax Credits allocated to the Apartment Complex will not exceed the amount the Agency determines is necessary for the financial feasibility of the Apartment Complex and its viability as a qualified low-income housing project throughout the credit period. 1.27 To the best of the General Partner's knowledge, the proposed operations of the Apartment Complex and the Partnership satisfy the requirements of the State's Qualified Allocation Plan, including any specific targeting, set-asides or other factors upon which the Missouri Housing Development Commission based its determination that the proposed operations of the Apartment Complex and the Partnership satisfy the Qualified Allocation Plan. 1.28 The Operating Partnership has not elected pursuant to Code Section 42 to lock in the applicable Tax Credit rate prior to placement in service of each building. 1.29 Each of the representations and disclosures made by the Operating Partnership to the Missouri Housing Development Commission (the "Agency") in the Low Income Housing Tax Credit Allocation Application (the "Credit Application") upon which the Lombard Heights Apartments Reservation (LIHTC No. 97-122) dated October 22, 1997 between the Agency and the Operating Partnership (the "Credit Reservation Agreement") was based, is true and correct as of the date hereof. 1.30 Each of the covenants, agreements, and conditions contained in the Credit Application and Credit Reservation Agreement, has been duly performed or satisfied by the Operating Partnership or the General Partner, as applicable, to the extent that performance of any such covenant or agreement or satisfaction of any conditions is required on or prior to the date hereof, and the General Partner has no reason to believe that the covenants, agreements, and conditions required to be performed or satisfied after the date hereof will not be performed or satisfied in a timely manner. 1.31 The General Partner has not received from the Agency any notice of default or of withdrawal or cancellation of the Tax Credit reservation or allocation to the Operating Partnership as described in the Credit Reservation Agreement. 1.32 [*Reserved*] 1.33 At the time the Limited Partners are admitted into the Partnership, the General Partner will have an aggregate net worth calculated in accordance with generally accepted accounting principals but not including the value of any equity or debt interest such General Partner has in the Partnership, equal to at least ten percent (10%) of the Capital Contributions to the Partnership. 1.34 The General Partner and any entity that is related to the General Partner or to the Operating Partnership and that receives a fee from the Operating Partnership, directly or indirectly, is on the accrual method of accounting for tax purposes. If any fee received by the General Partner is treated as a guaranteed payment under Section 707(c) of the Code, the General Partner will recognize such fee as income at the time such fee is accrued by the Operating Partnership. 1.35 The General Partner will be actively involved in the management and operation of the Operating Partnership, will devote substantial and continuing attention to the activities of the Operating Partnership, and will provide substantial services to the Operating Partnership. 1.36 The development and leasing activity in which the Operating Partnership will engage will not contain personal or recreational benefit for the partners of the Operating Part- nership. 1.37 The Operating Partnership will keep active records and carry out the proposed activity in a manner consistent with profitable businesses in the same activity. 1.38 The Operating Partnership will have an objective to carry on businesses for profit and divide the gains therefrom. 1.39 The Operating Partnership may earn a profit, including profit from appreciation in the value of the Apartment Complex. 1.40 The Mortgage Loan and all other debt financing of the Apartment Complex require the noncontingent repayment of principal on or before a fixed maturity date, and will be consid- ered and treated as a loan by the Lender. 1.41 The Operating Partnership's Lender is not a party from whom the Operating Partnership acquired any portion of the Apartment Complex, and none of the financing was issued in exchange for any portion of the Apartment Complex. The Operating Partnership's Lender will not receive a fee with respect to the Operating Partnership's investment in the Apartment Complex. 1.42 Aside from the Permanent Loan, the following is a description of any and all existing or proposed financing of the Apartment Complex that involves any direct or indirect grant or federal subsidy (including, without limitation, federal grants, below-market interest rate loans, and tax-exempt bonds): None other than the Permanent Loan. 1.43 The Project will not receive moderate rehabili- tation assistance under Section 8(e)(2) of the United States Housing Act of 1937 (unless pursuant to the Stewart B. McKinney Homeless Assistance Act of 1988). 1.44 If the Apartment Complex is a scattered site project within the meaning of Code Section 42, 100% of the rental units in the Apartment Complex will be rent-restricted within the meaning of Code Section 42. 1.45 All Units in the Apartment Complex are to be of equal quality and all Apartment Complex amenities are to be made available to all tenants on a comparable basis without separate fees except for one unit in which the on-site manager shall reside. 1.46 There will be no direct or indirect personal liability of the Operating Partnership or of any of the Partners for the repayment of the principal of and payment of interest on the Mortgage Loans, and the sole recourse of the Lender under the Mortgage Loans, with respect to the principal thereof and interest thereon, will be to the property securing the indebtedness. 1.47 The Apartment Complex is not located in a qualified census tract ("QCT") or a HUD-designated difficult to develop area ("DDA"), which qualifies the Apartment Complex for the 130% basis boost pursuant to Code Section 42. 1.48 [Reserved] 1.49 If the Apartment Complex's eligible basis includes rehabilitation expenditures that are expected to generate Projected Credit under Section 42(e) of the Code (the "Rehabilitation Credit"), the Operating Partnership expects to incur within a 24-month period expenditures equal to at least the greater of (i) $3,000 per residential unit or (ii) 10% of the unadjusted basis of the buildings in the Apartment Complex. 1.50 If necessary to insure that 100% of the Projected Credit is available to the Project, the Partnership will elect to defer the commencement of the tax credit period in accordance with Section 42(f)(1)(b). 1.51 At least 50% of the aggregate basis of the Land and buildings comprising the Apartment Complex will be financed by the Permanent Loan. If the bond financing is limited to the Permanent Loan, the proceeds of the Permanent Loan will be used to pay off the Construction Loan upon completion of the Apartment Complex before the expiration of the first year in the Tax Credit period. 1.52 The Permanent Loan will be funded by tax exempt bonds, the interest on which is exempt from tax under Code Section 103; such bonds are subject to the volume cap imposed by Code Section 146; and principal payments on the Permanent Loan are to be applied within a reasonable period to redeem such bonds. 2. Indemnification 2.01 The General Partner (for purposes of this Section 2.01, jointly and severally, the "Indemnifying Parties" or, individually, an "Indemnifying Party") agrees to indemnify and hold harmless the Limited Partners (for purposes of this Section 2.01, the "Indemnified Parties" or, individually, an "Indemnified Party") and each officer, director, employee and person, if any, who controls any Indemnified Party against any losses, claims, damages or liabilities (collectively, "Liabilities"), joint or several, to which any Indemnified Party or such officer, director, employee or controlling person may become subject, insofar as such Liabilities or actions in respect thereof arise out of or are based upon (i) a breach by such Indemnifying Party of any of its representations, warranties or covenants to such Indemnified Party or any such of its officers, directors, employees or controlling persons under this Certification and Agreement or (ii) liability in connection with the Land and/or the Apartment Complex, as each term is defined in the Operating Partnership Agreement, under any statute, regulation, ordinance, or other provision of federal, state, or local law pertaining to the protection of the environment, or otherwise pertaining to public health or employee health and safety, including, without limitation, protection from hazardous waste, lead-based paint, methane gas, urea formaldehyde insulation, oil, toxic substance, underground storage tanks, polychlorinated biphenals (PCBs), and radon; and to reimburse each such Indemnified Party and each such officer, director, employee or controlling person for any legal or other expenses reasonably incurred by it or them in connection with defending against any such Liability or action; provided, however, that the Indemnifying Party shall not be required to indemnify any Indemnified Party or any such officer, director, employee or controlling person for any payment made to any claimant in settlement of any Liability or action unless such payment is approved by the Indemnifying Party or by a court having jurisdiction of the controversy. This indemnity agreement shall remain in full force and effect notwithstanding any investigation made by any party hereto, shall survive the termination of any agreement which refers to this indemnity and shall be in addition to any liability which the Indemnifying Party may otherwise have. 2.02 No Indemnifying Party shall be liable under the indemnity agreements contained in Section 2.01 unless the Indem- nified Party shall have notified the Indemnifying Party in writing within forty-five (45) business days after the summons or other first legal process giving information of the nature of the claim shall have been served upon the Indemnified Party or any such of its officers, directors, employees or controlling per- sons, but failure to notify an Indemnifying Party of any such claim shall not relieve it from any liability which it may have to the Indemnified Party or any such of its officers, directors, employees or controlling persons against whom action is brought otherwise than on account of its indemnity agreement contained in Section 2.01. In case any action is brought against any Indemni- fied Party or any such of its officers, directors, employees or controlling persons upon any such claim, and it notifies the Indemnifying Party of the commencement thereof as aforesaid, the Indemnifying Party shall be entitled to participate at its own expense in the defense, or, if it so elects, in accordance with arrangements satisfactory to any other Indemnifying Party or parties similarly notified, to assume the defense thereof, with counsel who shall be reasonably satisfactory to such Indemnified Party or any such of its officers, directors, employees or controlling persons and any other Indemnified Parties who are defendants in such action; and after notice from the Indemnifying Party to such Indemnified Party or any such of its officers, directors, employees or controlling persons of its election so to assume the defense thereof and the retaining of such counsel by the Indemnifying Party, the Indemnifying Party shall not be liable to such Indemnified Party or any such of its officers, directors, employees or controlling persons for any legal or other expenses subsequently incurred by such Indemnified Party or any such of its officers, directors, employees or controlling persons in connection with the defense thereof. 3. Miscellaneous 3.01 This Certification and Agreement is made solely for the benefit of the Limited Partners, Burns & Levinson LLP, and James M Ramsey, Esq., (and, to the extent provided in Section 2, the officers, directors, partners, employees and controlling persons referred to therein), and their respective successors and assigns, and no other person shall acquire or have any right under or by virtue of this Agreement. 3.02 This Certification and Agreement may be executed in several counterparts, each of which shall be deemed to be an original, all of which together shall constitute one and the same instrument. IN WITNESS WHEREOF, the undersigned have set their hands and seals as of the date first above written. OPERATING PARTNERSHIP: LOMBARD PARTNERS, L.P. Cunningham-Warren Properties, L.L.C. as General Partner By: /s/ Hollis O. Cunningham Hollis O. Cunningham, Manager Exhibit A Lombard Partners Fact Sheet 1. Sources and Uses of Funds: Sources of Funds: A. Senior Mortgage Loan (T-Exempt Bonds) $ 800,000 B. Junior Mortgage Loan $ 0 C. Grant $ 0 D. General Partner Capital Contributions $ 164,217 E. Investment Partnership Capital Contribution $ 359,958 F. Deferred Development Fee Obligation $ 198,626 $1,522,801 Application of Funds: A. Total Construction Cost $ 972,395 B. Soft Costs $ 326,780 C. Land Costs $ 25,000 D. Development Fee $ 198,626 $ 1,522,801 2. Eligible Basis: $ 1,327,025 3. Qualified Basis: $ 1,335,025 4. Type of Credit: New Construction - 4% 5. Rent-up Schedule: 100% by December 1, 1998 6. Projected Credit to the Investment Partnership Years 1999 - 2008 (99.99%): $ 47,994 7. Total Projected Credit to the Operating Partnership (100%): $ 47,999 8. Tax Credit Approval: A. Application: 1. Date: October 22, 1997 2. Credit Amount Requested: $49,317 B. Credit Reservation: 1. Date: January 16, 1998 2. Credit Amount Reserved: $49,317 C. Carryover Allocation: N.A. 1. Date: 2. Credit Amount Allocated: D. Credit Rate Lock-in Agreement 1. Date: April, 1998 2. Rate locked-in: 3.59% E. Form 8609 1. Date: _____________ 2. Credit Amount Allocated: ___________ 9. Apartment Complex: A. Name: Lombard Heights Apartments B. Address: 305 East Lombard Street C. County: Springfield, Missouri D. Type of Project: Low Income Housing 10. 1999 Area Median Income: $ 41,100 11. Type of Units: Square Feet Basic Utility Number Type Unit Rent Allowance 1 1 bedroom 699 $409 $53 2 2 bedroom 862 $489 $66 3 3 bedroom 1,008 $556 $85 12. Difference between rents allowed by FmHA and rents allowed under the Rent Restriction Test, if applicable: N.A. 13. Rental Assistance: N.A. 14. (Projected) Annual Operating Expenses: $ 48,246 (year 2) 15. Replacement Reserve Account A. Annual: $ 4,800 16. Operating Reserve Account: $ 36,000 17. Amount of Annual Asset Management Fee Limited Partnership: $ 1,800 18. Amount of Annual Incentive Partnership Management Fee: $ 1,800 [annual] 19. Amount of Total Depreciable Basis Allocated to Personal Property: $1,025,673 20. Completion Date: July, 1998 21. Total Capital Contribution of Investment Partnership: $ 359,958 22. Schedule of Capital Contributions: A. $233,973 consisting of $158,973 in cash contributions plus the bridge Loan Note in the amount of $75,000 upon admission. B. $89,990 on the latest to occur of (A) Cost Certification, (B) receipt of an updated title insurance policy satisfactory to the Special Limited Partner, (C) Initial 100% Occupancy Date, (D) State Designation, (E) receipt of a payoff letter from the Contractor stating that all amounts payable to the Contractor have been paid in full and that the Partnership is not in violation of the Construction Contract, (F) Substantial Completion, (G) receipt of a valid and recorded Extended Use Commitment and receipt of a subordination agreement subordinating the Mortage Loan to the extended Use Commitment, (H) receipt of updated insurance certificates relating to the Apartment Complex satisfactory to the Special Limited Partnership or (I) satisfaction of all of the conditions to the payment of the First Installment. C. $30,995 on the latest to occur of (A) Rental Achievement or (B) satisfaction of all of the conditions to the payment of the First and Second Installment (the "Third Installment"); and D. $5,000 on the latest to occur of (A) the receipt by the Investment Partnership of the Partnership's federal income tax return and an audited financial statement for the year in which Rental Achievement occurred or (B) satisfaction of all of the conditions to the payment of the First, Second and Third Installments (the "Fourth Installment"). 23. Fees, Special Distributions and Other Items to be paid from Capital Contributions A. Development Fee: $198,626 (All Deferred) 24. Consulting Fee to Boston Capital 0 Partners, Inc., if applicable 25. Operating General Partner: Cunningham-Warren Properties, LLC Attn: Hollis O. Cunningham Address: 11260 W 155th Terrace Overland Park, Kansas 66221 Telephone Number: (913) 681-8193 26. Managing General Partner: Cunningham-Warren Properties, LLC Attn: Hollis O. Cunningham Address: 11260 W 155th Terrace Overland Park, Kansas 66221 Telephone Number: (913) 681-8193 27. Developer: Cunningham-Warren Properties, LLC Attn: Hollis O. Cunningham Address: 11260 W 155th Terrace Overland Park, Kansas 66221 Telephone Number: (913) 681-8193 28. Ownership Interests Normal Capital Cash Operations Transactions Flow Operating General Partner 0.01% 75% 85% Investment Partnership 99.8% 25% 15% Special Limited Partner 0.01% 0% 0% 29. Management Agent: Cunningham-Warren Properties, LLC Attn: Hollis O. Cunningham Address: 11260 W 155th Terrace Overland Park, Kansas 66221 Telephone Number: (913) 681-8193 Amount of Fee: Five percent (5%) of Gross Income 30. Management Construction Agent: Cunningham-Warren Properties, LLC Attn: Hollis O. Cunningham Address: 11260 W 155th Terrace Overland Park, Kansas 66221 Telephone Number: (913) 681-8193 Amount of Compensation: 18% of contract price Builder's Profit: $ 147,951 31. Architect: Warren & Goodin, Inc. Attn: G. Windsor Warren Address: 420 South Avenue Springfield, Missouri 65806 Telephone Number: (417) 869-8900 Amount of Fee: $68,000 32. Auditor: _____________________ Attn: _____________________ Address: _____________________ _____________________ Telephone Number: _____________________ 33. Tax Return Preparer: _____________________ Attn: _____________________ Address: _____________________ ________________ Telephone Number: _______________ 34. Federal Taxpayer ID Number: ________________ 35. State Housing Credit Agency: Missouri Housing Development Commission 36. State Housing Agency LIHTC Number: (816) 759-6600 37. Operating Deficit Guaranty The General Partner shall be obligated to make Subordinated Loans to the Partner- ship to cover debt service, operating expenses and the Replacement Reserve Fund to the extent these exceed available operating income subject to a $250,000 limit for the five year period following Rental Achievement. 38. Guaranty of Development Lost Overruns/ Excess Development Costs G.P. is obligated to pay all Excess Development Costs 39. Guarantors: Cunningham-Warren Properties, L.L.C. G. Windsor Warren Hollis O. Cunningham G. Windsor Warren as trustee u/d/t dated July 19, 1991 (the "Trust") 40. Post-Closing Follow-Up Required Extended Use-form in file from agency cc: Boston Capital Communications Limited Partnership Accounting Department Exhibit B Certificate of Operating Partnership and Operating General Partner Re: Lack of Disqualifications The Operating Partnership and its Operating General Partner (as identified on the Certification and Agreement to which this Certificate is attached as Exhibit B) hereby represent to you that none of (i) the Operating Partnership, (ii) any predecessor of the Operating Partnership, (iii) any of the Operating Partnership's affiliates ("affiliate" meaning a person that controls or is controlled by, or is under common control with, the Operating Partnership), (iv) any sponsor (meaning any person who (1) is directly or indirectly instrumental in organizing the Operating Partnership or (2) will directly or indirectly manage or participate in the management of the Operating Partnership or (3) will regularly perform, or select the person or entity who will regularly perform, the primary activities of the Operating Partnership), (v) any officer, director, principal or general partner of the Operating Partnership or of any sponsor, (vi) the officer, director, principal, promoter or general partner of Operating General Partner, (vii) any beneficial owner of ten percent (10%) or more of any class of the equity securities of the Operating Partnership or of any sponsor (beneficial ownership meaning the power to vote or direct the vote and/or the power to dispose or direct the disposition of such securities), (viii) any promoter of the Operating Partnership (meaning any person who, acting alone or in conjunction with one or more other persons, directly or indirectly has taken, is taking or will take the initiative in founding and organizing the business of the Operating Partnership or any person who, in connection with the founding and organizing of the business or enterprise of the Operating Partnership, directly or indirectly receives in consideration of services or property, or both services and property, ten percent (10%) or more of any class of securities of the Operating Partnership or ten percent (10%) or more of the proceeds from the sale of any class of such securities; provided, however, a person who receives such securities or proceeds either solely as underwriting commissions or solely in consideration of property shall not be deemed a promoter if such person does not otherwise take part in founding and organizing the enterprise) presently connected with the Operating Partnership in any capacity: (1) Has filed a registration statement which is the subject of any pending proceeding or examination under the secur- ities laws of any jurisdiction, or which is the subject of a any refusal order or stop order thereunder entered within five (5) years prior to the date hereof; (2) Has been convicted of or pleaded nolo contendere to a misdemeanor or felony or, within the last ten (10) years, been held liable in a civil action by final judgment of a court based upon conduct showing moral turpitude in connection with the offer, purchase or sale of any security, franchise or commodity (which term, for the purposes of this Certificate shall hereinafter include commodity futures contracts) or any other aspect of the securities or commodities business, or involving racketeering, the making of a false filing or a violation of Sections 1341, 1342 or 1343 of Title 18 of the United States Code or arising out of the conduct of the business of an issuer, underwriter, broker, dealer, municipal securities dealer, or investment adviser, or involving theft, conversion, misappropriation, fraud, breach of fiduciary duty, deceit or intentional wrongdoing including, but not limited to, forgery, embezzlement, obtaining money under false pretenses, larceny fraudulent conversion or misappropriation of property or conspiracy to defraud, or which is a crime involving moral turpitude, or within the last five (5) years of a misdemeanor or felony which is a criminal violation of statutes designed to protect consumers against unlawful practices involving insurance, securities, commodities, real estate, franchises, business opportunities, consumer goods or other goods and services; (3) Is subject to (a) any administrative order, judgment or decree entered within five (5) years prior to the date hereof entered or issued by or procured from a state securities commission or administrator, the Securities and Exchange Commission ("SEC"), the Commodities Futures Trading Commission or the U.S. Postal Service, or to (b) any administrative order or judgment, arising out of the conduct of the business of an underwriter, broker, dealer, municipal securities dealer, or investment adviser, or involving deceit, theft, fraud or fraudulent conduct, or breach of fiduciary duty, or which is based upon a state banking, insurance, real estate or securities law or (c) has been the subject of any administrative order, judgment or decree in any state in which fraud, deceit, or intentional wrongdoing, including, but not limited to, making untrue statements of material fact or omitting to state material facts, was found; (4) Is subject to any pending proceeding in any jurisdiction relating to the exemption from registration of any security or offering, or to any order, judgment or decree in which registration violations were found or which prohibits, denies or revokes the use of any exemption from registration in connection with the offer, purchase or sale of securities, or to an SEC censure or other order based on a finding of false filing; (5) Is subject to any order, judgment or decree of any court or regulatory authority of competent jurisdiction entered within five (5) years prior to the date hereof, temporarily, preliminarily or permanently restraining or enjoining such persons from engaging in or continuing any conduct or practice in connection with any aspect of the securities or commodities business or involving the making of any false filing or arising out of the conduct of the business of an underwriter, broker, dealer, municipal securities dealer, or investment adviser, or which restrains or en joins such person from activities subject to federal or state statutes designed to protect consumers against unlawful or deceptive practices involving insurance, banking, commodities, real estate, franchises, business opportunities, consumer goods and services, or is subject to a United States Postal Service false representation order entered within five (5) years prior to the date hereof, or is subject to a temporary restraining order or preliminary injunction with respect to conduct alleged to have violated Section 3005 of Title 39 of the United States Code; (6) Is suspended or expelled from membership in, or suspended or barred from association with a member of, an exchange registered as a national securities exchange, an association registered as a national securities association, or any self- regulatory organization registered pursuant to the Securities Exchange Act of 1934, or a Canadian securities exchange, or association or self-regulatory organization operating under the authority of the Commodity Futures Trading Commission, or is subject to any currently effective order or order entered within the past five years of the SEC, the Commodity Futures Trading Commission or any state securities administrator denying regis- tration to, or revoking or suspending the registration of, such person as a broker-dealer, agent, futures commission merchant, commodity pool operator, commodity trading adviser or investment adviser or associated person of any of the foregoing, or prohib- iting the transaction of business as a broker-dealer or agent; (7) Has, in any application for registration or in any report required to be filed with, or in any proceeding before the SEC or any state securities commission or any regulatory authority willfully made or caused to be made any statement which was at the time and in the light of the circumstances under which it was made false or misleading with respect to any material fact, or has willfully omitted to state in any such application, report or proceeding any material fact which is required to be stated therein or necessary in order to make the statements made, in the light of the circumstances under which they are made, not misleading, or has willfully failed to make any required amendment to or supplement to such an application, report or statement in a timely manner; (8) Has willfully violated any provision of the Securities Act of 1933, the Securities Exchange Act of 1934, the Trust Indenture Act of 1939, the Investment Advisers Act of 1940, the Investment Company Act of 1940, the Commodity Exchange Act of 1974 or the securities laws of any state, or any predecessor law, or of any rule or regulation under any of such statutes; (9) Has willfully aided, abetted, counseled, commanded, induced or procured the violation by any other person of any of the statutes or rules or regulations referred to in subsection (8) hereof; (10) Has failed reasonably to supervise his agents, if he is a broker-dealer, or his employees, if he is an investment adviser, but no person shall be deemed to have failed in such supervision if there have been established procedures, and a system for applying such procedures, which would reasonably be expected to prevent and detect, insofar as practicable, any violation of statutes, rules or orders described in subsection (8) and if such person has reasonably discharged the duties and obligations incumbent upon him by reason of such procedures and system without reasonable cause to believe that such procedures and system were not being complied with; (11) Is subject to a currently effective state admini- strative order or judgment procured by a state securities admini- strator within five (5) years prior to the date hereof or is subject to a currently effective United States Postal Service fraud order or has engaged in dishonest or unethical practices in the securities business or has taken unfair advantage of a customer or is the subject of sanctions imposed by any state or federal securities agency or self-regulatory agency; (12) Is insolvent, either in the sense that his liabilities exceed his assets or in the sense that he cannot meet his obligations as they mature, or is in such financial condition that he cannot continue his business with safety to his customers, or has not sufficient financial responsibility to carry out the obligations incident to his operations or has been adjudged a bankrupt or made a general assignment for the benefit of creditors; or (13) Is selling or has sold, or is offering or has offered for sale, in any state securities through any unregistered agent required to be registered under any securities laws of Missouri or for any broker-dealer or issuer with knowledge that such broker-dealer or issuer had not or has not complied with such securities laws. If the Operating Partnership is subject to the requirements of Section 12, 14 or 15(d) of the Securities Exchange Act of 1934, then the Operating Partnership has filed all reports required by those Sections to be filed during the twelve (12) calendar months preceding the date hereof (or for such shorter period that the Operating Partnership was required to file such reports). EX-10 4 LOMBARD HEIGHTS APARTMENTS DEVELOPMENT AGREEMENT LOMBARD HEIGHTS APARTMENTS DEVELOPMENT AGREEMENT This Development Agreement is made and entered into as of October __, 1998 between Lombard Partners, L.P., a Missouri limited partnership (the "Partnership"), and Cunningham-Warren Properties, L.L.C., a Kansas limited liability company (the "Developer"). Cunningham-Warren Properties, L.L.C., a State of Missouri limited liability company, and (the "General Partner") and BCTC 94, Inc., a Massachusetts corporation (the "Special Limited Partner") and Boston Capital Tax Credit Fund IV, L.P. a Massachusetts limited partnership (the "Investment Partnership or the Fund"), have entered into that certain Lombard Partners, L.P. Amended and Restated Agreement of Limited Partnership of the Partnership (the "Partnership Agreement"), to (i) continue the Partnership; (ii) admit the Special Limited Partner as the Special Limited Partner and the Fund as a Limited Partner of the Partnership; (iii) reassign Interests in the Partnership; (iv) provide for the withdrawal of the withdrawing limited partner; and (v) set forth all of the provisions governing the Partnership; and WHEREAS, the Partnership has been formed to acquire, construct, rehabilitate, develop, own, maintain, and operate a 24-unit multi-family rental housing development intended for rental to individuals of low and moderate income, known as Lombard Heights Apartments and located in Springfield, Missouri (the "Apartment Complex"); and WHEREAS, the Partnership desires to appoint the Developer to provide certain services for the Partnership with respect to overseeing the acquisition, construction, development and/or rehabilitation of the Apartment Complex until the acquisition, construction, development and/or rehabilitation work is completed, including ratifying and confirming certain services provided by the Developer prior to the date of this Agreement. NOW, THEREFORE, in consideration of the foregoing, of the mutual promises of the parties hereto and of other good and valuable consideration, the receipt and sufficiency of which hereby are acknowledged, it is agreed as follows: 1. APPOINTMENT. The Partnership hereby appoints the Developer to render services for the Partnership in supervising and overseeing the acquisition, construction, development and/or rehabilitation of the Apartment Complex as herein contemplated, and ratifies and confirms the services of such nature performed by the Developer for the Partnership prior to the date of this Agreement. 2. AUTHORITY AND OBLIGATIONS. (a) In conformity with the provisions of the Partnership Agreement, the Developer has performed certain services related to the acquisition, construction, development and/or rehabilitation of the Apartment Complex and shall oversee the acquisition, construction, development and/or rehabilitation of the Apartment Complex, and shall perform the services and carry out the responsibilities with respect to the Apartment Complex as are set forth herein, and such additional duties and responsibilities and are designated from time to time by the General Partner. (b) The Developer's services shall be performed in the name and on behalf of the Partnership and shall consist of the duties set forth in the following subparagraphs of this Section 2(b) and as provided elsewhere in this Agreement; provided, however, that if the performance of any duty of the Developer set forth in this Agreement is beyond the reasonable control of the Developer, the Developer shall nonetheless be obligated to (i) use its best efforts to perform such duty and (ii) promptly notify the Partnership that the performance of such duty is beyond its reasonable control. The Developer has performed or shall perform the following: (i) Negotiate and assist the structuring of the Apartment Complex by the Partnership; (ii) Negotiate and cause to be executed in the name and on behalf of the Partnership agreements for architectural, engineering, testing or consulting services for the Apartment Complex, and any agreements for the construction and/or rehabilitation of any improvement or tenant improvements to be constructed and/or rehabilitated or installed by the Partnership or the furnishing of any supplies, materials, machinery or equipment therefor, or any amendments thereof, provided that no agreement shall be executed nor binding commitment made until the terms and conditions thereof and the party with whom the agreement is to be made shall have been approved by the Partnership unless the terms, conditions, and parties comply with guidelines issued by the General Partner concerning such agreements; (iii) Assist the Partnership in dealing with neighborhood groups, local organizations, abutters and other parties in interest in the development of the Apartment Complex; (iv) Provide the initial equity funding for the construction and/or rehabilitation of the Apartment Complex; (v) Establish and implement appropriate administrative and financial controls for the design and construction and/or rehabilitation of the Apartment Complex, including but not limited to: (A) coordination and administration of the Apartment Complex by the architect, general contractor, and other contractors, professionals and consultants employed in connection with the design and construction and/or rehabilitation of the Apartment Complex: (B) administration of any construction and/or rehabilitation contracts on behalf of the Partnership; (C) participation in conferences and the rendering of such advice and assistance as will aid in developing economical, efficient and desirable design and construction and/or rehabilitation procedures; (D) the rendering of advice and recommendations as to the selection procedures for the selection of subcontractors and suppliers; (E) the review and submission to the Partnership for approval of all requests for payments under any architectural agreement, general contractor's agreement, or any loan agreements with any lending institutions providing funds for the benefit of the Partnership for the design or construction and/or rehabilitation of any improvement; (F) the submission of any suggestions or request for changes which could in any reasonable manner improve the design, efficiency or cost of the Apartment Complex; (G) applying for and maintaining in full force and effect any and all governmental permits and approvals required for the lawful construction and/or rehabilitation of the Apartment Complex; (H) compliance with all terms and conditions applicable to the Partnership or the Apartment Complex contained in any governmental permit or approval required or obtained for the lawful construction and/or rehabilitation of the Apartment Complex, or in any insurance policy affecting or covering the Apartment Complex; (I) furnishing such consultation and advice relating to the construction, rehabilitation and/or development of the Apartment Complex as may be reasonably requested from time to time by the Partnership; (J) keeping the Partnership fully informed on a regular basis of the progress of the design and construction and/or rehabilitation of the Apartment Complex, including the preparation of such reports as are provided for herein or as may be reasonably be requested by the Partnership; (K) giving or making the Partnership's instructions, requirements, approvals and payments provided for in the agreements with the Apartment Complex architect, general contractor, and other contractors, professionals and consultants retained for the Apartment Complex; and (L) at the Partnership's expense, on behalf of, and as the attorney-in-fact for, the Partnership, filing any notices of completion required or permitted to be filed upon the completion of any improvement(s) and taking such actions as may be required to obtain a certificate of substantial completion; (vi) Assist the Partnership in obtaining access to utilities and required zoning approvals; (vii) Inspect the progress of the course of construction and/or rehabilitation of the Apartment Complex, including verification of the materials and labor being furnished to and on such construction, so as to be fully competent to approve or disapprove requests for payment made by the Apartment Complex architect and the general contractor, or by any other parties with respect to the design and construction and/or rehabilitation of the Apartment Complex, and in addition to verify that the same is being carried out substantially in accordance with the plans and specifications approved by the Partnership or, in the event that the same is not being so carried out, to promptly so notify the Partnership; (viii) If requested to do so by the Partnership, perform on behalf of the Partnership all obligations of the Partnership with respect to the design and construction and/or rehabilitation of the Apartment Complex contained in any loan agreement or security agreement entered into in connection with any financing for the Apartment Complex, or in any lease or rental agreement relating to the space in the Apartment Complex, or in any agreement entered into with any governmental body or agency relating to the terms and conditions of such constructions, provided that copies of such agreements have been provided by the Partnership to the Developer or the Partnership has otherwise notified the Developer in writing of such obligations; (ix) To the extent requested to do so by the Partnership, prepare and distribute to the Partnership a critical path schedule, and periodic updates thereto as necessary to reflect any material changes, but in any event not less frequently than quarterly, other design or construction and/or rehabilitation cost estimates as required by the Partnership, and financial accounting reports, including monthly progress reports on the quality, progress and cost of construction and/or rehabilitation and recommendations as to the drawing of funds from any loans arranged by the Partnership to cover the cost of design and construction and/or rehabilitation of the Apartment Complex; (x) Assist the Partnership in obtaining and maintaining insurance coverage for the Apartment Complex, the Partnership and its employees during the development phase of the Apartment Complex, in accordance with an insurance schedule approved by the Partnership, which insurance shall include general public liability insurance covering claims for personal injury, including but not limited to bodily injury, or property damage, occurring in or upon the Property or the streets, passageways, curbs and vaults adjoining the Property. Such insurance shall be in a liability amount approved by the Partnership; (xi) During the construction and/or rehabilitation and development period of the Apartment Complex, comply with all applicable present and future laws, ordinances, orders, rules, regulations and requirement (hereinafter called "laws) of all federal, state and municipal governments, courts, departments, commissions, boards and offices, any national or local Board of Fire Underwriters or Insurance Services Offices having jurisdiction in the county in which the Apartment Complex is located or any other body exercising functions similar to those of any of the foregoing, or any insurance carriers providing any insurance coverage for the Partnership or the Apartment Complex, which will be applicable to the Apartment Complex or any part thereof. Any such compliance undertaken by the Developer on behalf of and in the name of the Partnership, in accordance with the provisions of this Agreement, shall be at the Partnership's expense. The Developer shall likewise ensure that all agreements between the Partnership and independent contractors comply with all such applicable laws; (xii) Assemble and retain all contracts, agreements and other records and data as may be necessary to carry out the Developer's functions hereunder. Without limiting the foregoing, the Developer will prepare, accumulate and furnish to the General Partner and the appropriate governmental authorities, as necessary, data and information sufficient to identify the market value of improvement in place as of each real property tax lien date, and will make application for appropriate exclusions from the capital costs of the Apartment Complex for purposes of real property ad valorem taxes; (xiii) Coordinate and administer the design and construction and/or rehabilitation of all interior tenant improvements to the extent required under any leases or other occupancy agreements to be constructed and/or rehabilitated or furnished by the Partnership with respect to the initial leasing of space in the Apartment Complex, whether involving building standard or non-building standard work; (xiv) Use its best efforts to accomplish the timely completion of the Apartment Complex in accordance with the approved plans and specifications and the time schedules for such completion approved by the Partnership; (xv) At the direction of the Partnership, implement any decisions of the Partnership made in connection with the design, development and construction and/or rehabilitation of the Apartment Complex or any policies and procedures relating thereto, exclusive of leasing activities; and (xvi) Perform and administer any and all other services and responsibilities of the Developer which are set forth in any other provisions of this Agreement, or which are requested to be performed by the Partnership and are within the general scope of the services described herein. (c) Notwithstanding any provisions of this Agreement, the Developer shall not take any action, expend any sum, make any decision, give any consent, approval, or authorization or incur any obligation with respect to any of the following matters unless and until the same has been approved by the General Partner: (i) Approval of all construction and/or rehabilitation and architectural contracts and all architectural plans, specifications and drawings prior to the construction and/or rehabilitation and/or alteration of any improvements contemplated thereby, except for such matters as may be expressly delegated in writing to the Developer by the General Partner; (ii) Any proposed change in the work of the construction and/or rehabilitation of the Apartment Complex, or in the plans and specifications therefor as previously approved by the General Partner, or in the cost thereof, or any change which would affect the design, cost, value or quality of the Apartment Complex, except for such matters as may be expressly delegated in writing to the Developer by the General Partner; or (iii) Expending an amount greater than the amount which the Developer in good faith believes to be fair and reasonable market value at the time and place of contracting for any good purchased or leased or services engaged on behalf of the Partnership or otherwise in connection with the Apartment Complex. 3. ACCOUNTS AND RECORDS. (a) The Developer, on behalf of the Partnership, shall keep such books of account and other records as may be required and approved by the General Partner, including, but not limited to, records relating to the costs for which construction and/or rehabilitation advances have been requested and/or received. The Developer shall keep vouchers, statements, receipted bills and invoices and all other records, in the form approved by the General Partner, covering all collections, if any, disbursements and other data in connection with the Apartment Complex prior to final completion of construction and/or rehabilitation. All accounts and records relating to the Apartment Complex, including all correspondence, shall be surrendered to the Partnership upon demand without charge therefor. (b) All books and records prepared or maintained by the Developer shall be kept and maintained at all times at the place or places approved by the General Partner, and shall be available for the subject to audit, inspection and copying by the management agent for the Apartment Complex, the General Partner or any representative or auditor therefor or supervisory or regulatory authority, at the times and in the manner set forth in the Partnership Agreement of the Partnership. 4. DEVELOPMENT FEE. For services performed and to be performed under Sections 1 and 2 of this Agreement, the Partnership agrees to pay the Developer a Development Fee in the amount of $213,185, in accordance with Section 8.10 of the Partnership Agreement. The entire Development Fee shall be deemed earned as and when the services specified herein shall have been rendered and in any event shall have been earned upon the latest to occur of: (i) Substantial Completion, (ii) Cost Certification and (iii) Final Closing. The Development Fee shall be deferred and paid in accordance with Section 11.03A or Section 11.04A of the Partnership Agreement; or, if not sooner paid, on October 1, 2008. In the event the Development Fee is not paid in full by October 1, 2008, then the General Partner shall make a Special Capital Contribution to the Partnership in accordance with Section 5.01 of the Partnership Agreement. 5. WITHHOLDING OF FEE PAYMENTS. In the event that (a) the General Partner or any successor General Partner shall not have substantially complied with any material provisions under this Agreement or the Partnership Agreement, or (b) any financing commitment of any lender of the Partnership, or any agreement entered into by the Partnership for financing related to the Apartment Complex, shall have terminated prior to their respective termination date(s), or (c) foreclosure proceedings shall have been commenced against the Apartment Complex, then (i) the Developer shall be in default under this Agreement and the General Partner shall be in default under the Partnership Agreement, and the Partnership shall withhold payment of any installment of the Development Fee payable pursuant to Section 4 of this Agreement and Section 8.10 of the Partnership Agreement, and (ii) the General Partner shall be liable for the Partnership's payment of any and all installments of the Development Fee payable pursuant to Section 4 of this Agreement and Section 8.10 of the Partnership Agreement, to the extent that the Fund has withheld any Installment(s) pursuant to Section 5.03 of the Partnership Agreement as a result of any default as described above. All amounts so withheld by the Partnership under this Section 5 or Section 8.12 of the Partnership Agreement shall be promptly released only after the Developer and/or the General Partner has cured the default justifying the withholding, as demonstrated by evidence reasonably acceptable to the Special Limited Partner. 6. ASSIGNMENT OF FEES. The Developer shall not assign, pledge or otherwise encumber, for security or otherwise, the Development Fee set forth above to be made by the Partnership, or any portion(s) thereof or any of their right(s) thereto, without prior Notice to the Fund. 7. SUCCESSORS AND ASSIGNS, TERMINATION. This Agreement shall be binding on the parties hereto, their heirs, successors, and assigns. However, this Agreement may not be assigned by any party hereto without the Consent of the Special Limited Partner, nor may it be terminated without the Consent of the Special Limited Partner. In the event that (a) the Interests of the General Partner as General Partner is converted, transferred or reduced, pursuant to Section 6.03 of the Partnership Agreement, or (b) the General Partner or its successor(s) is removed from the Partnership pursuant to Section 8.13 of the Partnership Agreement, any further payment of installments of the Development Fee pursuant to Section 4 above shall be governed by such Sections 6.03 and 8.13, as applicable. 8. DEFINED TERMS. Capitalized terms used in this Agreement and not specifically defined herein shall have the same meanings assigned to them as in the Partnership Agreement. 9. SEPARABILITY OF PROVISIONS. Each provision of this Agreement shall be considered separable and if for any reason any provision which is not essential to the effectuation of the basic purposes of this Agreement is determined to be invalid and contrary to any existing or future law, such invalidity shall not impair the operation of or affect those provisions of this Agreement which are valid. 10. NO CONTINUING WAIVER. The waiver by any party of any breach of this Agreement shall not operate or be construed to be a waiver of any subsequent breach. 11. APPLICABLE LAW. This Agreement shall be construed and enforced in accordance with the laws of the state of Missouri. 12. NOTICES. Any notice required to be given to the parties under this Agreement shall be sent to the addresses set forth in the first paragraph hereof. IN WITNESS WHEREOF, the parties have caused this Development Agreement to be duly executed as of the date first written above. PARTNERSHIP: LOMBARD PARTNERS, L.P. CUNNINGHAM-WARREN PROPERTIES, L.L.C. as General Partner BY: /s/ Hollis O. Cunningham Hollis O. Cunningham, Manager DEVELOPER: CUNNINGHAM-WARREN PROPERTIES, L.L.C. BY:/s/ Hollis O. Cunningham Hollis O. Cunningham, Manager EX-10 5 LOMBARD HEIGHTS APARTMENTS GUARANTY GUARANTY THIS GUARANTY is executed and delivered as of October 15, 1998, by Cunningham-Warren Properties, L.L.C., a Kansas limited liability company, having an address at 11915 Windsor, Leawood, Kansas 66209 ("C.W. Properties"), G. Windsor Warren, individually, ("G.W. Warren"), Hollis O. Cunningham, individually, ("H. Cunningham"), G. Windsor Warren, as trustee u/d/t dated July 19, 1991 as such Trust may be amended from time to time (the "Trust"), (each jointly and severally and each of C.W. Properties, G.W. Warren, H. Cunningham and the Trust being hereinafter referred to collectively as, the "Guarantor") in favor of Lombard Partners, L.P., a Missouri limited partnership having an address at 420 South Avenue, Springfield, Missouri 65806 (the "Partnership"). WITNESSETH THAT: WHEREAS, concurrently with the execution of this Guaranty, Cunningham-Warren Properties, L.L.C., a State of Missouri limited liability company, and (the "General Partner") and BCTC 94, Inc., a Massachusetts corporation (the "Special Limited Partner") and Boston Capital Tax Credit Fund IV, L.P. a Massachusetts limited partnership (the "Investment Partnership"), have entered into that certain Lombard Partners, L.P. Amended and Restated Agreement of Limited Partnership of the Partnership (the "Agreement") pursuant to which the General Partner has agreed, inter alia, (i) to make certain Excess Development Cost advances and Operating Deficit Loans, (ii) to repurchase the Investment Partnership's Interest in certain circumstances, (iii) to guaranty payment of the Asset Management Fee and the Development Fee and (iv) to repay certain Credit Recovery Loans (as such terms are defined in the Agreement) and the Investment Partnership has agreed to contribute capital to the Partnership according to the terms and conditions set forth therein, a true copy of which is attached hereto as Exhibit A, by this reference fully incorporated herein; and WHEREAS, the Guarantor acknowledges that the Investment Partnership, as a condition precedent to the making of said capital contributions, has required the execution of this Guaranty by the Guarantor and that the Investment Partnership is relying upon same in making said capital contributions; and WHEREAS, the Guarantor deems it to be in the Guarantor's financial advantage and benefit to execute this Guaranty in light of the Guarantor's financial interests in the Partnership. NOW, THEREFORE, in consideration of the foregoing and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the Guarantor agrees as follows: 1. The Guarantor hereby jointly and severally, absolutely and unconditionally, guaranties, irrespective of the validity or enforceability of the Agreement or security therefor, the due and punctual performance of the General Partner's obligations, including, without limitation, the General Partner's obligations (i) to make certain Excess Development Cost advances and Operating Deficit Loans in an amount of not greater than $250,000 during the five year period following Rental Achievement, all as set forth in Section 8.09(b) of the Agreement, (ii) to repurchase the Investment Partnership's Interest in certain circumstances, (iii) to guaranty payment of the Asset Management Fee and the Development Fee and (iv) to repay certain Credit Recovery Loans (as such terms are defined in the Agreement); all of such guaranteed obligations being hereinafter sometimes referred to as the "Obligations". 2. Except to the extent prohibited by law, the Guarantor expressly waives the following: presentment and demand for payment or performance of any of the Obligations or this Guaranty, notice of default or nonpayment of the Obligations under the Agreement or hereunder, and any other notice or demand required by law and lawfully waivable by Guarantor and not otherwise explicitly required hereunder; any defenses otherwise available to a surety or guarantor; any right to require suit against the General Partner or any other party before enforcing this Guaranty; and any right of subrogation to the Partnership's rights against the General Partner until the Obligations are paid or performed in full. 3. The Guarantor hereby consents and agrees that renewals and extensions of time of payment, surrender, release, exchange, substitution, dealing with or taking of additional collateral security, making advances to perform Obligations then in default, taking or release of other guarantees, abstaining from taking guarantees, waivers of any defaults, rights or remedies and any and all other forbearances or indulgences granted to the General Partner or any other party may be made, granted and/or effected without notice to the Guarantor and without in any manner affecting any of the Guarantor's liability hereunder. 4. The Guarantor agrees that the Guarantor shall remain bound under this Guaranty and that the Guarantor's obligations hereunder shall not be discharged, modified or in any way limited by the recovery of any judgment against the General Partner or any other Guarantor or obligor for the Obligations, any action to enforce the same or any other circumstance which might otherwise constitute a legal or equitable discharge or defense of the Guarantor except for final payment and performance in full of all of the Obligations in accordance with their respective terms and in accordance with this Guaranty. The Guarantor further agrees that the invalidity, irregularity or unenforceability of all or any part of the Obligations or any security therefor shall not affect, impair or be a defense to this Guaranty or discharge, modify or in any way limit the liability of the Guarantor hereunder. No modification, release, limitation or rendering void of the liabilities of the General Partner or of any other guarantor(s) of Obligations which occurs in or as a result of the operation of any existing or future federal or state laws affecting the rights of creditors, including without limitation the Federal Bankruptcy Code, shall discharge, modify or in any way limit the Guarantor's liability hereunder. If at any time all or any part of any previous payment applied to any of the Obligations must be returned by the recipient for any reason, whether as a result of a court order, administrative order, settlement or otherwise, the Guarantor is and shall remain jointly and severally liable hereunder for the full amount returned as if such amount had never been received by the recipient, notwithstanding any termination of this Guaranty or the cancellation of any of the Agreement or any other instrument or other agreement evidencing any or all of the Obligations. 5. In the event that the Partnership or the Investment Partnership (or any partner of the Investment Partnership) becomes liable under any statute, regulation, ordinance or other provision of federal, state or local law pertaining to the protection of the environment or otherwise pertaining to public health or employee health and safety, including, without limitation, protection from hazardous waste, lead-based paint, asbestos, methane gas, urea formaldehyde insulation, oil, toxic substance, underground storage tanks, polychlorinated biphenyls (PCBs), and radon, the Guarantor shall jointly and severally indemnify and hold harmless the Partnership and the Investment Partnership (and any partner of the Investment Partnership) for any and all costs, expenses (including reasonable attorneys' fees), damages or liabilities to the extent that the Partnership or the Investment Partnership (or any partner of the Investment Partnership is required to discharge such costs, expenses, damages or liabilities in whole or in part from any source. The foregoing indemnification shall be a recourse obligation of the Guarantor and shall survive the dissolution of the Partnership and/or the insolvency or bankruptcy of the Guarantor. 6. The Partnership and the Guarantor agree that so long as the Obligations hereunder remain outstanding, the Investment Partnership shall be a third party beneficiary under this Agreement and shall be entitled to enforce the provisions hereof as if it were a party hereto. The Guarantor hereby irrevocably authorizes and empowers the Investment Partnership, and irrevocably appoint the Investment Partnership, the Guarantor's attorney-in-fact, to demand, sue for, collect and receive every payment or advance due under the obligations and give security therefor and to file and invoke claims and such other proceedings in their names as the Investment Partnership may deem necessary or advisable to enforce the obligations under this Guaranty. 7. Any notice to the Guarantor by the Partnership or the Investment Partnership at any time shall not imply that such notice or any further or similar notice was or is required. Any notice, demand, request or other communication given hereunder or in connection herewith (the "Notices") shall be deemed sufficient if in writing including telegraphic, telexed or telecopied communication, mailed, telegraphed, telexed or telecopied to the party to receive such Notice at such party's address first set forth above or at such other address as such party may hereafter designate by Notice given in like fashion. Notices shall be deemed given when received. 8. The Guarantor further jointly and severally agrees to pay and/or reimburse the Partnership and Investment Partnership for any and all costs, expenses and reasonable attorneys' fees paid or incurred by the Partnership or the Investment Partnership in enforcing or collecting or endeavoring to enforce or collect the Obligations or in enforcing or endeavoring to enforce this Guaranty, to the extent that the Partnership and/or the Investment Partnership prevails in any such enforcement or collection. 9. The Guarantor agrees that any and all existing or future indebtedness, liability or obligations of the General Partner to the Guarantor are and shall be fully subordinated to the Obligations until payment and/or performance of the Obligations in full so that during the continuance of any Event of Default under the Agreement with respect to the Obligations the Guarantor shall not be entitled to receive any amount due on any such indebtedness, liability or obligation of the General Partner to the Guarantor and in any event the Guarantor shall not accelerate same or exercise any remedies thereunder unless the Partnership or the Investment Partnership do so. 10. The Guarantor further covenants and agrees that during such time as this Guaranty is in effect, the Guarantor will not make or permit any substantial diminution in the Guarantor's net worth (except as a result of guarantees and other transactions in the ordinary course of the Guarantor's business) without having first obtained the Investment Partnership's written consent therefor. 11. The Guarantor consents and agrees to, and ratifies and confirms, all terms, covenants, promises, agreements or other provisions of the Agreement which expressly apply to the Guarantor. 12. All rights and remedies afforded to the Partnership and the Investment Partnership by reason of this Guaranty, the Agreement, or by law are separate and cumulative and the exercise of one shall not in any way limit or prejudice the exercise of any other such rights or remedies. No delay or omission by the Partnership or the Investment Partnership in exercising any such right or remedy shall operate as a waiver thereof. No waiver of any rights or remedies hereunder, and no modification or amendment hereof, shall be deemed made by the Partnership or the Investment Partnership unless in writing and duly signed by the Partnership or the Investment Partnership. Any such written waiver shall apply only to the particular instance specified therein and shall not impair the further exercise of such right or remedy or of any other right or remedy by the Partnership or the Investment Partnership, and no single or partial exercise of any right or remedy hereunder shall preclude any other or further exercise thereof or of any other right or remedy. 13. The Guarantor irrevocably: (i) agrees that any suit, action, or other legal proceeding arising out of this Guaranty may be brought in the courts of record of the State of Missouri or the courts of the United States located in the State of Missouri; and (ii) consents to the jurisdiction of each such court in any such suit, action or proceeding; and (iii) waives any objection which either may have to the laying of venue of such suit, action or proceeding in any such courts and waive any right to a trial by jury in any of such courts. 14. This Guaranty shall operate as a continuing, joint and several Guaranty of the Obligations, and shall be binding upon the Guarantor and the Guarantor's successors and assigns and shall inure to the benefit of the Partnership and the Investment Partnership and its successors and assigns. This Guaranty shall be governed by and construed in accordance with the laws of the State of Missouri. 15. The provisions of this Guaranty are severable. Any provision of this Guaranty which is prohibited or unenforceable will be ineffective to the extent of such prohibition or unenforceability without invalidating or modifying the remaining provisions of this Guaranty. Any such prohibited or unenforceable provision will be reformed to the extent necessary to make it enforceable in a manner carrying out the intention of the parties as nearly as is possible. 16. Capitalized terms used but not defined herein shall have the meanings ascribed to such terms in the Agreement. IN WITNESS WHEREOF, the Guarantor has caused this Guaranty to be duly executed under seal as of the date first written above. WITNESS: _______________________________ GUARANTOR: Cunningham-Warren Properties. L.L.C. By: /s/ Hollis O. Cunningham Hollis O. Cunningham, Manager _______________________________ By: /s/ G. Windsor Warren G. Windsor Warren _______________________________ /s/ Hollis O. Cunningham Hollis O. Cunningham _______________________________ Windsor Warren Trust u/d/t dated July 19, 1991 /s/ G. Windsor Warren G. Windsor Warren, as Trustee EXHIBIT A [Attach copy of [NAME OF PARTNERSHIP AGREEMENT]] EX-10 6 LOMBARD HEIGHTS APARTMENTS PARTNERSHIP MANAGEMENT SERVICES AGREEMENT PARTNERSHIP MANAGEMENT SERVICES AGREEMENT THIS PARTNERSHIP MANAGEMENT SERVICES AGREEMENT is between Lombard Partners, L.P., a Missouri limited partnership (the "Partnership"), and Cunningham-Warren Properties, L.L.C., a Kansas limited liability company (the "General Partner") and BCTC 94, Inc., a Massachusetts corporation (the "Special Limited Partner"). WHEREAS, the General Partner, the Special Limited Partner, and Boston Capital Tax Credit Fund IV, L.P., a Massachusetts limited partnership (the "Investment Partnership") executed the Lombard Partners, L.P. Amended and Restated Agreement of Limited Partnership as of October 15, 1998 to, among other things, (i) continue the Partnership; (ii) provide for the admission of the Fund to the Partnership as a Limited Partner and the admission of the Special Limited Partner to the Partnership as the Special Limited Partner; (iii) reassign Partnership Interests; (iv) provide for the withdrawal of the certain Limited Partners; and (v) set forth all of the provisions governing the Partnership; and WHEREAS, the Partnership has been formed to acquire, own, rehabilitate, maintain and operate a 24-unit multi-family rental housing development intended for rental to individuals of low and moderate income, known as Lombard Heights Apartments and located in Springfield, Missouri (the "Apartment Complex"); and WHEREAS, the Partnership desires that the General Partner provide certain management services with respect to the business of the Partnership for the period commencing as of the date hereof and continuing throughout the term of the Partnership; and WHEREAS, the Partnership and the Special Limited Partnership wish to appoint a management agent to manage the Apartment Complex on behalf of the Partnership. NOW, THEREFORE, in consideration of the foregoing, of the mutual promises of the parties hereto, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties agree as follows: 1. APPOINTMENTS. The Partnership hereby appoints the General Partner to render certain services on behalf of the Partnership during the term of the Partnership as herein contemplated and the Special limited Partner hereby consents to the appointment of Cunningham Management Company, as management agent (the "Management Agent") for the Apartment Complex with such management rights of the Management Agent being subject to (i) the terms of the Management Agreement, dated October ___, 1998 by and between the Partnership and the Management agent (the "Management Agreement"), (ii) the provisions of the Partnership Agreement (including, but not limited to, Sections 8.05, 8.11, 8.14, 8.15, 8.16 and 11.03 thereof) and, (iii) the terms of this Agreement. 2. AUTHORITY. In conformity with the provisions of the Partnership Agreement, throughout the term of the Partnership, the General Partner shall have the authority and the obligation to: (a) administer, manage and direct the business of the Partnership, and take such further action as it may deem necessary or desirable to further the interests of the Partnership; (b) monitor the day-to-day operations of the Apartment Complex and make recommendations with respect thereto; (c) investigate and make recommendations with respect to the selection and conduct of relations with consultants and technical advisors (including, without limitation, accountants and other similar advisors, attorneys, corporate fiduciaries, escrow agents, depositories, custodians, agents for collection, insurers, insurance agents and banks) and persons acting in any other capacity, in connection with the Partnership; (d) maintain appropriate books and records of the Partnership in accordance with sound federal income tax accounting principles, including information relating to the sale by the General Partner or any Affiliate of goods or services to the Partnership; (e) be responsible for the safekeeping and use of all funds and assets of the Partnership, including the maintenance of bank accounts; (f) prepare and provide, or cause to be prepared and provided, all reports, tax returns, financial statements and other information, in the form and at the times provided for in Section 13.04 of the Partnership Agreement; (g) as and to the extent provided in Section 13.04 of the Partnership Agreement, furnish or cause to be furnished to the Partners copies of any and all financial reports that may be requested by any party(ies) to any of the Project Documents or any governmental agencies having jurisdiction; (h) furnish or cause to be furnished to the Fund all such information as the Fund may reasonably request from time to time with respect to the financial and physical conditions of the Apartment Complex and the financial and administrative affairs of the Partnership; and (i) provide office space, support staff and administrative services as required by the Partnership. 3. FEES. For services to be performed under this Agreement, the Partnership shall pay to the General Partner, solely from the Cash Flow of the Partnership available for distribution and in accordance with Section 11.03A of the Partnership Agreement, an annual Incentive Partnership Management Fee. Such fee shall be in accordance with the provisions of the Project Documents, and shall be in an amount equal to $1,800 per year commencing in 1999, if available, out of Cash Flow in accordance with Section 11.03A of the Partnership Agreement. 4. WITHHOLDING OF FEE PAYMENTS. In the event that (a) the General Partner or any successor General Partner shall not have substantially complied with any material provisions under this Agreement or the Partnership Agreement, or (b) any financing commitment of any lender of the Partnership, or any agreement entered into by the Partnership for financing related to the Apartment Complex, shall have terminated prior to their respective termination date(s), or (c) foreclosure proceedings shall have been commenced against the Apartment Complex, then (i) the General Partner shall be in default under this Agreement and the Partnership Agreement, and the Partnership shall withhold payment of any installment of the Incentive Partnership Management Fee payable pursuant to Section 3 of this Agreement and Section 8.11 of the Partnership Agreement. All amounts so withheld by the Partnership under this Section 4 or Section 8.12 of the Partnership Agreement shall be promptly released only after the General Partner has cured the default justifying the withholding, as demonstrated by evidence reasonably acceptable to the Special Limited Partner. 5. ASSIGNMENT OF FEES. The General Partner shall not assign, pledge or otherwise encumber, for security or otherwise, the payments of the Incentive Partnership Management Fee set forth above to be made by the Partnership, or any portion(s) thereof or any of its respective right(s) thereto, without prior written notice and the written consent of the Special Limited Partner. 6. SUCCESSORS AND ASSIGNS; TERMINATION. This Agreement shall be binding on the parties hereto, their heirs, successors and assigns. However, this Agreement may not be assigned by any party without the consent of the Special Limited Partner, nor may it be terminated without the consent of the Special Limited Partner. In the event that (a) the Interest of a General Partner as General Partner is converted, transferred or reduced pursuant to Section 6.03 of the Partnership Agreement, or (b) the General Partner or its successor(s) is removed from the Partnership pursuant to Section 8.13 of the Partnership Agreement, any further payment of fees from the Partnership pursuant to Section 3 above shall be governed by such Sections 6.03 and 8.13, as appropriate. 7. DEFINED TERMS. Capitalized terms used in this Agreement and not specifically defined herein shall have the same meanings assigned to them as in the Partnership Agreement. 8. SEPARABILITY OF PROVISIONS. Each provision of this Agreement shall be considered separable and if for any reason any provision which is not essential to the effectuation of the basic purposes of this Agreement is determined to be invalid and contrary to any existing or future law, such invalidity shall not impair the operation of or affect those provisions of this Agreement which are valid. 9. NO CONTINUING WAIVER. The waiver by any party of any breach of this Agreement shall not operate or be construed to be a waiver of any subsequent breach. 10. APPLICABLE LAW. This Agreement shall be construed and enforced in accordance with the laws of the State of Missouri. IN WITNESS WHEREOF, the parties have caused this Partnership Management Services Agreement to be duly executed as of October ___, 1998. GENERAL PARTNER: LOMBARD PARTNERS, L.P. Cunningham-Warren Properties, L.L.C. ____________________ By: /s/ Hollis O. Cunningham Witness Hollis O. Cunningham, Manager INVESTMENT PARTNERSHIP: BOSTON CAPITAL TAX CREDIT FUND IV, L.P. By: Boston Capital Associates IV, L.P., its General Partner By: C & M Associates d/b/a Boston Capital Associates, its General Partner ____________________________ By: /s/ Bonnie Kate Fox Witness Bonnie Kate Fox, Attorney in fact for John P. Manning, General Partner SPECIAL LIMITED PARTNER: BCTC 94, Inc. ____________________________ By:_________________________ Witness Bonnie Kate Fox, Attorney in fact for John P. Manning, President -----END PRIVACY-ENHANCED MESSAGE-----