EX-99.1 3 dex991.htm EXHIBIT 99.1 Exhibit 99.1

Exhibit 99.1

Tutor-Saliba Corporation

and Subsidiaries

Consolidated Financial Statements as of

December 31, 2007 and 2006, and for the

Years Ended December 31, 2007, 2006 and 2005, and

Independent Auditors’ Report

 

1


INDEPENDENT AUDITORS’ REPORT

To the Board of Directors and Shareholders of Tutor-Saliba Corporation

Sylmar, CA

We have audited the accompanying consolidated balance sheets of Tutor-Saliba Corporation and subsidiaries (the “Company”) as of December 31, 2007 and 2006, and the related consolidated statements of income, shareholders equity, and cash flows for each of the three years in the period ended December 31, 2007. These financial statements are the responsibility of the Company’s management. Our responsibility is to express an opinion on these financial statements based on our audits.

We conducted our audits in accordance with auditing standards generally accepted in the United States of America. Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement. An audit includes consideration of internal control over financial reporting as a basis for designing audit procedures that are appropriate in the circumstances, but not for the purpose of expressing an opinion on the effectiveness of the Company’s internal control over financial reporting. Accordingly, we express no such opinion. An audit also includes examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements, assessing the accounting principles used and significant estimates made by management, as well as evaluating the overall financial statement presentation. We believe that our audits provide a reasonable basis for our opinion.

In our opinion, such consolidated financial statements present fairly, in all material respects, the financial position of the Company as of December 31, 2007 and 2006, and the results of its operations and its cash flows for each of the three years in the period ended December 31, 2007, in conformity with accounting principles generally accepted in the United States of America.

As discussed in Note 1 to the consolidated financial statements, in 2007, the Company changed its method of reporting its interests in construction joint ventures in the consolidated balance sheets and consolidated statements of cash flows from the equity method of accounting to the proportionate consolidation method and, retrospectively, adjusted the 2006 and 2005 consolidated financial statements for the change.

/s/Deloitte and Touche LLP

Los Angeles, California

April 25, 2008 (May 28, 2008, as to the effects of discontinued operations discussed in Note 14)

 

2


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

CONSOLIDATED BALANCE SHEETS

 

    December 31,
    2007   2006

ASSETS

   

Current assets:

   

Cash and cash equivalents

  $ 192,802,901   $ 37,575,733

Restricted cash

    24,000,000  

Marketable securities

      93,424,299

Receivables

    223,216,615     175,091,118

Unbilled work

    29,018,934     19,280,817

Advances to related parties

      4,595,513

Advances to affiliates

    108,079     342,570

Inventory

    2,478,893     1,374,194

Deferred income taxes

    192,896     158,245

Other current assets

    6,896,448     6,971,790
           

Total current assets

    478,714,766     338,814,279
           

Property and equipment, net of depreciation

    100,491,769     85,972,239
           

Noncurrent assets:

   

Minority interest receivable

    13,172,309     13,389,225

Goodwill

    2,694,467  

Identified intangible asset, net

    2,929,157  

Other assets

    3,490,326     3,581,319
           

Total noncurrent assets

    22,286,259     16,970,544
           

Total assets

  $ 601,492,794   $ 441,757,062
           
LIABILITIES AND SHAREHOLDERS’ EQUITY    

Current liabilities:

   

Current maturities of long-term debt

  $ 12,074,077   $ 17,261,589

Accounts and subcontracts payable

    236,970,144     122,937,180

Accrued liabilities

    22,840,295     23,278,006

Advances from affiliates

    523,948     576,200

Deferred contract revenue

    56,229,238     47,476,186

Income taxes payable

    2,536,311     399,805
           

Total current liabilities

    331,174,013     211,928,966
           

Noncurrent liabilities:

   

Long-term debt, less current maturities

    53,616,849     60,220,891

Deferred income taxes

    1,311,424     2,176,016

Other long-term liabilities

    3,760,165     5,718,689
           

Total noncurrent liabilities

    58,688,438     68,115,596
           

Total liabilities

    389,862,451     280,044,562
           

Other commitments and Contingencies (Note 12)

   

Shareholders’ equity:

   

Capital stock, no par value: authorized 1,000,000 shares:

   

issued and outstanding 900,043 shares

    6,756,510     6,756,510

Additional paid-in capital

    11,075,563     11,075,563

Accumulated other comprehensive income

    144,570     38,901,604

Retained earnings

    193,653,700     104,978,823
           

Total shareholders’ equity

    211,630,343     161,712,500
           

Total liabilities and shareholders’ equity

  $ 601,492,794   $ 441,757,062
           

See notes to consolidated financial statements.

 

3


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

CONSOLIDATED STATEMENTS OF INCOME

 

     Year Ended December 31,  
     2007     2006     2005  

REVENUE:

      

Construction revenue

   $ 1,150,872,378     $ 513,445,293     $ 386,755,250  

Sales revenue

     951,470       1,011,730       834,753  
                        

Total revenue

     1,151,823,848       514,457,023       387,590,003  
                        

COST OF REVENUES:

      

Cost of construction revenue

     1,061,735,990       484,735,017       370,825,774  

Amortization of intangible asset

     1,230,843      

Cost of sales revenue

     636,155       699,114       508,692  
                        

Total cost of revenues

     1,063,602,988       485,434,131       371,334,466  
                        

Gross profit

     88,220,860       29,022,892       16,255,537  

Gain on sale of property and equipment

     (446,325 )     (453,750 )     (7,523,793 )

Cost of contract litigation settlement

         14,651,537  

General and administrative expenses

     36,237,164       26,823,295       26,352,043  
                        

Income (loss) from operations

     52,430,021       2,653,347       (17,224,250 )

OTHER INCOME (EXPENSES):

      

Interest and other income

     6,076,770       3,474,082       2,772,034  

Net gain on sale of marketable securities

     94,104,632       8,882,610       21,370,376  

Gain on derivative

         16,936,063  

Interest expense

     (4,196,814 )     (5,256,848 )     (3,414,423 )

Other expense

     (975,656 )     (877,607 )     (574,092 )
                        

Total other income, net

     95,008,932       6,222,237       37,089,958  
                        

Income before minority interest and income taxes

     147,438,953       8,875,584       19,865,708  

Provision for income taxes

     4,399,231       1,662,632       848,849  
                        

Income before minority interest

     143,039,722       7,212,952       19,016,859  

Minority interest

     (110,705 )     (40,268 )     (16,103 )
                        

INCOME FROM CONTINUING OPERATIONS

     142,929,017       7,172,684       19,000,756  
                        

DISCONTINUED OPERATIONS:

      

Income (loss) from discontinued operations before minority interest and income taxes

     337,053       (177,668 )     392,660  

Provision for income taxes

     4,798       3,875       4,869  
                        

Income (loss) before minority interest

     332,255       (181,543 )     387,791  

Minority interest

     (106,211 )     145,773       1,019,238  
                        

INCOME (LOSS) FROM DISCONTINUED OPERATIONS

     226,044       (35,770 )     1,407,029  
                        

NET INCOME

   $ 143,155,061     $ 7,136,914     $ 20,407,785  
                        

See notes to consolidated financial statements.

 

4


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

CONSOLIDATED STATEMENTS OF SHAREHOLDERS’ EQUITY

 

    Capital
Stock
  Additional
Paid-In
Capital
  Accumulated
Other
Comprehensive
Income
    Retained
Earnings
    Total  

BALANCE AT JANUARY 1, 2005

  $ 6,756,510   $ 11,075,563   $ 25,848,752     $ 116,267,696     $ 159,948,521  

Comprehensive income:

         

Net income

          20,407,785       20,407,785  

Other comprehensive income:

         

Realized holding gains on marketable securities (net of tax of $(320,555))

        (21,049,820 )       (21,049,820 )

Unrealized holding gains arising during the period on marketable securities (net of tax of $309,874)

        20,348,419         20,348,419  

Foreign currency translation adjustments (net of tax of $27,185)

        52,771         52,771  
                           

Total comprehensive income

        (648,630 )     20,407,785       19,759,155  

Distributions to shareholder

          (14,768,598 )     (14,768,598 )
                                   

BALANCE AT DECEMBER 31, 2005

    6,756,510     11,075,563     25,200,122       121,906,883       164,939,078  

Comprehensive income:

         

Net income

          7,136,914       7,136,914  

Other comprehensive income:

         

Realized holding gains on marketable securities (net of tax of $(133,239))

        (8,749,371 )       (8,749,371 )

Unrealized holding gains arising during the period on marketable securities (net of tax of $344,599)

        22,628,669         22,628,669  

Foreign currency translation adjustments (net of tax of $(91,602))

        (177,816 )       (177,816 )
                           

Total comprehensive income

        13,701,482       7,136,914       20,838,396  

Distributions to shareholder

          (24,064,974 )     (24,064,974 )
                                   

BALANCE AT DECEMBER 31, 2006

    6,756,510     11,075,563     38,901,604       104,978,823       161,712,500  

Comprehensive income:

         

Net income

          143,155,061       143,155,061  

Other comprehensive income:

         

Realized holding gains on marketable securities (net of tax of $(1,411,569))

        (92,693,063 )       (92,693,063 )

Unrealized holding gains arising during the period on marketable securities (net of tax of $814,393)

        53,478,482         53,478,482  

Foreign currency translation adjustments (net of tax of $235,706)

        457,547         457,547  
                           

Total comprehensive income

        (38,757,034 )     143,155,061       104,398,027  

Distributions to shareholders

          (54,480,184 )     (54,480,184 )
                                   

BALANCE AT DECEMBER 31, 2007

  $ 6,756,510   $ 11,075,563   $ 144,570     $ 193,653,700     $ 211,630,343  
                                   

See notes to consolidated financial statements.

 

5


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

CONSOLIDATED STATEMENTS OF CASH FLOWS

 

    Year Ended December 31,  
    2007     2006     2005  

CASH FLOWS FROM OPERATING ACTIVITIES:

     

Net Income

  $ 143,155,061     $ 7,136,914     $ 20,407,785  

Adjustments to reconcile net income to net cash provided by (used in) operating activities:

     

Depreciation and amortization

    6,558,732       5,389,887       4,426,815  

Amortization of intangible asset

    1,230,843      

Net gain from sale of property and equipment

    (446,325 )     (406,312 )     (8,330,437 )

Net gain on sale of marketable securities

    (94,104,632 )     (8,882,610 )     (21,370,376 )

Gain on derivative

        (16,936,063 )

Deferred income taxes

    (302,067 )     491,828       (135,911 )

Minority interest in consolidated subsidiaries

    216,916       (105,505 )     (1,003,135 )

Increase (decrease) in cash attributed to changes in operating assets and liabilities:

     

Receivables

    (58,982,923 )     (59,122,930 )     21,146,222  

Inventory

    (1,104,699 )     (381,115 )     158,479  

Other assets

    (140,464 )     350,900       (4,807,720 )

Advances from (to) joint ventures partners, net

    182,240       (234,845 )     957,325  

Advances from (to) related parties

    2,097,251       (677,465 )  

Unbilled work

    1,577,606       2,190,316       1,803,003  

Accounts payable and other liabilities

    111,195,217       9,385,058       4,773,308  

Deferred contract revenue

    4,104,487       16,042,428       5,165,181  
                       

Net cash provided by (used in) operating activities

    115,237,243       (28,823,451 )     6,254,476  
                       

CASH FLOWS FROM INVESTING ACTIVITIES:

     

Proceeds from sale of property and equipment

    4,585,364       2,808,988       13,186,680  

Proceeds from sales of marketable securities

    147,717,224       21,248,000       29,274,460  

Purchases of property and equipment

    (23,815,351 )     (22,138,835 )     (6,748,292 )

Increase in restricted cash

    (24,000,000 )    

Advances to related parties

    (173,728 )     (1,309,664 )     (511,565 )

Cash acquired from acquisition

    83,494      
                       

Net cash provided by investing activities

    104,397,003       608,489       35,201,283  
                       

CASH FLOWS FROM FINANCING ACTIVITIES:

     

Proceeds from long-term debt

    18,514,200       29,093,397       4,620,477  

Principal payments of long-term debt

    (21,113,084 )     (9,108,310 )     (17,831,050 )

(Paydown) draw on line of credit

    (10,000,000 )     10,000,000    

Distributions to shareholders

    (51,808,194 )     (20,003,774 )     (14,768,598 )
                       

Net cash (used in) provided by financing activities

    (64,407,078 )     9,981,313       (27,979,171 )
                       

Net increase (decrease) in cash and cash equivalents

    155,227,168       (18,233,649 )     13,476,588  

Cash and cash equivalents at beginning of year

    37,575,733       55,809,382       42,332,794  
                       

Cash and cash equivalents at end of year

  $ 192,802,901     $ 37,575,733     $ 55,809,382  
                       

SUPPLEMENTAL CASH FLOW INFORMATION:

     

Cash paid during the period for:

     

Interest

  $ 6,274,740     $ 10,772,006     $ 5,298,228  
                       

Income taxes

  $ 2,633,810     $ 1,628,682     $ 648,021  
                       

NONCASH INVESTING AND FINANCING ACTIVITIES:

     

Marketable securities distributed to shareholder

  $ —       $ 4,061,200     $ —    
                       

Advances to related parties distributed to shareholder

  $ 2,671,990     $ —       $ —    
                       

Capitalized lease obligation incurred for transportation equipment

  $ 521,234     $ 1,260,566     $ 375,677  
                       

Refinancing of long-term debt on equipment

  $ —       $ 10,923,122     $ —    
                       

Unrealized holding gains on marketable securities

  $ 53,478,482     $ 22,628,669     $ 20,348,419  
                       

Accrued liabilities incurred from purchase of marketable securities

  $ —       $ —       $ 19,682,351  
                       

Receivable arising from sale of marketable securities

  $ 12,678,428     $ —       $ 4,391,165  
                       

See notes to consolidated financial statements.

 

6


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

Nature of Business:

Tutor-Saliba Corporation was incorporated in 1981 as a successor to businesses that had been providing construction services since 1949. Tutor-Saliba Corporation and its majority-owned subsidiaries (the “Company”) provide diversified general contracting, design-build, and preconstruction services to public agencies and private clients. The Company’s construction business is conducted through three basic segments or operations: domestic civil, domestic building, and international. The Company focuses on large, complex construction projects in the civil infrastructure and commercial building sectors. The Company manages all aspects of these construction projects and directly performs many significant construction specialties, including concrete forming and placement, site excavation, structural steel erection and electrical and mechanical services. The Company provides these services by using traditional general contracting arrangements, such as fixed price, guaranteed maximum price, and cost plus fee contracts.

In an effort to limit its financial and/or operational risk on certain of its larger and more complex projects, the Company participates in construction joint ventures, often as the sponsor or manager of the project, for the purpose of bidding and, if awarded, providing the agreed-upon construction services. Each joint venture participant usually agrees in advance to provide a predetermined percentage of capital, as required, and to share in the same percentage of profit or loss on the project.

Principles of Consolidation:

The consolidated financial statements include the accounts of Tutor-Saliba Corporation and its majority-owned and controlled subsidiaries. All intercompany balances and transactions have been eliminated in consolidation.

Prior to 2007, The Company’s noncontrolling interests in construction joint ventures were accounted for on the equity method in the consolidated balance sheets and on the proportionate consolidation method in the consolidated statements of income. Beginning in 2007, construction joint venture interests are accounted for using the proportionate consolidation method in the consolidated balance sheets, as well as the consolidated statements of income, whereby the Company’s proportionate share of each joint venture’s assets, liabilities, revenues, and cost of operations are included in the appropriate classifications in the consolidated financial statements. The Company believes the change, which results in presenting all joint venture activity using a consistent methodology in both the consolidated balance sheets and consolidated statements of income, is preferable.

 

7


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

1. SIGNIFICANT ACCOUNTING POLICIES, Continued

 

The change had no impact on the consolidated statements of income for any period presented. Although the change impacted various classifications within the consolidated balance sheets and consolidated statements of cash flows, there was no impact to shareholders’ equity. Consolidated balance sheets and consolidated statements of cash flows have been retrospectively adjusted to conform to the 2007 presentation. The impact on the consolidated financial statements is as follows (in thousands):

Consolidated Balance Sheets

 

    December 31,  
    2007     2006  
    Equity
Method
  Proportionate
Consolidation
Method
  Effect of
Change
    As Previously
Reported
  As
Reported
  Effect of
Change
 

Cash and cash equivalents

  173,739   192,803   19,064     19,956   37,576   17,620  

Receivables

  206,394   223,217   16,823     143,456   175,091   31,635  

Unbilled work

  28,492   29,019   527     18,914   19,281   367  

Equity in and advances to construction joint ventures

  4,289     (4,289 )   2,478     (2,478 )

Other current assets

  6,752   6,896   144     6,940   6,972   32  

Accounts and subcontracts payable

  226,440   236,970   10,530     104,023   122,937   18,914  

Accrued liabilities

  18,482   22,840   4,358     18,673   23,278   4,605  

Advances to affiliates

    416   416       234   234  

Deferred contract revenue

  41,174   56,229   15,055     27,196   47,476   20,280  

Other long-term liabilities

  1,851   3,760   1,909     2,575   5,719   3,144  

Consolidated Statements of Cash Flows

 

     December 31,  
     2007  
     Equity
Method
    Proportionate
Consolidation
Method
    Effect of
Change
 

Net (gain) loss from joint ventures

   (21,191 )     21,191  

Distributions from joint ventures

   21,693       (21,693 )

Receivables

   (73,795 )   (58,983 )   14,812  

Other assets

   (23 )   (3 )   20  

Advances to (from) joint ventures, net

   2,011     182     (1,829 )

Unbilled work

   1,738     1,578     (160 )

Accounts payable and other liabilities

   121,062     111,195     (9,867 )

Deferred contract revenue

   9,329     4,104     (5,225 )

Contributions to joint ventures

   (4,328 )     4,328  

 

8


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

1. SIGNIFICANT ACCOUNTING POLICIES, Continued

 

Consolidated Statements of Cash Flows

 

     December 31,  
    2006     2005  
    As Previously
Reported
    As
Reported
    Effect of
Change
    As Previously
Reported
    As
Reported
    Effect of
Change
 

Net gain from sale of property and equipment

  (454 )   (406 )   48     (7,524 )   (7,507 )   17  

Net (gain) loss from joint ventures

  (6,883 )     6,883     3,794       (3,794 )

Distributions from joint ventures

  21,132       (21,132 )   22,725       (22,725 )

Receivables

  (51,777 )   (59,123 )   (7,346 )   (8,017 )   21,146     29,163  

Other assets

  270     351     81     (4,835 )   (4,808 )   27  

Advances (to) from joint ventures, net

  (267 )   (235 )   32     (6,026 )   957     6,983  

Unbilled work

  2,138     2,190     52     (16,030 )   1,803     17,833  

Accounts payable and other liabilities

  1,540     9,385     7,845     7,234     4,773     (2,461 )

Deferred contract revenue

  6,463     16,042     9,579     4,379     5,165     786  

Proceeds from sale of property and equipment

  1,256     2,809     1,553        

Distributions from joint ventures

        22,948       (22,948 )

Contributions to joint ventures

  (6,368 )     6,368     (3,200 )     3,200  

Principal payments of long-term debt

  (9,094 )   (9,108 )   (14 )   (16,541 )   (17,831 )   (1,290 )

Use of Estimates in the Preparation of Financial Statements:

The consolidated financial statements have been prepared in conformity with accounting principles generally accepted in the United States of America, which require management to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosures of contingent assets and liabilities at the date of the consolidated financial statements, as well as the reported amounts of revenues and expenses during the reporting period. Actual results could differ from those estimates. On an ongoing basis, the Company reviews its estimates based on information that is currently available. Changes in facts and circumstances may result in revised estimates.

Method of Accounting for Contracts:

Revenues and profits from the Company’s construction contracts are recognized by applying percentages of completion for the period to the total estimated profits for the respective contracts. Percentage of completion

is determined by relating the actual cost of the work performed to date to the current estimated total cost of the respective contracts. When the estimate on a contract indicates a loss, the Company’s policy is to record the entire loss during the accounting period in which it is estimated. In the ordinary course of business, at a minimum on a quarterly basis, the Company prepares updated estimates of the total forecasted revenue, cost and profit or loss for each contract. The cumulative effect of revisions in estimates of the total forecasted revenue and costs, including unapproved change orders and claims, during the course of the work is reflected in the accounting period in which the facts that caused the revision become known. The financial impact of these revisions to any one contract is a function of both the amount of the revision and the percentage of completion of the contract. An amount equal to the costs incurred which are attributable to

 

9


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

1. SIGNIFICANT ACCOUNTING POLICIES, Continued

 

unapproved change orders and claims are included in the total estimated revenue when realization is determined to be probable. Profits from unapproved change orders and claims are recorded in the total estimated revenue in the period such amounts are resolved.

The Company includes in current assets and current liabilities amounts related to construction contracts realizable and payable over a period in excess of one year. Deferred contract revenue represents excess of billings to date over the amount of contract costs and profits (or contract revenue) recognized to date on the percentage-of-completion accounting method on certain contracts. Unbilled work represents the excess of contract costs and profits (or contract revenue) recognized to date on the percentage-of-completion accounting method over billings to date on the remaining contracts. Unbilled work results when (1) the appropriate contract revenue amount has been recognized in accordance with the percentage-of-completion accounting method, but a portion of the revenue recorded cannot be billed currently due to the billing terms defined in the contract and/or (2) costs, recorded at estimated realized value, related to unapproved change orders or claims are incurred. Unbilled work on contracts consisted of the following:

 

     December 31,
     2007    2006

Unbilled costs and profits incurred to date

   $ 3,544,855    $ 5,751,342

Unapproved change orders

     14,122,686      5,831,605

Claims

     11,351,393      7,697,870
             
   $ 29,018,934    $ 19,280,817
             

The prerequisite for billing “Unbilled costs and profits incurred to date” is provided in the defined billing terms of each of the applicable contracts. The prerequisite for billing “Unapproved change orders” or “Claims” is the final resolution and agreement between the parties. The amount of unbilled work at December 31, 2007 estimated by management to be collected beyond one year is approximately $5,600,000.

Significant Estimates:

As outlined above, the Company’s revenue is recognized on the percentage-of-completion basis. Consequently, construction revenue and gross margin for each reporting period are determined on a contract-by-contract basis by reference to estimates by the Company’s management of expected costs to be incurred to complete each project. These estimates include provisions for known and anticipated cost overruns and cost recoveries, if any exist or are expected to occur. These estimates are subject to revision in the normal course of business and could be material.

Foreign Currency Translation:

The functional currency for foreign operations is the local currency. The assets and liabilities of the Company’s international subsidiaries are translated into U.S. dollars using current exchange rates at the balance sheet date. Operating statement items are translated at average exchange rates prevailing during the period. The resulting cumulative translation adjustments of $144,570 and $(312,977) at December 31, 2007 and 2006, respectively, are recorded in the foreign currency translation adjustment account as part of accumulated other comprehensive income in shareholders’ equity. Foreign currency transaction gains and losses, if any, are included in operations as they occur.

 

10


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

1. SIGNIFICANT ACCOUNTING POLICIES, Continued

 

Cash and Cash Equivalents:

Cash equivalents represent all highly liquid debt instruments with maturities, when purchased, of three months or less.

Cash and cash equivalents as reported in the accompanying consolidated balance sheets consist of amounts held by the Company that are available for general corporate purposes and the Company’s proportionate share of amounts held by construction joint ventures that are available only for joint venture-related uses. Cash held by construction joint ventures is distributed from time to time to the Company and to the other joint venture participants in accordance with their percentage interest. Cash distributions received by the Company from its construction joint ventures are then available for general corporate purposes. Cash and cash equivalents consisted of the following:

 

     December 31,
     2007    2006

Corporate cash and cash equivalents
(available for general purposes)

   $ 173,738,595    $ 19,955,991

Company’s share of joint venture
cash and cash equivalents (available only for joint venture purposes, including future distributions)

     19,064,306      17,619,742
             
   $ 192,802,901    $ 37,575,733
             

Restricted Cash

As of December 31, 2007 and 2006, the Company had $24,000,000 and $0, respectively, of restricted cash. Restricted cash consists of amounts held as collateral on the revolving credit facility (see Note 5).

Marketable Securities:

The Company accounts for marketable securities, all of which are publicly traded equity securities of Perini Corporation (see Note 8), as available for sale, in accordance with Financial Accounting Standards Board (FASB) Statement No. 115, Accounting for Certain Investments in Debt and Equity Securities. As of December 31, 2007, the Company no longer held any marketable securities. Unrealized holding gains and losses for “available-for-sale” securities were reported as a part of accumulated other comprehensive income in shareholders’ equity until realized. The unrealized holding gains were $0 and $39,214,581 at December 31, 2007 and 2006, respectively.

Accounting for a Derivative:

On March 29, 2000, the Company entered into a shareholders’ agreement (the “Agreement”) with certain shareholders of Perini Corporation, whereby the Company received the option to purchase 2,352,941 shares of Perini Corporation common stock commencing on the third anniversary of the closing of the Agreement and ending on the sixth anniversary of the closing. The call price on the option was set at $4.25 per share and increased by 14% each year the option was outstanding. The option became exercisable on March 29, 2003. On December 30, 2005, the Company exercised its call option for an exercise price of $8.365 per

 

11


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

1. SIGNIFICANT ACCOUNTING POLICIES, Continued

 

share. The option was accounted for as a derivative and recorded at fair value. Unrealized gains and losses were recognized through earnings under the provisions of FASB Statement No. 133, Accounting for Derivative Instruments and Hedging Activities, as amended by FASB Statement No. 149, Amendment of Statement 133 on Derivative Instruments and Hedging Activities. For the year ended December 31, 2005, the Company recorded a gain of $16,936,063 in other income for the change in fair value of the option.

Inventory:

Inventory consists of construction materials, equipment parts, and supplies that have not been assigned and charged to specific contracts. Inventory is stated at the lower of cost or market. Cost is determined generally on the specific identification method.

Property, Equipment, and Long-Lived Assets:

Property and equipment are stated at cost. Depreciation is provided using the straight-line method over its estimated useful lives ranging from three to forty years after an allowance for salvage.

All long-lived assets are reviewed by management in accordance with FASB Statement No. 144, Accounting for the Impairment or Disposal of Long-Lived Assets, for impairment whenever events or changes in circumstance indicate that the carrying value of such assets may not be recoverable from expected future undiscounted cash flows. Major renewals and betterments are capitalized and maintenance and repairs are charged to operations as incurred. When property and equipment are retired or otherwise disposed of, the cost and accumulated depreciation are removed from the appropriate account and any gain or loss is included in results of operations. No impairments were identified as of December 31, 2007 and 2006.

Goodwill and other Intangible Assets:

Goodwill is subject to annual impairment test pursuant to FASB Statement No. 142, Goodwill and Other Intangible Assets. The Company regularly evaluates whether events or circumstances have occurred which may indicate a possible impairment of goodwill. The Company believes the methodology used in testing impairment of goodwill, which includes significant judgements and estimates, provides a reasonable basis in determining whether an impairment charge should be taken.

Income Taxes:

The Company accounts for income taxes in accordance with FASB Statement No. 109, Accounting for Income Taxes, which requires the use of an asset and liability method of accounting for income taxes. Deferred income taxes are provided to reflect the tax effect of differences between the financial statement carrying amounts and the tax bases of assets and liabilities. The Company elected to be treated as an S corporation effective January 1, 1996. As a result, taxable income, loss and credits flow directly to the shareholder and tax-related assets and liabilities of the Company become the obligation of the shareholder of the S corporation and are no longer reflected in the consolidated financial statements. The deferred tax assets, liabilities, and provision reflected in the consolidated financial statements are those that do not flow through to the shareholder, as they relate to taxable subsidiaries.

 

12


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

1. SIGNIFICANT ACCOUNTING POLICIES, Continued

 

In July 2006, the FASB issued FASB Interpretation (FIN) No. 48, Accounting for Uncertainty in Income Taxes—an interpretation of FASB Statement No. 109. FIN No. 48 increases the relevancy and comparability of financial reporting by clarifying the way companies account for uncertainty in measuring income taxes. FIN No. 48 prescribes a comprehensive model for how a company should recognize, measure, present, and disclose in its financial statements uncertain tax positions that the company has taken or expects to take on a tax return. FIN No. 48 only allows a favorable tax position to be included in the calculation of tax liabilities and expenses if a company concludes that it is more likely than not that its adopted tax position will prevail if challenged by tax authorities. FIN No. 48 also provides guidance on the accounting for and recording of interest and penalties on uncertain tax positions. The Company adopted FIN No. 48 on January 1, 2007, and the adoption of FIN No. 48 did not have an impact on the financial condition and results of operations.

Fair Value of Financial Instruments:

Marketable securities approximate their fair value as determined by market quotes. The carrying value of receivables and other amounts arising out of normal contract activities, including retentions that may be settled beyond one year are estimated to approximate fair value. All significant debt obligations, interest rates, and their carrying value are considered to approximate market rates and fair value.

New Accounting Pronouncements:

In September 2006, the FASB issued FASB Statement No. 157, Fair Value Measurements. FASB Statement No. 157 defines fair value, establishes a framework for measuring fair value, and expands disclosures about fair value measurements. In February 2008, the FASB issued FASB Staff Position (FSP) No. FAS 157-1 and FSP No. FAS 157-2, affecting implementation of FASB Statement No. 157. FSP No. FAS 157-1 excludes FASB Statement No. 13, Accounting for Leases, and other accounting pronouncements that address fair value measurements under FASB Statement No. 13, from the scope of FASB Statement No. 157. FSP No. FAS 157-2 delays the effective date of FASB Statement No. 157 for nonfinancial assets and nonfinancial liabilities, except for items that are recognized or disclosed at fair value on a recurring basis, to fiscal years beginning after November 15, 2008. The Company does not believe the adoption of FASB Statement No. 157, as amended by FSP No. FAS 157-1 and FSP No. FAS 157-2 will have a material impact on the financial condition and results of operations.

In February 2007, the FASB issued FASB Statement No. 159, The Fair Value Option for Financial Assets and Financial Liabilities. FASB Statement No. 159 permits entities to choose to measure many financial instruments and certain other items at fair value. The objective of the guidance is to improve financial reporting by providing entities with the opportunity to mitigate volatility in reported earnings caused by measuring related assets and liabilities differently without having to apply complex hedge accounting provisions. FASB Statement No. 159 is effective as of the beginning of the first fiscal year after November 15, 2007. The Company does not believe the adoption of FASB Statement No. 159 will have a material impact on the Company’s financial condition and results of operations.

In December 2007, the FASB issued FASB Statement No. 141 (revised 2007), Business Combinations. FASB Statement No. 141(R) establishes principles and requirements for how an acquirer recognizes and measures in its financial statements the identifiable assets acquired, the liabilities assumed, any noncontrolling interest in the acquiree, and the goodwill acquired. FASB Statement No. 141(R) also

 

13


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

1. SIGNIFICANT ACCOUNTING POLICIES, Continued

 

establishes disclosure requirements to enable the evaluation of the nature and financial effects of the business combination. FASB Statement No. 141(R) is effective for fiscal years beginning after December 15, 2008. The Company will apply the provision of FASB Statement No. 141(R) prospectively as of that date.

In December 2007, the FASB issued FASB Statement No. 160, Noncontrolling Interests in Consolidated Financial Statements—an amendment of Accounting Research Bulletin No. 51. FASB Statement No. 160 establishes accounting and reporting standards for ownership interests in subsidiaries held by parties other than the parent, the amount of consolidated net income attributable to the parent and to the noncontrolling interest, changes in a parent’s ownership interest, and the valuation of retained noncontrolling equity investments when a subsidiary is deconsolidated. FASB Statement No. 160 also establishes disclosure requirements that clearly identify and distinguish between the interests of the parent and the interests of the noncontrolling owners. FASB Statement No. 160 is effective for fiscal years beginning after December 15, 2008. The Company is currently evaluating the potential impact of the adoption of FASB Statement No. 160 on the Company’s financial condition and results of operations.

 

2. RECEIVABLES

Receivables consisted of the following:

 

     December 31,
     2007    2006

Receivables:

     

Contract receivables

   $ 101,435,119    $ 76,403,192

Retainage receivables

     105,522,310      83,099,401

Trade and other

     16,259,186      15,588,525
             

Total receivables

   $ 223,216,615    $ 175,091,118
             

Retainage:

Many of the contracts under which the Company performs work contain retainage provisions. Retainage refers to that portion of revenue earned by the Company but held for payment by the customer pending satisfactory completion of the project. The Company believes that all amounts retained by customers under such provisions are fully collectible. Retainage on active contracts is classified as a current asset regardless of the term of the contract. Retainage is generally collected within one year of the completion of the contract. As of December 31, 2007 and 2006, the amount of retainage expected to be collected beyond one year was $66,775,000 and $38,650,000, respectively.

 

14


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

3. PROPERTY AND EQUIPMENT

 

Property and equipment, at cost, consisted of the following:

 

     December 31,
     2007    2006

Land

   $ 6,591,263    $ 6,591,263

Building and improvements

     61,341,726      60,583,871

Transportation equipment

     10,938,880      11,034,344

Construction equipment

     80,305,067      65,338,114

Office equipment

     2,897,427      2,857,491
             

Property and equipment, gross

     162,074,363      146,405,083

Less accumulated depreciation

     61,582,594      60,432,844
             

Property and equipment, net of depreciation

   $ 100,491,769    $ 85,972,239
             

Included in property and equipment as of December 31, 2007 and 2006 are amounts recorded under capital leases for transportation equipment of $3,350,866 and $3,100,782 respectively. Accumulated depreciation on transportation equipment recorded under capital leases was $1,553,557 and $1,575,298 as of December 31, 2007 and 2006, respectively.

 

4. OPERATING LEASES

During 2005, the Company entered into a new non-cancelable operating lease for a corporate aircraft, after the buyout of an existing lease. The Company has the right to voluntarily terminate the lease and purchase the asset on any installment payment date after the first 12-month anniversary of the lease for the outstanding lease balance. Upon expiration of the initial lease term in December 2015, the Company has the option of either purchasing the asset for the outstanding lease balance or returning the asset to the lessor. The Company’s shareholder has personally guaranteed this lease. Total rental expense under this lease and for the years ended December 31, 2007, 2006, and 2005 was $3,456,380, $3,456,380, and $4,161,426 respectively.

The Company leases facilities from its principal shareholder and an affiliate owned by the principal shareholder under non-cancelable operating lease agreements with monthly payments of $140,000 which increases at 3% per annum beginning July 1, 2007, expiring in July 31, 2016. Lease expense for these leases recorded on a straight-line basis for years ended December 31, 2007, 2006, and 2005 was $1,926,636, $1,823,871, and $1,280,000 respectively.

Future minimum lease payments, including a guaranteed residual of $18,162,015 on the transportation equipment lease at December 31, 2007 are as follows:

 

     Third-Party    Related-Party    Total

2008

   $ 3,456,380    $ 1,756,356    $ 5,212,736

2009

     3,456,380      1,809,047      5,265,427

2010

     3,456,380      1,863,318      5,319,698

2011

     3,456,380      1,919,218      5,375,598

2012

     3,456,380      1,976,794      5,433,174

Thereafter

     28,531,155      7,577,533      36,108,688
                    

Total

   $ 45,813,055    $ 16,902,266    $ 62,715,321
                    

 

15


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

5. LONG-TERM DEBT

 

Long-term debt consisted of the following:

 

      December 31,
     2007    2006
Notes payable collateralized by construction and transportation equipment payable in monthly principal installments of $581,344, plus fixed interest ranging from 6% to 7.9%, through maturity, which extends to January 2013.    $ 26,181,987    $ 21,797,178
Notes payable collateralized by construction and transportation equipment payable in monthly principal and interest installments of $283,645, with fixed interest ranging from 6.02% to 6.99%, through maturity, which extends to December 2012.      11,755,637      7,823,987
Revolving credit facility, secured by certain marketable securities and/or cash and other general assets, monthly interest at prime rate, which is 8.25% and 7.25% at December 31, 2006 and 2007, respectively or fixed at LIBOR plus 1.50%, at the Company’s option, through maturity, which is November 2008. The effective rate at December 31, 2006 was 8.25%.         10,000,000
Term loan, secured by certain marketable securities, monthly interest at prime rate, which is 8.25%, or fixed at LIBOR, plus 1.5%, at the Company’s option, which is 6.85% at December 31, 2006, through maturity, which was November 2007. The effective rate at December 31, 2006 was 6.85%.         10,000,000
Real estate note payable in monthly installments of $199,365, including principal and interest fixed at 8.47% through maturity, which is July 2010.      24,370,345      24,656,525
Mortgage note, guaranteed by the principal shareholder, payable in monthly installments of interest only at prime rate, which is 7.25% at December 31, 2007, through maturity, which is October 2008.      1,460,000      1,460,000
Mortgage note payable in monthly installments of $8,711, including principal and interest fixed at 6.5% through maturity, which is August 2011.      312,108      393,461
Transportation equipment capital leases payable through maturity, which is June 2011.      1,610,849      1,351,329
             
Long-term debt      65,690,926      77,482,480
Less current maturities      12,074,077      17,261,589
             
Long-term debt, less current maturities    $ 53,616,849    $ 60,220,891
             

 

16


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

5. LONG-TERM DEBT, Continued

 

The Company, in September 2007, entered into a new revolving credit facility, which expires on August 2009. The facility, which replaced a $25,000,000 existing facility, provides for borrowings up to $50,000,000, including a letter of credit facility of up to $8,000,000. As of December 31, 2007 and 2006 outstanding balances under the credit facilities were $0 and $10,000,000, in addition to standby letters of credit in the amounts of $6,531,696 and $4,500,000 and availability under the credit facilities was $43,468,304, and $10,500,000 respectively. Certain of the Company’s marketable securities and/or cash and other general assets secure the credit facility. The credit facility contains certain financial covenants, including maintenance of minimum levels of net worth and profitability and maintenance of certain debt-to-worth and current ratios. At December 31, 2007 and 2006, the Company was in compliance with its financial covenants.

The mortgage notes payable are collateralized by separate first trust deeds on real property. The real estate note payable is collateralized by a deed of trust on real property (commercial real estate).

Maturities of long-term debt at December 31, 2007 are as follows:

 

2008

   $ 12,074,077

2009

     10,835,411

2010

     33,962,152

2011

     5,820,357

2012

     2,989,875

Thereafter

     9,054
      

Total

   $ 65,690,926
      

 

17


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

6. INCOME TAXES

 

The provision for income taxes includes the following:

 

     Year Ended December 31,  
     2007     2006     2005  

Current

      

State

   $ 2,377,493     $ 240,711     $ 761,330  

Federal

     249,201       277,997       11,197  

Foreign

     2,079,402       655,971       217,102  
                        

Total current

     4,706,096       1,174,679       989,629  
                        

Deferred

      

State

     (422,026 )     181,161       (256,005 )

Foreign

     119,959       310,667       120,094  
                        

Total deferred

     (302,067 )     491,828       (135,911 )
                        

Total provision for income taxes

     4,404,029       1,666,507       853,718  

Less attributed to discontinued operations

     4,798       3,875       4,869  
                        

Provision for income taxes from continuing operations

   $ 4,399,231     $ 1,662,632     $ 848,849  
                        
The table below reconciles the difference between the statutory federal income tax rate and the effective rate provided for income before income taxes in the consolidation statements of income.   
     Year Ended December 31,  
     2007     2006     2005  

Federal income taxes at the statutory rate

   $ 51,398,577     $ 3,081,197     $ 7,195,520  

State income taxes, net of federal benefits

     1,941,051       421,872       506,794  

Permanent Differences

      

Earnings subject to different federal corporate tax rates

     (48,588,048 )     (1,293,088 )     (6,668,534 )

Change in valuation allowance

       (416,457 )     (334,033 )

Change in rates

     (22,874 )     (71,996 )     (205,586 )

Foreign earnings taxed at different rates

     (217,476 )     (80,108 )     235,173  

Other

     (107,201 )     25,087       124,384  
                        

Total provision for income taxes

     4,404,029       1,666,507       853,718  

Less attributed to discontinued operations

     4,798       3,875       4,869  
                        

Provision for income taxes from continuing operations

   $ 4,399,231     $ 1,662,632     $ 848,849  
                        

 

18


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

6. INCOME TAXES, Continued

 

The total income before taxes for the years ended is recorded as follows:

 

     Year Ended December 31,
     2007    2006     2005

Income before taxes:

       

Domestic

   $ 140,647,726    $ 5,588,177     $ 20,884,279

Foreign

     6,911,364      3,215,244       377,224
                     

Total income before taxes

     147,559,090      8,803,421       21,261,503

Less attributed to discontinued operations

     230,842      (31,895 )     1,411,898
                     

Total income before taxes from continuing operations

   $ 147,328,248    $ 8,835,316     $ 19,849,605
                     

Operating loss carryforwards of the Company’s taxable subsidiaries, which totaled $1,606,774, were fully utilized in 2006. The decrease in the valuation allowance for years ended December 31, 2006 and 2005, associated with these operating loss carryforwards were $694,579 and $334,405, respectively.

Components of the net deferred tax liability (asset) recognized by type of temporary difference are as follows:

 

     December 31,  
     2007     2006  

Current

    

Other

   $ (192,896 )   $ (158,245 )
                

Total current

     (192,896 )     (158,245 )
                

Non-Current

    

Contract accounting

     (16,442 )     97,672  

Depreciation

     1,325,899       1,098,959  

Unrealized gain on marketable securities

       1,154,294  

Sale of stock book/tax difference

       (177,528 )

Other

     1,967       2,619  
                

Total noncurrent

     1,311,424       2,176,016  
                

Total

   $ 1,118,528     $ 2,017,771  
                

As of January 1, 2007 and December 31, 2007, the Company identified and reviewed potential uncertainties related to taxes upon the adoption of FIN 48 and determined that the exposure to those uncertainties did not have a material impact on the Company’s results of operations or financial condition.

The Company recognizes interest and penalties accrued related to uncertain tax positions as a component of the income tax provision. There were no material uncertain tax positions as of December 31, 2007 and 2006. For the years ended December 31, 2007, 2006, and 2005, there have been no interest and penalties recorded as a component of the income tax provision.

 

19


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

7. STOCK TRANSACTION

 

On October 1, 2007, certain executives of the Company entered into a Stock Purchase Agreement with the Company’s principal shareholder (“principal shareholder”), in which the executives acquired 34,500 shares of common stock of the Company, representing 3.83% of the shares outstanding, for total consideration of $9,582,179. In addition, the parties entered into a Buy-Sell Agreement (“Buy-Sell”) dated October 1, 2007, placing substantial restrictions on the ability of the executives to sell the shares acquired under the Agreement.

In the event that the executives terminate their employment with the Company, the Buy-Sell provides that the principal shareholder has a right to purchase the shares acquired by the executives at the original price. The Buy-Sell terminates on the occurrence of a reorganization, merger, or consolidation involving another corporation in which the Company is not the survivor, or the closing of a public offering of the shares of stock of the Company (“IPO”).

Because of the restrictions placed on transfer or sale of the shares, the executives’ rights to any excess of the fair value of the shares estimated at $555 per share at the grant date over cost (in the amount of $9,565,321) can only be realized through the termination of the agreement or at the sole discretion of the principal shareholder to pay fair market value under certain provisions of the agreement. Accordingly, no compensation expense will be recognized in connection with this transaction until such time that termination of the Buy-Sell Agreement becomes likely or the Buy-Sell Agreement is terminated.

 

8. RELATED-PARTY TRANSACTIONS

At December 31, 2007 and 2006, the Company’s principal shareholder has provided guarantees to the Company in the maximum amount of $11,000,000 that support recovery of the Company’s minority interest receivable related to the Company’s commercial real estate.

At December 31, 2007 and 2006, the Company’s principal shareholder also has provided a guarantee on a transportation equipment lease. In addition, the Company’s principal shareholder has non-cancelable operating leases on facilities (see Note 4).

The Company’s principal shareholder is Chairman and CEO of Perini Corporation. Included in the Company’s consolidated financial statements are $0 and $93,424,299 as of December 31, 2007 and 2006, respectively, in marketable securities and $0 and $39,214,581 as of December 31, 2007 and 2006, respectively, in unrealized holding gains arising during the period on marketable securities, both in connection with the Company’s ownership of Perini Corporation common shares.

As a condition to an investor group’s acquisition of shares of Perini Corporation Series B Preferred Stock for an aggregate of $30 million, which was approved by the shareholders in January 1997, Perini Corporation entered into an agreement with the Company and sole shareholder of the Company, to provide certain management services, as defined. The management agreement has been renewed annually by the Perini Corporation Board of Directors under the same basic terms and conditions as the initial agreement except that the amount of the annual fee payable thereunder to the Company was increased effective September 15, 2004, from $375,000 to $800,000, and effective March 15, 2006, from $800,000 to $900,000. Compensation for the sole shareholder to provide management services consisted of $800,000 for the year ended December 31, 2005, and $879,000 for the year ended December 31, 2006 and $979,000 for the year ended December 31, 2007. Payments under the agreement paid to the Company were passed directly to the sole shareholder.

 

20


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

8. RELATED-PARTY TRANSACTIONS, Continued

 

Included in the Company’s consolidated financial statements are $25,267,005, $18,986,733, and $25,488,288 in revenues for the years ended December 31, 2007, 2006, and 2005, respectively, derived from the Company’s interest in various construction joint ventures with Perini Corporation. Also included were total assets of $13,893,235 and $11,942,279 as of December 31, 2007 and 2006, respectively, relating to these construction joint ventures. One of these joint ventures is involved in a continuing dispute with the Los Angeles County Metropolitan Transportation Authority (see Note 12).

The Company’s principal shareholder, and an affiliate of the principal shareholder, had $0 and $4,595,513 due to the company as of December 31, 2007 and 2006, respectively. The 2006 amounts consisted of construction services due from an affiliate of the shareholder, and the shareholder, as well as short-term advances.

An affiliate of the Company’s principal shareholder had an outstanding note payable due to a joint venture, of which the Company’s proportionate share was $210,368 at December 31, 2007 and 2006, and is included in the accompanying consolidated balance sheets.

 

9. RETIREMENT PLANS

The Company participates in multi-employer defined benefit pension plans in connection with union collective bargaining agreements. Contributions are based upon hours worked by employees covered under these agreements and are funded on a current basis. The Company contributed and charged to expense $9,053,011, $3,198,333, and $2,317,922 for the years ended December 31, 2007, 2006, and 2005, respectively. The increase in 2007 was primarily due to increased operations from a single, large project located in Nevada.

The Company sponsors a 401(k) profit-sharing plan for non-union domestic employees. Effective July 1, 2006, the Company began contributing $0.30 per dollar (an increase from $0.25 per dollar) of employee contributions up to 10% of eligible salary. Participants are fully vested in their contributions and vest at a rate of 20% per year of participation in the plan, becoming fully vested in 5 years. The Company contributed and charged to expense $458,555, $369,497, and $262,778 for the years ended December 31, 2007, 2006, and 2005, respectively.

The Company sponsors a 401(k) profit-sharing plan for non-union territory of Guam employees. The Company contributes $0.25 per dollar of employee contributions up to 6% of eligible salary. Participants are fully vested in their contributions and vest at a rate of 20% per year of participation in the plan, becoming fully vested in 5 years. The Company contributed and charged to expense $69,858, $57,228, and $43,867 for the years ended December 31, 2007, 2006, and 2005, respectively.

 

10. ACQUISITION

Acquisition of Powerco Electric Corp.

On September 30, 2007, the Company purchased 100% of the outstanding stock of Powerco Electric Corp. (“PEC”), a commercial electrical subcontractor, for $3,300,000 in cash. PEC, performs work in and around the Los Angeles area, specializing in commercial building projects. The Company has included PEC’s assets and liabilities in the December 31, 2007 consolidated balance sheet. The results of operations beginning October 1, 2007 are included in the Company’s consolidated financial statements.

 

21


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

10. ACQUISITION, Continued

 

The transaction was accounted for using the purchase method of accounting as required by FASB Statement No. 141, Business Combinations, including the allocation of the purchase to the tangible and intangible assets of Powerco Electric Corp., which has been finalized. The following table summarizes the fair value of the assets acquired and liabilities assumed as of September 30, 2007:

 

Current assets

   $ 21,684,107  

Property and equipment, net

     325,969  

Goodwill

     2,826,117  

Intangibles

     4,160,000  
        

Total assets acquired

     28,996,193  

Current liabilities

     (7,745,611 )

Other long-term liabilities

     (17,950,582 )
        

Total acquisition costs

   $ 3,300,000  
        

The following table identifies the intangible asset acquired and its respective amortization period. The amount assigned to an intangible asset represents the Company’s estimate of the fair value of the intangible asset acquired, which is being amortized in relation to contract revenue as of October 1, 2007.

 

     Amount    Amortization Period

Construction contract backlog

   $ 4,160,000    4 years
         

Total intangible asset acquired

   $ 4,160,000   
         

 

11. SIGNIFICANT RISKS AND UNCERTAINTIES

Concentrations:

A majority of the Company’s cash balances are on deposit with financial institutions and exceed federally insured deposit limits. A substantial portion of the Company’s labor force (40%) is subject to collective bargaining agreements, which expire in years 2008 and beyond. Revenues from various projects in California for University of California, Los Angeles totaled $161,809,062 (or 31% of consolidated revenues) in 2006, and $181,410,073 (or 46% of consolidated revenues) in 2005. Revenues from a single project in Nevada for Wynn Las Vegas, LLC totaled $581,506,255 (or 50% of consolidated revenues) in 2007, and $120,215,151 (or 23% of consolidated revenues) in 2006. Revenues from two projects for California Department of Transportation totaled $89,910,092 (or 23% of consolidated revenues) in 2005. Revenues from a single project for Los Angeles World Airports totaled $64,746,760 (or 12% of consolidated revenues) in 2006.

The Company had accounts receivable due from various projects for University of California, Los Angeles in the amount of $39,284,017 (or 18% of receivables) in 2007, and $62,323,735 (or 43% of receivables) in 2006. Accounts receivable due from a single project for Wynn Las Vegas, LLC totaled $95,398,666 (or 43% of receivables) in 2007, and $22,130,719 (or 15% of receivables) in 2006.

 

22


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

12. OTHER COMMITMENTS AND CONTINGENCIES

 

Contingent liabilities of the Company include the industry standard contractor liabilities for performance and completion of construction contracts. In addition, the Company is a defendant in various lawsuits. Except as discussed below, in the opinion of management, the resolution of these matters will not likely have a material adverse effect on the financial position, result of operations or cash flows of the Company.

The Company, from time to time, enters into certain types of contracts that contingently require the Company to indemnify parties against third-party claims. These contracts primarily relate to: (i) business sales and purchase agreements, under which the Company may provide customary indemnification, and (ii) certain lease agreements, under which the Company may be required to indemnify the lessor for environmental and other liabilities, and other claims arising from the Company’s use of the applicable asset.

The terms of such obligations vary. Generally, a maximum obligation is not explicitly stated. Because the obligated amounts of these types of agreements often are not explicitly stated, the overall maximum amount of the obligations cannot be reasonably estimated. Historically, the Company has not been obligated to make significant payments for these obligations, and no liabilities have been recorded for these obligations on its consolidated balance sheets as of December 31, 2007 and 2006.

Tutor-Saliba/Perini JV v. Los Angeles MTA—1995:

Los Angeles Superior Court Case No. BC 123559

In March 1995, a joint venture, Tutor-Saliba/Perini (“TSP”), in which Tutor-Saliba Corporation is the 60% partner, filed a complaint in Los Angeles Superior Court against the Los Angeles County Metropolitan Transportation Authority (“MTA”) for breach of contract, which sought damages of approximately $16 million to compensate TSP and its subcontractors for the costs of extra work, delays, and interest on late payments under four separate contracts with the MTA. In February 1999, the MTA filed a cross-complaint generally alleging violation of the California False Claims Act (“CFCA”) and several other federal and state statutory provisions.

Trial commenced before a jury in May 2001. During trial, the Judge ruled that TSP may have failed to produce certain documents to the MTA, and the Judge penalized TSP for its alleged non-compliance by dismissing TSP’s claim and by ruling, without jury finding of fact, that TSP was liable to the MTA for damages on the MTA’s counterclaim. Pursuant to the Judge’s instructions, the Jury awarded the MTA approximately $32 million in damages and prejudgment interest, subsequently, in March 2002, the judge awarded an additional $31 million in legal fees and costs. Tutor-Saliba’s share of the aggregate award being approximately $37.8 million.

TSP appealed the verdict and the Court’s rulings on motions and sanctions.

On January 25, 2005, the State of California Court of Appeal issued an opinion in which it reversed the entire $63 million trial court’s judgment and found that the trial court judge had abused his discretion and violated TSP’s due process rights and imposed an impermissibly overbroad sanction in issuing terminating sanctions that prevented the joint venture from presenting its claims and severely limited TSP in defending itself against the MTA’s lawsuit. The Court of Appeal also directed the trial court to dismiss MTA’s claims that TSP had violated the Unfair Competition Law and remanded the remainder of the case to the trial court for further proceedings, including a new trial, with a new judge, on the joint venture’s claims against the MTA.

 

23


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

12. OTHER COMMITMENTS AND CONTINGENCIES, Continued

 

The case was reassigned to the Complex Civil Division, Los Angeles Superior Court—Central Civil West, with the Presiding Judge of that division being assigned to the case. The Court is seeking ways to resolve the case short of full trial, but in a manner that would be upheld by the Court of Appeal, elected to bifurcate the trial and try the MTA’s suggested strongest claim first. That claim was a pass-through subcontractor claim that the MTA agreed to pay through an executed change order for approximately $111,000, in or about 1995 (“Tunnel Handrail” claim). Trial commenced on the MTA’s Tunnel Handrail claim on November 17, 2006, and was completed on December 18, 2006, with the Jury entering a verdict in favor of the MTA pertaining to the “handrail” issue. A final judgment with respect to this claim will not be entered until the entire case has been resolved and will be subject to appeal.

In February 2007, the court granted TSP a motion and precluded MTA in future proceedings from presenting its claims that TSP breached its contract and violated the CFCA.

On December 26, 2007 the Court issued an order and opinions regarding TSP’s and MTA’s affirmative claims, on the “night restrictions” issues, which determined that no claims have sufficient prima facie evidence to proceed to trial. MTA has filed a notice of its intent to seek a “new trial” as to the Court’s denial of MTA’s night restrictions claims in the entirety.

The court has indicated that it would like the parties to resolve the entire case through mediation. Those efforts to date have failed.

Due to the major issues of the case still remaining to be scheduled for retrial, the ultimate financial impact of the lawsuit is not yet determinable. Therefore, no provision for loss, if any, has been recorded in the consolidated financial statements.

 

13. LITIGATION SETTLEMENT

City and County of San Francisco v. Tutor-Saliba Corporation, Perini Corporation and

Buckley & Company Inc., A Joint Venture, et al.—2003:

United States District Court-Northern District Case No. C02-5286-CW

On November 1, 2002, the City and County of San Francisco (“CCSF”) filed a complaint in United States District Court-Northern District against the joint venture, Tutor-Saliba Corporation, Perini Corporation and Buckley & Company, Inc. (“TSPB”), its individual members, including Tutor-Saliba Corporation (the “Company”) and their respective bonding companies. The complaint was not served on the Company or the bonding companies until 2003. The complaint arose out of six San Francisco International Airport construction contracts with the San Francisco Airport Commission (“Airport Commission”) entered into during 1996 and 1997 that were subsequently successfully completed and closed-out under an agreement between TSPB, the Company, and the Airport Commission, in 2001.

On February 17, 2006, a settlement agreement was reached with the CCSF during mediation. The settlement agreement was reached in pursuit of the best interests of all parties involved, to put to rest divisive issues, and avoid the considerable continuing future cost and expense of litigation. The agreement resolves all issues of disputed liability between the parties and allows the parties to refocus their resources towards more productive purposes. The settlement agreement provided that the CCSF will be paid the total sum of $19 million, payable over a period of years ending in 2009. The Company recorded a charge to net income of $14,651,537 representing its portion of this settlement in the year ended December 31, 2005. The San Francisco Board of Supervisors and the Airport Commission approved the agreement on March 30, 2006. At

 

24


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

13. LITIGATION SETTLEMENT, Continued

 

December 31, 2007, the Company’s present value portion of the remaining liability of $5,551,486, of which $2,179,960 is current, is included in the accompanying consolidated balance sheet.

 

14. DISCONTINUED OPERATIONS

Effective January 1, 2008, the Company entered into an exchange transaction with an affiliate owned by the Company’s majority shareholder. The Company transferred its partnership interest in a commercial office building in exchange for a 2% interest in one of the Company’s consolidated subsidiaries that was held by the affiliated company. The December 31, 2007 consolidated balance sheet reflects $26,759,142 in property and equipment, minority interest receivable of $13,423,058, cash of $3,855,279, other net assets of $1,853,748 and mortgage debt of $24,370,345 associated with the Company’s interest in this partnership. The December 31, 2007 book value of the 2% interest in the Company’s consolidated subsidiary is $250,749. Based on this exchange transaction, the activities relating to the commercial office building have been reported as discontinued operations for all periods presented. Revenues of $6,686,436, $6,393,109 and $6,342,813 and pretax income (loss) of $230,842, $(31,895) and $1,411,898 for the years ended December 31, 2007, 2006 and 2005, respectively were reported as discontinued operations. The transaction had no impact to net income in the accompanying consolidated statements of income. The net book value of assets distributed over assets received was recorded as a distribution of $21,270,133 on January 1, 2008.

 

15. SUBSEQUENT EVENTS

Purchase of North Valley Commerce Center, Building G

On October 30, 2007, the Company entered into an agreement to purchase the North Valley Commerce Center, Building G in Sylmar California for $6.5 million in cash. The property will consist of an office and warehouse facility, currently under construction. As of January 25, 2008, the Company has made initial deposits for the property totaling $300,000 into an escrow account. The purchase is expected to close upon substantial completion of the building.

Acquisition of Desert Plumbing & Heating Co. Inc.

On January 4, 2008, the Company purchased 100% of the outstanding stock of Desert Plumbing & Heating Co. Inc. (“DPH”), a mechanical subcontractor located in Las Vegas, NV, for $35.0 million cash and an earn-out based upon a percentage of DPH’s earnings over the next three years, up to a maximum of $4 million annually. DPH operates primarily in the state of Nevada and had approximately 25 contracts in progress, primarily in the Las Vegas hotel and gaming market, at the time of the acquisition.

In the event the Company becomes a public company by public offering or otherwise, the earn-out payments to the former DPH shareholders will be payable in shares of stock in the parent company in an amount equivalent to the maximum earn-out payment of $12 million.

The transaction will be accounted for using the purchase method of accounting as required by FASB Statement No. 141 Business Combinations, including the allocation of the purchase to the tangible and intangible assets of DPH.

 

25


TUTOR-SALIBA CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

As of December 31, 2007 and 2006 and for each of the three years in the period ended December 31, 2007

15. SUBSEQUENT EVENTS, Continued

 

All Star Aggregate, Inc.

On March 7, 2008, the Company entered into an agreement for the transfer and purchase of certain mineral material mining contracts, equipment, and material stockpiles used to operate All Star Aggregate, Inc.’s existing business in Sloan Pit, located in Clark County, NV, for a purchase price of $5,200,000.

Bureau of Land Management Leases

On March 12, 2008, the Company entered into a ten-year renewable contract with the Bureau of Land Management (“BLM”) for the extraction of 19,500,000 tons of limestone aggregate on land located at Mount Diablo Meridian, NV. Pursuant to the Company’s September 12, 2007 high bid of $0.90 per ton and a $0.01 per ton administrative fee, the total contract price equates to $17,745,000 and requires a 5% deposit in the amount of $877,500 prior to beginning extraction. The balance of the contract price will be paid monthly over the contract term based upon the value of materials removed in the prior month. In addition, the Company is obligated under a separate agreement to pay a third party a finders fee related to the transaction in the amount of $300,000.

Perini Merger

On April 2, 2008, the Company entered into a definitive agreement with Perini Corporation, a publicly traded construction company, under which the two companies would be combined, in tax-free, all-stock merger. The transaction is subject to customary closing conditions, including the approval of Perini’s shareholders and receipt of regulatory approvals.

 

26