10-K 1 f04753e10vk.htm FORM 10-K e10vk
Table of Contents



LOGO

UNITED STATES SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549


Form 10-K

     
þ
  ANNUAL REPORT UNDER SECTION 13 OR 15(d) OF THE SECURITIES AND EXCHANGE ACT OF 1934
 
    For the fiscal year ended December 31, 2004
or
 
o
  TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
    For the transition period from           to

Commission file number 1-12911

Granite Construction Incorporated

(Exact name of registrant as specified in its charter)
     
Delaware   77-0239383
(State or other jurisdiction of
incorporation or organization)
  (I.R.S. Employer
Identification Number)
585 West Beach Street,
Watsonville, California
(Address of principal executive offices)
  95076
(Zip Code)

Registrant’s telephone number, including area code:

(831) 724-1011

Securities registered pursuant to Section 12(b) of the Act:

     
Title of each class Name of each exchange on which registered


Common Stock, $0.01 par value
  New York Stock Exchange

Securities registered pursuant to Section 12(g) of the Act:

None

      Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities and Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.     Yes     þ          No o

      Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K is not contained herein, and will not be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K.     o

      Indicate by check mark whether the registrant is an accelerated filer (as defined by Rule 12b-2 of the Act).     Yes     þ          No o.

      The aggregate market value of voting and non-voting common equity held by non-affiliates of the registrant was $606,589,271 as of June 30, 2004, based upon the average of the bid and asked prices per share of the registrant’s Common Stock as reported on the New York Stock Exchange on such date. Shares of Common Stock held by each executive officer and director and by each person who owns 5% or more of the outstanding Common Stock have been excluded in that such persons may be deemed to be affiliates. This determination of affiliate status is not necessarily a conclusive determination for other purposes.

      At February 18, 2005, 41,610,795 shares of Common Stock, par value $0.01, of the registrant were outstanding.

DOCUMENTS INCORPORATED BY REFERENCE

      Certain information called for by Part III is incorporated by reference to the definitive Proxy Statement for the Annual Meeting of Shareholders of Granite Construction Incorporated to be held on May 23, 2005, which will be filed with the Securities and Exchange Commission not later than 120 days after December 31, 2004.




TABLE OF CONTENTS

             
Page
No.

PART I
   BUSINESS     2  
   PROPERTIES     10  
   LEGAL PROCEEDINGS     11  
   SUBMISSION OF MATTERS TO A VOTE OF SECURITY HOLDERS     11  
 
PART II
   MARKET FOR REGISTRANT’S COMMON EQUITY, RELATED SHAREHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES     12  
   SELECTED CONSOLIDATED FINANCIAL DATA     14  
   MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATION     15  
   QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK     29  
   CONSOLIDATED FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA     30  
   CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURE     30  
   CONTROLS AND PROCEDURES     30  
   OTHER INFORMATION     31  
 
PART III
   DIRECTORS AND EXECUTIVE OFFICERS OF THE REGISTRANT     31  
   EXECUTIVE COMPENSATION     31  
   SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT     32  
   CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS     32  
   PRINCIPAL ACCOUNTANT FEES AND SERVICES     32  
 
PART IV
   EXHIBITS AND FINANCIAL STATEMENT SCHEDULES     32  
 EXHIBIT 23
 EXHIBIT 31.1
 EXHIBIT 31.2
 EXHIBIT 32

1


Table of Contents

FORWARD-LOOKING DISCLOSURE

      From time to time, Granite makes certain comments and disclosures in reports and statements, including in this Annual Report on Form 10-K (“Report”), or statements made by its officers or directors that are not based on historical facts and which may be forward-looking in nature. Under the Private Securities Litigation Reform Act of 1995, a “safe harbor” may be provided to us for certain of these forward-looking statements. We wish to caution readers that forward-looking statements are subject to risks regarding future events and the future results of Granite that are based on current expectations, estimates, forecasts, and projections as well as the beliefs and assumptions of Granite’s management. Words such as “outlook”, “believes”, “expects”, “appears”, “may”, “will”, “should”, “anticipates” or the negative thereof or comparable terminology, are intended to identify such forward-looking statements. In addition, other written or oral statements which constitute forward-looking statements have been made and may in the future be made by or on behalf of Granite. These forward-looking statements are estimates reflecting the best judgment of senior management that rely on a number of assumptions concerning future events, many of which are outside of our control, and involve a number of risks and uncertainties that could cause actual results to differ materially from those suggested by the forward-looking statements. Factors that might cause or contribute to such differences include, but are not limited to, those more specifically described in this Report under “Item 1. Business” under the heading “Risk Factors”. Granite undertakes no obligation to publicly revise or update any forward-looking statements for any reason. As a result, the reader is cautioned not to rely on these forward-looking statements, which speak only as of the date of this Annual Report on Form 10-K.

PART I

 
Item 1. Business

Introduction

      We were originally incorporated in 1922 as Granite Construction Company. In 1990, Granite Construction Incorporated was incorporated in Delaware as the holding company for Granite Construction Company and its wholly owned subsidiaries. Unless otherwise indicated, the terms “we,” “us,” “our,” “Company” and “Granite” refer to Granite Construction Incorporated and its consolidated subsidiaries.

      We are one of the largest heavy civil construction contractors in the United States. We operate nationwide, serving both public and private sector clients. Within the public sector, we primarily concentrate on infrastructure projects, including the construction of roads, highways, bridges, dams, tunnels, canals, mass transit facilities and airport runways. Within the private sector, we perform site preparation and infrastructure services for buildings, plants, subdivisions and other facilities. Our diversification in both the public and private sectors and our mix of project types and sizes have contributed to our revenue growth and profitability in various economic environments.

      We own and lease substantial aggregate reserves and own a number of construction materials processing plants. We also have one of the largest contractor-owned heavy construction equipment fleets in the United States. We believe that the ownership of these assets enables us to compete more effectively by ensuring availability of these resources at a favorable cost.

      We have determined that certain of the construction joint ventures in which we participate are variable interest entities as defined by Financial Accounting Standards Board Interpretation No. 46 (revised December 2003) “Consolidation of Variable Interest Entities” (“FIN 46”) (see Note 5 of the “Notes to the Consolidated Financial Statements”). Accordingly, we have consolidated those joint ventures where we have determined that we are the primary beneficiary on a prospective basis effective January 1, 2004. Included in our December 31, 2004 consolidated balance sheet are assets (primarily current assets) of $94.8 million and current liabilities of $84.1 million resulting from these consolidations. Included in our revenue for the year ended December 31, 2004, is $104.3 million and included in our backlog at December 31, 2004 was $280.5 million resulting from these consolidations. There was no material effect on our net income as a result of these consolidations.

Operating Structure

      We are organized into two operating segments, the Branch Division and the Heavy Construction Division (“HCD”). The Branch Division is comprised of branch offices that serve local markets, while HCD is composed of regional offices and pursues major infrastructure projects throughout the nation. HCD focuses on building larger heavy civil projects with contract durations that are generally greater than two years, while Branch Division projects are typically smaller in size and shorter in duration.

2


Table of Contents

      The two divisions complement each other in a variety of ways. HCD is a major user of construction equipment and has developed substantial expertise with large, complex projects. The branches draw on these resources, which are generally not available to smaller, local competitors. Conversely, the Branch Division offices have greater knowledge of local markets and provide HCD with valuable information regarding larger projects in their respective areas, as well as providing a source of aggregates. The two divisions sometimes jointly perform projects when a project in a particular region exceeds the local branch’s capabilities, such as the $390.4 million design/build Garden Grove Freeway State Route 22 Improvement project in central Orange County, California that was awarded in 2004 and the $170.7 million Reno ReTRAC project in Reno, Nevada that was awarded in 2002.

      As decentralized profit centers, the branches and HCD regional offices independently estimate, bid and complete contracts. Both divisions are supported by centralized functions, including finance, accounting, tax, human resources, labor relations, safety, legal, insurance, surety, corporate development and information technology. We believe that centralized support for decentralized profit centers results in a more market-responsive business with effective controls and reduced overhead.

      When determining whether to bid on a project, two key factors we consider are our ability to be competitive at acceptable profit margins and the availability of estimating and project building personnel. Other factors considered include: the customer; the geographic location; our competitive advantages and disadvantages relative to likely competitors for the project; our current and projected workload; and the likelihood of follow-up work. Both operating divisions use a proprietary computer-based project estimating system that reflects our significant accumulated experience. We believe that an exhaustive, detailed approach to a project’s estimate and bid is important in order to best identify the project’s risks and opportunities. Our estimates are comprehensive in nature, sometimes totaling hundreds of pages of analysis. Each project is broken down into items of work, for which separate labor, equipment and materials estimates are made and subcontractor quotes are solicited and analyzed. Once a project begins, the estimate provides us with a budget against which the actual project cost is regularly measured, enabling us to manage our projects more effectively.

      Information about our business segments is incorporated in Note 16 of the “Notes to the Consolidated Financial Statements.”

      Branch Division. In 2004, Branch Division contract revenue and sales of aggregate products was $1,287.6 million (60.3% of our total revenue), compared with $1,152.7 million (62.5% of our total revenue) in 2003. The Branch Division has both public and private sector clients. Public sector activities include both new construction and improvement of streets, roads, highways and bridges. For example, the branches widen and repave roads and modify and replace bridges. Major private sector contracts include site preparation for housing and commercial development, including excavation, grading and street paving, and installation of curbs, gutters, sidewalks and underground utilities.

      The Branch Division currently has eleven branch offices in the western United States with additional satellite operations. Our eight branch offices in California are located in Bakersfield, Fresno (Central Valley), Indio (Southern California), Sacramento (Northern California), San Jose (Bay Area), Santa Barbara, Stockton and Watsonville (Monterey Bay Area). Our branch offices outside of California are located in Arizona, Nevada and Utah. Additionally, the Branch Division operating results include our majority-owned Wilder Construction Company subsidiary (“Wilder”), which has locations in Alaska, Oregon and Washington. Each branch effectively operates as a local or regional construction company and our branch management is encouraged to participate actively in the local community. While individual branch revenues vary from year to year, in 2004 these revenues (including Wilder) ranged from $38.5 million to $196.1 million.

      As part of our strategy, our branches mine aggregates and operate plants that process aggregates into construction materials for internal use and for sale to others. These activities are integrated into the Branch Division construction business providing both a source of profits and a competitive advantage to our construction business. The amount of aggregate products produced in these branch operations that are used in our construction projects was approximately 44.0% during 2004 and has ranged from 43.0% to 56.0% over the last five years. The remainder is sold to unaffiliated parties and accounted for $264.4 million of revenue in 2004, representing 12.4% of our total revenue and 20.5% of Branch Division revenue, compared with $252.7 million, or 13.7% of our total revenue and 21.9% of Branch Division revenue in 2003, and $227.7 million, or 12.9% of our total revenue and 19.2% of Branch Division revenue in 2002. We have significant aggregate reserves that we have acquired by ownership in fee or through long-term leases.

      Heavy Construction Division. In 2004, revenue from HCD was $848.6 million (39.7% of our total revenue), compared with $691.8 million (37.5% of our total revenue) in 2003. Included in HCD revenue during 2004 is $104.3 million resulting from the consolidation of our partners’ share of construction joint venture revenue under

3


Table of Contents

FIN 46 (see Note 5 of the “Notes to the Consolidated Financial Statements”). Like the Branch Division, HCD builds infrastructure projects for both public and private sector clients. Its projects have included major highways, large dams, mass transit facilities, bridges, pipelines, canals, tunnels, waterway locks and dams, airport runways, contract mine stripping, reclamation and large site preparation. It also performs activities such as demolition, clearing, large-scale earthwork and grading, dewatering, drainage improvements, structural concrete, rail signalization, and concrete and asphalt paving. HCD projects are usually larger and more complex than those performed by the Branch Division. HCD has completed projects in over twenty-three states from coast to coast.

      HCD markets, estimates, bids and provides management oversight of its projects from our Watsonville, California headquarters and regional estimating offices in Bloomington, Minnesota; Davis, California; Lewisville, Texas; Mt. Vernon, New York and Tampa, Florida. Project staff located at job sites have the managerial, technical and clerical capacity to meet on-site project management requirements. HCD has the ability, if appropriate, to process locally sourced aggregates into construction materials using owned or rented portable crushing, concrete and asphalt processing plants.

      HCD participates in joint ventures with other large construction companies. Joint ventures are used for large, technically complex projects, including design/build projects, where it is desirable to share risk and resources. Joint venture partners typically provide independently prepared estimates and shared financing, equipment, local knowledge and expertise (see “Joint Ventures” in “Management’s Discussion and Analysis of Financial Condition and Results of Operation”).

      Design/build projects have become a significant market opportunity for HCD. Unlike traditional projects where owners first hire a design firm and then put the project out to bid for construction, design/build projects provide the owner with a single point of responsibility and a single contact for both design and construction. HCD’s revenue from design/build projects has generally grown over the last ten years and represented 37.4% of HCD revenue (16.0% of total company revenue) in 2004. Although these projects carry additional risk as compared to traditional bid/build projects, the profit opportunities can also be higher. We frequently bid design/build projects as a part of a joint venture team.

Business Strategy

      Our fundamental objective is to increase long-term shareholder value by focusing on consistent profitability from controlled revenue growth. Shareholder value is measured by the appreciation of the value of our common stock over a period of years as well as a return from dividends. Further, it is a specific measure of our financial success to achieve a return on net assets greater than the cost of capital, creating “Granite Value Added”. To accomplish these objectives, we employ the following strategies:

      Infrastructure Construction Focus — We concentrate our core competencies on this segment of the construction industry, which includes the building of roads, highways, bridges, dams and tunnels, mass transit facilities, railroad infrastructure and underground utilities as well as site preparation. This focus incorporates our specialized strengths, which include grading, paving and concrete structures.

      Employee Development — We believe that our employees are key to the successful implementation of our business strategies. Significant resources are employed to attract, nurture and retain extraordinary talent and fully develop each employee’s capabilities.

      Ownership of Aggregate Materials and Construction Equipment — We own and lease aggregate reserves and own processing plants that are vertically integrated into our construction operations and we own a large fleet of carefully maintained heavy construction equipment. By ensuring availability of these resources at favorable cost, we believe we have bidding advantages in many of our markets.

      Selective Bidding — We focus our resources to bid on jobs that meet our selective bidding criteria, which includes analyzing the risk of a potential job in relation to available manpower to estimate and prepare the proposal, degree of competition, experience with the type of work, relationship with the owner, local resources and partnerships, equipment resources, and size and complexity of the job.

      Diversification — To mitigate the risks inherent in construction and general economic factors, we pursue projects: (i) in both the public and private sectors; (ii) for a wide range of customers within each sector (from the federal government to small municipalities and from large corporations to individual homeowners); (iii) in diverse geographic markets; and (iv) of various sizes, durations and complexities.

      Decentralized Profit Centers — We approach each selected market with a local focus through our decentralized structure. Each of our branches and each HCD regional estimating office is an individual profit center.

4


Table of Contents

      Profit-based Incentives — We compensate our profit center managers with lower-than-market fixed salaries coupled with a substantial variable cash and restricted stock incentive element based on the annual profit performance of their respective profit centers.

      Controlled Expansion — We intend to continue our expansion by selectively adding branches or branch satellite locations in the western United States, exploring opportunities to establish branch-like businesses in other areas of the country, pursuing major infrastructure projects throughout the nation and expanding into other construction related market segments through acquisitions. Additionally, we intend to leverage our financial capacity by investing in development projects that provide an acceptable return on our investment.

      Accident Prevention — We believe that the prevention of accidents is both a moral obligation and good business. By identifying and concentrating resources to address jobsite hazards, we continually strive to reduce our incident rates and the costs associated with accidents.

      Environmental Responsibility — We believe it benefits everyone to maintain environmentally responsible operations. We are committed to effective air quality control measures and reclamation at our plant sites and to waste reduction and recycling of the potentially environmentally sensitive products used in our operations.

      Quality and High Ethical Standards — We emphasize the importance of performing high quality work and maintaining high ethical standards through an established code of conduct and an effective corporate compliance program.

Customers

      We have customers in both the public and private sectors. The Branch Division’s largest volume customer is the California Department of Transportation (“Caltrans”). In 2004, contracts with Caltrans represented 6.3% of our revenue and total public sector revenue generated in California represented 19.8% of our revenue. Other Branch Division customers include other state departments of transportation, county and city public works departments, school districts and developers and owners of industrial, commercial and residential sites. HCD’s customers are predominantly in the public sector and currently include the state departments of transportation in a number of states as well as local transit authorities and federal agencies (see Note 1 of the “Notes to the Consolidated Financial Statements”).

Backlog

      Our backlog includes the total value of awarded contracts that have not been completed, including our proportionate share of unconsolidated joint venture contracts. Our backlog was $2.4 billion at December 31, 2004, up from $2.0 billion at December 31, 2003. Approximately $920.0 million of the December 31, 2004 backlog is expected to remain at December 31, 2005. With the exception of certain federal government contracts, we include a construction project in our backlog at such time as a contract is awarded and funding is in place. Certain federal government contracts that extend beyond one year are funded on a year-by-year basis. Included in our backlog at December 31, 2004 is approximately $35.0 million , for which federal government funding has not yet been fully appropriated. Substantially all of the contracts in our backlog may be canceled or modified at the election of the customer, however, we have not been materially adversely affected by contract cancellations or modifications in the past (see “Contract Provisions and Subcontracting”). A sizeable percentage of our anticipated contract revenue in any year is not reflected in our backlog at the start of the year due to the short duration of smaller Branch Division projects that are initiated and completed during each year (“turn business”). Backlog by segment is presented in “Backlog” under “Management’s Discussion and Analysis of Financial Condition and Results of Operation”.

Equipment and Plants

      We purchase and maintain many pieces of equipment, including cranes, bulldozers, barges, backhoes, excavators, scrapers, motor graders, loaders, trucks, pavers and rollers as well as construction materials processing plants. In 2004 and 2003, we spent approximately $46.6 million and $53.7 million, respectively, for construction

5


Table of Contents

equipment, plants and vehicles. At December 31, 2004, we maintained the following construction equipment, plants and vehicles:
         
Heavy construction equipment
    2,364  units  
Trucks, truck-tractors and trailers and vehicles
    4,908  units  
Aggregate crushing plants
    49 plants  
Asphalt concrete plants
    57 plants  
Portland cement concrete batch plants
    26 plants  
Asphalt rubber plants
    4 plants  
Lime slurry plants
    11 plants  

      We believe that ownership of equipment is generally preferable to leasing because ownership ensures the equipment is available as needed and normally results in lower equipment costs. We attempt to keep our equipment as fully utilized as possible by pooling equipment for use by both the Branch Division and HCD. We regularly lease or rent equipment on a short-term basis to supplement existing equipment and respond to construction activity peaks.

Employees

      On December 31, 2004, we employed 1,851 salaried employees, who work in management, estimating and clerical capacities, and 3,178 hourly employees. The total number of hourly personnel employed by us is subject to the volume of construction in progress. During 2004, the number of hourly employees ranged from 2,684 to 6,112 and averaged approximately 4,700. Our wholly owned subsidiaries, Granite Construction Company and Granite Halmar Construction Company, Inc. and our majority-owned subsidiary, Wilder Construction Company are parties to craft collective bargaining agreements in many areas in which they work.

      We believe our employees are our most valuable resource and that our workforce possesses a strong dedication to and pride in our company. Among salaried and non-union hourly employees, this dedication is reinforced by 23.5% equity ownership through our Employee Stock Ownership Plan, our Profit Sharing and 401k Plan and performance-based incentive compensation arrangements at December 31, 2004. Our managerial and supervisory personnel have an average of approximately eleven years of service with us.

Competition

      Factors influencing our competitiveness include: price; reputation for quality; the availability of aggregate materials; machinery and equipment; financial strength; knowledge of local markets and conditions; and project management and estimating abilities. Although some of our competitors are larger than us and may possess greater resources, we believe that we compete favorably on the basis of the foregoing factors. Historically the construction business has not usually required large amounts of capital, particularly for the smaller size of construction work pursued by our Branch Division, which can result in relative ease of market entry for companies possessing acceptable qualifications. Branch Division competitors range from small local construction companies to large regional and national construction companies. While the market areas of these competitors overlap with several of the markets served by our branches, few, if any, compete in all of our market areas. In addition, most of our branches own and/or have long-term leases on aggregate resources that provide an extra measure of competitive advantage in certain markets. HCD normally competes with large regional and national construction companies, which may or may not be larger than Granite. Although the construction business is highly competitive, we believe we are well positioned to compete effectively in the markets in which we operate.

Contract Provisions and Subcontracting

      The majority of contracts with our customers are either “fixed unit price” or “fixed price.” Under fixed unit price contracts, we are committed to provide materials or services required by a project at fixed unit prices (for example, dollars per cubic yard of concrete poured or cubic yard of earth excavated). While the fixed unit price contract shifts the risk of estimating the quantity of units required for a particular project to the customer, any increase in our unit cost over the expected unit cost in the bid, whether due to inflation, inefficiency, faulty estimates or other factors, is borne by us unless otherwise provided in the contract. Fixed price contracts are priced on a lump-sum basis under which we bear the risk that we may not be able to perform all the work profitably for the specified amount. The percentage of fixed price contracts in our backlog has increased from approximately 51.0% at December 31, 2003 to approximately 58.0% at December 31, 2004. Our contracts are generally obtained through competitive bidding in response to advertisements by federal, state and local government agencies and private

6


Table of Contents

parties. Less frequently, contracts may be obtained through direct negotiations with private owners. Our contract risk mitigation process includes review of bids fitting certain criteria by various levels of management and, in some cases, by the executive committee of our Board of Directors.

      There are a number of factors that can create variability in contract performance and results as compared to a project’s original bid. The most significant of these include the completeness and accuracy of the original bid, recognition of costs associated with added scope changes, extended overhead due to owner and weather delays, subcontractor performance issues, changes in productivity expectations, site conditions that differ from those assumed in the original bid (to the extent contract remedies are unavailable), the availability and skill level of workers in the geographic location of the project and a change in the availability and proximity of materials. All of these factors can impose inefficiencies on contract performance, which can drive up costs and lower profits. Conversely, if any of these or other factors are more positive than the assumptions in our bid, project profitability can improve. Design/ build projects carry other risks such as the risk inherent in estimating quantities before the project design is completed and design error risk, including both additional construction costs due to any design errors and liability to the contract owner for the design of the project. Although we manage this additional risk by adding contingencies to our bid amounts, obtaining errors and omissions insurance and obtaining indemnifications from our design consultants where possible, there is no guarantee that these risk management strategies will always be successful.

      All state and federal government contracts and most of our other contracts provide for termination of the contract for the convenience of the contract owner, with provisions to pay us for work performed through the date of termination. We have not been materially adversely affected by these provisions in the past.

      Many of our contracts contain provisions that require us to pay liquidated damages if specified completion schedule requirements are not met. Although we had not been significantly impacted by these provisions historically, during 2004 we were required to pay approximately $9.0 million in liquidated damages on two projects. Although we are disputing the validity of these liquidated damages, there is no guarantee that we will be successful in recovering the amounts paid.

      We act as prime contractor on most of the construction projects we undertake. We accomplish the majority of our projects with our own resources and subcontract specialized activities such as electrical and mechanical work. As prime contractor, we are responsible for the performance of the entire contract, including subcontract work. Thus, we are subject to increased costs associated with the failure of one or more subcontractors to perform as anticipated. We manage this risk by reviewing the size of the subcontract, the financial stability of the subcontractor and other factors and, based on this review, determine whether to require that the subcontractor furnish a bond or other type of security that guarantees their performance. Disadvantaged business enterprise regulations require us to use our best efforts to subcontract a specified portion of contract work done for governmental agencies to certain types of subcontractors. Some of these subcontractors or other subcontractors may not be able to obtain surety bonds. Prior to 2004 we had not experienced significant costs associated with subcontractor performance issues. However in 2004 we experienced significant additional costs related to subcontractor non-performance on one large project (see “Gross Profit” in “Management’s Discussion and Analysis of Financial Condition and Results of Operation”).

Insurance and Bonding

      We maintain general and excess liability, construction equipment and workers’ compensation insurance; all in amounts consistent with industry practices.

      In connection with our business, we generally are required to provide various types of surety bonds that provide an additional measure of security for our performance under certain public and private sector contracts. Our ability to obtain surety bonds depends upon our capitalization, working capital, past performance, management expertise and external factors, including the capacity of the overall surety market. Surety companies consider such factors in light of the amount of our backlog that we have currently bonded and their current underwriting standards, which may change from time to time. In the last few years we have seen a steady decrease in the capacity of the surety market, driven primarily by substantial increases in surety industry losses and consolidation in the surety market through acquisition. This shrinking capacity has resulted in higher premiums and increased difficulty obtaining bonding, in particular for larger more complex projects throughout the market. In order to help mitigate these factors, in the last few years we have gone from working with a single surety to a co-surety structure involving three sureties. Our majority owned subsidiary, Wilder Construction Company, continues to work with a single surety and obtains surety bonds on a stand alone basis. Although we do not believe that this shrinking surety market capacity

7


Table of Contents

has significantly impacted our ability to grow our business, there is no assurance that it will not significantly impact our ability to obtain new contracts in the future (see “Risk Factors”).

Government and Environmental Regulations

      Our operations are subject to compliance with regulatory requirements of federal, state and local agencies and authorities, including regulations concerning workplace safety, labor relations and disadvantaged businesses. Additionally, all of our operations are subject to various federal, state and local laws and regulations relating to the environment, including those relating to discharges to air, water and land, the handling and disposal of solid and hazardous waste, the handling of underground storage tanks and the cleanup of properties affected by hazardous substances. Certain environmental laws impose substantial penalties for non-compliance and others, such as the federal Comprehensive Environmental Response, Compensation and Liability Act, impose strict, retroactive, joint and several liability upon persons responsible for releases of hazardous substances. We continually evaluate whether we must take additional steps at our locations to ensure compliance with environmental laws. While compliance with applicable regulatory requirements has not materially adversely affected our operations in the past, there can be no assurance that these requirements will not change and that compliance will not adversely affect our operations in the future. In addition, our aggregate materials operations require operating permits granted by governmental agencies. We believe that tighter regulations for the protection of the environment and other factors will make it increasingly difficult to obtain new permits and renewal of existing permits may be subject to more restrictive conditions than currently exist.

      As is the case with other companies in the same industry, some of our aggregate products contain varying amounts of crystalline silica, a common mineral. Also, some of our construction and material processing operations release as dust crystalline silica that is in the materials being handled. Excessive, prolonged inhalation of very small-sized particles of crystalline silica has been associated with respiratory disease (including silicosis). The Mine Safety and Health Administration and the Occupational Safety and Health Administration have established occupational thresholds for crystalline silica exposure as respirable dust. We monitor to verify that our dust control procedures are keeping occupational exposures at or below the requisite thresholds and to verify that respiratory protective equipment is made available when required. We also communicate, through safety information sheets and other means, what we believe to be appropriate warnings and cautions to employees and customers about the risks associated with excessive, prolonged inhalation of mineral dust in general and crystalline silica in particular.

      In December 2004, the Superior Court for Alameda County approved the Consent Judgments containing the final terms of the settlement reached in the California Safe Drinking Water and Toxic Enforcement Act (“Prop 65”) action brought by two private citizens groups and the California Attorney General’s Prop 65 asphalt-related action. Settling defendants, which include Granite, are companies involved in the manufacture, sale, distribution, transportation, application, storage, use and/or recycling of asphalt related product for use in paving operations. We, along with other settling defendants entered into these Consent Judgments pursuant to a settlement of certain disputed claims alleged by the private citizens and the California Attorney General while denying any fact or violation of applicable laws, including, but not limited to violations of Prop 65. The amount of the settlement was not material to our financial position, results of operations or cash flows.

Risk Factors

      Set forth below and elsewhere in this Report and in other documents we file with the SEC are various risks and uncertainties that could cause our actual results to differ materially from the results contemplated by the forward-looking statements contained in the Report.

  •  Economic downturns and reductions in government funding could have a negative impact on our business. Significant portions of our revenues are derived from contracts that are funded by federal, state and local government agencies. Our ability to obtain future public sector work at reasonable margins is highly dependent on the amount of work that is available to bid, which is largely a function of the level of government funding available. We also perform commercial and residential site development and other work for customers in the private sector. The availability of this private sector work can be significantly adversely affected by general economic downturns.
 
  •  Our fixed price and fixed unit price contracts subject us to the risk of increased project cost. As more fully described under “Contract Provisions and Subcontracting” above, the profitability of our fixed price and fixed unit price contracts can be adversely affected by a number of factors that can cause our actual costs to materially exceed the costs estimated at the time of our original bid.

8


Table of Contents

  •  Accounting for our revenues and costs involves significant estimates. As further described in “Critical Accounting Estimates” under “Management’s Discussion and Analysis of Financial Condition and Results of Operation,” accounting for our contract related revenues and costs as well as other cost items requires management to make a variety of significant estimates and assumptions. Although we believe we have sufficient experience and processes to enable us to formulate appropriate assumptions and produce reliable estimates, these assumptions and estimates may change significantly in the future and these changes could result in a material adverse effect on our financial position and the results of our operations.
 
  •  Weather can significantly impact our quarterly revenues and profitability. Our ability to perform work is significantly impacted by weather conditions such as precipitation and temperature. Changes in weather conditions can create significant variability in our quarterly revenues and profitability, particularly in the first and fourth quarters of the year. Additionally, delays and other weather impacts may increase a project’s cost and decrease its profitability.
 
  •  Our success depends on attracting and retaining qualified personnel in a competitive environment. The single largest factor in our ability to profitably execute our work is our ability to attract, develop and retain qualified personnel. Our success in attracting qualified people is dependent on the resources available in individual geographic areas and the impact on the labor supply due to general economic conditions as well as our ability to provide a competitive compensation package and work environment.
 
  •  We work in a highly competitive marketplace. As more fully described under “Competition” above, we have multiple competitors in all of the areas in which we work. During economic down cycles or times of lower government funding for public works projects, competition for the fewer available projects intensifies and this increased competition may result in a decrease in our ability to be competitive at acceptable margins.
 
  •  An inability to secure and permit aggregate reserves could negatively impact our future operations and results. Tighter regulations for the protection of the environment and the finite nature of property containing suitable aggregate reserves are making it increasingly challenging and costly to secure and permit aggregate reserves. Although we have thus far been able to secure and permit reserves to support our business, it is likely to become increasingly difficult to do so and there is no assurance that we will be able to secure and permit reserves in the future.
 
  •  We are subject to environmental and other regulation. As more fully described under “Government and Environmental Regulations” above, we are subject to a number of federal, state and local laws and regulations relating to the environment and workplace safety, the noncompliance of which can result in substantial penalties as well as civil and criminal liability. While compliance with these laws and regulations has not materially adversely affected our operations in the past, there can be no assurance that these requirements will not change and that compliance will not adversely affect our operations in the future.
 
  •  Strikes or work stoppages could have a negative impact on our operations and results. We are party to collective bargaining agreements covering a substantial portion of our craft workforce. Although our results and operations have not been significantly impacted by strikes or work stoppages in the past, such labor actions could have a significant impact on our operations if they occur in the future.
 
  •  Unavailability of insurance coverage could have a negative impact on our operations and results. We maintain insurance coverage as part of our overall risk management strategy and due to requirements to maintain specific coverage in our financing agreements and in most of our construction contracts. Although we have been able to obtain insurance coverage to meet our requirements in the past, there is no assurance that such insurance coverage will be available in the future.
 
  •  An inability to obtain bonding would have a negative impact on our operations and results. As more fully described in “Insurance and Bonding” above, we generally are required to provide surety bonds securing our performance under the majority of our public and private sector contracts. Our inability to obtain surety bonds in the future would significantly impact our ability to obtain new contracts, which would have a material adverse effect on our business.
 
  •  Our joint venture contracts with project owners subject us to joint and several liability. If a joint venture partner fails to perform we could be liable for completion of the entire contract and, if the contract were unprofitable, this could result in a material adverse effect on our financial position, results of operations and cash flows.

9


Table of Contents

  •  We use diesel fuel, asphalt oil and other petroleum based products that are subject to significant price fluctuations. These materials are used to run our equipment and materials processing plants and are a significant part of the asphalt paving materials that are used in many of our construction projects or are sold to outside parties. Although we can be partially protected by asphalt or fuel price escalation clauses in some of our contracts, not all contracts provide such protection. We have not been significantly adversely affected by price fluctuations in the past; however, there is no guarantee that we will not be in the future.
 
  •  As a part of our growth strategy we expect to make future acquisitions and acquisitions involve many risks. These risks include difficulties integrating the operations and personnel of the acquired companies, diversion of management’s attention, potential difficulties and increased costs associated with completion of any assumed construction projects, insufficient revenues to offset increased expenses associated with acquisitions and the potential loss of key employees of the acquired companies. Acquisitions may also cause us to increase our liabilities, record goodwill or other non-amortizable intangible assets that will be subject to impairment testing and potential impairment charges and incur amortization expenses related to certain other intangible assets. Failure to manage and successfully integrate acquisitions could harm our business and operating results significantly.
 
  •  Failure of our subcontractors to perform as anticipated could have a negative impact on our results. As further described under “Contract Provisions and Subcontracting” above, we subcontract a portion of many of our contracts to specialty subcontractors and we are ultimately responsible for the successful completion of their work. Although we seek to require bonding from our higher risk subcontractors, they are not always bondable and there is no guarantee that we will not incur a material loss due to subcontractor performance issues.
 
  •  Our long-term debt and credit arrangements contain restrictive covenants and failure to meet these covenants could significantly harm our financial condition. Our long-term debt and credit arrangements and related restrictive covenants are more fully described in Note 10 of the “Notes to the Consolidated Financial Statements” included in this report. In most cases, failure to meet the restrictive covenants would result in an immediate repayment liability for all amounts due and cancellation of open lines of credit. Additionally, failure to meet restrictive covenants related to our debt and credit agreements would trigger cross-default provisions that would cause us to also be in default of our surety agreements. Although we have not had difficulty meeting these covenants in the past, failure to do so in the future could have material adverse effects on our business and financial condition.

      The foregoing list is not exhaustive. There can be no assurance that we have correctly identified and appropriately assessed all factors affecting our business or that the publicly available and other information with respect to these matters is complete and correct. Additional risks and uncertainties not presently known to us or that we currently believe to be immaterial also may adversely impact us. Should any risks and uncertainties develop into actual events, these developments could have material adverse effects on our business, financial condition and results of operations. For these reasons, the reader is cautioned not to place undue reliance on our forward-looking statements.

Website Access

      Our website address is www.graniteconstruction.com. On our website we make available, free of charge, our annual report on Form 10-K, quarterly reports on Form 10-Q, current reports on Form 8-K, and all amendments to those reports as soon as reasonably practicable after such material is electronically filed with or furnished to the Securities and Exchange Commission. The information on our website is not incorporated into, and is not part of, this report. These reports, and any amendments to them, are also available at the website of the Securities and Exchange Commission, www.sec.gov.

 
Item 2. Properties

      Operations of Granite and our subsidiaries are conducted on both owned and leased properties with a total of approximately 1.0 million square feet of office and shop space situated on approximately 5,000 acres. Materials related operations of Granite and our subsidiaries are conducted on both owned and leased properties with a total of approximately 10,000 acres of owned quarry land with approximately 366,000,000 tons of aggregate reserves, and approximately 4,000 acres of leased quarry land with approximately 206,000,000 tons of aggregate reserves. We consider our available and future aggregate reserves adequate to meet our expected operating needs. We pursue a plan of acquiring new sources of aggregate reserves to replenish those depleted and to support future growth with a

10


Table of Contents

goal of maintaining approximately thirty years of aggregate reserves at most of our branch locations. Additionally, we own 2,605 acres of land that is either held for sale or is currently under development and intended for future sale.
 
Item 3. Legal Proceedings

      Our wholly-owned subsidiary, Granite Construction Company “GCCO”, as a member of a joint venture, Wasatch Constructors is among a number of construction companies and the Utah Department of Transportation that were named in a lawsuit filed in the United States District Court for the District of Utah. The plaintiffs are two independent contractor truckers who filed the lawsuit on behalf of the United States under the federal False Claims Act seeking to recover damages and civil penalties in excess of $46.4 million.

      Among other things, the plaintiffs allege that certain defendants, who were subcontractors to Wasatch, defrauded the Government by charging Wasatch for dirt and fill material they did not provide and that Wasatch and UDOT knowingly paid for such excess material. The plaintiffs also allege that Wasatch committed certain other acts including providing substandard workmanship and materials; failure to comply with clean air and clean water standards and the filing of false certifications regarding its entitlement to the payment of bonuses.

      The original complaint was filed in January 1999 and the Third Amended Complaint was filed in February 2003. On May 30, 2003, Wasatch Constructors and the coordinated defendants filed their motion to dismiss the Third Amended Complaint. On December 23, 2003, the Court issued its order granting Wasatch Constructors and the coordinated defendants’ motion to dismiss the Third Amended Complaint but allowed the plaintiffs one last opportunity to amend their complaint. Plaintiffs’ Fourth Amended Complaint was filed on July 12, 2004. The Company and GCCO believe that the allegations in the lawsuit are without merit and intend to defend them vigorously.

      Additionally, we are one of approximately one hundred defendants named in four California State Court lawsuits where four plaintiffs have, by way of various causes of action, including strict products and market share liability, alleged personal injuries caused by exposure to silica products and related materials during plaintiffs’ use or association with sandblasting or grinding concrete. The plaintiffs in each lawsuit have categorized the defendants as equipment defendants, respirator defendants, premises defendants and sand defendants. We have been identified as a sand defendant, meaning a party that manufactured, supplied or distributed silica-containing products. Our preliminary investigation reveals that we have not knowingly sold or distributed abrasive silica sand for sandblasting.

      We are a party to a number of other legal proceedings and believe that the nature and number of these proceedings are typical for a construction firm of our size and scope. Our litigation typically involves claims regarding public liability or contract related issues. While management currently believes, after consultation with counsel, that the ultimate outcome of these proceedings, individually and in the aggregate, will not have a material adverse effect on our financial position or overall trends in results of operations, litigation is subject to inherent uncertainties. Were an unanticipated unfavorable ruling to occur, there exists the possibility of a material adverse impact on the results of operations for the period in which the ruling occurs.

 
Item 4. Submission of Matters to a Vote of Security Holders

      We did not submit any matters to a vote of security holders during the fourth quarter of the year ended December 31, 2004.

Executive Officers of the Registrant

      Our executive officers are as follows:

             
Name Age Position



William G. Dorey
    60     President, Chief Executive Officer and Director
Mark E. Boitano
    56     Executive Vice President and Chief Operating Officer
James H. Roberts
    48     Senior Vice President and Branch Division Manager
Michael F. Donnino
    50     Senior Vice President and Heavy Construction Division Manager
William E. Barton
    60     Senior Vice President and Chief Financial Officer

      Granite Construction Incorporated was incorporated in Delaware in January 1990 as the holding company for Granite Construction Company, which was incorporated in California in 1922. All dates of service for our executive officers include the periods in which they served for Granite Construction Company.

11


Table of Contents

      Mr. Dorey has been an employee of Granite since 1968 and has served in various capacities, including Director since January 22, 2004, President and Chief Executive Officer since January 1, 2004, President and Chief Operating Officer from February 2003 to December 31, 2003, and Executive Vice President and Chief Operating Officer from 1998 to February 2003. He is also a director of Wilder Construction Company and served as a director of TIC Holdings, Inc. from 1997 to 2002. Mr. Dorey received a B.S. degree in Construction Engineering from Arizona State University in 1967.

      Mr. Boitano has been an employee of the Company since 1977 and has served in various capacities, including Chief Operating Officer since January 1, 2004 and Executive Vice President since February 2003. He also served as Branch Division Manager from 1998 to January 2004, and Senior Vice President from 1998 to February 2003. In 2001, he became a director of Wilder Construction Company. Mr. Boitano received a B.S. degree in Civil Engineering from Santa Clara University in 1971 and an M.B.A. degree from California State University, Fresno in 1977.

      Mr. Roberts joined Granite in 1981 and has served in various capacities, including Senior Vice President and Branch Division Manager since May 24, 2004, Vice President and Assistant Branch Division Manager from 1999 to 2004, and Regional Manager of Nevada and Utah Operations from 1995 to 1999. He received a B.S.C.E. in 1979 and an M.S.C.E. in 1980 from the University of California, Berkeley, and an M.B.A. from the University of Southern California in 1981.

      Mr. Donnino joined Granite in 1977 and has served as Senior Vice President and Heavy Construction Division Manager since January 1, 2005. He served as Vice President and Heavy Construction Division Assistant Manager during 2004, Texas Regional Manager from 2000 to 2003 and Dallas Area Manager from 1991 to 2000. Mr. Donnino received a B.S.C.E. in Structural, Water and Soils Engineering from the University of Minnesota in 1976.

      Mr. Barton has been an employee of the Company since 1980 and has served as Senior Vice President and Chief Financial Officer since 1999, and as Vice President and Chief Financial Officer from 1990 to 1999. In 1997, Mr. Barton became a director of TIC Holdings, Inc., and in January 2000 he also became a director of Wilder Construction Company. He received a B.S. degree in Accounting and Finance from San Jose State University in 1967 and an M.B.A. degree from Santa Clara University in 1973.

PART II

 
Item 5. Market for Registrant’s Common Equity, Related Shareholder Matters and Issuer Purchases of Equity Securities

      Our common stock trades on the New York Stock Exchange under the ticker symbol GVA. See “Quarterly Results” in “Management’s Discussion and Analysis of Financial Condition and Results of Operation” for a two-year summary of quarterly dividends and high and low sales prices of our stock.

      We have paid quarterly cash dividends since the second quarter of 1990 and we intend to continue to pay quarterly cash dividends. However, declaration and payment of dividends is within the sole discretion of our Board of Directors, subject to limitations imposed by Delaware law and compliance with our credit agreements, and will depend on our earnings, capital requirements, financial condition and such other factors as the Board of Directors deems relevant.

      As of February 18, 2005, there were 41,610,795 shares of common stock outstanding held by 968 shareholders of record.

12


Table of Contents

      During the three months ended December 31, 2004, we did not sell any of our equity securities that were not registered under the Securities Act of 1933, as amended. The following table sets forth information regarding the repurchase of shares of our common stock during the three months ended December 31, 2004:

                                 
Total Number of
Shares Purchased as Approximate Dollar Value
Part of Publicly of Shares That May Yet
Total Number of Average Price Paid Announced Plans or Be Purchased Under the
Period Shares Purchased(1) per Share Programs(2) Plans or Programs(2)





October 1, 2004 through October 31, 2004
                    $ 22,787,537  
November 1, 2004 through November 30, 2004
                    $ 22,787,537  
December 1, 2004 through December 31, 2004
    3,638     $ 26.41           $ 22,787,537  
     
     
     
         
      3,638     $ 26.41                
     
     
     
         


(1)  The total number of shares purchased includes shares purchased in connection with employee tax withholding for shares granted under our Amended and Restated 1999 Equity Incentive Plan.
 
(2)  On October 16, 2002, we publicly announced that our Board of Directors had authorized us to repurchase up to $25.0 million worth of shares of our Company’s common stock at management’s discretion.

13


Table of Contents

 
Item 6. Selected Consolidated Financial Data

      The selected consolidated operations data for 2004, 2003 and 2002 and consolidated balance sheet data as of December 31, 2004 and 2003 set forth below have been derived from our audited consolidated financial statements, and are qualified by reference to those consolidated financial statements. The selected consolidated operations data for 1994 through 2001 and the consolidated balance sheet data as of December 31, 1994 through 2002 have been derived from our audited consolidated financial statements not included herein. These historical results are not necessarily indicative of the results of operations to be expected for any future period.

Selected Consolidated Financial Data

                                                                                         
Years Ended December 31,

2004* 2003 2002 2001 2000 1999 1998 1997 1996 1995 1994











(In Thousands, Except Per Share Data)
Operating Summary
                                                                                       
Revenue
  $ 2,136,212     $ 1,844,491     $ 1,764,742     $ 1,547,994     $ 1,348,325     $ 1,328,774     $ 1,226,100     $ 1,028,205     $ 928,799     $ 894,796     $ 693,388  
Gross profit
    222,021       226,450       224,584       183,616       190,618       179,201       153,092       111,730       110,655       111,963       89,988  
As a percent of revenue
    10.4 %     12.3 %     12.7 %     11.9 %     14.1 %     13.5 %     12.5 %     10.9 %     11.9 %     12.5 %     13.0 %
General and administrative expenses
    157,035       151,879       146,467       119,282       105,043       94,939       83,834       73,593       71,587       69,610       62,795  
As a percent of revenue
    7.4 %     8.2 %     8.3 %     7.7 %     7.8 %     7.1 %     6.8 %     7.2 %     7.7 %     7.8 %     9.1 %
Net Income
    57,007       60,504       49,279       50,528       55,815       52,916       46,507       27,832       27,348       28,542       19,488  
As a percent of revenue
    2.7 %     3.3 %     2.8 %     3.3 %     4.1 %     4.0 %     3.8 %     2.7 %     2.9 %     3.2 %     2.8 %
Net income per share:
                                                                                       
Basic
  $ 1.41     $ 1.51     $ 1.23     $ 1.27     $ 1.41     $ 1.35     $ 1.17     $ 0.70     $ 0.70     $ 0.73     $ 0.50  
Diluted
    1.39       1.48       1.21       1.24       1.38       1.31       1.13       0.69       0.68       0.72       0.49  
Weighted average shares of common and common stock equivalents outstanding:
                                                                                       
Basic
    40,390       40,175       40,016       39,794       39,584       39,087       39,839       39,596       39,311       38,874       38,826  
Diluted
    41,031       40,808       40,723       40,711       40,409       40,445       41,009       40,413       40,122       39,711       39,434  
     
     
     
     
     
     
     
     
     
     
     
 
Balance Sheet Summary
                                                                                       
Total assets
  $ 1,277,954     $ 1,060,410     $ 983,819     $ 929,684     $ 711,142     $ 679,572     $ 626,571     $ 551,809     $ 473,045     $ 454,744     $ 349,098  
Cash, cash equivalents and marketable securities
    277,692       201,985       182,694       193,233       100,731       108,077       121,424       72,769       72,230       66,992       48,638  
Working capital
    355,927       274,947       220,396       248,413       180,051       143,657       142,448       103,910       92,542       77,179       65,537  
Current maturities of long-term debt
    15,861       8,182       8,640       8,114       1,130       5,985       10,787       12,921       10,186       13,948       10,070  
Long-term debt
    148,503       126,708       132,380       131,391       63,891       64,853       69,137       58,396       43,602       39,494       17,237  
Other long-term liabilities
    40,641       29,938       13,742       10,026       6,370                                      
Shareholders’ equity
    550,474       504,891       454,869       418,502       377,764       327,732       301,282       257,434       233,605       209,905       182,692  
Book value per share
    13.23       12.16       11.03       10.19       9.24       8.09       7.26       6.26       5.73       5.22       4.61  
Dividends per share
    0.40       0.40       0.32       0.32       0.29       0.27       0.20       0.16       0.17       0.13       0.06  
Common shares outstanding
    41,612       41,528       41,257       41,089       40,882       40,494       41,474       41,100       40,784       40,242       39,650  
     
     
     
     
     
     
     
     
     
     
     
 
Backlog
  $ 2,437,994     $ 1,985,788     $ 1,856,451     $ 1,377,172     $ 1,120,481     $ 793,256     $ 901,592     $ 909,793     $ 597,876     $ 590,075     $ 550,166  
     
     
     
     
     
     
     
     
     
     
     
 


Effective January 1, 2004, we adopted Financial Accounting Standards Board Interpretation No. 46 (revised December 2003) “Consolidation of Variable Interest Entities” (see Note 5 of the “Notes to the Consolidated Financial Statements”).

14


Table of Contents

 
Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operation

General

      We are one of the largest heavy civil contractors in the United States and are engaged in the construction of highways, dams, airports, mass transit facilities and other infrastructure-related projects. We have offices in Alaska, Arizona, California, Florida, Georgia, Minnesota, Nevada, New York, Oregon, Texas, Utah and Washington. Our business involves two operating segments: the Branch Division and the Heavy Construction Division.

      Our contracts are obtained primarily through competitive bidding in response to advertisements by federal, state and local agencies and private parties and to a lesser extent through negotiation with private parties. Our bidding activity is affected by such factors as backlog, current utilization of equipment and other resources, ability to obtain necessary surety bonds and competitive considerations. Bidding activity, backlog and revenue resulting from the award of new contracts may vary significantly from period to period.

      The two primary economic drivers of our business are (1) federal, state and local public funding levels and (2) the overall health of the economy, both nationally and locally. The level of demand for our services will have a direct correlation to these drivers. For example, a weak economy will generally result in a reduced demand for construction in the private sector. This reduced demand increases competition for fewer private sector projects and will ultimately also increase competition in the public sector as companies migrate from bidding on the scarce private sector work to projects in the public sector. A weak economy also tends to produce less tax revenue to the public sector that can have the effect of decreasing the funds available for spending on infrastructure improvements. There are funding sources that have been specifically earmarked for infrastructure spending, such as gasoline taxes, which are not necessarily directly impacted by a weak economy. However, even these funds can be temporarily at risk as state and local governments struggle to balance their budgets. Greater competition can reduce revenue growth and/or increase pressure on gross profit margins. Conversely, higher public funding and/or a robust economy will increase demand for our services and provide opportunities for revenue growth and margin improvement.

      Our general and administrative costs include salaries and related expenses, incentive compensation, discretionary profit sharing and other variable compensation, as well as other overhead costs to support our overall business. In general, these costs will increase in response to the growth and the related increased complexity of our business. These costs may also vary depending on the number of projects in process in a particular area and the corresponding level of estimating activity. For example, as large projects are completed or if the level of work slows down in a particular area, we will often re-assign employees who had been working on projects to estimating and bidding activities until another project is ready to start, which temporarily moves their salaries and other related costs from cost of revenue to general and administrative expense. Additionally, our compensation strategy for selected management personnel is to rely heavily on a variable cash and restricted stock performance-based incentive element. The cash portion of these incentives is expensed when earned while the restricted stock portion is expensed over the vesting period of the stock (generally three to five years). Depending on the mix of cash and restricted stock, these incentives can have the effect of increasing general and administrative expenses in a very profitable year and decreasing expenses in less profitable years.

Critical Accounting Estimates

      The preparation of financial statements in conformity with accounting principles generally accepted in the United States of America requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosure of contingent assets and liabilities at the date of the financial statements and the reported amounts of revenues and expenses during the reporting period. Our estimates, judgments and assumptions are continually evaluated based on available information and experience; however actual amounts could differ from those estimates.

      Certain of our accounting policies and estimates require higher degrees of judgment than others in their application. These include the recognition of revenue and earnings from construction contracts, accounting for

15


Table of Contents

construction joint ventures, the valuation of long-lived assets and insurance estimates. We evaluate all of our estimates and judgments on an on-going basis.

      Revenue Recognition for Construction Contracts: The majority of our contracts with our customers are either “fixed unit price” or “fixed price”. Under fixed unit price contracts, we are committed to provide materials or services required by a project at fixed unit prices (for example, dollars per cubic yard of concrete poured or cubic yards of earth excavated). While the fixed unit price contract shifts the risk of estimating the quantity of units required for a particular project to the customer, any increase in our unit cost over the expected unit cost in the bid, whether due to inflation, inefficiency, faulty estimates or other factors, is borne by us unless otherwise provided in the contract. Fixed price contracts are priced on a lump-sum basis under which we bear the risk that we may not be able to perform all the work profitably for the specified contract amount. The percentage of fixed price contracts in our backlog has increased from approximately 51.0% at December 31, 2003 to approximately 58.0% at December 31, 2004. All state and federal government contracts and many of our other contracts provide for termination of the contract for the convenience of the party contracting with us, with provisions to pay us for work performed through the date of termination.

      We use the percentage of completion accounting method for construction contracts in accordance with the American Institute of Certified Public Accountants Statement of Position 81-1, “Accounting for Performance of Construction-Type and Certain Production-Type Contracts.” Revenue and earnings on construction contracts, including construction joint ventures, are recognized on the percentage of completion method in the ratio of costs incurred to estimated final costs. Revenue in an amount equal to cost incurred is recognized prior to contracts reaching 25% completion. The related profit is deferred until the period in which such percentage completion is attained. It is our judgment that until a project reaches 25% completion, there is insufficient information to determine what the estimated profit on the project will be with a reasonable level of assurance. Revenue from contract claims is recognized when we have a signed settlement agreement and payment is assured. Revenue from contract change orders, which occur in most large projects, is recognized when the owner has agreed to the change order in writing. Provisions are recognized in the statement of income for the full amount of estimated losses on uncompleted contracts whenever evidence indicates that the estimated total cost of a contract exceeds its estimated total revenue. Contract cost consists of direct costs on contracts, including labor and materials, amounts payable to subcontractors, direct overhead costs and equipment expense (primarily depreciation, fuel, maintenance and repairs). Depreciation is provided using accelerated methods for construction equipment. Contract cost is recorded as incurred and revisions in contract revenue and cost estimates are reflected in the accounting period when known. The 25% threshold is applied to all percentage of completion projects without exception unless and until we project a loss on the project, in which case the estimated loss is immediately recognized.

      The accuracy of our revenue and profit recognition in a given period is almost solely dependent on the accuracy of our estimates of the cost to complete each project. Our cost estimates for all of our significant projects use a highly detailed “bottom up” approach and we believe our experience allows us to produce materially reliable estimates. However, our projects can be highly complex and in almost every case the profit margin estimates for a project will either increase or decrease to some extent from the amount that was originally estimated at the time of bid. Because we have many projects of varying levels of complexity and size in process at any given time (during 2004 we worked on over 4,600 projects) these changes in estimates can offset each other without materially impacting our overall profitability. However, large changes in cost estimates, particularly in the bigger, more complex projects in our Heavy Construction Division, can have a more significant effect on profitability.

      There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include the completeness and accuracy of the original bid, recognition of costs associated with added scope changes, extended overhead due to owner and weather delays, subcontractor performance issues, changes in productivity expectations, site conditions that differ from those assumed in the original bid (to the extent contract remedies are unavailable), the availability and skill level of workers in the geographic location of the project and a change in the availability and proximity of materials. The foregoing factors as well as the stage of completion of contracts in process and the mix of contracts at

16


Table of Contents

different margins may cause fluctuations in gross profit between periods and these fluctuations may be significant.

      Construction Joint Ventures and Other Variable Interest Entities: As described in Note 5 of the “Notes to the Consolidated Financial Statements” and in “Management’s Discussion and Analysis of Financial Condition and Results of Operation” under “Joint Ventures,” we participate in various construction joint venture partnerships in order to share expertise, risk and resources for certain highly complex projects.

      We have determined that certain of the construction joint ventures as well as certain other partnerships in which we participate are variable interest entities as defined by Financial Accounting Standards Board Interpretation No. 46 (revised December 2003) “Consolidation of Variable Interest Entities” (“FIN 46”) and we have consolidated those for which we are the primary beneficiary on a prospective basis effective January 1, 2004 (see Note 5 of the “Notes to the Consolidated Financial Statements”). Consistent with industry practice and Emerging Issues Task Force Issue 00-01, “Investor Balance Sheet and Income Statement Display under the Equity Method for Investments in Certain Partnerships and Other Ventures”, we account for our share of the operations of construction joint ventures in which we have determined we are not the primary beneficiary on a pro rata basis in the consolidated statements of income and as a single line item in the consolidated balance sheets.

      Determining whether an entity is a Variable Interest Entity (“VIE”) and whether we are the primary beneficiary involves a substantial amount of estimation and judgment, including estimates of the amount and timing of future cash flows. Although we believe that the estimates and judgments we used are reasonable and supportable, the use of different assumptions and estimates could produce a different result. The decision as to whether or not to consolidate a joint venture has an impact on the amount of recorded revenue, contract costs, assets and liabilities but has little or no impact on recorded net income.

      Valuation of Long-Lived Assets: Long-lived assets, which include property, equipment and acquired identifiable intangibles, are reviewed for impairment whenever events or changes in circumstances indicate that the carrying amount of an asset may not be recoverable. Impairment evaluations involve management estimates of asset useful lives and future cash flows. Actual useful lives and cash flows could be different from those estimated by management and this could have a material effect on our operating results and financial position.

      Additionally, we had approximately $27.9 million in goodwill at December 31, 2004, $18.0 million relating to HCD and $9.9 million relating to our Branch Division. We perform goodwill impairment tests on an annual basis and more frequently when events and circumstances occur that indicate a possible impairment of goodwill. In determining whether there is an impairment of goodwill, we calculate the estimated fair value of the reporting unit in which the goodwill is recorded using a discounted future cash flow method. We then compare the resulting fair value to the net book value of the reporting unit, including goodwill. If the net book value of a reporting unit exceeds its fair value, we would measure the amount of the impairment loss by comparing the implied fair value of the reporting unit’s goodwill with the carrying amount of that goodwill. To the extent that the carrying amount of a reporting unit’s goodwill exceeds its implied fair value, we recognize a goodwill impairment loss. We performed our annual impairment test in 2004 and we determined that no impairment had occurred. The discounted future cash flow method used in the first step of our impairment test involves significant estimates including future cash inflows from estimated revenues, future cash outflows from estimated project cost and general and administrative costs, estimates of timing of collection and payment of various items and future growth rates as well as discount rate and terminal value assumptions. Although we believe the estimates and assumptions that we used in testing for impairment are reasonable and supportable, significant changes in any one of these assumptions could produce a significantly different result.

17


Table of Contents

Current Year

 
Revenue
                                                     
Years Ended December 31,

2004 2003 2002



Amount Percent Amount Percent Amount Percent






(In thousands)
Revenue by Division:
                                               
 
Branch Division
  $ 1,287,615       60.3 %   $ 1,152,726       62.5 %   $ 1,187,812       67.3 %
 
Heavy Construction Division
    848,597       39.7 %     691,765       37.5 %     576,930       32.7 %
     
     
     
     
     
     
 
    $ 2,136,212       100.0 %   $ 1,844,491       100.0 %   $ 1,764,742       100.0 %
     
     
     
     
     
     
 
Revenue by Geographic Area:
                                               
 
California
  $ 761,365       35.6 %   $ 680,597       36.9 %   $ 738,392       41.8 %
 
West (excluding California)
    634,206       29.7 %     593,781       32.2 %     598,432       33.9 %
 
Midwest
    84,587       4.0 %     59,911       3.2 %     73,612       4.2 %
 
South
    358,631       16.8 %     345,258       18.7 %     251,604       14.3 %
 
Northeast
    297,423       13.9 %     164,944       9.0 %     102,702       5.8 %
     
     
     
     
     
     
 
    $ 2,136,212       100.0 %   $ 1,844,491       100.0 %   $ 1,764,742       100.0 %
     
     
     
     
     
     
 
Revenue by Market Sector:
                                               
 
Federal agencies
  $ 118,613       5.6 %   $ 63,852       3.5 %   $ 56,039       3.2 %
 
State agencies
    709,629       33.2 %     722,055       39.1 %     692,263       39.2 %
 
Local public agencies
    724,855       33.9 %     553,146       30.0 %     515,071       29.2 %
     
     
     
     
     
     
 
   
Total public sector
  $ 1,553,097       72.7 %   $ 1,339,053       72.6 %   $ 1,263,373       71.6 %
     
     
     
     
     
     
 
 
Private sector
    318,762       14.9 %     252,693       13.7 %     273,636       15.5 %
 
Material sales
    264,353       12.4 %     252,745       13.7 %     227,733       12.9 %
     
     
     
     
     
     
 
    $ 2,136,212       100.0 %   $ 1,844,491       100.0 %   $ 1,764,742       100.0 %
     
     
     
     
     
     
 

      Revenue: Revenue from our Branch Division increased $134.9 million, or 11.7%, in the year ended December 31, 2004 from the year ended December 31, 2003. The increase in Branch Division revenue primarily reflected increases in private sector construction revenue and sales of construction materials as a result of the increase in demand created by the continuing strong housing market in California and other Branch Division locations. The increase in revenue from construction materials was also due to increases in both unit volume and average sales price of certain products, which we believe reflect an appreciation in the market for the growing scarcity of finite aggregate resources and the results of our strategic focus on maximizing revenue from external sales of materials. Public sector revenue as a percent of total branch revenue remained relatively unchanged compared with 2003 as increased local government agency revenue was largely offset by a reduction in state government agency work, particularly in California. We continue to experience reduced awards from the California State Department of Transportation due to ongoing budgetary uncertainty in the state (see “Outlook”).

      Revenue from our Heavy Construction Division increased $156.8 million, or 22.7%, in the year ended December 31, 2004 from the year ended December 31, 2003. Included in HCD revenue for the year ended December 31, 2004 was $104.3 million (all in the public sector) resulting from the consolidation of our partners’ share of construction joint venture revenue under FIN 46 (see Note 5 of the “Notes to the Consolidated Financial Statements”). The remainder of the increase over 2003 was due primarily to results from a higher backlog at the beginning of 2004, particularly in the Northeast.

18


Table of Contents

 
Backlog
                                     
December 31,

2004 2003


Amount Percent Amount Percent




(In thousands)
Backlog by Division:
                               
 
Heavy Construction Division
  $ 1,876,091       77.0 %   $ 1,529,398       77.0 %
 
Branch Division
    561,903       23.0 %     456,390       23.0 %
     
     
     
     
 
    $ 2,437,994       100.0 %   $ 1,985,788       100.0 %
     
     
     
     
 
Backlog by Geographic Area:
                               
 
California
  $ 607,737       24.9 %   $ 259,035       13.0 %
 
West (excluding California)
    369,294       15.1 %     317,520       16.0 %
 
Midwest
    120,578       4.9 %     36,096       1.8 %
 
South
    757,605       31.1 %     642,534       32.4 %
 
Northeast
    582,780       24.0 %     730,603       36.8 %
     
     
     
     
 
    $ 2,437,994       100.0 %   $ 1,985,788       100.0 %
     
     
     
     
 
Backlog by Market Sector:
                               
 
Federal agencies
  $ 64,348       2.6 %   $ 105,397       5.3 %
 
State agencies
    1,003,614       41.2 %     747,214       37.6 %
 
Local public agencies
    1,137,821       46.7 %     962,255       48.5 %
     
     
     
     
 
   
Total public sector
    2,205,783       90.5 %     1,814,866       91.4 %
     
     
     
     
 
 
Private sector
    232,211       9.5 %     170,922       8.6 %
     
     
     
     
 
    $ 2,437,994       100.0 %   $ 1,985,788       100.0 %
     
     
     
     
 

      Backlog: Backlog in our Heavy Construction Division at December 31, 2004 was $1,876.1 million, an increase of $346.7 million, or 22.7%, from backlog at December 31, 2003. Included in HCD backlog at December 31, 2004 was $280.5 million resulting from the consolidation of our partners’ share of construction joint venture backlog under FIN 46 (see Note 5 of the “Notes to the Consolidated Financial Statements”). The remainder of the increase resulted from new awards in California and in the South, partially offset by a reduction in the Northeast and reflected changes primarily in public sector backlog. Additions to HCD backlog in the fourth quarter of 2004 included a $147.8 million design/build bridge project in Florida, a $131.1 million highway project in Texas and a $49.8 million transit structure project in New York.

      Branch Division backlog at December 31, 2004 was $561.9 million, an increase of $105.5 million, or 23.1%, from the December 31, 2003 level. The increase was due primarily to higher backlog in the private sector for projects located throughout the West, including California, due largely to the continued strong demand in the housing sector. Public sector backlog increases in states other than California were generally offset by a decrease in California, where ongoing budgetary issues have had a negative impact on the amount of funding available for infrastructure projects. Branch Division awards in the fourth quarter of 2004 included a $28.3 million bridge project in Alaska and a $16.3 million sewer pipeline project in California.

19


Table of Contents

 
Gross Profit
                         
Years Ended December 31,

2004 2003 2002



(In thousands)
Branch Division gross profit
  $ 185,509     $ 170,024     $ 173,480  
Percent of division revenue
    14.4 %     14.7 %     14.6 %
     
     
     
 
Heavy Construction Division gross profit
  $ 41,036     $ 56,920     $ 50,759  
Percent of division revenue
    4.8 %     8.2 %     8.8 %
     
     
     
 
Other
  $ (4,524 )   $ (494 )   $ 345  
     
     
     
 
Total gross profit
  $ 222,021     $ 226,450     $ 224,584  
Percent of revenue
    10.4 %     12.3 %     12.7 %
     
     
     
 

      Gross Profit: As more fully described under “Critical Accounting Estimates” we recognize revenue only equal to cost, deferring profit recognition, until a project reaches 25% completion. Because we have a large number of projects at various stages of completion in our Branch Division, this policy generally has very little impact on the Branch Division’s gross profit on a quarterly or annual basis. However, HCD has fewer projects in process at any given time and those projects tend to be much larger than Branch Division projects. As a result, HCD gross profit as a percent of revenue can vary significantly in periods where one or several very large projects reach 25% completion and the deferred profit is recognized or conversely, in periods where backlog is growing rapidly and a higher percentage of projects are in their early stages with no associated gross margin recognition.

      Additionally, as we also describe under “Critical Accounting Estimates” we do not recognize revenue from contract claims until we have a signed agreement and payment is assured and we do not recognize revenue from contract change orders until the contract owner has agreed to the change order in writing. However, we do recognize the costs related to any contract claims or pending change orders when they are incurred. As a result, our gross profit as a percent of revenue can vary during periods where a large volume of change orders or contract claims are pending resolution (reducing gross profit percent) or, conversely, during periods where large change orders or contract claims are agreed or settled (increasing gross profit percent). Although this variability can occur in both our Branch Division and HCD, it can be much more pronounced in HCD because of the larger size of their projects.

      Revenue from projects that were less than 25% complete was $132.2 million in 2004 and $107.9 million in 2003. Included in revenue from projects less than 25% complete for the year ended December 31, 2004 is $24.2 million resulting from the consolidation of our partners’ share of construction joint venture backlog under FIN 46 (see Note 5 of the “Notes to the Consolidated Financial Statements”). This increase in revenue from projects less than 25% complete had the effect of reducing our overall gross margin. No significant claim revenue was recognized in either 2004 or 2003.

      Gross profit as a percent of revenue in our Branch Division decreased slightly in 2004 as compared with 2003 reflecting normal variability in the mix of work performed during the year.

      The decrease in HCD gross profit as a percent of revenue in 2004 as compared with 2003 was due primarily to downward revisions in certain profit forecasts due to additional estimated costs to complete. The net impact of these estimate changes on recognized gross profit during 2004 was a reduction in gross profit of approximately $40.0 million, of which approximately $10.0 million was recognized in the fourth quarter. Included in the net impact of this change in estimate in both the quarter and year ended December 31, 2004 was approximately $2.0 million representing our partners’ proportionate share that has been newly consolidated during 2004 (see Note 5 of the “Notes to the Consolidated Financial Statements”). The majority of this change in estimate related to downward revisions of ten projects. The amount attributable to each project ranged from approximately $1.4 million to $11.6 million. The cost estimate changes resulted from a variety of factors including costs associated with added scope changes, extended overhead due to owner and weather delays, design problems on design/build projects, subcontractor performance issues, changes in productivity

20


Table of Contents

expectations and higher estimated liquidated damages on two projects. At December 31, 2004, six of these projects were greater than 90% complete, two were greater than 85% complete and the remaining two projects averaged 59% complete. Although we believe that our estimates of the cost to complete these projects are achievable, it is possible that the actual cost to complete will be greater than our current estimate and any future estimate changes could be significant.
 
General and Administrative Expenses
                           
Years Ended December 31,

2004 2003 2002



(In thousands)
Salaries and related expenses
  $ 82,379     $ 78,832     $ 72,329  
Incentive compensation, discretionary profit sharing and other variable compensation
    25,467       28,309       25,727  
Other general and administrative expenses
    49,189       44,738       48,411  
     
     
     
 
 
Total
  $ 157,035     $ 151,879     $ 146,467  
     
     
     
 
Percent of revenue
    7.4 %     8.2 %     8.3 %
     
     
     
 

      General and Administrative Expenses: General and administrative expenses increased by $5.2 million from 2003 to 2004. Salaries and related expenses increased in 2004 due primarily to additional staffing needed to support a higher volume of work. Incentive compensation, discretionary profit sharing and other variable compensation decreased in 2004 due to lower profitability in 2004. The increase in other general administrative costs in 2004 related to increased bidding activity and higher revenue volume as well as costs associated with complying with the requirements of Section 404 of the Sarbanes-Oxley Act of 2002. Other general and administrative costs include information technology, occupancy, office equipment and supplies, depreciation, travel and entertainment, outside services, advertising and marketing, training and other miscellaneous expenses, none of which individually exceeded 10% of total general and administrative expenses.

 
Gain on Sales of Property and Equipment
                         
Years Ended December 31,

2004 2003 2002



(In thousands)
Gain on sales of property and equipment
  $ 18,566     $ 4,714     $ 2,128  

      Gain on Sales of Property and Equipment: Gain on sales of property and equipment increased by $13.9 million from 2003 to 2004 due primarily to the $10.0 million gain on sale of certain assets related to our redi-mix concrete business in Utah in March 2004.

 
Other Income (Expense)
                           
Years Ended December 31,

2004 2003 2002



(In thousands)
Interest income
  $ 7,962     $ 6,422     $ 10,048  
Interest expense
    (7,191 )     (8,577 )     (9,162 )
Equity in income of affiliates
    6,162       17,657       3,366  
Other, net
    4,439       2,738       (1,758 )
     
     
     
 
 
Total
  $ 11,372     $ 18,240     $ 2,494  
     
     
     
 

      Other Income (Expense): Equity in income of affiliates primarily comprised income from our equity method investment in two land development partnerships in the year ended December 31, 2004 and $18.4 million in income related to the sale of the State Route 91 Toll Road Franchise by the California Private Transportation Corporation, of which we are a 22.2% limited partner in the year ended December 31, 2003.

21


Table of Contents

Provision for Income Taxes

                         
Years Ended December 31,

2004 2003 2002



(In thousands)
Provision for income taxes
  $ 28,477     $ 35,304     $ 29,951  
Effective tax rate
    30.0 %     36.2 %     36.2 %

      Provision for Income Taxes: Our effective tax rate decreased to 30.0% in 2004 from 36.2% in 2003 due primarily to the inclusion in our pre-tax income of the minority interest in the income of our consolidated construction joint ventures as required by FIN 46 (see Note 5 of the “Notes to the Consolidated Financial Statements”), which are generally not subject to income taxes on a stand-alone basis, and a lower overall state tax rate, net of federal tax benefit, due to changes in the mix of earnings in differing tax jurisdictions. The American Jobs Creation Act of 2004 provides for a new deduction for domestic production which will be phased in over six years beginning in 2005. As a result, we expect that our 2005 tax expense will be positively impacted by this deduction, adjusting our effective tax rate between 0.8% and 1.0%.

Outlook

      Looking ahead, our performance in 2005 will be dependent largely on the Branch Division’s ability to capitalize on the private sector opportunities available in the West and HCD’s ability to deliver improved performance from its backlog. Our materials business remains strong, and we continue to monitor the legislative activities affecting our industry, particularly the funding of transportation projects at both federal, state and local levels.

      The Branch Division has been implementing its strategic direction taken several years ago to capitalize on the healthy private sector market in the West. We have made the organizational adjustments and added staff to allow us to better serve this market, particularly in California where we continue to witness population and job growth producing strong housing starts in many of our regions. We have yet, however, to see an increase in Caltrans work being let and we do not anticipate this will change in 2005. Conversely, the private sector market is currently showing no signs of slowing down. Our strategy for the Branch Division is to continue to serve both the private and public sector markets. This strategy provides us the flexibility to take advantage of opportunities in a variety of markets and economic environments.

      Our materials business, which is also being driven by the private sector market, remains strong. With third-party sales representing 21% of the Branch Division’s revenue in 2004, the ownership of aggregate materials is becoming increasingly more valuable both as a resource for our core construction business as well as a strategic and profitable retail business. Our plan is to continue to invest in this part of our business by acquiring additional aggregate reserves, “Green fielding” new facilities and expanding our existing operations. Our financial resources provide us with the ability to take advantage of these investment opportunities as they arise.

      Our 2005 focus for all of our business, but particularly for our HCD business, is to successfully execute on our backlog. We believe the division’s margin performance has, in part, been impacted by its rapid growth and, as a result we are continuing to build the division’s support infrastructure and are focusing considerable attention on the basic fundamentals of this business beginning with management oversight, a disciplined bidding philosophy and a commitment to project execution and forecasting. Specifically, we have been bidding our work with higher margins and spending less effort on the top line growth of the division. In addition, over this past year, we have added a second assistant division manager, added two new regional managers and added support staff as well as instituting new procedures to surface problems sooner. While we have some underperforming projects yet to complete, we believe we will begin to see our efforts reflected in improved financial results from the division in 2005.

      On the legislative front, we continue to closely monitor Congress’ on-going efforts to reauthorize the federal transportation bill that replaces the previous legislation (the six-year $218 billion Transportation Equity Act for the 21st Century) that expired in September 2003. The President’s FY2006 Budget released in

22


Table of Contents

early February included a revised funding proposal of $284 billion over six years — a $28 billion increase over the $256 billion proposed by the Administration in the FY2005 budget. According to the American Road and Transportation Builders Association (“ARTBA”), this increase is paid for through new revenue from the Highway Trust Fund (“HTF”) generated by the credit of ethanol-related tax subsidies to the HTF and from a reduction in fuel tax evasion. Subsequently, the House introduced its $284 billion six-year bill for FY2004 through FY2009 that is expected to go before the full House for a vote in March. According to legislative analysts with ARTBA, the Senate is expected to introduce a similar measure by early March. We are working closely with industry organizations and lobbyists to support a long-term bill this year that provides for more than the minimum investment levels proposed by the President and the House.

      As anticipated, in California, Governor Schwarzenegger proposed no additional transportation funding in his initial 2005-2006 Budget submission and called for an additional loan of $1.3 billion from Proposition 42 monies to the General Fund to help mitigate the State’s fiscal shortfall. The General Fund currently owes more than $3 billion to transportation accounts to be paid back in future years. The Budget picture will become clearer with the Governor’s May revisions and the actions of the Legislature in framing a final Budget document. The Governor and legislative leaders in both houses have proposed constitutional firewalls to protect Proposition 42 funds in future fiscal years.

      As we discussed last quarter, the defeat of two California gaming initiatives, Proposition 68 and 70, on last November’s ballot were expected to boost the state’s transportation accounts by as much as $1.2 billion. Originally, these funds were to be made available during the first half of 2005, provided litigation was resolved and the bonds were let. According to industry analysts, while the Governor remains strongly committed to ensuring that transportation programs will benefit from the sale of bonds, the recently proposed state budget anticipates that legal issues will prevent the sale of those bonds in 2004-05 by proposing to shift the bond proceeds to the 2005-06 budget. Additionally, State Treasurer Phil Angelides has estimated that the bonds will yield only two-thirds of the $1.2 billion originally projected.

      In summary, we expect to build our capabilities across both divisions in 2005 and pursue opportunities in new and existing markets throughout the United States. As always, our top priorities remain the safe and successful execution of our work and the improvement of our bottom line financial performance.

Prior Years

      Revenue: Revenue from our Branch Division decreased $35.1 million, or 3.0%, in the year ended December 31, 2003 from the year ended December 31, 2002. Branch Division revenue in 2003 included $199.5 million from our majority-owned Wilder Construction Company (“Wilder”) subsidiary, which was consolidated in our financial statements beginning in May 2002, versus $155.4 million in 2002. The decrease in Branch Division revenue reflected a decrease in construction revenue, primarily in the public sector, partially offset by the increase in Wilder revenue referred to above and an increase in revenue from the sale of construction materials. Many of our Branch Division businesses were impacted by the effects of a weaker general economy and uncertainty surrounding public funding, particularly in California. The increase in revenue from construction materials was due to increases in both unit volume and average sales price of certain products, which we believe reflected an appreciation in the market for the growing scarcity of finite aggregate resources and the results of a strategic focus on maximizing revenue from external sales of materials.

      Revenue from our Heavy Construction Division increased $114.8 million, or 19.9%, in the year ended December 31, 2003 from the year ended December 31, 2002 due primarily to results from a higher backlog at the beginning of 2003. Geographically, this revenue growth came from projects in the South and from our Granite Halmar location in New York.

      Backlog: Backlog in our Heavy Construction Division at December 31, 2003 was $1,529.4 million, an increase of $163.7 million, or 12.0%, from the December 31, 2002 level. The increase took place primarily in the South and at our Granite Halmar location in New York and reflected increases in both public sector and private sector backlog. Additions to HCD backlog in the fourth quarter of 2003 included a $38.8 million

23


Table of Contents

interchange project in Florida, a $23.4 million roadway and bridge project in Florida and a $216.7 million transit facility project in New York.

      Branch Division backlog at December 31, 2003 was $456.4 million, a decrease of $34.4 million or 7.0% from the December 31, 2002 level. The decrease was due primarily to lower backlog in the public sector, particularly in California where the continuing budget crisis had a negative impact on the amount of funding available for infrastructure projects. Branch division awards in the fourth quarter of 2003 include a $25.0 million share of a joint venture highway improvement project in Nevada and a $19.0 million highway reconstruction project in Utah.

      Gross Profit: Revenue from projects that were less than 25% complete was $107.9 million in 2003 and $99.1 million in 2002. Because the variance between the two years was not significant, the impact on the comparability of gross profit as a percent of revenue between the two years was also not significant. No significant claim revenue was recognized in either 2003 or 2002.

      Gross profit as a percent of revenue in our Branch Division increased slightly in 2003 as compared with 2002. This was due to an increase in the profitability of sales of construction materials, partially offset by lower gross profit margin on the Division’s construction work. Construction gross margins in the Branch Division were under pressure due to increased competition resulting from reductions in various state and local transportation funding programs; however the margins on the sale of materials benefited from a higher average sales price.

      Gross profit as a percent of revenue in HCD decreased in 2003 as compared with 2002 due largely to profit forecasts on several projects that were revised downward to give recognition to additional estimated costs to complete for which we either did not expect to receive additional revenue or we had not yet reached agreement with the contract owner for additional revenue.

      General and Administrative Expenses: General and administrative expenses increased by $5.4 million from 2002 to 2003. This increase was primarily attributed to expenses from our Wilder subsidiary and our expansion into Northern California, both of which were first reflected in our costs in May 2002. Excluding the Wilder and Northern California locations added in May of 2002, salaries and related expenses increased by approximately $1.7 million in 2003. Incentive compensation, discretionary profit sharing and other variable compensation increased in 2003 as compared with 2002 due to higher net income in 2003. Other general and administrative costs include information technology, occupancy, office equipment and supplies, depreciation, travel and entertainment, outside services, advertising and marketing, training and other miscellaneous expenses, none of which individually exceeded 10% of total general and administrative expenses.

      Operating Income: Our Heavy Construction Division’s contribution to operating income increased in 2003 compared with 2002 due primarily to increased revenue as described in “Revenue” above. Branch Division contribution to operating income decreased in 2003 compared with 2002 due to lower revenue as described in “Revenue” above and higher general and administrative expenses due primarily to expenses from our Wilder subsidiary and our expansion into Northern California, both of which were first reflected in our costs in May 2002. Unallocated other corporate expenses principally comprise corporate general and administrative expenses.

      Other Income (Expense): Included in equity in income of affiliates in 2003 is $18.4 million recognized in the first quarter of 2003 related to the sale of the State Route 91 toll road franchise by the California Private Transportation Corporation (“CPTC”), of which we are a 22.2% limited partner, as well as a gain of approximately $1.9 million recognized on the sale of a portion of our investment in T.I.C. Holdings, Inc. (“TIC”). Interest income decreased in 2003, largely due to the absence of the recognition of deferred interest income on a note receivable from CPTC in 2002 and lower “look back” interest income related to taxes paid on income from construction projects.

24


Table of Contents

Liquidity and Capital Resources

                           
December 31,

2004 2003 2002



(In thousands)
Cash and cash equivalents
  $ 161,627     $ 69,919     $ 52,032  
Net cash provided by (used in) by:
                       
 
Operating activities
    79,233       77,589       104,045  
 
Investing activities
    (41,427 )     (33,039 )     (134,110 )
 
Financing activities
    (15,812 )     (26,663 )     (43,077 )
Capital expenditures
    89,636       62,805       57,415  
Working capital
    355,927       274,947       220,396  

      Our primary sources of liquidity are cash flows from operations and borrowings under our credit facilities. We expect the principal use of funds for the foreseeable future will be for capital expenditures, working capital, debt service, acquisitions and other investments. We have budgeted $89.0 million for capital expenditures in 2005, which includes amounts for construction equipment, aggregate and asphalt plants, buildings, leasehold improvements and the purchase of land and aggregate reserves. Additionally, we are seeking authorization, subject to Board Approval, to spend up to approximately $50.0 million for materials related investments.

      Our cash and cash equivalents and short-term and long-term marketable securities totaled $277.7 million at December 31, 2004 and included $67.4 million of cash from our newly consolidated joint ventures (see Note 5 of the “Notes to the Consolidated Financial Statements”). This joint venture cash is for the working capital needs of each joint venture’s project. The decision to distribute cash must generally be made jointly by all of the partners. We believe that our current cash and cash equivalents, short-term investments, cash generated from operations and amounts available under our existing credit facilities will be sufficient to meet our expected working capital needs, capital expenditures, financial commitments and other liquidity requirements associated with our existing operations through the next 12 months and beyond. If we experience a significant change in our business such as the execution of a significant acquisition, we would likely need to acquire additional sources of financing, which may be limited by the terms of our existing debt covenants, or may require the amendment of our existing debt agreements.

      Cash provided by operating activities of $79.2 million for the year ended December 31, 2004 represents a $1.6 million increase from the amount provided by operating activities in 2003. The increase primarily reflects variations based on the amount and progress of work being performed. In particular, there was a higher growth in accounts payable and accrued expenses and other liabilities related primarily to a higher volume of work performed in the fourth quarter of 2004 compared with the fourth quarter of 2003 that was only partially offset by a higher growth in accounts receivable. Additionally, there was a decrease in the cash flow from net billings in excess of cost and estimated earnings due to an increase in the number of projects with billing provisions that require completion of discrete components of work rather than the more typical monthly unit price billing terms. Such billing provisions result in delays in our ability to bill and receive payment from the project owner.

      Cash used by investing activities of $41.4 million in 2004 represents an $8.4 million increase from the amount used in investing activities in 2003. The increase was largely due to higher net additions to property and equipment as well as $9.2 million used to purchase additional shares of our majority-owned subsidiary, Wilder Construction Company, in April 2004. These increases in cash used by investing activities were partially offset by higher net maturities of marketable securities.

      Cash used by financing activities was $15.8 million in 2004, a decrease of $10.9 million from 2003. The decrease was mainly due to higher proceeds from long-term debt in 2004, which include $25 million advanced under our bank revolving line of credit, partially offset by higher payments of long-term debt and net distributions of $12.6 million to our partners in our construction joint ventures which we began consolidating in 2004 as a result of our implementation of FIN 46 (see Note 5 of the “Notes to the Consolidated Financial Statements”).

25


Table of Contents

Contractual Obligations

      The following table summarizes our significant contractual obligations outstanding as of December 31, 2004 (in thousands):

                                         
Payments due by period

Less than More than
Total 1 Year 1-3 Years 3-5 Years 5 Years





Long term debt(1)
  $ 164,364     $ 15,861     $ 65,985     $ 35,312     $ 47,206  
Operating leases(2)
    27,678       6,324       9,150       3,561       8,643  
Purchase obligations under construction contracts(3)
    1,397,353       869,513       438,717       89,123        
Other purchase obligations(4)
    13,733       13,733                    
Deferred compensation obligations(5)
    21,181       140       2,587       4,332       14,122  
Wilder stock repurchase obligation(6)
    17,172       661       1,579       1,000       13,932  
     
     
     
     
     
 
Total
  $ 1,641,481     $ 906,232     $ 518,018     $ 133,328     $ 83,903  
     
     
     
     
     
 


(1)  These obligations represent the aggregate minimum principal maturities of long-term debt and do not include interest. See Note 10 of the “Notes to the Consolidated Financial Statements.”
 
(2)  These obligations represent the minimum rental commitments and minimum royalty requirements under all noncancellable operating leases. See Note 15 of the “Notes to the Consolidated Financial Statements.”
 
(3)  These obligations represent our best estimate of future purchases of materials and subcontract services related to our current contract backlog.
 
(4)  These obligations represent firm purchase commitments for equipment and other goods and services not connected with our construction backlog which are individually greater than $10,000 and have an expected purchase after February 28, 2005.
 
(5)  The timing of expected payment of deferred compensation is based on estimates and is subject to change.
 
(6)  The years of expected payment for redemptions is based on estimates and is subject to change. See Note 15 of the “Notes to the Consolidated Financial Statements.”

      In 2002, our Board of Directors authorized us to repurchase up to $25.0 million of our common stock of which $22.8 million remained at December 31, 2004. In addition, we are authorized to purchase shares for contribution to our Employee Stock Ownership Plan (“ESOP”).

      We had standby letters of credit totaling approximately $2.9 million outstanding at December 31, 2004, all of which expire between February and October of 2005. Additionally, we generally are required to provide various types of surety bonds that provide an additional measure of security under certain public and private sector contracts. At December 31, 2004, approximately $2.4 billion of our backlog was bonded and performance bonds totaling approximately $7.5 billion were outstanding. Performance bonds do not have stated expiration dates; rather, we are generally released from the bonds when each contract is accepted by the owner. The ability to maintain bonding capacity to support our current and future level of contracting requires that we maintain cash and working capital balances satisfactory to our sureties.

      In addition to our working capital and cash generated from operations, we currently have access to funds under a $100.0 million bank revolving line of credit, which allows for unsecured borrowings through June 27, 2006, with interest rate options. Outstanding borrowings under the revolving line of credit are at our choice of selected LIBOR rates plus a margin that is recalculated quarterly. The margin was 1.25% at December 31, 2004. The unused and available portion of this line of credit was $72.3 million at December 31, 2004. Additionally, our Wilder subsidiary has a bank revolving line of credit of $10.0 million that expires in June 2006. There were no amounts outstanding under the Wilder line of credit at December 31, 2004.

      Restrictive covenants under the terms of our debt agreements require the maintenance of certain financial ratios and the maintenance of tangible net worth (as defined) (see Note 10 of the “Notes to the Consolidated

26


Table of Contents

Financial Statements”). We were in compliance with these covenants at December 31, 2004. Additionally, our Wilder subsidiary has restrictive covenants (on a Wilder stand-alone basis) under the terms of its debt agreements that include the maintenance of certain ratios of working capital, liabilities to net worth and tangible net worth and restricts Wilder capital expenditures in excess of specified limits. Wilder was in compliance with these covenants at December 31, 2004. Failure to comply with these covenants could cause the amounts due under the debt agreements to become currently payable.

Joint Ventures

      We participate in various construction joint venture partnerships in order to share expertise, risk and resources for certain highly complex projects. Generally, each construction joint venture is formed to accomplish a specific project, is jointly controlled by the joint venture partners and is dissolved upon completion of the project. We select our joint venture partners based on our analysis of the prospective venturers’ construction and financial capabilities, expertise in the type of work to be performed and past working relationships with us, among other criteria. The joint venture agreements typically provide that our interests in any profits and assets, and our respective share in any losses and liabilities that may result from the performance of the contract are limited to our stated percentage interest in the project.

      The venture’s contract with the project owner typically requires joint and several liability among the joint venture partners. Our agreements with our joint venture partners provide that each party will assume and pay its full proportionate share of any losses resulting from a project; however, if one of our partners is unable to pay its proportionate share we would be fully liable under our contract with the project owner. Circumstances that could lead to a loss under these guarantee arrangements include a partner’s inability to contribute additional funds to the venture in the event that the project incurred a loss or additional costs that we could incur should the partner fail to provide the services and resources toward project completion that had been committed to in the joint venture agreement.

      Under each joint venture agreement, one partner is designated as the sponsor. The sponsoring partner typically provides all administrative, accounting and most of the project management support for the project and generally receives a fee from the joint venture for these services. We have been designated as the sponsoring partner in certain of our current joint venture projects and are a non-sponsoring partner in others.

      We also participate in various “line item” joint venture agreements under which each partner is responsible for performing certain discrete items of the total scope of contracted work. The revenue for these discrete items is defined in the contract with the project owner and each venture partner bears the profitability risk associated with its own work. All partners in a line item joint venture are jointly and severally liable for completion of the total project under the terms of the contract with the project owner. There is not a single set of books and records for a line item joint venture. Each partner accounts for its items of work individually as it would for any self-performed contract. We account for our portion of these contracts as a project in our accounting system and include receivables and payables associated with our work on our balance sheet.

      Although our agreements with our joint venture partners for both construction joint ventures and line item joint ventures provide that each party will assume and pay its share of any losses resulting from a project, if one of our partners was unable to pay its share we would be fully liable under our contract with the project owner. Circumstances that could lead to a loss under these guarantee arrangements include a partner’s inability to contribute additional funds to the venture in the event that the project incurred a loss or additional costs that we could incur should the partner fail to provide the services and resources toward project completion that had been committed to in the joint venture agreement. At December 31, 2004 approximately $385.8 million of work representing either our partners’ proportionate share or work that our partners’ are directly responsible for in line item joint ventures, had yet to be completed. We have never incurred a loss under these joint and several liability provisions, however, it is possible that we could in the future and such a loss could be significant.

Off-Balance-Sheet Arrangements

      See “Joint Ventures” above.

27


Table of Contents

Recent Accounting Pronouncements

      See Note 1 of the “Notes to the Consolidated Financial Statements” for a description of recent accounting pronouncements, including the expected dates of adoption and effects on our financial position, results of operations and cash flows.

Quarterly Results

      The following table sets forth selected unaudited financial information for the eight quarters in the two-year period ended December 31, 2004. This information has been prepared on the same basis as the audited financial statements and, in the opinion of management, contains all adjustments necessary for a fair presentation thereof.

QUARTERLY FINANCIAL DATA

(Unaudited — In thousands, except per share data)
                                   
2004 Quarters Ended Dec. 31 Sept. 30 June 30 March 31





Revenue
  $ 540,615     $ 699,825     $ 558,754     $ 337,018  
Gross profit
    56,245       95,348       59,744       10,684  
 
As a percent of revenue
    10.4 %     13.6 %     10.7 %     3.2 %
Net income (loss)
    19,525       32,785       13,806       (9,109 )
 
As a percent of revenue
    3.6 %     4.7 %     2.5 %     (2.7 )%
Net income (loss) per share:
                               
 
Basic
  $ 0.48     $ 0.81     $ 0.34     $ (0.23 )
 
Diluted
  $ 0.47     $ 0.80     $ 0.34     $ (0.23 )
Dividends per share
  $ 0.10     $ 0.10     $ 0.10     $ 0.10  
Market price
                               
 
High
  $ 27.90     $ 23.99     $ 24.18     $ 24.61  
 
Low
  $ 22.91     $ 17.17     $ 17.52     $ 20.64  
                                   
2003 Quarters Ended Dec. 31 Sept. 30 June 30 March 31





Revenue
  $ 492,726     $ 580,200     $ 469,405     $ 302,160  
Gross profit
    58,191       82,059       53,183       33,017  
 
As a percent of revenue
    11.8 %     14.1 %     11.3 %     10.9 %
Net income
    13,858       25,834       10,794       10,018  
 
As a percent of revenue
    2.8 %     4.5 %     2.3 %     3.3 %
Net income per share:
                               
 
Basic
  $ 0.34     $ 0.64     $ 0.27     $ 0.25  
 
Diluted
  $ 0.34     $ 0.63     $ 0.26     $ 0.25  
Dividends per share
  $ 0.10     $ 0.10     $ 0.10     $ 0.10  
Market price
                               
 
High
  $ 24.25     $ 21.54     $ 20.43     $ 17.05  
 
Low
  $ 18.66     $ 16.95     $ 15.67     $ 13.56  

      Net income (loss) per share calculations are based on the weighted average common shares outstanding for each period presented. Accordingly, the sum of the quarterly net income (loss) per share amounts may not equal the per share amount reported for the year.

28


Table of Contents

 
Item 7A. Quantitative and Qualitative Disclosures About Market Risk

      We are exposed to financial market risks due largely to changes in interest rates, which we have managed primarily by managing the maturities in our investment portfolio. We currently do not have any material business transactions in foreign currencies.

      The fair value of our short-term held-to-maturity investment portfolio and related income would not be significantly impacted by changes in interest rates since the investment maturities are short and the interest rates are primarily fixed. The fair value of our long-term held-to-maturity investment portfolio may be impacted by changes in interest rates. Our mutual fund portfolio of $22.3 million is exposed to equity price risks.

      We had senior notes payable of $40.0 million at December 31, 2004 which carry a fixed interest rate of 6.54% per annum with principal payments due in nine equal annual installments that began in 2002 and senior notes payable of $75.0 million at December 31, 2004 which carry a fixed interest rate of 6.96% per annum with principal payments due in nine equal annual installments beginning in 2005.

      We had amounts due under our line of credit totaling $25.0 million at December 31, 2004 which bear interest at 6 month LIBOR plus a margin of 1.25%. The interest rate resets every six months and all amounts outstanding are due in June 2006. At December 31, 2004 $10.0 million of the outstanding amount bore interest at 3.76% and the remaining $15.0 million bore interest at 4.04%.

      In February 2003, we entered into two interest rate swap agreements in order to gain access to the lower borrowing rates normally available on floating-rate debt, while avoiding the prepayment and other costs that would be associated with refinancing our long-term fixed-rate debt. The swaps purchased have a combined notional amount of $50 million, a thirty-month term with six-month settlement periods and provide for us to pay variable interest at LIBOR plus set rate spreads and receive fixed interest of between 6.54% and 6.96%. The notional amount does not quantify risk or represent assets or liabilities, but rather, is used in the determination of cash settlement under the swap agreement. As a result of purchasing these swaps, we are exposed to credit losses from any counter-party non-performance; however, we do not anticipate any such losses from these agreements, which are with a major financial institution. The agreements also expose us to interest rate risk should LIBOR rise during the term of the agreements. These swap agreements are accounted for under Statement of Financial Accounting Standards No. 133, “Accounting for Derivative Instruments and Hedging Activities” (“SFAS 133”). Under the provisions of SFAS 133, we initially recorded the interest rate swaps at fair value, and subsequently recorded any changes in fair value in other income, net. Fair value is determined based on quoted market prices, which reflect the difference between estimated future variable-rate payments and future fixed-rate receipts and was a liability of approximately $342,000 at December 31, 2004.

      The table below presents notional amounts, weighted average pay rates, and weighted average receive rates by year for our interest rate swaps (in thousands):

                         
2005 Thereafter Total



Interest Rate Swaps:
                       
Notional Amount
  $ 50,000           $ 50,000  
Weighted Average Pay Rate
    7.23 %           7.23 %
Weighted Average Receive Rate
    6.71 %           6.71 %

29


Table of Contents

      The table below presents principal amounts and related weighted average interest rates by year for our cash and cash equivalents, held-to-maturity investments and significant debt obligations (in thousands):

                                                           
2005 2006 2007 2008 2009 Thereafter Total







Assets
                                                       
Cash, cash equivalents and held-to-maturity investments
  $ 241,565     $ 13,369     $ 268     $ 192                 $ 255,394  
Weighted average interest rate
    2.12 %     3.17 %     2.96 %     4.58 %                 2.18 %
Liabilities
Fixed rate debt
                                                       
 
Senior notes payable
  $ 15,000     $ 15,000     $ 15,000     $ 15,000     $ 15,000     $ 40,000     $ 115,000  
 
Weighted average interest rate
    6.77 %     6.77 %     6.77 %     6.77 %     6.77 %     6.89 %     6.81 %
Variable rate debt
                                                       
 
Revolving line of credit
        $ 25,000                             $ 25,000  
 
Weighted average interest rate
          3.93 %                             3.93 %

      The estimated fair value of our cash, cash equivalents and short-term held-to-maturity investments approximate the principal amounts reflected above based on the generally short maturities of these financial instruments. The estimated fair value of our long-term held-to-maturity investments approximates the principal amounts above due to the relatively minor difference between the effective yields of these investments and rates currently available on similar instruments. Rates currently available to us for debt with similar terms and remaining maturities are used to estimate fair value of existing debt. Based on the lower fixed borrowing rates currently available to us for bank loans with similar terms and average maturities, the fair value of the senior notes payable was approximately $126.1 million as of December 31, 2004 and $129.1 million as of December 31, 2003. The estimated fair value of amounts payable under our revolving line of credit at December 31, 2004 approximates the principal amount reflected above since the variable interest rate approximates the rate currently available to us for a loan with similar terms.

 
Item 8. Consolidated Financial Statements and Supplementary Data

      The following consolidated financial statements of Granite and the auditor’s report are incorporated by reference from Part IV, Item 15(1) and (2):

  Report of Independent Registered Public Accounting Firm
 
  Consolidated Balance Sheets — At December 31, 2004 and 2003
 
  Consolidated Statements of Income — Years Ended December 31, 2004, 2003 and 2002
 
  Consolidated Statements of Shareholders’ Equity — Years Ended December 31, 2004, 2003 and 2002
 
  Consolidated Statements of Cash Flows — Years Ended December 31, 2004, 2003 and 2002
 
  Notes to the Consolidated Financial Statements

      Additionally, a two-year Summary of Quarterly Results (unaudited) is included in “Quarterly Results” under “Management’s Discussion and Analysis of Financial Condition and Results of Operation”.

 
Item 9. Changes in and Disagreements with Accountants on Accounting and Financial Disclosure

      Not applicable.

 
Item 9A. Controls and Procedures

      Evaluation of Disclosure Controls and Procedures: We carried out an evaluation, under the supervision of and with the participation of management, including our Chief Executive Officer and our Chief Financial Officer, of the design and operation of our disclosure controls and procedures (as defined in Rules 13a-15(e)

30


Table of Contents

and 15d-15(e) under the Securities Exchange Act of 1934, as amended (the “Exchange Act”)). Based on this evaluation, our Chief Executive Officer and Chief Financial Officer concluded that, as of December 31, 2004, our disclosure controls and procedures were effective for gathering, analyzing and disclosing the information we are required to disclose in the reports we file under the Exchange Act, within the time periods specified in the Securities and Exchange Commission’s rules and forms.

      Changes in Internal Control Over Financial Reporting: During the fourth quarter of 2004, there have been no significant changes in our internal control over financial reporting that have materially affected, or were reasonably likely to materially affect, our internal control over financial reporting.

      Management’s Report on Internal Control Over Financial Reporting: Our management is responsible for establishing and maintaining adequate internal control over financial reporting, as such term is defined in Exchange Act Rules 13a-15(f) and 15(d)-15(f). Under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer, management conducted an evaluation of the effectiveness of our internal control over financial reporting based on the framework in “Internal Control — Integrated Framework” issued by the Committee of Sponsoring Organizations of the Treadway Commission. Based on this evaluation under the framework in “Internal Control — Integrated Framework”, our management concluded that our internal control over financial reporting was effective as of December 31, 2004.

      Our management’s assessment of the effectiveness of our internal control over financial reporting as of December 31, 2004 has been audited by PricewaterhouseCoopers LLP, an independent registered public accounting firm, as stated in their report which is included herein.

Item 9B.     Other Information

      Not applicable.

PART III

      Certain information required by Part III is omitted from this Report. We will file our definitive proxy statement for our Annual Meeting of Shareholders to be held on May 23, 2005 (the “Proxy Statement”) pursuant to Regulation 14A not later than 120 days after the end of the fiscal year covered by this Report, and certain information included therein is incorporated herein by reference.

 
Item 10. Directors and Executive Officers of the Registrant

      For information regarding our Directors and compliance with Section 16(a) of the Securities Exchange Act of 1934, we direct you to the sections entitled “Election Of Directors” and “Section 16(a) Beneficial Ownership Reporting Compliance,” respectively, in the Proxy Statement. For information regarding our Audit/ Compliance Committee’s financial expert and our Committees of the Board we direct you to the section captioned “Committees of the Board” in the Proxy Statement. For information regarding our Nomination Policy we direct you to the section captioned “Board of Directors’ Nomination Policy” in the Proxy Statement. We will deliver the Proxy Statement to our shareholders in connection with our Annual Meeting of Shareholders to be held on May 23, 2005. This information is incorporated herein by reference. Information regarding our Executive Officers is contained in the section entitled “Executive Officers of the Registrant,” in Part I of this Report.

 
Item 11. Executive Compensation

      For information regarding our Executive Compensation, we direct you to the section captioned “Executive Compensation and Other Matters” in the Proxy Statement we will deliver to our shareholders in connection with our Annual Meeting of Shareholders to be held on May 23, 2005. This information is incorporated herein by reference.

31


Table of Contents

 
Item 12. Security Ownership of Certain Beneficial Owners and Management

      This information is located in the section captioned “Stock Ownership of Certain Beneficial Owners and Management and Equity Compensation Plan Information,” which will appear in the Proxy Statement we will deliver to our shareholders in connection with our Annual Meeting of Shareholders to be held on May 23, 2005. This information is incorporated herein by reference.

 
Item 13. Certain Relationships and Related Transactions

      You will find this information in the section captioned “Certain Relationships and Related Transactions,” which will appear in the Proxy Statement we will deliver to our shareholders in connection with our Annual Meeting of Shareholders to be held on May 23, 2005. This information is incorporated herein by reference.

 
Item 14. Principal Accountant Fees and Services

      You will find this information in the subsection captioned “Principal Accountant Fees and Services,” under the section “Report of the Audit/ Compliance Committee,” which will appear in the Proxy Statement we will deliver to our shareholders in connection with our Annual Meeting of Shareholders to be held on May 23, 2005. This information is incorporated herein by reference.

PART IV

 
Item 15. Exhibits and Financial Statement Schedules

      The following documents are filed as part of this Report:

  1.  Financial Statements. The following consolidated financial statements and related documents are filed as part of this Report:

             
Page

    Report of Independent Registered Public Accounting Firm     F-1  
    Consolidated Balance Sheets at December 31, 2004 and 2003     F-3  
    Consolidated Statements of Income for the Years Ended        
      December 31, 2004, 2003 and 2002     F-4  
    Consolidated Statements of Shareholders’ Equity for the        
      Years Ended December 31, 2004, 2003 and 2002     F-5  
    Consolidated Statements of Cash Flows for the Years Ended        
      December 31, 2004, 2003 and 2002     F-6  
    Notes to the Consolidated Financial Statements     F-7 to F-26  

   2.  Financial Statement Schedule. The following financial statement schedule of Granite for the years ended December 31, 2004, 2003 and 2002 is filed as part of this report and should be read in conjunction with the consolidated financial statements of Granite.

             
Schedule Page


    Schedule II — Schedule of Valuation and Qualifying Accounts     S-1  

  Schedules not listed above have been omitted because the required information is either not material, not applicable or is shown in the consolidated financial statements or notes thereto.

   3.  Exhibits. The Exhibits listed in the accompanying Exhibit Index are filed or incorporated by reference as part of this Report.

32


Table of Contents

REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

To the Shareholders and Board of Directors of

Granite Construction Incorporated:

      We have completed an integrated audit of Granite Construction Incorporated’s 2004 consolidated financial statements and of its internal control over financial reporting as of December 31, 2004 and audits of its 2003 and 2002 consolidated financial statements in accordance with the standards of the Public Company Accounting Oversight Board (United States). Our opinions, based on our audits, are presented below.

Consolidated financial statements and financial statement schedule

      In our opinion, the consolidated financial statements listed in the index appearing under Item 15(1) present fairly, in all material respects, the financial position of Granite Construction Incorporated and its subsidiaries at December 31, 2004 and 2003, and the results of their operations and their cash flows for each of the three years in the period ended December 31, 2004 in conformity with accounting principles generally accepted in the United States of America. In addition, in our opinion, the financial statement schedule listed in the index appearing under Item 15(2) presents fairly, in all material respects, the information set forth therein when read in conjunction with the related consolidated financial statements. These financial statements and financial statement schedule are the responsibility of the Company’s management. Our responsibility is to express an opinion on these financial statements and financial statement schedule based on our audits. We conducted our audits of these statements in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement. An audit of financial statements includes examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements, assessing the accounting principles used and significant estimates made by management, and evaluating the overall financial statement presentation. We believe that our audits provide a reasonable basis for our opinion.

      As discussed in Notes 1 and 5 to the Consolidated Financial Statements, effective January 1, 2004 the Company adopted the provisions of Financial Accounting Standards Board Interpretation No. 46 (revised December 2003), “Consolidation of Variable Interest Entities” an interpretation of Accounting Research Bulletin No. 51, “Consolidated Financial Statements.”

Internal control over financial reporting

      Also, in our opinion, management’s assessment, included in Management’s Report on Internal Control Over Financial Reporting appearing under Item 9A, that the Company maintained effective internal control over financial reporting as of December 31, 2004 based on criteria established in Internal Control — Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO), is fairly stated, in all material respects, based on those criteria. Furthermore, in our opinion, the Company maintained, in all material respects, effective internal control over financial reporting as of December 31, 2004, based on criteria established in Internal Control — Integrated Framework issued by the COSO. The Company’s management is responsible for maintaining effective internal control over financial reporting and for its assessment of the effectiveness of internal control over financial reporting. Our responsibility is to express opinions on management’s assessment and on the effectiveness of the Company’s internal control over financial reporting based on our audit. We conducted our audit of internal control over financial reporting in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether effective internal control over financial reporting was maintained in all material respects. An audit of internal control over financial reporting includes obtaining an understanding of internal control over financial reporting, evaluating management’s assessment, testing and evaluating the design and operating effectiveness of internal control, and performing such other procedures as we consider necessary in the circumstances. We believe that our audit provides a reasonable basis for our opinions.

F-1


Table of Contents

      A company’s internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company’s internal control over financial reporting includes those policies and procedures that (i) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (ii) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (iii) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company’s assets that could have a material effect on the financial statements.

      Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.

  PRICEWATERHOUSECOOPERS LLP

San Jose, California

March 3, 2005

F-2


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

CONSOLIDATED BALANCE SHEETS

                     
December 31,

2004 2003


(In thousands, except
share and per share data)
ASSETS
Current assets
               
 
Cash and cash equivalents
  $ 161,627     $ 69,919  
 
Short-term marketable securities
    102,237       90,869  
 
Accounts receivable, net
    357,842       288,210  
 
Costs and estimated earnings in excess of billings
    54,384       31,189  
 
Inventories
    31,711       29,878  
 
Deferred income taxes
    21,012       22,421  
 
Equity in construction joint ventures
    20,895       42,250  
 
Other current assets
    75,630       43,915  
     
     
 
   
Total current assets
    825,338       618,651  
     
     
 
Property and equipment, net
    376,197       344,734  
     
     
 
Long-term marketable securities
    13,828       41,197  
     
     
 
Investments in affiliates
    10,725       18,295  
     
     
 
Other assets
    51,866       37,533  
     
     
 
    $ 1,277,954     $ 1,060,410  
     
     
 
LIABILITY AND SHAREHOLDERS’ EQUITY
 
Current liabilities
               
 
Current maturities of long-term debt
  $ 15,861     $ 8,182  
 
Accounts payable
    191,782       135,468  
 
Billings in excess of costs and estimated earnings
    144,401       99,337  
 
Accrued expenses and other current liabilities
    117,367       100,717  
     
     
 
   
Total current liabilities
    469,411       343,704  
     
     
 
Long-term debt
    148,503       126,708  
     
     
 
Other long-term liabilities
    40,641       29,938  
     
     
 
Deferred income taxes
    44,135       44,297  
     
     
 
Commitments and contingencies
               
Minority interest in consolidated subsidiaries
    24,790       10,872  
     
     
 
Shareholders’ equity
               
 
Preferred stock, $0.01 par value, authorized 3,000,000 shares, none outstanding
           
 
Common stock, $0.01 par value, authorized 100,000,000 shares; issued and outstanding 41,612,319 shares in 2004 and 41,528,317 in 2003
    416       415  
 
Additional paid-in capital
    76,766       73,651  
 
Retained earnings
    482,635       442,272  
 
Accumulated other comprehensive income
    1,475       76  
     
     
 
      561,292       516,414  
 
Unearned compensation
    (10,818 )     (11,523 )
     
     
 
      550,474       504,891  
     
     
 
    $ 1,277,954     $ 1,060,410  
     
     
 

The accompanying notes are an integral part of these consolidated financial statements.

F-3


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

CONSOLIDATED STATEMENTS OF INCOME

                               
Years Ended December 31,

2004 2003 2002



(In thousands, except per share data)
Revenue:
                       
 
Construction
  $ 1,871,859     $ 1,591,746     $ 1,537,009  
 
Material sales
    264,353       252,745       227,733  
     
     
     
 
   
Total revenue
    2,136,212       1,844,491       1,764,742  
     
     
     
 
Cost of revenue:
                       
 
Construction
    1,701,277       1,413,538       1,351,570  
 
Material sales
    212,914       204,503       188,588  
     
     
     
 
   
Total cost of revenue
    1,914,191       1,618,041       1,540,158  
     
     
     
 
     
Gross Profit
    222,021       226,450       224,584  
General and administrative expenses
    157,035       151,879       146,467  
Gain on sales of property and equipment
    18,566       4,714       2,128  
     
     
     
 
     
Operating income
    83,552       79,285       80,245  
     
     
     
 
Other income (expense):
                       
 
Interest income
    7,962       6,422       10,048  
 
Interest expense
    (7,191 )     (8,577 )     (9,162 )
 
Equity in income of affiliates
    6,162       17,657       3,366  
 
Other, net
    4,439       2,738       (1,758 )
     
     
     
 
      11,372       18,240       2,494  
     
     
     
 
     
Income before provision for income taxes and minority interest
    94,924       97,525       82,739  
Provision for income taxes
    28,477       35,304       29,951  
     
     
     
 
     
Income before minority interest
    66,447       62,221       52,788  
Minority interest in consolidated subsidiaries
    (9,440 )     (1,717 )     (3,509 )
     
     
     
 
     
Net income
  $ 57,007     $ 60,504     $ 49,279  
     
     
     
 
Net income per share
                       
 
Basic
  $ 1.41     $ 1.51     $ 1.23  
 
Diluted
  $ 1.39     $ 1.48     $ 1.21  
Weighted average shares of common stock
                       
 
Basic
    40,390       40,175       40,016  
 
Diluted
    41,031       40,808       40,723  
Dividends per share
  $ 0.40     $ 0.40     $ 0.32  
     
     
     
 

The accompanying notes are an integral part of these consolidated financial statements.

F-4


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

CONSOLIDATED STATEMENTS OF SHAREHOLDERS’ EQUITY

                                                             
Accumulated
Additional Other
Years Ended December 31, Outstanding Common Paid-in Retained Comprehensive Unearned
2002, 2003 and 2004 Shares Stock Capital Earnings Income (Loss) Compensation Total








(In thousands, except share data)
Balances, December 31, 2001
    41,089,487     $ 411     $ 62,380     $ 367,546     $ (440 )   $ (11,395 )   $ 418,502  
Comprehensive income:
                                                       
 
Net income
                      49,279                      
 
Other comprehensive income:
                                                       
   
Changes in net unrealized losses on investments
                            (962 )              
 
Total comprehensive income
                                                    48,317  
Restricted stock issued
    270,057       3       6,141                   (6,318 )     (174 )
Amortized restricted stock
                                  5,798       5,798  
Repurchase of common stock
    (624,531 )     (6 )     (6,525 )     (5,224 )                 (11,755 )
Cash dividends on common stock
                      (13,218 )                 (13,218 )
Common stock contributed to ESOP
    191,800       2       3,987                         3,989  
Warrants exercised
    322,950       3       2,875                         2,878  
Stock options exercised and other
    7,252             532                         532  
     
     
     
     
     
     
     
 
Balances, December 31, 2002
    41,257,015       413       69,390       398,383       (1,402 )     (11,915 )     454,869  
Comprehensive income:
                                                       
 
Net income
                      60,504                      
 
Other comprehensive income:
                                                       
   
Changes in net unrealized gains on investments
                            1,478                
 
Total comprehensive income
                                                    61,982  
Restricted stock issued
    349,090       4       5,202                   (5,559 )     (353 )
Amortized restricted stock
                                  5,951       5,951  
Repurchase of common stock
    (82,695 )     (2 )     (1,314 )                       (1,316 )
Cash dividends on common stock
                      (16,615 )                 (16,615 )
Stock options exercised and other
    4,907             373                         373  
     
     
     
     
     
     
     
 
Balances, December 31, 2003
    41,528,317       415       73,651       442,272       76       (11,523 )     504,891  
Comprehensive income:
                                                       
 
Net income
                      57,007                      
 
Other comprehensive income:
                                                       
   
Changes in net unrealized gains on investments
                            1,399                
 
Total comprehensive income
                                                    58,406  
Restricted stock issued
    166,650       2       4,367                   (5,306 )     (937 )
Amortized restricted stock
                                  6,011       6,011  
Repurchase of common stock
    (293,239 )     (3 )     (6,424 )                       (6,427 )
Cash dividends on common stock
                        (16,644 )                 (16,644 )
Common stock contributed to ESOP
    192,000       2       3,987                         3,989  
Stock options exercised and other
    18,591             1,185                         1,185  
     
     
     
     
     
     
     
 
Balances, December 31, 2004
    41,612,319     $ 416     $ 76,766     $ 482,635     $ 1,475     $ (10,818 )   $ 550,474  
     
     
     
     
     
     
     
 

The accompanying notes are an integral part of these consolidated financial statements.

F-5


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

CONSOLIDATED STATEMENTS OF CASH FLOWS

                               
Years Ended December 31,

2004 2003 2002



(In thousands)
Operating Activities
                       
 
Net income
  $ 57,007     $ 60,504     $ 49,279  
 
Adjustments to reconcile net income to net cash provided by operating activities:
                       
   
Depreciation, depletion and amortization
    62,459       65,693       58,668  
   
Gain on sales of property and equipment
    (18,566 )     (4,714 )     (2,128 )
   
Change in deferred income taxes
    (5,868 )     4,089       (3,311 )
   
Amortization of unearned compensation
    6,011       5,951       5,798  
   
Common stock contributed to ESOP
    3,989             3,989  
   
Minority interest in consolidated subsidiaries
    9,440       1,717       3,509  
   
Equity in income of affiliates
    (6,162 )     (17,657 )     (3,366 )
   
Gain on sale of equity investment
    (3,288 )     (1,853 )      
 
Changes in assets and liabilities, net of the effects of acquisitions and FIN 46 consolidations:
                       
   
Accounts receivable
    (28,222 )     (22,314 )     21,882  
   
Inventories
    (1,833 )     106       (1,352 )
   
Equity in construction joint ventures
    (208 )     (17,921 )     (1,256 )
   
Other assets
    (23,699 )     (29,708 )     (616 )
   
Accounts payable
    38,431       16,655       (23,113 )
   
Billings in excess of costs and estimated earnings, net
    (25,037 )     5,389       (6,204 )
   
Accrued expenses and other liabilities
    14,779       11,652       2,266  
     
     
     
 
     
Net cash provided by operating activities
    79,233       77,589       104,045  
     
     
     
 
Investing Activities
                       
 
Purchases of marketable securities
    (96,975 )     (190,957 )     (494,633 )
 
Maturities and sales of marketable securities
    113,243       191,863       430,549  
 
Additions to property and equipment
    (89,636 )     (62,805 )     (57,415 )
 
Proceeds from sales of property and equipment
    24,389       8,498       6,029  
 
Proceeds from sales of equity investment
    7,463       6,033       13,051  
 
Distributions from affiliates, net
    9,308       14,152       2,447  
 
Acquisition of businesses, net of cash received
                (36,034 )
 
Acquisition of minority interest
    (9,219 )            
 
Other investing activities
          177       1,896  
     
     
     
 
     
Net cash used by investing activities
    (41,427 )     (33,039 )     (134,110 )
     
     
     
 
Financing Activities
                       
 
Proceeds from long-term debt
    70,703       20,480       5,547  
 
Repayments of long-term debt
    (52,142 )     (31,511 )     (25,195 )
 
Stock options exercised
    161       43       75  
 
Repurchase of common stock
    (6,427 )     (1,316 )     (11,755 )
 
Dividends paid
    (16,636 )     (15,763 )     (13,197 )
 
Proceeds from exercise of warrants
                2,878  
 
Contributions from minority partners
    5,601       1,548        
 
Distributions to minority partners
    (17,229 )     (420 )      
 
Other financing activities
    157       276       (1,430 )
     
     
     
 
     
Net cash used in financing activities
    (15,812 )     (26,663 )     (43,077 )
     
     
     
 
Increase (decrease) in cash and cash equivalents
    21,994       17,887       (73,142 )
Cash and cash equivalent added in FIN 46 consolidations
    69,714              
Cash and cash equivalents at beginning of year
    69,919       52,032       125,174  
     
     
     
 
Cash and cash equivalents at end of year
  $ 161,627     $ 69,919     $ 52,032  
     
     
     
 
Supplementary Information
                       
 
Cash paid during the period for:
                       
   
Interest
  $ 7,000     $ 8,935     $ 9,604  
   
Income taxes
    29,557       30,096       28,599  
 
Non-cash investing and financing activity:
                       
   
Restricted stock issued for services, net
  $ 4,369     $ 5,206     $ 6,144  
   
Dividends accrued but not paid
    4,161       4,153       3,301  
   
Financed acquisition of assets
    14,680       4,004        
   
Notes received from sale of assets
    8,893              
   
Subsidiary preferred stock exchanged for subsidiary common stock
                3,299  
   
Subsidiary notes payable issued in exchange for redemption of subsidiary common stock
          897       1,868  

The accompanying notes are an integral part of these consolidated financial statements.

F-6


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 
1. Summary of Significant Accounting Policies

      Description of Business: Granite Construction Incorporated is a heavy civil contractor engaged in the construction of highways, dams, airport runways, mass transit facilities, real estate site development and other infrastructure related projects with offices in Alaska, Arizona, California, Florida, Minnesota, Nevada, New York, Oregon, Texas, Utah and Washington. Unless otherwise indicated, the terms “we,” “us,” “our,” and “Granite” refer to Granite Construction Incorporated and its consolidated subsidiaries.

      Principles of Consolidation: The consolidated financial statements include the accounts of Granite Construction Incorporated and its wholly owned and majority owned subsidiaries. All material inter-company transactions and accounts have been eliminated. We use the equity method of accounting for affiliated companies where we have the ability to exercise significant influence, but not control. Additionally, we participate in joint ventures with other construction companies. We have consolidated these joint ventures where we have determined that through our participation in these joint ventures that we have a variable interest and are the primary beneficiary as defined by Financial Accounting Standards Board Interpretation No. 46 (revised December 2003) “Consolidation of Variable Interest Entities,” (“FIN 46”). Where we have determined we are not the primary beneficiary we account for our share of the operations of jointly controlled ventures on a pro rata basis in the consolidated statements of income and as a single line item in the consolidated balance sheets in accordance with Emerging Issues Task Force Issue 00-01, “Investor Balance Sheet and Income Statement Display under the Equity Method for Investments in Certain Partnerships and Other Ventures.”

      Use of Estimates in the Preparation of Financial Statements: The preparation of financial statements in conformity with accounting principles generally accepted in the United States of America requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosure of contingent assets and liabilities at the date of the financial statements and the reported amounts of revenues and expenses during the reporting period. Actual results could differ from those estimates.

      Revenue Recognition: The majority of our contracts with our customers are either “fixed unit price” or “fixed price”. Under fixed unit price contracts, we are committed to provide materials or services required by a project at fixed unit prices (for example, dollars per cubic yard of concrete poured or cubic yards of earth excavated). While the fixed unit price contract shifts the risk of estimating the quantity of units required for a particular project to the customer, any increase in our unit cost over the expected unit cost in the bid, whether due to inflation, inefficiency, faulty estimates or other factors, is borne by us unless otherwise provided in the contract. Fixed price contracts are priced on a lump-sum basis under which we bear the risk that we may not be able to perform all the work profitably for the specified contract amount. The percentage of fixed price contracts in our backlog has increased from approximately 51.0% at December 31, 2003 to approximately 58.0% at December 31, 2004. All state and federal government contracts and many of our other contracts provide for termination of the contract for the convenience of the party contracting with us, with provisions to pay us for work performed through the date of termination.

      We use the percentage of completion accounting method for construction contracts in accordance with the American Institute of Certified Public Accountants Statement of Position 81-1, “Accounting for Performance of Construction-Type and Certain Production-Type Contracts.” Revenue and earnings on construction contracts, including construction joint ventures, are recognized on the percentage of completion method in the ratio of costs incurred to estimated final costs. Revenue in an amount equal to cost incurred is recognized prior to contracts reaching 25% completion. The related profit is deferred until the period in which such percentage completion is attained. It is our judgment that until a project reaches 25% completion, there is insufficient information to determine what the estimated profit on the project will be with a reasonable level of assurance. Revenue from contract claims is recognized when we have a signed settlement agreement and payment is assured. Revenue from contract change orders, which occur in most large projects, is recognized when the owner has agreed to the change order in writing. Provisions are recognized in the statement of

F-7


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

income for the full amount of estimated losses on uncompleted contracts whenever evidence indicates that the estimated total cost of a contract exceeds its estimated total revenue.

      Contract cost consists of direct costs on contracts, including labor and materials, amounts payable to subcontractors, direct overhead costs and equipment expense (primarily depreciation, fuel, maintenance and repairs). Depreciation is provided using accelerated methods for construction equipment. Contract cost is recorded as incurred and revisions in contract revenue and cost estimates are reflected in the accounting period when known. The 25% threshold is applied to all percentage of completion projects without exception unless and until we project a loss on the project, in which case the estimated loss is immediately recognized.

      Revenue from the sale of materials is recognized when delivery occurs and risk of ownership passes to the customer.

      Balance Sheet Classifications: We include in current assets and liabilities amounts receivable and payable under construction contracts that may extend beyond one year. Additionally, we include the cost of property purchased for development and sale in current assets. A one-year time period is used as the basis for classifying all other current assets and liabilities.

      Cash and Cash Equivalents: Cash equivalents are securities having maturities of three months or less from the date of purchase.

      Marketable Securities: We determine the classification of our marketable securities at the time of purchase and reevaluate these determinations at each balance sheet date. Debt securities are classified as held-to-maturity when we have the positive intent and ability to hold the securities to maturity. Held-to-maturity investments are stated at amortized cost. Debt securities for which we do not have the positive intent or ability to hold to maturity are classified as available-for-sale, along with any investments in equity securities. Securities available-for-sale are carried at fair value with the unrealized gains and losses, net of income taxes, reported as a separate component of other comprehensive income until realized. We have no investments that qualify as trading.

      The amortized cost of debt securities is adjusted for amortization of premiums and accretion of discounts to maturity, which is included in interest income. Realized gains and losses are included in other income, net. The cost of securities sold is based on the specific identification method.

      Financial Instruments: The carrying value of marketable securities approximates their fair value as determined by market quotes. Rates currently available to us for debt with similar terms and remaining maturities are used to estimate the fair value of existing debt. The carrying value of receivables and other amounts arising out of normal contract activities, including retentions, which may be settled beyond one year, is estimated to approximate fair value.

      Concentrations: We maintain the majority of cash balances and all of our marketable securities with several financial institutions. We invest with high credit quality financial institutions and, by policy, limit the amount of credit exposure to any financial institution. A significant portion of our labor force is subject to collective bargaining agreements. Collective bargaining agreements covering approximately 4.0% of our labor force at December 31, 2004 will expire during 2005.

      Revenue earned by both the Branch Division and the Heavy Construction Division from federal, state and local government agencies amounted to $1,553.1 million (72.7%) in 2004, $1,339.1 million (72.6%) in 2003 and $1,263.4 million (71.6%) in 2002. California Department of Transportation represented $134.5 million (6.3%) in 2004, $166.5 million (9.0%) in 2003 and $209.6 million (11.9%) in 2002 of total revenue. At December 31, 2004 and 2003, we had significant amounts receivable from these agencies. We perform ongoing credit evaluations of our customers and generally do not require collateral, although the law provides us the ability to file mechanics’ liens on real property improved for private customers in the event of non-

F-8


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

payment by such customers. We maintain reserves for potential credit losses and such losses have been within management’s expectations. We have no foreign operations.

      Inventories: Inventories consist primarily of quarry products valued at the lower of average cost or market.

      Property and Equipment: Property and equipment are stated at cost. Depreciation for construction equipment, and office furniture and equipment is primarily provided using accelerated methods over lives ranging from three to ten years and the straight-line method over lives from three to twenty years for the remaining depreciable assets. We believe that accelerated methods best approximate the service provided by the construction equipment, and office furniture and equipment. Depletion of quarry property is based on the usage of depletable reserves. We frequently sell property and equipment that has reached the end of its useful life or no longer meets our needs, including depleted quarry property. Such property is held in property and equipment until sold. The cost and accumulated depreciation or depletion of property sold or retired is removed from the accounts and gains or losses, if any, are reflected in earnings for the period. We capitalized interest costs related to certain self-constructed assets of $1.9 million in 2004, $823,000 in 2003 and $218,000 in 2002. Maintenance and repairs are charged to operations as incurred.

      Long-Lived Assets: Long-lived assets held and used by us are reviewed for impairment whenever events or changes in circumstances indicate that the carrying amount of an asset may not be recoverable. An impairment loss is recorded when the asset’s carrying value exceeds its estimated undiscounted future cash flows.

      We perform goodwill impairment tests annually during our fourth quarter and more frequently when events and circumstances occur that indicate a possible impairment of goodwill. In determining whether there is an impairment of goodwill, we calculate the estimated fair value of the reporting unit in which the goodwill is recorded using a discounted future cash flow method. We then compare the resulting fair value to the net book value of the reporting unit, including goodwill. If the net book value of a reporting unit exceeds its fair value, we measure the amount of the impairment loss by comparing the implied fair value of the reporting unit’s goodwill with the carrying amount of that goodwill. To the extent that the carrying amount of a reporting unit’s goodwill exceeds its implied fair value, we recognize a goodwill impairment loss. We performed our annual impairment test in 2004 and we determined that no impairment had occurred.

      Other intangible assets include covenants not to compete, permits and trade name which are being amortized on a straight-line basis over terms from two to fifteen years.

      Reclamation Costs: We account for the costs related to legal obligations to reclaim aggregate mining sites and other facilities in accordance with Statement of Financial Accounting Standards No. 143 (“SFAS 143”), “Accounting for Asset Retirement Obligations,” which was effective for our fiscal year beginning January 1, 2003. Accordingly, we record our estimated reclamation liability when incurred, capitalize the estimated liability as part of the related asset’s carrying amount and allocate it to expense over the asset’s useful life. The adoption of SFAS 143 in 2003 did not have a material effect on our financial position, results of operations or cash flows.

      Warranties: Many of our construction contracts contain warranty provisions covering defects in equipment, materials, design or workmanship that generally run from six months to one year after our customer accepts the project. Because of the nature of our projects, including contract owner inspections of the work both during construction and prior to acceptance, we have not experienced material warranty costs for these short-term warranties and therefore, do not believe an accrual for these costs is necessary. Certain construction contracts carry longer warranty periods, ranging from two to ten years for which we have accrued an estimate of warranty cost. The warranty cost is estimated based on our experience with the type of work and

F-9


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

any known risks relative to the project. However, these accrued costs were not material at December 31, 2004 or December 31, 2003.

      Accrued Insurance Costs: We carry insurance policies to cover various risks, primarily general liability and workers compensation, under which we are liable to reimburse the insurance company for a portion of each claim paid. The amounts that we are liable for generally range from the first $250,000 to $1.0 million per occurrence. We accrue for the estimated ultimate liability for incurred losses, both reported and unreported, using actuarial methods based on historic trends modified, if necessary, by recent events.

      Stock Option Compensation: As more fully described in Note 12, we maintain an equity incentive plan that allows for the grant of incentive and nonqualified stock options to employees and our Board of Directors. We account for options granted under this plan under the fair value recognition provisions of Statement of Financial Accounting Standard No. 123, “Accounting for Stock-Based Compensation” (“SFAS 123”).

      Income Taxes: Deferred taxes are provided on a liability method whereby deferred tax assets are recognized for deductible temporary differences and operating loss carry-forwards and deferred tax liabilities are recognized for taxable temporary differences. Temporary differences are the differences between the reported amounts of assets and liabilities and their tax bases. Deferred tax assets are reduced by a valuation allowance when, in the opinion of management, it is more likely than not that some portion or all of the deferred tax assets will not be realized. Deferred tax assets and liabilities are adjusted for the effects of changes in tax laws and rates on the date of enactment.

      Computation of Earnings Per Share: Basic earnings per share is computed by dividing income available to common shareholders by the weighted average number of common shares outstanding, excluding restricted common stock. Diluted earnings per share are computed giving effect to all dilutive potential common shares that were outstanding during the period. Dilutive potential common shares consist of the incremental common shares issuable upon the exercise of stock options, warrants and upon the vesting of restricted common stock.

      Reclassifications: Certain financial statement items have been reclassified to conform to the current year’s format. These reclassifications had no impact on previously reported net income, financial position or cash flows.

      Recent Accounting Pronouncements: In January 2003, the Financial Accounting Standards Board (“FASB”) issued Interpretation No. 46, “Consolidation of Variable Interest Entities” which is an interpretation of Accounting Research Bulletin No. 51, “Consolidated Financial Statements” and requires a variable interest entity (“VIE”) to be consolidated by a company that is considered to be the primary beneficiary of that VIE. In December 2003, the FASB issued Interpretation No. 46 (revised December 2003), “Consolidation of Variable Interest Entities” (“FIN 46”) to address certain implementation issues.

      We were required to adopt FIN 46 no later than the end of the first interim or annual reporting period ending after March 15, 2004. As is common in the construction industry, we have entered into certain construction contracts with third parties through joint ventures and we have determined that certain of these joint ventures are VIEs. As a result of our adoption of FIN 46, we have consolidated all VIEs in which we are the primary beneficiary prospectively as of January 1, 2004 (see Note 5). We continue to account for all other such joint ventures in accordance with Emerging Issues Task Force Issue 00-01, “Investor Balance Sheet and Income Statement Display under the Equity Method for Investments in Certain Partnerships and Other Ventures.”

      In December, 2004, FASB issued Statement No. 123 (revised 2004), “Share-Based Payment” (“SFAS 123-R”), which is a revision of SFAS 123. SFAS 123-R supersedes APB Opinion No. 25, “Accounting for Stock Issued to Employees”, and amends FASB Statement No. 95, “Statement of Cash Flows”. Generally, the approach to accounting for share-based payments in SFAS 123-R is similar to the approach described in SFAS 123. However, SFAS 123-R requires all share-based payments to employees,

F-10


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

including grants of employee stock options, to be recognized in the financial statements based on their fair values (i.e., pro forma disclosure is no longer an alternative to financial statement recognition). SFAS 123-R is effective for financial statements at both interim and annual periods beginning after June 15, 2005. The adoption of SFAS 123-R is not expected to have a material effect on our financial position, results of operations or cash flows.

 
2. Change in Accounting Estimate

      The decrease in HCD gross profit as a percent of revenue in 2004 as compared with 2003 was due primarily to downward revisions in certain profit forecasts due to additional estimated costs to complete. The net impact of these estimate changes on recognized gross profit during 2004 was a reduction in gross profit of approximately $40.0 million, of which approximately $10.0 million was recognized in the fourth quarter. Included in the net impact of this change in estimate in both the quarter and year ended December 31, 2004 was approximately $2.0 million representing our partners’ proportionate share that has been newly consolidated during 2004 (see Note 5). The majority of this change in estimate related to downward revisions of ten projects. The amount attributable to each project ranged from approximately $1.4 million to $11.6 million. The cost estimate changes resulted from a variety of factors including costs associated with added scope changes, extended overhead due to owner and weather delays, design problems on design/build projects, subcontractor performance issues, changes in productivity expectations and higher estimated liquidated damages on two projects. At December 31, 2004, six of these projects were greater than 90% complete, two were greater than 85% complete and the remaining two projects averaged 59% complete. Although we believe that our estimates of the cost to complete these projects are achievable, it is possible that the actual cost to complete will be greater than our current estimate and any future estimate changes could be significant.

 
3.  Marketable Securities

      The carrying amounts of marketable securities were as follows at December 31, 2004 and 2003 (in thousands):

                                                   
Held-to-Maturity Available-for-Sale Total



2004 2003 2004 2003 2004 2003






Securities classified as current:
                                               
 
U.S. Government and agency obligations
  $ 25,213     $ 27,380     $     $     $ 25,213     $ 27,380  
 
Commercial paper
    32,931       41,526                   32,931       41,526  
 
Municipal bonds
    18,966       7,954                   18,966       7,954  
 
Domestic banker’s acceptance
    2,829                         2,829        
 
Mutual funds
                22,298       14,009       22,298       14,009  
     
     
     
     
     
     
 
      79,939       76,860       22,298       14,009       102,237       90,869  
     
     
     
     
     
     
 
Securities classified as long-term:
                                               
 
U.S. Government and agency obligations
    6,538       20,603                   6,538       20,603  
 
Municipal bonds
    7,290       20,594                   7,290       20,594  
     
     
     
     
     
     
 
      13,828       41,197                   13,828       41,197  
     
     
     
     
     
     
 
Total marketable securities
  $ 93,767     $ 118,057     $ 22,298     $ 14,009     $ 116,065     $ 132,066  
     
     
     
     
     
     
 

      Held-to-maturity investments are carried at amortized cost, which approximates fair value. Unrealized holding gains and losses for all debt securities were insignificant for the years ended December 31, 2004 and

F-11


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

2003. We recognized unrealized holding gains of $2,304 ($1,399 after tax), $2,310 ($1,478 after tax) and unrealized holding losses of $1,481 ($962 after tax) related to our available-for-sale investment in mutual funds as a component of the other comprehensive income for the years ended December 31, 2004, 2003 and 2002, respectively. Included in our mutual fund portfolio at December 31, 2003 were investments with a fair value of $8.6 million that had unrealized losses of $0.4 million. Each of these investments had been in a loss position for more than 12 months at December 31, 2003. We evaluated the nature of these investments and the severity and duration of the impairments and concluded that the impairments were not other than temporary. At December 31, 2004, none of our investments in our mutual fund portfolio were in an unrealized loss position.

      At December 31, 2004, scheduled maturities of held-to-maturity investments were as follows (in thousands):

         
Within one year
  $ 79,939  
After one year through five years
    13,828  
     
 
    $ 93,767  
     
 

      For the years ended December 31, 2004 and 2003, changes in our marketable securities were as follows (in thousands):

                                                 
December 31, 2004 December 31, 2003


Held-to- Available- Held-to- Available-
Maturity for-Sale Total Maturity for-Sale Total






Purchases
  $ 88,222     $ 8,753     $ 96,975     $ 188,599     $ 2,358     $ 190,957  
Maturities and sales
    (110,475 )     (2,768 )     (113,243 )     (191,863 )           (191,863 )
Amortization and other
    (2,037 )           (2,037 )                  
Unrealized gains
          2,304       2,304             2,310       2,310  
     
     
     
     
     
     
 
Net Change
  $ (24,290 )   $ 8,289     $ (16,001 )   $ (3,264 )   $ 4,668     $ 1,404  
     
     
     
     
     
     
 
 
4.  Accounts Receivable
                   
December 31,

2004 2003


(In thousands)
Construction contracts:
               
 
Completed and in progress
  $ 197,995     $ 179,019  
 
Retentions
    121,876       76,508  
     
     
 
      319,871       255,527  
Construction material sales
    31,157       29,690  
Other
    8,668       4,238  
     
     
 
      359,696       289,455  
Less: allowance for doubtful accounts
    1,854       1,245  
     
     
 
    $ 357,842     $ 288,210  
     
     
 

      Accounts receivable includes amounts billed and billable for public and private contracts and do not bear interest. The balances billed but not paid by customers pursuant to retainage provisions in construction contracts generally become due upon completion of the contracts and acceptance by the owners. Retainage

F-12


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

amounts of $121.9 million at December 31, 2004 are expected to be collected as follows: $87.0 million in 2005, $23.3 million in 2006, $10.1 million in 2007 and $1.5 million in 2008 and thereafter.

 
5.  Construction Joint Ventures

      We participate in various construction joint venture partnerships. Generally, each construction joint venture is formed to accomplish a specific project, is jointly controlled by the joint venture partners and is dissolved upon completion of the project. The joint venture agreements typically provide that our interests in any profits and assets, and our respective share in any losses and liabilities that may result from the performance of the contract is limited to our stated percentage interest in the project. Although the venture’s contract with the project owner typically requires joint and several liability, our agreements with our joint venture partners provide that each partner will assume and pay its full proportionate share of any losses resulting from a project. We have no significant commitments beyond completion of the contract.

      We have determined that certain of these joint ventures are variable interest entities as defined by FIN 46. Accordingly, we have consolidated those joint ventures where we have determined that we are the primary beneficiary on a prospective basis effective January 1, 2004. The joint ventures we have consolidated are engaged in construction projects with total contract values ranging from $63.8 million to $390.4 million. Our proportionate share of the consolidated joint ventures ranges from 52.0% to 69.0%. Included in our December 31, 2004 consolidated balance sheet are assets (primarily current assets) of $94.8 million and current liabilities of $84.1 million resulting from these consolidations. There was no material effect on our net income as a result of these consolidations for the year ended December 31, 2004.

      Consistent with Emerging Issues Task Force Issue 00-01, “Investor Balance Sheet and Income Statement Display under the Equity Method for Investments in Certain Partnerships and Other Ventures,” we account for our share of the operations of construction joint ventures in which we have determined we are not the primary beneficiary on a pro rata basis in the consolidated statements of income and as a single line item in the consolidated balance sheets. The joint ventures in which we hold a significant interest but are not the primary beneficiary are engaged in construction projects with total contract values ranging from $90.4 million to $236.0 million. Our proportionate share of equity in these joint ventures ranges from 25% to 40%, the most significant of which includes a 40% share of a rapid transit project in New York, a 30% share of a rapid transit project in Maryland and a 30% share of a rapid transit project in Florida.

      The combined assets, liabilities and net assets of joint ventures in which we have determined we are not the primary beneficiary are as follows (in thousands):

                     
December 31,

2004 2003


Assets:
               
 
Total
  $ 96,070     $ 224,540  
 
Less other venturers’ interest
    63,724       121,731  
     
     
 
   
Company’s interest
    32,346       102,809  
     
     
 
Liabilities:
               
 
Total
    33,229       127,776  
 
Less other venturers’ interest
    21,778       67,217  
     
     
 
   
Company’s interest
    11,451       60,559  
     
     
 
Company’s interest in net assets
  $ 20,895     $ 42,250  
     
     
 

F-13


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

      The revenue and costs of revenue of joint ventures in which we have determined we are not the primary beneficiary are as follows (in thousands):

                             
Years Ended December 31,

2004 2003 2002



Revenue:
                       
 
Total
  $ 229,265     $ 473,918     $ 386,212  
 
Less other venturers’ interest
    159,631       261,405       184,386  
     
     
     
 
   
Company’s interest
    69,634       212,513       201,826  
     
     
     
 
Cost of revenue:
                       
 
Total
    211,715       423,652       335,844  
 
Less other venturers’ interest
    147,599       236,131       159,048  
     
     
     
 
   
Company’s interest
    64,116       187,521       176,796  
     
     
     
 
Company’s interest in gross profit
  $ 5,518     $ 24,992     $ 25,030  
     
     
     
 
 
6.  Investments in Affiliates

      We have investments in affiliates that are accounted for using the equity method. The most significant of these investments are a 50% interest in a limited liability company, which owns and operates an asphalt terminal in Nevada and a 25% interest in a limited partnership which develops land and leases buildings in California. During 2000 and 2002, we made advances to the asphalt terminal limited liability company of which $4.6 million remained outstanding at December 31, 2004.

      In January 2003, the California Private Transportation Company LP (“CPTC”), of which we are a 22% limited partner, closed the sale of the State Route 91 toll road franchise to the Orange County Transportation Authority for $72.5 million in cash and the assumption of $135.0 million in long-term debt. We completed construction of the $60.4 million project in 1995 and have maintained an equity interest in the partnership since its inception. Included in other income (expense) for the year ended December 31, 2003 is $18.4 million related to this sale by CPTC.

      During the year ended December 31, 2002 we purchased additional common stock of Wilder Construction Company (“Wilder”), bringing our ownership interest in Wilder above 50%. Accordingly, we changed our method of accounting for our investment in Wilder from the equity method of accounting to consolidation as of the date we exceeded 50% ownership (see “Wilder Construction Company” in Note 17 for additional discussion of and disclosure related to our investment in Wilder).

      At December 31, 2002, we held a minority interest in T.I.C. Holdings, Inc. (“TIC”) of approximately 16%, which we accounted for under the cost method of accounting. In June 2003, TIC repurchased 0.3 million shares of the TIC shares held by us for a cash payment of $6.0 million. The transaction reduced our interest in TIC to approximately 11% and resulted in a gain of $1.9 million, which is included in other income (expense) for the year ended December 31, 2003. In December 2004, TIC repurchased an additional 0.3 million shares of TIC shares held by us for a cash payment of $7.5 million. The transaction reduced our interest in TIC to approximately 6% and resulted in a gain of $3.3 million, which is included in other income (expense) for the year ended December 31, 2004.

F-14


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

      Our investments in affiliates comprised (in thousands):

                         
Years Ended December 31,

2004 2003 2002



Equity method investments in affiliates
  $ 6,548     $ 9,940     $ 6,430  
Cost method investment in TIC
    4,177       8,355       12,540  
     
     
     
 
Total investments in affiliates
  $ 10,725     $ 18,295     $ 18,970  
     
     
     
 

      The following table provides summarized financial information on a combined 100% basis for our affiliates accounted for under the equity method (in thousands):

                             
Years Ended December 31,

2004 2003 2002



Balance sheet data:
                       
 
Current assets
  $ 13,795     $ 13,450     $ 29,597  
 
Long-term assets
    87,961       129,699       226,697  
     
     
     
 
   
Total assets
    101,756       143,149       256,294  
     
     
     
 
 
Current liabilities
    6,080       5,802       25,483  
 
Long-term liabilities
    66,995       86,819       223,305  
     
     
     
 
   
Total liabilities
    73,075       92,621       248,788  
     
     
     
 
 
Net assets
  $ 28,681     $ 50,528     $ 7,506  
     
     
     
 
Earnings data:
                       
 
Revenue
  $ 138,222     $ 124,547     $ 553,661  
 
Gross profit
    73,828       9,034       52,701  
 
Earnings before taxes
    60,301       101,542       22,005  
 
Net income
  $ 60,301     $ 101,542     $ 14,877  
     
     
     
 
 
7.  Property and Equipment (in thousands)
                 
December 31,

2004 2003


Land
  $ 53,974     $ 53,583  
Quarry property
    101,545       75,329  
Buildings and leasehold improvements
    78,350       64,276  
Equipment and vehicles
    700,290       693,657  
Office furniture and equipment
    17,478       13,926  
     
     
 
      951,637       900,771  
Less accumulated depreciation, depletion and amortization
    575,440       556,037  
     
     
 
    $ 376,197     $ 344,734  
     
     
 

F-15


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

      We have recorded liabilities associated with our legally required obligations to reclaim owned and leased quarry property and related facilities in accordance with SFAS 143. A reconciliation of these asset retirement obligations since adoption of SFAS 143 is as follows:

                 
December 31,

2004 2003


Beginning balance
  $ 5,557     $  
Reclamation liability prior to adoption of SFAS 143
          3,023  
Impact of adoption of SFAS 143
          2,771  
Liabilities incurred and revisions to estimates
    5,847        
Liabilities settled
    (329 )     (613 )
Accretion
    421       376  
     
     
 
Ending balance
  $ 11,496     $ 5,557  
     
     
 
 
8.  Intangible Assets

      The following table indicates the allocation of goodwill by reportable segment which is included in other assets on our consolidated balance sheets (in thousands):

                     
December 31,

2004 2003


Goodwill by segment:
               
 
Heavy Construction Division
  $ 18,011     $ 18,011  
 
Branch Division
    9,900       1,056  
     
     
 
   
Total goodwill
  $ 27,911     $ 19,067  
     
     
 

      The increase in goodwill during 2004 was primarily related to our purchase of Wilder Construction Company common stock (see Note 17).

      The following intangible assets are included in other assets on our consolidated balance sheets (in thousands):

                             
December 31, 2004

Gross Accumulated Net
Value Amortization Value



Amortized intangible assets:
                       
 
Covenants not to compete
  $ 1,139     $ (781 )   $ 358  
 
Permits
    2,000       (494 )     1,506  
 
Tradenames
    1,425       (361 )     1,064  
 
Other
    622       (580 )     42  
     
     
     
 
   
Total amortized intangible assets
  $ 5,186     $ (2,216 )   $ 2,970  
     
     
     
 

F-16


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

                             
December 31, 2003

Gross Accumulated Net
Value Amortization Value



Amortized intangible assets:
                       
 
Covenants not to compete
  $ 1,249     $ (674 )   $ 575  
 
Permits
    2,000       (361 )     1,639  
 
Tradenames
    1,602       (991 )     611  
 
Acquired contracts
    900       (900 )      
 
Other
    622       (188 )     434  
     
     
     
 
   
Total amortized intangible assets
  $ 6,373     $ (3,114 )   $ 3,259  
     
     
     
 

      Aggregate amortization expense related to these intangible assets for the years ended December 31, 2004, 2003 and 2002 was $0.9 million, $1.3 million and $1.8 million, respectively. Amortization expense expected to be recorded in the future is as follows: $607,000 in 2005, $446,000 in 2006, $352,000 in 2007, $340,000 in 2008, $263,000 in 2009 and $962,000 thereafter.

 
9.  Accrued Expenses and Other Current Liabilities (in thousands)
                 
December 31,

2004 2003


Payroll and related employee benefits
  $ 40,053     $ 42,393  
Accrued insurance
    34,795       29,160  
Other
    42,519       29,164  
     
     
 
    $ 117,367     $ 100,717  
     
     
 
 
10.  Long-Term Debt and Credit Arrangements (in thousands)
                 
December 31,

2004 2003


Senior notes payable
  $ 115,000     $ 121,667  
Bank revolving line of credit
    25,000        
Mortgages
    19,989       4,931  
Wilder subsidiary promissory notes
    3,228       5,759  
Other notes payable
    1,147       2,533  
     
     
 
      164,364       134,890  
Less current maturities
    15,861       8,182  
     
     
 
    $ 148,503     $ 126,708  
     
     
 

The aggregate minimum principal maturities of long-term debt for each of the five years following December 31, 2004 are as follows (in thousands): 2005 - $15,861; 2006 — $49,741; 2007 — $16,244; 2008 — $19,657; 2009 — $15,655; and beyond 2009 — $47,206.

     Senior notes payable in the amount of $40.0 million are due to a group of institutional holders. The notes are due in equal annual installments from 2002 through 2010 and bear interest at 6.54% per annum. Additional senior notes payable in the amount of $75.0 million are due to a second group of institutional holders. The notes are due in nine equal annual installments beginning in 2005 and bear interest at 6.96% per annum. Based on the borrowing rates currently available to us for bank loans with similar terms and average maturities, the fair value of the senior notes payable was approximately $126.1 million as of December 31,

F-17


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

2004 and $129.1 million as of December 31, 2003. Restrictive covenants under the terms of our senior notes payable agreements include the maintenance of certain levels of working capital and cash flow and require the maintenance of tangible net worth (as defined) of approximately $395.4 million. We were in compliance with these covenants at December 31, 2004.

      On June 27, 2003, we entered into an agreement for a $100.0 million bank revolving line of credit, which allows for unsecured borrowings for up to three years through June 27, 2006, with interest rate options. At December 31, 2004, we had $25.0 million outstanding under this agreement. Outstanding borrowings under the revolving line of credit are at our choice of selected LIBOR rates plus a margin that is recalculated quarterly with interest payable periodically and principal payable on June 27, 2006. The margin was 1.25% at December 31, 2004. Additionally, we have standby letters of credit totaling $2.9 million, of which $2.7 million reduces the amount available under the line of credit. The unused and available portion of the line of credit at December 31, 2004 was $72.3 million. Restrictive covenants under the terms of this line of credit include the maintenance of certain financial ratios and tangible net worth (as defined) of approximately $417.6 million. We were in compliance with these covenants at December 31, 2004. Additionally, our Wilder subsidiary has a bank revolving line of credit of $10.0 million that expires in 2006, with borrowings collateralized by certain of Wilder’s equipment, accounts receivable, inventory and general intangibles. Outstanding borrowings under this line are charged interest at the bank’s prime rate (5.25% as of December 31, 2004) less 1.0%. There were no amounts outstanding at December 31, 2004.

      Mortgages are comprised primarily of notes incurred in connection with the purchase of property. These notes are collateralized by the property purchased and bear interest at 4.1% to 8.8% per annum with principal and interest payable in installments through 2034. The carrying amount of property pledged as collateral was approximately $39.9 million at December 31, 2004.

      The Wilder subsidiary promissory notes are due primarily to former Wilder employees relating to the repurchase of Wilder stock. These notes are unsecured, bear interest at prime (5.25% at December 31, 2004) and are payable in annual installments through March 2010. Additionally, our Wilder subsidiary has restrictive covenants (on a Wilder stand-alone basis) under the terms of its debt agreements that include the maintenance of certain ratios of working capital, liabilities to net worth and tangible net worth and restricts Wilder capital expenditures in excess of specified limits. Wilder was in compliance with these covenants at December 31, 2004.

 
11.  Employee Benefit Plans

      Employee Stock Ownership Plan: Our Employee Stock Ownership Plan (“ESOP”) covers all employees not included in collective bargaining agreements, except employees of our majority owned subsidiary, Wilder and certain consolidated construction joint ventures. As of December 31, 2004, the ESOP owned 7,911,038 shares of our common stock. Dividends on shares held by the ESOP are charged to retained earnings and all shares held by the ESOP are treated as outstanding in computing our earnings per share.

      Contributions to the ESOP are discretionary and comprise shares of our stock that were purchased on the market and immediately contributed to the plan. Compensation cost is measured as the cost to purchase the shares (market value on the date of purchase and contribution). Contribution expense was $2.0 million in each of the years ended December 31, 2004, 2003 and 2002.

      Profit Sharing and 401k Plan: The plan is a defined contribution plan covering all employees not included in collective bargaining agreements, except employees of our majority owned subsidiary, Wilder and certain consolidated construction joint ventures. Each employee can elect to have up to 15% of gross pay contributed to the 401k plan on a before-tax basis. The plan allows for company matching and additional contributions at the discretion of the Board of Directors.

F-18


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

      Our contributions to the Profit Sharing and 401k Plan for the years ended December 31, 2004, 2003 and 2002 were $6.2 million, $5.9 million and $5.4 million, respectively. Included in the contributions were 401k matching contributions of $4.5 million, $4.2 million and $3.9 million, respectively.

      Other: Two of our wholly owned subsidiaries, Granite Construction Company and Granite Halmar Construction Company, Inc. and our majority owned subsidiary, Wilder, also contribute to various multi-employer pension plans on behalf of union employees. Under the Employee Retirement Income Security Act, a contributor to a multi-employer plan is liable, upon termination or withdrawal from a plan, for its proportionate share of a plan’s unfunded vested liability. We currently have no intention of withdrawing from any of the multi-employer pension plans in which we participate. Contributions to these plans for the years ended December 31, 2004, 2003 and 2002 were $20.5 million, $19.5 million and $19.6 million, respectively. Additionally, Wilder provides a 401k plan covering all of its employees and a separate defined contribution plan covering employees not covered by other plans. Wilder’s contributions under these plans totaled approximately $2.1 million, $2.0 million and $2.0 million in the years ended December 31, 2004, 2003 and 2002, respectively. We also provide non-qualified deferred compensation plans to certain of our highly compensated employees that provide the participants the opportunity to defer payment of certain compensation as defined in the plan.

 
12.  Shareholders’ Equity

      1999 Equity Incentive Plan: Our Amended and Restated 1999 Equity Incentive Plan (the “Plan”) provides for the grant of restricted common stock, incentive and nonqualified stock options, performance units and performance shares to employees and awards to our Board of Directors in the form of stock units or stock options (“Director Options”). A total of 4,250,000 shares of our common stock have been reserved for issuance under the Plan of which approximately 2,554,000 remained available as of December 31, 2004. The exercise price for incentive and nonqualified stock options granted to employees under the Plan may not be less than 100% and 85%, respectively, of the fair market value at the date of the grant. The exercise price for options granted to our Directors under the Plan is 50.0% of the market price of our common stock at the date of grant and the fair market value of the option represents the value of the services provided in their role as Directors. Employee options granted will be exercisable at such time and be subject to such restrictions/conditions as determined by the compensation committee and Director Options are immediately exercisable. No option will be exercisable later than ten years from the date of grant. Restricted common stock is issued for services to be rendered and may not be sold, transferred or pledged for such period as determined by the compensation committee.

      At December 31, 2004 there were approximately 1,163,000 restricted shares outstanding. Restricted stock compensation cost is measured as the stock’s fair value at the date of grant. The compensation cost is recognized ratably over the vesting period — generally three to five years. Restricted shares become fully vested when a holder reaches age 62. An employee may not sell or otherwise transfer unvested shares and, in the event that employment is terminated prior to the end of the vesting period, any unvested shares are surrendered to us. We have no obligation to repurchase restricted stock. Compensation expense related to restricted shares for the years ended December 31, 2004, 2003 and 2002 was $6.0 million, $6.0 million and $5.8 million, respectively.

      We granted Director Options under the Plan to purchase shares of our stock for the years ended December 31, 2004, 2003 and 2002 at a weighted average exercise price of $11.33, $9.92, and $9.70,

F-19


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

respectively. The options are immediately exercisable and options for 86,748 shares remain outstanding at December 31, 2004. Director Option transactions are summarized as follows:

                         
December 31,

2004 2003 2002



Options outstanding, beginning of year
    86,063       55,812       40,187  
Options granted
    17,151       35,158       22,877  
Options exercised
    (16,466 )     (4,907 )     (7,252 )
     
     
     
 
Options outstanding, end of year
    86,748       86,063       55,812  
     
     
     
 

      The fair value of each option grant was estimated at the grant date using a Black-Scholes option-pricing model. We recognized $281,000, $330,000 and $229,000 of compensation expense related to grants of stock options in 2004, 2003 and 2002, respectively.

      Dividend Reinvestment and Stock Purchase Plan: During 2001, we adopted a Dividend Reinvestment and Stock Purchase Plan (the “DRP Plan”) under which 4,500,000 shares of common stock are authorized for purchase. The DRP Plan offers participation to record holders of common stock or other interested investors. Under the DRP Plan, participants may buy additional shares of common stock by automatically reinvesting all or a portion of the cash dividends paid on their shares of common stock or by making optional cash investments.

 
13.  Weighted Average Shares Outstanding

      A reconciliation of the weighted average shares outstanding used in calculating basic and diluted net income per share in the accompanying Consolidated Statements of Income is as follows (in thousands):

                             
Years Ended December 31,

2004 2003 2002



Weighted Average Shares Outstanding
                       
 
Weighted average common stock outstanding
    41,580       41,464       41,275  
 
Less weighted average restricted stock outstanding
    1,190       1,289       1,259  
     
     
     
 
 
Total
    40,390       40,175       40,016  
     
     
     
 
Diluted Weighted Average Shares Outstanding
                       
 
Basic weighted average shares outstanding
    40,390       40,175       40,016  
 
Effect of dilutive securities:
                       
   
Warrants
                100  
   
Common stock options and units
    52       29       19  
   
Restricted stock
    589       604       588  
     
     
     
 
 
Total
    41,031       40,808       40,723  
     
     
     
 

      Restricted stock representing approximately 254,000 shares, 364,000 shares and 258,000 shares for the years ended December 31, 2004, 2003 and 2002, respectively, have been excluded from the calculation of diluted net income per share because their effects are anti-dilutive.

F-20


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

 
14.  Income Taxes

      Provision for income taxes (in thousands):

                           
Years Ended December 31,

2004 2003 2002



Federal:
                       
 
Current
  $ 28,238     $ 25,348     $ 28,553  
 
Deferred
    (4,861 )     3,496       (3,263 )
     
     
     
 
      23,377       28,844       25,290  
     
     
     
 
State:
                       
 
Current
    6,107       5,867       5,263  
 
Deferred
    (1,007 )     593       (602 )
     
     
     
 
      5,100       6,460       4,661  
     
     
     
 
    $ 28,477     $ 35,304     $ 29,951  
     
     
     
 

      Reconciliation of statutory to effective tax rate:

                         
Years Ended
December 31,

2004 2003 2002



Federal statutory tax rate
    35.0 %     35.0 %     35.0 %
State taxes, net of federal tax benefit
    3.5       4.6       4.3  
Percentage depletion deduction
    (2.3 )     (1.2 )     (2.9 )
Minority interest in joint ventures
    (3.2 )            
Other
    (3.0 )     (2.2 )     (0.2 )
     
     
     
 
      30.0 %     36.2 %     36.2 %
     
     
     
 

      The impact on the effective tax rate related to minority interest in joint ventures is a result of the consolidation of construction joint ventures as required by FIN 46 (see Note 5), which are not subject to income taxes on a stand-alone basis.

F-21


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

      Deferred tax assets and liabilities (in thousands):

                   
December 31,

2004 2003


Deferred tax assets:
               
 
Accounts receivable
  $ 1,262     $ 1,200  
 
Inventory
    2,664       2,451  
 
Property and equipment
    408       522  
 
Insurance
    131       2,963  
 
Deferred compensation
    10,721       3,577  
 
Other accrued liabilities
    12,701       8,545  
 
Contract recognition
    64       3,377  
 
Net operating loss carryforward
    4,628       3,439  
 
Valuation allowance
    (4,628 )     (3,439 )
     
     
 
    $ 27,951     $ 22,635  
     
     
 
Deferred tax liabilities:
               
 
Property and equipment
  $ 49,492     $ 38,625  
 
TIC basis difference
    722       1,498  
 
Other
    860       4,388  
     
     
 
    $ 51,074     $ 44,511  
     
     
 

      The deferred tax asset for other accrued liabilities relates to various items including accrued vacation and accrued reclamation costs which are deductible in future periods. The deferred tax liability for the TIC basis difference represents the undistributed earnings of TIC for which income and the related tax provision have been recognized in our records.

      Our deferred tax asset for net operating loss carryforwards relates to state and local tax carryforwards for a subsidiary, which expire between 2021 and 2024. We have provided a valuation allowance on these assets because of uncertainty regarding their realizability due to recent losses. The increases in the carryforwards and associated valuation allowance for the years ended December 31, 2004, 2003 and 2002 were a result of taxable losses generated by the subsidiary in those years.

F-22


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

 
15.  Commitments, Contingencies and Guarantees

      Leases: Minimum rental commitments and minimum royalty requirements under all noncancellable operating leases, primarily quarry property and construction equipment, in effect at December 31, 2004 were (in thousands):

         
Years Ending
December 31,

2005
  $ 6,324  
2006
    5,433  
2007
    3,717  
2008
    1,873  
2009
    1,688  
Later years (through 2046)
    8,643  
     
 
Total minimum rental commitment
  $ 27,678  
     
 

      Operating lease rental expense was $8.0 million in 2004, $10.4 million in 2003 and $8.1 million in 2002.

      Litigation: Our wholly-owned subsidiary, Granite Construction Company “GCCO”, as a member of a joint venture, Wasatch Constructors, is among a number of construction companies and the Utah Department of Transportation that were named in a lawsuit filed in the United States District Court for the District of Utah. The plaintiffs are two independent contractor truckers who filed the lawsuit on behalf of the United States under the federal False Claims Act seeking to recover damages and civil penalties in excess of $46.4 million.

      Among other things, the plaintiffs allege that certain defendants, who were subcontractors to Wasatch, defrauded the Government by charging Wasatch for dirt and fill material they did not provide and that Wasatch and UDOT knowingly paid for such excess material. The plaintiffs also allege that Wasatch committed certain other acts including providing substandard workmanship and materials; failure to comply with clean air and clean water standards and the filing of false certifications regarding its entitlement to the payment of bonuses.

      The original complaint was filed in January 1999 and the Third Amended Complaint was filed in February 2003. On May 30, 2003, Wasatch Constructors and the coordinated defendants filed their motion to dismiss the Third Amended Complaint. On December 23, 2003, the Court issued its order granting Wasatch Constructors and the coordinated defendants’ motion to dismiss the Third Amended Complaint but allowed the plaintiffs one last opportunity to amend their complaint. Plaintiffs’ Fourth Amended Complaint was filed on July 12, 2004. The Company and GCCO believe that the allegations in the lawsuit are without merit and intend to defend them vigorously.

      Additionally, we are one of approximately one hundred defendants named in four California State Court lawsuits where four plaintiffs have, by way of various causes of action, including strict products and market share liability, alleged personal injuries caused by exposure to silica products and related materials during plaintiffs’ use or association with sandblasting or grinding concrete. The plaintiffs in each lawsuit have categorized the defendants as equipment defendants, respirator defendants, premises defendants and sand defendants. We have been identified as a sand defendant, meaning a party that manufactured, supplied or distributed silica-containing products. Our preliminary investigation reveals that we have not knowingly sold or distributed abrasive silica sand for sandblasting.

      We are a party to a number of other legal proceedings and believe that the nature and number of these proceedings are typical for a construction firm of our size and scope. Our litigation typically involves claims regarding public liability or contract related issues. While management currently believes, after consultation

F-23


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

with counsel, that the ultimate outcome of these proceedings, individually and in the aggregate, will not have a material adverse effect on our financial position or overall trends in results of operations, litigation is subject to inherent uncertainties. Were an unanticipated unfavorable ruling to occur, there exists the possibility of a material adverse impact on the results of operations for the period in which the ruling occurs.

      Guarantees: As discussed in Note 5, we participate in various construction joint venture partnerships. We also participate in various “line item” joint venture agreements under which each partner is responsible for performing certain discrete items of the total scope of contracted work. The revenue for these discrete items is defined in the contract with the project owner and each venture partner bears the profitability risk associated with its own work. All partners in a line item joint venture are jointly and severally liable for completion of the total project under the terms of the contract with the project owner. There is not a single set of books and records for a line item joint venture. Each partner accounts for its items of work individually as it would for any self-performed contract. We account for our portion of these contracts as a project in our accounting system and include receivables and payables associated with our work on our balance sheet.

      Although our agreements with our joint venture partners for both construction joint ventures and line item joint ventures provide that each party will assume and pay its share of any losses resulting from a project, if one of our partners was unable to pay its share we would be fully liable under our contract with the project owner. Circumstances that could lead to a loss under these guarantee arrangements include a partner’s inability to contribute additional funds to the venture in the event that the project incurred a loss or additional costs that we could incur should the partner fail to provide the services and resources toward project completion that had been committed to in the joint venture agreement. At December 31, 2004 approximately $385.8 million of work representing either our partners’ proportionate share or work that our partners’ are directly responsible for in line item joint ventures, had yet to be completed. We have never incurred a loss under these joint and several liability provisions, however, it is possible that we could in the future and such a loss could be significant.

      Wilder Common Stock: Substantially all of the non-Granite held common shares of our majority-owned subsidiary, Wilder Construction Company, are redeemable by the holders upon retirement, voluntary termination, death or permanent disability. Approximately 53% of these shares are held by Wilder founders or non-employees and are accounted for under Statement of Financial Accounting Standards No. 150 “Accounting for Certain Financial Instruments with Characteristics of Both Liabilities and Equity” and related pronouncements, and accordingly, the redemption value of these shares is included in other long-term liabilities. The remaining 47% are accounted for as stock-based compensation. Wilder generally has up to eight years to pay the redemption price following a redemption event, as defined in its shareholder agreements, and the redemption price is adjusted each year, primarily for the Wilder net income attributable to the shares. If all of these Wilder shares had been redeemed at the December 31, 2004 redemption price, a payment of $17.2 million would have been required.

 
16.  Business Segment Information

      We have two reportable segments: the Branch Division and the Heavy Construction Division (“HCD”). The Branch Division is comprised of branch offices, including our majority owned subsidiary, Wilder Construction Company, that serve local markets, while HCD pursues major infrastructure projects throughout the nation. HCD focuses on building larger heavy civil projects with contract durations that are frequently greater than two years, while the Branch Division projects are typically smaller in size and shorter in duration. HCD has been the primary participant in our construction joint ventures. Substantially all of our revenue from the sales of materials is from the Branch Division.

      The accounting policies of the segments are the same as those described in the Summary of Significant Accounting Policies (see Note 1). We evaluate performance based on operating profit or loss (excluding gain on sales of property and equipment), and do not include income taxes, interest income, interest expense or

F-24


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

other income (expense). Unallocated other corporate expenses principally comprise corporate general and administrative expenses.

      Summarized segment information (in thousands):

                           
HCD Branch Total



2004
                       
 
Revenues from external customers
  $ 872,812     $ 1,263,400     $ 2,136,212  
 
Intersegment revenue transfer
    (24,215 )     24,215        
     
     
     
 
 
Net revenue
    848,597       1,287,615       2,136,212  
 
Depreciation, depletion and amortization
    14,386       42,581       56,967  
 
Operating income
    8,957       106,016       114,973  
 
Property and equipment
    47,829       298,223       346,052  
2003
                       
 
Revenues from external customers
  $ 702,055     $ 1,142,436     $ 1,844,491  
 
Intersegment revenue transfer
    (10,290 )     10,290        
     
     
     
 
 
Net revenue
    691,765       1,152,726       1,844,491  
 
Depreciation, depletion and amortization
    14,185       47,958       62,143  
 
Operating income
    26,246       91,860       118,106  
 
Property and equipment
    43,505       281,531       325,036  
2002
                       
 
Revenues from external customers
  $ 596,243     $ 1,168,499     $ 1,764,742  
 
Intersegment revenue transfer
    (19,313 )     19,313        
     
     
     
 
 
Net revenue
    576,930       1,187,812       1,764,742  
 
Depreciation, depletion and amortization
    12,326       42,537       54,863  
 
Operating income
    19,305       100,165       119,470  
 
Property and equipment
    43,676       287,145       330,821  

      Included in HCD operating income for the year ended December 31, 2004 is operating income from our newly consolidated joint ventures of $7.1 million (see Note 5).

      Reconciliation of segment operating income to consolidated totals (in thousands):

                           
Years Ended December 31,

2004 2003 2002



Total operating income for reportable segments
  $ 114,973     $ 118,106     $ 119,470  
Other income
    11,372       18,240       2,494  
Gain on sales of property and equipment
    18,566       4,714       2,128  
Unallocated other corporate expenses
    (49,987 )     (43,535 )     (41,353 )
     
     
     
 
 
Income before provision for income taxes and minority interest
  $ 94,924     $ 97,525     $ 82,739  
     
     
     
 

F-25


Table of Contents

GRANITE CONSTRUCTION INCORPORATED

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS — (Continued)

      Reconciliation of segment assets to consolidated totals (in thousands):

                           
December 31,

2004 2003 2002



Total assets for reportable segments
  $ 346,052     $ 325,036     $ 330,821  
Assets not allocated to segments:
                       
 
Cash and cash equivalents
    161,627       69,919       52,032  
 
Marketable securities
    116,065       132,066       130,662  
 
Deferred income taxes
    21,012       22,421       23,056  
 
Other current assets
    540,462       435,442       375,907  
 
Property and equipment
    30,145       19,698       17,142  
 
Other assets
    62,591       55,828       54,199  
     
     
     
 
Consolidated total assets
  $ 1,277,954     $ 1,060,410     $ 983,819  
     
     
     
 
 
17.  Acquisitions

      Wilder Construction Company: In April 2000 we began purchasing shares of common stock of Wilder Construction Company (“Wilder”). Our investment in Wilder was recorded under the equity method of accounting until April of 2002 when our interest in Wilder increased to above 50% and we began consolidating the financial position, results of operations and cash flows of Wilder. Through December 31, 2004 we have purchased a 75% interest in Wilder for cash totaling $36.5 million, including a $9.2 million purchase in 2004.

      We have accounted for this step acquisition using the purchase method of accounting in accordance with Statement of Financial Accounting Standards No. 141, “Business Combinations.” The purchase price was allocated to assets acquired and liabilities assumed based on their estimated fair values at the date of acquisition and the excess purchase price over the estimated fair value of net assets acquired of $8.8 million was allocated to goodwill.

      Other Acquisitions: During 2002, we purchased certain assets and assumed certain contracts and liabilities of two northern California construction contractors and materials suppliers for cash consideration of $23.3 million and we purchased certain assets and assumed certain contracts of a quarry operation located near Gilroy, California for cash consideration of approximately $13.9 million. These purchases were accounted for using the purchase method of accounting. The results of each of the acquired businesses’ operations were included in our consolidated results from their respective acquisition dates. In each of these transactions the estimated fair value of the assets acquired exceeded the purchase price; therefore, no goodwill was recorded.

 
18.  Sale of Assets

      In March 2004, we sold certain assets related to our ready-mix concrete business in Utah for cash of $10.0 million and promissory notes with an estimated fair value of $8.9 million which are payable in installments through 2010. The sale transaction resulted in the recognition of a gain of approximately $10.0 million, which is included in gain on sales of property and equipment for the year ended December 31, 2004.

F-26


Table of Contents

SIGNATURES

      Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

  GRANITE CONSTRUCTION INCORPORATED

  By:  /s/ WILLIAM E. BARTON
 
  William E. Barton
  Senior Vice President and Chief Financial Officer

Date: March 1, 2005

      Pursuant to the requirements of the Securities Exchange Act of 1934, this report has been signed below on March 1, 2005, by the following persons in the capacities indicated.

         
 
/s/ WILLIAM G. DOREY

[William G. Dorey]
  President, Chief Executive Officer and Director
 
/s/ WILLIAM E. BARTON

[William E. Barton]
  Senior Vice President and Chief Financial Officer, Principal Accounting and Financial Officer
 
/s/ DAVID H. WATTS

[David H. Watts]
  Chairman of the Board and Director
 
/s/ JOSEPH J. BARCLAY

[Joseph J. Barclay]
  Director
 
/s/ LINDA GRIEGO

[Linda Griego]
  Director
 
/s/ DAVID H. KELSEY

[David H. Kelsey]
  Director
 
/s/ REBECCA A. MCDONALD

[Rebecca A. McDonald]
  Director
 
/s/ RAYMOND E. MILES

[Raymond E. Miles]
  Director
 
/s/ J. FERNANDO NIEBLA

[J. Fernando Niebla]
  Director
 
/s/ WILLIAM H. POWELL

[William H. Powell]
  Director
 
/s/ GEORGE B. SEARLE

[George B. Searle]
  Director


Table of Contents

SCHEDULE II

GRANITE CONSTRUCTION INCORPORATED

SCHEDULE OF VALUATION AND QUALIFYING ACCOUNTS
                                   
Charged
(Credited) to
Balance at Expenses or Balance at
Beginning of Other Accounts, End of
Description Year Net Deductions Year





(In thousands)
YEAR ENDED DECEMBER 31, 2004
                               
 
Inventory reserves
  $ 4,592     $ (501 )   $     $ 4,091  
     
     
     
     
 
YEAR ENDED DECEMBER 31, 2003
                               
 
Inventory reserves
  $ 4,957     $ (365 )   $     $ 4,592  
     
     
     
     
 
YEAR ENDED DECEMBER 31, 2002
                               
 
Inventory reserves
  $ 3,617     $ 1,340     $     $ 4,957  
     
     
     
     
 

S-1


Table of Contents

INDEX TO 10-K EXHIBITS

     
Exhibit
No. Exhibit Description


3.1*
  Certificate of Incorporation of Granite Construction Incorporated (Registration Statement on Form S-1, File No. 33-33795)
3.1.a*
  Amendment to the Certificate of Incorporation of Granite Construction Incorporated (Exhibit 3.1.a to 10-K for year ended December 31, 1998)
3.1.b*
  Amendment to Certificate of Incorporation of Granite Construction Incorporated (Exhibit 3.1.b to 10-K for year ended December 31, 2000)
3.1.c*
  Certificate of Correction of Certificate of Incorporation of Granite Construction Incorporated effective January 31, 2001 (Exhibit 3.1.c to 10-K for year ended December 31, 2000)
3.1.d*
  Certificate of Correction of Certificate of Incorporation of Granite Construction Incorporated filed May 22, 1998, effective January 31, 2001 (Exhibit 3.1.d to 10-K for year ended December 31, 2000)
3.1.e*
  Certificate of Correction of Certificate of Incorporation of Granite Construction Incorporated filed May 23, 2000, effective January 31, 2001 (Exhibit 3.1.e to 10-K for year ended December 31, 2000)
3.1.f*
  Amendment to the Certificate of Incorporation of Granite Construction Incorporated effective May  25, 2001 (Exhibit 3.1 to 10-Q for quarter ended June 30, 2001)
3.1.g*
  Certificate of Granite Construction Incorporated as Amended effective May 25, 2001 (Exhibit 3.1.a to 10-Q for quarter ended June 30, 2001)
3.2*
  Bylaws of Granite Construction Incorporated, as amended and restated effective February 27, 1991 (Exhibit 3.2 to 10-K for year ended December 31, 1991)
3.2.a*
  Amended Bylaws of Granite Construction Incorporated effective May 24, 2004 (Exhibit 3.2 to 10-Q for quarter ended June 30, 2004)
10.1* **
  Amendment to and Restatement of the Granite Construction Incorporated Key Management Deferred Compensation Plan adopted and effective January 1, 1998 (Exhibit 10.8 to 10-K for year ended December 31, 1998)
10.1.a* **
  Amendment 1 to Granite Construction Incorporated Key Management Deferred Compensation Plan dated April 23, 1999 (Exhibit 10.6.a to 10-K for year ended December 31, 1999)
10.1.b* **
  Amendment 2 to Granite Construction Incorporated Key Management Deferred Compensation Plan dated March 24, 2003 (Exhibit 10.1 to 10-Q for quarter ended March 31, 2003)
10.2* **
  Amendment to and Restatement of the Granite Construction Incorporated Key Management Deferred Incentive Compensation Plan adopted and effective January 1, 1998 (Exhibit 10.9 to 10-K for year ended December 31, 1998)
10.2.a* **
  Amendment 1 to Granite Construction Incorporated Key Management Deferred Incentive Compensation Plan dated April 23, 1999 (Exhibit 10.7.a to 10-K for year ended December 31, 1999)
10.2.b* **
  Amendment 2 to Granite Construction Incorporated Key Management Deferred Incentive Compensation Plan dated November 1, 2001 (Exhibit 10.9.b to 10-K for year ended December 31, 2001)
10.3*
  Granite Construction Incorporated Amended and Restated 1999 Equity Incentive Plan (Exhibit 10.1 to 10-Q for quarter ended, June 30, 2004)
10.4*
  Credit Agreement dated and effective June 29, 2001 (Exhibit 10.1 to 10-A for quarter ended June 30, 2001)
10.5*
  Continuing Guaranty Agreement from the Subsidiaries of Granite Construction Incorporated as Guarantors of financial accommodations pursuant to the terms of the Credit Agreement dated June  29, 2001 (Exhibit 10.2 to 10-Q for quarter ended June 30, 2001)
10.6*
  Credit Agreement dated and effective June 27, 2003 (Exhibit 10.1 to 10-Q for quarter ended June 30, 2003)
10.6.a*
  First Amendment Agreement to the June 27, 2003 Credit Agreement dated as of September 15, 2004 (Exhibit 10.1 to 10-Q for quarter ended September 30, 2004)


Table of Contents

     
Exhibit
No. Exhibit Description


10.7*
  Continuing Guaranty Agreement from the Subsidiaries of Granite Construction Incorporated as Guarantors of financial accommodations pursuant to the terms of the Credit Agreement dated June  27, 2003 (Exhibit 10.2 to 10-Q for quarter ended June 30, 2003)
10.7.a*
  Consent and Agreement of Guarantors from the Subsidiaries of Granite Construction Incorporated as Guarantors of financial accommodations pursuant to the terms of the First Amendment Agreement dated as of September 15, 2004 (Exhibit 10.2 to 10-Q for quarter ended September 30, 2004)
10.8*
  Note Purchase Agreement between Granite Construction Incorporated and certain purchasers dated May 1, 2001 (Exhibit 10.3 to 10-Q for quarter ended June 30, 2001)
10.8.a*
  First Amendment to Note Purchase Agreement between Granite Construction Incorporated and certain purchasers dated June 15, 2003 (Exhibit 10.4 to 10-Q for quarter ended June 30, 2003)
10.9*
  Amendment to and Restated Note Purchase Agreement between Granite Construction Incorporated and certain purchasers dated November 1, 2001 (Exhibit 10.12 to 10-K for year ended December 31, 2001)
10.9.a*
  First Amendment to Amended and Restated Note Purchase Agreement between Granite Construction Incorporated and certain purchasers dated June 15, 2003 (Exhibit 10.3 to 10-Q for quarter ended June 30, 2003)
10.10*
  Subsidiary Guaranty Agreement from the Subsidiaries of Granite Construction Incorporated as Guarantors of the Guaranty of Notes and Note Agreement and the Guaranty of Payment and Performance dated May 1, 2001 (Exhibit 10.4 to 10-Q for quarter ended June 30, 2001)
10.11*
  Subsidiary Guaranty Supplement from the Subsidiaries of Granite Construction Incorporated as Guarantors of the Guaranty of Notes and Note Agreement and the Guaranty of Payment and Performance dated November 15, 2001 (Exhibit 10.13.a to 10-K for year ended December 31, 2001)
10.12*
  International Swap Dealers Association, Inc. Master Agreement between BNP Paribas and Granite Construction Incorporated dated as of February 10, 2003 (Exhibit 10.5 to 10-Q for quarter ended June 30, 2003)
10.13**
  Form of Amended and Restated Director and Officer Indemnification Agreement
21*
  List of subsidiaries of Granite Construction Incorporated (Exhibit 21 to 10-K for year ended December 31, 2003)
23†
  Consent of PricewaterhouseCoopers, LLP
31.1†
  Certification of Chief Executive Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002
31.2†
  Certification of Chief Financial Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002
32††
  Certification of Chief Executive Officer and Chief Financial Officer Pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002


Incorporated by reference

**  Compensatory plan or management contract

†  Filed herewith
 
††  Furnished herewith