EX-99.(E) 6 ea166621ex99-e_bloom.htm AMENDED AND RESTATED PREFERRED DISTRIBUTOR AGREEMENT, DATED OCTOBER 23, 2021, BY AND BETWEEN BLOOM ENERGY CORPORATION, BLOOM SK FUEL CELL, LLC AND SK ECOPLANT CO., LTD

Exhibit E

 

Amended and Restated Preferred Distributor Agreement

 

This Amended and Restated Preferred Distributor Agreement (this “Agreement”) is entered into as of October 23, 2021 (the “Effective Date”) by and among Bloom Energy Corporation (“Bloom Corp”), a corporation established under the laws of the State of Delaware, United States of America, Bloom SK Fuel Cell, LLC (“JV”), a limited liability company organized under the laws of the Republic of Korea, and SK ecoplant Co., Ltd. (f/k/a SK Engineering & Construction Co., Ltd.) (“Distributor”), a corporation established under the laws of the Republic of Korea. Each of Bloom Corp, JV and Distributor are referred to herein as a “Party,” and together, as the “Parties.”

 

RECITALS

 

WHEREAS, Bloom Corp develops, manufactures and supplies certain Products in connection with electric power facilities. Distributor is experienced and engaged in the business of engineering, procuring, and constructing electric power facilities on a turnkey basis, including the distribution of electric power generation components integrated into such facilities;

 

WHEREAS, Bloom Corp and Distributor entered into a preferred distributor agreement dated November 14, 2018 (the “PDA”);

 

WHEREAS, Bloom Corp and Distributor agreed to amend the PDA on the terms of an amendment agreement dated December 19, 2018, an amendment agreement dated January 30, 2019 and a joinder and amendment agreement dated April 17, 2020 pursuant to which JV became a party to the PDA (such amendments, collectively, the “Amendments”); and WHEREAS, the Parties have further agreed to amend and restate the PDA (as amended by the Amendments) in its entirety as set forth in this Agreement.

 

NOW, THEREFORE, in consideration of the mutual covenants, representations, warranties and agreements hereinafter set forth, and intending to be legally bound hereby, the Parties agree as follows:

 

AGREEMENT

 

1. Definitions and Rules of Interpretation.

 

(a) Definitions.

 

Adjusted Quarterly Quantity” shall have the meaning given to it in Section 2(e)(ii)(1) hereof.

 

Ancillary Equipment” means, collectively, the Company-Required Ancillary Equipment and the Distributor-Procured Ancillary Equipment.

 

Bloom Corp” has the meaning set forth in the Preamble.

 

Bloom Energy Server” means the solid oxide fuel cell server manufactured by Company, consisting of the exterior box and all components inside, including without limitation the Fuel Cell Stack and power electronics.

 

1

 

 

Bundang Standard” means a limitation of liability in each service year equal to twenty- five percent (25%) of the annual LTSA service fee for such service year; provided, that if liability for liquidated damages in any year exceed the foregoing limitation, then such underperformance will be debited from the performance bank for the following service year.

 

CCA” means that certain Commercial Collaboration Agreement, dated as of the date hereof, by and between Bloom Corp and Distributor.

 

Claims” shall have the meaning given to it in Section 11(b) hereof.

 

Commissioning Capacity Specification” means the Rated Capacity specification required for Products to pass the Commissioning Test applicable to such Products, as defined in the Purchase Order for such Products.

 

Commissioning Completion” shall have the meaning given to it in Section 4(a) hereof.

 

Commissioning Duration Specification” means the period of time during which the Commissioning Test for Products is performed, as defined in the Purchase Order for such Products.

 

Commissioning Efficiency Specification” means the efficiency specification required for Products to pass the Commissioning Test applicable to such Products, as defined in the Purchase Order for such Products.

 

Commissioning Test” means the testing of the Products for a Project to determine whether it achieves the Commissioning Efficiency Specification when brought to the Commissioning Capacity Specification for the Commissioning Duration Specification, calculated by dividing (a) the AC electrical output (expressed in Therms) of the Products as measured at the Products’ transformers, by (b) the total LHV fuel input (expressed in Therms) of the Products, as measured at the Products’ Company-designated gas meter. The Commissioning Test includes the pre-power up check, fuel flow test, water system test, communication system test, and items as may be specified in a Purchase Order.

 

Company” means (a) Bloom Corp, with respect to rights, obligations, liabilities, and other terms and conditions applicable to Products supplied by Bloom Corp; and (b) JV, with respect to rights, obligations, liabilities, and other terms and conditions applicable to Products supplied by JV.

 

Company Performance LD Cap” shall have the meaning given to it in Section 3(c)(ii) hereof.

 

Company-Required Ancillary Equipment” means equipment for a Project, other than the Bloom Energy Server, which Distributor must purchase from Company to enable installation and operation, including without limitation equipment set forth on Exhibit A, as may be updated and delivered to Distributor from time to time.

 

2

 

 

Company Trademarks” shall have the meaning given to it in Section 9(f) hereof.

 

Component AC” means the a/c inverter unit module; as such module may be updated by Bloom Corp in current and future generations of Energy Server.

 

Component FP” means the fuel processing unit module; as such module may be updated by Bloom Corp in current and future generations of Energy Server.

 

Component PE” means the power enclosure module, including power electronics; as such module may be updated by Bloom Corp in current and future generations of Energy Server.

 

Component PM” means the power module; as such module may be updated by Bloom Corp in current and future generations of Energy Server.

 

Confidential Information” shall mean (i) any information disclosed by Company to Distributor that is in written, graphic, machine readable or other tangible form and is marked “Confidential,” “Proprietary” or in some other manner to indicate its confidential nature; (ii) oral information disclosed by Company to Distributor pursuant to this Agreement that is designated as confidential at the time of disclosure, and reduced to a writing marked as confidential and delivered by Company to Distributor within a reasonable time; (iii) any information a reasonable person in the circumstances would understand to be confidential, including without limitation non-public information contained in an RFP submission and the pricing terms of this Agreement. Notwithstanding any failure to so identify it, all non-public information embodied in the Products, including without limitation the source code underlying object code and bitmaps embodied in the Products, shall be Confidential Information.

 

Customer” means any third party that obtains a Product integrated into a stationary solid oxide fuel cell power facility in the Territory for the purpose of generating electricity, and not for further distribution or resale.

 

Customer Agreement” means an agreement between a Customer and Distributor for the supply of Products. Where Distributor is the EPC Contractor for a Project, the Customer Agreement may be an EPC Agreement. Where Distributor is not the EPC Contractor for a Project, the Customer Agreement is not required to be the EPC Agreement.

 

Deficiency” shall have the meaning given to it in Section 2(e)(ii)(1) hereof.

 

Delivery” and “Delivered” shall have the meanings given to them in Section 7(d)(i) hereof.

 

Distributor Excess Performance LD Commitment” shall have the meaning given to it in Section 3(d)(i) hereof.

 

Distributor-Procured Ancillary Equipment” means equipment for a Project, not including the Bloom Energy Server and Company-Required Ancillary Equipment, which Distributor may procure from suppliers other than Company, for use in the installation of a Project.

 

3

 

 

Documentation” means published written documentation related to the specifications, performance, installation, use or maintenance of the Products provided by Company or a Supplier under this Agreement.

 

Energy Server” and Bloom Energy Server are interchangeable and means the solid oxide fuel cell Bloom Energy Server®, composed of the Component FP, Component PE, Component PM and Component AC modules and all components therein; as such server may be updated by Bloom Corp from time to time in its discretion.

 

EPC” means “engineering, procurement, and construction.”

 

EPC Contractor” is the entity responsible for engineering, procuring and constructing each Project.

 

Exception” shall mean Exceptions to Distributor ROFR and Exceptions to Company ROFR.

 

Excess Performance LD Agreement” shall have the meaning given to it in Section 3(d)(i) hereof.

 

Excess Performance LD Requirements” means that such Project (a) is not a Non- EPC Project, (b) has a performance liquidated damages cap under the LTSA that is equal to or less than the Bundang Standard, and (c) has performance commitments under the LTSA that are not in excess of the Standard Performance Commitments.

 

Final Deficiency” shall have the meaning given to it in Section 2(e)(ii)(1) hereof.

 

Final Readjusted Quarterly Quantity” shall have the meaning given to it in Section 2(e)(ii)(1) hereof.

 

Force Majeure” means any act or circumstance that delays or interferes with the affected Party’s performance of its obligations in accordance with this Agreement, if such act or event is beyond the reasonable control, and not the result of the fault or negligence, of the affected Party. “Force Majeure” shall include the following acts or events:

 

(i) acts of God;

 

(ii) acts of civil or military authority, war, riot, or other civil disturbances;

 

(iii) fire or explosions not caused by the Products;

 

(iv) the elements, extraordinarily extreme weather, and acts of nature, or environmental factors including storms, floods, dust, lightning and earthquakes;

 

(v) failure to maintain gas pressure or gas quality requirements at the input of the Product;

 

4

 

 

(vi) a malfunction or failure of the electric grid at the applicable site of the Project (e.g. a brownout or blackout), including without limitation, the failure of the electric grid to comply with, as applicable, the standards set forth in the IEEE Standard 1547 for Interconnecting Distributed Resources with Electric Power System, as may be amended from time to time;

 

(vii) sabotage, vandalism, theft, accident or destruction caused by a third party (other than a contractor retainer by either Party), that materially impair either Party’s ability to perform its obligations under this Agreement;

 

(viii) any issues caused by the addition or operation of onsite generation or electrical infrastructure not comprising the Products;

 

(ix) strikes, walkouts, lockouts or similar labor actions or disputes;

 

(x) any other cause or causes which are beyond such Party’s reasonable control; or

 

(xi) the inability to connect to the internet, or any other failure or unavailability of internet connectivity or availability for any cause whatsoever, including fiber optic cable cuts, interruption or failure of digital transmission links, hacker attacks.

 

“Force Majeure” shall not include a Party’s financial inability to perform under this Agreement.

 

Bookings Target” shall have the meaning given to it in Section 2(e)(vi) hereof.

 

Fuel Cell Stack” shall have the meaning given to it in JVA.

 

GenCo” means a generation company owned by the government of the Republic of Korea.

 

Hot Box” shall have the meaning given to it in the JVA.

 

Indemnified Parties” shall have the meaning given to it in Section 11(b) hereof.

 

Indemnifying Party” shall have the meaning given to it in Section 11(b) hereof.

 

Initial Term” shall have the meaning given to it in Section 13(a) hereof.

 

Invoice Due Date” means, for invoices issued by Company (a) prior to January 1, 2019, within sixty (60) days of receipt of such invoice; and (b) on or after January 1, 2019, within forty- five (45) days of receipt of such invoice.

 

JV” has the meaning set forth in the Preamble.

 

JVA” means the Joint Venture Agreement, dated September 24, 2019, by and between Bloom Corp and SK ecoplant Co., Ltd. (f/k/a SK Engineering & Construction Co., Ltd.), as may be amended, modified and supplemented, from time to time.

 

JV Scope” shall have the meaning given to it in the JVA.

 

5

 

 

kW” means kilowatts, and “MW” means megawatts. All references to kW and MW of Projects refer to the rated output of such Projects.

 

LD Backstop Payment” shall have the meaning given to it in Section 3(d)(ii) hereof. “Licensed Material” means (a) the Products, and (b) all documentation delivered hereunder by Company to Distributor for use pursuant to the terms and conditions of this Agreement.

 

Limited License” shall have the meaning set forth in Section 9(b) hereof.

 

LTSA” means the “long term service agreement” pursuant to which O&M services for a Project are rendered.

 

Major Subcontract” means any subcontract or series of subcontracts for the performance of Distributor’s obligations under this Agreement or under a Customer Agreement, having an aggregate value in excess of fifty percent (50%) of the engineering and construction budget for such Project.

 

Market” means Projects in the Territory that are not subject to an Exception.

 

Marketing Materials” shall have the meaning set forth in Section 9(h) hereof. “Non-EPC Project” shall have the meaning given to it in Section 3(d)(iii) hereof.

 

Notice of Commissioning Completion” shall have the meaning given to it in Section 4(a) hereof.

 

O&M” shall have the meaning given to it in Section 3(a) hereof.

 

Original Quarterly Quantity” shall have the meaning given to it in Section 2(e)(i)

 

Performance Insurance” means a policy of insurance covering Company’s non-payment of amounts due to Customer pursuant to a LTSA in connection with a refund, repurchase, or similar consideration for passage of title and possession to the applicable Products to Company.

 

Permitted Subcontractor” means a subcontractor set forth on Exhibit B, or otherwise approved by Bloom Corp in writing (following the passing of appropriate due diligence of such subcontractor conducted by Bloom Corp), not to be unreasonably withheld, delayed, or denied; provided, however, that in no event shall a competitor or potential competitor to Bloom Corp be a Permitted Subcontractor.

 

Pre-Commissioning Completion Warranty” shall have the meaning given to it in Section 4(b)(i) hereof.

 

Pre-Commissioning Completion Warranty Period” shall have the meaning given to it in Section 4(b)(i) hereof.

 

Product” means any of the Energy Server and Company-Required Ancillary Equipment and any Software, Documentation or Updates provided pursuant to this Agreement.

 

Product Price” shall have the meaning given to it in Section 6(a)(i) hereof.

 

6

 

 

Prohibited Activities” shall have the meaning set forth in Section 9(c) hereof.

 

Project” means a stationary utility-scale or commercial & industrial fuel cell energy generation project composed of Energy Servers, together with applicable Company-Required Ancillary Equipment and Distributor-Procured Ancillary Equipment.

 

Purchase Agreement” shall mean the Securities Purchase Agreement, dated as of the date of this Agreement, by and between Bloom Corp and Distributor, as may be amended and restated, supplemented, or otherwise modified from time to time in accordance with its terms.

 

Purchase Order” shall have the meaning given to it in Section 7(b) hereof.

 

Purchase Period” shall have the meaning given to it in Section 2(e)(ii)(1) hereof.

 

Rated Capacity” means the aggregate rated capacity (expressed in kW) of the Bloom Energy Servers included in the Project, as set forth in a duly-accepted Purchase Order.

 

Readjusted Quarterly Quantity” shall have the meaning given to it in Section 2(e)(ii)(1) hereof.

 

Renewal Term” shall have the meaning given to it in Section 13(a) hereof.

 

ROFR” shall have the meaning given to it in Section 2(a) hereof.

 

ROFR Exercise Period” shall have the meaning given to it in Section 2(a) hereof.

 

Second Distribution Agreement” means that certain preferred distributor agreement, dated as of January 30, 2019, by and between Company and Second Distributor, as may be amended and restated, supplemented, or otherwise modified from time to time in accordance with its terms.

 

Second Distributor” means SK D&D Co., Ltd.

 

Standard Performance Commitments” means:

 

(a)Performance Guarantee (i.e. remedy is payment of liquidated damages): (i) 95% lifetime cumulative total output factor with banking (pre- transformer); (ii) if required by Customer, 56% lifetime cumulative LHV efficiency with banking (pre-transformer); provided that in case Products of 7.5 Generation is successfully developed and commercialized, then such lifetime cumulative LHV efficiency shall be adjusted subject to mutual agreement between Bloom Corp and Distributor; and

 

7

 

 

 

(b)Performance Warranty (i.e. remedy is repair, replacement, repurchase): (i) 90% lifetime cumulative total output factor with banking (pre- transformer); (ii) if required by Customer, 54% lifetime cumulative LHV efficiency with banking (pre-transformer); provided that in case Products of 7.5 Generation is successfully developed and commercialized, then such lifetime cumulative LHV efficiency shall be adjusted subject to mutual agreement between Bloom Corp and Distributor.

 

SOEC” means the Company-developed solid oxide electrolyzer.

 

Software” means the software provided by Company or a Supplier pursuant to this Agreement

 

Subsequent Deficiency” shall have the meaning given to it in Section 2(e)(ii)(1)

 

Suppliers” means any providers of third party software that is included with Software provided under this Agreement.

 

Technical Advisor” shall have the meaning give to it in Section 4(c) hereof. “Term” shall have the meaning given to it in Section 13(a) hereof. “Territory” means the Republic of Korea.

 

Third Party Software” has the meaning given to it in Section 9(d) hereof.

 

Transfer Price” means the sum of (a) JV’s cost of supplying the applicable Product comprising JV Scope (including administrative costs), plus (b) an amount required to comply with all transfer pricing laws and regulations promulgated by the Republic of Korea and the United States of America and their respective political subdivisions and states, as applicable.

 

Tri-Party Agreement” means that certain Tri-Party Consent and Agreement, dated as of January 30, 2019, by and among Company, Distributor, and Second Distributor, as may be amended, amended and restated, supplemented, or otherwise modified from time to time in accordance with its terms.

 

Updates” means any corrections, enhancements, bug fixes or other modifications for the Products provided to Distributor by Company pursuant to this Agreement.

 

Warranty Correction” shall have the meaning given to it in Section 4(b)(ii) hereof.

 

(b) Rules of Interpretation. Unless a clear contrary intention appears, (i) the singular includes the plural and vice versa; (ii) “include” or “including” means including without limiting the generality of the description preceding such term; (iii) the word “or” is not exclusive, unless otherwise expressly stated; (iv) headings are provided for the convenience of the parties and shall not affect the interpretation of a provision; (v) all references to days or time shall mean such day or time in California, U.S.A., except as may be expressly set forth in a Purchase Order; (vi) all references to money shall be in United States dollars; except as may be expressly set forth in a Purchase Order; and (vii) all references to “Korea” refer to the Republic of Korea. References to sections, exhibits and schedules are, unless otherwise indicated, references to sections, exhibits, and schedules to this Agreement. References to an exhibit shall mean the referenced exhibit and any sub-exhibits, schedules, sub-parts, components or attachments included therewith. References to a section shall mean the referenced section and all sub-sections thereof. All exhibits attached to this Agreement are incorporated herein by this reference and made a part hereof for all purposes.

 

8

 

 

2. ROFR; Appointment of Distributor.

 

(a) Mutual Right of First Refusal. Distributor shall have the right of first refusal during the Term (the “Distributor ROFR”) to serve as the distributor of the Products for any fuel cell generation project in the Territory that is not subject to an Exception to Distributor ROFR. The Parties will follow the framework set forth in the CCA for future SOEC distributorship rights for the Distributor. Company shall have the right of first refusal during the Term (the “Company ROFR”; and each of Distributor ROFR and Company ROFR, a “ROFR”) to serve as Distributor’s supplier of the generation equipment for any fuel cell generation project in the Territory that is not subject to an Exception to Company ROFR. Each ROFR is exercisable within ninety (90) days (“ROFR Exercise Period”) from the date that Company or Distributor, as applicable, delivers written notice to the counterparty, requesting such counterparty’s determination of whether it will exercise its ROFR for such project. When a Party requests the counterparty’s determination of whether it will exercise its ROFR for a project the Party requesting such determination shall continue to serve as the supplier or distributor (as applicable to Company or Distributor, respectively) for such project.

 

(b) A Party’s ROFR will automatically terminate, and the counterparty proposing such fuel cell generation project may determine whether to pursue such project, by itself or with third parties, without the involvement of Party holding such ROFR, if the Party holding such ROFR does not deliver written notice within the ROFR Exercise Period that it wishes to exercise its right to serve as supplier or distributor (as applicable to Company and Distributor, respectively), for such project. The ROFR is not a right to require that Company or Distributor consummate any particular sales or service transaction for any particular Project. Company and Distributor may each, in its sole discretion and for any reason, determine whether to pursue or consummate any Project and enter into a Purchase Order. If a Party chooses not to pursue or consummate any transaction for which it has exercised the ROFR within the ROFR Exercise Period, such Party shall not thereafter pursue or consummate such Project by itself or with a third party. For the avoidance of doubt, a Party shall have no right with respect to any project for which it does not exercise its right to serve as supplier or distributor (as applicable to Company and Distributor, respectively) within the ROFR Exercise Period.

 

(c) Exceptions to Right of First Refusal.

 

(i) During the Initial Term of this Agreement:

 

(1) The following projects are exempt from Distributor’s ROFR (each, an “Exception to Distributor ROFR”):

 

a. any project for which Distributor is ineligible to participate due to applicable law or applicable procurement rules (e.g. RFP rules) for such Project;

 

b. any project with an existing Company customer headquartered outside of the Republic of Korea requesting a commercial & industrial application;

 

9

 

 

c. D&D Project pursuant to Second Distributions Agreement;

 

and

 

d. any project which is not a stationary utility-scale or commercial & industrial fuel cell generation project in the Territory.

 

(2) The following projects are exempt from Company’s ROFR (each, an “Exception to Company ROFR”):

 

a. the SKIPC Hydrogen Fuel Cell project with Doosan for phosphoric acid fuel cells under development as of the Effective Date.

 

(ii) Prior to the commencement of any Renewal Term, the Parties shall mutually agree in writing regarding the Exceptions to Distributor ROFR and Exceptions to Company ROFR to be applicable during such Renewal Term.

 

(iii) During the Term, the Parties can mutually agree to add, delete, or modify the Exceptions to Distributor ROFR and Exceptions to Company ROFR.

 

(d) Material Breach. If either Party offers a project that is subject to the counterparty’s ROFR (and is not subject to an applicable Exception) herein without first sending a notice to the Party holding such ROFR in accordance with Section 2(a), it shall constitute a material breach of this Agreement, but such breach may be cured by revoking such offer to the third party within five (5) days of written notice thereof and thereafter proceeding in accordance with ROFR procedures set forth in Section 2(a).

 

(e) Commitment.

 

(i) Commitment. Distributor shall purchase, on a take or pay basis, the following volume of Energy Servers for each of the periods set forth below (with respect to each quarter of each calendar year, the quantity indicated below for such quarter, the “Original Quarterly Quantity”):

 

Calendar Year

Quarter 1 (MW) Quarter 2 (MW) Quarter 3 (MW) Quarter 4 (MW)
2021 N/A N/A N/A 39.6
2022 20 20 20 40
2023 20 30 50 50
2024* 40 40 60 60

 

*2024 Original Quarterly Quantity subject to Section 2(e)(ii)(5) and 2(e)(iii).

 

10

 

 

(ii) Commitment Shortfall.

 

(1) Roll Over; Limitation. With respect to any calendar quarter, in the event Distributor fails to accept Delivery of all of such quarter’s Original Quarterly Quantity (the amount of such deficiency for such quarter, the “Deficiency”), such Deficiency shall be rolled over to the subsequent quarter and be included in the Original Quarterly Quantity of such subsequent quarter (such adjusted Original Quarterly Quantity, “Adjusted Quarterly Quantity”), and if Distributor fails to accept Delivery all of the Adjusted Quarterly Quantity by the end of such quarter (the amount of such deficiency for such subsequent quarter, the “Subsequent Deficiency”), then such Subsequent Deficiency shall be rolled over to the subsequent quarter and be included in the Original Quarterly Quantity of such subsequent quarter (such adjusted Original Quarterly Quantity, “Readjusted Quarterly Quantity”), and if Distributor fails to accept Delivery of all of the Readjusted Quarterly Quantity by the end of such quarter (the amount of such deficiency for such subsequent quarter, the “Final Deficiency”), then such Final Deficiency shall be rolled over to the subsequent quarter and included in the Original Quarterly Quantity of such subsequent quarter (the “Final Readjusted Quarterly Quantity”). At the end of such quarter, Distributor shall either (i) accept Delivery of the Final Readjusted Quarterly Quantity or (ii) pay the Company the amount Distributor would have paid to Company had it accepted Delivery of the Final Readjusted Quarterly Quantity. Distributor’s failure to perform either (i) or (ii) of the immediately preceding sentence shall constitute a material breach by Distributor of this Agreement. The period commencing on the first day of the quarter in which a Deficiency occurs and ending on the day immediately preceding the first anniversary of such first day shall hereinafter be referred to as the “Purchase Period.” For illustrative purposes only, if Distributor fails to satisfy the Original Quarterly Quantity for the third quarter of 2022, and subsequently fails to satisfy the Adjusted Quarterly Quantity in the fourth quarter of 2022, then any such deficiency (whether rolled over from the first quarter or the second quarter of the Purchase Period) shall be satisfied by the end of the second quarter of 2023 and no further roll over of any deficiency shall be permitted.

 

(2) Premium. The Product Price applicable to any amount rolled over from the preceding quarter pursuant to Section 2(e)(ii)(1) above shall be increased by 5% per annum and shall begin to accrue from the first day of the quarter following the quarter in which the Deficiency occurred until paid (on a basis of a “first in, first out” principle such that the first volumes of orders following a quarter in which a deficiency occurs will deemed to be orders of the previous quarter’s deficiency until the previous quarter’s deficiency has been reduced to zero) (thePremium”).

 

(3) Excess. In the event that Distributor satisfies more than 100% of such quarter’s Original Quarterly Quantity, the excess shall be credited against the Original Quarterly Quantity of the subsequent quarter.

 

(4) Satisfaction of Commitment. For purposes of this Section 2(e), commitment shall be deemed satisfied when the Product is Delivered.

 

(5) 2024. Delivery of up to 50 MW in markets other than the Territory and U.S. may be credited against Distributor’s commitment to purchase Energy Servers in any quarter of year 2024 set forth in Section 2(e)(i) above and/or, sales, and/or distribution of SOEC equivalent (50 MW SOFC = 120 MW SOEC) at the Product Price of the Energy Server in 2024 multiplied by 2.6.

 

(iii) Commitment in Years 2023 and 2024. Notwithstanding anything to the contrary contained herein, if the JV cannot perform Full Assembly (as defined in the JVA) as contemplated by Section 6.2 of the JVA for reasons attributable directly and solely to Bloom Corp, which shall not include Force Majeure or any other reasons beyond Bloom Corp’s or the JV’s contemplation or control, then this Section 2(e) and the obligations to purchase Original Quarterly Quantities in 2024 set forth in this Section 2(e) shall be adjusted by agreement between the Parties and in direct proportion to the shortfall addressed in this Section 2(e)(iii).

 

11

 

 

(iv) Amendment to Commitment and JV Scope. Notwithstanding anything to the contrary contained herein, if the Clean Hydrogen Energy Portfolio Standards and any other rules and regulations applicable or relevant to the Products that are promulgated or amended by the government of Korea deviate materially from the Parties’ economic-value expectations, which are that the Clean Hydrogen Energy Portfolio Standards incentive will be substantially similar to the existing renewable-portfolio-standard (RPS) incentive based on renewable energy credits (RECS) of at least one-hundred thousand Korean Won per megawatt hour (KRW 100,000/ MWh) then Distributor and Bloom Corp shall negotiate in good faith to amend the Original Quarterly Quantities set forth in Section 2(e)(i) above and the JV Scope.

 

(v) GenCo RFP. If Distributor delivers written notice to Company requesting Company’s determination of whether it will exercise its ROFR for a GenCo RFP, and is selected as the winner of such GenCo RFP but Company chooses not to execute a Purchase Order for such GenCo RFP, then the MW capacity of the transaction shall be applied to the annual target for such calendar year as though a Purchase Order had been executed; provided, however, that notwithstanding the foregoing, such MW capacity shall not be applied for such calendar year if the reason that Company chose not to exercise its ROFR or execute a Purchase Order arose from either (a) risks to protection of Company’s intellectual property; or (b) the lack of a Distributor Excess Performance LD Commitment for such transaction.

 

(vi) Bookings Target. By no later than two (2) months prior to the end of each calendar year, Distributor shall provide the Company with a twelve (12) month non-binding bookings target of its anticipated requirements for Product in the Territory for the subsequent calendar year, which may be updated by Distributor from time to time during the course of such subsequent year (each, a “Bookings Target”). Distributor’s initial Bookings Target is set forth below. Each Bookings Target is a non-binding estimate and shall not obligate Distributor to purchase the volume of Product set forth in such Bookings Target.

 

 

Calendar Year Quantity
2022 150 MW
2023 200 MW
2024 250 MW

 

(vii) Appointment.

 

(1) Subject to the terms and conditions of this Agreement and the Tri- Party Agreement, Company hereby appoints Distributor, for the Term, as an authorized distributor of the Products from Company for redistribution to Customers pursuant to each Project in the Territory for which Distributor has exercised the ROFR pursuant to Section 2(a). This appointment is nonexclusive with respect to Projects outside the Territory, Projects subject to an Exception, Projects for which Distributor has not exercised the ROFR pursuant to Section 2(a), and Projects for which contracted sales occur following the expiration of the Term or earlier termination of this Agreement in accordance with its terms. In such cases, Company reserves the right to license and distribute the Products directly and through any other remarketers, dealers, distributors, sales representatives or other channels and for any purposes. In such cases, Company reserves the right to market and sell upgrades for the Products and/or other products or services to any Customer that has previously obtained a licensed Product from Distributor. Subject to the terms and conditions of this Agreement, Distributor will be free to establish its own pricing for Products.

 

12

 

 

 

(2) Each license of Products from Company to Distributor pursuant to this Agreement shall be subject to, and governed by, this Agreement, including without limitation the intellectual property provisions set forth in Section 9, and the export and import restrictions set forth in Section 14. Company shall not be bound by, and specifically objects to, any term, condition or other provision which is different from or in addition to the provisions of this Agreement and which is submitted by Distributor in any order, receipt, acceptance, confirmation, correspondence or otherwise, unless Company specifically agrees to such provision in a writing signed by Company.

 

(f) Second Distributor. The Parties acknowledge that: (a) Company and Second Distributor have entered into the Second Distribution Agreement; and, (b) the Parties and Second Distributor have entered into the Tri-Party Agreement. The Parties Agree that, notwithstanding anything in this Agreement to the contrary, including without limitation Section 2 hereof, Second Distributor may serve as a distributor of Company in the Territory and Company may supply Products and Ancillary Equipment to Second Distributor for Projects in the Territory, in each case without any obligation to notify or receive the consent of Distributor. Product and Ancillary Equipment purchases by Second Distributor shall not, however, be credited towards Distributor’s take-or-pay purchase obligations under this Agreement. The Parties agree that all disputes related to or arising out of Company’s relationship with Second Distributor or any supply or service transaction conducted between Company and Second Distributor shall be exclusively and finally resolved pursuant to the terms and conditions of the Tri-Party Agreement.

 

3. Resale Terms and Conditions.

 

(a) Intellectual Property.

 

(i) Distributor shall comply with all intellectual property limitations set forth in Section 9.

 

(ii) Distributor shall make best efforts to ensure that the intellectual property provisions of the Customer Agreement (and, if applicable, related RFP bid materials) comply with the following requirements, and shall receive Company’s written consent prior to executing a Customer Agreement (which may occur as early as submission of RFP bid materials) which does not comply with such provisions: (a) Company shall have the exclusive right to conduct all monitoring, control, operations, and maintenance activities (“O&M”) for each Project during the life thereof; (b) Customer and all third parties shall otherwise comply with the Prohibited Activities; (c) Company shall have a right of re-purchase upon abandonment, or attempted sale or transfer of the Products or Project; and (d) pursuant to the terms and conditions of the LTSA, Company shall have a right of re-purchase upon termination of the LTSA for any reason.

 

13

 

 

(b) Customer Agreement.

 

(i) Responsibility. Any Customer Agreement consummated with respect to a Project shall be by and between Distributor and Customer, and Company shall have no obligation or liability thereunder. As between Distributor and Customer, Distributor shall be responsible for the performance of all obligations thereunder, including obligations with respect to development, permitting, engineering, procurement, and construction. Distributor shall not subcontract any obligation under the Customer Agreement or this Agreement unless such subcontractor is a Permitted Subcontractor; provided, however, that any and all Major Subcontracts shall be subject to Company’s prior written consent. Distributor shall be solely responsible for the engagement, management and payment of its subcontractors, and shall be solely responsible for the acts, omissions or defaults of its subcontractors and their agents, representatives and employees.

 

(ii) Terms and Conditions. In the event that Customer of a Project imposes unfavorable terms and conditions in its Customer Agreement that conflicts with or deviates from this Agreement, both Parties shall use best efforts to negotiate with Customer the terms and conditions of the Customer Agreement as the equal level with this Agreement.

 

(iii) EPC Contractor. The Parties intend that Distributor will be the EPC Contractor for any Project for which it has exercised the ROFR. However, if Company provides its prior written consent regarding the third party chosen to serve as the EPC Contractor for such Project (a Project for which Distributor is not the EPC Contractor, a “Non-EPC Project”) and the terms of such relationship, then Distributor may nonetheless exercise the ROFR for such Project and the Parties may execute a Purchase Order for such Project. All activities of any EPC Contractor (including without limitation Distributor) shall be subject to the intellectual property provisions set forth in Section 3(a), and Company (and not Distributor or any third party) shall perform all activities which require opening a Bloom Energy Server, including without limitation in connection with the commissioning of each Project. For the avoidance of doubt, EPC Contractor pricing shall be taken into consideration by Distributor when Distributor determines whether to exercise a ROFR, and the pricing set forth in Section 5 shall not be subject to change arising out of costs and expenses related to the EPC Contractor of a Project.

 

(iv) Buy-Down LDs. Liquidated damages commonly referred to as “buy-down liquidated damages” and assessed prospectively for future performance of a Project based upon performance during commercial operation of such Project (e.g. one (1) year or two (2) years of commercial operation), do not form part of Company’s offer for any Project. If buy-down liquidated damages are required by the rules of procurement for any project (e.g. the rules of a request for proposals), then the Parties may, by mutual written agreement, decide in writing to pursue such Project upon terms and conditions with respect to such buy-down liquidated damages which are mutually acceptable to the Parties; provided, that neither Party shall be under any obligation to enter into any such agreement.

 

(v) Performance Bond. If a Customer Agreement requires Distributor to post a “performance bond” or equivalent financial security to secure performance of the Delivery of the Products and the passage of the Commissioning Test (a “Performance Bond”), the Parties shall set forth in the applicable Purchase Order the requirements of such financial security, and the Parties’ respective responsibility therefor; provided, that in no event shall Company’s responsibility for posting a Performance Bond exceed the lesser of (a) the pro-rata percentage of the contract price under such Customer Agreement attributable to the supply of the Products; and (b) one hundred percent (100%) of the Product Price of such Products as set forth in the Purchase Order therefor. The contractual liability of Company for failure to timely Deliver the Products or for the Products to pass the Commissioning Test, together with the draw conditions for a Performance Bond posted by Company, shall be set forth in the Purchase Order. The Parties shall make best efforts to negotiate in the Customer Agreement to minimize exposure related to such liabilities.

 

14

 

 

(c) LTSA.

 

(i) LTSA Negotiation. Company shall be solely authorized and responsible for all marketing (including bid materials), negotiation, and execution of any LTSA for any Project that is, or is proposed to be, subject to a Customer Agreement. Distributor may not, without Company’s prior written consent, make any representation on Customer’s behalf with respect to any LTSA, including without limitation representation regarding pricing, performance commitments, or limitations of liability. Distributor shall have the opportunity to participate in LTSA negotiations with Company and Customer for any LTSA that is subject to the Distributor Excess Performance LD Commitment. Distributor shall not have liability pursuant to any LTSA, except as set forth in an Excess Performance LD Agreement.

 

(ii) Company Performance Liquidated Damages. Notwithstanding anything to the contrary in this Agreement, Company’s total liability for performance liquidated damages for any Project that is not a Non-EPC Project, for the term of the LTSA of such Project, shall in no event exceed (a) during the first ten (10) years of commercial operation, a total of five percent (5%) of the pre-tax Bloom Energy Server equipment sale price from Company to Distributor; and (b) for each succeeding ten (10) year period, a total of five percent (5%) of the pre-tax Bloom Energy Server equipment sale price from Company to Distributor (the foregoing, collectively, the “Company Performance LD Cap”).

 

(d) Distributor Backstop.

 

(i) Distributor Excess Performance LD Commitment. Distributor shall sign an agreement with Customer (“Excess Performance LD Agreement”) for any Project which meets the Excess Performance LD Requirements, which Excess Performance LD Agreement shall provide that, in the event that Customer requires liquidated damages in excess of the Company Performance LD Cap, then (a) Distributor (and not Company) shall furnish such excess liquidated damages; (b) Customer’s sole recourse for such excess liquidated damages shall be to Distributor (and not to Company); and (c) such liquidated damages from Distributor shall be applied only after liquidated damages from Company (up to the Company Performance LD Cap) have been applied (the foregoing, collectively, the “Distributor Excess Performance LD Commitment”). The Parties will use best efforts to negotiate with such Customer a total performance liquidated damage cap under the LTSA that does not exceed the Bundang Standard. If the performance liquidated damage cap for a Project is equal to or less than the Bundang Standard, Distributor shall provide the Excess Performance LD Commitment, as described above. The Parties will also use best efforts to negotiate with such Customer an agreement that the Excess Performance LD Agreement will be a separate instrument from the LTSA.

 

15

 

 

(ii) LD Backstop Payment. In consideration of such Distributor’s obligation to provide the Distributor Excess Performance LD Commitment, Company shall pay to Distributor Thirty Dollars per kilowatt of Rated Capacity per year (USD$30/kW/year) with respect to the Project subject to such LTSA (the “LD Backstop Payment”). If Company receives payments from Customer pursuant to the LTSA in Korean Won, then Company shall pay Distributor an amount equivalent to the LD Backstop Payment in Korean Won, at the foreign exchange rate used by the Customer to pay Company pursuant to the LTSA. Company shall pay the LD Backstop Payment on a pro-rata basis with the timing of payments received for such year by the Company from the Customer pursuant to the LTSA; provided, that each such pro-rata portion of the LD Backstop Payment shall be paid from Company to Distributor within thirty (30) days from receipt of the applicable Customer payment to Company. For illustrative purposes, if the Customer pays the LTSA fee to the Company on a quarterly basis (i.e. four (4) times per year), then the pro-rata quarterly LD Backstop Payment from Company to Distributor would be $7.50/kW/quarter.

 

(iii) Exceptions. The Parties intend that Distributor will be the EPC Contractor for each Project for which Distributor has exercised the ROFR. If Distributor is the EPC Contractor for any such Project, then Distributor shall provide the Distributor Excess Performance LD Commitment for such Project. If Distributor is not the EPC Contractor for any such Project, then Distributor shall not be required to provide the Distributor Excess Performance LD Commitment for such Non-EPC Project.

 

(iv) Confirmation Instrument. In connection with each Excess Performance LD Agreement that Distributor executes with a Customer, the Parties shall execute an instrument setting forth their respective obligations pursuant to this Section 3(d), which instrument shall not expire prior to the expiration of the Excess Performance LD Agreement.

 

4. Commissioning and Pre-Commissioning Completion Warranty.

 

(a) Commissioning. Company shall perform the Commissioning Test at the earliest practicable date after the Products are mechanically complete as a complete Project (or, if such Project is in phases, a complete phase of such Project), and have all governmental authorizations and third party consents required to bring such Project (or phase thereof, as applicable) to operational power levels and perform the Commissioning Test. Upon passage of the Commissioning Test, Company shall deliver to Distributor a notice of commissioning completion, substantially in the form set forth in Exhibit D (“Notice of Commissioning Completion” and the date of commencement of operations set forth therein, the “Commissioning Completion Date”). If the Products fails to pass the Commissioning Test, Distributor may submit a claim under the Pre-Commissioning Completion Warranty to Company for verification pursuant to Section 4(b).

 

(b) Pre-Commissioning Completion Warranty.

 

(i) Pre-Commissioning Completion Warranty. Subject to Section 4(b)(iii), Company warrants to Distributor, that, during the period commencing upon Delivery and continuing until the achievement of Commissioning of the Products for a Project (“Pre-Commissioning Completion Warranty Period”), such Products shall be free from physical defects in design, materials and workmanship that prevent such Products from achieving Commissioning Completion (the “Pre- Commissioning Completion Warranty”). The Pre-Commissioning Completion Warranty is not transferable to any third person, including a Customer, without Company’s prior written consent.

 

16

 

  

(ii) Warranty Correction. If Products fail to satisfy the Pre-Commissioning Completion Warranty during the Pre-Commissioning Completion Warranty Period, Distributor shall make a written warranty claim to Company and Company shall verify whether such warranty claim is valid. Company shall either repair or replace (as determined by Company) the applicable Products (a “Warranty Correction”) and re-perform the Commissioning Test within times acceptable to Customer; provided, that if Company has commenced and thereafter diligently pursued such Warranty Correction, but the nature of the specific remedy cannot be performed at the time requested by Customer, then such period shall conform to terms and conditions under the Purchase Order. Company may, as it deems necessary or appropriate, re-perform a Warranty Correction within such period (as may be extended pursuant to the foregoing sentence). Upon completion of the Warranty Correction, Company shall notify Distributor in writing, and Commissioning Test shall be re- performed. Breach of the Pre-Commissioning Completion Warranty shall not be extended to the Pre- Commissioning Completion Warranty Period after the achievement of Commissioning Completion. If Company fails to provide a Warranty Correction within the time required by the Customer Agreement, and as a result Customer rejects the Products, then Company shall pay to Distributor, as Distributor’s sole and exclusive remedy, the Refund Amount. The “Refund Amount” is an amount equal to (a) amounts refunded from Distributor to Customer pursuant to such Customer Agreement caused by such rejection; plus (b) direct third party costs and expenses incurred by Distributor to restore such Site in satisfaction of the terms and conditions of such Customer Agreement (including amounts in connection with disassembling works constructed at the Site); provided, however, that in no event shall Company’s liability for a Refund Amount exceed the sum of (X) the aggregate Product Price of such Products, plus (Y) the costs incurred by Distributor to install such Products (without Distributor markup or margin), plus (Z) the direct third party costs incurred by Distributor to restore such Site (without Distributor markup or margin) (such sum, the “Refund Cap”).

 

(iii) Warranty of JV Scope. For the avoidance of doubt, Products constituting JV Scope shall be subject to the Pre-Commissioning Completion Warranty set forth in Section 4 of this Agreement. Warranty claims, if any, for Products constituting JV Scope shall be directed to either Bloom Corp or JV, as the supplier of such Products pursuant to the Purchase Order for such Products; and in the event the applicable defect underlying a warranty claim arises from the JV Scope supplied by JV, JV shall be responsible for the Pre-Commissioning Completion Warranty with respect to such defect and in the event the applicable defect underlying a warranty claim arises from Company- Required Ancillary Equipment supplied by Bloom Corp, Bloom Corp shall be responsible for the Pre- Commissioning Completion Warranty with respect to such defect.

 

(iv) Exclusions. The Pre-Commissioning Completion Warranty shall not cover any obligations on the part of Company to the extent caused by or arising from (a) the Products affected by loss, vandalism, or other third-party actions or omissions after Delivery; (b) any failure relating to failure of natural gas supply to conform to the required specifications; (c) removal of any safety device by any person other than Company, (d) accidents, abuse, improper third party testing, (e) Force Majeure events, or (f) commissioning, operation, repair, opening or accessing, or modification of the Products by anyone other than Company or Company’s authorized agents.

 

17

 

 

(c) Technical Advisor. During the period of construction, Company shall make reasonably available an employee of Company or its affiliates during business hours (telephonically, via email, or at the Site, as may be mutually agreed and coordinated) to serve as technical advisor regarding Company technology (a “Technical Advisor”). Such Technical Advisor shall provide interpretive advice to Distributor regarding the technical specifications, installation manual, and other Product- specific information. Such advice shall exclude any supervision, management, or evaluation of Distributor’s or its contractors’ personnel, agents or subcontractors and work relating thereto, and any responsibility for planning, scheduling or management of Distributor’s work (including in connection with development or permitting).

 

5. Post-COD Warranty Matters. The Parties expect that, following Commissioning Completion of the Products (a) the Products shall not be within the scope of Distributor’s warranty to a Customer, as set forth in the Customer Agreement; and (b) Company’s performance commitments and financial responsibility under the LTSA do not include responsibility for damaged, defective, or otherwise underperforming Ancillary Equipment. If the foregoing expectation is not fulfilled in any Customer Agreement or LTSA, the Purchase Order for such Products shall reflect the Parties’ respective responsibility to the other Party, if any, for the damaged, defective, or otherwise underperforming Products or Ancillary Equipment.

 

6. Prices and Payment.

 

(a) Pricing.

 

(i) The “Product Price” applicable to Products and the services provided by Technical Advisors pursuant to this Agreement shall be as set forth in the table below, as applicable to Bloom Corp or JV, respectively, as supplier. In all cases, the “Product Price” shall be exclusive of taxes and the costs and expenses of Performance Insurance. The Parties will meet to discuss in good faith further updates to the Product Price and will incorporate any further changes to the Product Price in the table set forth below in a further amendment to this Agreement; provided that the price of Energy Server shall not be changed.

 

18

 

 

UNTIL DECEMBER 31, 2022

 

 

  Bloom Corp JV
1 Energy Server $3,560/kW minus (A) minus (B) N/A
2 Component AC + Component FP N/A (A) The Transfer Price applicable to the Component AC + Component FP
3 Company-Required Ancillary Equipment N/A (B) The Transfer Price applicable to the Company- Required Ancillary Equipment
4 Technical Advisory Services (C) $80/kW N/A

 

FROM JANUARY 1, 2023 UNTIL DECEMBER 31, 2023

 

 

  Bloom Corp JV
1 Hot Box $3,430/kW minus (A) minus (B) N/A
2

JV Scope: Hot Box

Integration,

Component AC,
Component FP,

Component PE,

Company-Required

Ancillary Equipment

N/A (A) The Transfer Price applicable to the JV Scope
3 Technical Advisory Services (B) $80/kW N/A

 

FROM JANUARY 1, 2024 UNTIL DECEMBER 31, 2024

 

 

  Bloom Corp JV
1 Hot Box $3,230/kW minus (A) minus (B) N/A
2

JV Scope: Hot Box

Integration,
Component AC,

Component FP,

Component PE,

Company-Required

N/A (A) The Transfer Price applicable to the JV Scope

 

19

 

 

(ii) Product Price Discussion. No later than June 30, 2023, Distributor and Company shall discuss whether an adjustment to the Product Price is appropriate for Projects with Purchase Orders to be executed in 2024, based upon market conditions, technological development, and other relevant factors. If the Parties do not enter into a mutual written amendment to this Agreement (which neither Party shall be under any obligation to conclude), then the above price shall continue to apply to Projects with Purchase Orders executed in 2024.

 

(b) GenCo RFPs. With respect to any Project to be bid into a request for proposals issued by a GenCo, Distributor may demonstrate to Company’s satisfaction, by delivery of a true and complete budget threshold document issued by such GenCo, that lower pricing is required to participate in such RFP. In such case, Company may determine whether to proceed with bidding such Project into the RFP upon lower pricing mutually-agreed with Distributor, or whether not to proceed with such bid. In addition, the Parties shall discuss the principal terms upon which they will participate in such RFP.

 

(c) Invoicing. Company shall invoice Distributor the Product Price applicable to the Products set forth in a Purchase Order as follows:

 

(i)Deposit: ten percent (10%), invoiced upon receipt of a Purchase Order.

 

(ii)Delivery: ninety percent (90%), invoiced upon Delivery of such Products.

 

(d) Payment. Except as expressly provided in this Agreement, payment obligations are non- cancellable, and payments made hereunder shall be irrevocable and non-refundable. Distributor shall pay all invoices by no later than the Invoice Due Date. If Distributor fails to make any payment when due, Company may, at its option and without prejudice to its other remedies, suspend performance, defer delivery or seek remedies available at law or in equity without liability to Company.

 

(e) Taxes. Taxes, duties or excises are not included in the fees charged for the Product, except as may be set forth in the Incoterm applicable to the shipment of such Product, as set forth in Section 7(d)(i)(1). If Company pays any taxes, duties or excises which are not included in the fees charged for the Product, Company shall itemize such taxes, duties or excises as a separate item on its invoices to Distributor, and Distributor shall reimburse Company for such taxes, duties or excises; provided, that Distributor shall not be required to make any such reimbursement if it provides a valid tax exemption certificate to Company prior to Delivery of such Product.

 

(f) Late Payments. Interest shall accrue daily on amounts which are not paid by the Party owing such amount when due pursuant to this Agreement at a rate equal to the lesser of six percent (6%) per year or the highest rate permitted by applicable law (if less than six percent (6%) per year). In the event that any payment to Company due hereunder is overdue, Company reserves the right to suspend performance until such delinquency is corrected.

 

7. Supply of Products.

 

(a) Forecasts. During the Term, Distributor shall provide Company with a good faith rolling twelve (12) month forecast, updated quarterly, for units of the Products (in kW) to be sold by Distributor hereunder during each month in such twelve (12) month period.

 

20

 

 

(b) Purchase Orders. Distributor shall initiate purchases under this Agreement by submitting written purchase orders to Company substantially in the form set forth as Exhibit C (each, a “Purchase Order”). Purchase Orders shall state unit quantities, unit descriptions, requested delivery dates, shipping instructions, and other matters, which shall in each case be subject to the Parties’ mutual agreement. Neither Party shall be obligated to execute a Purchase Order, nor shall any Purchase Order be binding upon either Party until signed by each of Distributor and Company. Once executed by both Parties, Purchase Orders shall be non-cancelable for any reason other than due to a Force Majeure event that causes the cancellation of such Project or in Distributor’s participation in such Project. For the avoidance of doubt, JV shall not have authority to execute Purchase Orders on behalf of Bloom Corp, and Bloom Corp shall not have authority to execute Purchase Orders on behalf of JV. In no event shall Bloom Corp be required to include Company-Required Ancillary Equipment or services performed by Technical Advisors in a Purchase Order for Energy Servers.

 

(c) Packing. All Products shipped by Company to Distributor under this Agreement shall be packaged in accordance with instructions set forth in the applicable Purchase Order.

 

(d) Title; Risk of Loss; Acceptance; and Shipment.

 

(i) Delivery. Title, risk of loss, and acceptance of the Products shall pass from Company to Distributor upon Delivery.

 

(1) “Delivery” shall occur as follows:

 

a. Products Supplied by Bloom Corp: when Products supplied by Bloom Corp arrive at the named destination place in the Republic of Korea as stated in the relevant PO, the Products are “Delivered.”

 

b. Products Supplied by JV: when Products supplied by JV are made available Ex Works at JV’s manufacturing facilities, the Products are “Delivered.”

 

(2) Risk of Loss. The risk of loss specified in Section 7(d)(i)(1)(a) shall govern the Parties’ respective liabilities. As between Company and Distributor, the insurance of Distributor shall be responsible for insurable losses occurring on or after passage of risk of loss from Company to Distributor pursuant to Section 7(d)(i)(1).

 

(e) Product Updates. Company shall have the right to make design modifications to Products from time to time and in its sole discretion, at any time prior to the execution of a Purchase Order for such Product. Following execution of a Purchase Order for a Product, Company shall not, without the prior written consent of Distributor, make design modifications to the Products set forth in such Purchase Order that represent a material change to such Products’ form, fit, or function.

 

21

 

 

8. Marketing and Administration.

 

(a) Independent Contractor. Distributor is an independent contractor, not an employee, agent, or representative of Company. Distributor is not authorized to, and will not attempt to, create or assume any obligation or liability, express or implied, in the name of or otherwise on behalf of Company. Without limiting the generality of the foregoing, Distributor will not enter into any contract, agreement or other commitment, make any warranty or guaranty, or incur any obligation or liability in the name or otherwise on behalf of Company. This Agreement will not be interpreted or construed as creating or evidencing any agency, franchise, association, joint venture or partnership among the Parties.

 

(b) Marketing. Distributor shall market, promote, and distribute the Products in the Territory as Company’s “preferred partner” in the Territory and as otherwise mutually agreed by the Parties. These efforts may include without limitation the use of mailings, advertising, seminars, and other customary marketing techniques. Company will provide support to Distributor for Market development activities, and may choose to engage in marketing activities.

 

(c) Feedback. Distributor shall provide Company with prompt written notification of any comments or complaints about the Products that are made by Customers, and of any problems with the Products or their use that Distributor becomes aware of. Such written notification shall be the property of Company, and shall be considered to be part of Company’s Confidential Information.

 

(d) Audit. Company shall have the right to inspect and audit Distributor’s marketing, use, deployment, and exploitation of the Products for compliance with the terms and conditions of this Agreement.

 

(e) Force Majeure. Neither Party shall be liable under any circumstance, nor be deemed to be in breach of this Agreement, for any delay or failure in performance or interruption of service resulting from Force Majeure. In the case of a delay due to an event of Force Majeure, affected deadlines shall be extended by a period of time equal to the time lost due to Force Majeure.

 

9. Ownership.

 

(a) Proprietary Rights. Company or its Suppliers own all right, title and interest (including without limitation all intellectual property rights), in and to the Products and any modifications or improvements thereto, whether or not made by Company. Distributor acknowledges that the licenses granted under this Agreement do not provide Distributor with title to or ownership of any intellectual property rights contained in or related to the Products, but only a right of limited use under the terms and conditions of this Agreement. Except as expressly set forth in Section 3 and this Section 9, Company reserves all rights and grants Distributor no licenses of any kind hereunder. Distributor hereby assigns to Company all information, including but not limited to feedback or suggestions, provided to Company with respect to the Products, and such information shall be deemed Confidential Information.

 

(b) License Grant. Subject to the terms and conditions of this Agreement, Company grants to Distributor a limited, non-exclusive, non-transferable, royalty-free license to market, sell and offer to sell the Products to Customers within the Market during the Term, including use of all Licensed Material for such purpose (the “Limited License”).

 

22

 

  

(c) Restrictions. The Limited License does not include any rights to, and Distributor shall not (and shall not permit any Customer to) conduct any of the following activities (such activities, the “Prohibited Activities”):

 

(i) Disassemble, decompile or “unlock”, translate, decode or otherwise reverse engineer, or attempt in any manner to reconstruct or discover, any part of the Products or other Licensed Materials;

 

(ii) Modify, adapt, enhance, or create a derivative work of the Products or other Licensed Materials. Only Company shall have the right to modify, adapt, enhance or create a derivative work of the Products or any other Licensed Material;

 

(iii) Use the Licensed Materials to develop or manufacture a product that is similar to Products or other Licensed Materials;

 

(iv) Open the covering, access the interior, or give others the opportunity to open the covering or access the interior, of any Products. Only Company and its authorized representatives may open or access such interior;

 

(v) Copy or remove any proprietary notices, labels, or marks on Licensed Materials without Company’s prior written consent;

 

(vi) Except as expressly permitted by this Agreement, assign, sublicense, distribute, rent, lease, loan, sell, transfer, network, publish, make available, or permit any third party access to the Products or other Licensed Materials;

 

(vii) Develop intellectual property, or help any third party develop intellectual property, which could be asserted against Company’s intellectual property in the Products or other Licensed Materials;

 

(viii) File any action (or directly or indirectly support or be involved in any such action) in any court or agency which in any way attack the validity, enforceability, ownership, or protectability of any intellectual property of Company (including trade secrets), Confidential Information of Company, or other proprietary Company information; or

 

(ix) Cause or permit any third party to do any of the foregoing.

 

(d) Software. Distributor acknowledges that the Software may contain or be provided with copyrighted software of Company’s Suppliers as identified in associated documentation or other printed materials (“Third Party Software”) which is obtained under a license from such Suppliers. All third party licensors and Suppliers retain all right, title and interest in and to such Third Party Software and all copies thereof, including all copyright and other intellectual property rights. Distributor’s use and distribution of any Third Party Software shall be subject to and Distributor shall comply and cause all Customers to comply with the applicable restrictions and other terms and conditions set forth (i) in this Agreement or the Documentation applicable to the Software and (ii) in such Third Party Software documentation or printed materials.

 

23

 

  

(e) Proprietary Notices. Distributor will ensure that all copies of the Products will incorporate copyright and other proprietary notices in the same manner that Company incorporates such notices in the Products or in any manner reasonably requested by Company. Distributor will not remove any copyright or other proprietary notices incorporated on or in the Products by Company.

 

(f) Use of Trademarks. During the term of this Agreement, Distributor may advertise the Products under the trademarks, marks, and trade names that Company may provide from time to time (the “Company Trademarks”). Distributor understands that Company has applied for applicable federal and state registration of certain of its trademarks and agrees, upon Company’s request, to so indicate on the Products and in any advertisement, promotional materials or other documents that contain the Products’ names. Nothing herein will grant to Distributor any right, title or interest in Company Trademarks. At no time during or after the term of this Agreement will Distributor challenge or assist others to challenge Company Trademarks or the registration thereof or attempt to register any trademarks, marks or trade names confusingly similar to those of Company. Distributor will follow reasonable trademark usage guidelines communicated by Company, will provide examples of its usage of Company Trademarks upon request by Company, and will promptly correct any deviations from such guidelines upon notification by Company of such deviations.

 

(g) Use of Trade Names. Distributor will present and promote the sale of the Products fairly. Distributor may represent itself as an authorized Distributor of Company and use Company’s product names in Distributor’s advertising and promotional media provided (i) that Distributor conspicuously indicates in all such media that such names are trademarks of Company and (ii) that Distributor submits all such media to Company for prior approval and satisfies the requirements set forth in paragraph (c) above. Upon termination of this Agreement for any reason, Distributor will immediately cease all use of the Products’ names and Company Trademarks and, at Distributor’s election, destroy or deliver to Company all materials in Distributor’s control or possession which bear such names and trademarks, including any sales literature. Distributor will not challenge any intellectual property rights claimed by Company in such trademarks.

 

(h) Use of Marketing Materials. Company may provide Distributor with marketing materials, such as marketing literature, Company logos, and/or artwork, as Company may determine in its sole discretion (the “Marketing Materials”). Company hereby grants Distributor permission to use, reproduce, translate, and distribute the Marketing Materials solely in connection with Distributor’s distribution of Products hereunder. Distributor hereby assigns to Company all intellectual property rights in any and all translations of the Marketing Materials. Upon termination of this Agreement for any reason, Distributor will immediately cease all use of the Marketing Materials and, at Distributor’s election, destroy or deliver to Company all Marketing Materials in Distributor’s control or possession.

 

24

 

 

10. Confidentiality.

 

(a) Confidential Information. During the period this Agreement is in effect and for ten (10) years thereafter, the Parties shall hold Confidential Information of the other Party in confidence and use the same degree of care, but in no event less than reasonable care, to avoid disclosure of Confidential Information as it uses with respect to its own confidential and proprietary information of similar type and importance. The receiving Party agrees to disclose Confidential Information only to its employees or other agents who have a bona fide need to know solely to perform its obligations or exercise its rights hereunder, who will each agree to comply with this section. The receiving Party shall not sell, license, sublicense, publish, display, distribute, disclose or otherwise make available the Confidential Information to any third party nor use such information except as authorized by this Agreement. The receiving Party shall immediately notify the disclosing Party of the unauthorized disclosure or use of the Products or Confidential Information and to assist Company in remedying such unauthorized use or disclosure. It is further understood and agreed that any breach of this Section 10 or Section 9(c) is a material breach of this Agreement and any such breach would cause irreparable harm to the disclosing Party, entitling the disclosing Party to injunctive relief in addition to all other remedies available at equity or law. Notwithstanding the above, non-public information contained in an RFP and the prices hereunder shall be Confidential Information of both Parties.

 

(b) Exceptions. Notwithstanding the above, receiving Party shall be under no obligation not to disclose any information that it can prove: (i) was in the public domain at the time it was disclosed or has entered the public domain through no fault of the receiving Party; (ii) was known to the receiving Party, without restriction, at the time of disclosure, as demonstrated by files in existence at the time of disclosure; (iii) is disclosed with the prior written approval of the disclosing Party; (iv) becomes known to receiving Party, without restriction, from a source other than the disclosing Party without breach of this Agreement by receiving Party; or (v) is disclosed pursuant to the order or requirement of a court, administrative agency, other governmental body, or the requirements of a public stock exchange; provided, however, that receiving Party shall provide prompt notice thereof to disclosing Party to enable disclosing Party to seek a protective order or otherwise prevent or restrict such disclosure.

 

11. Indemnification.

 

(a) Intellectual Property Indemnification.

 

(i) Company shall indemnify, defend and hold Distributor harmless against any third party action (including a Customer) alleging that the Products infringe any valid U.S. patent or copyright, and Company shall pay all settlements entered into, and all final judgments and costs (including reasonable attorneys’ fees) awarded against Distributor in connection with such action, provided Distributor (i) notifies Company promptly in writing of any such action, (ii) gives Company exclusive control and authority over the defense or settlement of such action, (iii) does not enter into any settlement or compromise of any such action without the prior written consent of Company and (iv) provides all reasonable assistance to Company at the request and expense of Company. If any Licensed Material becomes, or in the opinion of Company may become, the subject of an infringement claim, Company may, at its option, (i) procure for Distributor the right to continue using such Licensed Material, (ii) modify or replace such Licensed Material with substantially equivalent non- infringing products, or (iii) require the return of such Licensed Material and refund to Distributor a pro-rata portion of the Product Price of such Licensed Material on a depreciated basis, without depreciation for the first year after achievement of Commissioning, and thereafter on a straight line amortization of the Product Price equal to the term of the LTSA (e.g. nineteen year amortization for a twenty-year LTSA); with the provision of remedies pursuant to this Section 11(a)(i) being the sole and exclusive remedies for an infringement claim subject to this Section 11(a).

 

25

 

 

(ii) Company shall have no indemnification obligations with respect to any third party action alleging that (i) the use of any Products, or any part of them, in combination with products or technology not supplied by Company, or (ii) any service or other process utilizing any Products, infringes any third party intellectual property right, and in such event Distributor will indemnify, defend and hold harmless Company, and its officers, directors and employees, against any such action, and Distributor will pay all settlements entered into, and all final judgments and costs (including reasonable attorneys’ fees) awarded against such party in connection with such action, provided Company (i) notifies Distributor promptly in writing of any such action, (ii) gives Distributor exclusive control and authority over the defense or settlement of such action, (iii) does not enter into any settlement or compromise of any such action without Distributor’s prior written consent and (iv) provides all reasonable assistance to Distributor at the request and expense of Distributor.

 

(b) Mutual Indemnification. Except as otherwise set forth in this Agreement, each Party (such Party providing indemnification, the “Indemnifying Party”) shall indemnify, defend and hold harmless the other Party and its affiliates, and each of their respective directors, officers, members, shareholders, employees and contractors (collectively, the “Indemnified Parties”), from and against all third party (not including affiliates, third party beneficiaries, or persons with an equity or security interest the Indemnified Party or its assets) claims, demands, actions, causes of action, and proceedings (“Claims”) for injury or death of any person or loss or damage to property, in each case to the extent caused by the Indemnifying Party’s gross negligence or willful misconduct; provided, that the Indemnified Party shall provide the Indemnifying Party prompt notice of any such Claim, authorize the Indemnifying Party to settle or defend such Claim, provide the Indemnifying Party control of the defense of such Claim, and assist such defense (at the Indemnifying Party’s reasonable expense) upon request of the Indemnifying Party. Notwithstanding the foregoing, an Indemnifying Party shall not be required to indemnify, defend or hold harmless for any Claim arising out of the negligence, willful misconduct or breach of this Agreement by the Indemnified Party. The provision of remedies pursuant to this Section 11(b) are the sole and exclusive remedies for an indemnification claim subject to this Section 11(b).

 

12. Limited Warranties. EXCEPT AS EXPRESSLY PROVIDED PURSUANT TO THE PRE- COMMISSIONING COMPLETION WARRANTY SET FORTH IN SECTION 4(b) AND SECTION 5 HEREIN, THE PRODUCTS ARE PROVIDED “AS IS”, AND COMPANY AND ITS SUPPLIERS MAKE NO WARRANTY, EXPRESS, IMPLIED, STATUTORY OR OTHERWISE, WITH RESPECT TO PRODUCTS OR ANY PART THEREOF, INCLUDING WITHOUT LIMITATION ANY IMPLIED WARRANTY OF TITLE, MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, NONINFRINGEMENT, OR THOSE ARISING FROM COURSE OF PERFORMANCE, DEALING, USAGE OR TRADE. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, NEITHER COMPANY NOR ANY OF ITS SUPPLIERS WARRANT THAT THE PRODUCTS OR ANY PART THEREOF WILL MEET DISTRIBUTOR’S REQUIREMENTS OR BE UNINTERRUPTED, OR ERROR-FREE, OR THAT ANY ERRORS IN THE PRODUCTS WILL BE CORRECTED.

 

26

 

 

13. Term and Termination.

 

(a) The term of this Agreement shall commence on the Effective Date and terminate on December 31, 2024 (the “Initial Term”). Thereafter, this Agreement shall be renewed automatically for three (3) year renewal terms (each a “Renewal Term”), unless not extended by either Party pursuant to the following sentence (the Initial Term and any Renewal Term, together, the “Term”). Commencing six (6) months prior to the expiration of the Initial Term or any Renewal Term, the Parties shall discuss whether to extend the Term for the immediately succeeding Renewal Term, upon mutually-agreed terms; provided, that if the annual target established pursuant to Section 2(e) for the concluding year has been satisfied, neither Party may prevent the Term for extending for the immediately succeeding Renewal Term. During each such six (6) month period, neither Party may terminate this Agreement. Subject to the foregoing, if the annual target for the concluding year has not been satisfied, then upon the conclusion of such six (6) month period, either Party may, without liability, terminate this Agreement by written notice to the other Party, with such termination to become effective upon the expiration of such calendar year (without renewal).

 

(b) Termination for Cause. Except as set forth in the last sentence of this Section 13(b), if either Party defaults in the performance of any material provision of this Agreement, then the non- defaulting Party may give written notice to the defaulting Party that if the default is not cured within thirty (30) days this Agreement will be terminated. If the non-defaulting Party gives such notice and the default is not cured during the thirty-day period, then this Agreement shall automatically terminate at the end of that period. Notwithstanding the foregoing, if Distributor breaches the provisions of Section 9 hereof, then the Company shall be entitled to terminate this Agreement effective immediately upon delivery of written notice to Distributor.

 

(c) Termination for Insolvency and Related Events. This Agreement shall terminate, without notice, (i) upon the institution by or against either Party of insolvency, receivership or bankruptcy proceedings or any other proceedings for the settlement of such Party’s debts, (ii) upon either Party’s making an assignment for the benefit of creditors, or (iii) upon either Party’s dissolution or ceasing to do business.

 

(d) Effect of Termination. Purchase orders and services contracted during the Term shall survive the expiration or earlier termination of this Agreement. Subject to the foregoing, if this Agreement is terminated, then all of Distributor’s rights and licenses with respect to the Products shall terminate, provided that each Customer license granted in accordance with this Agreement shall survive in accordance with its terms, subject to termination for default in accordance with its terms. Upon termination, Distributor must destroy any and all promotional literature, price quotations, order forms, data, information and other items received by Distributor from Company in connection with this Agreement.

 

(e) Limitation of Liability. In the event of termination by either Party in accordance with any of the provisions of this Agreement, neither Party shall be liable to the other, because of such termination, for compensation, reimbursement or damages on account of the loss of prospective profits or anticipated sales or on account of expenditures, inventory, investments, leases or commitments in connection with the business or goodwill of either Party. Termination shall not, however, relieve either Party of any obligations incurred prior to the termination, including, without limitation, i) the obligation of Distributor to pay Company for Products purchased prior to such termination or ii) the obligation of Company to provide purchased Products to Distributor.

 

27

 

  

(f) Survival of Certain Terms. The provisions of Sections 1 and Sections 9-13, and Section 17-18 of this Agreement, and all payment obligations incurred during the term of this Agreement, shall survive the expiration or termination of this Agreement for any reason. All other rights and obligations of the parties shall cease upon termination of this Agreement.

 

14. Import and Export Requirements. Distributor shall, at its own expense, pay all import and export licenses and permits, customs charges and duty fees, if any, and shall take all other actions, if any, required to accomplish the export and import of the Products purchased by Distributor. The Products are specifically subject to U.S. Export Administration Regulations. Distributor agrees to strictly comply with all export, re-export and import restrictions and regulations of the Department of Commerce or other agency or authority of the United States or the Territory or other applicable countries, and not to transfer, or authorize the transfer of, directly or indirectly, the Products or any direct product thereof to a prohibited country or otherwise in violation of any such restrictions or regulations. Distributor agrees to ensure that the Products provided hereunder are only installed in the Territory. Distributor’s failure to comply with this Section is a material breach of this Agreement.

 

15. Compliance with Laws; Business Practices.

 

(a) Each Party shall comply with, and ensure that its contractors and employees comply with, all laws and regulations of the United States and all other jurisdictions in which such Party carries out activities under or related to this Agreement, including laws prohibiting bribery and other unethical business practices. Without limitation, the Parties’ performance of this Agreement shall comply with including, but not limited to the Foreign Corrupt Practices Act of 1977 of the United States and, as applicable, the Improper Solicitation and Graft Act (Kim Young Ran Act), and, all other applicable anti-corruption legal requirements and with all applicable embargo and other economic sanctions legal requirements.

 

(b) Notwithstanding any provisions herein to the contrary, each Party shall indemnify, defend and hold harmless the other Party and its officers, directors, affiliates, employees and representatives from and against any claim, loss, damages, liability, expense or cost of whatever nature, including reasonable attorneys’ fees and costs, arising out of or related to such Party’s or its employee’s or agent’s failure to comply with applicable law as provided in this Section 15(a) or the terms and conditions of Section 15(c). The obligation of each Party under this Section 15 shall survive the termination or expiration of this Agreement. Any breach or threatened breach of Section 15(a) and Section 15(c) by a Party shall give the other Party the immediate right to terminate this Agreement.

 

(c) Anti-Bribery and Anti-Corruption.

 

(i) Representations and Warranties.

 

(1) Distributor represents, warrants and covenants to Company that it will comply with, and shall ensure that its stockholders, directors, officers, employees, agents, representatives, and contractors (including Permitted Subcontractors) comply with, the U.S. Foreign Corrupt Practices Act of 1977 (“FCPA”), as amended (15 U.S.C. §§78dd-1 et seq.), and other applicable anti-corruption laws and regulations applicable to a Party in carrying out the activities or related to this Agreement (“Anti-Corruption Laws”).

 

28

 

 

(2) Distributor represents, warrants and covenants to Company that neither it nor any of its stockholders, directors, officers, employees, agents, representatives, or its contractors (including Permitted Subcontractors), has made, offered, promised or authorized or will make, offer, promise or authorize, in connection with the sale of the Products or other performance contemplated in this Agreement, any payment or transfer of anything of value, directly or indirectly, to any person for the purpose of influencing any act or decision of such person or securing an improper advantage to assist Company or its affiliates in obtaining or retaining business in connection with this Agreement.

 

(ii) Annual Certification. Distributor agrees that it will, at the request of Company (but no more than once per calendar year), provide Company with a certification in the form hereto attached and incorporated by reference as Exhibit F.

 

(iii) Training. Distributor agrees that it will cause each person who is involved in carrying out the activities under this Agreement (including without limitation stockholders, directors, officers, employees, agents and representatives, if such persons are involved in carrying out activities under this Agreement) to participate in training related to compliance with Anti-Corruption Laws, such training of which shall consist of such persons taking part in the anti-corruption training program of the Company in Korea or on-line (in which case Korean subtitles shall be prepared and provided by the Company).

 

(iv) Audit Rights. For the purpose of allowing Company to monitor Distributor’s compliance with this Section 15 and/or any Anti-Corruption Laws, the Company shall have the right to conduct an investigation or audit, or have its authorized representatives conduct an investigation or audit of Distributor’s fuel cell business related books, records, and other documentation relevant to Distributor’s activities under this Agreement, to verify compliance with this Section 15 and with Anti-Corruption Laws. Distributor shall cooperate with such investigation or audit, which shall be conducted through the review of information and materials provided by Distributor at the request of the Company to which is relevant to verification of compliance with this Section 15 or with Anti- Corruption Laws, and Distributor shall grant Company the ability to conduct interviews and Q&A sessions with persons relevant to such audit. Distributor shall cooperate with information and materials requested by the person conducting the audit under this Section.

 

(v) Notice of Breach. Distributor agrees that, should it learn or have reason to know of (a) any payment or transfer of anything of value or any offer, promise or authorization of any payment or transfer of anything of value to any person for the purpose of obtaining or retaining business or securing any improper advantage for or on behalf of Company or its affiliates; or (b) any other development during the term of this Agreement that in any way makes inaccurate or incomplete any representation, warranty or covenant in this Section 15, Distributor will immediately advise Company of such knowledge and the basis known to Distributor related to such knowledge.

 

29

 

 

(vi) Relationships to Officials.

 

(1) During the Term, Distributor represents, warrants, and covenants that it is not and shall not become, and that none of Distributor’s directors, officers, employees, agents and representatives are an employee or officer of a government of any country, including any federal, regional or local department , agency or enterprise owned or controlled by the government; an employee or officer of a political party (for the avoidance of doubt, excluding memberships in any political party); an employee or officer of a public international organization (for the avoidance of doubt, excluding industry related associations and foundations); or a candidate for political office.

 

(2) Distributor shall implement a program to cause its directors, officers, employees, agents and representatives who are involved in carrying out the performance of this Agreement to notify Distributor if any immediate family member of such person is an employee or officer of a government of any country, including any federal, regional or local department, agency or enterprise owned or controlled by the government; an employee or officer of a political party (for the avoidance of doubt, excluding membership is any political party); an employee or officer of a public international organization (for the avoidance of doubt, excluding industry related associations and foundations); or a candidate for political office. Distributor shall, on a quarterly basis, notify Company of the results of such program, and identify the persons who have notified Distributor of the fact that such person’s immediate family member(s) is holding such position(s), and the position(s) that is held by such family member(s).

 

(vii) Meetings with Government Officials; Reports. Each Party understands and acknowledges that Distributor may meet with government officials in connection with the performance of this Agreement. In the event that Distributor proposes to meet with any government official(s) with the title of director (kwa jang) or higher in connection with the performance of this Agreement, Distributor shall provide prior notice to the Company of such proposed meeting, including the name(s) and title of the government officials and a description of the meeting agenda and shall invite the Company to attend all such meetings. In the event the Company decides not to attend or unable to attend such meetings, Distributor shall provide promptly a summary of each such meeting, including the name and title of the attendees to the Company.

 

(d) Breach and Remedy.

 

(i) Non-Curable Breach. Distributor’s breach of Section 15(a) or Section 15(c)(i) constitutes a non-curable breach of this Agreement. In the event of Distributor’s breach of Section 15(a) or Section 15(c)(i), Company shall have the right, exercisable immediately upon written notice to Distributor, to terminate this Agreement, and Company’s obligations to Distributor shall be immediately terminated, including without limitation payment of fees (provided, that any and all fees that are accrued and not paid as of the date of termination shall become due and payable as of the date of termination).

 

(ii) Curable Breach. Distributor’s breach of Section 15(b) or any subsection of Section 15(c) other than Section 15(c)(i), if remaining uncured twenty (20) days after written notice from Supplier, shall constitute a breach of this Agreement. In the event of Distributor’s breach of Section 15(b) or any subsection of Section 15(c) other than Section 15(c)(i) remains uncured after such period, Distributor shall have the remedies set forth in Section 15(d)(iv).

 

30

 

 

(iii) Other Variations. In the event that a Party violated Anti-Corruption Laws prior to the Effective Date of the Joinder and Amendment No. 3 to the PDA, dated April 17, 2020, or violates Anti-Corruption Laws and such violation is not in connection with this Agreement, then the non-violating Party shall have the remedies set forth in Section 15(d)(iv).

 

(iv) Consequences of Curable Breaches and Other Violations.

 

(1) In the event that Distributor breaches this Agreement in the manner set forth in Section 15(d)(ii), or a Party violates Anti-Corruption Laws in the manner set forth in Section 15(d)(iii), and such breach or violation has an adverse impact on the non-defaulting Party (as determined by the non-defaulting Party in its discretion), each Party shall use reasonable commercial efforts to work together to avoid exercising any of the remedies set forth in Section 15(d)(iv)(2) (including through taking actions that can address the adverse impact on the non-defaulting Party); provided, that this will not in any way limit the right of the non-breaching or non-violating Party to ultimately exercise the remedies set forth in Section 15(d)(iv)(2) if the adverse impact is not able to be addressed (as determined by the non-breaching or non-violating Party in its discretion).

 

(2) If the Parties’ efforts to address the adverse impact to the non- breaching or non-violating Party pursuant to Section 15(d)(iv)(1) have been unsuccessful (as determined by the non-breaching or non-violating Party in its discretion), then the remedies set forth in this Section 15(d)(iv)(2) shall be available to such Party. The election between Options 1-3 (as defined below in this Section 15(d)(iv)(2)) shall be mutually decided by the Parties, but if the Parties do not reach agreement, then the non-breaching or non-violating Party shall retain the right to terminate this Agreement set forth in as Option 3, below. For the avoidance of doubt, termination of this Agreement shall be the last resort of the Parties after taking efforts pursuant to Section 15(d)(iv)(1) and considering Option 1 and Option 2, below; provided, that this will not in any way limit the right of the non-breaching or non-violating Party to ultimately exercise the termination remedy set forth in Option 3 if the adverse impact is not able to be addressed (as determined by the non-breaching or non-violating Party in its discretion).

 

Option 1”: Suspend each Party’s respective ROFR until such time as such breach or violation no longer has an adverse impact on the non-breaching or non-violating Party (as determined by the non-defaulting Party in its discretion).

 

Option 2”: If Distributor is the defaulting Party, to assign this Agreement from Distributor to an affiliate of Distributor which is not involved (directly or indirectly) in such breach or violation; provided, than such assignment (a) does not pose an adverse impact to Company (as determined in Company’s discretion); and (b) is subject to Company’s prior written consent in accordance with Section 18(c); such consent not to be unreasonably withheld.

 

Option 3”: The non-breaching or non-violating Party may terminate this Agreement terminate this Agreement immediately upon written notice.

 

31

 

  

16. Export Compliance. Distributor shall not export, re-export, resell, ship or divert directly or indirectly any portion of the Products or other technical information supplied hereunder in any form, including without limitation any technical data furnished hereunder, to any country except as the laws of the United States of America expressly permit, or for which an export license or other governmental approval is required, without first obtaining such license or approval. This obligation shall survive any termination of this Agreement.

 

17. Limitation of Liability.

 

(a) NEITHER COMPANY NOR DISTRIBUTOR SHALL BE LIABLE TO THE OTHER BY REASON OF LOSS OF PROFITS, OR FOR ANY SPECIAL, CONSEQUENTIAL, INCIDENTAL, PUNITIVE OR INDIRECT DAMAGES (OR DIRECT DAMAGES IN THE CASE OF THE SUPPLIERS) ON ANY THEORY OF LIABILITY, WHETHER IN CONTRACT, TORT (INCLUDING WITHOUT LIMITATION NEGLIGENCE), STRICT LIABILITY OR OTHERWISE ARISING OUT OF OR UNDER THIS AGREEMENT OR ANY USE OR INABILITY TO USE THE PRODUCTS OR EQUIPMENT, OR FOR BREACH OF THIS AGREEMENT. EACH PARTY’S TOTAL LIABILITY ARISING OUT OF OR UNDER THIS AGREEMENT, OR FOR BREACH OF THIS AGREEMENT, WHETHER IN CONTRACT, TORT (INCLUDING WITHOUT LIMITATION NEGLIGENCE), STRICT LIABILITY OR OTHERWISE, SHALL NOT EXCEED FOR ANY PURCHASE ORDER THE CONTRACT AMOUNT PURSUANT TO SUCH PURCHASE ORDER, PROVIDED, HOWEVER, THAT NOTWITHSTANDING THE FOREGOING, COMPANY’S LIABILITY FOR PAYMENT OF A REFUND AMOUNT PURSUANT TO SECTION 4(b)(ii) SHALL NOT BE SUBJECT TO SUCH LIMITATION, BUT IN NO EVENT SHALL COMPANY’S LIABILITY FOR PAYMENT OF A REFUND AMOUNT EXCEED THE APPLICABLE REFUND CAP.

 

(b) Notwithstanding the limitations of liability set forth in Section 17(a), such limitations of liability shall not apply to or limit in anyway any liability of Distributor or Company (i) arising from fraud or willful misconduct or gross negligence of such Party; or (ii) in respect of any obligation of such Party to indemnify for third party claims pursuant to Section 11 (including without limitation in respect of costs and expense incurred by the indemnified Party in respect of such third party claim).

 

(c) Liability of Bloom Corp and JV. Notwithstanding any other provision of this Agreement to the contrary, the duties and obligations of Bloom Corp and JV under this Agreement are several and not joint, and neither Bloom Corp nor JV shall be liable for the duties or obligations of the other Party arising as “Company” hereunder. Except with respect to Bloom Corp’s right to exercise the Company ROFR pursuant to Section 2(a), the rights of Bloom Corp and JV shall be several, and neither Bloom Corp nor JV shall have the authority to waive or exercise any right on behalf of the other Party acting as “Company” hereunder.

 

32

 

 

18. General.

 

(a) Governing Law. This Agreement is governed and interpreted in accordance with the laws of the State of California and the United States of America without reference to conflicts of laws principles and excluding the United Nations Convention on Contracts for the Sale of Goods.

 

(b) Dispute Resolution.

 

(i) All controversies, claims, disputes or difference in connection with this Agreement shall be finally settled by arbitration administered by the Korean Commercial Arbitration Board (“KCAB”) in accordance with the International Arbitration Rules of the KCAB. The venue of arbitration proceedings and seat of arbitration shall be Seoul, the Republic of Korea.

 

(ii) The number of arbitrators shall be three, with Company and Distributor nominating one arbitrator each and the two arbitrators shall jointly nominate the third arbitrator.

 

(c) Assignment. Distributor shall not transfer, assign or delegate this Agreement or any rights or obligations hereunder, whether voluntarily, by operation of law or otherwise, without the prior written consent of Company. Subject to the foregoing, the terms and conditions of this Agreement shall be binding upon and inure to the benefit of the parties to it and their respective heirs, successors, assigns and legal representatives.

 

(d) Publicity. No public release or announcement concerning the transactions contemplated hereby shall be issued by any Party without the prior written consent of the other Parties (which consents shall not be unreasonably withheld, conditioned or delayed), except for any such release or announcement as may be required by securities law or other applicable law or the applicable rules or regulations of any securities exchange or securities market, in which case the disclosing Party shall (to the extent permissible under applicable law) allow the other Parties, as applicable, reasonable time to comment on such release or announcement in advance of such issuance and the disclosing party shall consider the other Parties’ comments in good faith.

 

(e) Merger, Modification and Waiver. This Agreement constitutes the entire agreement between Company and Distributor with respect to the subject matter hereof, and merges all prior negotiations and drafts of the parties with regard thereto. No modification of or amendment to this Agreement, nor any waiver of any rights under this Agreement, by Company shall be effective unless in writing. If there is any conflict between the terms and conditions of this Agreement and the terms and conditions of any Purchase Order or other document, the terms and conditions of this Agreement shall prevail; provided, that if a specific provision of a Purchase Order expressly states that it prevails in the event of conflict with the terms and conditions of this Agreement, then such specific provision of such Purchase Order shall prevail. The waiver of one breach or default or any delay in exercising any rights shall not constitute a waiver of any subsequent breach or default.

 

(f) Severability. If any of the provisions of this Agreement is held by a court of competent jurisdiction to be invalid or unenforceable under any applicable statute or rule of law, it shall be replaced with the valid provision that most closely reflects the intent of the parties and the remaining provisions shall continue in full force and effect.

 

33

 

 

(g) Notices. All notices permitted or required under this Agreement shall be in writing and shall be delivered in person; by courier, overnight delivery, or confirmed fax; or mailed by first class, registered or certified mail, postage prepaid, to the address of the Party specified in this Agreement or such address as either Party may specify in writing. Such notice shall be deemed to have been given upon receipt.

 

  Bloom Corp
   
  Bloom Energy Corporation
   
  4353 North First Street
  San Jose, CA 95134
   
  Attn: Shawn Soderberg, General Counsel
  Email: Shawn.Soderberg@bloomenergy.com
   
  JV
   
  Bloom SK Fuel Cell, LLC
   
  1-Dong, 225,
  Suchul-Daero (Gongdan-Dong 188-8)
  Gumi-Si, Gyeongsangbuk-do, 39270, Korea
   
  Attn: Randy Ahuja
  Email: Randy.Ahuja@bloomenergy.com
   
  Distributor
   
  SK ecoplant Co., Ltd.
   
  19, Yulgok-ro 2-gil, Jongno-gu
  Seoul 03143, Korea
   
  Attn: Wang Jae Lee, Head of Hydrogen Business Center
  Email: justinwlee@sk.com

 

 

(h) Counterparts. This Agreement may be executed in any number of separate counterparts and delivered by electronic means (including in Portable Document Format (.PDF) and digital signature formats such as DocuSign), each of which shall be deemed an original and all of which together shall constitute one instrument.

 

(i) Advice of Legal Counsel. Each Party acknowledges and represents that, in executing this Agreement, it has had the opportunity to seek advice as to its legal rights from legal counsel and that the person signing on its behalf has read and understood all of the terms and provisions of this Agreement. This Agreement shall not be construed against any Party by reason of the drafting or preparation thereof.

 

34

 

 

IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their duly authorized representatives as of the date first written above.

 

  BLOOM CORP
  BLOOM ENERGY CORPORATION
     
  By:   /s/ Gregory Cameron
  Name:  Gregory Cameron
  Title: Chief Financial Officer
     
  JV  
  BLOOM SK FUEL CELL, LLC
     
  By:  
  Name: Randy Ahuja
  Title: Chief Executive Officer
     
  DISTRIBUTOR
  SK ECOPLANT CO., LTD.
     
  By:    
  Name: Wang Jae Lee
  Title: Head of Hydrogen Business Center

 

35

 

 

IN WITNESS WHEREOF, the Parties have caused this Agreement co be executed by their duly authorized representatives as of the date first written above.

 

  BLOOM CORP
  BLOOM ENERGY CORPORATION
     
  By:    
  Name: Gregory Cameron
  Title: Chief Financial Officer
     
  JV
  BLOOM SK FUEL CELL, LLC
     
  By: /s/ Randy Ahuja
  Name: Randy Ahuja
  Title: Chief Executive Officer
     
  DISTRIBUTOR
  SK ECOPLANT CO., LTD.
     
  By:  
  Name:  Wang Jae Lee
  Title: Head of Hydrogen Business Center

 

36

 

  

IN WITNESS WHEREOF, the Parties have caused this Agreement co be executed by their duly authorized representatives as of the date first written above.

 

  BLOOM CORP
  BLOOM ENERGY CORPORATION
     
  By:    
  Name:  Gregory Cameron
  Title: Chief Financial Officer
     
  JV  
  BLOOM SK FUEL CELL, LLC
     
  By:    
  Name: Randy Ahuja
  Title: Chief Executive Officer
     
  DISTRIBUTOR
  SK ECOPLANT CO., LTD.
     
  By: /s/ Wang Jae Lee
  Name: Wang Jae Lee
  Title: Head of Hydrogen Business Center

 

37

 

  

EXHIBIT A

 

COMPANY-REQUIRED ANCILLARY EQUIPMENT

 

1.Mechanical installation kit
2.Electrical installation kit
3.Plumbing installation kit
4.Telemetry cabinet
5.Water Distribution Module
6.Water Distribution Module installation kit
7.Cosmetic side panels
8.Cosmetic rear panels (if systems not installed back-to-back)
9.Forklift cover panels
10.Varmint protection kit
11.Signage kit
12.Installation alignment fixture

 

38

 

  

EXHIBIT B

 

PERMITTED SUBCONTRACTORS

 

Machinery/Piping:

 

-연합개발㈜ Yeonhab Development Co., Ltd.
-강우기업㈜ Kangwu Engineering & Construction Co., Ltd.
-대성기공 Daesung Co., Ltd.
-㈜동부 Dong Bu Co., Ltd.

 

Electrical/Instrument:

 

-㈜피앤케이파워시스 P&K Powersys Co., Ltd.
-㈜민성 Minsung Co., Ltd.
-금양산업개발㈜ Kumyang Electric Co., Ltd.

 

39

 

 

EXHIBIT C

 

FORM OF PURCHASE ORDER

 

[To be agreed in writing by the Parties.]

 

[Signatures Follow]

 

IN WITNESS WHEREOF, the Parties have caused this Purchase Order to be executed by their duly authorized representatives.

 

PROPOSED:

SK ECOPLANT CO., LTD.

 

ACCEPTED:

BLOOM ENERGY CORPORATION

     
Signature:   Signature:
     
     

Name:

 

Name:

     
     

Title:

 

Title:

     
     

Date:

 

Date:

     

 

40

 

 

EXHIBIT D

 

FORM OF NOTICE OF COMMISSIONING COMPLETION

 

   Installation Information and Notice of Acceptance

 

Customer: {Insert Contract Customer Name}
   
Customer Address:   {Insert Site Address}
  {Insert City, State, Zip}
     
Site Address:   {Insert Site Name (Site ID)}
  {Insert Site Address}
  {Insert City, State, Zip}

 

Bloom Energy Sales Order Number: ____________________

 

Installation Information

 

Product Serial Number Shipment Date Installation Complete Date Full Power Date
         

  

   Acceptance Details

 

By signing below, Bloom Energy represents that the Product in aggregate at the installation Site has passed the following Commissioning tests:

 

Test Name Date Status
Electrical Tie In Connection   Complete
Commissioning Complete   Complete
System Startup   Complete
Permission to Operate   Complete
Full Power Date   Complete

  

41

 

 

Bloom Energy Corporation

 

_______________________________
Signature

 

_______________________________
Name

 

_______________________________
Date

 

42

 

 

EXHIBIT E

 

BENCHMARK COST TEMPLATE

 

Systems
(100kW)

Component FP Installation Kits Water Distribution Module ("WDM") Telemetry
         

 

Benchmark Cost Data:

 

Cost
Category
Material Freight Labor Manufacturing Overhead Total
($/unit)

Component

FP

         

Installation

Kits

         
WDM          
Telemetry          
Total          

 

Cost

Category

Material Freight Labor

Manufacturing

Overhead

Total

($/quarter)

Total

($/kW)

Component

FP

           

Installation

Kits

           
WDM            
Telemetry            
Total            

 

43

 

  

EXHIBIT F

 

FORM OF COMPLIANCE CERTIFICATION

 

SK ecoplant Co. Ltd (“Distributor”), Bloom Energy Corporation (“Bloom Corp”) and Bloom SK Fuel Cell, Ltd. (JV) have entered into that certain Amended and Restated Preferred Distributor Agreement, dated as of [ ], 2021 (as amended, amended and restated, supplemented or modified from time to time, the A&R PDA”). Capitalized terms used herein and not otherwise defined herein shall have the meanings ascribed to such terms in the A&R PDA.

 

The undersigned certifies, in its capacity as [TITLE] of Distributor, and on behalf of Distributor for the benefit of Company, that:

 

(a) As of the date hereof, the undersigned is an officer of Distributor with responsibility for assuring that Distributor complies with the certifications set forth herein.

 

(b) From November 14, 2018 to the date hereof, none of Distributor, its stockholders, its directors, its officers, its employees, its representatives or its agents have (a) made, offered, promised or authorized, in connection with the sale of Products or other performance contemplated in the A&R PDA, any payment or transfer anything of value, directly or indirectly, to any person for the purpose of influencing any act or decision of such person or securing an improper advantage in connection with any activity arising from the performance of the A&R PDA; or (b) otherwise violated any Anti- Corruption Laws (as defined in the A&R PDA) in connection with any activity in the performance of the A&R PDA.

 

(c) As of the date hereof, the undersigned is not aware of any activities by Distributor or any of its stockholders, its directors, its officers, its employees, its representatives, or its agents that constitutes a violation of Section 15 of the A&R PDA (or subsections thereof).

 

Distributor covenants that, should the undersigned learn of any matter that would cause the certifications set forth above to become untrue or materially misleading, the undersigned shall immediately advise the General Counsel of Bloom Corp and the Representative Director of JV.

 

  DISTRIBUTOR
   
  SK ECOPLANT CO., LTD.
     
  By:  
  Name: [_]
  Title: [_]
  Date: [_]

 

 

44