XML 50 R18.htm IDEA: XBRL DOCUMENT v3.3.0.814
COMMITMENTS AND CONTINGENCIES
9 Months Ended
Sep. 30, 2015
Statement [Line Items]  
Commitments and Contingencies Disclosure [Text Block]
COMMITMENTS AND CONTINGENCIES

Nuclear Insurance

Under Price-Anderson, SCE&G (for itself and on behalf of Santee Cooper, a one-third owner of Summer Station Unit 1) maintains agreements of indemnity with the NRC that, together with private insurance, cover third-party liability arising from any nuclear incident occurring at SCE&G's nuclear power plant. Price-Anderson provides funds up to $12.9 billion for public liability claims that could arise from a single nuclear incident. Each nuclear plant is insured against this liability to a maximum of $375 million by ANI with the remaining coverage provided by a mandatory program of deferred premiums that could be assessed, after a nuclear incident, against all owners of commercial nuclear reactors. Each reactor licensee is currently liable for up to $127.3 million per reactor owned for each nuclear incident occurring at any reactor in the United States, provided that not more than $18.9 million of the liability per reactor would be assessed per year. SCE&G’s maximum assessment, based on its two-thirds ownership of Summer Station Unit 1, would be $84.8 million per incident, but not more than $12.6 million per year. Both the maximum assessment per reactor and the maximum yearly assessment are adjusted for inflation at least every five years.

SCE&G currently maintains insurance policies (for itself and on behalf of Santee Cooper) with NEIL. The policies provide coverage to Summer Station Unit 1 for property damage and outage costs up to $2.75 billion resulting from an event of nuclear origin. In addition, a builder's risk insurance policy has been purchased from NEIL for the construction of the New Units. This policy provides the owners of the New Units up to $500 million in limits of accidental property damage occurring during construction. The NEIL policies, in the aggregate, are subject to a maximum loss of $2.75 billion for any single loss occurrence. All of the NEIL policies permit retrospective assessments under certain conditions to cover insurer’s losses. Based on the current annual premium, SCE&G’s portion of the retrospective premium assessment would not exceed $45.9 million.
 
To the extent that insurable claims for property damage, decontamination, repair and replacement and other costs and expenses arising from a nuclear incident at Summer Station Unit 1 exceed the policy limits of insurance, or to the extent such insurance becomes unavailable in the future, and to the extent that SCE&G's rates would not recover the cost of any purchased replacement power, SCE&G will retain the risk of loss as a self-insurer. SCE&G has no reason to anticipate a serious nuclear incident. However, if such an incident were to occur, it likely would have a material impact on the Company’s results of operations, cash flows and financial position.

New Nuclear Construction

In 2008, SCE&G, on behalf of itself and as agent for Santee Cooper, contracted with the Consortium for the design and construction of the New Units at the site of Summer Station.  

SCE&G's current ownership share in the New Units is 55%. As discussed below, under an agreement signed in January 2014 (and subject to customary closing conditions, including necessary regulatory approvals), SCE&G has agreed to acquire an additional 5% ownership in the New Units from Santee Cooper.

EPC Contract and BLRA Matters

The construction of the New Units and SCE&G’s related recovery of financing costs through rates is subject to review and approval by the SCPSC as provided for in the BLRA. Under the BLRA, the SCPSC has approved, among other things, a milestone schedule and a capital costs estimates schedule for the New Units. This approval constitutes a final and binding determination that the New Units are used and useful for utility purposes, and that the capital costs associated with the New Units are prudent utility costs and expenses and are properly included in rates, so long as the New Units are constructed or are being constructed within the parameters of the approved milestone schedule, including specified schedule contingencies, and the approved capital costs estimates schedule. Subject to the same conditions, the BLRA provides that SCE&G may apply to the SCPSC annually for an order to recover through revised rates SCE&G’s weighted average cost of capital applied to all or part of the outstanding balance of construction work in progress concerning the New Units. Such annual rate changes are described in Note 2. As of September 30, 2015, SCE&G’s investment in the New Units, including related transmission, totaled $3.3 billion, for which the financing costs on $2.4 billion have been reflected in rates under the BLRA.

The SCPSC granted initial approval of the construction schedule and related forecasted capital costs in 2009. The NRC issued COLs in March 2012. In November 2012, the SCPSC approved an updated milestone schedule and additional updated capital costs for the New Units. In addition, the SCPSC approved revised substantial completion dates for the New Units based on that March 2012 issuance of the COL and the amounts agreed upon by SCE&G and the Consortium in July 2012 to resolve known claims by the Consortium for costs related to COL delays, design modifications of the shield building and certain prefabricated structural modules for the New Units and unanticipated rock conditions at the site. In October 2014, the South Carolina Supreme Court affirmed the SCPSC's order on appeal.

Since the settlement of delay-related claims in 2012, the Consortium has continued to experience delays in the schedule, including those related to fabrication and delivery of sub-modules for the New Units. The fabrication and delivery of sub-modules have been and remain focus areas of the Consortium. Shield building panels are considered critical path items for both New Units, and the current schedule for production of such panels will require mitigation to support the updated substantial completion dates (see below).

During the fourth quarter of 2013, the Consortium began a full re-baselining of the Unit 2 and Unit 3 construction schedules to incorporate a more detailed evaluation of the engineering and procurement activities necessary to accomplish the schedules and to provide a detailed reassessment of the impact of the revised Unit 2 and Unit 3 schedules on engineering and design resource allocations, procurement, construction work crew efficiencies, and other items. The result was a revised, fully integrated project schedule with timing of specific construction activities (Revised, Fully-Integrated Construction Schedule) along with related cost information.

The Revised, Fully-Integrated Construction Schedule indicated that the substantial completion of Unit 2 was expected to occur in mid-June 2019 and that the substantial completion of Unit 3 was expected to be approximately 12 months later. The Consortium continues to refine and update the Revised, Fully-Integrated Construction Schedule as designs are finalized, as construction progresses, and as additional information is received.

In September 2015, the SCPSC approved an updated BLRA milestone schedule based on revised substantial completion dates for Units 2 and 3 of June 2019 and June 2020, respectively, each subject to an 18-month contingency period. In addition, the SCPSC approved certain updated owner's costs ($245 million) and other capital costs ($453 million), of which $539 million were associated with the schedule delays and other contested costs. SCE&G's total projected capital costs (in 2007 dollars) and gross construction cost estimates (including escalation and AFC) were estimated to be $5.2 billion and $6.8 billion, respectively. These projections included cost amounts related to the Revised, Fully-Integrated Construction Schedule for which SCE&G had not accepted responsibility and which were the subject of dispute. As such, these updated milestone schedule and projections did not reflect the resolution of negotiations. In addition, the SCPSC approved a revision to the allowed return on equity for new nuclear construction from 11.0% to 10.5%. This revised return on equity will be applied prospectively for the purpose of calculating revised rates sought by SCE&G under the BLRA on and after January 1, 2016, until such time as the New Units are completed.

On October 27, 2015, SCE&G, Santee Cooper and the Consortium reached a settlement regarding the above mentioned disputes, and the EPC Contract was amended. The October 2015 Amendment will become effective upon the consummation of the acquisition by WEC of the stock of Stone & Webster from CB&I, and will become null and void in the event such acquisition is not consummated by March 31, 2016. Following that acquisition, Stone & Webster will continue to be a member of the Consortium as a subsidiary of WEC rather than CB&I, and WEC intends to engage Fluor Corporation or its affiliate(s) as a subcontracted construction manager.

Among other things, upon effectiveness, the October 2015 Amendment would (i) resolve by settlement and release substantially all outstanding disputes between SCE&G and the Consortium, in exchange for (a) an additional cost to be paid by SCE&G and Santee Cooper of $300 million (SCE&G’s 55% portion being $165 million) and an increase in the fixed component of the contract price by that amount, and (b) a credit to SCE&G and Santee Cooper of $50 million (SCE&G’s 55% portion being approximately $27 million) to be applied to the target component of the contract price, (ii) revise the guaranteed substantial completion dates of Units 2 and 3 to August 31, 2019 and 2020, respectively, (iii) revise the delay-related liquidated damages computation requirements, including those related to the eligibility of the New Units to earn Internal Revenue Code Section 45J production tax credits (see also below), and cap those aggregate liquidated damages at $463 million per New Unit (SCE&G’s 55% portion being approximately $255 million per New Unit), (iv) provide for payment to the Consortium of a completion bonus of $275 million per New Unit (SCE&G’s 55% portion being approximately $151 million per New Unit) for each New Unit placed in service by the deadline to qualify for production tax credits, (v) provide for the development of a revised construction milestone payment schedule, with SCE&G and Santee Cooper making monthly payments of $100 million (SCE&G’s 55% portion being $55 million) for each of the first five months following effectiveness, followed by payments made based on milestones achieved, and (vi) provide that SCE&G and Santee Cooper waive and cancel the CB&I parent company guaranty with respect to the project. The payment obligations under the EPC Contract are joint and several obligations of WEC and Stone & Webster, and the October 2015 Amendment provides for Toshiba Corporation, WEC’s parent company, to reaffirm its guaranty of WEC’s payment obligations. Under the October 2015 Amendment, SCE&G’s total estimated project costs will increase by approximately $286 million over the $6.8 billion approved by the SCPSC in September 2015, and will bring its total estimated gross construction cost of the project (including escalation and AFC) to approximately $7.1 billion.

In addition to the above, upon effectiveness, the October 2015 Amendment would provide for an explicit definition of a Change in Law designed to reduce the likelihood of certain future commercial disputes. As part of this, the Consortium would also acknowledge and agree that the project scope includes providing New Units that meet the standards of the NRC approved Design Control Document Revision 19. The October 2015 Amendment would also establish a dispute resolution board process for certain commercial claims and disputes, including any dispute that might arise with respect to the development of the revised construction milestone payment schedule referred to above. The EPC Contract would also be revised to eliminate the requirement or ability to bring suit before substantial completion of the project.

Finally, upon effectiveness, the October 2015 Amendment would provide SCE&G and Santee Cooper an irrevocable option, until November 1, 2016 and subject to regulatory approvals, to further amend the EPC Contract to fix the total amount to be paid to the Consortium for its entire scope of work on the project (excluding a limited amount of work within the time and materials component of the contract price) after June 30, 2015 at $6.082 billion (SCE&G’s 55% portion being approximately $3.345 billion). This total amount to be paid would be subject to adjustment for amounts paid since June 30, 2015. Were this fixed price option to be exercised, the aggregate delay-related liquidated damages amount referred to in (iii) above would be capped at $338 million per unit (SCE&G’s 55% portion being approximately $186 million per unit), and the completion bonus amounts referred to in (iv) above would be $150 million per New Unit (SCE&G’s 55% portion being approximately $83 million per New Unit). The exercise of this fixed price option would result in SCE&G’s total estimated project costs increasing by approximately $774 million over the $6.8 billion approved by the SCPSC in September 2015, and would bring its total estimated gross construction cost (including escalation and AFC) of the project to approximately $7.6 billion.

Resolution of the disputes as described in (i) above, or in the case of the exercise of the fixed price option, would result in estimated project costs above the amounts approved by the SCPSC; however, the guaranteed substantial completion dates fall within the SCPSC approved 18-month contingency periods. SCE&G expects to hold an allowable ex parte communication briefing with the SCPSC on November 19, 2015 and, following an evaluation as to whether to exercise the fixed price option, expects to file a petition, as provided under the BLRA, for an update to the project’s estimated capital cost schedule which would incorporate the impact of this October 2015 Amendment.

Additional claims by the Consortium or SCE&G involving the project schedule and budget may arise as the project continues. The parties to the EPC Contract have established both informal and formal dispute resolution procedures in order to resolve such issues. SCE&G expects to resolve all disputes through both the informal and formal procedures and anticipates that any costs that arise through such dispute resolution processes (including those reflected in the October 2015 Amendment described above), as well as other costs identified from time to time, will be recoverable through rates.

Santee Cooper Matters

As noted above, SCE&G has agreed to acquire an additional 5% ownership in the New Units from Santee Cooper. Under the terms of this agreement, SCE&G will acquire a 1% ownership interest in the New Units at the commercial operation date of Unit 2, an additional 2% ownership interest no later than the first anniversary of such commercial operation date, and the final 2% no later than the second anniversary of such commercial operation date. SCE&G has agreed to pay an amount equal to Santee Cooper's actual cost, including its cost of financing, of the percentage conveyed as of the date of each conveyance. In addition, the agreement provides that Santee Cooper will not transfer any of its remaining interest in the New Units to third parties until the New Units are complete. This transaction will not affect the payment obligations between the parties during construction for the New Units, nor is it anticipated that the payments for the additional ownership interest would be reflected in a revised rates filing under the BLRA. Based on the current milestone schedule and capital costs schedule approved by the SCPSC in September 2015 and without considering the October 2015 Amendment discussed above, SCE&G’s estimated cost would be approximately $750 million for the additional 5% interest being acquired from Santee Cooper.

Nuclear Production Tax Credits

The IRS has notified SCE&G that, subject to a national megawatt capacity limitation, the electricity to be produced by each of the New Units (advanced nuclear units, as defined) would qualify for nuclear production tax credits under Section 45J of the Internal Revenue Code to the extent that such New Unit is operational before January 1, 2021 and other eligibility requirements are met. These nuclear production tax credits (related to SCE&G's 55% share of both New Units) could total as much as approximately $1.4 billion. Such credits would be earned over the first eight years of each New Unit's operations and would be realized by SCE&G over those years or during allowable carry-forward periods. Based on the guaranteed substantial completion dates provided above, both New Units are expected to be operational and to qualify for the nuclear production tax credits; however, further delays in the schedule or changes in tax law could impact such conclusions. When and to the extent that production tax credits are realized, their benefits are expected to be provided directly to SCE&G's electric customers.

Other Project Matters

When the NRC issued the COLs for the New Units, two of the conditions that it imposed were requiring inspection and testing of certain components of the New Units' passive cooling system, and requiring the development of strategies to respond to extreme natural events resulting in the loss of power at the New Units. In addition, the NRC directed the Office of New Reactors to issue to SCE&G an order requiring enhanced, reliable spent fuel pool instrumentation. SCE&G prepared and submitted an integrated response plan for the New Units to the NRC in August 2013. That plan is currently under review by the NRC and SCE&G does not anticipate any additional regulatory actions as a result of that review, but it cannot predict future regulatory activities or how such initiatives would impact construction or operation of the New Units.

Environmental
 
The Company's operations are subject to extensive regulation by various federal and state authorities in the areas of air quality, water quality, control of toxic substances and hazardous and solid wastes. Applicable statutes and rules include the CAA, CWA, Nuclear Waste Act and CERCLA, among others. In many cases, regulations proposed by such authorities could have a significant impact on the Company's financial condition, results of operations and cash flows. In addition, the Company often cannot predict what conditions or requirements will be imposed by regulatory or legislative proposals. To the extent that compliance with environmental regulations or legislation results in capital expenditures or operating costs, the Company expects to recover such expenditures and costs through existing ratemaking provisions.

From a regulatory perspective, SCANA, SCE&G and GENCO continually monitor and evaluate their current and projected emission levels and strive to comply with all state and federal regulations regarding those emissions. SCE&G and GENCO participate in the sulfur dioxide and nitrogen oxide emission allowance programs with respect to coal plant emissions and also have constructed additional pollution control equipment at several larger coal-fired electric generating plants. Further, SCE&G is engaged in construction activities of the New Units which are expected to reduce GHG emission levels significantly once they are completed and dispatched by potentially displacing some of the current coal-fired generation sources. These actions are expected to address many of the rules and regulations discussed herein.

On August 3, 2015, the EPA issued a revised carbon standard for new power plants by re-proposing NSPS under the CAA for emissions of carbon dioxide from newly constructed fossil fuel-fired units. The final rule requires all new coal-fired power plants to meet a carbon emission rate of 1,400 pounds carbon dioxide per MWh and new natural gas units to meet 1,000 pounds carbon dioxide per MWh. While most new natural gas plants will not be required to include any new technologies, no new coal-fired plants could be constructed without partial carbon capture and sequestration capabilities. The Company is evaluating the final rule, but does not plan to construct new coal-fired units in the foreseeable future. In addition, on August 3, 2015, the EPA issued its final rule on emission guidelines for states to follow in developing plans to address GHG emissions from existing units. The rule includes state-specific goals for reducing national carbon dioxide emissions by 32% from 2005 levels by 2030. The rule also provides for nuclear reactors under construction, such as the New Units, to count towards compliance and establishes a phased-in compliance approach beginning in 2022. The Company is currently evaluating the rule and expects any costs incurred to comply with such rule to be recoverable through rates.

In July 2011, the EPA issued the CSAPR to reduce emissions of sulfur dioxide and nitrogen oxide from power plants in the eastern half of the United States. A series of court actions stayed this rule until October 23, 2014, when the Court of Appeals granted a motion to lift the stay. On December 3, 2014, the EPA published an interim final rule that aligns the dates in the CSAPR text with the revised court-ordered schedule, thus delaying the implementation dates to 2015 for Phase 1 and to 2017 for Phase 2. The CSAPR replaces the CAIR and requires a total of 28 states to reduce annual sulfur dioxide emissions and annual or ozone season nitrogen oxide emissions to assist in attaining the ozone and fine particle NAAQS. The rule establishes an emissions cap for sulfur dioxide and nitrogen oxide and limits the trading for emission allowances by separating affected states into two groups with no trading between the groups. On July 28, 2015, the Court of Appeals held that Phase 2 emissions budgets for certain states, including South Carolina, required reductions in emissions beyond the point necessary to achieve downwind attainment and were, therefore, invalid. The Court of Appeals remanded CSAPR, without vacating the rule, to the EPA for further consideration. The opinion of the Court of Appeals has no immediate impact on SCE&G and GENCO or their generation operations. Air quality control installations that SCE&G and GENCO have already completed have positioned them to comply with the existing allowances set by the CSAPR. Any cost incurred to comply with CSAPR are expected to be recoverable through rates.

In April 2012, the EPA's MATS rule containing new standards for mercury and other specified air pollutants became effective. The rule provides up to four years for generating facilities to meet the standards, and the Company's evaluation of the rule is ongoing. The Company's decision to retire certain coal-fired units (see Note 2) and its project to build the New Units along with other actions are expected to result in the Company's compliance with MATS.

On November 19, 2014, the EPA finalized its reconsideration of certain provisions applicable during startup and shutdown of generating facilities. SCE&G and GENCO have received a one year extension (until April 2016) to comply with MATS at Cope, McMeekin, Wateree and Williams Stations. These extensions will allow time to convert McMeekin Station to burn natural gas and to install additional pollution control devices at the other plants that will enhance the control of certain MATS-regulated pollutants. On June 29, 2015, the U.S. Supreme Court ruled that the EPA unreasonably failed to consider costs in its decision to regulate, and remanded a case challenging the regulation on that basis to the Court of Appeals. The ruling, however, is not expected to have an impact on SCE&G or GENCO due to the aforementioned retirements and conversions.

The CWA provides for the imposition of effluent limitations that require treatment for wastewater discharges. Under the CWA, compliance with applicable limitations is achieved under state-issued NPDES permits. As a facility’s NPDES permit is renewed (every five years), any new effluent limitations would be incorporated. The ELG Rule becomes effective on January 4, 2016. After this date, state regulators will modify facility NPDES permits to match more restrictive standards, thus requiring facilities to retrofit with new wastewater treatment technologies. Compliance dates will vary by type of wastewater, and some will be based on a facility's five year permit cycle and thus may range from 2018 to 2023. The Company expects that wastewater treatment technology retrofits will be required at Williams and Wateree Stations and may be required at other facilities. Any costs incurred to comply with the ELG Rule are expected to be recoverable through rates.

The CWA Section 316(b) Existing Facilities Rule became effective in October 2014. This rule establishes national requirements for the location, design, construction and capacity of cooling water intake structures at existing facilities that reflect the best technology available for minimizing the adverse environmental impacts of impingement and entrainment. SCE&G and GENCO are conducting studies and implementing plans to ensure compliance with this rule. In addition, Congress is expected to consider further amendments to the CWA. Such legislation may include toxicity-based standards as well as limitations to mixing zones.

On April 17, 2015, the EPA's final rule for CCR was published in the Federal Register and became effective in the fourth quarter of 2015. This rule regulates CCR as a non-hazardous waste under Subtitle D of the Resource Conservation and Recovery Act and imposes certain requirements on ash storage ponds and other CCR management facilities at SCE&G's and GENCO's coal-fired generating facilities. Although the full effects of this rule are still being evaluated, SCE&G and GENCO have already closed or have begun the process of closure of all of their ash storage ponds and have previously recognized AROs for such ash storage ponds under existing requirements. The Company does not expect the incremental compliance costs associated with this rule to be significant and expects to recover such costs in future rates.

The Nuclear Waste Act required that the United States government accept and permanently dispose of high-level radioactive waste and spent nuclear fuel by January 31, 1998, and it imposed on utilities the primary responsibility for storage of their spent nuclear fuel until the repository is available. SCE&G entered into a Standard Contract for Disposal of Spent Nuclear Fuel and/or High-Level Radioactive Waste with the DOE in 1983. As of September 30, 2015, the federal government has not accepted any spent fuel from Summer Station Unit 1, and it remains unclear when the repository may become available. SCE&G has on-site spent nuclear fuel storage capability in its existing fuel pool until at least 2017 and is constructing a dry cask storage facility to accommodate the spent nuclear fuel output for the life of Summer Station Unit 1. SCE&G may evaluate other technology as it becomes available.

The provisions of CERCLA authorize the EPA to require the clean-up of hazardous waste sites. The states of South Carolina and North Carolina have similar laws. The Company maintains an environmental assessment program to identify and evaluate current and former operations sites that could require clean-up. In addition, regulators from the EPA and other federal or state agencies periodically notify the Company that it may be required to perform or participate in the investigation and remediation of a hazardous waste site. As site assessments are initiated, estimates are made of the amount of expenditures, if any, deemed necessary to investigate and remediate each site. These estimates are refined as additional information becomes available; therefore, actual expenditures may differ significantly from the original estimates. Amounts estimated and accrued to date for site assessments and clean-up relate solely to regulated operations. Such amounts are recorded in regulatory assets and amortized, with recovery provided through rates.
 
SCE&G is responsible for four decommissioned MGP sites in South Carolina which contain residues of by-product chemicals. These sites are in various stages of investigation, remediation and monitoring under work plans approved by DHEC and the EPA. SCE&G anticipates that major remediation activities at all these sites will continue at least through 2017 and will cost an additional $19.0 million, which is accrued in Other within Deferred Credits and Other Liabilities on the condensed consolidated balance sheet. SCE&G expects to recover any cost arising from the remediation of MGP sites through rates. At September 30, 2015, deferred amounts, net of amounts previously recovered through rates and insurance settlements, totaled $34.7 million and are included in regulatory assets.

Asset Retirement Obligations

The Company recognizes a liability for the present value of an ARO when incurred if the liability can be reasonably estimated. Uncertainty about the timing or method of settlement of a conditional ARO is factored into the measurement of the liability when sufficient information exists, but such uncertainty is not a basis upon which to avoid liability recognition.
 
The legal obligations associated with the retirement of long-lived tangible assets that result from their acquisition, construction, development and normal operation relate primarily to the Company’s utility operations.  As of September 30, 2015 and December 31, 2014, the Company has recorded AROs of approximately $174 million and $201 million, respectively, for nuclear plant decommissioning and AROs of approximately $315 million and $362 million, respectively, for other conditional obligations primarily related to generation, transmission and distribution properties, including gas pipelines. All of the amounts recorded are based upon estimates which are subject to varying degrees of imprecision, particularly since such payments will be made many years in the future.

A reconciliation of the beginning and ending carrying amount of asset retirement obligations is as follows:
Millions of dollars
 
September 30, 2015
 
December 31, 2014
Beginning balance
 
$
563

 
$
576

Liabilities incurred
 

 
3

Liabilities settled
 
(15
)
 
(6
)
Accretion expense
 
20

 
26

Revisions in estimated cash flows
 
(79
)
 
(36
)
Ending balance
 
$
489

 
$
563



Revisions in estimated cash flows during 2015 primarily relate to changes in the expected timing of settlement of AROs in light of changes in the estimated useful lives of certain electric utility properties identified as part of a customary depreciation study.
SCEG  
Statement [Line Items]  
Commitments and Contingencies Disclosure [Text Block]
COMMITMENTS AND CONTINGENCIES

 Nuclear Insurance

Under Price-Anderson, SCE&G (for itself and on behalf of Santee Cooper, a one-third owner of Summer Station Unit 1) maintains agreements of indemnity with the NRC that, together with private insurance, cover third-party liability arising from any nuclear incident occurring at SCE&G's nuclear power plant. Price-Anderson provides funds up to $12.9 billion for public liability claims that could arise from a single nuclear incident. Each nuclear plant is insured against this liability to a maximum of $375 million by ANI with the remaining coverage provided by a mandatory program of deferred premiums that could be assessed, after a nuclear incident, against all owners of commercial nuclear reactors. Each reactor licensee is currently liable for up to $127.3 million per reactor owned for each nuclear incident occurring at any reactor in the United States, provided that not more than $18.9 million of the liability per reactor would be assessed per year.  SCE&G’s maximum assessment, based on its two-thirds ownership of Summer Station Unit 1, would be $84.8 million per incident, but not more than $12.6 million per year. Both the maximum assessment per reactor and the maximum yearly assessment are adjusted for inflation at least every five years.
 
SCE&G currently maintains insurance policies (for itself and on behalf of Santee Cooper) with NEIL.  The policies provide coverage to Summer Station Unit 1 for property damage and outage costs up to $2.75 billion resulting from an event of nuclear origin. In addition, a builder's risk insurance policy has been purchased from NEIL for the construction of the New Units. This policy provides the owners of the New Units up to $500 million in limits of accidental property damage occurring during construction. The NEIL policies, in the aggregate, are subject to a maximum loss of $2.75 billion for any single loss occurrence. All of the NEIL policies permit retrospective assessments under certain conditions to cover insurer’s losses.  Based on the current annual premium, SCE&G’s portion of the retrospective premium assessment would not exceed $45.9 million.
 
To the extent that insurable claims for property damage, decontamination, repair and replacement and other costs and expenses arising from a nuclear incident at Summer Station Unit 1 exceed the policy limits of insurance, or to the extent such insurance becomes unavailable in the future, and to the extent that SCE&G's rates would not recover the cost of any purchased replacement power, SCE&G will retain the risk of loss as a self-insurer.  SCE&G has no reason to anticipate a serious nuclear incident.  However, if such an incident were to occur, it likely would have a material impact on Consolidated SCE&G’s results of operations, cash flows and financial position.

New Nuclear Construction

In 2008, SCE&G, on behalf of itself and as agent for Santee Cooper, contracted with the Consortium for the design and construction of the New Units at the site of Summer Station.  

SCE&G's current ownership share in the New Units is 55%. As discussed below, under an agreement signed in January 2014 (and subject to customary closing conditions, including necessary regulatory approvals), SCE&G has agreed to acquire an additional 5% ownership in the New Units from Santee Cooper.

EPC Contract and BLRA Matters

The construction of the New Units and SCE&G’s related recovery of financing costs through rates is subject to review and approval by the SCPSC as provided for in the BLRA. Under the BLRA, the SCPSC has approved, among other things, a milestone schedule and a capital costs estimates schedule for the New Units. This approval constitutes a final and binding determination that the New Units are used and useful for utility purposes, and that the capital costs associated with the New Units are prudent utility costs and expenses and are properly included in rates, so long as the New Units are constructed or are being constructed within the parameters of the approved milestone schedule, including specified schedule contingencies, and the approved capital costs estimates schedule. Subject to the same conditions, the BLRA provides that SCE&G may apply to the SCPSC annually for an order to recover through revised rates SCE&G’s weighted average cost of capital applied to all or part of the outstanding balance of construction work in progress concerning the New Units. Such annual rate changes are described in Note 2. As of September 30, 2015, SCE&G’s investment in the New Units, including related transmission, totaled $3.3 billion, for which the financing costs on $2.4 billion have been reflected in rates under the BLRA.

The SCPSC granted initial approval of the construction schedule and related forecasted capital costs in 2009. The NRC issued COLs in March 2012. In November 2012, the SCPSC approved an updated milestone schedule and additional updated capital costs for the New Units. In addition, the SCPSC approved revised substantial completion dates for the New Units based on that March 2012 issuance of the COL and the amounts agreed upon by SCE&G and the Consortium in July 2012 to resolve known claims by the Consortium for costs related to COL delays, design modifications of the shield building and certain prefabricated structural modules for the New Units and unanticipated rock conditions at the site. In October 2014, the South Carolina Supreme Court affirmed the SCPSC's order on appeal.

Since the settlement of delay-related claims in 2012, the Consortium has continued to experience delays in the schedule, including those related to fabrication and delivery of sub-modules for the New Units. The fabrication and delivery of sub-modules have been and remain focus areas of the Consortium. Shield building panels are considered critical path items for both New Units, and the current schedule for production of such panels will require mitigation to support the updated substantial completion dates (see below).

During the fourth quarter of 2013, the Consortium began a full re-baselining of the Unit 2 and Unit 3 construction schedules to incorporate a more detailed evaluation of the engineering and procurement activities necessary to accomplish the schedules and to provide a detailed reassessment of the impact of the revised Unit 2 and Unit 3 schedules on engineering and design resource allocations, procurement, construction work crew efficiencies, and other items. The result was a revised, fully integrated project schedule with timing of specific construction activities (Revised, Fully-Integrated Construction Schedule) along with related cost information.

The Revised, Fully-Integrated Construction Schedule indicated that the substantial completion of Unit 2 was expected to occur in mid-June 2019 and that the substantial completion of Unit 3 was expected to be approximately 12 months later. The Consortium continues to refine and update the Revised, Fully-Integrated Construction Schedule as designs are finalized, as construction progresses, and as additional information is received.

In September 2015, the SCPSC approved an updated BLRA milestone schedule based on revised substantial completion dates for Units 2 and 3 of June 2019 and June 2020, respectively, each subject to an 18-month contingency period. In addition, the SCPSC approved certain updated owner's costs ($245 million) and other capital costs ($453 million), of which $539 million were associated with the schedule delays and other contested costs. SCE&G's total projected capital costs (in 2007 dollars) and gross construction cost estimates (including escalation and AFC) were estimated to be $5.2 billion and $6.8 billion, respectively. These projections included cost amounts related to the Revised, Fully-Integrated Construction Schedule for which SCE&G had not accepted responsibility and which were the subject of dispute. As such, these updated milestone schedule and projections did not reflect the resolution of negotiations. In addition, the SCPSC approved a revision to the allowed return on equity for new nuclear construction from 11.00% to 10.50%. This revised return on equity will be applied prospectively for the purpose of calculating revised rates sought by SCE&G under the BLRA on and after January 1, 2016, until such time as the New Units are completed.

On October 27, 2015, SCE&G, Santee Cooper and the Consortium reached a settlement regarding the above mentioned disputes, and the EPC Contract was amended. The October 2015 Amendment will become effective upon the consummation of the acquisition by WEC of the stock of Stone & Webster from CB&I, and will become null and void in the event such acquisition is not consummated by March 31, 2016. Following that acquisition, Stone & Webster will continue to be a member of the Consortium as a subsidiary of WEC rather than CB&I, and WEC intends to engage Fluor Corporation or its affiliate(s) as a subcontracted construction manager.

Among other things, upon effectiveness, the October 2015 Amendment would (i) resolve by settlement and release substantially all outstanding disputes between SCE&G and the Consortium, in exchange for (a) an additional cost to be paid by SCE&G and Santee Cooper of $300 million (SCE&G’s 55% portion being $165 million) and an increase in the fixed component of the contract price by that amount, and (b) a credit to SCE&G and Santee Cooper of $50 million (SCE&G’s 55% portion being approximately $27 million) to be applied to the target component of the contract price, (ii) revise the guaranteed substantial completion dates of Units 2 and 3 to August 31, 2019 and 2020, respectively, (iii) revise the delay-related liquidated damages computation requirements, including those related to the eligibility of the New Units to earn Internal Revenue Code Section 45J production tax credits (see also below), and cap those aggregate liquidated damages at $463 million per New Unit (SCE&G’s 55% portion being approximately $255 million per New Unit), (iv) provide for payment to the Consortium of a completion bonus of $275 million per New Unit (SCE&G’s 55% portion being approximately $151 million per New Unit) for each New Unit placed in service by the deadline to qualify for production tax credits, (v) provide for the development of a revised construction milestone payment schedule, with SCE&G and Santee Cooper making monthly payments of $100 million (SCE&G’s 55% portion being $55 million) for each of the first five months following effectiveness, followed by payments made based on milestones achieved, and (vi) provide that SCE&G and Santee Cooper waive and cancel the CB&I parent company guaranty with respect to the project. The payment obligations under the EPC Contract are joint and several obligations of WEC and Stone & Webster, and the October 2015 Amendment provides for Toshiba Corporation, WEC’s parent company, to reaffirm its guaranty of WEC’s payment obligations. Under the October 2015 Amendment, SCE&G’s total estimated project costs will increase by approximately $286 million over the $6.8 billion approved by the SCPSC in September 2015, and will bring its total estimated gross construction cost of the project (including escalation and AFC) to approximately $7.1 billion.

In addition to the above, upon effectiveness, the October 2015 Amendment would provide for an explicit definition of a Change in Law designed to reduce the likelihood of certain future commercial disputes. As part of this, the Consortium would also acknowledge and agree that the project scope includes providing New Units that meet the standards of the NRC approved Design Control Document Revision 19. The October 2015 Amendment would also establish a dispute resolution board process for certain commercial claims and disputes, including any dispute that might arise with respect to the development of the revised construction milestone payment schedule referred to above. The EPC Contract would also be revised to eliminate the requirement or ability to bring suit before substantial completion of the project.

Finally, upon effectiveness, the October 2015 Amendment would provide SCE&G and Santee Cooper an irrevocable option, until November 1, 2016 and subject to regulatory approvals, to further amend the EPC Contract to fix the total amount to be paid to the Consortium for its entire scope of work on the project (excluding a limited amount of work within the time and materials component of the contract price) after June 30, 2015 at $6.082 billion (SCE&G’s 55% portion being approximately $3.345 billion). This total amount to be paid would be subject to adjustment for amounts paid since June 30, 2015. Were this fixed price option to be exercised, the aggregate delay-related liquidated damages amount referred to in (iii) above would be capped at $338 million per unit (SCE&G’s 55% portion being approximately $186 million per unit), and the completion bonus amounts referred to in (iv) above would be $150 million per New Unit (SCE&G’s 55% portion being approximately $83 million per New Unit). The exercise of this fixed price option would result in SCE&G’s total estimated project costs increasing by approximately $774 million over the $6.8 billion approved by the SCPSC in September 2015, and would bring its total estimated gross construction cost (including escalation and AFC) of the project to approximately $7.6 billion.

Resolution of the disputes as described in (i) above, or in the case of the exercise of the fixed price option, would result in estimated project costs above the amounts approved by the SCPSC; however, the guaranteed substantial completion dates fall within the SCPSC approved 18-month contingency periods. SCE&G expects to hold an allowable ex parte communication briefing with the SCPSC on November 19, 2015 and, following an evaluation as to whether to exercise the fixed price option, expects to file a petition, as provided under the BLRA, for an update to the project’s estimated capital cost schedule which would incorporate the impact of this October 2015 Amendment.

Additional claims by the Consortium or SCE&G involving the project schedule and budget may arise as the project continues. The parties to the EPC Contract have established both informal and formal dispute resolution procedures in order to resolve such issues. SCE&G expects to resolve all disputes through both the informal and formal procedures and anticipates that any costs that arise through such dispute resolution processes (including those reflected in the October 2015 Amendment described above), as well as other costs identified from time to time, will be recoverable through rates.

Santee Cooper Matters

As noted above, SCE&G has agreed to acquire an additional 5% ownership in the New Units from Santee Cooper. Under the terms of this agreement, SCE&G will acquire a 1% ownership interest in the New Units at the commercial operation date of Unit 2, an additional 2% ownership interest no later than the first anniversary of such commercial operation date, and the final 2% no later than the second anniversary of such commercial operation date. SCE&G has agreed to pay an amount equal to Santee Cooper's actual cost, including its cost of financing, of the percentage conveyed as of the date of each conveyance. In addition, the agreement provides that Santee Cooper will not transfer any of its remaining interest in the New Units to third parties until the New Units are complete. This transaction will not affect the payment obligations between the parties during construction for the New Units, nor is it anticipated that the payments for the additional ownership interest would be reflected in a revised rates filing under the BLRA. Based on the current milestone schedule and capital costs schedule approved by the SCPSC in September 2015 and without considering the October 2015 Amendment discussed above, SCE&G’s estimated cost would be approximately $750 million for the additional 5% interest being acquired from Santee Cooper.

Nuclear Production Tax Credits

The IRS has notified SCE&G that, subject to a national megawatt capacity limitation, the electricity to be produced by each of the New Units (advanced nuclear units, as defined) would qualify for nuclear production tax credits under Section 45J of the Internal Revenue Code to the extent that such New Unit is operational before January 1, 2021 and other eligibility requirements are met. These nuclear production tax credits (related to SCE&G's 55% share of both New Units) could total as much as approximately $1.4 billion. Such credits would be earned over the first eight years of each New Unit's operations and would be realized by SCE&G over those years or during allowable carry-forward periods. Based on the guaranteed substantial completion dates provided above, both New Units are expected to be operational and to qualify for the nuclear production tax credits; however, further delays in the schedule or changes in tax law could impact such conclusions. When and to the extent that production tax credits are realized, their benefits are expected to be provided directly to SCE&G's electric customers.

Other Project Matters

When the NRC issued the COLs for the New Units, two of the conditions that it imposed were requiring inspection and testing of certain components of the New Units' passive cooling system, and requiring the development of strategies to respond to extreme natural events resulting in the loss of power at the New Units. In addition, the NRC directed the Office of New Reactors to issue to SCE&G an order requiring enhanced, reliable spent fuel pool instrumentation. SCE&G prepared and submitted an integrated response plan for the New Units to the NRC in August 2013. That plan is currently under review by the NRC and SCE&G does not anticipate any additional regulatory actions as a result of that review, but it cannot predict future regulatory activities or how such initiatives would impact construction or operation of the New Units.

Environmental
 
Consolidated SCE&G's operations are subject to extensive regulation by various federal and state authorities in the areas of air quality, water quality, control of toxic substances and hazardous and solid wastes. Applicable statutes and rules include the CAA, CWA, Nuclear Waste Act and CERCLA, among others. In many cases, regulations proposed by such authorities could have a significant impact on Consolidated SCE&G's financial condition, results of operations and cash flows. In addition, Consolidated SCE&G often cannot predict what conditions or requirements will be imposed by regulatory or legislative proposals. To the extent that compliance with environmental regulations or legislation results in capital expenditures or operating costs, Consolidated SCE&G expects to recover such expenditures and costs through existing ratemaking provisions.

From a regulatory perspective, SCE&G and GENCO continually monitor and evaluate their current and projected emission levels and strive to comply with all state and federal regulations regarding those emissions. SCE&G and GENCO participate in the sulfur dioxide and nitrogen oxide emission allowance programs with respect to coal plant emissions and also have constructed additional pollution control equipment at several larger coal-fired electric generating plants. Further, SCE&G is engaged in construction activities of the New Units which are expected to reduce GHG emission levels significantly once they are completed and dispatched by potentially displacing some of the current coal-fired generation sources. These actions are expected to address many of the rules and regulations discussed herein.

On August 3, 2015, the EPA issued a revised carbon standard for new power plants by re-proposing NSPS under the CAA for emissions of carbon dioxide from newly constructed fossil fuel-fired units. The final rule requires all new coal-fired power plants to meet a carbon emission rate of 1,400 pounds carbon dioxide per MWh and new natural gas units to meet 1,000 pounds carbon dioxide per MWh. While most new natural gas plants will not be required to include any new technologies, no new coal-fired plants could be constructed without partial carbon capture and sequestration capabilities. SCE&G and GENCO are evaluating the final rule, but do not plan to construct new coal-fired units in the foreseeable future. In addition, on August 3, 2015, the EPA issued its final rule on emission guidelines for states to follow in developing plans to address GHG emissions from existing units. The rule includes state-specific goals for reducing national carbon dioxide emissions by 32% from 2005 levels by 2030. The rule also provides for nuclear reactors under construction, such as the New Units, to count towards compliance and establishes a phased-in compliance approach beginning in 2022. Consolidated SCE&G is currently evaluating the rule and expects any costs incurred to comply with such rule to be recoverable through rates.

In July 2011, the EPA issued the CSAPR to reduce emissions of sulfur dioxide and nitrogen oxide from power plants in the eastern half of the United States. A series of court actions stayed this rule until October 23, 2014, when the Court of Appeals granted a motion to lift the stay. On December 3, 2014, the EPA published an interim final rule that aligns the dates in the CSAPR text with the revised court-ordered schedule, thus delaying the implementation dates to 2015 for Phase 1 and to 2017 for Phase 2. The CSAPR replaces the CAIR and requires a total of 28 states to reduce annual sulfur dioxide emissions and annual or ozone season nitrogen oxide emissions to assist in attaining the ozone and fine particle NAAQS. The rule establishes an emissions cap for sulfur dioxide and nitrogen oxide and limits the trading for emission allowances by separating affected states into two groups with no trading between the groups. On July 28, 2015, the Court of Appeals held that Phase 2 emissions budgets for certain states, including South Carolina, required reductions in emissions beyond the point necessary to achieve downwind attainment and were, therefore, invalid. The Court of Appeals remanded CSAPR, without vacating the rule, to the EPA for further consideration. The opinion of the Court of Appeals has no immediate impact on SCE&G and GENCO or their generation operations. Air quality control installations that SCE&G and GENCO have already completed have positioned them to comply with the existing allowances set by the CSAPR. Any cost incurred to comply with CSAPR are expected to be recoverable through rates.

In April 2012, the EPA's MATS rule containing new standards for mercury and other specified air pollutants became effective.  The rule provides up to four years for generating facilities to meet the standards, and SCE&G and GENCO's evaluation of the rule is ongoing. SCE&G's decision to retire certain coal-fired units (see Note 2) and its project to build the New Units along with other actions are expected to result in SCE&G's compliance with MATS.

On November 19, 2014, the EPA finalized its reconsideration of certain provisions applicable during startup and shutdown of generating facilities. SCE&G and GENCO have received a one year extension (until April 2016) to comply with MATS at Cope, McMeekin, Wateree and Williams Stations. These extensions will allow time to convert McMeekin Station to burn natural gas and to install additional pollution control devices at the other plants that will enhance the control of certain MATS-regulated pollutants. On June 29, 2015, the U.S. Supreme Court ruled that the EPA unreasonably failed to consider costs in its decision to regulate, and remanded a case challenging the regulation on that basis to the Court of Appeals. The ruling, however, is not expected to have an impact on SCE&G or GENCO due to the aforementioned retirements and conversions.

The CWA provides for the imposition of effluent limitations that require treatment for wastewater discharges. Under the CWA, compliance with applicable limitations is achieved under state-issued NPDES permits. As a facility’s NPDES permit is renewed (every five years), any new effluent limitations would be incorporated. The ELG Rule becomes effective on January 4, 2016. After this date, state regulators will modify facility NPDES permits to match more restrictive standards, thus requiring facilities to retrofit with new wastewater treatment technologies. Compliance dates will vary by type of wastewater, and some will be based on a facility's five year permit cycle and thus may range from 2018 to 2023. Consolidated SCE&G expects that wastewater treatment technology retrofits will be required at Williams and Wateree Stations and may be required at other facilities. Any costs incurred to comply with the ELG Rule are expected to be recoverable through rates.

The CWA Section 316(b) Existing Facilities Rule became effective in October 2014. This rule establishes national requirements for the location, design, construction and capacity of cooling water intake structures at existing facilities that reflect the best technology available for minimizing the adverse environmental impacts of impingement and entrainment. SCE&G and GENCO are conducting studies and implementing plans to ensure compliance with this rule. In addition, Congress is expected to consider further amendments to the CWA. Such legislation may include toxicity-based standards as well as limitations to mixing zones.

On April 17, 2015, the EPA's final rule for CCR was published in the Federal Register and became effective in the fourth quarter of 2015. This rule regulates CCR as a non-hazardous waste under Subtitle D of the Resource Conservation and Recovery Act and imposes certain requirements on ash storage ponds and other CCR management facilities at SCE&G's and GENCO's coal-fired generating facilities. Although the full effects of this rule are still being evaluated, SCE&G and GENCO have already closed or have begun the process of closure of all of their ash storage ponds and have previously recognized AROs for such ash storage ponds under existing requirements. Consolidated SCE&G does not expect the incremental compliance costs associated with this rule to be significant and expects to recover such costs in future rates.
 
The Nuclear Waste Act required that the United States government accept and permanently dispose of high-level radioactive waste and spent nuclear fuel by January 31, 1998, and it also imposed on utilities the primary responsibility for storage of their spent nuclear fuel until the repository is available. SCE&G entered into a Standard Contract for Disposal of Spent Nuclear Fuel and/or High-Level Radioactive Waste with the DOE in 1983. As of September 30, 2015, the federal government has not accepted any spent fuel from Summer Station Unit 1, and it remains unclear when the repository may become available. SCE&G has on-site spent nuclear fuel storage capability in its existing fuel pool until at least 2017 and is constructing a dry cask storage facility to accommodate the spent nuclear fuel output for the life of Summer Station Unit 1. SCE&G may evaluate other technology as it becomes available.
 
The provisions of CERCLA authorize the EPA to require the clean-up of hazardous waste sites. The state of South Carolina has similar laws. SCE&G maintains an environmental assessment program to identify and evaluate current and former operations sites that could require clean-up. In addition, regulators from the EPA and other federal or state agencies periodically notify SCE&G that it may be required to perform or participate in the investigation and remediation of a hazardous waste site. As site assessments are initiated, estimates are made of the amount of expenditures, if any, deemed necessary to investigate and remediate each site. These estimates are refined as additional information becomes available; therefore, actual expenditures may differ significantly from the original estimates. Amounts estimated and accrued to date for site assessments and clean-up relate solely to regulated operations. Such amounts are recorded in regulatory assets and amortized, with recovery provided through rates.

SCE&G is responsible for four decommissioned MGP sites in South Carolina which contain residues of by-product chemicals.  These sites are in various stages of investigation, remediation and monitoring under work plans approved by DHEC and the EPA.  SCE&G anticipates that major remediation activities at all these sites will continue at least through 2017 and will cost an additional $19.0 million, which is accrued in Other within Deferred Credits and Other Liabilities on the condensed consolidated balance sheet.  SCE&G expects to recover any cost arising from the remediation of MGP sites through rates.  At September 30, 2015, deferred amounts, net of amounts previously recovered through rates and insurance settlements, totaled $34.7 million and are included in regulatory assets.

Asset Retirement Obligations

Consolidated SCE&G recognizes a liability for the present value of an ARO when incurred if the liability can be reasonably estimated. Uncertainty about the timing or method of settlement of a conditional ARO is factored into the measurement of the liability when sufficient information exists, but such uncertainty is not a basis upon which to avoid liability recognition.
 
The legal obligations associated with the retirement of long-lived tangible assets that result from their acquisition, construction, development and normal operation relate primarily to Consolidated SCE&G’s utility operations.  As of September 30, 2015 and December 31, 2014, Consolidated SCE&G has recorded AROs of approximately $174 million and $201 million, respectively, for nuclear plant decommissioning and AROs of approximately $286 million and $335 million, respectively, for other conditional obligations primarily related to generation, transmission and distribution properties, including gas pipelines. All of the amounts recorded are based upon estimates which are subject to varying degrees of imprecision, particularly since such payments will be made many years in the future.

A reconciliation of the beginning and ending carrying amount of asset retirement obligations is as follows:

Millions of dollars
 
September 30, 2015
 
December 31, 2014
Beginning balance
 
$
536

 
$
547

Liabilities incurred
 

 
3

Liabilities settled
 
(15
)
 
(6
)
Accretion expense
 
18

 
25

Revisions in estimated cash flows
 
(79
)
 
(33
)
Ending balance
 
$
460

 
$
536



Revisions in estimated cash flows during 2015 primarily relate to changes in the expected timing of settlement of AROs in light of changes in the estimated useful lives of certain electric utility properties identified as part of a customary depreciation study.