10KSB 1 sp4.htm _________________________________________________________________

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, DC  20549


FORM 10-KSB


[X]

ANNUAL REPORT UNDER SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934


For the fiscal year ended December 31, 2005


[ ]

TRANSITION REPORT UNDER SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934


For the transition period _________to_________


Commission file number 0-10884


SHELTER PROPERTIES IV

(Name of small business issuer in its charter)


South Carolina

57-0721760

(State or other jurisdiction of

(I.R.S. Employer

incorporation or organization)

(Identification No.)


55 Beattie Place, P.O. Box 1089

Greenville, South Carolina 29602

(Address of principal executive offices)


(864) 239-1000

Issuer's telephone number


Securities registered under Section 12(b) of the Exchange Act:


None


Securities registered under Section 12(g) of the Exchange Act:


Units of Limited Partnership Interest

(Title of class)


Check whether the issuer is not required to file reports pursuant to Section 13 or 15(d) of the Exchange Act []


Check whether the issuer (1) filed all reports required to be filed by Section 13 or 15(d) of the Exchange Act of 1934 during the past 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.  Yes  X  No ___


Check if there is no disclosure of delinquent filers in response to Item 405 of Regulation S-B contained in this form, and no disclosure will be contained, to the best of registrant's knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-KSB or any amendment to this Form 10-KSB.  [X]


Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act) Yes []  No[X]


State issuer's revenues for its most recent fiscal year.  $9,507,000


State the aggregate market value of the voting partnership interests held by non-affiliates computed by reference to the price at which the partnership interests were sold, or the average bid and asked prices of such partnership interests, as of December 31, 2005.  No market exists for the limited partnership interests of the Registrant, and, therefore, no aggregate market value can be determined.


DOCUMENTS INCORPORATED BY REFERENCE

None



The matters discussed in this report contain certain forward-looking statements, including, without limitation, statements regarding future financial performance and the effect of government regulations. Actual results may differ materially from those described in the forward-looking statements and will be affected by a variety of risks and factors including, without limitation: national and local economic conditions; the terms of governmental regulations that affect the Registrant and interpretations of those regulations; the competitive environment in which the Registrant operates; financing risks, including the risk that cash flows from operations may be insufficient to meet required payments of principal and interest; real estate risks, including variations of real estate values and the general economic climate in local markets and competition for tenants in such markets; litigation, including costs associated with prosecuting and defending claims and any adverse outcomes and possible environmental liabilities. Readers should carefully review the Registrant's financial statements and the notes thereto, as well as the risk factors described in the documents the Registrant files from time to time with the Securities and Exchange Commission.


PART I


Item 1.

Description of Business


Shelter Properties IV (the "Partnership" or "Registrant") was organized as a limited partnership under the laws of the State of South Carolina on August 21, 1981.  The general partner responsible for management of the Partnership's business is Shelter Realty IV Corporation, a South Carolina corporation (the "Corporate General Partner"). The Corporate General Partner is a subsidiary of Apartment Investment and Management Company ("AIMCO"), a publicly traded real estate investment trust. The other general partner is AIMCO Properties, L.P., an affiliate of the Corporate General Partner and AIMCO. The Partnership Agreement provides that the Partnership is to terminate on December 31, 2022 unless terminated prior to such date.


Commencing June 8, 1982, the Partnership offered pursuant to a Registration Statement filed with the Securities and Exchange Commission up to 49,900 Units of Limited Partnership Interest (the "Units") at a purchase price of $1,000 per Unit with a minimum purchase of 5 Units ($5,000) or 2 Units ($2,000) for an Individual Retirement Account. An additional 100 Units were purchased by the Corporate General Partner.


The offering terminated on December 15, 1982.  Upon termination of the offering, the Partnership had accepted subscriptions for 50,000 Units, including 100 Units purchased by the Corporate General Partner, for an aggregate of $50,000,000. The Partnership invested approximately $38,000,000 of such proceeds in five existing apartment properties. Since its initial offering, the Partnership has not received, nor are limited partners required to make, additional capital contributions.


The Partnership is engaged in the business of operating and holding real estate properties for investment. In 1982 and 1983, during its acquisition phase, the Partnership acquired five existing apartment properties. The Partnership continues to own and operate two of these properties. See "Item 2. Description of Properties".


The Partnership has no employees. Management and administrative services are performed by the Corporate General Partner and by agents retained by the Corporate General Partner.  An affiliate of the Corporate General Partner has been providing such property management services.





Risk Factors


The real estate business in which the Partnership is engaged is highly competitive. There are other residential properties within the market area of the Partnership's properties. The number and quality of competitive properties, including those which may be managed by an affiliate of the Corporate General Partner in such market area, could have a material effect on the rental market for the apartments at the Partnership's properties and the rents that may be charged for such apartments. While the Corporate General Partner and its affiliates are a significant factor in the United States in the apartment industry, they own an insignificant percentage of total apartment units in the United States and competition for apartments is local.


Laws benefiting disabled persons may result in the Partnership's incurrence of unanticipated expenses. Under the Americans with Disabilities Act of 1990, or ADA, all places intended to be used by the public are required to meet certain Federal requirements related to access and use by disabled persons. Likewise, the Fair Housing Amendments Act of 1988, or FHAA, requires apartment properties first occupied after March 13, 1990 to be accessible to the handicapped.  These and other Federal, state and local laws may require modifications to the Partnership's properties, or restrict renovations of the properties.  Noncompliance with these laws could result in the imposition of fines or an award of damages to private litigants and also could result in an order to correct any non-complying feature, which could result in substantial capital expenditures. Although the Corporate General Partner believes that the Partnership's properties are substantially in compliance with the present requirements, the Partnership may incur unanticipated expenses to comply with the ADA and the FHAA.


Both the income and expenses of operating the properties owned by the Partnership are subject to factors outside of the Partnership's control, such as changes in the supply and demand for similar properties resulting from various market conditions, increases/decreases in unemployment or population shifts, changes in the availability of permanent mortgage financing, changes in zoning laws, or changes in patterns or needs of users. In addition, there are risks inherent in owning and operating residential properties because such properties are susceptible to the impact of economic and other conditions outside of the control of the Partnership.


From time to time, the Federal Bureau of Investigation, or FBI, and the United States Department of Homeland Security issue alerts regarding potential terrorist threats involving apartment buildings. Threats of future terrorist attacks, such as those announced by the FBI and the Department of Homeland Security, could have a negative effect on rent and occupancy levels at the Partnership’s properties. The effect that future terrorist activities or threats of such activities could have on the Partnership’s operations is uncertain and unpredictable. If the Partnership were to incur a loss at a property as a result of an act of terrorism, the Partnership could lose all or a portion of the capital invested in the property, as well as the future revenue from the property.


There have been, and it is possible there may be other, Federal, state and local legislation and regulations enacted relating to the protection of the environment. The Partnership is unable to predict the extent, if any, to which such new legislation or regulations might occur and the degree to which such existing or new legislation or regulations might adversely affect the properties owned by the Partnership.


The Partnership monitors its properties for evidence of pollutants, toxins and other dangerous substances, including the presence of asbestos. In certain cases environmental testing has been performed, which resulted in no material adverse conditions or liabilities. In no case has the Partnership received notice that it is a potentially responsible party with respect to an environmental clean up site.


A further description of the Partnership's business is included in "Management's Discussion and Analysis or Plan of Operation" included in "Item 6" of this Form 10-KSB.


Item 2.

Description of Properties


The following table sets forth the Partnership's investments in properties:


 

Date of

  

Property

Purchase

Type of Ownership

Use

    

Baymeadows Apartments

9/30/82

Fee ownership subject

Apartment

  Jacksonville, Florida

 

to first mortgage

904 units

    

Quail Run Apartments

1/03/83

Fee ownership subject

Apartment

  Columbia, South Carolina

 

to first mortgage (1)

332 units


(1)

Property is held by a Limited Partnership in which the Partnership owns a 99.99% interest.


Schedule of Properties


Set forth below for each of the Partnership's properties is the gross carrying value, accumulated depreciation, depreciable life, method of depreciation and Federal tax basis.


 

Gross

    
 

Carrying

Accumulated

Depreciable

Method of

Federal

Property

Value

Depreciation

Life

Depreciation

Tax Basis

 

(in thousands)

  

(in thousands)

      

Baymeadows Apartments

     

 Apartments

$56,743

$29,988

5-36 yrs

S/L

$20,254

Quail Run Apartments

     

 Apartments

 15,353

 10,404

5-34 yrs

S/L

  1,947

      

Total

$72,096

$40,392

  

$22,201


See "Note A – Organization and Significant Accounting Policies" to the financial statements included in "Item 7. Financial Statements" for a description of the Partnership's depreciation and capitalization policies.


Schedule of Property Indebtedness


The following table sets forth certain information relating to the loans encumbering the Partnership's properties.


 

Principal

   

Principal

 

Balance At

Stated

  

Balance

 

December 31,

Interest

Period

Maturity

Due At

Property

2005

Rate(1)

Amortized

Date

Maturity (2)

 

(in thousands)

   

(in thousands)

Baymeadows

     

 1st mortgage

$40,000

4.87%

(3)

9/05/12

$33,624

      

Quail Run

     

  1st mortgage

  7,696

6.94%

240 mo.

07/01/22

     --

Total

$47,696

   

$33,624


(1)

Fixed rate mortgages.


(2)

See "Item 7, Financial Statements - Note B" for information with respect to the Partnership's ability to prepay these loans and other specific details about the loans.


(3)

See paragraph below.


On August 22, 2005, the Partnership obtained an additional mortgage from a new lender in the principal amount of approximately $15,917,000 on one of its investment properties, Baymeadows Apartments. The additional mortgage loan agreement requires monthly payments of interest only beginning on October 5, 2005 until September 5, 2007, with the interest rate being 4.87%.  From October 5, 2007 through September 5, 2012, the Loan Agreement requires monthly payments of principal and interest calculated using a 300 month loan amortization period. If the Property completes the required rehabilitation work within 36 months of the date of the loan agreement and the property achieves gross rental income of at least $8,724,000 from not more than 95% of the units within 36 months, then the installments for the remaining period of the loan will be calculated using a 360 month amortization period. If the above two requirements are not met within 36 months, then the installments for the remaining period of the loan will be calculated using a 240 month amortization period.  The mortgage matures on September 5, 2012 at which time the unpaid principal amount and any interest accrued but remaining unpaid becomes due.


The existing lender assigned the existing mortgage note of approximately $24,083,000 to the holder of the additional mortgage note.  The terms of the existing mortgage note were modified to match the terms for the additional mortgage note and the two loans were then combined into one mortgage note issued by the new lender for $40,000,000.  During the year ended December 31, 2005, the Partnership recognized a loss on early extinguishment of debt of approximately $304,000 due to the write off of unamortized loan costs on the original loan and a prepayment penalty paid to the original lender.    Total capitalized loan costs for the additional mortgage were approximately $863,000.


Rental Rates and Occupancy


Average annual rental rates and occupancy for the years ended December 31, 2005 and 2004:


 

Average Annual

Average Annual

 

Rental Rates

Occupancy

 

(per unit)

 

Property

2005

2004

2005

2004

Baymeadows (1)

$9,416

$8,743

75%

93%

Quail Run (2)

 7,909

 7,848

94%

87%


(1)

The Corporate General Partner attributes the decrease in occupancy at Baymeadows Apartments to the redevelopment of the property that has resulted in 111 units being unavailable for rent at December 31, 2005.


(2)

The Corporate General Partner attributes the increase in occupancy at Quail Run Apartments to improvements made at the property and increased advertising.


As noted under "Item 1. Description of Business", the real estate industry is highly competitive. Both properties are subject to competition from other residential apartment complexes in the area. The Corporate General Partner believes that the properties are adequately insured. Each property is an apartment complex which leases units for lease terms of one year or less.  No tenant leases 10% or more of the available rental space. Quail Run Apartments is in good condition subject to normal depreciation and deterioration as is typical for assets of this type and age. See capital improvements below for discussion of Baymeadows Apartments.


Real Estate Taxes and Rates


Real estate taxes and rates in 2005 for each property were:


 

2005

2005

 

Billing

Rate

 

(in thousands)

 

Baymeadows

$ 578

   1.48%

Quail Run

  254

34.44% (a)


(a)

The rates are based on the local authority's assessed value of the investment property.


Capital Improvements


Baymeadows Apartments


During the year ended December 31, 2005, the Partnership completed approximately $13,449,000 of capital improvements at Baymeadows Apartments arising from the redevelopment and new construction of the property, which includes capitalization of construction period  interest costs of approximately $284,000, capitalized tax and insurance expenses of approximately $84,000 and other construction period operating costs of approximately $51,000 for the year ended December 31, 2005. Approximately 111 units were in redevelopment and not in service at December 31, 2005. Additional capital improvements of approximately $304,000 were also completed which consisted primarily of electrical upgrades, and water heater, appliance, floor covering and air conditioning unit replacements. These improvements were funded from operating cash flow, advances from an affiliate of the Corporate General Partner and refinancing proceeds. The Partnership regularly evaluates the capital improvement needs of the property.  The property is currently undergoing a redevelopment project in order to become more competitive with other properties in the area in an effort to increase occupancy at the property. Based on current redevelopment plans, the Corporate General Partner anticipates the redevelopment to be completed in December 2006 at a total estimated cost of approximately $32,425,000 of which approximately $13,195,000 was completed as of December 31, 2005.  The project is being funded by refinance proceeds and advances from an affiliate of the Corporate General Partner. In addition, a project was approved during the year ended December 31, 2005 to add 288 new apartment units at the property. The Corporate General Partner anticipates the construction to begin during 2006 and to be completed during 2008 at a total estimated cost of approximately $26,953,000 of which approximately $254,000 was completed as of December 31, 2005. The balance of the costs associated with the redevelopment are expected to be funded from operating cash flow, the remaining refinance proceeds and advances from affiliates of the Corporate General Partner. In addition to the redevelopment project and the new construction, certain routine capital expenditures are anticipated during 2006. Such capital expenditures will depend on the physical condition of the property as well as replacement reserves and anticipated cash flow generated by the property.


Quail Run Apartments


During the year ended December 31, 2005, the Partnership completed approximately $195,000 in capital expenditures at Quail Run Apartments, consisting primarily of structural upgrades, parking area resurfacing, recreational facility upgrades, floor covering, air conditioning unit, and appliance replacements. These improvements were funded from operating cash flow. The Partnership regularly evaluates the capital improvement needs of the property.  While the Partnership has no material commitments for property improvements and replacements, certain routine capital expenditures are anticipated during 2006.  Such capital expenditures will depend on the physical condition of the property as well as the anticipated cash flow generated by the property. The Partnership has entered into a contract with a third party to sell the property during the first quarter of 2006.


Capital expenditures will be incurred only if cash is available from operations, advances from an affiliate of the Corporate General Partner,  or from Partnership reserves.  To the extent that capital improvements are completed, the Partnership's distributable cash flow, if any, may be adversely affected at least in the short term.


Item 3.

Legal Proceedings


In March 1998, several putative unit holders of limited partnership units of the Partnership commenced an action entitled Rosalie Nuanes, et al. v. Insignia Financial Group, Inc., et al. (the "Nuanes action") in the Superior Court of the State of California for the County of San Mateo. The plaintiffs named as defendants, among others, the Partnership, its Corporate General Partner and several of their affiliated partnerships and corporate entities. The action purported to assert claims on behalf of a class of limited partners and derivatively on behalf of a number of limited partnerships (including the Partnership) that are named as nominal defendants, challenging, among other things, the acquisition of interests in certain Corporate General Partner entities by Insignia Financial Group, Inc. ("Insignia") and entities that were, at one time, affiliates of Insignia; past tender offers by the Insignia affiliates to acquire limited partnership units; management of the partnerships by the Insignia affiliates; and the series of transactions which closed on October 1, 1998 and February 26, 1999 whereby Insignia and Insignia Properties Trust, respectively, were merged into AIMCO. The plaintiffs sought monetary damages and equitable relief, including judicial dissolution of the Partnership. In addition, during the third quarter of 2001, a complaint captioned Heller v. Insignia Financial Group (the "Heller action") was filed against the same defendants that are named in the Nuanes action. On or about August 6, 2001, plaintiffs filed a first amended complaint. The Heller action was brought as a purported derivative action, and asserted claims for, among other things, breach of fiduciary duty, unfair competition, conversion, unjust enrichment, and judicial dissolution. On January 28, 2002, the trial court granted defendants motion to strike the complaint.  Plaintiffs took an appeal from this order.


On January 8, 2003, the parties filed a Stipulation of Settlement in proposed settlement of the Nuanes action and the Heller action. On June 13, 2003, the court granted final approval of the settlement and entered judgment in both the Nuanes and Heller actions. On August 12, 2003, an objector ("Objector") filed an appeal (the “Appeal”) seeking to vacate and/or reverse the order approving the settlement and entering judgment thereto. On May 4, 2004, the Objector filed a second appeal challenging the court’s use of a referee and its order requiring Objector to pay those fees.


On March 21, 2005, the Court of Appeals issued opinions in both pending appeals.  With regard to the settlement and judgment entered thereto, the Court of Appeals vacated the trial court’s order and remanded to the trial court for further findings on the basis that the “state of the record is insufficient to permit meaningful appellate review”.  The matter was transferred back to the trial court on June 21, 2005.  With regard to the second appeal, the Court of Appeals reversed the order requiring the Objector to pay referee fees. With respect to the related Heller appeal, on July 28, 2005, the Court of Appeals reversed the trial court’s order striking the first amended complaint.


On August 18, 2005, Objector and his counsel filed a motion to disqualify the trial court based on a peremptory challenge and filed a motion to disqualify for cause on October 17, 2005, both of which were ultimately denied and/or struck by the trial court.  On or about October 13, 2005 Objector filed a motion to intervene and on or about October 19, 2005 filed both a motion to take discovery relating to the adequacy of plaintiffs as derivative representatives and a motion to dissolve the anti-suit injunction in connection with settlement.  On November 14, 2005, Plaintiffs filed a Motion For Further Findings pursuant to the remand ordered by the Court of Appeals. Defendants joined in that motion.  On February 3, 2006, the Court held a hearing on the various matters pending before it and has ordered additional briefing from the parties and Objector.  


The Corporate General Partner does not anticipate that any costs to the Partnership, whether legal or settlement costs, associated with these cases will be material to the Partnership’s overall operations.


AIMCO Properties L.P. and NHP Management Company, both affiliates of the Corporate General Partner, are defendants in a lawsuit alleging that they willfully violated the Fair Labor Standards Act (“FLSA”) by failing to pay maintenance workers overtime for all hours worked in excess of forty per week. The complaint, filed in the United States District Court for the District of Columbia, attempts to bring a collective action under the FLSA and seeks to certify state subclasses in California, Maryland, and the District of Columbia. Specifically, the plaintiffs contend that AIMCO Properties L.P. and NHP Management Company failed to compensate maintenance workers for time that they were required to be "on-call". Additionally, the complaint alleges AIMCO Properties L.P. and NHP Management Company failed to comply with the FLSA in compensating maintenance workers for time that they worked in excess of 40 hours in a week.   In June 2005 the Court conditionally certified the collective action on both the on-call and overtime issues, which allows the plaintiffs to provide notice of the collective action to all non-exempt maintenance workers from August 7, 2000 through the present.  Notices have been sent out to all current and former hourly maintenance workers. The opt-in period has not yet closed. Defendants will have the opportunity to opt-in to the collective action, and AIMCO Properties, L.P. and NHP Management Company will have the opportunity to move to decertify the collective action.  Because the court denied plaintiffs’ motion to certify state subclasses, on September 26, 2005, the plaintiffs filed a class action with the same allegations in the Superior Court of California (Contra Costa County) and on November 5, 2005 in Montgomery County Maryland Circuit Court.  Although the outcome of any litigation is uncertain, AIMCO Properties, L.P. does not believe that the ultimate outcome will have a material adverse effect on its consolidated financial condition or results of operations. Similarly, the Corporate General Partner does not believe that the ultimate outcome will have a material adverse effect on the Partnership’s consolidated financial condition or results of operations.


The Partnership has an ongoing dispute with a general contractor and its subcontractors formerly involved in the redevelopment project at Baymeadows Apartments. The contractor and its subcontractors have filed liens against the property for amounts held back by the Partnership due to the contractor’s deficient performance. The Corporate General Partner is investigating a claim for liquidated damages under the contract against the contractor due to its delayed performance. The Partnership has recorded an accrual as of December 31, 2005 based upon an estimate of costs to be incurred. The Corporate General Partner does not believe that the ultimate outcome will have a material adverse effect on the Partnership’s consolidated financial condition or results of operations.


Item 4.

Submission of Matters to a Vote of Security Holders


During the quarter ended December 31, 2005, no matter was submitted to a vote of unit holders through the solicitation of proxies or otherwise.


PART II


Item 5.

Market for Partnership Equity and Related Partner Matters


The Partnership, a publicly-held limited partnership, offered and sold 49,900 limited partnership units (the “Units”) aggregating $49,900,000.  An additional 100 units were purchased by the Corporate General Partner. The Partnership currently has 1,557 holders of record owning an aggregate of 49,995 Units. Affiliates of the Corporate General Partner owned 36,381 units or 72.77% at December 31, 2005. No public trading market has developed for the Units, and it is not anticipated that such a market will develop in the future.


The following table sets forth the distributions made by the Partnership for the year ended December 31, 2005 and 2004 (in thousands, except per unit data).


  

Per Limited

 

Per Limited

 

Year Ended

Partnership

Year Ended

Partnership

 

December 31, 2005

Unit

December 31, 2004

Unit

     

Operations

$  150

$ 2.96

$ 1,765

$ 34.94


Future cash distributions will depend on the levels of cash generated from operations, the availability of cash reserves and the timing of debt maturities, property sales and/or refinancings. The Partnership’s cash available for distribution is reviewed on a monthly basis. Given the substantial redevelopment projects ongoing at Baymeadows Apartments it is not expected that the Partnership will generate sufficient funds from operations, after required capital expenditures, to permit additional distributions to its partners in 2006 or subsequent periods. See “Item 2. Description of Properties – Capital Improvements” for information relating to anticipated capital expenditures at the properties.


In addition to its indirect ownership of the general partner interest in the Partnership, AIMCO and its affiliates owned 36,381 Units in the Partnership representing 72.77% of the outstanding Units at December 31, 2005. A number of these Units were acquired pursuant to tender offers made by AIMCO or its affiliates. It is possible that AIMCO or its affiliates will acquire additional Units in exchange for cash or a combination of cash and units in AIMCO Properties, L.P., the operating partnership of AIMCO, either through private purchases or tender offers. Pursuant to the Partnership Agreement, unitholders holding a majority of the Units are entitled to take action with respect to a variety of matters that include, but are not limited to, voting on certain amendments to the Partnership Agreement and voting to remove the Corporate General Partner. As a result of its ownership of 72.77% of the outstanding Units, AIMCO and its affiliates are in a position to control all such voting decisions with respect to the Partnership. Although the Corporate General Partner owes fiduciary duties to the limited partners of the Partnership, the Corporate General Partner also owes fiduciary duties to AIMCO as its sole stockholder. As a result, the duties of the Corporate General Partner, as corporate general partner, to the Partnership and its limited partners may come into conflict with the duties of the Corporate General Partner to AIMCO as its sole stockholder.


Item 6.

Management's Discussion and Analysis or Plan of Operation


This item should be read in conjunction with the consolidated financial statements and other items contained elsewhere in this report.


The Partnership’s financial results depend upon a number of factors including the ability to attract and maintain tenants at the investment properties, interest rates on mortgage loans, costs incurred to operate the investment properties, general economic conditions and weather. As part of the ongoing business plan of the Partnership, the Corporate General Partner monitors the rental market environment of its investment properties to assess the feasibility of increasing rents, maintaining or increasing occupancy levels and protecting the Partnership from increases in expenses. As part of this plan, the Corporate General Partner attempts to protect the Partnership from the burden of inflation-related increases in expenses by increasing rents and maintaining a high overall occupancy level. However, the Corporate General Partner may use rental concessions and rental rate reductions to offset softening market conditions, accordingly, there is no guarantee that the Corporate General Partner will be able to sustain such a plan. Further, a number of factors that are outside the control of the Partnership, such as the local economic climate and weather can adversely or positively affect the Partnership’s financial results.


Results of Operations


The Partnership’s net loss for the year ended December 31, 2005 was approximately $561,000, compared to net income of approximately $1,230,000 for the year ended December 31, 2004. The decrease in net income for the year ended December 31, 2005 was due to a decrease in total revenues and an increase in total expenses. Total revenues decreased due to decreases in rental income and other income.  Rental income decreased due to a decrease in occupancy at Baymeadows, partially offset by an increase in occupancy at Quail Run Apartments, a decrease in bad debt expense and collection at both investment properties and an increase in the average rental rate at both investment properties.  Other income decreased due to decreases in utility reimbursements, lease cancellation fees, late charges, and an increase in appliance rental fees expense at Baymeadows Apartments.


Total expenses increased due to increases in depreciation, interest, property tax and general and administrative expenses, and the recognition of loss on early extinguishment of debt (as discussed in “Liquidity and Capital Resources”). Operating expense remained relatively constant for the year ended December 31, 2005 as decreases in contract labor and supplies and property management fees at Baymeadows Apartments and an increase in capitalized construction period operating cost were partially offset by increases in advertising, payroll and related costs and utilities at Baymeadows Apartments, and property management fees at Quail Run Apartments as a result of the increase in rental income. Depreciation expense increased due to property improvements and replacements placed into service during the past twelve months at the investment properties.  Interest expense increased due to an increase in the variable rate on the mortgage at Baymeadows Apartments and due to the refinancing of the mortgage at Baymeadows Apartments, which resulted in a higher principle balance, partially offset by capitalized interest associated with the redevelopment at Baymeadows Apartments.  Property tax expense increased at Baymeadows Apartments due to an increase in the assessed value of the property, partially offset by capitalized taxes associated with the redevelopment project at Baymeadows Apartments.  


In September 2004, Baymeadows Apartments experienced damage from hurricanes Frances and Jeanne.  At December 31, 2004, the Partnership estimated total damage costs from the hurricanes of approximately $51,000, which were not covered by insurance proceeds and were included in operating expenses for the year ended December 31, 2004.  During 2004, the Partnership recognized a casualty loss of approximately $6,000 and during the year 2005 the Partnership recognized an additional casualty loss of approximately $1,000 as a result of the write-off of undepreciated damaged assets.  These losses are included in operating expense.  In addition to the damages, the Partnership incurred additional clean up costs of approximately $46,000 during the year ended December 31, 2005 for hurricanes Frances and Jeanne, which were not covered by insurance proceeds, and these costs are included in operating expense.


General and administrative expenses increased for the year ended December 31, 2005 due to an increase in the cost of services included in the management reimbursements charged by the Corporate General Partner as allowed under the Partnership Agreement. Also included in general and administrative expenses are costs associated with the quarterly and annual communications with investors and regulatory agencies and the annual audit required by the Partnership Agreement.


Liquidity and Capital Resources


At December 31, 2005, the Partnership had cash and cash equivalents of approximately $5,911,000 compared to approximately $505,000 at December 31, 2004. Cash and cash equivalents increased approximately $5,406,000 since December 31, 2004 due to approximately $14,267,000 and $2,671,000 of cash provided by financing and operating activities respectively, partially offset by approximately $11,532,000 of cash used in investing activities. Cash provided by financing activities consisted of advances received from an affiliate and proceeds from mortgage note payable partially offset by repayment of the mortgage note payable on Baymeadows Apartments, debt extinguishment costs, loan costs paid, principal payments on the mortgages encumbering the Partnership’s properties, repayment of advances from affiliates, and distributions to the partners. Cash used in investing activities consisted of property improvements and replacements partially offset by withdrawals from restricted escrows. The Partnership invests its working capital reserves in interest bearing accounts.


The sufficiency of existing liquid assets to meet future liquidity and capital expenditure requirements is directly related to the level of capital expenditures required at the properties to adequately maintain the physical assets and other operating needs of the Partnership and to comply with Federal, state, and local legal and regulatory requirements. The Corporate General Partner monitors developments in the area of legal and regulatory compliance. For example, the Sarbanes-Oxley Act of 2002 mandates or suggests additional compliance measures with regard to governance, disclosure, audit and other areas. In light of these changes, the Partnership expects that it will incur higher expenses related to compliance. The Partnership regularly evaluates the capital improvement needs of the properties.  The Partnership currently expects to budget approximately $18,800,000 for 2006 related to the redevelopment and new construction projects at Baymeadows Apartments. While the Partnership has no other material commitments for property improvements and replacements, certain routine capital expenditures are anticipated during 2006.  Such capital expenditures will depend on the physical condition of the properties as well as replacement reserves, anticipated cash flow generated by the properties and advances from an affiliate of the Corporate General Partner.  Capital expenditures will be incurred only if cash is available from operations or from Partnership reserves.  To the extent that capital improvements are completed, the Partnership's distributable cash flow, if any, may be adversely affected at least in the short term.


The Partnership’s assets are thought to be generally sufficient for any near-term needs (exclusive of capital improvements and the redevelopment projects) of the Partnership. The mortgage indebtedness of Quail Run Apartments of approximately $7,696,000 is being amortized over 240 months at which time it is scheduled to be fully amortized.


On August 22, 2005, the Partnership obtained an additional mortgage from a new lender in the principal amount of approximately $15,917,000 on one of its investment properties, Baymeadows Apartments. The additional mortgage loan agreement requires monthly payments of interest only beginning on October 5, 2005 until September 5, 2007, with the interest rate being 4.87%.  From October 5, 2007 through September 5, 2012, the Loan Agreement requires monthly payments of principal and interest calculated using a 300 month loan amortization period. If the Property completes the rehabilitation work within 36 months of the date of the loan agreement and the property achieves gross rental income of at least $8,724,000 from not more than 95% of the units within 36 months, then the installments for the remaining period of the loan will be calculated using a 360 month amortization period. If the above two requirements are not met within 36 months, then the installments for the remaining period of the loan will be calculated using a 240 month amortization period.  The mortgage matures on September 5, 2012 at which time the unpaid principal amount and any interest accrued but remaining unpaid becomes due.


The following table sets forth the distributions made by the Partnership for the years ended December 31, 2005 and 2004 (in thousands, except per unit data).


  

Per Limited

 

Per Limited

 

Year Ended

Partnership

Year Ended

Partnership

 

December 31, 2005

Unit

December 31, 2004

Unit

     

Operations

$  150

$ 2.96

$ 1,765

$ 34.94


Future cash distributions will depend on the levels of cash generated from operations, the availability of cash reserves and the timing of debt maturities, property sales and/or refinancings. The Partnership’s cash available for distribution is reviewed on a monthly basis. Given the substantial redevelopment projects ongoing at Baymeadows Apartments it is not expected that the Partnership will generate sufficient funds from operations, after required capital expenditures, to permit additional distributions to its partners in 2006 or subsequent periods.


In addition to its indirect ownership of the general partner interest in the Partnership, AIMCO and its affiliates owned 36,381 limited partnership units (the “Units”) in the Partnership representing 72.77% of the outstanding Units at December 31, 2005. A number of these Units were acquired pursuant to tender offers made by AIMCO or its affiliates. It is possible that AIMCO or its affiliates will acquire additional Units in exchange for cash or a combination of cash and units in AIMCO Properties, L.P., the operating partnership of AIMCO, either through private purchases or tender offers. Pursuant to the Partnership Agreement, unitholders holding a majority of the Units are entitled to take action with respect to a variety of matters that include, but are not limited to, voting on certain amendments to the Partnership Agreement and voting to remove the Corporate General Partner. As a result of its ownership of 72.77% of the outstanding Units, AIMCO and its affiliates are in a position to control all such voting decisions with respect to the Partnership. Although the Corporate General Partner owes fiduciary duties to the limited partners of the Partnership, the Corporate General Partner also owes fiduciary duties to AIMCO as its sole stockholder. As a result, the duties of the Corporate General Partner, as corporate general partner, to the Partnership and its limited partners may come into conflict with the duties of the Corporate General Partner to AIMCO as its sole stockholder.


Critical Accounting Policies and Estimates


A summary of the Partnership’s significant accounting policies is included in "Note A – Organization and Significant Accounting Policies" which is included in the consolidated financial statements in "Item 7. Financial Statements".  The Corporate General Partner believes that the consistent application of these policies enables the Partnership to provide readers of the financial statements with useful and reliable information about the Partnership’s operating results and financial condition.  The preparation of consolidated financial statements in conformity with accounting principles generally accepted in the United States requires the Partnership to make estimates and assumptions. These estimates and assumptions affect the reported amounts of assets and liabilities at the date of the financial statements as well as reported amounts of revenues and expenses during the reporting period.  Actual results could differ from these estimates.  Judgments and assessments of uncertainties are required in applying the Partnership’s accounting policies in many areas. The following may involve a higher degree of judgment and complexity.


Impairment of Long-Lived Assets


Investment properties are recorded at cost, less accumulated depreciation, unless the carrying amount of the asset is not recoverable.  If events or circumstances indicate that the carrying amount of a property may not be recoverable, the Partnership will make an assessment of its recoverability by comparing the carrying amount to the Partnership’s estimate of the undiscounted future cash flows, excluding interest charges, of the property.   If the carrying amount exceeds the aggregate undiscounted future cash flows, the Partnership would recognize an impairment loss to the extent the carrying amount exceeds the estimated fair value of the property.


Real property investment is subject to varying degrees of risk.  Several factors may adversely affect the economic performance and value of the Partnership’s investment properties.  These factors include, but are not limited to, general economic climate; competition from other apartment communities and other housing options; local conditions, such as loss of jobs or an increase in the supply of apartments that might adversely affect apartment occupancy or rental rates; changes in governmental regulations and the related cost of compliance; increases in operating costs (including real estate taxes) due to inflation and other factors, which may not be offset by increased rents; and changes in tax laws and housing laws, including the enactment of rent control laws or other laws regulating multi-family housing.  Any adverse changes in these factors could cause impairment of the Partnership’s assets.


Capitalized Costs Related to Redevelopment and Construction Projects


The Partnership capitalizes costs incurred in connection with capital expenditure activities, including redevelopment and construction projects. Costs associated with redevelopment projects are capitalized in accordance with Statement of Financial Accounting Standard (“SFAS”) No. 67, “Accounting for Costs and the Initial Rental Operations of Real Estate Properties.” Included in these capitalized costs are payroll costs associated with time spent by site employees in connection with the planning, execution and control of all capital expenditure activities at the property level.  The Partnership capitalizes interest, property taxes and operating costs in accordance with SFAS No. 34 “Capitalization of Interest Costs” during periods in which redevelopment and construction projects are in progress.


Revenue Recognition


The Partnership generally leases apartment units for twelve-month terms or less.  The Partnership will offer rental concessions during particularly slow months or in response to heavy competition from other similar complexes in the area.  Rental income attributable to leases, net of any concessions, is recognized on a straight-line basis over the term of the lease.  The Partnership evaluates all accounts receivable from residents and establishes an allowance, after the application of security deposits, for accounts greater than 30 days past due on current tenants and all receivables due from former tenants.


Item 7.

Financial Statements



SHELTER PROPERTIES IV




LIST OF FINANCIAL STATEMENTS


Report of Independent Registered Public Accounting Firm


Consolidated Balance Sheet - December 31, 2005


Consolidated Statements of Operations - Years ended December 31, 2005 and 2004


Consolidated Statements of Changes in Partners' Capital (Deficiency) - Years ended December 31, 2005 and 2004


Consolidated Statements of Cash Flows - Years ended December 31, 2005 and 2004


Notes to Consolidated Financial Statements







Report of Independent Registered Public Accounting Firm



The Partners

Shelter Properties IV



We have audited the accompanying consolidated balance sheet of Shelter Properties IV as of December 31, 2005, and the related consolidated statements of operations, changes in partners' capital (deficiency), and cash flows for each of the two years in the period ended December 31, 2005. These financial statements are the responsibility of the Partnership's management. Our responsibility is to express an opinion on these financial statements based on our audits.


We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement.  We were not engaged to perform an audit of the Partnership’s internal control over financial reporting.  Our audits included consideration of internal control over financial reporting as a basis for designing audit procedures that are appropriate in the circumstances, but not for the purpose of expressing an opinion on the effectiveness of the Partnership’s internal control over financial reporting. Accordingly, we express no such opinion. An audit also includes examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements, assessing the accounting principles used and significant estimates made by management, and evaluating the overall financial statement presentation. We believe that our audits provide a reasonable basis for our opinion.


In our opinion, the financial statements referred to above present fairly, in all material respects, the consolidated financial position of Shelter Properties IV at December 31, 2005, and the consolidated results of its operations and its cash flows for each of the two years in the period ended December 31, 2005, in conformity with U.S. generally accepted accounting principles.




/s/ERNST & YOUNG LLP



Greenville, South Carolina

March 6, 2006








SHELTER PROPERTIES IV

 

CONSOLIDATED BALANCE SHEET

(in thousands, except unit data)

 

December 31, 2005




Assets

  

Cash and cash equivalents

 

$  5,911

Receivables and deposits

 

     366

Other assets

 

   1,193

Investment properties (Notes B and F):

  

Land

$  2,759

 

Buildings and related personal property

  69,337

 
 

  72,096

 

Less accumulated depreciation

  (40,392)

  31,704

   
  

$ 39,174

   

Liabilities and Partners' Capital (Deficiency)

  

Liabilities

  

Accounts payable

 

$  2,342

Tenant security deposit liabilities

 

     119

Accrued property taxes

 

      45

Other liabilities

 

     604

Mortgage notes payable (Note B)

 

  47,696

   

Partners' Capital (Deficiency)

  

General partners

$     91

 

Limited partners (49,995 units issued and

  

outstanding)

  (11,723)

  (11,632)

   
  

$ 39,174




See Accompanying Notes to Consolidated Financial Statements












SHELTER PROPERTIES IV

 

CONSOLIDATED STATEMENTS OF OPERATIONS

(in thousands, except per unit data)



 

Years Ended December 31,

 

2005

2004

Revenues:

  

Rental income

$  8,622

$  9,355

Other income

     885

     928

Total revenues

   9,507

  10,283

   

Expenses:

  

Operating

   4,507

   4,518

General and administrative

     289

     255

Depreciation

   2,441

   2,309

Interest

   1,771

   1,284

Property taxes

     756

     687

Loss on extinguishment of debt (Note B)

     304

      --

Total expenses

  10,068

   9,053

   

Net (loss) income (Note C)

 $   (561)

$  1,230

   

Net (loss) income allocated to general partners (1%)

 $     (6)

$     12

Net (loss) income allocated to limited partners (99%)

     (555)

   1,218

   
 

 $   (561)

$  1,230

   

Net (loss) income per limited partnership unit

 $ (11.10)

$  24.36

   

Distributions per limited partnership unit

$   2.96

$  34.94




See Accompanying Notes to Consolidated Financial Statements










SHELTER PROPERTIES IV

 

CONSOLIDATED STATEMENTS OF CHANGES IN PARTNERS' CAPITAL (DEFICIENCY)

(in thousands, except unit data)




 

Limited

   
 

Partnership

General

Limited

 
 

Units

Partners

Partners

Total

     

Original capital contributions

50,000

$     2

$ 50,000

$ 50,002

     

Partners' capital (deficiency)

    

  at December 31, 2003

49,995

$   105

 $(10,491)

 $(10,386)

     

Distributions to partners

    --

     (18)

   (1,747)

   (1,765)

     

Net income for the year ended

    

  December 31, 2004

    --

     12

   1,218

   1,230

     

Partners' capital (deficiency)

    

  at December 31, 2004

49,995

     99

  (11,020)

  (10,921)

     

Distributions to partners

    --

      (2)

     (148)

     (150)

     

Net loss for the year ended

    

  December 31, 2005

    --

      (6)

     (555)

     (561)

     

Partners' capital (deficiency)

    

  at December 31, 2005

49,995

$    91

 $(11,723)

 $(11,632)




See Accompanying Notes to Consolidated Financial Statements












SHELTER PROPERTIES IV

 

CONSOLIDATED STATEMENTS OF CASH FLOWS

(in thousands)


 

Years Ended December 31,

 

2005

2004

Cash flows from operating activities:

  

Net (loss) income

 $   (561)

$  1,230

Adjustments to reconcile net (loss) income to net

  

cash provided by operating activities:

  

Depreciation

   2,441

   2,309

Bad debt expense

     195

     241

Casualty loss

       1

       6

Loss on early extinguishment of debt

     304

      --

Amortization of loan costs

     141

     147

Change in accounts:

  

Receivables and deposits

      (99)

     (373)

Other assets

      97

      (92)

Accounts payable

      53

      (86)

Tenant security deposit liabilities

      (58)

      (66)

Accrued property taxes

      45

     (240)

Other liabilities

     112

      18

Net cash provided by operating activities

   2,671

   3,094

Cash flows from investing activities:

  

Property improvements and replacements

  (11,762)

   (1,135)

Net withdrawals from restricted escrows

     230

       5

Net cash used in investing activities

  (11,532)

   (1,130)

Cash flows from financing activities:

  

Proceeds from mortgage note payable

  40,000

      --

Repayments of mortgage note payable

  (24,083)

      --

Debt extinguishment costs

      (23)

      --

Payments on mortgage notes payable

     (614)

     (853)

Distributions to partners

     (150)

   (1,765)

Advances from affiliate

   2,413

      --

Repayment of advances from affiliates

   (2,413)

      --

Loan costs paid

     (863)

      --

Net provided by (used in) financing activities

  14,267

   (2,618)

Net increase (decrease) in cash and cash equivalents

   5,406

     (654)

Cash and cash equivalents at beginning of year

     505

   1,159

Cash and cash equivalents at end of year

$  5,911

$    505

Supplemental disclosure of cash flow information:

  

Cash paid for interest

$  1,645

$  1,184

Supplemental disclosure of non-cash activity:

  

Property improvements and replacements in accounts

  

  payable

$  2,215

$     29




See Accompanying Notes to Consolidated Financial Statements












SHELTER PROPERTIES IV

 

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

 

DECEMBER 31, 2005



Note A - Organization and Significant Accounting Policies


Organization: Shelter Properties IV (the "Partnership" or "Registrant") was organized as a limited partnership under the laws of the State of South Carolina on August 21, 1981. The general partner responsible for management of the Partnership's business is Shelter Realty IV Corporation, a South Carolina corporation (the "Corporate General Partner"). The Corporate General Partner is a subsidiary of Apartment Investment and Management Company ("AIMCO"), a publicly traded real estate investment trust. The other general partner is AIMCO Properties, L.P., an affiliate of the Corporate General Partner and AIMCO. The Partnership Agreement provides that the Partnership is to terminate on December 31, 2022 unless terminated prior to such date. The Partnership commenced operations on July 22, 1982, and completed its acquisition of apartment properties on March 31, 1983.  The Partnership operates two apartment properties located in the Southeast.


Basis of Presentation:  Certain 2004 balances have been reclassified to conform with the 2005 presentation.


Principles of Consolidation: The financial statements include all the accounts of the Partnership and its 99.99% owned partnership. The General Partner of the consolidated partnership is the Corporate General Partner. The Corporate General Partner may be removed by the Partnership; therefore, the consolidated partnership is controlled and consolidated by the Partnership. All significant interpartnership balances have been eliminated.


Deferred Costs: Loan costs of approximately $1,067,000 less accumulated amortization of approximately $76,000 are included in other assets on the accompanying consolidated balance sheet. The loan costs are amortized over the terms of the related loan agreements. The total amortization expense for the years ended December 31, 2005 and 2004 was approximately $141,000 and $147,000, respectively, and is included in interest expense. Amortization expense is expected to be approximately $134,000 for the years 2006 through 2010.


Leasing commissions and other direct costs incurred in connection with successful leasing efforts are deferred and amortized over the terms of the related leases.  Amortization of these costs is included in operating expenses.


Use of Estimates: The preparation of consolidated financial statements in conformity with accounting principles generally accepted in the United States requires management to make estimates and assumptions that affect the amounts reported in the financial statements and accompanying notes. Actual results could differ from those estimates.


Allocation of Cash Distributions: Cash distributions by the Partnership are allocated between general and limited partners in accordance with the provisions of the Partnership Agreement. The Partnership Agreement provides that net cash from operations means revenue received less operating expenses paid, adjusted for certain specified items which primarily include mortgage payments on debt, property improvements and replacements not previously reserved, and the effects of other adjustments to reserves including reserve amounts deemed necessary by the Corporate General Partner. In the following notes to financial statements, whenever net cash from operations is used, it has the aforementioned meaning. As required by the Partnership Agreement, the following is a reconciliation of "net cash provided by operating activities" in the accompanying consolidated statements of cash flows to "net cash from operations", as defined in the Partnership Agreement. However, "net cash from operations" should not be considered an alternative to net income as an indicator of the Partnership's operating performance or to cash flows as a measure of liquidity.


 

Years Ended December 31,

 

2005

2004

 

(in thousands)

Net cash provided by operating activities

$  2,671

$ 3,094

Property improvements and replacements

  (11,762)

  (1,135)

Payments on mortgage notes payable

     (614)

    (853)

Changes in restricted escrows, net

     230

      5

Changes in reserves for net operating

  

  Liabilities

     (345)

    598

Additional reserves

      --

  (1,709)

   

Net cash used in operations

$ (9,820)

$    --


For the year ended December 31, 2004, the Corporate General Partner reserved approximately $1,709,000 to fund capital improvements and repairs at the Partnership’s properties.

 

Distributions made from reserves no longer considered necessary by the Corporate General Partner are considered to be additional net cash from operations for allocation purposes.


The Partnership Agreement provides that 99% of distributions of net cash from operations are allocated to the limited partners until they receive net cash from operations for such fiscal year equal to 7% of their adjusted capital values (as defined in the Partnership Agreement), at which point the general partners will be allocated all net cash from operations until they have received distributions equal to 10% of the aggregate net cash from operations distributed to partners for such fiscal year. Thereafter, the general partners will be allocated 10% of any distributions of remaining net cash from operations for such fiscal year.


All distributions of distributable net proceeds (as defined in the Partnership Agreement) from property dispositions and refinancings will be allocated to the limited partners until each limited partner has received an amount equal to a cumulative 7% per annum of the average of the limited partners' adjusted capital value, less any prior distributions of net cash from operations and distributable net proceeds, and has also received an amount equal to the limited partners' adjusted capital value.  Thereafter, the general partners receive 1% of the selling price of properties sold where they acted as a broker, and then the limited partners will be allocated 85% of any remaining distributions of distributable net proceeds and the general partners will receive 15%.


Allocation of Profits, Gains, and Losses: Profits, gains and losses of the Partnership are allocated between general and limited partners in accordance with the provisions of the Partnership Agreement.


Profits, not including gains from property dispositions, are allocated as if they were distributions of net cash from operations.


Any gain from property dispositions attributable to the excess, if any, of the indebtedness relating to a property immediately prior to the disposition of such property over the Partnership's adjusted basis in the property shall be allocated to each partner having a negative capital account balance, to the extent of such negative balance. The balance of any gain shall be treated on a cumulative basis as if it constituted an equivalent amount of distributable net proceeds and shall be allocated to the general partners to the extent that general partners would have received distributable net proceeds in connection therewith; the balance shall be allocated to the limited partners.  However, the interest of the general partners will be equal to at least 1% of each gain at all times during the existence of the Partnership.


All losses, including losses attributable to property dispositions, are allocated 99% to the limited partners and 1% to the general partners. Accordingly, net income as shown in the consolidated statements of operations and consolidated changes in partners' capital (deficiency) for both of the years ended December 31, 2005 and 2004 were allocated 99% to the limited partners and 1% to the general partners. Net income per limited partnership unit for each such year was computed as 99% of net income divided by 49,995 units outstanding.


Other Reserves: The Corporate General Partner may designate a portion of cash generated from operations as "other reserves" in determining net cash from operations. The Corporate General Partner designated as other reserves an amount equal to the net liabilities related to the operations of apartment properties during the current fiscal year that are expected to require the use of cash during the next fiscal year. The changes in other reserves during the years ended December 31, 2005 and 2004 were a decrease of approximately $345,000 and an increase of approximately $598,000, respectively. These amounts were determined by considering changes in the balances of receivables and deposits, other assets, accounts payable, tenant security deposit liabilities, accrued taxes and other liabilities. At this time, the Corporate General Partner expects to continue to adjust other reserves based on the net change in the aforementioned account balances.


Fair Value of Financial Instruments: Statement of Financial Accounting Standards ("SFAS") No. 107, "Disclosures about Fair Value of Financial Instruments", as amended by SFAS No. 119, "Disclosures about Derivative Financial Instruments and Fair Value of Financial Instruments", requires disclosure of fair value information about financial instruments, whether or not recognized in the balance sheet, for which it is practicable to estimate fair value.  Fair value is defined in the SFAS as the amount at which the instruments could be exchanged in a current transaction between willing parties, other than in a forced or liquidation sale. The Partnership believes that the carrying amounts of its financial instruments (except for long term debt) approximate their fair values due to the short term maturity of these instruments. The Partnership estimates the fair value of its long-term debt by discounting future cash flows using a discount rate commensurate with that currently believed to be available to the Partnership for similar term, fully amortizing long-term debt. The fair value of the Partnership's long term debt approximates its carrying balance.


Cash and Cash Equivalents: Cash and cash equivalents include cash on hand and in banks. At certain times, the amount of cash deposited at a bank may exceed the limit on insured deposits. Cash balances include approximately $5,883,000 at December 31, 2005 that are maintained by an affiliated management company on behalf of affiliated entities in cash concentration accounts.


Depreciation: Depreciation is provided by the straight-line method over the estimated lives of the apartment properties and related personal property. For Federal income tax purposes, the accelerated cost recovery method is used for real property over 19 years for additions after May 8, 1985, and before January 1, 1987. As a result of the Tax Reform Act of 1986, for additions after December 31, 1986, the modified accelerated cost recovery method is used for depreciation of (1) real property over 27 1/2 years and (2) personal property additions over 5 years.


Tenant Security Deposits: The Partnership requires security deposits from lessees for the duration of the lease and such deposits are included in receivables and deposits. Deposits are refunded when the tenant vacates, provided the tenant has not damaged its space and is current on its rental payments.


Leases: The Partnership generally leases apartment units for twelve-month terms or less.  The Partnership will offer rental concessions during particularly slow months or in response to heavy competition from other similar complexes in the area.  Rental income attributable to leases, net of any concessions, is recognized on a straight-line basis over the term of the lease.  The Partnership evaluates all accounts receivable from residents and establishes an allowance, after the application of security deposits, for accounts greater than 30 days past due on current tenants and all receivables due from former tenants.


Leasing commissions and other direct costs incurred in connection with successful leasing efforts are deferred and amortized over the terms of the related leases.  Amortization of these costs is included in operating expenses.


Investment Properties: Investment properties consist of two apartment complexes and are stated at cost.  The Partnership capitalizes costs incurred in connection with capital expenditure activities, including redevelopment and construction projects, other tangible property improvements and replacements of existing property components.  Costs associated with redevelopment projects are capitalized in accordance with Statement of Financial Accounting Standard (“SFAS”) No. 67, “Accounting for Costs and the Initial Rental Operations of Real Estate Properties.”  Costs incurred in connection with capital projects are capitalized where the costs of the project exceed $250.  Included in these capitalized costs are payroll costs associated with time spent by site employees in connection with the planning, execution and control of all capital expenditure activities at the property level.  The Partnership capitalizes interest, property taxes and operating costs in accordance with SFAS No. 34 “Capitalization of Interest Costs” during periods in which redevelopment and construction projects are in progress.  During the years ended December 31, 2005 and 2004, the Partnership capitalized interest of approximately $284,000 and $11,000, property taxes of approximately $84,000 and $3,000, and operating costs of approximately $51,000 and $14,000. Capitalized costs are depreciated over the useful life of the asset.  Expenditures for ordinary repairs, maintenance and apartment turnover costs are expensed as incurred.


In accordance with SFAS No. 144, “Accounting for the Impairment or Disposal of Long-Lived Assets”, the Partnership records impairment losses on long-lived assets used in operations when events and circumstances indicate the assets might be impaired and the undiscounted cash flows estimated to be generated by those assets are less than the carrying amounts of those assets.  No adjustments for impairment of value were necessary for the years ending December 31, 2005 and 2004.


Advertising: The Partnership expenses the costs of advertising as incurred. Advertising costs were approximately $155,000 and $131,000 for the years ended December 31, 2005 and 2004, respectively.

 

 

Segment Reporting: SFAS No. 131, "Disclosure about Segments of an Enterprise and Related Information" established standards for the way that public business enterprises report information about operating segments in annual financial statements and requires that those enterprises report selected information about operating segments in interim financial reports. SFAS No. 131 also established standards for related disclosures about products and services, geographic areas, and major customers. As defined in SFAS No. 131, the Partnership has only one reportable segment.


Recent Accounting Pronouncement:  In May 2005, the Financial Accounting Standards Board issued SFAS No. 154 “Accounting Changes and Error Corrections, which replaces APB Opinion No. 20 and SFAS No. 3, and changes the requirements for the accounting for and reporting of a change in accounting principle. This statement is effective for accounting changes and corrections of errors made in fiscal years beginning after December 15, 2005, although early adoption is permitted for accounting changes and corrections of errors made in fiscal years beginning after the date SFAS No. 154 was issued. The Partnership does not anticipate that the adoption of SFAS No. 154 will have a material effect on the Partnership’s consolidated financial condition or results of operations.


Note B - Mortgage Notes Payable


The principal terms of mortgage notes payable are as follows:


 

Principal

Monthly

  

Principal

 

Balance At

Payment

Stated

 

Balance

 

December 31,

Including

Interest

Maturity

Due At

Property

2005

Interest

Rate (1)

Date

Maturity

 

(in thousands)

  

(in thousands)

Baymeadows

     

  1st mortgage

$40,000

$ 162

4.87%

09/05/12

$33,624

      

Quail Run

     

  1st mortgage

  7,696

   65

6.94%

07/01/22

     --

Total

$47,696

$ 227

  

$33,624


(1)

Fixed rate mortgages.


On August 22, 2005, the Partnership obtained an additional mortgage from a new lender in the principal amount of approximately $15,917,000 on one of its investment properties, Baymeadows Apartments. The additional mortgage loan agreement requires monthly payments of interest only beginning on October 5, 2005 until September 5, 2007, with the interest rate being 4.87%. From October 5, 2007 through September 5, 2012, the Loan Agreement requires monthly payments of principal and interest calculated using a 300 month loan amortization period. If the Property completes the required rehabilitation work within 36 months of the date of the loan agreement and the property achieves gross rental income of at least $8,724,000 from not more than 95% of the units within 36 months, then the installments for the remaining period of the loan will be calculated using a 360 month amortization period. If the above two requirements are not met within 36 months, then the installments for the remaining period of the loan will be calculated using a 240 month amortization period.  The mortgage matures on September 5, 2012 at which time the unpaid principal amount and any interest accrued but remaining unpaid becomes due.


The existing lender assigned the existing mortgage note of approximately $24,083,000 to the holder of the additional mortgage note.  The terms of the existing mortgage note were modified to match the terms for the additional mortgage note and the two loans were then combined into one mortgage note issued by the new lender for $40,000,000.  During the year ended December 31, 2005, the Partnership recognized a loss on early extinguishment of debt of approximately $304,000 due to the write off of unamortized loan costs on the original loan and a prepayment penalty paid to the original lender.    Total capitalized loan costs for the additional mortgage were approximately $863,000.


The mortgage notes payable are non-recourse and are secured by a pledge of the respective apartment properties and revenues generated by the properties. A prepayment penalty is required on the mortgage encumbering Quail Run Apartments if repaid prior to maturity. Further, the properties may not be sold subject to existing indebtedness.


Scheduled principal payments of mortgage notes payable subsequent to December 31, 2005 are as follows (in thousands):


2006

$   256

2007

    481

2008

  1,244

2009

  1,616

2010

  1,703

Thereafter

 42,396

Total

$47,696

Note C - Income Taxes


The Partnership has received a ruling from the Internal Revenue Service that it will be classified as a partnership for Federal income tax purposes.  Accordingly, no provision for income taxes is made in the consolidated financial statements of the Partnership. Taxable income or loss of the Partnership is reported in the income tax returns of its partners.


The following is a reconciliation of reported net (loss) income and Federal taxable (loss) income (in thousands, except per unit data):


 

Years Ended December 31,

 

2005

2004

   

Net (loss) income as reported

 $  (561)

$ 1,230

Add (deduct):

  

  Casualty

     --

      7

  Depreciation differences

    342

  1,009

  Change in prepaid rental

     11

     (53)

  Other

    (114)

    (239)

   

Federal taxable (loss) income

 $  (322)

$ 1,954

   

Federal taxable (loss) income per

  

limited partnership unit

 $ (6.37)

$ 38.70


The following is a reconciliation between the Partnership's reported amounts and Federal tax basis of net liabilities (in thousands):


Net liabilities as reported

 $(11,632)

Land and buildings

   7,000

Accumulated depreciation

  (16,503)

Syndication

   6,293

Other

     641

  

Net liabilities – Federal tax basis

 $(14,201)


Note D - Transactions with Affiliated Parties


The Partnership has no employees and depends on the Corporate General Partner and its affiliates for the management and administration of all Partnership activities. The Partnership Agreement provides for (i) certain payments to affiliates for services and (ii) reimbursement of certain expenses incurred by affiliates on behalf of the Partnership.


Affiliates of the Corporate General Partner receive 5% of gross receipts from both of the Partnership's properties as compensation for providing property management services. The Partnership paid to such affiliates approximately $469,000 and $504,000 during the years ended December 31, 2005 and 2004, respectively, which are included in operating expenses.


An affiliate of the Corporate General Partner received reimbursement of accountable administrative expenses amounting to approximately $250,000 and $255,000 for the years ended December 31, 2005 and 2004, respectively, which are included in general and administrative expenses and investment properties.  The portion of these reimbursements included in investment properties for the years ended December 31, 2005 and 2004 are fees related to construction management services provided by an affiliate of the Corporate General Partner of approximately $23,000 and $42,000, respectively.  


Pursuant to the Partnership Agreement and in connection with the refinance of Baymeadows Apartments in August 2005, the Corporate General Partner was paid a refinance fee of 1% of the new mortgage amount or $400,000 for its assistance in arranging the new loan.   This cost was capitalized and included in other assets on the consolidated balance sheet.


Pursuant to the Partnership Agreement and in connection with the sale of Countrywood Village in August of 2000, the Corporate General Partner is entitled to a commission of up to 1% for its assistance in the sale. Payment of such commission is subordinate to the limited partners receiving a cumulative 7% return on their investment. This return has not yet been met, and accordingly, the commission of $178,000 was accrued and is included in other liabilities in the accompanying consolidated balance sheet at December 31, 2005.


Pursuant to the Partnership Agreement, during the year ended December 31, 2005, an affiliate of the Corporate General Partner advanced the Partnership approximately $2,413,000 to fund the redevelopment at Baymeadows Apartments and to pay mortgage refinance fees at Baymeadows Apartments. Interest was charged at the prime rate plus 2%, and was approximately $27,000 for the year ended December 31, 2005. There were no such advances made during the year ended December 31, 2004. The Partnership repaid approximately $2,440,000 of advances and associated interest during the year ended December 31, 2005 from the proceeds from the refinance of Baymeadows Apartments (see “Note B”).


The Partnership insures its properties up to certain limits through coverage provided by AIMCO which is generally self-insured for a portion of losses and liabilities related to workers compensation, property casualty, general liability and vehicle liability. The Partnership insures its properties above the AIMCO limits through insurance policies obtained by AIMCO from insurers unaffiliated with the Corporate General Partner. During the years ended December 31, 2005 and 2004, the Partnership was charged by AIMCO and its affiliates approximately $166,000 and $159,000, respectively, for insurance coverage and fees associated with policy claims administration.


In addition to its indirect ownership of the general partner interest in the Partnership, AIMCO and its affiliates owned 36,381 limited partnership units (the “Units”) in the Partnership representing 72.77% of the outstanding Units at December 31, 2005. A number of these Units were acquired pursuant to tender offers made by AIMCO or its affiliates. It is possible that AIMCO or its affiliates will acquire additional Units in exchange for cash or a combination of cash and units in AIMCO Properties, L.P., the operating partnership of AIMCO, either through private purchases or tender offers. Pursuant to the Partnership Agreement, unitholders holding a majority of the Units are entitled to take action with respect to a variety of matters that include, but are not limited to, voting on certain amendments to the Partnership Agreement and voting to remove the Corporate General Partner. As a result of its ownership of 72.77% of the outstanding Units, AIMCO and its affiliates are in a position to control all such voting decisions with respect to the Partnership. Although the Corporate General Partner owes fiduciary duties to the limited partners of the Partnership, the Corporate General Partner also owes fiduciary duties to AIMCO as its sole stockholder. As a result, the duties of the Corporate General Partner, as corporate general partner, to the Partnership and its limited partners may come into conflict with the duties of the Corporate General Partner to AIMCO as its sole stockholder.


Note E - Casualty


In September 2004, Baymeadows Apartments experienced damage from hurricanes Frances and Jeanne.  At December 31, 2004, the Partnership estimated total damage costs from the hurricanes of approximately $51,000, which were not covered by insurance proceeds and were included in operating expenses for the year ended December 31, 2004.  During 2004, the Partnership recognized a casualty loss of approximately $6,000 and during the year 2005 the Partnership recognized an additional casualty loss of approximately $1,000 as a result of the write-off of undepreciated damaged assets.  This loss is included in operating expense.  In addition to the damages, the Partnership incurred additional clean up costs of approximately $46,000 during the year ended December 31, 2005 for hurricanes Frances and Jeanne, which were not covered by insurance proceeds, and these costs are included in operating expenses.


Note F – Investment Properties and Accumulated Depreciation


     
  

Initial Cost

 
  

To Partnership

 
  

(in thousands)

 
     
   

Buildings

Cost

   

and Related

Capitalized

   

Personal

Subsequent to

Description

Encumbrances

Land

Property

Acquisition

 

(in thousands)

  

(in thousands)

     

Baymeadows Apartments

$40,000

$ 1,884

$26,916

$27,943

Quail Run Apartments

  7,696

    875

 10,642

  3,836

     

Totals

$47,696

$ 2,759

$37,558

$31,779



 

Gross Amount At Which Carried

   
 

At December 31, 2005

   
 

(in thousands)

   
       
  

Buildings

    
  

And Related

    
  

Personal

 

Accumulated

Date

Depreciable

Description

Land

Property

Total

Depreciation

Acquired

Life-Years

    

(in thousands)

  

Baymeadows Apartments

$ 1,884

$54,859

$56,743

$29,988

09/30/82

5-36

Quail Run Apartments

    875

 14,478

 15,353

 10,404

01/03/83

5-34

       

Totals

$ 2,759

$69,337

$72,096

$40,392

  


One of the Partnership’s investment properties, Baymeadows Apartments, is currently under redevelopment.  Based on current redevelopment plans, the Corporate General Partner anticipates the redevelopment to be completed in the December 2006 at a total estimated cost of approximately $32,425,000 of which approximately $13,195,000 was completed as of December 31, 2005.  Included in these construction costs are capitalized interest costs of approximately $284,000 and $11,000, capitalized tax and insurance expenses of approximately $84,000 and $3,000, and other construction period operating costs of approximately $51,000 and $14,000 for the years ended December 31, 2005 and 2004, respectively. The project is being funded from refinance proceeds and it is expected that the redevelopment will continued to be funded by refinance proceeds and advances from an affiliate of the Corporate General Partner.


In addition, a project was approved during the year ended December 31, 2005 to add 288 new apartment units at the property. The Corporate General Partner anticipates the construction to begin during 2006 and to be completed during 2008 at a total estimated cost of approximately $26,953,000 of which approximately $254,000 was completed as of December 31, 2005. It is expected that the new construction will be funded by operating cash flow and advances from an affiliate of the Corporate General Partner.


Reconciliation of "Investment Properties and Accumulated Depreciation":


 

Years Ended December 31,

 

2005

2004

 

(in thousands)

Investment Properties

  

Balance at beginning of year

$ 58,151

$ 57,005

  Property improvements

  13,948

   1,164

  Disposition of assets

       (3)

      (18)

Balance at end of year

$ 72,096

$ 58,151

   

Accumulated Depreciation

  

Balance at beginning of year

$ 37,953

$ 35,656

  Additions charged to expense

   2,441

   2,309

  Disposition of assets

       (2)

      (12)

Balance at end of year

$ 40,392

$ 37,953


The aggregate cost of the investment properties for Federal income tax purposes at December 31, 2005 and 2004 is approximately $79,096,000 and $65,805,000, respectively. The accumulated depreciation taken for Federal income tax purposes at December 31, 2005 and 2004 is approximately $56,895,000 and $55,151,000, respectively.


Note G - Contingencies


In March 1998, several putative unit holders of limited partnership units of the Partnership commenced an action entitled Rosalie Nuanes, et al. v. Insignia Financial Group, Inc., et al. (the "Nuanes action") in the Superior Court of the State of California for the County of San Mateo. The plaintiffs named as defendants, among others, the Partnership, its Corporate General Partner and several of their affiliated partnerships and corporate entities. The action purported to assert claims on behalf of a class of limited partners and derivatively on behalf of a number of limited partnerships (including the Partnership) that are named as nominal defendants, challenging, among other things, the acquisition of interests in certain Corporate General Partner entities by Insignia Financial Group, Inc. ("Insignia") and entities that were, at one time, affiliates of Insignia; past tender offers by the Insignia affiliates to acquire limited partnership units; management of the partnerships by the Insignia affiliates; and the series of transactions which closed on October 1, 1998 and February 26, 1999 whereby Insignia and Insignia Properties Trust, respectively, were merged into AIMCO. The plaintiffs sought monetary damages and equitable relief, including judicial dissolution of the Partnership. In addition, during the third quarter of 2001, a complaint captioned Heller v. Insignia Financial Group (the "Heller action") was filed against the same defendants that are named in the Nuanes action. On or about August 6, 2001, plaintiffs filed a first amended complaint. The Heller action was brought as a purported derivative action, and asserted claims for, among other things, breach of fiduciary duty, unfair competition, conversion, unjust enrichment, and judicial dissolution. On January 28, 2002, the trial court granted defendants motion to strike the complaint.  Plaintiffs took an appeal from this order.


On January 8, 2003, the parties filed a Stipulation of Settlement in proposed settlement of the Nuanes action and the Heller action. On June 13, 2003, the court granted final approval of the settlement and entered judgment in both the Nuanes and Heller actions. On August 12, 2003, an objector ("Objector") filed an appeal (the “Appeal”) seeking to vacate and/or reverse the order approving the settlement and entering judgment thereto. On May 4, 2004, the Objector filed a second appeal challenging the court’s use of a referee and its order requiring Objector to pay those fees.


On March 21, 2005, the Court of Appeals issued opinions in both pending appeals.  With regard to the settlement and judgment entered thereto, the Court of Appeals vacated the trial court’s order and remanded to the trial court for further findings on the basis that the “state of the record is insufficient to permit meaningful appellate review”.  The matter was transferred back to the trial court on June 21, 2005.  With regard to the second appeal, the Court of Appeals reversed the order requiring the Objector to pay referee fees. With respect to the related Heller appeal, on July 28, 2005, the Court of Appeals reversed the trial court’s order striking the first amended complaint.


On August 18, 2005, Objector and his counsel filed a motion to disqualify the trial court based on a peremptory challenge and filed a motion to disqualify for cause on October 17, 2005, both of which were ultimately denied and/or struck by the trial court.  On or about October 13, 2005 Objector filed a motion to intervene and on or about October 19, 2005 filed both a motion to take discovery relating to the adequacy of plaintiffs as derivative representatives and a motion to dissolve the anti-suit injunction in connection with settlement.  On November 14, 2005, Plaintiffs filed a Motion For Further Findings pursuant to the remand ordered by the Court of Appeals. Defendants joined in that motion.  On February 3, 2006, the Court held a hearing on the various matters pending before it and has ordered additional briefing from the parties and Objector.  


The Corporate General Partner does not anticipate that any costs to the Partnership, whether legal or settlement costs, associated with these cases will be material to the Partnership’s overall operations.


AIMCO Properties L.P. and NHP Management Company, both affiliates of the Corporate General Partner, are defendants in a lawsuit alleging that they willfully violated the Fair Labor Standards Act (“FLSA”) by failing to pay maintenance workers overtime for all hours worked in excess of forty per week. The complaint, filed in the United States District Court for the District of Columbia, attempts to bring a collective action under the FLSA and seeks to certify state subclasses in California, Maryland, and the District of Columbia. Specifically, the plaintiffs contend that AIMCO Properties L.P. and NHP Management Company failed to compensate maintenance workers for time that they were required to be "on-call". Additionally, the complaint alleges AIMCO Properties L.P. and NHP Management Company failed to comply with the FLSA in compensating maintenance workers for time that they worked in excess of 40 hours in a week.   In June 2005 the Court conditionally certified the collective action on both the on-call and overtime issues, which allows the plaintiffs to provide notice of the collective action to all non-exempt maintenance workers from August 7, 2000 through the present.  Notices have been sent out to all current and former hourly maintenance workers. The opt-in period has not yet closed. Defendants will have the opportunity to move to decertify the collective action.  Because the court denied plaintiffs’ motion to certify state subclasses, on September 26, 2005, the plaintiffs filed a class action with the same allegations in the Superior Court of California (Contra Costa County), and on November 5, 2005 in Montgomery Country Maryland Circuit Court.  Although the outcome of any litigation is uncertain, AIMCO Properties, L.P. does not believe that the ultimate outcome will have a material adverse effect on its consolidated financial condition or results of operations. Similarly, the Managing General Partner does not believe that the ultimate outcome will have a material adverse effect on the Partnership’s consolidated financial condition or results of operations.


The Partnership has an ongoing dispute with a general contractor and its subcontractors formerly involved in the redevelopment project at Baymeadows Apartments. The contractor and its subcontractors have filed liens against the property for amounts held back by the Partnership due to the contractor’s deficient performance. The Corporate General Partner is investigating a claim for liquidated damages under the contract against the contractor due to its delayed performance. The Partnership has recorded an accrual as of December 31, 2005 based upon an estimate of costs to be incurred. The Corporate General Partner does not believe that the ultimate outcome will have a material adverse effect on the Partnership’s consolidated financial condition or results of operations.


The Partnership is unaware of any other pending or outstanding litigation matters involving it or its investment properties that are not of a routine nature arising in the ordinary course of business.


Environmental


Various Federal, state and local laws subject property owners or operators to liability for management, and the costs of removal or remediation, of certain hazardous substances present on a property. Such laws often impose liability without regard to whether the owner or operator knew of, or was responsible for, the release or presence of the hazardous substances. The presence of, or the failure to manage or remedy properly, hazardous substances may adversely affect occupancy at affected apartment communities and the ability to sell or finance affected properties. In addition to the costs associated with investigation and remediation actions brought by government agencies and potential fines or penalties imposed by such agencies in connection therewith, the presence of hazardous substances on a property could result in claims by private plaintiffs for personal injury, disease, disability or other infirmities. Various laws also impose liability for the cost of removal, remediation or disposal of hazardous substances through a licensed disposal or treatment facility. Anyone who arranges for the disposal or treatment of hazardous substances is potentially liable under such laws. These laws often impose liability whether or not the person arranging for the disposal ever owned or operated the disposal facility. In connection with the ownership, operation and management of its properties, the Partnership could potentially be liable for environmental liabilities or costs associated with its properties.  


Mold


The Partnership is aware of lawsuits against owners and managers of multifamily properties asserting claims of personal injury and property damage caused by the presence of mold, some of which have resulted in substantial monetary judgments or settlements.  The Partnership has only limited insurance coverage for property damage loss claims arising from the presence of mold and for personal injury claims related to mold exposure.  Affiliates of the Corporate General Partner have implemented a national policy and procedures to prevent or eliminate mold from its properties and the Corporate General Partner believes that these measures will minimize the effects that mold could have on residents.  To date, the Partnership has not incurred any material costs or liabilities relating to claims of mold exposure or to abate mold conditions.  Because the law regarding mold is unsettled and subject to change the Corporate General Partner can make no assurance that liabilities resulting from the presence of or exposure to mold will not have a material adverse effect on the Partnership’s consolidated financial condition or results of operations.


SEC Investigation


On December 19, 2005, AIMCO announced that the Central Regional Office of the Securities and Exchange Commission (the “Commission”) has informed AIMCO that its investigation has been recommended for termination and no enforcement action has been recommended to the Commission regarding AIMCO.


Note H – Subsequent Event


Subsequent to December 31, 2005, the Partnership entered into a Purchase and Sale Contract to sell Quail Run Apartments to a third party for a purchase price of approximately $14,439,000. The anticipated closing date for the transaction is March 31, 2006. The Partnership determined that certain criteria of SFAS No. 144 were not met at December 31, 2005 and therefore continues to report the assets and liabilities of Quail Run Apartments as held for investment and the operations of Quail Run Apartments as continuing operations. At December 31, 2005, the carrying amounts of the mortgage note payable and investment property for Quail Run Apartments are approximately $7,696,000 and $4,949,000, respectively. The operating results of Quail Run Apartments for the years ended December 31, 2005 and 2004 were losses of approximately $101,000 and $159,000, respectively, which included revenues of approximately $2,667,000 and $2,453,000, respectively.









Item 8.

Changes in and Disagreements with Accountants on Accounting and

Financial Disclosure


None.


Item 8a.

Controls and Procedures


(a)

Disclosure Controls and Procedures. The Partnership’s management, with the participation of the principal executive officer and principal financial officer of the Corporate General Partner, who are the equivalent of the Partnership’s principal executive officer and principal financial officer, respectively, has evaluated the effectiveness of the Partnership’s disclosure controls and procedures (as such term is defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934, as amended (the “Exchange Act”)) as of the end of the period covered by this report. Based on such evaluation, the principal executive officer and principal financial officer of the Corporate General Partner, who are the equivalent of the Partnership’s principal executive officer and principal financial officer, respectively, have concluded that, as of the end of such period, the Partnership’s disclosure controls and procedures are effective.


(b)

Internal Control Over Financial Reporting. There have not been any changes in the Partnership’s internal control over financial reporting (as such term is defined in Rules 13a-15(f) and 15d-15(f) under the Exchange Act) during the fourth quarter of 2005 that have materially affected, or are reasonably likely to materially affect, the Partnership’s internal control over financial reporting.


Item 8b.

Other Information


None.









PART III



Item 9.

Directors, Executive Officers, Promoters and Control Persons, Compliance with Section 16(a) of the Exchange Act


The Partnership has no directors or officers. The Corporate General Partner is Shelter Realty IV Corporation.  The names and ages of, as well as the position and offices held by, the present director and officers of the Corporate General Partner are set forth below. There are no family relationships between or among any directors or officers.


Name

Age

Position

   

Martha L. Long

46

Director and Senior Vice President

Harry G. Alcock

43

Director and Executive Vice President

Miles Cortez

62

Executive Vice President, General Counsel

  

  and Secretary

Patti K. Fielding

42

Executive Vice President

Thomas M. Herzog

43

Executive Vice President and Chief

  

  Financial Officer

Robert Y. Walker, IV

40

Senior Vice President and Chief Accounting

  

  Officer

Stephen B. Waters

44

Vice President


Martha L. Long has been a Director and Senior Vice President of the Corporate General Partner since February 2004. Ms. Long has been with AIMCO since October 1998 and has served in various capacities.  From 1998 to 2001, Ms. Long served as Senior Vice President and Controller of AIMCO and the Corporate General Partner.  During 2002 and 2003, Ms. Long served as Senior Vice President of Continuous Improvement for AIMCO.


Harry G. Alcock was appointed as a Director of the Corporate General Partner in October 2004 and was appointed Executive Vice President of the Corporate General Partner in February 2004 and has been Executive Vice President and Chief Investment Officer of AIMCO since October 1999.  Mr. Alcock has had responsibility for acquisition and financing activities of AIMCO since July 1994, serving as Vice President from July 1996 to October 1997 and as a Senior Vice President from October 1997 to October 1999.


Miles Cortez was appointed Executive Vice President, General Counsel and Secretary of the Corporate General Partner in February 2004 and of AIMCO in August 2001.  Prior to joining AIMCO, Mr. Cortez was the senior partner of Cortez Macaulay Bernhardt & Schuetze LLC, a Denver law firm, from December 1997 through September 2001.


Patti K. Fielding was appointed Executive Vice President - Securities and Debt of the Corporate General Partner in February 2004 and of AIMCO in February 2003.  Ms. Fielding was appointed Treasurer of AIMCO in January 2005.  Ms. Fielding is responsible for debt financing and the treasury department.  Ms. Fielding previously served as Senior Vice President - Securities and Debt of AIMCO from January 2000 to February 2003.  Ms. Fielding joined AIMCO in February 1997 as a Vice President.


Thomas M. Herzog was appointed Chief Financial Officer of the Corporate General Partner and AIMCO in November 2005 and was appointed Executive Vice President of the Corporate General Partner and AIMCO in July 2005.  In January 2004, Mr. Herzog joined AIMCO as Senior Vice President and Chief Accounting Officer and of the Corporate General Partner in February 2004.  Prior to joining AIMCO in January 2004, Mr. Herzog was at GE Real Estate, serving as Chief Accounting Officer & Global Controller from April 2002 to January 2004 and as Chief Technical Advisor from March 2000 to April 2002.  Prior to joining GE Real Estate, Mr. Herzog was at Deloitte & Touche LLP from 1990 to 2000.


Robert Y. Walker, IV was appointed Senior Vice President of the Corporate General Partner and AIMCO in August 2005 and became the Chief Accounting Officer of the Corporate General Partner and AIMCO in November 2005.  From June 2002, until he joined AIMCO, Mr. Walker served as senior vice president and chief financial officer at Miller Global Properties, LLC, a Denver-based private equity, real estate fund manager.  From May 1997 to June 2002, Mr. Walker was employed by GE Capital Real Estate, serving as global controller from May 2000 to June 2002.


Stephen B. Waters was appointed Vice President of the Corporate General Partner in April 2004.  Mr. Waters previously served as a Director of Real Estate Accounting since joining AIMCO in September 1999.  Mr. Waters has responsibility for partnership accounting with AIMCO.


One or more of the above persons are also directors and/or officers of a general partner (or general partner of a general partner) of limited partnerships which either have a class of securities registered pursuant to Section 12(g) of the Securities Exchange Act of 1934, or are subject to the reporting requirements of Section 15(d) of such Act. Further, one or more of the above persons are also officers of Apartment Investment and Management Company and the general partner of AIMCO Properties, L.P., entities that have a class of securities registered pursuant to Section 12(g) of the Securities Exchange Act of 1934, or are subject to the reporting requirements of Section 15 (d) of such Act.


The board of directors of the Corporate General Partner does not have a separate audit committee. As such, the board of directors of the Corporate General Partner fulfills the functions of an audit committee. The board of directors has determined that Martha L. Long meets the requirement of an "audit committee financial expert".


The directors and officers of the Corporate General Partner with authority over the Partnership are all employees of subsidiaries of AIMCO. AIMCO has adopted a code of ethics that applies to such directors and officers that is posted on AIMCO's website (www.AIMCO.com). AIMCO's website is not incorporated by reference to this filing.


Item 10.

Executive Compensation


None of the directors and officers of the Corporate General Partner received any remuneration from the Partnership during the year ended December 31, 2005.


Item 11.

Security Ownership of Certain Beneficial Owners and Management


Except as noted below, no person or entity was known by the Partnership to be the beneficial owner of more than 5% of the Limited Partnership Units of the Partnership as of December 31, 2005.


Entity

Number of Units

Percentage

Cooper River Properties, LLC

  

  (an affiliate of AIMCO)

 3,685

 7.37%

AIMCO IPLP, L.P.

  

  (an affiliate of AIMCO)

16,052

32.11%

AIMCO Properties, L.P.

  

  (an affiliate of AIMCO)

16,644

33.29%


Cooper River Properties, LLC and AIMCO IPLP, L.P. are indirectly ultimately owned by AIMCO. Their business addresses are 55 Beattie Place, Greenville, South Carolina 29602.


AIMCO Properties, L.P. is indirectly ultimately owned by AIMCO. Its business address is 4582 S. Ulster St. Parkway, Suite 1100, Denver, Colorado 80237.


No director or officer of the Corporate General Partner owns any Units. The Corporate General Partner owns 100 Units as required by the terms of the Partnership Agreement governing the Partnership.


Item 12.

Certain Relationships and Related Transactions


The Partnership has no employees and depends on the Corporate General Partner and its affiliates for the management and administration of all Partnership activities. The Partnership Agreement provides for (i) certain payments to affiliates for services and (ii) reimbursement of certain expenses incurred by affiliates on behalf of the Partnership.


Affiliates of the Corporate General Partner receive 5% of gross receipts from both of the Partnership's properties as compensation for providing property management services. The Partnership paid to such affiliates approximately $469,000 and $504,000 during the years ended December 31, 2005 and 2004, respectively, which is included in operating expenses.


An affiliate of the Corporate General Partner received reimbursement of accountable administrative expenses amounting to approximately $250,000 and $255,000 for the years ended December 31, 2005 and 2004, respectively, which is included in general and administrative expenses and investment properties.  The portion of these reimbursements included in investment properties for the years ended December 31, 2005 and 2004 are fees related to construction management services provided by an affiliate of the Corporate General Partner of approximately $23,000 and $42,000, respectively.  


Pursuant to the Partnership Agreement and in connection with the sale of Countrywood Village in August of 2000, the Corporate General Partner is entitled to a commission of up to 1% for its assistance in the sale. Payment of such commission is subordinate to the limited partners receiving a cumulative 7% return on their investment. This return has not yet been met, and accordingly, the commission of $178,000 was accrued and is included in other liabilities in the accompanying consolidated balance sheet at December 31, 2005.


Pursuant to the Partnership Agreement and in connection with the refinance of Baymeadows Apartments in August 2005, the Corporate General Partner was paid a refinance fee of 1% of the new mortgage amount or $400,000 for its assistance in arranging the new loan.   This cost was capitalized and included in other assets on the consolidated balance sheet.


Pursuant to the Partnership Agreement, during the year ended December 31, 2005, an affiliate of the Corporate General Partner advanced the Partnership approximately $2,413,000 to fund the redevelopment at Baymeadows Apartments and to pay mortgage refinance fees at Baymeadows Apartments. Interest was charged at the prime rate plus 2%, and was approximately $27,000 for the year ended December 31, 2005. There were no such advances made during the year ended December 31, 2004. The Partnership repaid approximately $2,440,000 of advances and associated interest during the year ended December 31, 2005 from the proceeds from the refinance of Baymeadows Apartments.


The Partnership insures its properties up to certain limits through coverage provided by AIMCO which is generally self-insured for a portion of losses and liabilities related to workers compensation, property casualty, general liability and vehicle liability. The Partnership insures its properties above the AIMCO limits through insurance policies obtained by AIMCO from insurers unaffiliated with the Corporate General Partner. During the years ended December 31, 2005 and 2004, the Partnership was charged by AIMCO and its affiliates approximately $166,000 and $159,000, respectively, for insurance coverage and fees associated with policy claims administration.


In addition to its indirect ownership of the general partner interest in the Partnership, AIMCO and its affiliates owned 36,381 limited partnership units (the “Units”) in the Partnership representing 72.77% of the outstanding Units at December 31, 2005. A number of these Units were acquired pursuant to tender offers made by AIMCO or its affiliates. It is possible that AIMCO or its affiliates will acquire additional Units in exchange for cash or a combination of cash and units in AIMCO Properties, L.P., the operating partnership of AIMCO, either through private purchases or tender offers. Pursuant to the Partnership Agreement, unitholders holding a majority of the Units are entitled to take action with respect to a variety of matters that include, but are not limited to, voting on certain amendments to the Partnership Agreement and voting to remove the Corporate General Partner. As a result of its ownership of 72.77% of the outstanding Units, AIMCO and its affiliates are in a position to control all such voting decisions with respect to the Partnership. Although the Corporate General Partner owes fiduciary duties to the limited partners of the Partnership, the Corporate General Partner also owes fiduciary duties to AIMCO as its sole stockholder. As a result, the duties of the Corporate General Partner, as corporate general partner, to the Partnership and its limited partners may come into conflict with the duties of the Corporate General Partner to AIMCO as its sole stockholder.


Item 13.

Exhibits


See Exhibit Index.


Item 14.

Principal Accountant Fees and Services


The Corporate General Partner has reappointed Ernst & Young LLP as independent auditors to audit the consolidated financial statements of the Partnership for 2006.  The aggregate fees billed for services rendered by Ernst & Young LLP for 2005 and 2004 are described below.


Audit Fees.  Fees for audit services totaled approximately $35,000 and $36,000 for 2005 and 2004, respectively.   Fees for audit services also include fees for the reviews of the Partnership's Quarterly Reports on Form 10-QSB.


Tax Fees.  Fees for tax services totaled approximately $13,000 and $12,000 for 2005 and 2004, respectively.   


SIGNATURES




In accordance with Section 13 or 15(d) of the Exchange Act, the registrant caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.



 

SHELTER PROPERTIES IV

  
 

By:   Shelter Realty IV Corporation

 

      Corporate General Partner

  
 

By:   /s/Martha L. Long

 

      Martha L. Long

 

      Senior Vice President

  
 

By:   /s/Stephen B. Waters

 

      Stephen B. Waters

 

      Vice President

  
 

Date: March 30, 2006



In accordance with the Exchange Act, the registrant caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.



/s/Harry G. Alcock

Director and Executive

Date: March 30, 2006

Harry G. Alcock

Vice President

 
   

/s/Martha L. Long

Director and Senior

Date: March 30, 2006

Martha L. Long

Vice President

 
   

/s/Stephen B. Waters

Vice President

Date: March 30, 2006

Stephen B. Waters

  










SHELTER PROPERTIES IV


EXHIBIT INDEX



Exhibit

Description of Exhibit


 3

See Exhibit 4(a)


 4

(a)

Amended and Restated Certificate and Agreement of Limited Partnership (included as Exhibit A to the Prospectus of Registrant dated June 8, 1982 contained in Amendment No. 1 to Registration Statement No. 2-77217, of Registrant filed June 8, 1982 (the "Prospectus") and incorporated herein by reference).


(b)

Subscription Agreement and Signature Page (included as Exhibit 8 to the Prospectus and incorporated herein by reference).


10(i)

Contracts related to acquisition of properties:


(a)

Real Estate Sales Agreement dated May 5, 1982, First Modification to Real Estate Agreement dated June 18, 1982 (filed as Exhibit 12(b) to Amendment No. 1 to Registration Statement No. 2-77217 of Registrant filed June 8, 1982 and incorporated herein by reference) and Second Modification to Real Estate Sales Agreement dated September 30, 1982 between Baymeadows Associates and U.S. Shelter Corporation to purchase Baymeadows Apartments (filed as Exhibit 10(a) to Form 10-K of Registrant dated January 26, 1983 and incorporated herein by reference).


(d)

Real Estate Purchase Agreement dated December 3, 1982 between Quail Run Apartments, a Limited Partnership and Percival Partnership and U.S. Shelter Corporation to purchase Quail Run Apartments.  (Filed as Exhibit 10(b) to Form 8-K of Registrant dated December 15, 1982 and incorporated herein by reference.)


(iii)

Contracts related to refinancing of debt:


(g)

Multifamily Note dated June 14, 2002, between Shelter Properties IV and Keycorp Real Estate Capital Markets, Inc. for Quail Run Apartments.  (Filed as Exhibit 10(iii)g to Form 10-QSB - Quarterly or Transitional Report filed November 13, 2002 and incorporated herein by reference.)  


(j)

Consolidated, Amended and Restated Multifamily Note dated November 1, 2002 between Shelter Properties IV and GMAC Commercial Mortgage Corporation.*


(k)

Guaranty dated November 1, 2002 by AIMCO Properties, L.P., for the benefit of GMAC Commercial Mortgage Corporation.*


(l)

Consolidated Amended and Restated Payment Guaranty dated November 1, 2002 by Shelter Properties IV for the benefit of GMAC Commercial Mortgage Corporation.*


(m)

Completion/Repair and Security Agreement dated November 1, 2002 between Shelter Properties IV and GMAC Commercial Mortgage Corporation for the benefit of GMAC Commercial Mortgage Corporation.*



10(iii)(n)

Additional Mortgage Note, dated August 22, 2005 between Shelter Properties IV, L.P., a South Carolina limited partnership and Allstate Life Insurance Company, an Illinois corporation for Baymeadows Apartments (Filed as Exhibit 10(n) to Form 8-K of Registrant dated August 22, 2005 and incorporated herein by reference).


(o)

Modification, Restatement and Consolidation of Notes dated August 22, 2005 between Shelter Properties IV, L.P. and Allstate Life Insurance Company (Filed as Exhibit 10(o) to Form 8-K of Registrant dated August 22, 2005 and incorporated herein by reference).


(p)

Second Consolidated, Amended and Restated Multifamily Mortgage, Assignment of Rents and Security Agreement, dated August 22, 2005, between Shelter Properties IV, L.P. and Allstate Life Insurance Company (Filed as Exhibit 10(p) to Form 8-K of Registrant dated August 22, 2005 and incorporated herein by reference).


(q)

Nonrecourse Exception Indemnity Agreement dated August 22, 2005 by AIMCO Properties, L.P., for the benefit of Allstate Life Insurance Company (Filed as Exhibit 10(q) to Form 8-K of Registrant dated August 22, 2005 and incorporated herein by reference).


*Filed as Exhibits 10(iii)j through 10(iii)m, respectively, to Form 8-K of Registrant dated November 15, 2002 and incorporated herein by reference.


28

(a)

Agreement of Limited Partnership for Quail Run IV Limited Partnership between Shelter IV GP Limited Partnership and Shelter Properties IV entered into on February 12, 1992.  (Filed as Exhibit 28 to Form 10QSB - Quarterly or Transitional Report filed June 11, 1993 and incorporated herein by reference.)


31.1

Certification of equivalent of Chief Executive Officer pursuant to Securities Exchange Act Rules 13a-14(a)/15d-14(a), as Adopted Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.


31.2

Certification of equivalent of Chief Financial Officer pursuant to Securities Exchange Act Rules 13a-14(a)/15d-14(a), as Adopted Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.


32.1

Certification of the equivalent of the Chief Executive Officer and Chief Financial Officer pursuant to 18 U.S.C. Section 1350, as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.


Exhibit 31.1

CERTIFICATION

I, Martha L. Long, certify that:

1.

I have reviewed this annual report on Form 10-KSB of Shelter Properties IV;

2.

Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;


3.

Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the small business issuer as of, and for, the periods presented in this report;


4.

The small business issuer's other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) for the small business issuer and have:


(a)

Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the small business issuer, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;


(b)

Evaluated the effectiveness of the small business issuer's disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and


(c)

Disclosed in this report any change in the small business issuer's internal control over financial reporting that occurred during the small business issuer's most recent fiscal quarter (the small business issuer's fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the small business issuer's internal control over financial reporting; and


5.

The small business issuer's other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the small business issuer's auditors and the audit committee of the small business issuer's board of directors (or persons performing the equivalent functions):


(a)

All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the small business issuer's ability to record, process, summarize and report financial information; and


(b)

Any fraud, whether or not material, that involves management or other employees who have a significant role in the small business issuer's internal control over financial reporting.

Date:  March 30, 2006

/s/Martha L. Long

Martha L. Long

Senior Vice President of Shelter Realty IV Corporation, equivalent of the chief executive officer of the Partnership









Exhibit 31.2

CERTIFICATION

I, Stephen B. Waters, certify that:

1.

I have reviewed this annual report on Form 10-KSB of Shelter Properties IV;

2.

Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;


3.

Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the small business issuer as of, and for, the periods presented in this report;


4.

The small business issuer's other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) for the small business issuer and have:


(a)

Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the small business issuer, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;


(b)

Evaluated the effectiveness of the small business issuer's disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and


(c)

Disclosed in this report any change in the small business issuer's internal control over financial reporting that occurred during the small business issuer's most recent fiscal quarter (the small business issuer's fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the small business issuer's internal control over financial reporting; and


5.

The small business issuer's other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the small business issuer's auditors and the audit committee of the small business issuer's board of directors (or persons performing the equivalent functions):


(a)

All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the small business issuer's ability to record, process, summarize and report financial information; and


(b)

Any fraud, whether or not material, that involves management or other employees who have a significant role in the small business issuer's internal control over financial reporting.

Date:  March 30, 2006

/s/Stephen B. Waters

Stephen B. Waters

Vice President of Shelter Realty IV Corporation, equivalent of the chief financial officer of the Partnership









Exhibit 32.1



Certification of CEO and CFO

Pursuant to 18 U.S.C. Section 1350,

As Adopted Pursuant to

Section 906 of the Sarbanes-Oxley Act of 2002



In connection with the Annual Report on Form 10-KSB of Shelter Properties IV (the "Partnership"), for the fiscal year ended December 31, 2005 as filed with the Securities and Exchange Commission on the date hereof (the "Report"), Martha L. Long, as the equivalent of the Chief Executive Officer of the Partnership, and Stephen B. Waters, as the equivalent of the Chief Financial Officer of the Partnership, each hereby certifies, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that, to the best of his knowledge:


(1)

The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and


(2)

The information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Partnership.



 

      /s/Martha L. Long

 

Name: Martha L. Long

 

Date: March 30, 2006

  
 

      /s/Stephen B. Waters

 

Name: Stephen B. Waters

 

Date: March 30, 2006



This certification is furnished with this Report pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 and shall not be deemed filed by the Partnership for purposes of Section 18 of the Securities Exchange Act of 1934, as amended.