As a result of issues generated in the ordinary course of business, the Companies are involved in legal proceedings before various courts and are periodically subject to governmental examinations (including by regulatory authorities), inquiries and investigations. Certain legal proceedings and governmental examinations involve demands for unspecified amounts of damages, are in an initial procedural phase, involve uncertainty as to the outcome of pending appeals or motions, or involve significant factual issues that need to be resolved, such that it is not possible for the Companies to estimate a range of possible loss. For such matters that the Companies cannot estimate, a statement to this effect is made in the description of the matter. Other matters may have progressed sufficiently through the litigation or investigative processes such that the Companies are able to estimate a range of possible loss. For legal proceedings and governmental examinations that the Companies are able to reasonably estimate a range of possible losses, an estimated range of possible loss is provided, in excess of the accrued liability (if any) for such matters. The Companies maintain various insurance programs, including general liability insurance coverage which provides coverage for personal injury or wrongful death cases. Any accrued liability is recorded on a gross basis with a receivable also recorded for any probable insurance recoveries. Estimated ranges of loss are inclusive of legal fees and net of any anticipated insurance recoveries. Any estimated range is based on currently available information and involves elements of judgment and significant uncertainties. Any estimated range of possible loss may not represent the Companies’ maximum possible loss exposure. The circumstances of such legal proceedings and governmental examinations will change from time to time and actual results may vary significantly from the current estimate. For current proceedings not specifically reported below, management does not anticipate that the liabilities, if any, arising from such proceedings would have a material effect on the Companies’ financial position, liquidity or results of operations.

The Companies are subject to costs resulting from a number of federal, state and local laws and regulations designed to protect human health and the environment. These laws and regulations affect future planning and existing operations. They can result in increased capital, operating and other costs as a result of compliance, remediation, containment and monitoring obligations.

The CAA, as amended, is a comprehensive program utilizing a broad range of regulatory tools to protect and preserve the nation’s air quality. At a minimum, states are required to establish regulatory programs to meet applicable requirements of the CAA. However, states may choose to develop regulatory programs that are more restrictive. Many of the Companies’ facilities are subject to the CAA’s permitting and other requirements.

The EPA published final non-attainment designations for the October 2015 ozone standard in June 2018 with states required to develop plans to address the new standard. Certain states in which the Companies operate have developed plans, and had such plans approved or partially approved by the EPA, which are not expected to have a material impact on the Companies’ results of operations or cash flows. However, until implementation plans for the standard are developed and approved for all states in which the Companies operate, the Companies are unable to predict whether or to what extent the new rules will ultimately require additional controls. The

expenditures required to implement additional controls could have a material impact on the Companies’ results of operations and cash flows.

In July 2019, the EPA published the final rule informally referred to as the ACE Rule, as a replacement for the Clean Power Plan. The ACE Rule regulated GHG emissions from existing coal-fired power plants pursuant to Section 111(d) of the CAA and required states to develop plans by July 2022 establishing unit-specific performance standards for existing coal-fired power plants. In January 2021, the U.S. Court of Appeals for the D.C. Circuit vacated the ACE Rule and remanded it to the EPA. This decision would take effect upon issuance of the court’s mandate. In March 2021, the court issued a partial mandate vacating and remanding all parts of the ACE Rule except for the portion of the ACE Rule that repealed the Clean Power Plan. In October 2021, the U.S. Supreme Court agreed to hear a challenge of the U.S. Court of Appeals for the D.C. Circuit’s decision on the ACE Rule. In June 2022, the U.S. Supreme Court reversed the D.C. Circuit’s decision on the ACE Rule and remanded the case back to the D.C. Circuit. Until the case is resolved by the D.C. Circuit and/or the EPA issues new rulemaking, the Companies cannot predict an impact to its operations, financial condition and/or cash flows.

In August 2016, the EPA issued a draft rule proposing to reaffirm that a source’s obligation to obtain a PSD or Title V permit for GHGs is triggered only if such permitting requirements are first triggered by non-GHG, or conventional, pollutants that are regulated by the New Source Review program, and exceed a significant emissions rate of 75,000 tons per year of CO2 equivalent emissions. Until the EPA ultimately takes final action on this rulemaking, the Companies cannot predict the impact to their results of operations, financial condition and/or cash flows.

In December 2018, the EPA proposed revised Standards of Performance for Greenhouse Gas Emissions from New, Modified, and Reconstructed Stationary Sources. The proposed rule would amend the previous determination that the best system of emission reduction for newly constructed coal-fired steam generating units is no longer partial carbon capture and storage. Instead, the proposed revised best system of emission reduction for this source category is the most efficient demonstrated steam cycle (e.g., supercritical steam conditions for large units and subcritical steam conditions for small units) in combination with best operating practices. The proposed revision to the performance standards for coal-fired steam generating units remains pending. Until the EPA ultimately takes final action on this rulemaking, the Companies cannot predict the impact to their results of operations, financial condition and/or cash flows.

The CWA, as amended, is a comprehensive program requiring a broad range of regulatory tools including a permit program to authorize and regulate discharges to surface waters with strong enforcement mechanisms. The Companies must comply with applicable aspects of the CWA programs at their operating facilities.

In October 2014, the final regulations under Section 316(b) of the CWA that govern existing facilities and new units at existing facilities that employ a cooling water intake structure and that have flow levels exceeding a minimum threshold became effective. The rule establishes a national standard for impingement based on seven compliance options, but forgoes the creation of a single technology standard for entrainment. Instead, the EPA has delegated entrainment technology decisions to state regulators. State regulators are to make case-by-case entrainment technology determinations after an examination of five mandatory facility-specific factors, including a social cost-benefit test, and six optional facility-specific factors. The rule governs all electric generating stations with water withdrawals above two MGD, with a heightened entrainment analysis for those facilities over 125 MGD. Dominion Energy and Virginia Power currently have 15 and nine facilities, respectively, that are subject to the final regulations. Dominion Energy is also working with the EPA and state regulatory agencies to assess the applicability of Section 316(b) to eight hydroelectric facilities, including three Virginia Power facilities. The Companies anticipate that they may have to install impingement control technologies at certain of these stations that have once-through cooling systems. The Companies are currently evaluating the need or potential for entrainment controls under the final rule as these decisions will be made on a case-by-case basis after a thorough review of detailed biological, technological, and cost benefit studies. DESC is conducting studies and implementing plans as required by the rule to determine appropriate intake structure modifications at certain facilities to ensure compliance with this rule. While the impacts of this rule could be material to the Companies’ results of operations, financial condition and/or cash flows, the existing regulatory

frameworks in South Carolina and Virginia provide rate recovery mechanisms that could substantially mitigate any such impacts for the regulated electric utilities.

In September 2015, the EPA released a final rule to revise the Effluent Limitations Guidelines for the Steam Electric Power Generating Category. The final rule established updated standards for wastewater discharges that apply primarily at coal and oil steam generating stations. Affected facilities are required to convert from wet to dry or closed cycle coal ash management, improve existing wastewater treatment systems and/or install new wastewater treatment technologies in order to meet the new discharge limits. In April 2017, the EPA granted two separate petitions for reconsideration of the Effluent Limitations Guidelines final rule and stayed future compliance dates in the rule. Also in April 2017, the U.S. Court of Appeals for the Fifth Circuit granted the EPA’s request for a stay of the pending consolidated litigation challenging the rule while the EPA addresses the petitions for reconsideration. In September 2017, the EPA signed a rule to postpone the earliest compliance dates for certain waste streams regulations in the Effluent Limitations Guidelines final rule from November 2018 to November 2020; however, the latest date for compliance for these regulations was December 2023. In October 2020, the EPA released the final rule that extends the latest dates for compliance. Individual facilities’ compliance dates will vary based on circumstances and the determination by state regulators and may range from 2021 to 2028. While the impacts of this rule could be material to the Companies’ results of operations, financial condition and/or cash flows, the existing regulatory frameworks in South Carolina and Virginia provide rate recovery mechanisms that could substantially mitigate any such impacts for the regulated electric utilities.

The operations of the Companies are subject to a variety of state and federal laws and regulations governing the management and disposal of solid and hazardous waste, and release of hazardous substances associated with current and/or historical operations. The CERCLA, as amended, and similar state laws, may impose joint, several and strict liability for cleanup on potentially responsible parties who owned, operated or arranged for disposal at facilities affected by a release of hazardous substances. In addition, many states have created programs to incentivize voluntary remediation of sites where historical releases of hazardous substances are identified and property owners or responsible parties decide to initiate cleanups.

From time to time, the Companies may be identified as a potentially responsible party in connection with the alleged release of hazardous substances or wastes at a site. Under applicable federal and state laws, the Companies could be responsible for costs associated with the investigation or remediation of impacted sites, or subject to contribution claims by other responsible parties for their costs incurred at such sites. The Companies also may identify, evaluate and remediate other potentially impacted sites under voluntary state programs. Remediation costs may be subject to reimbursement under the Companies’ insurance policies, rate recovery mechanisms, or both. Except as described below, the Companies do not believe these matters will have a material effect on results of operations, financial condition and/or cash flows.

Dominion Energy has determined that it is associated with former manufactured gas plant sites, including certain sites associated with Virginia Power. At 13 sites associated with Dominion Energy, remediation work has been substantially completed under federal or state oversight. Where required, the sites are following state-approved groundwater monitoring programs. Dominion Energy commenced remediation activities at one site in the second quarter of 2022. In addition, Dominion Energy has proposed remediation plans for one site at Virginia Power and expects to commence remediation activities in 2023 depending on receipt of final permits and approvals. At December 31, 2022 and 2021, Dominion Energy had $47 million and $45 million, respectively, of reserves recorded, of which $1 million in both periods is reflected in liabilities held for sale. Dominion Energy’s reserves include charges of $14 million ($11 million after-tax) recorded in 2020, in other operations and maintenance expense in the Consolidated Statements of Income, except for $4 million ($3 million after-tax) presented in discontinued operations. At both December 31, 2022 and 2021, Virginia Power had $25 million of reserves recorded. Virginia Power’s reserves include charges of $10 million ($7 million after-tax) recorded in 2020, in other operations and maintenance expense in the Consolidated Statements of Income. Dominion Energy is associated with 12 additional sites, including two associated with Virginia Power, which are not under investigation by any state or federal environmental agency nor the subject of any current or proposed plans to perform remediation activities. Due to the uncertainty surrounding such sites, the Companies are unable to make an estimate of the potential financial statement impacts.

The Companies are defendants in a number of lawsuits and claims involving unrelated incidents of property damage and personal injury. Due to the uncertainty surrounding these matters, the Companies are unable to make an estimate of the potential financial statement impacts; however, they could have a material impact on results of operations, financial condition and/or cash flows.

The following describes certain legal proceedings involving Dominion Energy, SCANA or DESC relating primarily to events occurring before closing of the SCANA Combination. No reference to, or disclosure of, any proceeding, item or matter described

below shall be construed as an admission or indication that such proceeding, item or matter is material. For certain of these matters, and unless otherwise noted therein, Dominion Energy is unable to estimate a reasonable range of possible loss and the related financial statement impacts, but for any such matter there could be a material impact to its results of operations, financial condition and/or cash flows. For the matters for which Dominion Energy is able to reasonably estimate a probable loss, Dominion Energy’s Consolidated Balance Sheets at December 31, 2022 and 2021 include reserves of $94 million and $274 million, respectively, included in other current liabilities, and insurance receivables of $68 million and $118 million, respectively, included within other receivables. These balances at December 31, 2022 and 2021 include $68 million and $85 million, respectively, of offsetting reserves and insurance receivables related to personal injury or wrongful death cases which are currently pending. During the year ended December 31, 2022, charges included in Dominion Energy’s Consolidated Statements of Income were inconsequential. Dominion Energy’s Consolidated Statements of Income for the years ended December 31, 2021 and 2020 include charges of $100 million ($75 million after-tax) and $90 million ($68 million after-tax), respectively, within impairment of assets and other charges (reflected in the Corporate and Other segment). In addition, Dominion Energy’s Consolidated Statements of Income for the year ended December 31, 2020 include charges of $25 million ($25 million after-tax) within other income (reflected in the Corporate and Other segment).

In September 2017, a shareholder derivative action was filed against certain former executive officers and directors of SCANA in the State Court of Common Pleas in Richland County, South Carolina (the State Court Derivative Case). In September 2018, this action was consolidated with another action in the Business Court Pilot Program in Richland County. The plaintiffs allege, among other things, that the defendants breached their fiduciary duties to shareholders by their gross mismanagement of the NND Project, and that the defendants were unjustly enriched by bonuses they were paid in connection with the project. In January 2019, the defendants filed a motion to dismiss the consolidated action. In February 2019, one action was voluntarily dismissed. In March 2020, the court denied the defendants’ motion to dismiss. In April 2020, the defendants filed a notice of appeal with the South Carolina Court of Appeals and a petition with the Supreme Court of South Carolina seeking appellate review of the denial of the motion to dismiss. In June 2020, the plaintiffs filed a motion to dismiss the appeal with the South Carolina Court of Appeals, which was granted in July 2020. In August 2020, the Supreme Court of South Carolina denied the defendants’ petition seeking appellate review. Also in August 2020, the defendants filed a petition for rehearing with the South Carolina Court of Appeals relating to the July 2020 ruling by the court, which was denied in October 2020. In November 2020, SCANA filed a petition of certiorari with the Supreme Court of South Carolina seeking appellate review of the denial of SCANA’s motion to dismiss. This petition was denied in June 2021. Also in June 2021, the parties reached an agreement in principle in the amount of $33 million to resolve this matter, subject to court approval. This settlement was reached in contemplation of and to be utilized to satisfy a portion of the Federal Court Merger Case and the State Court Merger Case discussed below. In November 2021, the parties executed a settlement agreement and filed with the State Court of Common Pleas in Richland County, South Carolina for approval. In June 2022, the State Court of Common Pleas in Richland County, South Carolina issued final approval of the settlement agreement with the funds utilized to satisfy a portion of the State Court Merger Case as discussed below.

In January 2018, a purported class action was filed against SCANA, Dominion Energy and certain former executive officers and directors of SCANA in the State Court of Common Pleas in Lexington County, South Carolina (the City of Warren Lawsuit). The plaintiff alleges, among other things, that defendants violated their fiduciary duties to shareholders by executing a merger agreement that would unfairly deprive plaintiffs of the true value of their SCANA stock, and that Dominion Energy aided and abetted these actions. Among other remedies, the plaintiff seeks to enjoin and/or rescind the merger.

In February 2018, a purported class action was filed against Dominion Energy and certain former directors of SCANA and DESC in the State Court of Common Pleas in Richland County, South Carolina (the Metzler Lawsuit). The allegations made and the relief sought by the plaintiffs are substantially similar to that described for the City of Warren Lawsuit.

In September 2019, the U.S. District Court for the District of South Carolina granted the plaintiffs’ motion to consolidate the City of Warren Lawsuit and the Metzler Lawsuit (the Federal Court Merger Case). In October 2019, the plaintiffs filed an amended complaint against certain former directors and executive officers of SCANA and DESC, which stated substantially similar allegations to those in the City of Warren Lawsuit and the Metzler Lawsuit as well as an inseparable fraud claim. In November 2019, the defendants filed a motion to dismiss. In April 2020, the U.S. District Court for the District of South Carolina denied the motion to dismiss. In May 2020, SCANA filed a motion to intervene, which was denied in August 2020. In September 2020, SCANA filed a notice of appeal with the U.S. Court of Appeals for the Fourth Circuit. In June 2021, the parties reached an agreement in principle in the amount of $63 million to resolve this matter as well as the State Court Merger Case described below, subject to court approval. This settlement was reached in contemplation of and to be partially satisfied by the State Court Derivative Case settlement described above. In November 2021, the parties executed a settlement agreement, as described above relating to this matter as well as the State Court Derivative Case and the State Court Merger Case, and filed with the State Court of Common Pleas in Richland County, South Carolina for approval. In June 2022, this case was dismissed in connection with the final approval by the State Court of Common Pleas in Richland County, South Carolina of the settlement agreement.

In May 2019, a case was filed against certain former executive officers and directors of SCANA in the State Court of Common Pleas in Richland County, South Carolina (the State Court Merger Case). The plaintiff alleges, among other things, that the defendants breached their fiduciary duties to shareholders by their gross mismanagement of the NND Project, were unjustly enriched by the bonuses they were paid in connection with the project and breached their fiduciary duties to secure and obtain the best price for the sale of SCANA. Also in May 2019, the case was removed to the U.S. District Court of South Carolina by the non-South Carolina defendants. In June 2019, the plaintiffs filed a motion to remand the case to state court. In January 2020, the case was remanded to state court. In February 2020, the defendants filed a motion to dismiss. In June 2021, the parties reached an agreement in principle as described above relating to this matter as well as the Federal Court Merger Case and the State Court Derivative Case. In November 2021, the parties executed a settlement agreement, as described above relating to this matter as well as the State Court Derivative Case and the Federal Court Merger Case, and filed with the State Court of Common Pleas in Richland County, South Carolina for approval. In June 2022, the State Court of Common Pleas in Richland County, South Carolina issued final approval of the settlement agreement. Also in June 2022, Dominion Energy utilized the $33 million of insurance proceeds from the State Court Derivative Case settlement, the issuance of 0.4 million shares of its common stock and the payment of $2 million in cash to satisfy its obligations under the settlement agreement.

In August 2017, a case was filed in the U.S. District Court for the District of South Carolina on behalf of persons who were formerly employed at the NND Project. In July 2018, the court certified this case as a class action. In February 2019, certain of these plaintiffs filed an additional case, which case has been dismissed and the plaintiffs have joined the case filed August 2017. The plaintiffs allege, among other things, that SCANA, DESC, Fluor Corporation and Fluor Enterprises, Inc. violated the Worker Adjustment and Retraining Notification Act in connection with the decision to stop construction at the NND Project. The plaintiffs allege that the defendants failed to provide adequate advance written notice of their terminations of employment and are seeking damages, which could be as much as $100 million for 100% of the NND Project. In January 2021, the U.S. District Court for the District of South Carolina granted summary judgment in favor of SCANA, DESC, Fluor Corporation and Fluor Enterprises, Inc. In February 2021, the plaintiffs filed a notice of appeal with the U.S. Court of Appeals for the Fourth Circuit. In November 2021, the U.S Court of Appeals for the Fourth Circuit affirmed the lower court ruling. In March 2022, the deadline to file an appeal to the Supreme Court of the United States expired.

In September 2018, a case was filed in the State Court of Common Pleas in Fairfield County, South Carolina by Fluor Enterprises, Inc. and Fluor Daniel Maintenance Services, Inc. against DESC and Santee Cooper. The plaintiffs make claims for indemnification, breach of contract and promissory estoppel arising from, among other things, the defendants' alleged failure and refusal to defend and indemnify the Fluor defendants in the aforementioned case. As a result of the ruling in favor of the defendants in the aforementioned case, DESC was able to resolve Fluor’s claims for an inconsequential amount.

In June 2018, DESC received a notice of proposed assessment of approximately $410 million, excluding interest, from the SCDOR following its audit of DESC’s sales and use tax returns for the periods September 1, 2008 through December 31, 2017. The proposed assessment, which includes 100% of the NND Project, is based on the SCDOR’s position that DESC’s sales and use tax exemption for the NND Project does not apply because the facility will not become operational. In December 2020, the parties reached an agreement in principle in the amount of $165 million to resolve this matter. In June 2021, the parties executed a settlement agreement which allows DESC to fund the settlement amount through a combination of cash, shares of Dominion Energy common stock or real estate with an initial payment of at least $43 million in shares of Dominion Energy common stock. In August 2021, Dominion Energy issued 0.6 million shares of its common stock to satisfy DESC’s obligation for the initial payment under the settlement agreement. In May 2022, Dominion Energy issued an additional 0.9 million shares of its common stock to partially satisfy DESC’s remaining obligation under the settlement agreement. In June 2022, DESC requested approval from the South Carolina Commission to transfer certain real estate with a total settlement value of $51 million to satisfy its remaining obligation under the settlement agreement. In July 2022, the South Carolina Commission voted to approve the request and issued its final order in August 2022. In September 2022, DESC transferred certain non-utility property with a fair value of $28 million to the SCDOR under the settlement agreement, resulting in a gain of $18 million ($14 million after-tax) recorded in losses (gains) on sales of assets (reflected in Dominion Energy South Carolina) in Dominion Energy’s Consolidated Statements of Income for the year ended December 31, 2022. In December 2022, DESC transferred additional utility property with a fair value of $3 million to the SCDOR, resulting in an inconsequential gain. In October 2022, DESC filed for approval to transfer the remaining real estate with FERC which was received in November 2022. The transfers of such utility properties are expected to be completed by early 2024 and to result in a gain of approximately $20 million upon completion.

In May 2018, a consolidated complaint against DESC, SCANA and the State of South Carolina was filed in the State Court of Common Pleas in Hampton County, South Carolina (the DESC Ratepayer Case). The plaintiffs alleged, among other things, that DESC was negligent and unjustly enriched, breached alleged fiduciary and contractual duties and committed fraud and misrepresentation in failing to properly manage the NND Project, and that DESC committed unfair trade practices and violated state anti-trust laws. In December 2018, the State Court of Common Pleas in Hampton County entered an order granting preliminary approval of a class action settlement. The court entered an order granting final approval of the settlement in June 2019, which became effective in July 2019. The settlement agreement, contingent upon the closing of the SCANA Combination, provided that SCANA and DESC establish an escrow account and proceeds from the escrow account would be distributed to the plaintiffs, after payment of certain taxes, attorneys' fees and other expenses and administrative costs. The escrow account would include (1) up to $2.0 billion, net of a credit of up to $2.0 billion in future electric bill relief, which would inure to the benefit of the escrow account in favor of class members over a period of time established by the South Carolina Commission in its order related to matters before the South Carolina Commission related to the NND Project, (2) a cash payment of $115 million and (3) the transfer of certain DESC-owned real estate or sales proceeds from the sale of such properties, which counsel for the plaintiffs estimated to have an aggregate value between $60 million and $85 million. At the closing of the SCANA Combination, SCANA and DESC funded the cash payment portion of the escrow account. In July 2019, DESC transferred $117 million representing the cash payment, plus accrued interest, to the plaintiffs. Through August 2020, property, plant and equipment with a net recorded value of $27 million had been transferred to the plaintiffs in coordination with the court-appointed real estate trustee to satisfy the settlement agreement. In September 2020, the court entered an order approving a final resolution of the transfer of real estate or sales proceeds with a cash contribution of $38.5 million by DESC and the conveyance of property, plant and equipment with a net recorded value of $3 million, which was completed by DESC in October 2020. In December 2021, the court approved a motion for and DESC completed the repurchase of $8 million of property, plant and equipment previously transferred to the plaintiffs.

In September 2017, a purported class action was filed by Santee Cooper ratepayers against Santee Cooper, DESC, Palmetto Electric Cooperative, Inc. and Central Electric Power Cooperative, Inc. in the State Court of Common Pleas in Hampton County, South Carolina (the Santee Cooper Ratepayer Case). The allegations were substantially similar to those in the DESC Ratepayer Case. In March 2020, the parties executed a settlement agreement relating to this matter as well as the Luquire Case and the Glibowski Case described below. The settlement agreement provided that Dominion Energy and Santee Cooper establish a fund for the benefit of class members in the amount of $520 million, of which Dominion Energy’s portion was $320 million of shares of Dominion Energy common stock. In July 2020, the court issued a final approval of the settlement agreement. In September 2020, Dominion Energy issued $322 million of shares of Dominion Energy common stock to satisfy its obligation under the settlement agreement, including interest charges.

In July 2019, a similar purported class action was filed by certain Santee Cooper ratepayers against DESC, SCANA, Dominion Energy and former directors and officers of SCANA in the State Court of Common Pleas in Orangeburg, South Carolina (the Luquire Case). In August 2019, DESC, SCANA and Dominion Energy were voluntarily dismissed from the case. The claims were similar to the Santee Cooper Ratepayer Case. In March 2020, the parties executed a settlement agreement as described above relating to this matter as well as the Santee Cooper Ratepayer Case and the Glibowski Case. This case was dismissed as part of the Santee Cooper Ratepayer Case settlement described above.

In January 2018, a purported class action was filed, and subsequently amended, against SCANA, DESC and certain former executive officers in the U.S. District Court for the District of South Carolina (the Glibowski Case). The plaintiff alleged, among other things, that SCANA, DESC and the individual defendants participated in an unlawful racketeering enterprise in violation of RICO and conspired to violate RICO by fraudulently inflating utility bills to generate unlawful proceeds. In March 2020, the parties executed a settlement agreement as described above relating to this matter as well as the Santee Cooper Ratepayer Case and the Luquire Case. This case was dismissed as part of the Santee Cooper Ratepayer Case settlement described above.

In September 2017, a purported class action was filed against SCANA and certain former executive officers and directors in the U.S. District Court for the District of South Carolina. Subsequent additional purported class actions were separately filed against all or nearly all of these defendants (collectively the SCANA Securities Class Action). In January 2018, the U.S. District Court for the District of South Carolina consolidated these suits, and the plaintiffs filed a consolidated amended complaint in March 2018. The plaintiffs alleged, among other things, that the defendants violated §10(b) of the Securities Exchange Act of 1934, as amended, and Rule 10b-5 promulgated thereunder, and that the individually named defendants are liable under §20(a) of the same act. In December 2019, the parties executed a settlement agreement pursuant to which SCANA would pay $192.5 million, up to $32.5 million of which could be satisfied through the issuance of shares of Dominion Energy common stock, subject to court approval. In February 2020, the

U.S. District Court for the District of South Carolina granted preliminary approval of the settlement agreement, pending a fairness hearing, and granted final approval in July 2020. In March 2020, SCANA funded an escrow account with $160 million in cash and paid the balance of $32.5 million in cash in August 2020 to satisfy the settlement.

In November 2017, Fairfield County filed a complaint and a motion for temporary injunction against DESC in the State Court of Common Pleas in Fairfield County, South Carolina, making allegations of breach of contract, fraud, negligent misrepresentation, breach of fiduciary duty, breach of implied duty of good faith and fair dealing and unfair trade practices related to DESC’s termination of the FILOT agreement between DESC and Fairfield County related to the NND Project. The plaintiff sought a temporary and permanent injunction to prevent DESC from terminating the FILOT agreement. The plaintiff withdrew the motion for temporary injunction in December 2017. In July 2021, the parties executed a settlement agreement requiring DESC to pay $99 million, which could be satisfied in either cash or shares of Dominion Energy common stock. Also in July 2021, the State Court of Common Pleas in Fairfield County, South Carolina approved the settlement. In July 2021, Dominion Energy issued 1.4 million shares of Dominion Energy common stock to satisfy DESC’s obligation under the settlement agreement.

In September and October 2017, SCANA was served with subpoenas issued by the U.S. Attorney’s Office for the District of South Carolina and the Staff of the SEC’s Division of Enforcement seeking documents related to the NND Project. In February 2020, the SEC filed a complaint against SCANA, two of its former executive officers and DESC in the U.S. District Court for the District of South Carolina alleging that the defendants violated federal securities laws by making false and misleading statements about the NND Project. In April 2020, SCANA and DESC reached an agreement in principle with the Staff of the SEC’s Division of Enforcement to settle, without admitting or denying the allegations in the complaint. In December 2020, the U.S. District Court for the District of South Carolina issued an order approving the settlement which required SCANA to pay a civil monetary penalty totaling $25 million, and SCANA and DESC to pay disgorgement and prejudgment interest totaling $112.5 million, which disgorgement and prejudgment interest amount were deemed satisfied by the settlements in the SCANA Securities Class Action and the DESC Ratepayer Case. SCANA paid the civil penalty in December 2020. The SEC civil action against two former executive officers of SCANA remains pending and is currently subject to a stay granted by the court in June 2020 at the request of the U.S. Attorney’s Office for the District of South Carolina.

In addition, the South Carolina Law Enforcement Division is conducting a criminal investigation into the handling of the NND Project by SCANA and DESC. Dominion Energy is cooperating fully with the investigations by the U.S. Attorney’s Office and the South Carolina Law Enforcement Division, including responding to additional subpoenas and document requests. Dominion Energy has also entered into a cooperation agreement with the U.S. Attorney’s Office and the South Carolina Attorney General’s Office. The cooperation agreement provides that in consideration of its full cooperation with these investigations to the satisfaction of both agencies, neither such agency will criminally prosecute or bring any civil action against Dominion Energy or any of its current, previous, or future direct or indirect subsidiaries related to the NND Project. A former executive officer of SCANA entered a plea agreement with the U.S. Attorney’s Office and the South Carolina Attorney General’s Office in June 2020 and entered a guilty plea with the U.S. District Court for the District of South Carolina in July 2020. Another former executive officer of SCANA entered a plea agreement with the U.S. Attorney's Office and the South Carolina Attorney General's Office in November 2020 and entered guilty pleas in the U.S. District Court for the District of South Carolina and in South Carolina state court in February 2021. As a result of the pleas, Dominion Energy has terminated indemnity for these former executive officers related to these two cases.

DESC, for itself and as agent for Santee Cooper, entered into an engineering, construction and procurement contract with Westinghouse and WECTEC in 2008 for the design and construction of the NND Project, of which DESC’s ownership share is 55%. Various difficulties were encountered in connection with the project. The ability of Westinghouse and WECTEC to adhere to established budgets and construction schedules was affected by many variables, including unanticipated difficulties encountered in connection with project engineering and the construction of project components, constrained financial resources of the contractors, regulatory, legal, training and construction processes associated with securing approvals, permits and licenses and necessary amendments to them within projected time frames, the availability of labor and materials at estimated costs and the efficiency of project labor. There were also contractor and supplier performance issues, difficulties in timely meeting critical regulatory requirements, contract disputes, and changes in key contractors or subcontractors. These matters preceded the filing for bankruptcy protection by Westinghouse and WECTEC in March 2017, and were the subject of comprehensive analyses performed by SCANA and Santee Cooper.

Based on the results of SCANA’s analysis, and in light of Santee Cooper's decision to suspend construction on the NND Project, in July 2017, SCANA determined to stop the construction of the units and to pursue recovery of costs incurred in connection with the

construction under the abandonment provisions of the Base Load Review Act or through other means. This decision by SCANA became the focus of numerous legislative, regulatory and legal proceedings. Some of these proceedings are described above.

In September 2017, DESC, for itself and as agent for Santee Cooper, filed with the U.S. Bankruptcy Court for the Southern District of New York Proofs of Claim for unliquidated damages against each of Westinghouse and WECTEC. These Proofs of Claim were based upon the anticipatory repudiation and material breach by Westinghouse and WECTEC of the contract, and assert against Westinghouse and WECTEC any and all claims that are based thereon or that may be related thereto.

Westinghouse’s reorganization plan was confirmed by the U.S. Bankruptcy Court for the Southern District of New York and became effective in August 2018. In connection with the effectiveness of the reorganization plan, the contract associated with the NND Project was deemed rejected. DESC contested approximately $285 million of filed liens in Fairfield County, South Carolina. Most of these asserted liens were claims that relate to work performed by Westinghouse subcontractors before the Westinghouse bankruptcy, although some of them were claims arising from work performed after the Westinghouse bankruptcy.

DESC and Santee Cooper were responsible for amounts owed to Westinghouse for valid work performed by Westinghouse subcontractors on the NND Project after the Westinghouse bankruptcy filing until termination of the interim assessment agreement. In December 2019, DESC and Santee Cooper entered into a confidential settlement agreement with W Wind Down Co LLC resolving claims relating to the interim assessment agreement.

Further, some Westinghouse subcontractors that made claims against Westinghouse in the bankruptcy proceeding also filed claims against DESC and Santee Cooper in South Carolina state court for damages. Many of these claimants asserted construction liens against the NND Project site. In December 2021, settlements were reached to resolve all remaining claims made by Westinghouse subcontractors. All amounts for which Dominion Energy was ultimately responsible were funded utilizing, and did not exceed, the portion of the Toshiba Settlement allocated for such balances within the SCANA Merger Approval Order recorded in regulatory liabilities on Dominion Energy’s Consolidated Balance Sheets.

The NRC requires nuclear power plant owners to annually update minimum financial assurance amounts for the future decommissioning of their nuclear facilities. Decommissioning involves the decontamination and removal of radioactive contaminants from a nuclear power station once operations have ceased, in accordance with standards established by the NRC. The 2022 calculation for the NRC minimum financial assurance amount, aggregated for Dominion Energy and Virginia Power’s nuclear units, excluding joint owners’ assurance amounts and Millstone Unit 1, as this unit is in a decommissioning state, was $3.6 billion and $2.1 billion, respectively, and has been satisfied by a combination of the funds being collected and deposited in the nuclear decommissioning trusts and the real annual rate of return growth of the funds allowed by the NRC. The 2022 NRC minimum financial assurance amounts above were calculated using preliminary December 31, 2022 U.S. Bureau of Labor Statistics indices. Dominion Energy believes that decommissioning funds and their expected earnings will be sufficient to cover expected decommissioning costs for the Millstone units. In addition, Dominion Energy believes that the decommissioning funds and their expected earnings will be sufficient to cover expected decommissioning costs for the Summer unit, particularly when combined with future ratepayer collections and contributions. The Companies believe the decommissioning funds and their expected earnings for the Surry and North Anna units will be sufficient to cover decommissioning costs, particularly when combined with future ratepayer collections and contributions to these decommissioning trusts, if such future collections and contributions are required. This reflects a positive long-term outlook for trust fund investment returns as the decommissioning of the units will not be complete for decades. The Companies will continue to monitor these trusts to ensure they meet the NRC minimum financial assurance requirement, which may include, if needed, the use of parent company guarantees, surety bonding or other financial instruments recognized by the NRC. See Note 9 for additional information on nuclear decommissioning trust investments.

The Price-Anderson Amendments Act of 1988 provides the public up to $13.7 billion of liability protection on a per site, per nuclear incident basis, via obligations required of owners of nuclear power plants, and allows for an inflationary provision adjustment every five years. During the third quarter of 2022, the total liability protection per nuclear incident available to all participants in the Secondary Financial Protection Program increased from $13.5 billion to $13.7 billion. This increase does not impact Dominion Energy’s responsibility per active unit under the Price-Anderson Amendments Act of 1988. The Companies have purchased $450 million of coverage from commercial insurance pools for Millstone, Summer, Surry and North Anna with the remainder provided through the mandatory industry retrospective rating plan. In the event of a nuclear incident at any licensed nuclear reactor in the U.S., the Companies could be assessed up to $138 million for each of their licensed reactors not to exceed $20 million per year per reactor. There is no limit to the number of incidents for which this retrospective premium can be assessed. The current levels of nuclear property insurance coverage for Millstone, Summer, Surry and North Anna are all $1.06 billion.

The Companies’ nuclear property insurance coverage for Millstone, Summer, Surry and North Anna meets or exceeds the NRC minimum requirement for nuclear power plant licensees of $1.06 billion per reactor site. This includes coverage for premature decommissioning and functional total loss. The NRC requires that the proceeds from this insurance be used first, to return the reactor to and maintain it in a safe and stable condition and second, to decontaminate the reactor and station site in accordance with a plan approved by the NRC. Nuclear property insurance is provided by NEIL, a mutual insurance company, and is subject to retrospective premium assessments in any policy year in which losses exceed the funds available to the insurance company. Dominion Energy and Virginia Power's maximum retrospective premium assessment for the current policy period is $65 million and $33 million, respectively. Based on the severity of the incident, the Board of Directors of the nuclear insurer has the discretion to lower or eliminate the maximum retrospective premium assessment. The Companies have the financial responsibility for any losses that exceed the limits or for which insurance proceeds are not available because they must first be used for stabilization and decontamination. Additionally, DESC maintains an excess property insurance policy with the European Mutual Association for Nuclear Insurance. The policy provides coverage to Summer for property damage and outage costs up to $1 million resulting from an event of a non-nuclear origin. The European Mutual Association for Nuclear Insurance policy permits retrospective assessments under certain conditions to cover insurer's losses. Based on the current annual premium, DESC's share of the retrospective premium assessment would not exceed an inconsequential amount.

Millstone, Virginia Power and Summer also purchase accidental outage insurance from NEIL to mitigate certain expenses, including replacement power costs, associated with the prolonged outage of a nuclear unit due to direct physical damage. Under this program, the Companies are subject to a retrospective premium assessment for any policy year in which losses exceed funds available to NEIL. Dominion Energy and Virginia Power's maximum retrospective premium assessment for the current policy period is $32 million and $9 million, respectively.

ODEC, a part owner of North Anna, Santee Cooper, a part owner of Summer and Massachusetts Municipal and Green Mountain, part owners of Millstone’s Unit 3, are responsible to the Companies for their share of the nuclear decommissioning obligation and insurance premiums on applicable units, including any retrospective premium assessments and any losses not covered by insurance.

The Companies entered into contracts with the DOE for the disposal of spent nuclear fuel under provisions of the Nuclear Waste Policy Act of 1982. The DOE failed to begin accepting the spent fuel on January 31, 1998, the date provided by the Nuclear Waste Policy Act and by the Companies’ contracts with the DOE. The Companies have previously received damages award payments and settlement payments related to these contracts.

By mutual agreement of the parties, the settlement agreements are extendable to provide for resolution of damages incurred after 2013. The settlement agreements for the Surry, North Anna and Millstone nuclear power stations have been extended and provided for periodic payments for damages incurred through December 31, 2022. In November 2022, the DOE notified the Companies that it intends to extend these agreements through December 31, 2025 and future additional extensions are contemplated by the settlement agreements. A similar agreement for Summer extends until the DOE has accepted the same amount of spent fuel from the facility as if it has fully performed its contractual obligations.

In June 2018, a lawsuit for Kewaunee was filed in the U.S. Court of Federal Claims for recovery of spent nuclear fuel storage costs incurred after 2013. In March 2019, Dominion Energy amended its filing for recovery of spent nuclear fuel storage to include costs incurred for the year ended December 31, 2018. In January 2022, a settlement agreement was entered into for $48 million. Dominion Energy received the settlement funds in February 2022.

In 2022, Virginia Power received payments of $17 million for resolution of claims incurred at North Anna and Surry for the period of January 1, 2020 through December 31, 2020. In addition, Dominion Energy received payments of $7 million for resolution of claims incurred at Millstone for the period of July 1, 2020 through June 30, 2021 and $1 million for resolution of its share of claims incurred at Summer for the period of January 1, 2021 through December 31, 2021.

In 2021, Virginia Power received payments of $25 million for resolution of claims incurred at North Anna and Surry for the period of January 1, 2019 through December 31, 2019. In addition, Dominion Energy received payments of $9 million for resolution of claims incurred at Millstone for the period of July 1, 2019 through June 30, 2020 and $1 million for resolution of its share of claims incurred at Summer for the period of January 1, 2020 through December 31, 2020.

In 2020, Virginia Power received payments of $24 million for resolution of claims incurred at North Anna and Surry for the period of January 1, 2018 through December 31, 2018. In addition, Dominion Energy received payments of $11 million for resolution of claims incurred at Millstone for the period of July 1, 2018 through June 30, 2019 and $4 million for resolution of its share of claims incurred at Summer for the period of January 1, 2019 through December 31, 2019.

The Companies continue to recognize receivables for certain spent nuclear fuel-related costs that they believe are probable of recovery from the DOE. Dominion Energy’s receivables for spent nuclear fuel-related costs totaled $56 million and $52 million at December 31, 2022 and 2021, respectively. Virginia Power’s receivables for spent nuclear fuel-related costs totaled $37 million and $39 million at December 31, 2022 and 2021, respectively.

The Companies will continue to manage their spent fuel until it is accepted by the DOE.

At December 31, 2022, Dominion Energy had the following long-term commitments that are noncancelable or are cancelable only under certain conditions, and that a third party has used to secure financing for the facility that will provide the contracted goods or services:


	2023		2024		2025		2026		2027		Thereafter		Total
(millions)
Purchased electric capacity(1)	$	71	$	70	$	70	$	73	$	73	$	630	$	987

(1)

Commitments represent estimated amounts payable for energy under power purchase contracts with qualifying facilities which expire at various dates through 2046. Energy payments are generally based on fixed dollar amounts per month and totaled $61 million and $59 million for the years ended December 31, 2022 and 2021, respectively.

At December 31, 2022, Dominion Energy had issued four guarantees related to Cove Point, an equity method investment, in support of terminal services, transportation and construction. Two of the Cove Point guarantees have a cumulative maximum exposure of $1.9 billion while the other two guarantees have no maximum limit. No amounts related to these guarantees have been recorded.

In addition, at December 31, 2022, Dominion Energy had issued an additional $20 million of guarantees, primarily to support third parties. No amounts related to these guarantees have been recorded.

Dominion Energy also enters into guarantee arrangements on behalf of its consolidated subsidiaries, primarily to facilitate their commercial transactions with third parties. If any of these subsidiaries fail to perform or pay under the contracts and the counterparties seek performance or payment, Dominion Energy would be obligated to satisfy such obligation. To the extent that a liability subject to a guarantee has been incurred by one of Dominion Energy’s consolidated subsidiaries, that liability is included in the Consolidated Financial Statements. Dominion Energy is not required to recognize liabilities for guarantees issued on behalf of its subsidiaries unless it becomes probable that it will have to perform under the guarantees. Terms of the guarantees typically end once obligations have been paid. Dominion Energy currently believes it is unlikely that it would be required to perform or otherwise incur any losses associated with guarantees of its subsidiaries’ obligations.

At December 31, 2022, Dominion Energy had issued the following subsidiary guarantees:


	Maximum Exposure
(millions)
Commodity transactions(1)	$	2,567
Nuclear obligations(2)		243
Solar(3)		304
Other(4)		1,229
Total(5)(6)	$	4,343

(1)

Guarantees related to commodity commitments of certain subsidiaries. These guarantees were provided to counterparties in order to facilitate physical and financial transaction related commodities and services.

(2)

Guarantees primarily related to certain DGI subsidiaries regarding all aspects of running a nuclear facility.

(3)

Includes guarantees to facilitate the development of solar projects. Includes $90 million of guarantees related to entities held for sale.

(4)

Guarantees related to other miscellaneous contractual obligations such as leases, environmental obligations, construction projects and insurance programs. Also includes guarantees entered into by Dominion Energy RNG Holdings, II, Inc. on behalf of a subsidiary to facilitate construction of renewable natural gas facilities. Due to the uncertainty of workers’ compensation claims, the parental guarantee has no stated limit.

(5)

Excludes Dominion Energy’s guarantee of an offshore wind installation vessel discussed in Note 15.

(6)

In July 2016, Dominion Energy signed an agreement with a lessor to construct and lease a new corporate office property in Richmond, Virginia. The lessor provided equity and obtained financing commitments from debt investors, totaling $365 million, which funded total project costs. The project became substantially complete in August 2019 at which point the facility was available for Dominion Energy’s use and the five-year lease term commenced. At the end of the initial lease term, Dominion Energy can (i) extend the term of the lease for an additional five

years, subject to the approval of the participants, at current market terms, (ii) purchase the property for an amount equal to the project costs or, (iii) subject to certain terms and conditions, sell the property on behalf of the lessor to a third party using commercially reasonable efforts to obtain the highest cash purchase price for the property. If the project is sold and the proceeds from the sale are insufficient to repay the investors for the project costs, Dominion Energy may be required to make a payment to the lessor, up to 87% of project costs, for the difference between the project costs and sale proceeds. At December 31, 2022, no amounts have been recorded related to this guarantee.

Additionally, at December 31, 2022, Dominion Energy had purchased $249 million of surety bonds, including $172 million at Virginia Power and $39 million related to entities held for sale, and authorized the issuance of letters of credit by financial institutions of $202 million to facilitate commercial transactions by its subsidiaries with third parties. Under the terms of surety bonds, the Companies are obligated to indemnify the respective surety bond company for any amounts paid.

As part of commercial contract negotiations in the normal course of business, the Companies may sometimes agree to make payments to compensate or indemnify other parties for possible future unfavorable financial consequences resulting from specified events. The specified events may involve an adverse judgment in a lawsuit or the imposition of additional taxes due to a change in tax law or interpretation of the tax law. The Companies are unable to develop an estimate of the maximum potential amount of any other future payments under these contracts because events that would obligate them have not yet occurred or, if any such event has occurred, they have not been notified of its occurrence. However, at December 31, 2022, the Companies believe any other future payments, if any, that could ultimately become payable under these contract provisions, would not have a material impact on their results of operations, cash flows or financial position.

In 2020, Dominion Energy made unconditional promises to several charitable organizations, including to support its commitment to diversity and social justice through scholarship programs and donations to historically black colleges and universities. As a result, Dominion Energy recorded charges totaling $80 million in other income in its Consolidated Statements of Income for the year ended December 31, 2020. These commitments are to be funded at various intervals through 2028. Dominion Energy’s Consolidated Balance Sheets include $32 million and $43 million in other deferred credits and other liabilities at December 31, 2022 and 2021, respectively and $11 million and $26 million in other current liabilities at December 31, 2022 and 2021, respectively.