Document

TERMS OF LEASE

DESCRIPTION

2.2 Premises:

207,066 rentable square feet of space, comprised of (A) 19,060 rentable square feet of space on the fourteenth (14^th) floor of the Building and commonly known as Suite 1400 (the “Phase I Premises”); and (B) 188,006 rentable square feet of space, comprised of (i) 23,289 rentable square feet of space on the fourth (4^th) floor of the Building and commonly known as Suite 400; (ii) 23,289 rentable square feet of space on the fifth (5^th) floor of the Building and commonly known as Suite 500; (iii) 23,289 rentable square feet of space on the sixth (6^th) floor of the Building and commonly known as Suite 600; (iv) 23,289 rentable square feet of space on the seventh (7^th) floor of the Building and commonly known as Suite 700; (v) 19,039 rentable square feet of space on the eighth (8^th) floor of the Building and commonly known as Suite 800; (vi) 19,039 rentable square feet of space on the ninth (9^th) floor of the Building and commonly known as Suite 900; (vii) 19,039 rentable square feet of space on the tenth (10^th) floor of the Building and commonly known as Suite 1000; (viii) 19,039 rentable square feet of space on the eleventh (11^th) floor of the Building and commonly known as Suite 1100; and (ix) 18,694 rentable square feet of space on the fifteenth (15^th) floor of the Building and commonly known as Suite 1500 (collectively, the “Phase II Premises”). The Phase I Premises and the Phase II Premises, as further depicted on Exhibit A to this Lease, are, individually and collectively referred to herein as the “Premises”.

2.3 Project:

The Building is the principal component of an office project known as "100 First Plaza," as further set forth in Section 1.1.2 of this Lease.

2.4 Must-Take Space:

47,939 rentable square feet of space, comprised of (i) 9,137 rentable square feet of space on the twelfth (12^th) floor of the Building and commonly known as Suite 1200 (“Suite 1200”); (ii) 19,401 rentable square feet of space on the sixteenth (16^th) floor of the Building and commonly known as Suite 1600 (“Suite 1600”); and (iii) 19,401 rentable square feet of space on the seventeenth (17^th) floor of the Building and commonly known as Suite 1700 (“Suite 1700”). Suite 1200, Suite 1600 and Suite 1700, as further depicted on Exhibit G to this Lease, are individually and collectively referred to herein as the “Must-Take Space”.



TERMS OF LEASE			DESCRIPTION
3. Lease Term (Article 2):
3.1 Length of Term:			The period commencing on the Phase I Premises Lease Commencement Date and ending on the last day of the one hundred twentieth (120^th) Lease Month after the later of (i) the Phase II Premises Lease Commencement Date; or (ii) the Deferred Delivery Date (as such terms are defined in Section 2.1 below).
3.2 Target Phase I Premises Delivery Date:			February 1, 2018
3.3 Phase I Premises Lease Commencement Date:			The date that is ninety (90) days following the Phase I Premises Delivery Date (as defined in Section 2.3 below), which the parties anticipate to be May 1, 2018.
3.4 Target Phase II Premises Delivery Date:			June 1, 2018, subject to Tenant’s Deferred Delivery Right in Section 2.1 below.
3.5 Phase II Premises Lease Commencement Date:			The date that is one hundred fifty (150) days following the Phase II Premises Delivery Date (as defined in Section 2.3 below), which the parties anticipate to be November 1, 2018.
3.6 Lease Expiration Date:			The last day of the one hundred twentieth (120^th) Lease Month after the later of (i) the Phase II Premises Lease Commencement Date; or (ii) the Deferred Delivery Date.
3.7 Option Term(s):			Two (2) five (5)-year options to renew, as more particularly set forth in Section 2.2 of this Lease.
4. Base Rent (Article 3):
4.1 Phase I Premises:
	Period During Lease Term	Annual Base Rent*		Monthly Installment of Base Rent*	Annual Rental Rate per Rentable Square Foot*
	Phase I Lease Year 1	$1,448,560.00		$120,713.33◊	$76.00
	Lease Year 2	$1,492,016.80		$124,334.73	$78.28
	Lease Year 3	$1,536,777.30		$128,064.78	$80.63**
	Lease Year 4	$1,582,880.62		$131,906.72	$83.05**
	Lease Year 5	$1,630,367.04		$135,863.92	$85.54**
	Lease Year 6	$1,679,278.05		$139,939.84	$88.10**
	Lease Year 7	$1,729,656.39		$144,138.03	$90.75**



TERMS OF LEASE			DESCRIPTION
	Lease Year 8	$1,781,546.08		$148,462.17	$93.47**
	Lease Year 9	$1,834,992.46		$152,916.04	$96.27**
	Lease Year 10	$1,890,042.23		$157,503.52	$99.16**
	Lease Year 11◦	$1,946,743.50		$162,228.63	$102.14**
	For purposes of this schedule, “Phase I Lease Year 1” shall mean the eighteen (18) calendar month period commencing on the Phase I Premises Lease Commencement Date and ending on the last day of the month in which the first anniversary of the Phase II Premises Lease Commencement Date occurs (or if the Phase II Premises Lease Commencement Date is the first day of a calendar month, then the first Phase I Lease Year shall commence on the Phase I Premises Lease Commencement Date and end on the day immediately preceding the first anniversary of the Phase II Premises Lease Commencement Date), and the second and each succeeding Lease Year shall commence on the first day of the next calendar month; and further provided that the last Lease Year shall end on the Lease Expiration Date.
4.2 Phase II Premises:
	Period During Lease Term	Annual Base Rent*		Monthly Installment of Base Rent*	Annual Rental Rate per Rentable Square Foot*
	Phase II Lease Year 1	$14,288,456.00		$1,190,704.67◊	$76.00
	Lease Year 2	$14,717,109.68		$1,226,425.81	$78.28
	Lease Year 3	$15,158,622.97		$1,263,218.58	$80.63**
	Lease Year 4	$15,613,381.66		$1,301,115.14	$83.05**
	Lease Year 5	$16,081,783.11		$1,340,148.59	$85.54**
	Lease Year 6	$16,564,236.60		$1,380,353.05	$88.10**
	Lease Year 7	$17,061,163.70		$1,421,763.64	$90.75**
	Lease Year 8	$17,572,998.61		$1,464,416.55	$93.47**
	Lease Year 9	$18,100,188.57		$1,508,349.05	$96.27**
	Lease Year 10	$18,643,194.23		$1,553,599.52	$99.16**
	Lease Year 11◦	$19,202,490.06		$1,600,207.51	$102.14**
	For the purposes of this schedule, “Phase II Lease Year 1” shall mean the twelve (12) calendar month period commencing on the Phase II Premises Lease Commencement Date and ending on the last day of the month in which the first anniversary of the Phase II Premises Lease Commencement Date occurs (or if the Phase II Premises Lease Commencement Date is the first day of a calendar month, then the first Phase II Lease Year shall commence on the Phase II Premises Lease Commencement Date and end on the day immediately preceding the first anniversary of the Phase II Premises Lease Commencement Date), and the second and each succeeding Lease Year shall commence on the first day of the next calendar month; and further provided that the last Lease Year shall end on the Lease Expiration Date.



TERMS OF LEASE			DESCRIPTION
* The initial Annual Base Rent amount was calculated by multiplying the initial annual rental rate per rentable square foot (the “initial Annual Rental Rate per Rentable Square Foot”) amount by the number of rentable square feet of space in the Premises, and the initial Monthly Installment of Base Rent amount was calculated by dividing the initial Annual Base Rent amount by twelve (12). Both Tenant and Landlord acknowledge and agree that multiplying the Monthly Installment of Base Rent amount by twelve (12) does not always equal the Annual Base Rent amount. The calculation of each Annual Base Rent amount reflects an annual increase of three percent (3%) commencing on the first (1^st) day of Lease Year 2 and each Monthly Installment of Base Rent amount was calculated by dividing the corresponding Annual Base Rent amount by twelve (12). ◊ Subject to the terms set forth in Section 3.2 below, (i) the Base Rent applicable to the Phase I Premises shall be abated during the period commencing as of the Phase I Premises Lease Commencement Date through the date which is eight (8) months following the Phase I Premises Lease Commencement Date, and (ii) the Base Rent applicable to the Phase II Premises shall be abated during the period commencing as of the Phase II Premises Lease Commencement Date through the date which is eight (8) months following the Phase II Premises Lease Commencement Date. ** The amounts identified in the column entitled "Annual Rental Rate per Rentable Square Foot" are rounded amounts and are provided for informational purposes only. ◦ Rent period applicable only if Tenant exercises the “Deferred Delivery Right”, as defined and described in Section 2.1 of this Lease.
5. Base Year (Article 4):
Phase I Premises:			Calendar year 2018.
Phase II Premises:			Calendar year 2019.
6. Tenant's Share (Article 4):			4.21% of the Office Space, with respect to the Phase I Premises and 41.49% of the Office Space, with respect to the Phase II Premises. Tenant’s Share for the Phase I Premises and the Phase II Premises, collectively, is 45.70% of the Office Space. 2.02% of the Office Space, with respect to Suite 1200, 4.28% of the Office Space, with respect to Suite 1600 and 4.28% of the Office Space with respect to Suite 1700. Tenant's Share for the Must-Take Space, collectively, is 10.58% of the Office Space.

1.1.1 The Premises. Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the Phase I Premises and the Phase II Premises set forth in Section 2.2 of the Summary (each, a “Phase” and individually and collectively, the "Premises"). The outline of the Premises is set forth in Exhibit A attached hereto and each floor or floors of the Premises has the number of rentable square feet as set forth in Section 2.2 of the Summary. The parties hereto agree that the lease of the Premises is upon and subject to the terms, covenants and conditions (the "TCCs") herein set forth, and Landlord and Tenant each covenant as a material part of the consideration for this Lease to keep and perform each and all of such TCCs by it to be kept and performed and that this Lease is made upon the condition of such performance. The parties hereto hereby acknowledge that the purpose of Exhibit A is to show the approximate location of the Premises in the "Building," as that term is defined in Section 1.1.2, below, only, and such Exhibit is not meant to constitute an agreement, representation or warranty as to the construction of the Premises, the precise area thereof or the specific location of the "Common Areas," as that term is defined in Section 1.1.3, below, or the elements thereof or of the accessways to the Premises or the "Project," as that term is defined in Section 1.1.2, below. Except as specifically set forth in this Lease and in the Work Letter attached hereto as Exhibit B (the "Work Letter"), Tenant shall accept the Premises in its existing "as-is" condition and Landlord shall not be obligated to provide or pay for any improvement work or services related to the improvement of the Premises. However, notwithstanding the foregoing, Landlord agrees that the Building Systems serving each Phase of the Premises (and in any Must-Take Space) shall be in good working order as of the date Landlord delivers possession of such Phase of the Premises to Tenant. Except to the extent caused by a BS/BS Exception (as defined in Article 7 below) or otherwise arising in connection with any Alterations performed by or on behalf of Tenant, if such Building Systems are not in good working order as of the date possession of the applicable Phase of the Premises is delivered to Tenant, Landlord shall be responsible for repairing the same at Landlord’s sole cost and expense, provided that Tenant has delivered written notice to Landlord (i) with respect to any Building Systems in the Phase I Premises, no later than forty-five (45) days following the Phase I Premises Lease Commencement Date, (ii) with respect to any Building Systems in the Phase II Premises, no later than forty-five (45) days following the Phase II Premises Lease Commencement Date, and (iii) with respect to any Building Systems in any Must-Take Space, no later than forty-five (45) days following the applicable Must-Take Effective Date (the “Systems Warranty”). Tenant also acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises, the Building or the Project or with respect to the suitability of any of the foregoing for the conduct of Tenant's business, except as specifically set forth in this Lease and the Work Letter.

1.1.3 Common Areas. Tenant shall have the non-exclusive right to use in common with other tenants in the Project, and subject to the Rules and Regulations (as defined below), those portions of the Project which are provided for use in common by Landlord, Tenant and any other tenants of the Project, such as entrances, lobbies, fire vestibules, restrooms, mechanical areas, ground floor corridors, elevators and elevator foyers, the Parking Garage electrical and janitorial closets, telephone and equipment rooms, loading and unloading areas, the Project’s plaza areas, if any, ramps, drives, stairs, and similar access ways and service ways and other common areas and facilities in and adjacent to the Building and the Project (such areas are collectively referred to herein as the "Common Areas"). The manner in which the Common Areas are maintained and operated shall be at the reasonable discretion of Landlord (but shall at least be consistent with the manner in which the common areas of the "Comparable Buildings," as that term is defined in Section 4 of Exhibit H to this Lease, are maintained and operated) and the use thereof shall be subject to the Rules and Regulations. Landlord reserves the right to close temporarily, make alterations or additions to, or change the location of elements of the Project and the Common Areas; provided that no such changes shall be permitted which materially reduce Tenant's rights or access hereunder. Except when and where Tenant's right of access is specifically excluded in this Lease, Tenant shall have the right of access to the Premises, the Building, the Common Areas and the Parking Garage twenty-four (24) hours per day, seven (7) days per week during the "Lease Term," as that term is defined in Section 2.1, below.

1.3 Right of First Offer. Landlord hereby grants to the tenant originally named herein (the "Original Tenant") and any Permitted Transferee Assignee (as defined in Section 14.8) an ongoing right of first offer (“Offer Right”) with respect to any separately demised space (excluding, however, any space located on the basement level, the ground floor, the second (2^nd) floor or the third (3^rd) floor) in the Building (each, a “Potential First Offer Space”); provided, however, that in the event Landlord or an entity which is controlled by, controls or is under common control with Landlord or manages the Building on behalf of Landlord, including, without limitation, any third party property managers (each, a “Landlord Affiliate”), in its sole and absolute discretion, elects to relocate some or all of its offices from the Building, each separately demised space located on the second (2^nd) and/or third (3^rd) floors of the Building vacated by Landlord or such Landlord Affiliate shall become a Potential First Offer Space for purposes of this Section 1.3. Notwithstanding the foregoing, such Offer Right of Tenant shall apply only following the expiration or earlier termination of the lease to the specific third party tenant (the “Third Party Tenant”) leasing any Potential First Offer Space (including renewals of such lease with such Third Party Tenant, irrespective of whether such renewal is entered into pursuant to an option or other right

set forth therein and whether such renewal is currently set forth in such lease with such Third Party Tenant or is subsequently granted or agreed upon with such Third Party Tenant, and regardless of whether such renewal is consummated pursuant to a lease amendment or a new lease with such Third Party Tenant). In addition, such Offer Right shall be subordinate to Landlord’s right to occupy any Potential First Offer Space for its own use and to all rights of other tenants of the Building, which rights relate to each Potential First Offer Space and are set forth in leases of space in the Building existing as of the date hereof, including, without limitation, any expansion, first offer, first refusal, first negotiation and other rights, to the extent executed substantially in accordance with their respective terms or pursuant to a lease amendment or a new lease. Landlord and any existing tenant of a Potential First Offer Space, and all such third party tenants in the Building with a right to lease a Potential First Offer Space, are collectively referred to as the “Superior Right Holders”. Tenant's Offer Right shall be subject to the TCCs set forth in this Section 1.3. Landlord represents and warrants that there are no Superior Right Holders to any First Offer Space, except as set forth on Exhibit K attached hereto.

1.3.1 Procedure for Offer. Subject to the terms of this Section 1.3.1, Landlord shall notify Tenant from time to time (the "First Offer Notice") when a Potential First Offer Space or any portion thereof (a “First Offer Space”) will become available for lease to third parties, free and clear of the rights of any Superior Right Holder. Pursuant to such First Offer Notice, Landlord shall offer to lease to Tenant the then available First Offer Space. The First Offer Notice shall describe the space so offered to Tenant and the “First Offer Rent,” as that term is defined in Section 1.3.3 below, and the other material economic terms upon which Landlord is willing to lease such space to Tenant, including, without limitation (i) the rentable square footage and location of the offered space, (ii) the date the space is anticipated to become available (the “Anticipated First Offer Delivery Date”), (iii) any tenant improvement allowances, rent concessions and free rent periods, and (iv) the length of the First Offer Space Term (subject to Section 1.3.5) (collectively, the “Economic Terms”). In no event shall Landlord have the obligation to deliver a First Offer Notice (and Tenant shall have no right to exercise its rights under this Section 1.3) during the last three (3) years of the initial "Lease Term," as that term is defined in Section 2.1 below; provided, however, that if Tenant timely and validly exercises its first option to extend the Lease Term in accordance with Section 2.2 below, Tenant shall once again have the Offer Right, subject to the terms and conditions of this Section 1.3, commencing as of the date that Landlord receives Tenant’s Exercise Notice (as defined in Section 2.2.3 below) and terminating as of the last day of the twenty-fourth (24^th) Lease Month of the first Option Term (as defined in Section 2.2.1 below).

1.3.3 First Offer Space Rent. If Tenant fails to deliver a Tenant's First Offer Space Rent Calculation, the First Offer Rent shall be as set forth in the First Offer Notice delivered by Landlord. If Tenant delivers a Tenant’s First Offer Space Rent Calculation to Landlord concurrent with Tenant’s delivery of the First Offer Exercise Notice, the First Offer Rent for the subject First Offer Space shall be equal to the Market Rent as determined pursuant to this Section 1.3.3, and Landlord shall deliver notice (the "Landlord First Offer Rent Notice") to Tenant on or before the date which is ten (10) business days after Landlord's receipt of Tenant's First Offer Space Rent Calculation, stating that (a) Landlord is accepting Tenant's First Offer Space Rent Calculation as the Market Rent, or (b) rejecting Tenant's First Offer Space Rent Calculation and setting forth Landlord's calculation of the Market Rent assuming that all other applicable Economic Terms for the subject First Offer Space are as provided in the First Offer Notice (subject to the requirements of this Section 1.3) and are used in Landlord’s calculation of Market Rent (the "Landlord's First Offer Space Rent Calculation"). Within ten (10) business days of its receipt of the Landlord First Offer Rent Notice, Tenant may, at its option, accept the Market Rent contained in the Landlord's First Offer Space Rent Calculation. If Tenant does not affirmatively accept or Tenant rejects the Market Rent specified in the Landlord's First Offer Space Rent Calculation, the parties shall follow the same procedure set forth in Section 2.2.4 below, provided that all references in Section 2.2.4 to (i) “Option Rent” shall be deemed to mean the “First Offer Rent”, (ii) “Option Term” shall be deemed to mean the applicable First Offer Space Term, and (iii) the “Outside Agreement Date” shall be deemed to mean the date that is forty-five (45) days after the date Landlord delivers the applicable Landlord’s First Offer Rent Notice to Tenant, and the Market Rent shall be determined in accordance with the terms of Section 2.2.4 below assuming that all other applicable Economic Terms for the subject First Offer Space are as provided in the First Offer Notice (subject to the requirements of this Section 1.3) and are used in the calculation of Market Rent. The terms of Section 3.2 of this Lease shall be inapplicable in connection with the subject First Offer Space.

Offer Space, then, upon Tenant’s request (which shall be expressly made, if at all, in Tenant’s First Offer Exercise Notice), Landlord shall remove the existing sheetrock that currently encases the internal stairwell (the “ROFO Internal Stairwell”) between the thirteenth (13^th) and fourteenth (14^th) floors of the Building, at its cost (it being agreed that if Tenant fails to request that Landlord remove the sheetrock that currently encases the ROFO Internal Stairwell in its First Offer Exercise Notice, Landlord shall have no obligation remove such sheetrock), prior to delivering possession of such First Offer Space located on the thirteenth (13^th) floor to Tenant, and the square footage of such stairwell area (which is 137 rentable square feet) shall be included in the Premises as of the First Offer Commencement Date for such First Offer Space (unless the square footage of such stairwell area was previously included in the Premises in connection with Tenant’s performance of the Phase II Premises Improvements, as defined in the Work Letter, pursuant to the Work Letter); provided, however, that Tenant, not Landlord, shall be responsible for complying with all applicable Laws relating to the use of and/or any alterations or other such requirements with respect to the ROFO Internal Stairwell. Tenant shall reasonably cooperate with Landlord in the performance of such work in the Premises in a timely manner and otherwise in accordance with the applicable amendment to this Lease pertaining to such First Offer Space. Notwithstanding anything to the contrary contained in this Lease, Tenant shall have no obligation to remove the ROFO Internal Stairwell or restore the existing sheetrock that currently encases the ROFO Internal Stairwell upon the expiration or sooner termination of this Lease.

1.3.5 Amendment to Lease. If Tenant timely exercises Tenant's right to lease a First Offer Space, then Landlord and Tenant shall, within fifteen (15) days after the date on which the First Offer Rent has been determined pursuant to Section 1.3.3 above, execute an amendment to this Lease for such First Offer Space upon the terms and conditions as set forth in the subject First Offer Notice, subject to the determination of the First Offer Rent as pursuant to this Section 1.3, and otherwise upon the terms and conditions of this Lease; provided, however, that an otherwise valid exercise of the such Offer Right shall be fully effective and irrevocable upon exercise whether or not a lease amendment is executed. In the event that the First Offer Rent shall not have been determined pursuant to the terms hereof prior to the commencement of the First Offer Space Term (as defined below), Tenant shall be required to pay the First Offer Rent set forth in Landlord’s First Offer Rent Notice provided by Landlord to Tenant, and upon the final determination of the First Offer Rent in accordance with Section 2.2.4, the payments made by Tenant shall be reconciled with the actual amounts due, and the appropriate party shall make any corresponding payment to the other party. Notwithstanding any contrary provision of this Section 1.3, the rentable square footage of the subject First Offer Space shall be determined by Landlord in accordance with Landlord’s then current standard of measurement for the Building (which, as of the date of this Lease is Office Building: Standard Methods of Measurement and Calculating Rentable Area – 2010 (Method A) or (Method B), as applicable), and shall not be subject to remeasurement during the initial Lease Term. Tenant shall commence payment of rent for the subject First Offer Space, and the term of Tenant's lease of the applicable First Offer Space (the “First Offer Space Term”) shall commence (the “First Offer Commencement Date”), upon the date set forth in the First Offer Notice (but in no event prior to the earlier to occur of (i) the date that is one hundred twenty (120) days after Landlord’s delivery of the subject First Offer Space to Tenant; or (ii) the date on which Tenant commences conduct of business in the First Offer Space) and, so long as the term of Tenant’s lease of the subject First Offer Space would exceed four (4) years, shall terminate conterminously

with the end of the Lease Term (as the same may be extended), it being agreed that the term length and termination date set forth in the subject First Offer Notice shall otherwise govern. Notwithstanding anything to the contrary herein, in no event shall Tenant be required to accept delivery of any First Offer Space prior to the Anticipated First Offer Delivery Date for such First Offer Space. In the event the First Offer Commencement Date with respect to a particular First Offer Space has not occurred on or before the date that is two hundred forty (240) days after the Anticipated First Offer Delivery Date (the “Required First Offer Delivery Date”), Tenant, as its sole remedy, may terminate this Lease, solely with respect to the undelivered portion of the First Offer Space (the “Undelivered First Offer Space”), by giving Landlord written notice of termination on or before the earlier to occur of: (i) five (5) business days after the Required First Offer Delivery Date; and (ii) the First Offer Commencement Date. In such event, (A) Landlord shall promptly refund any prepaid rent previously advanced by Tenant therefor and (B) the Undelivered First Offer Space shall again be deemed to be a Potential First Offer Space and subject to the TCCs of this Section 1.3. Landlord and Tenant acknowledge and agree that: (i) the determination of the date on which Landlord tenders possession of the First Offer Space shall be delayed on a day for day basis for each day to the extent such delay is caused by the acts or omissions of Tenant or any Tenant Parties (including without limitation, any failure of Tenant to timely deliver any additional insurance certificate or security required to be delivered with the First Offer Space, as applicable); and (ii) the Required First Offer Delivery Date shall be postponed by the number of days Landlord’s delivery of the First Offer Space is delayed due to events of Force Majeure.

1.3.6 Termination of Right of First Offer. Tenant's rights under this Section 1.3 shall be personal to Original Tenant or its Permitted Transferee Assignee, and may only be exercised by the Original Tenant or its Permitted Transferee Assignee (and not any other assignee or transferee of Tenant's interest in this Lease) if the Original Tenant or its Permitted Transferee Occupies at least sixty-seven percent (67%) of the Premises. As used in this Lease, Tenant shall be deemed to be “Occupying”, in “Occupancy” or any derivation thereof with respect to any portion of the Premises if and so long as (i) Tenant has not subleased such portion of the Premises (and provided that such portion of the Premises is not being marketed for sublease on the sublease market) and (ii) with respect to the portion of the Lease Term following the expiration of the Phase I Premises Improvement Allowance Sunset Date (as defined in the Work Letter) as to the Phase I Premises and with respect to the portion of the Lease Term following the Phase II Premises Improvement Allowance Sunset Date (as defined in the Work Letter) as to the Phase II Premises, Tenant has Substantially Completed (as defined in the Work Letter) its Improvements in the applicable portion of the Premises. Further, during the period commencing on the Phase I Premises Lease Commencement Date and continuing until the date immediately prior to the Phase II Premises Lease Commencement Date, Tenant shall be deemed to be in Occupancy, for purposes of this Lease, of any portion of the Phase I Premises and the Phase II Premises that Tenant has not subleased or marketed for sublease on the sublease market (a) notwithstanding that the Phase II Premises Lease Commencement Date has not yet occurred, and (b) so long as the Phase I Premises Improvements are Substantially Completed (as such terms are defined in Exhibit B attached hereto) and Tenant is reasonably phasing occupancy into the Phase II Premises. Tenant shall not have the right to lease the First Offer Space, as provided in this Section 1.3, if, as of the date of the attempted exercise of any right of first offer by Tenant, Tenant is in default under this Lease beyond any applicable notice and cure periods.

1.4.2 Subject to Section 1.4.6 below, Landlord shall provide notice to Tenant no later than thirty (30) days prior to the date Landlord anticipates delivery of each applicable Must-Take Space (each, an “Anticipated Must-Take Delivery Date”) and Tenant shall accept possession of each Must-Take Space as of the date Landlord delivers possession of such Must-Take Space to Tenant (each, a “Must-Take Delivery Date”) in the Delivery Condition (as defined in the Work Letter). If Landlord fails to deliver any applicable Must-Take Space within one hundred twenty (120) days of the applicable Anticipated Must-Take Delivery Date in the Delivery Condition, Tenant shall be entitled to an abatement of Base Rent in an amount equal to the per diem Base Rent for the Must-Take Space that would have been applicable to the Must-Take Space had Landlord delivered the Must-Take Space on the applicable Anticipated Must-Take Delivery Date in the Delivery Condition, for every day in the period beginning on the applicable Anticipated Must-Take Delivery Date and ending on the Must-Take Delivery Date. Any abatement accrued pursuant to this Section 1.4.2 shall be automatically applied to the first payment of Base Rent due on the subject undelivered portion of Must-Take Space. Landlord and Tenant acknowledge and agree that: (i) the determination of the date on which Landlord tenders possession of the subject Must-Take Space shall be delayed on a day for day basis for each day to the extent such delay is caused by the acts or omissions of Tenant or any Tenant Parties (including without limitation, any failure of Tenant to timely deliver any additional insurance certificate or security required to be delivered with the Must-Take Space, as applicable); and (ii) the Anticipated Must-Take Delivery Date shall be postponed by the number of days Landlord’s delivery of the subject Must-Take Space is delayed due to events of Force Majeure. Landlord estimates that the Must-Take Delivery Date for the entirety of the Must-Take Space will occur on February 1, 2020. In no event shall Tenant be required to take delivery of the Must-Take Space prior to February 1, 2020. As of the date that is one hundred fifty (150) days after each Must-Take Delivery Date (the “Must-Take Effective Date”) as applicable, the applicable Must-Take Space shall become part of the Premises and the rentable square footage of the Premises shall be increased to include the applicable Must-Take Space. The Must-Take Space shall be subject to all the terms and conditions of this Lease except as expressly modified herein and except that Tenant shall not be entitled to receive any allowances, abatements or other financial concessions granted with respect to the original Premises except as expressly provided in this Section 1.4. The Term with respect to the Must-Take Space (the “Must-Take Term”) shall commence on the Must-Take Effective Date and end, unless sooner terminated pursuant to the terms of this Lease, on the Lease Expiration Date, it being the intention of the parties hereto that the lease term for the Must-Take Space and the Lease Term for the initial Premises shall be coterminous. The applicable Must-Take Effective Date shall be delayed to the extent that Landlord fails to deliver possession of the subject Must-Take Space for any reason, including but not limited to, holding over by prior occupants. Except as otherwise expressly provided in Section 1.4.9 below, any such delay in the applicable Must-Take Effective Date shall not subject Landlord to any liability for any loss or damage resulting therefrom. If the Must-Take Effective Date is delayed, the Lease Expiration Date shall not be similarly extended.

1.4.3 The initial Annual Rental Rate per Rentable Square Foot for the Must-Take Space shall be the same as the Annual Rental Rate per Rentable Square Foot for the Premises on the date the applicable Must-Take Term commences. The Annual Rental Rate per Rentable Square Foot for the subject Must-Take Space shall increase at such times and in such amount as Base Rent for the initial Premises, it being the intent of Landlord and Tenant that the Annual Rental Rate per Rentable Square Foot for the Must-Take Space shall always be the same as the Annual Rental Rate per Rentable Square Foot for the initial Premises. Base Rent attributable to the Must-Take Space shall be payable in monthly installments in accordance with the terms and conditions of Article 3 of this Lease. Tenant shall be entitled to an abatement of Base Rent with respect to the Must-Take Space commencing as of the Must-Take Effective Date, in proportion to the eight (8) Lease Months of abated Base Rent applicable to the initial Premises, reduced on a prorated basis (based on a fraction, the numerator of which is the number of months of the applicable Must-Take Term, and the denominator of which is the number of months remaining in the initial Lease Term), due to any shorter term applicable to such Must-Take Space. Tenant shall pay Additional Rent for the Must-Take Space on the same terms and conditions set forth in this Lease, and Tenant's Share shall increase as set forth in Section 6 of Summary to account for the addition of the subject Must-Take Space; provided, however, that the Base Year for the subject Must-Take Space shall be either (a) the calendar year in which the subject Must-Take Effective Date occurs, if the subject Must-Take Effective Date occurs on or before September 30^th of such calendar year, or (b) the calendar year immediately subsequent to the calendar year in which the subject Must-Take Effective Date occurs, if the subject Must-Take Effective Date occurs after September 30^th of such calendar year. In addition, if the Base Year is determined pursuant to subpart (a) above, Tenant shall not be required to pay Tenant’s Share of Direct Expenses applicable to the subject Must-Take Space during the first twelve (12) full Lease Months of the applicable Must-Take Term.

1.4.4 In connection with Tenant’s leasing of the Must-Take Space, except as provided in Section 21.8 below, the L-C Amount (as defined in Section 21. 1 below) shall be increased as follows: (1) with respect to Suite 1200, by a total of Three Hundred Eighty Thousand and 00/100 Dollars ($380,000.00); and (2) with respect to Suite 1600, by a total of Seven Hundred Sixty Thousand and 00/100 Dollars ($760,000.00); and (3) with respect to Suite 1700, by a total of Seven Hundred Sixty Thousand and 00/100 Dollars ($760,000.00). The total amount by which the L-C Amount shall be increased pursuant to this Section 1.4.4 (the “Additional Must-Take L-C Amount”) shall be an amount equal to One Million Nine Hundred Thousand Dollars ($1,900,000). Tenant shall deliver to Landlord (i) Base Rent applicable to the subject Must-Take Space for the first month in which Base Rent is payable therefor; and (ii) an amendment to the existing L-C or a new or replacement L-C (which shall fully comply in all respect to the requirements set forth in Article 21 below), increasing the L-C Amount by the portion of the Additional Must-Take L-C Amount applicable to the subject Must-Take Space, on or before the earlier of (a) the date on which Landlord tenders possession of the subject Must-Take Space to Tenant; or (b) the date on which Tenant executes and delivers a Must-Take Amendment (as defined in Section 1.4.8). Landlord shall have no obligation to deliver the subject Must-Take Space to Tenant until Tenant delivers such amendment or new or replacement L-C and/or such prepaid Base Rent; provided, however, that if Landlord would have otherwise timely delivered the subject Must-Take Space, any such failure by Tenant shall not delay Tenant’s rent obligation as to the subject Must-Take Space (or otherwise be

1.4.5 Subject to the applicable express terms of Section 1.1.1, the subject Must-Take Space (including improvements, if any) shall be accepted by Tenant broom clean and in its “as-built” condition and configuration existing on the applicable Must-Take Delivery Date. Landlord shall provide an allowance (the "Must-Take Allowance") per square foot of rentable area in the applicable Must-Take Space in an amount determined by multiplying $0.83 by the number of full (or prorated for partial) calendar months of the applicable Must-Take Term (but in no event shall the Must-Take Allowance exceed $100.00 per rentable square foot of the applicable Must-Take Space). For example, if the Must-Take Term is forty (40) full (or prorated for partial) calendar months, then Tenant shall be entitled to receive an Must-Take Allowance of $33.20 per square foot of rentable area of the Must-Take Space ($0.83 x 40 = $33.20). Such Must-Take Allowance shall be applied toward the cost of initial improvements to be performed in the subject Must-Take Space (the "Must-Take Improvements") in accordance with the TCCs of the Work Letter. Tenant shall be entitled to apply a portion of the Must-Take Allowance, not to exceed an aggregate amount equal to the “Ancillary Use/Line Allocation Amount” (as defined below) toward the cost for the installation of Lines within the subject Must-Take Space and for improvements in the subject Must-Take Space related to Ancillary Uses. As used herein, the term “Ancillary Use/Line Allocation Amount” shall be an amount determined by multiplying $0.04 by the number of full calendar months of the applicable Must-Take Term (but in no event shall the Ancillary Use/Line Allocation Amount exceed $5.00 per rentable square foot of the subject Must-Take Space). For example, if the applicable Must-Take Term is forty (40) full calendar months, then the Ancillary Use/Line Allocation Amount shall be $1.60 per square foot of rentable area of the subject Must-Take Space ($0.04 x 40 = $1.60). The Must-Take Allowance shall be disbursed during construction of the Must-Take Improvements in the same manner and subject to the same conditions and limitations as applicable to the disbursement of the Improvement Allowance pursuant to Work Letter. No logistical coordination fee shall be payable to Landlord in connection with the Must-Take Improvements.

1.4.6 Subject to the terms of this Section 1.4.6, as of the later of (i) the applicable Must-Take Delivery Date; or (ii) the date that is one (1) business day following the date that Tenant has delivered all prepaid rental, an amendment to the existing L-C or a replacement L-C (as required pursuant to Section 1.4.4 above), and insurance certificates required hereunder, Landlord grants Tenant the right to enter the subject Must-Take Space at Tenant’s sole risk, solely for the purpose of performing the Must-Take Improvements and installing telecommunications and data cabling, equipment, furnishings and other personalty. Such possession prior to the applicable Must-Take Effective Date shall be subject to all of the terms and conditions of this Lease, except that Tenant shall not be required to pay Base Rent or Tenant’s Share of Direct Expenses applicable to the subject Must-Take Space with respect to the period of time prior to the applicable Must-Take Effective Date during which Tenant occupies the Premises solely for such purposes; provided, however, that Tenant shall be obligated to pay (a) the costs and expenses, calculated in accordance with the TCCs of Section 6.2, associated with any HVAC provided to Tenant after Building Hours (as defined below) at Tenant’s request and (b) Landlord’s reasonable costs and expenses to provide any additional Building security after Building Hours required due to any reasonable increased risk to property at the Building from Tenant’s construction activities as mutually agreed upon by Landlord

1.4.7 Landlord represents that the Must-Take Space is currently leased by Landlord to Andersen Tax LLC, a Delaware limited liability company (“Prior Tenant”), pursuant to the terms of a lease dated December 21, 2007 (as amended from time to time, the “Existing Lease”) with a term expiring on January 31, 2020 (the “Existing Lease Termination Date”). Subject to Prior Tenant’s existing option to renew the term for the Existing Lease, Landlord covenants and agrees to not extend the term of the Existing Lease beyond the Existing Lease Termination Date. Notwithstanding anything herein to the contrary, if the Existing Lease terminates (or the Prior Tenant’s right to possession is terminated) prior to its stated expiration date for any reason, Landlord shall provide Tenant with written notice of such prior termination (the “Prior Expiration Notice”). Such Prior Expiration Notice shall set forth Landlord’s reasonable estimate of the date on which Landlord expects to recover actual and legal possession of the Must-Take Space. If Landlord provides Tenant with a Prior Expiration Notice, Tenant may accelerate the Must-Take Effective Date with respect to all of the subject Must-Take Space to be a date prior to the Must-Take Effective Date set forth in Section 1.4.2 above (the “Accelerated Must-Take Delivery Date”) by giving written notice (an “Accelerated Must-Take Notice”) to Landlord within ten (10) business days after getting the Prior Expiration Notice, which Accelerated Must-Take Notice shall expressly indicate which portion of the available Must-Take Space Tenant elects to accelerate (provided, however, that Tenant shall not accelerate less than the entirety of the Must-Take Space on any given floor). If Tenant’s Accelerated Must-Take Notice indicates that Tenant is accelerating the Must-Take Effective Date for less than the entirety of a floor, Tenant shall be deemed to have elected to accelerate the applicable Must-Take Space with respect to the entirety of such floor. In addition, if Tenant’s Accelerated Must-Take Notice fails to indicate which portion of the Must-Take Space is subject to such acceleration, then Tenant shall be deemed to have accelerated the Must-Take Effective Date for the entirety of the Must-Take Space. Tenant shall lease the Must-Take Space set forth in the Accelerated Must-Take Notice in accordance with the terms and conditions set forth in this Section, except that the Must-Take Delivery Date shall be the Accelerated Must-Take Delivery Date, subject to the terms of Section 1.4.2 above. If Tenant fails to deliver the Accelerated Must-Take Notice to Landlord within the ten (10) business day period set forth above, then Landlord may lease all or any portion of the Must-Take Space (or any portion thereof) described in the Prior Expiration Notice until the Must-Take Delivery Date to any third party on whatever basis Landlord desires (and, in such case, Tenant’s Offer Right shall not apply to any portion of the Must-Take Space during the period prior to the Must-Take Delivery Date).

1.4.9 In addition to any abatement accrued pursuant to Section 1.4.2, in the event the Must-Take Delivery Date with respect to a particular Must-Take Space has not occurred on or before October 1, 2020 (the “Required Delivery Date”), Tenant may terminate this Lease, solely with respect to the undelivered portion of the Must-Take Space (the “Undelivered Must-Take Space”), by giving Landlord written notice of termination on or before the earlier to occur of: (i) five (5) business days after the Required Delivery Date; and (ii) the Must-Take Delivery Date. In such event, (A) this Section 1.4 shall be null and void with respect to any Undelivered Must-Take Space only and Landlord shall promptly refund any prepaid rent previously advanced by Tenant therefor pursuant to Section 1.4.4; (B) the required L-C Amount under this Lease shall be reduced by the portion of the Additional Must-Take L-C Amount applicable to such Undelivered Must-Take Space (as set forth in Section 1.4.4 above); and (C) the Undelivered Must-Take Space shall be deemed to be a Potential First Offer Space and subject to the TCCs of Section 1.3 above; provided, however, that the First Offer Rent for any Must-Take Space subsequently deemed a Potential First Offer Space shall be the lesser of (i) Market Rent and (ii) the then-current Base Rent payable for the initial Premises under this Lease. Landlord and Tenant acknowledge and agree that: (a) the determination of the date on which Landlord tenders possession of the Must-Take Space shall be delayed on a day for day basis for each day to the extent such delay is caused by the acts or omissions of Tenant or any Tenant Parties (including without limitation, any failure of Tenant to timely deliver the insurance certificate and L-C required pursuant to Section 1.4.4); and (b) the Required Delivery Date shall be postponed by the number of days Landlord’s delivery of the Must-Take Space is delayed due to events of Force Majeure (as defined below).

2.1 Initial Lease Term. The TCCs and provisions of this Lease shall be effective as of the Effective Date. The term of this Lease (the "Lease Term") with respect to (i) the Phase I Premises, shall commence on the Phase I Premises Lease Commencement Date set forth in Section 3.3 of the Summary (the “Phase I Premises Lease Commencement Date”); and (ii) with respect to the Phase II Premises, shall commence on the Phase II Premises Lease Commencement Date set forth in Section 3.5 of the Summary (the "Phase II Premises Lease Commencement Date"), and shall terminate on the date set forth in Section 3.6 of the Summary (the "Lease Expiration Date") unless this Lease is sooner terminated as hereinafter provided. The Phase I Premises Lease Commencement Date and the Phase II Premises Lease Commencement Date are sometimes individually and collectively referred to herein as the “Lease Commencement Date”. Further, the term “Lease Commencement Date” may be used herein to apply to either the Phase I Premises Lease Commencement Date or the Phase II Premises Lease Commencement Date, as indicated by the context in which such term is used. If Landlord is unable for any reason to deliver possession of the Phase I Premises to Tenant on any specific date, then, except as otherwise expressly provided

in Section 2.4 below, Landlord shall not be subject to any liability for its failure to do so, and such failure shall not affect the validity of this Lease or the obligations of Tenant hereunder. Tenant hereby acknowledges that the Phase II Premises are currently occupied by another tenant of the Building. If Landlord is unable for any reason to deliver possession of the Phase II Premises to Tenant on any specific date, such failure shall not affect the validity of this Lease or the obligations of Tenant hereunder (except as otherwise expressly provided in Section 2.4 below), provided that if such delay is the result of a holdover by the prior tenant, Landlord shall use commercially reasonable efforts to recover possession of the Phase II Premises and deliver the same to Tenant. Notwithstanding anything to the contrary set forth in this Lease, Tenant will have the right (the “Deferred Delivery Right”), upon written notice (a “Deferred Delivery Notice”) delivered to Landlord on or before January 31, 2018, to defer delivery of up to three (3) floors of the Phase II Premises, in full floor increments, for up to nine (9) months after the Target Phase II Premises Delivery Date set forth in Section 3.4 of the Summary. Tenant’s Deferred Delivery Notice shall expressly indicate the floor(s) that is/are subject to such deferment (hereinafter referred to as the “Deferred Space”) and the date on which Tenant desires to accept delivery of the Deferred Space (hereinafter referred to as the “Deferred Delivery Date”, and the period commencing on the Target Phase II Premises Delivery Date and continuing until the Deferred Delivery Date is hereinafter referred to as the “Deferred Delivery Period”). Notwithstanding the foregoing, in no event shall Tenant’s exercise of the Deferred Delivery Right, amend or modify any of Tenant’s obligations with respect to the Deferred Space set forth in this Lease (it being agreed that Tenant shall be responsible for all obligations set forth herein with respect to the Deferred Space, including, without limitation, Tenant’s obligation to pay Rent for the Deferred Space in accordance with the terms and conditions of this Lease), nor shall Tenant’s exercise of the Deferred Delivery Right modify, delay or amend the Phase II Premises Lease Commencement Date. If Tenant fails to provide a Deferred Delivery Notice on or before January 31, 2018 or if Tenant’s Deferred Delivery Notice fails to so indicate which floors are subject to the deferment and/or the length of such deferment, then Tenant’s Deferred Delivery Right shall be null and void and of no further force or effect and Tenant shall have no further or additional right to defer Landlord’s delivery of any portion of the Phase II Premises. For purposes of this Lease, the term "Lease Year" shall mean each consecutive twelve (12) calendar month period during the Lease Term; provided, however, that the first Lease Year of the initial Lease Term with respect to the Phase I Premises shall commence on the Phase I Premises Lease Commencement Date and end on the last day of the month in which the first anniversary of the Phase II Premises Lease Commencement Date occurs (or if the Phase II Premises Lease Commencement Date is the first day of a calendar month, then the first Lease Year of the initial Lease Term with respect to the Phase I Premises shall commence on the Phase I Premises Lease Commencement Date and end on the day immediately preceding the first anniversary of the Phase II Premises Lease Commencement Date), and the second and each succeeding Lease Year shall commence on the first day of the next calendar month; and further provided that the last Lease Year shall end on the Lease Expiration Date. For purposes of this Lease, the term "Lease Month" shall mean each succeeding calendar month during the Lease Term; provided that the first Lease Month shall commence on the Lease Commencement Date and shall end on the last day of the first (1^st) full calendar month of the Lease Term and that the last Lease Month shall expire on the Lease Expiration Date. Promptly following each Lease Commencement Date, Landlord may deliver to Tenant a notice in the form as set forth in Exhibit C, attached hereto (a "Commencement Letter"), as a confirmation only of the information set forth therein, which Tenant shall execute

2.2.1 Option Right. Landlord hereby grants the Original Tenant and its Permitted Transferee Assignee of this Lease, two (2) options to extend the Lease Term by a period of five (5) years (each, an "Option Term"), for either (a) the entire Premises; or (b) a portion of the Premises, provided that the following conditions are fully satisfied: (i) the portion of the Premises as to which Tenant elects to exercise the applicable option to extend (the “Extension Premises”) shall be comprised of full floors or the entirety of any partial floor then being leased by Tenant (and in no event shall Tenant have the right to exercise its option to extend as to a portion of any full floor comprising the Premises); (ii) the Extension Premises shall be comprised of no less than four (4) full floors of the Premises; (iii) the floors comprising the Extension Premises shall be continuous from the bottom up (i.e., starting up from the lowest floor of the Building comprising the Premises), or from the top down (i.e., starting down from the highest floor of the Building comprising the Premises) (for example, Tenant may not exercise the extension option as to the fifth (5^th) through tenth (10^th) floors only, and exclude the fourth (4^th), eleventh (11^th), fourteenth (14^th) and fifteenth (15^th) floors from the Extension Premises); and (iv) the remaining portion of the Premises that does not constitute a portion of the Extension Premises shall not result in space(s) being serviced by more than one (1) elevator bank of the Building. Each such extension option shall be exercisable only by "Notice" (as that term is defined in Section 29.18 of this Lease) delivered by Tenant to Landlord as provided below, provided that, as of the date of delivery of such Notice, (A) Tenant is not then in default under this Lease (after receipt of all required notices, if any, from Landlord and the expiration of all applicable cure periods set forth in this Lease) during the prior Lease Term, and (B) Tenant or its Permitted Transferee is in Occupancy of at least sixty-seven percent (67%) of the Premises then being leased by Tenant as of the date of the Notice. Upon the proper exercise of such option to extend, then the Lease Term, as it applies to the entire Premises or the Extension Premises, as applicable, shall be extended for a period of five (5) years. The rights contained in this Section 2.2 shall only be exercised by the Original Tenant or its Permitted Transferee Assignee (and not any other assignee, sublessee or other transferee of the Original Tenant's interest in this Lease) if Original Tenant and/or its Permitted Transferee is in Occupancy of at least sixty-seven percent (67%) of the Premises then being leased by Tenant.

2.2.3 Exercise of Option. The option contained in this Section 2.2 shall be exercised by Tenant, if at all, only in the manner set forth in this Section 2.2. Tenant shall deliver notice (the "Exercise Notice") to Landlord not more than eighteen (18) months nor less than fifteen (15) months prior to the expiration of the then Lease Term, stating that Tenant is exercising its option. Tenant’s Exercise Notice shall expressly specify the portion of the Premises as to which Tenant is exercising its extension option, subject to the limitations set forth in Section 2.2.1. If Tenant’s Exercise Notice fails to so specify the Extension Premises, Tenant shall be deemed to have elected to extend the Lease Term for the entire Premises. Concurrently with such Exercise Notice, Tenant shall deliver to Landlord Tenant's calculation of the Market Rent (the "Tenant's Option Rent Calculation"). Landlord shall deliver notice (the "Landlord Response Notice") to Tenant on or before the date which is thirty (30) days after Landlord's receipt of the Exercise Notice and Tenant's Option Rent Calculation, stating that (A) Landlord is accepting Tenant's Option Rent Calculation as the Market Rent, or (B) rejecting Tenant's Option Rent Calculation and setting forth Landlord's calculation of the Market Rent (the "Landlord's Option Rent Calculation"). Within thirty (30) days of its receipt of the Landlord Response Notice, Tenant may, at its option, accept the Market Rent contained in the Landlord's Option Rent Calculation. If Tenant does not affirmatively accept or Tenant rejects the Market Rent specified in the Landlord's Option Rent Calculation, the parties shall follow the procedure set forth in Section 2.2.4 below, and the Market Rent shall be determined in accordance with the terms of Section 2.2.4 below.

2.2.4.1 Landlord and Tenant shall each appoint one arbitrator who shall by profession be a MAI appraiser or real estate broker who shall have been active over the ten (10) year period ending on the date of such appointment in the appraising and/or leasing of first class, high-rise office properties in the vicinity of the Building. The determination of the arbitrators shall be limited solely to the issue area of whether Tenant's Final Option Rent Determination or Landlord's Final Option Rent Determination is the closest to the actual Option Rent as determined by the arbitrators, taking into account the requirements of Section 2.2.2 of this Lease. Each such arbitrator shall be appointed within fifteen (15) business days after the Outside Agreement Date. Landlord and Tenant may consult with their selected arbitrators prior to appointment and may select an arbitrator who is favorable to their respective positions (including an arbitrator who has previously represented Landlord and/or Tenant, as applicable). The arbitrators so selected by Landlord and Tenant pursuant to this Section 2.2.4 shall be deemed “Advocate Arbitrators” for purposes of this Section 2.2. If either party fails to timely appoint an Advocate Arbitrator, then the other party may deliver written notice of such failure to the party that failed to timely appoint an Advocate Arbitrator, and if such failure is not cured within five (5) business days following receipt of such written notice, then the Advocate Arbitrator timely appointed by the other party shall determine the Option Rent and such determination shall be binding upon the parties.

2.3 Early Access. Subject to the terms of this Section 2.3, and provided that this Lease has been fully executed by all parties and Tenant has delivered all prepaid rental, the L-C (as defined in Section 21.1), and insurance certificates required hereunder, Landlord grants Tenant the right to enter (i) the Phase I Premises as of the date on which Landlord delivers the entirety of the Phase I Premises to Tenant in the Delivery Condition (the “Phase I Premises Delivery Date”); provided that in no event shall the Phase I Premises Delivery Date be prior to the Target Phase I Premises Delivery Date, and (ii) the Phase II Premises as of the date on which Landlord delivers no less than seven (7) full floors of the Phase II Premises to Tenant in the Delivery Condition (the “Phase II Premises Delivery Date”); provided that in no event shall the Phase II Premises Delivery Date be prior to the Target Phase II Premises Delivery Date and provided further that if Landlord delivers less than the entirety of the Phase II Premises on the Phase II Premises Delivery Date, Landlord shall deliver the remainder of the Phase II Premises promptly upon Landlord’s possession of same. Landlord shall not be permitted to deliver less than seven (7) full floors of the Phase II Premises on the Phase II Premises Delivery Date. Tenant’s early access pursuant to this Section 2.3 shall be at Tenant’s sole risk, solely for the purpose of performing the Improvements (as defined in Exhibit B attached hereto), installing telecommunications and data cabling, equipment, furnishings and other personalty and moving into the Phase I Premises and the Phase II Premises. Such possession prior to the Lease Commencement Date shall be subject to all of the terms and conditions of this Lease, except that Tenant shall not be required to pay for freight elevator usage, security, access to loading docks, utilities, HVAC (as such term is defined in Section 6.1.1 below), Base Rent or Tenant’s Share of Direct Expenses with respect to the period of time prior to the applicable Lease Commencement Date during which Tenant occupies the Premises solely for such purposes (the “Construction Period”) and to the extent Landlord fails to deliver at least seven (7) floors of the Phase II Premises on the Phase II Premises Delivery Date, the Construction Period for the floors of the Phase II Premises delivered after the Phase II Premises Delivery Date shall be extended by the number of days in the period commencing on the Phase II Premises Delivery Date and ending on the actual date of delivery of such floors; provided, however, that during the Construction Period Tenant shall be obligated to pay (a) the costs and expenses, calculated in accordance with the TCCs of Section 6.2, associated with any HVAC provided to Tenant after Building Hours (as defined below) at Tenant’s request and (b) Landlord’s reasonable costs and expenses to provide any additional Building security after Building Hours required due to any reasonable increased risk to property at the Building from Tenant’s construction activities as mutually agreed upon by Landlord and Tenant or as may otherwise be required by applicable Law. Notwithstanding the foregoing, if Tenant takes possession of the Phase I Premises prior to the Phase I Premises Lease Commencement Date and/or the Phase II Premises prior to the Phase II Premises Lease Commencement Date for the conduct of Tenant's business, Tenant’s possession thereof shall be subject to the terms and conditions of this Lease and Tenant shall pay Base Rent and any other Rent applicable to such portion of the Phase I Premises and/or the Phase II Premises (on a suite by suite basis) and payable hereunder to Landlord for each day of possession following the date upon which Tenant commences conduct of business on such portion of the Premises until the Phase I Premises Lease Commencement Date and/or the Phase II Premises Lease Commencement Date, as applicable. During any period of such early access as set forth in this Section 2.3, in no event may Tenant cause a dangerous

2.4 Late Delivery Remedies. If Landlord fails to tender possession of the Phase I Premises to Tenant in the Delivery Condition on or before the date that is two (2) months following the Target Phase I Premises Delivery Date set forth in Section 3.2 of the Summary (the “Phase I Premises Required Delivery Date”), Tenant shall be entitled to an abatement of Base Rent applicable to the Phase I Premises which shall be automatically applied to the next payment(s) of Base Rent due on the Phase I Premises following the Phase I Premises Base Rent Abatement Period (as defined in Section 3.2 below) in an amount equal to the per diem Base Rent for the Phase I Premises for every day in the period beginning on the Phase I Premises Required Delivery Date and ending on the Phase I Premises Delivery Date. In addition, if Landlord fails to tender possession of any portion of the Phase II Premises in the Delivery Condition on or before the date that is two (2) months following the Target Phase II Premises Delivery Date set forth in Section 3.4 of the Summary (the “Phase II Premises Required Delivery Date”) (any such undelivered portion of the Phase II Premises is hereinafter referred to as the “Undelivered Phase II Premises”), Tenant shall be entitled to an abatement of Base Rent which shall be automatically applied to the next payment(s) of Base Rent due on the Undelivered Phase II Premises following the Phase II Premises Base Rent Abatement Period (as defined in Section 3.2 below) of an amount equal to the per diem Base Rent applicable to such Undelivered Phase II Premises (calculated on a per square foot basis for the Undelivered Phase II Premises) for every day in the period beginning on the Phase II Premises Required Delivery Date and ending on the Phase II Premises Delivery Date. In addition, if Landlord fails to tender possession of any such Undelivered Phase II Premises as of the date that is eight (8) months after the Target Phase II Premises Delivery Date (the “Outside Phase II Premises Delivery Date”), Tenant, as its sole remedy, may terminate this Lease, solely with respect to such Undelivered Phase II Premises and any Undelivered Must-Take Space as of the Outside Phase II Premises Delivery Date by giving Landlord written notice of termination on or before the earlier to occur of: (a) ten (10) business days after the Outside Phase II Premises Delivery Date; or (b) the date on which Landlord tenders possession of any such Undelivered Phase II Premises. In such event, this Lease shall be deemed terminated solely with respect to such Undelivered Phase II Premises and any Undelivered Must-Take Space, and shall continue in full force and effect as to the remaining portions of the Premises. In the event of such termination, the “Premises”, as used herein shall be deemed to mean the Premises as originally described herein, less the Undelivered Phase II Premises and any Undelivered Must-Take Space, and the terms of Section 1.4 of this Lease shall be null and void and of no further force and effect as to any Undelivered Must-Take Space only (and in such event, the required L-C Amount under this Lease shall be reduced by the portion of the Additional Must-Take L-C Amount applicable to such Undelivered Must-Take Space, as set forth in Section 1.4.4 above); provided, however, that if Tenant exercises its termination right as to the Undelivered Phase II Premises and any Undelivered Must-Take Space as provided herein, then following such termination, such Undelivered Phase II Premises and the Undelivered Must-Take Space shall be deemed Potential First Offer Space and provided further that the First Offer Rent for any such Potential First Offer Space shall be the lesser of (A) Market Rent and (B) the then-current Base Rent for the Phase I Premises. Landlord and Tenant shall enter into an amendment to this Lease modifying the rentable square footage of the Premises, Tenant’s Share, the amount of the Improvement Allowance, and other appropriate terms to document the termination of the Lease as

to the Undelivered Phase II Premises and any Undelivered Must-Take Space as provided herein. Landlord and Tenant acknowledge and agree that: (i) in no event shall the Phase II Premises Required Delivery Date apply to the Deferred Space for purposes of this Section 2.4 (it being agreed, for the avoidance of doubt, that Tenant shall not be entitled to a Base Rent abatement or a right to terminate this Lease with respect to any portion of the Phase II Premises designated as the Deferred Space pursuant Section 2.1); (ii) the determination of the date on which Landlord tenders possession of the Phase I Premises and the Phase II Premises, respectively, shall be delayed on a day for day basis for each day to the extent such delay is caused by the acts or omissions of Tenant or any Tenant Parties (including without limitation, any failure of Tenant to timely deliver the prepaid rent, insurance certificate and L-C required pursuant to Section 2.3); (iii) the Outside Phase II Premises Delivery Date with respect to the Deferred Space shall be delayed by the number of days in the Deferred Delivery Period (as defined in Section 2.1 below); (iv) the Phase I Premises Required Delivery Date, the Phase II Premises Required Delivery Date, and the Outside Phase II Premises Delivery Date shall each be postponed by the number of days Landlord’s delivery of the Phase I Premises and the Phase II Premises, as applicable, is delayed due to events of Force Majeure; (v) the date on which Landlord delivers the first portion of the Phase II Premises to Tenant shall be the “Phase II Premises Delivery Date” for purposes of determining the Phase II Premises Lease Commencement Date and the Lease Expiration Date notwithstanding that Landlord may subsequently deliver the remainder of the Phase II Premises and (vi) the Phase II Premises Improvement Allowance Sunset Date for the Undelivered Phase II Premises shall be extended by the number of days equal to the number of days in the period commencing on the date on which Landlord delivers the first portion of the Phase II Premises to Tenant and ending on the date on which Landlord delivers the entirety of the Phase II Premises.

3.1 In General. Tenant shall pay, without prior notice or demand, to Landlord or Landlord's agent at the remittance address and/or pursuant to the wiring instructions set forth in Section 11 of the Summary, or, at Landlord's option, at such other place (or pursuant to such other wiring instructions) as Landlord may from time to time designate in writing, by wire or a check for currency which, at the time of payment, is legal tender for private or public debts in the United States of America, base rent ("Base Rent") as set forth in Section 4 of the Summary, payable in equal monthly installments as set forth in Section 4 of the Summary in advance on or before the first day of each and every calendar month during the Lease Term, without any setoff or deduction whatsoever. In accordance with Section 4 of the Summary, any increases in Base Rent shall occur on the first day of the applicable Lease Month. The parties acknowledge, however, that Tenant shall pay Base Rent for each "calendar month" of the Lease Term (or a prorated portion of a "calendar month", as applicable), even though the first "Lease Month" may pertain to a period longer than one (1) calendar month. Tenant shall pay Base Rent applicable to the Phase I Premises and the Phase II Premises for the first month in which Base Rent is payable therefor on or before February 1, 2018. If any payment of Rent is for a period which is shorter than one month, the Rent for any such fractional month shall accrue on a daily basis during such fractional month and shall total an amount equal to the product of (i) a fraction, the numerator of which is the number

3.2 Base Rent Abatement. During the period commencing as of the Phase I Premises Lease Commencement Date through the date which is eight (8) months following the Phase I Premises Lease Commencement Date (the "Phase I Premises Base Rent Abatement Period"), Tenant shall not be obligated to pay any Base Rent otherwise attributable to the Phase I Premises during such Phase I Premises Base Rent Abatement Period (the "Phase I Premises Base Rent Abatement"). In addition, during the period commencing as of the Phase II Premises Lease Commencement Date through the date which is eight (8) months following the Phase II Premises Lease Commencement Date (the "Phase II Premises Base Rent Abatement Period", and each a “Base Rent Abatement Period”), Tenant shall not be obligated to pay any Base Rent otherwise attributable to the Phase II Premises during such Phase II Premises Base Rent Abatement Period (the "Phase II Premises Base Rent Abatement" and, together with the Phase I Premises Base Rent Abatement, the “Base Rent Abatement”). Landlord and Tenant acknowledge that the aggregate amount of the Base Rent Abatement equals $10,491,344.00. Tenant acknowledges and agrees that during each Base Rent Abatement Period, such abatement of Base Rent for the Premises shall have no effect on the calculation of any future increases in Base Rent or Direct Expenses payable by Tenant pursuant to the terms of this Lease, which increases shall be calculated without regard to such Base Rent Abatement. Additionally, Tenant shall be obligated to pay all "Additional Rent" (as that term is defined in Section 4.1 of this Lease) during each Base Rent Abatement Period subject to Section 4.4. Tenant acknowledges and agrees that the foregoing Base Rent Abatement has been granted to Tenant as additional consideration for entering into this Lease, and for agreeing to pay the Base Rent and perform the terms and conditions otherwise required under this Lease. If Tenant shall be in default under this Lease and shall fail to cure such default within the notice and cure period, if any, permitted for cure pursuant to this Lease, then Tenant’s right to receive the Base Rent Abatement shall toll (and Tenant shall be required to pay Base Rent during such period) until Tenant has cured, to Landlord’s reasonable satisfaction, such default and at such time Tenant shall be entitled to receive any unapplied Base Rent Abatement until fully applied.

4.2.4 "Operating Expenses" shall mean all expenses, costs and amounts of every kind and nature which Landlord pays or accrues during any Expense Year because of or in connection with the ownership, management, maintenance, security, repair or operation of the Project, or any portion thereof, as determined in accordance with sound real estate management and accounting practices, consistently applied. Without limiting the generality of the foregoing, Operating Expenses shall specifically include any and all of the following: (i) the cost of supplying all utilities, the cost of operating, repairing and maintaining the utility, telephone, mechanical, sanitary, storm drainage, and elevator systems, and the cost of maintenance and service contracts in connection therewith; (ii) the cost of licenses, certificates, permits and inspections and the cost of contesting any governmental enactments which may affect Operating Expenses, and the costs incurred in connection with a governmentally mandated transportation system management program or similar program; (iii) the cost of all insurance carried by Landlord in connection with the Project, and the commercially reasonable deductible portion of any insured loss otherwise covered by such insurance, provided that the deductibles of such insurance carried by Landlord in any Expense Year is no lower than the deductibles for such insurance carried by Landlord in the Base Year except to the extent such lower deductible is comparable to the deductibles for insurance then being carried by landlords of Comparable Buildings; (iv) the cost of landscaping, relamping, and all supplies, tools, equipment and materials used in the operation, repair and maintenance of the Project, or any portion thereof; (v) costs incurred in connection with the parking areas servicing the Project, as well as costs incurred in connection with the provision of any Shuttle Service (as defined in Section 29.41 below); (vi) fees and other costs, including management fees, consulting fees, legal fees and accounting fees, of all contractors and consultants in connection with the management, operation, maintenance and repair of the Project; (vii) payments under any equipment rental agreements and the fair rental value of any management office space (and if such management office is shared with other buildings owned by Landlord and Landlord’s affiliates, then such fair rental value shall be equitably prorated between the Building and such other buildings) provided that the square footage of such management office space allocated to the management of the Building in any Expense Year is no greater than one hundred twenty-five percent (125%) of the square footage of such management

office space allocated to the management of the Building in the Base Year; (viii) wages, salaries and other compensation and benefits, including taxes levied thereon, of all persons (other than persons generally considered to be higher in rank than the position of "Senior Asset Manager") engaged in the operation, maintenance and security of the Project; (ix) [INTENTIONALLY OMITTED]; (x) operation, repair and maintenance of all systems and equipment and components thereof of the Project; (xi) the cost of janitorial, alarm, security and other services, renovation, restoration and repair of wall and floor coverings, ceiling tiles and fixtures in Common Areas, maintenance and repair of curbs and walkways and repair to roofs, including, without limitation, roof patching; (xii) amortization of the cost of acquiring or the rental expense of personal property used in the maintenance, operation and repair of the Project, or any portion thereof (which amortization calculation shall include interest at the "Interest Rate," as that term is set forth in Article 25 of this Lease); (xiii) the cost of capital improvements (A) that are acquired to cause, in Landlord’s good faith judgment, an immediate (i.e., commencing within the first year after completion of such repairs or improvements or installation of such equipment) reduction in other Operating Expenses; (B) which are required in order for the Project, or any portion thereof, to maintain a certification under the U.S. Green Building Council's Leadership in Energy and Environmental Design ("LEED"), or other applicable certification agency in connection with Landlord’s sustainability practices for the Project (as such sustainability practices are to be determined by Landlord, in its reasonable discretion, from time to time); or (C) that are incurred due to any new Laws first enacted or made applicable to (x) Phase I Premises or the Common Areas after the Phase I Premises Lease Commencement Date or (y) with respect to Phase II Premises, or the Must-Take Space after the Lease Commencement Date applicable thereto; provided, however, that any capital expenditure shall be amortized with interest at the Interest Rate over its useful life as Landlord shall reasonably determine in accordance with sound real estate management and accounting practices; and (xiv) costs, fees, charges or assessments imposed by, or resulting from any mandate imposed on Landlord by, any federal, state or local government for fire and police protection, trash removal, community services, or other services which do not constitute "Tax Expenses" as that term is defined in Section 4.2.5, below. Notwithstanding the foregoing, for purposes of this Lease, Operating Expenses shall not, however, include:

Term after the Base Year shall not exceed one hundred five percent (105%) of the limit on Controllable Expenses for the first Expense Year of the initial Lease Term after the Base Year, etc. By way of illustration, if Controllable Expenses were $10.00 per rentable square foot for the first Expense Year of the initial Lease Term after the Base Year, then Controllable Expenses for the second Expense Year of the initial Lease Term after the Base Year shall not exceed $10.50 per rentable square foot, and Controllable Expenses for the third Expense Year of the initial Lease Term after the Base Year shall not exceed $11.03 per rentable square foot (whether or not actual Controllable Expenses were less than, equaled or exceeded the limit on Controllable Expenses the prior year). “Controllable Expenses” shall mean all Operating Expenses with the exception of (1) the cost of union labor (including janitorial staff and security personnel), including labor which is not union as of the date of this Lease, but which unionizes after the date of this Lease (but only to the extent that such cost exceeds one hundred five percent (105%) of the competitive cost for the same rendered by non-unionized persons or entities of similar skill, competence and experience), (2) any utility costs, (3) any insurance costs, (4) Tax Expenses, (5) costs to comply with applicable Laws and other governmental requirements, (6) any market-wide cost increases resulting from extraordinary circumstances, (7) refuse removal costs, (8) the cost to comply with or related to any other agreements recorded against the Project, and (9) the cost of any capital improvements and expenditures included in Operating Expenses pursuant to this Section 4.2.4 above.

If Landlord is not furnishing any particular work or service (the cost of which, if performed by Landlord, would be included in Operating Expenses) to a tenant who has undertaken to perform such work or service in lieu of the performance thereof by Landlord in the Base Year or in any Expense Year, Operating Expenses shall be deemed to be increased by an amount equal to the additional Operating Expenses which would reasonably have been incurred during such period by Landlord if it had at its own expense furnished such work or service to such tenant. If the Project is not at least one hundred percent (100%) occupied during all or a portion of the Base Year or any Expense Year, Landlord may elect to (and shall with respect to any Base Year) make an appropriate adjustment to the components of Operating Expenses for such year to determine the amount of Operating Expenses that would have been incurred had the Project been one hundred percent (100%) occupied; and the amount so determined shall be deemed to have been the amount of Operating Expenses for such year. If during any Expense Year after the Base Year a line item category is included in Operating Expenses that was not included in the Base Year due to a change in insurance requirements or in Landlord operations (i.e., if Landlord does not carry earthquake insurance in the Base Year but elects to carry such insurance in a subsequent Expense Year) (a “New Line Item”), Operating Expenses for the Base Year shall be adjusted to include the amount which would have been paid for such New Line Item in the Base Year had such New Line Item been included in the Base Year, as reasonably determined by Landlord (and, in the event that the New Line Item is initially incurred for only a partial Expense Year, the cost of such New Line Item shall be grossed up to represent a full calendar year for both the Base Year and the Expense Year in which the New Line Item first is incurred) and, following the expiration of the Expense Year during which the New Line Item initially occurs, Tenant shall be liable for Tenant’s Share of Operating Expenses for increases in Operating Expenses over the adjusted amount of the Base Year; provided, however, that any Operating Expenses that are renamed or recategorized (by applicable Laws or otherwise) or that otherwise in substance were included in the Base Year shall not be included in or treated as a New Line Item for purposes of this Section. Notwithstanding the foregoing, in no event shall

4.2.5.1 "Tax Expenses" shall mean all federal, state, county, or local governmental or municipal taxes, fees, charges or other impositions of every kind and nature, whether general, special, ordinary or extraordinary, (including, without limitation, real estate taxes, general and special assessments, transit taxes, leasehold taxes or taxes based upon the receipt of rent, including gross receipts or sales taxes applicable to the receipt of rent, unless required to be paid by Tenant, personal property taxes imposed upon the fixtures, machinery, equipment, apparatus, systems and equipment, appurtenances, furniture and other personal property used in connection with the Project, or any portion thereof), which shall be paid or accrued during any Expense Year (without regard to any different fiscal year used by such governmental or municipal authority) because of or in connection with the ownership, leasing and operation of the Project, or any portion thereof (including, without limitation, the land upon which the Building and the Parking Garage are located). If, for any tax fiscal year, the Project is not separately assessed, but is assessed jointly with other property, then Landlord shall equitably apportion such Tax Expenses for such tax fiscal year based upon allocable tax basis among the properties jointly assessed.

refuse removal and for other governmental services formerly provided without charge to property owners or occupants, and, in further recognition of the decrease in the level and quality of governmental services and amenities as a result of Proposition 13, Tax Expenses shall also include any governmental or private assessments or the Project's contribution towards a governmental or private cost-sharing agreement for the purpose of augmenting or improving the quality of services and amenities normally provided by governmental agencies; (iii) any assessment, tax, fee, levy, or charge allocable to or measured by the area of the Premises or the Rent payable hereunder, including, without limitation, any business or gross income tax or excise tax with respect to the receipt of such rent, or upon or with respect to the possession, leasing, operating, management, maintenance, alteration, repair, use or occupancy by Tenant of the Premises, or any portion thereof; (iv) any assessment, tax, fee, levy or charge, upon this transaction or any document to which Tenant is a party, creating or transferring an interest or an estate in the Premises; and (v) all of the real estate taxes and assessments imposed upon or with respect to the Building and all of the real estate taxes and assessments imposed on the land and improvements comprising the Project.

4.2.5.4 Any reasonable costs and expenses (including, without limitation, reasonable attorneys' fees) incurred in attempting to protest, reduce or minimize Tax Expenses shall be included in Tax Expenses in the Expense Year such expenses are paid. Except as set forth in Section 4.2.5.4, below, refunds of Tax Expenses shall be credited against Tax Expenses and refunded to Tenant regardless of when received, based on the Expense Year to which the refund is applicable, provided that in no event shall the amount to be refunded to Tenant for any such Expense Year exceed the total amount paid by Tenant as Tax Expenses under this Article 4 for such Expense Year. If Tax Expenses for any period during the Lease Term or any extension thereof are increased after payment thereof for any reason, including, without limitation, error or reassessment by applicable governmental or municipal authorities, Tenant shall pay Landlord upon demand Tenant's Share of any such increased Tax Expenses included by Landlord as Building Tax Expenses pursuant to the TCCs of this Lease. Notwithstanding anything to the contrary contained in this Section 4.2.5 (except as set forth in Section 4.2.5.2, above), there shall be excluded from Tax Expenses (i) any excess profits taxes, franchise taxes, gift taxes, capital stock or capital gains taxes, inheritance and succession taxes, estate taxes, documentary transfer taxes, federal or state income, corporate taxes or penalties incurred as a result of Landlord’s failure to pay taxes or to file any tax or informational returns and other taxes to the extent applicable to Landlord's general or net income (as opposed to rents, receipts or income attributable to operations at the Project), (ii) any items included as Operating Expenses, and (iii) any items paid by Tenant under Section 4.5 of this Lease. In addition to the foregoing, Tax Expenses shall exclude the value of tenant improvements in other tenants’ premises (as opposed to "Base Building" improvements, as that term is defined in Section 8.2 of this Lease), as allocated to such other tenants on the assessment and assessed for real property tax purposes at a valuation higher than One Hundred Dollars and No/100 ($100.00) per rentable square foot (the "Building Standard Improvement Value").

if Landlord is not independently appealing such Tax Expenses, Landlord shall retain a third-party in order to file and prosecute such appeal and shall, thereafter, diligently prosecute such appeal. Tenant may at any time in its sole discretion request Landlord to terminate an appeal it previously elected pursuant to Tenant's Appeal Request, and so long as the same does not have a material adverse impact on Landlord and/or Landlord’s management and operation of the Project (a “Material Adverse Tax Appeal Termination Impact”), as determined by Landlord in its reasonable discretion, Landlord shall so terminate such appeal; provided, however, that if Tenant requests termination of an appeal and Landlord elects in its sole discretion not to terminate such appeal following Tenant’s request for any reason other than due to a Material Adverse Tax Appeal Termination Impact, then Landlord shall pay all costs and expenses associated with such appeal from and after the date of Tenant’s request. If Tenant requests termination of an appeal and Landlord elects in its sole discretion not to terminate such appeal following Tenant’s request due to a Material Adverse Tax Appeal Termination Impact, then Tenant shall continue to pay all costs and expenses associated with such appeal. Tenant shall pay all costs incurred by Landlord in connection with any such appeal within thirty (30) days after Tenant's receipt of a reasonably detailed invoice. If the resulting appeal reduces the Tax Expenses for the tax fiscal year in question as compared to the original bill received for such tax fiscal year, then the costs for such appeal up to but not exceeding the amount of the reduction in Tax Expenses shall be included as an Operating Expense and passed through to the tenants of the Building and Landlord shall reimburse Tenant for the costs of such appeal so included in Operating Expenses; provided, however, that if Landlord continued the appeal at Landlord’s cost following Tenant’s request to terminate except for the reason of a Material Adverse Tax Appeal Termination Impact, then Landlord shall first reimburse its own costs of the portion of the appeal paid for by Landlord and then shall reimburse Tenant for the costs of the portion of the appeal paid for by Tenant. Tenant’s failure to timely deliver Tenant's Appeal Request as required above shall waive Tenant’s rights to request an appeal of such tax increase or assessment for the particular fiscal year. Nothing contained in this Section affects Tenant's obligation to timely pay Tenant's Share of Tax Expenses, which, until any appeal is concluded, shall be based on the original bill received by Landlord for the applicable tax fiscal year(s). Tenant’s obligations to pay Landlord for the costs of the appeal pursuant to this Section 4.2.5.5, and Tenant’s right to benefit from any reduction in the Tax Expenses, shall survive the expiration or earlier termination of this Lease in the event the appeal is not concluded until after the expiration or earlier termination of this Lease. Landlord agrees to keep Tenant apprised of all tax protest filings and proceedings undertaken by Landlord to obtain a reduction or refund of Tax Expenses.

4.4.1 Statement of Actual Direct Expenses and Payment by Tenant. Landlord shall give to Tenant on or before May 1 following the end of each Expense Year, a statement (the "Statement") which shall state in general major categories the Direct Expenses incurred or accrued for the particular Expense Year, and which shall indicate the amount of the Excess. Upon request from Tenant, Landlord shall provide more detailed information with respect to the expenses incurred by Landlord with respect to any of the general major categories. Upon receipt of the Statement for each Expense Year commencing or ending during the Lease Term, if an Excess is present, Tenant shall pay, within thirty (30) days after receipt of the Statement, the full amount of the Excess for such Expense Year, less the amounts, if any, paid during such Expense Year as "Estimated Excess," as that term is defined in Section 4.4.2, below, and if Tenant paid more as Estimated Excess than the actual Excess, Tenant shall receive a credit in the amount of Tenant's overpayment against Rent next due under this Lease. The failure of Landlord to timely furnish the Statement for any Expense Year shall not prejudice Landlord or Tenant from enforcing its rights under this Article 4. Even though the Lease Term has expired and Tenant has vacated the Premises, when the final determination is made of Tenant's Share of Direct Expenses for the Expense Year in which this Lease terminates, if an Excess is present, Tenant shall, within thirty (30) days after receipt of the Statement, pay to Landlord such amount, and if Tenant paid more as Estimated Excess than the actual Excess, Landlord shall, within thirty (30) days, deliver a check payable to Tenant in the amount of the overpayment. The provisions of this Section 4.4.1 shall survive the expiration or earlier termination of the Lease Term. Notwithstanding the immediately preceding sentence, Tenant shall not be responsible for Tenant's Share of any Direct Expenses attributable to any Expense Year which are first billed to Tenant more than eighteen (18) months following the expiration of any Expense Year (i.e. June 30 of the second year following the Expense Year), provided that in any event Tenant shall be responsible for Tenant's Share of Direct Expenses which (x) were levied by any governmental authority or by any public utility companies, and (y) Landlord had not previously received an invoice therefor and which are currently due and owing (i.e., costs invoiced for the first time regardless of the date when the work or service relating to this Lease was performed), at any time following the Lease Expiration Date which are attributable to any Expense Year.

4.4.2 Statement of Estimated Direct Expenses. In addition, prior to March 1 of each calendar year of the Lease Term, Landlord shall give Tenant a yearly expense estimate statement (the "Estimate Statement") which shall set forth, in general major categories, Landlord's reasonable estimate (the "Estimate") of what the total amount of Direct Expenses for the then-current Expense Year shall be and the estimated excess (the "Estimated Excess") as calculated by comparing the Direct Expenses for such Expense Year, which shall be based upon the Estimate, to the amount of Direct Expenses for the Base Year. Upon request from Tenant, Landlord shall provide more detailed information with respect to the expenses incurred by Landlord with respect to any of the general major categories. The failure of Landlord to timely furnish the Estimate Statement for any Expense Year shall not preclude Landlord from enforcing its rights to collect any Additional Rent under this Article 4, nor shall Landlord be prohibited from revising any Estimate Statement or Estimated Excess theretofore delivered to the extent necessary; provided that Landlord may not revise the Estimate Statement or Estimated Excess more than once in any Expense Year. Thereafter, Tenant shall pay, within thirty (30) days after receipt of the Estimate Statement, a fraction of the Estimated Excess for the then-current Expense Year (reduced by any amounts paid pursuant to the second to last sentence of this Section 4.4.2). Such fraction shall have as its numerator the number of months which have elapsed in such current Expense Year, including the month of such payment, and twelve (12) as its denominator. Until a new Estimate Statement is furnished (which Landlord shall have the right to deliver to Tenant at any time), Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the total Estimated Excess set forth in the previous Estimate Statement delivered by Landlord to Tenant. Throughout the Lease Term Landlord shall maintain books and records with respect to Direct Expenses in accordance with sound real estate management and accounting practices, consistently applied.

4.6 Landlord's Records. Upon Tenant's written request given not more than one (1) year after Tenant's receipt of a Statement for a particular Expense Year, and provided that Tenant is not then in default under this Lease with respect to the payment of Base Rent and/or Direct Expenses beyond applicable notice and cure periods, Landlord shall furnish Tenant with all reasonable supporting documentation in Landlord’s possession and control pertaining to the calculation of the Excess set forth in the Statement as Tenant may reasonably request. Landlord shall provide said documentation pertaining to the relevant Excess to Tenant within thirty (30) days after Tenant's written request therefor. Within one (1) year after receipt of a Statement by Tenant (the "Audit Period"), if Tenant disputes the amount of the Excess set forth in the Statement, an employee of Tenant with appropriate experience and financial responsibility within Tenant’s business or an independent, certified public accounting firm or other qualified financial consultant designated and reasonably approved by Landlord and paid for by Tenant (but in any event, not on a contingency fee basis), may, after reasonable notice to Landlord and at reasonable times, audit Landlord's records with respect to the Excess set forth in the Statement at Landlord's corporate offices, provided that Tenant is not then in default with respect to the payment of Base Rent and/or Direct Expenses under this Lease and Tenant has paid all amounts required to be paid under the applicable Estimate Statement and Statement, as the case may be (provided that Tenant may pay such amounts under protest). Tenant shall also have the right to review and dispute Direct Expenses for each Base Year in connection with Tenant’s review of any Expense Year after the applicable Base Year, but in no event later than the deadline for reviewing the 2021 Expense Year. In connection with such inspection, Tenant and Tenant's agents must agree in advance to follow Landlord's reasonable rules and procedures regarding an audit of the aforementioned Landlord records, and shall execute a commercially reasonable confidentiality agreement regarding such audit. Tenant's failure to audit the amount of the Excess set forth in any Statement within the Audit Period shall be deemed to be Tenant's approval of such Statement and Tenant, thereafter, waives the right or ability to audit the amounts set forth in such Statement. If after such audit, Tenant still disputes such Excess, an audit to determine the proper amount shall be made, at Tenant's expense, by an independent certified public accountant who has not represented Landlord or Tenant or any of their affiliates in the preceding five (5) years (the "Accountant") selected by Landlord and subject to Tenant's reasonable approval, and such determination by the Accountant shall be binding on Landlord and Tenant; provided that if the final determination ( as agreed upon by the parties or as determined by the Accountant) proves that Direct Expenses were overstated by more than three percent (3%), then the cost of the Accountant and the cost of such audit, in an amount not to exceed Ten Thousand and 00/100 Dollars ($10,000.00), shall be paid for by Landlord. If such final determination reflects that Tenant has overpaid the Excess for the period in question, then Landlord shall credit such Excess to Tenant’s next payment of Base Rent and Direct Expenses. If such final determination reflects that Tenant has underpaid the Excess, Tenant shall promptly pay such

5.2 Prohibited Uses. The uses prohibited under this Lease shall include, without limitation, use of the Premises or a portion thereof for (i) offices of any agency or bureau of the United States or any state or political subdivision thereof; (ii) offices or agencies of any foreign governmental or political subdivision thereof; (iii) offices of any health care professionals or service organization; (iv) radio and/or television stations; and (v) retail or restaurant uses. Tenant shall pay for the cost of any modifications that are necessary to cause the Base Building to comply with applicable Laws to the extent arising from Tenant’s occupancy density for the Premises. Tenant further covenants and agrees that it shall not use, or suffer or permit any person or persons to use, the Premises or any part thereof for any use or purpose contrary to the Rules and Regulations; or in violation of the laws of the United States of America, the State of California, or the ordinances, regulations or requirements of the local municipal or county governing body or other lawful authorities having jurisdiction over the Project including, without limitation, any "Environmental Laws" (as defined below) (collectively, “Laws”). Tenant shall not do or permit anything to be done in or about the Premises which will in any material way obstruct or interfere with the rights of other tenants or occupants of the Building, or injure or annoy them or use or allow the Premises to be used for any improper, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Notwithstanding the foregoing provisions of this Section 5.2 to the contrary, Tenant need not comply with any Laws so long as Tenant is contesting the validity thereof or the applicability thereof in accordance with the remainder of this Section 5.2. Tenant, at its expense, after notice to Landlord, may contest by appropriate proceedings prosecuted diligently and in good faith, the validity or applicability of any Laws with which Tenant is responsible for compliance hereunder, provided that (a) the condition which is the subject of such contest does not pose a danger to persons or property, (b) the certificate of occupancy or other occupancy permit for the Premises or the Project is neither subject to being suspended nor threatened to be suspended by reason of non-compliance or otherwise by reason of such contest, and (c) Landlord is not subject to criminal penalty or to prosecution for a crime by reason of Tenant’s non-compliance or otherwise by reason of such contest.

5.4 Cafeteria. Incidental to the Permitted Use and subject to the TCCs set forth in this Section 5.4, Tenant shall have the right, but not the obligation, to use a portion or portions of the Premises, at its expense and in accordance with applicable Laws, for the installation and operation of a kitchen and cafeteria, which includes facilities for food and beverage preparation, handling, cooking, consumption and other associated facilities (the “Cafeteria”), in each case solely for use by Tenant and Tenant’s partners, employees, contractors, consultants, invitees and guests (collectively, the “Ancillary Use Parties”). Landlord acknowledges and agrees that Tenant shall have no obligation to construct any Cafeteria. To the extent that Tenant operates a Cafeteria, such operation shall be in compliance with all applicable Laws and Tenant shall obtain and maintain the approval of all applicable governmental authorities and all necessary permits and licenses from such applicable governmental authorities, to operate a Cafeteria. No cooking odors shall be emitted from the Premises other than through ventilation equipment and systems installed therein to service a Cafeteria in accordance with the provisions of this Section 5.4 (which odors shall in no event be unreasonable or constitute a nuisance), and, in any event, no cooking odors shall be emitted from the Premises to other tenants’ premises or the Common Areas within the Building. Any Cafeteria installed by Tenant shall be for the exclusive use of Tenant and the Ancillary Use Parties in the Premises, and in connection with Tenant's use of such Cafeteria, Tenant shall not sell any food or beverages in or from the Premises at any time and/or serve any food and beverages in or from the Premises at any time to the general public. Except as expressly set forth to the contrary in this Lease, any alterations or improvements to install a Cafeteria and/or to install any cooking, ventilation, air conditioning, grease traps, commercial kitchen and other equipment in or for the Premises with respect to a Cafeteria (collectively, the “Cafeteria Facilities”) shall be performed by Tenant, at its expense, subject to and in compliance with the provisions of Article 8 below and in compliance with all applicable Laws and shall be considered an Alteration (as defined below). A Cafeteria and the Cafeteria Facilities therein shall be maintained and operated by Tenant, at Tenant's expense: (i) in manner consistent with Comparable Buildings; and (ii) in compliance with all applicable Laws, the Rules and Regulations, and the other provisions of this Lease. In accordance with the TCCs of Article 7 below, Tenant shall at its sole cost and expense keep, to the reasonable satisfaction of Landlord, any Cafeteria, Cafeteria Facilities and the Premises free from vermin, rats, mice and insects, and, prior to the opening of a Cafeteria, obtain and maintain at all times during the Lease Term, a service contract with a person or company approved by Landlord (which approval shall not be unreasonably withheld or delayed) for the extermination of vermin, rats, mice and insects in and about the Premises. Tenant shall deliver copy of such service contract and any renewals thereof to Landlord upon Landlord’s written request therefor. Tenant shall have the sole responsibility, at its expense, for providing all janitorial service (including wet and dry trash removal) for and cleaning of any Cafeteria (and the Cafeteria Facilities therein), as well as all exhaust vents therefor (and shall enter into a direct contract therefor with a janitorial company, subject to the TCCs of Section 6.1.5 below), and shall pay for all cleaning costs incurred by Landlord in cleaning any affected portions of the Building or Project to the extent arising from Tenant's operation of a Cafeteria. In addition, Tenant shall pay for all janitorial services provided to any Cafeteria (which shall constitute supplemental janitorial services and not Building standard janitorial services) and for all increased costs incurred by Landlord with respect to the management, operation, maintenance and repair of the Buildings resulting from Tenant's operation of a Cafeteria, within thirty (30) days of receiving an invoice therefor together with reasonable supporting evidence. Notwithstanding anything to the contrary contained elsewhere is this Lease, if Tenant

5.5 Fitness Center. Incidental to the Permitted Use, Tenant shall have the right, but not the obligation, to use the existing fitness center located on the eighth (8^th) floor of the Premises (the “Existing Fitness Center”) or to use another portion of the Premises, at its expense and in accordance with applicable Laws and TCCs of this Section 5.5, for the installation and operation of a new fitness center (the “New Fitness Center”), in each case solely for use by Tenant and the Ancillary Use Parties in the Premises. Landlord acknowledges and agrees that Tenant shall have no obligation to construct the New Fitness Center or to operate (except as otherwise expressly provided in this Section 5.5) the Existing Fitness Center. The Existing Fitness Center and the New Fitness Center, if applicable, are sometimes individually and collectively referred to herein as the “Fitness Center”. For the avoidance of doubt, a portion of the Premises shall not be deemed a “Fitness Center” hereunder if such portion does not include all of the following: cardio, weights, strength conditioning equipment, showers, floor mats, locker rooms, and mirrored walls consistent with fitness facilities. Tenant’s installation, use, operating and maintenance of the Fitness Center shall be subject to Tenant’s receipt, at its sole cost and expense, of all applicable governmental approvals related to the installation and operation of the Fitness Center and compliance with all applicable Laws, and may include, without limitation, the following primary uses: weight and aerobic training, personal training, aerobics, free weights, and installation of treadmills, stationary bicycles, elliptical machines, and stair-climbing machines, and shall in no event include installation or operation of a swimming pool, sauna or whirlpool facilities. Tenant shall install the New Fitness Center (or any modifications to the Existing Fitness Center) in accordance with the TCCs of Article 8 of this Lease or the TCCs of the Work Letter (if constructed by Tenant as part of the Improvements). If Tenant installs the New Fitness Center pursuant to this Section 5.5, in no event shall the New Fitness Center be located on a floor of the Building that is directly above and contiguous to a floor of the Building occupied by another tenant. Tenant shall be solely responsible for the structural engineer's costs of reviewing Tenant's plans and specifications and Tenant shall install any floor supports recommended by such structural engineer. In addition, Landlord, in its reasonable discretion, may require the installation of emergency drainage and Water Sensors (as that term is defined in Section 29.35 below) in connection with the installation of any new shower facilities in the Fitness Center, at Tenant’s sole cost and expense. Tenant shall pay for the cost of any changes to the Building Systems, Building Structure or Base Building arising from any such work performed with respect to the Fitness Center in accordance with Article 8. The Fitness Center shall be for the exclusive use of Tenant and the Ancillary Use Parties in the Premises (collectively, the "Fitness Center Users") and Tenant shall not make the Fitness Center available to other tenants or occupants of the Project (or their employees) or to members of the general public. The Fitness Center shall be of a reasonable size to provide fitness services to the Fitness Center Users. Tenant or Tenant's third party operator of the Fitness Center (either to be known as the "Fitness Center Provider") shall notify all Fitness Center Users that Landlord and the Landlord Parties are not responsible for, nor affiliated with, the operation of the Fitness Center. Landlord may, but shall not be obligated to, post signage at and/or about the Fitness Center disclaiming liability for the operation and management of the Fitness Center. Landlord shall have no responsibility with respect to the quality, care or services provided by the Fitness Center, or for any acts or omissions of any Fitness Center

Provider in connection with the operation of the Fitness Center. Furthermore, Tenant, for Tenant and for all Fitness Center Users and Fitness Center Providers, hereby agrees that the Landlord Parties shall not be liable for, and are hereby released from any responsibility for any loss, cost, damage, expense or liability, either to person or property, arising from the use of the Fitness Center by any Fitness Center Users. Tenant's obligations under this Section 5.5 are cumulative and in addition to all other obligations of Tenant under this Lease. Tenant shall have the sole responsibility, at its expense, for providing all janitorial service for and cleaning of the Fitness Center (and shall enter into a direct contract therefor with a janitorial company, subject to the TCCs of Section 6.1.5 below), and shall pay for all cleaning costs incurred by Landlord in cleaning any affected portions of the Building or Project resulting from Tenant's operation of the Fitness Center. In addition, Tenant shall pay for all janitorial services provided to the Fitness Center (which shall constitute supplemental janitorial services and not Building standard janitorial services) and for all actual and reasonable increased costs reasonably incurred by Landlord with respect to the management, operation, maintenance and repair of the Building resulting from Tenant’s operation of the Fitness Center, within thirty (30) days of receiving an invoice therefor together with reasonable supporting evidence. Notwithstanding anything to the contrary contained elsewhere is this Lease, if Tenant elects to install the New Fitness Center or modifies the Existing Fitness Center, unless Landlord otherwise notifies Tenant in writing, Tenant shall remove such Fitness Center and restore the portion of the Premises to a warm shell condition with all lighting and HVAC remaining in place or such other condition as may be required by Landlord at the time of Landlord’s approval of the applicable Alteration subject to the TCCs of the Lease (the “Restoration Condition”), upon the expiration or earlier termination of this Lease as to such portion of the Premises, but Tenant shall have no obligation to remove or restore the Existing Fitness Center in its configuration existing as of the date hereof.

5.6.1 Tenant’s Desk Agent. For so long as Tenant and/or its Permitted Transferee leases and is in Occupancy of at least 138,745 rentable square feet of the Premises and there exists no Tenant default, beyond any applicable notice and cure period, that Tenant does not reasonably dispute (collectively, the “Security Desk Use Conditions”), Tenant shall have the right to maintain, at its sole cost and expense, one (1) receptionist and/or lobby attendant at the existing security desk (or any replacement thereof) located in the lobby of the Building (the “Building Security Desk”) for Tenant’s or Tenant’s Transferee’s exclusive benefit (“Tenant’s Desk Agent”), subject to the TCCs in this Section 5.6. In the event that Tenant maintains such Tenant’s Desk Agent at the Building Security Desk, such person shall be engaged by Tenant for such services all at Tenant’s sole cost and expense; provided, however, that Landlord shall provide Tenant’s Desk Agent with no less than approximately four (4) feet of counter space and approximately four (4) feet of desk space at the Building Security Desk at no additional cost to Tenant. Tenant shall notify Landlord in advance of the name and other information reasonably required by Landlord with respect to Tenant’s Desk Agent and Tenant shall comply with Landlord’s reasonable security protocols with respect to such Tenant’s Desk Agent. Tenant shall ensure that Tenant’s Desk Agent shall maintain a professional and first-class appearance and cooperate at all times and reasonably communicate at all times with Building employees regarding any security matters and/or operational issues with respect to the Building Security Desk and the Building and to follow all security protocols and rules

and regulations implemented from time to time by Landlord with respect to the Building Security Desk and/or Tenant’s Desk Agent’s use thereof. Landlord acknowledges and agrees that, subject to this Section 5.6, Tenant’s Desk Agent shall be permitted to oversee access to the Premises in Tenant’s Desk Agent’s sole discretion, including without limitation, directing parties to the Premises and providing access and/or key card badges to third parties (provided, however, that the foregoing shall in no event modify or amend Landlord’s entry to the Premises which shall be governed by Article 27 of this Lease). Section 10.3 shall apply to Tenant’s use of the Building Security Desk and Tenant’s indemnity obligations pursuant to Section 10.1 shall apply to the acts and omissions of Tenant’s Desk Agent. In the event that Landlord reasonably determines that Tenant’s Desk Agent is not complying with Landlord’s security requirements or otherwise interfering with or compromising the Building’s security, then promptly following notice from Landlord, Tenant shall replace Tenant’s Desk Agent with another party reasonably acceptable to Landlord. If Tenant fails to do so within ten (10) business days following Landlord’s notice, Tenant’s right to maintain a Tenant’s Desk Agent pursuant to this Section 5.6 shall automatically terminate.

5.6.2 Tenant’s Security Equipment. During such time as Tenant maintains Tenant’s Desk Agent at the Building Security Desk pursuant to this Section 5.6, Tenant shall be entitled to install, at its sole cost and expense, certain security equipment related to Tenant’s operations at the Premises at the Building Security Desk. Any such security equipment installed by Tenant, including the manner of installation and the size and location of such equipment shall be subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. In no event shall such security equipment installed by Tenant unreasonably or adversely interfere with the Building’s systems and equipment or the operation of the Building Security Desk. Tenant shall coordinate the installation and operation of Tenant’s security equipment hereunder with Landlord to ensure that Tenant’s security equipment is compatible with the Building’s systems and equipment and to the extent that such equipment is not compatible with the Building systems and equipment, Tenant shall not be entitled to install or operate or replace it (and Tenant shall not actually install or operate or replace such security equipment unless Tenant has obtained Landlord’s approval of such compatibility in writing prior to such installation or operation). Tenant’s security equipment installed at the Building Security Desk shall be and shall remain in good working order and repair and compatible with any security systems and other Building systems of the Building and shall be installed and used in compliance with all other provisions of this Lease. In the event that Landlord reasonably determines that Tenant’s security equipment is interfering with the Building’s systems and equipment or the operation of the Building Security Desk, Tenant shall remove, at its sole cost and expense, such equipment promptly upon written notice from Landlord and repair any damage caused by such removal.

5.7 Tenant's Security System. Tenant may, at its own expense, install its own security and access system for the Premises ("Tenant's Security System"), either as an Alteration or as part of the initial Improvements; provided, however, that in the event that, subject to Landlord’s reasonable approval, Tenant's Security System ties into the Building’s security system, Tenant shall coordinate the installation and operation of Tenant's Security System with Landlord to ensure that Tenant's Security System is compatible with the Building security system and the Building Systems. Any installation of Tenant's Security System, including Landlord’s approval thereof, shall comply with and be governed by the terms of Article 8 of this Lease or the Work Letter, as applicable. Tenant shall be solely responsible, at Tenant's sole cost and expense, for the monitoring, operation, repair, replacement, and removal of Tenant's Security System. Tenant’s Security System shall not (a) create (i) an adverse effect on the Building Structure; (ii) a non-compliance with applicable Laws; (iii) an adverse effect on the Building Systems; (iv) an effect on the exterior appearance of the Building; or (v) unreasonable interference with the normal and customary office operations of any other tenant in the Building, (b) affect Landlord's ability to operate the Building, (c) be visible from the exterior of the Premises, or (d) be installed in the Common Areas other than the fire stairs on floors of the Building upon which the Premises comprise the full floor. Tenant shall provide Landlord with any information reasonably required regarding Tenant's Security System in the event access to the Premises is necessary in an emergency. Tenant shall keep Tenant’s Security System in good operating condition and repair and Tenant shall be solely responsible, at Tenant's sole cost and expense, for the monitoring, operation and removal of Tenant's Security System. Tenant’s Security System shall not make noise or visual alerts or alarms which disturb other occupants or which result in alarms or false alarms to which Landlord or its manager are called to respond. In no event shall Tenant install an access card reader system outside of the Premises (other than in the fire stairs) or any security cameras outside of the Premises. At Landlord's election prior to the expiration or earlier termination of this Lease, Tenant shall leave the Tenant's Security System in the Premises, in which event Tenant's Security System shall be surrendered with the Premises upon the expiration or earlier termination of this Lease and Tenant shall thereafter have no further rights with respect thereto. In the event that Landlord fails to elect to have the Tenant's Security System left in the Premises upon the expiration or earlier termination of this Lease, then Tenant shall remove the Tenant's Security System prior to the expiration or earlier termination of this Lease, and repair all damage to the Building resulting from such removal, at Tenant's sole cost and expense.

and (d) tying Tenant’s security system into the Building security system in a manner reasonably approved by Landlord so that, among other things, the Building security system can distinguish between an authorized entry into the fire stairs by one of Tenant’s employees and an unauthorized entry by another party. Tenant’s plans and specifications for the proposed access system installed pursuant to this Section 5.8 shall be subject to Landlord’s prior written approval, which approval will not be unreasonably withheld, conditioned or delayed. Tenant shall provide Landlord with a “master” card key so that Landlord shall have access through each fire stairs entry door. Tenant shall be solely responsible for the operation of such locking system and hereby waives any and all claims against Landlord and any Landlord Parties arising out of or in connection with parties gaining access to the Premises through the fire stairs due to a failure of Tenant’s Security System. Tenant shall be responsible for any additional cleaning costs with respect to the use of the fire stairs by Tenant’s employees. Tenant shall also be responsible for assuring that Tenant’s employees do not use the fire stairs for loitering, smoking or any other purpose other than travel between the aforesaid floors and use in the event of a fire or other emergency. In the event that Tenant no longer occupies any portion of a floor on which Tenant previously installed such access system, Tenant shall promptly remove such access system. Upon the earlier to occur of (i) the expiration or earlier termination of this Lease or (ii) the date that Tenant’s right to maintain such fire stairs access as to any particular floor shall terminate, Tenant shall, at its sole cost and expense, cause any access system installed by Tenant in connection such fire stairs usage to be removed and shall cause the areas in which such system was installed to be restored to the condition existing immediately prior to the placement of such system, ordinary wear and tear excepted. If Tenant fails to timely remove such access system or to restore the areas in which such area was located, as provided in the immediately preceding sentence, then Landlord may perform such work, and all reasonable and actual costs incurred by Landlord in so performing (including an administrative fee equal to five percent (5%) of the cost thereof) shall be reimbursed by Tenant to Landlord within thirty (30) days after Tenant's receipt of an invoice therefor together with reasonable supporting evidence. Tenant’s removal, restoration and payment obligations hereunder shall survive the expiration or earlier termination of this Lease.

6.1.5.1 Landlord shall provide Building standard janitorial services to the Premises, except on the dates of observation of the Holidays, in and about the Premises and window washing services in a manner consistent with other Comparable Buildings in accordance with Exhibit L attached hereto. Notwithstanding the foregoing, Tenant hereby acknowledges and agrees that Landlord shall have no obligation to provide any janitorial services to any Cafeteria or Fitness Center located at the Premises. Notwithstanding the foregoing, Tenant shall have the right, upon not less than sixty (60) days’ prior written notice to Landlord, to elect to provide all janitorial services, equipment and supplies and customary cleaning of the Premises (which, for the avoidance of doubt, shall include the Must-Take Space regardless of whether Tenant provides such notice prior to the Must-Take Effective Date) through Tenant’s employees or through a third party janitorial company, provided that such janitorial and cleaning services shall be performed in a manner and on a cleaning schedule consistent with Exhibit L attached hereto, and Tenant shall pay the cost of such contract directly to such janitorial services provider. Tenant agrees to include Landlord’s then-current janitorial company serving the Building in such bidding process for Tenant’s janitorial contract. Any third party janitorial company retained by Tenant shall be union, bonded, and shall be subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld so long as such janitorial company performs janitorial services to Class A building standards in Comparable Buildings, provided that Landlord shall not be deemed to be unreasonable for disapproving any such janitorial company if Landlord in good faith believes performance of such work or provision of such services by such company would interfere with harmonious labor relations in the Building. Any third party janitorial company retained by Tenant shall comply at all times with Landlord security procedures and rules and regulations for the Project. In the event of a labor disturbance which may include demonstrations against Landlord or Tenant as a result of Tenant’s decision to provide its own janitorial services, equipment and supplies as opposed to Landlord providing the same, then Tenant shall have two (2) business days from the date that such disturbance commences to resolve the labor issues. If the issues continue after the expiration of such two (2) business day period, then Tenant shall employ Landlord’s janitorial service provider for the Project for the “core” cleaning functions provided to all other tenants of the Project. In the event that Tenant retains, at its sole cost, an approved third party janitorial company to provide all janitorial services, equipment and supplies to the Premises, then Landlord shall have no further obligation to provide such janitorial services, equipment or supplies to the Premises pursuant to this Section 6.1.5. For so long as Tenant is providing and paying directly for all janitorial services, equipment and supplies to the Premises at its sole cost and expense, Operating Expenses for the applicable Base Year with respect to the Premises and for any applicable Expense Year during which Tenant is providing all such janitorial services, equipment and supplies to the Premises (prorated for any partial year) shall exclude the cost that would have otherwise been payable by Landlord for providing Building standard janitorial services, equipment and supplies to the Premises and the cost of janitorial services, equipment and supplies provided to any other office tenant spaces in the Building (but the cost of janitorial services, equipment and supplies to the Common Areas shall in all events be included in Operating Expenses). During any such period Tenant is entitled to and provides janitorial services, equipment and supplies to the Premises in accordance with this Section 6.1.5, Tenant shall be entitled to a credit against Base Rent and Operating Expenses in an amount equal to Landlord’s actual costs for providing Building standard janitorial services, equipment and supplies to other office tenant spaces in the Building (the “Janitorial Credit”). Landlord estimates that the Janitorial Credit will be $2.63 per rentable square foot per year for janitorial services and $0.22 per rentable square foot per year for janitorial supplies for the 2018 Expense Year. If Tenant elects to provide janitorial services, equipment and supplies to the Premises pursuant to this Section 6.1.5 and commences to provide such janitorial services, equipment and services to the Premises during the Base Rent Abatement Period, then the Janitorial Credit shall accrue commencing as of the date Tenant commences provision of such janitorial services, equipment and services to the Premises notwithstanding that Tenant is not obligated to pay Base Rent during the Base Rent Abatement Period and shall be applied to the Base Rent due and payable commencing as of the expiration of the Base Rent Abatement Period. In addition, during any such period Tenant is entitled to and provides janitorial services, equipment and supplies to the Premises in accordance with this Section 6.1.5, Tenant shall be responsible for providing any breakrooms and changing rooms for Tenant’s janitorial service provider and shall store all supplies and equipment in connection with such janitorial services within the Premises or within a storage area leased by Tenant within the Project (provided that if any full floor of the Premises contains a janitorial closet, Tenant shall use the same during any such period during which Tenant provides janitorial services, equipment and supplies to the Premises). If at any time during the Lease Term, Tenant is no longer providing and paying directly for janitorial services, equipment and supplies to the Premises as provided herein, then Operating Expenses for the applicable Base Year with respect to the Premises and for any applicable Expense Year during which Tenant is not providing all such janitorial services, equipment and supplies to the Premises (prorated for any partial year) shall be adjusted to include the cost of janitorial services payable by Landlord for providing janitorial services, equipment and supplies to

in the Building. Any third party janitorial company retained by Tenant shall comply at all times with Landlord security procedures and rules and regulations for the Project. In the event of a labor disturbance which may include demonstrations against Landlord or Tenant as a result of Tenant’s decision to provide its own janitorial services, equipment and supplies as opposed to Landlord providing the same, then Tenant shall have two (2) business days from the date that such disturbance commences to resolve the labor issues. If the issues continue after the expiration of such two (2) business day period, then Tenant shall employ Landlord’s janitorial service provider for the Project for the “core” cleaning functions provided to all other tenants of the Project. In the event that Tenant retains, at its sole cost, an approved third party janitorial company to provide all janitorial services, equipment and supplies to the Premises, then Landlord shall have no further obligation to provide such janitorial services, equipment or supplies to the Premises pursuant to this Section 6.1.5. For so long as Tenant is providing and paying directly for all janitorial services, equipment and supplies to the Premises at its sole cost and expense, Operating Expenses for the applicable Base Year with respect to the Premises and for any applicable Expense Year during which Tenant is providing all such janitorial services, equipment and supplies to the Premises (prorated for any partial year) shall exclude the cost that would have otherwise been payable by Landlord for providing Building standard janitorial services, equipment and supplies to the Premises and the cost of janitorial services, equipment and supplies provided to any other office tenant spaces in the Building (but the cost of janitorial services, equipment and supplies to the Common Areas shall in all events be included in Operating Expenses). During any such period Tenant is entitled to and provides janitorial services, equipment and supplies to the Premises in accordance with this Section 6.1.5, Tenant shall be entitled to a credit against Base Rent and Operating Expenses in an amount equal to Landlord’s actual costs for providing Building standard janitorial services, equipment and supplies to other office tenant spaces in the Building (the “Janitorial Credit”). Landlord estimates that the Janitorial Credit will be $2.63 per rentable square foot per year for janitorial services and $0.22 per rentable square foot per year for janitorial supplies for the 2018 Expense Year. If Tenant elects to provide janitorial services, equipment and supplies to the Premises pursuant to this Section 6.1.5 and commences to provide such janitorial services, equipment and services to the Premises during the Base Rent Abatement Period, then the Janitorial Credit shall accrue commencing as of the date Tenant commences provision of such janitorial services, equipment and services to the Premises notwithstanding that Tenant is not obligated to pay Base Rent during the Base Rent Abatement Period and shall be applied to the Base Rent due and payable commencing as of the expiration of the Base Rent Abatement Period. In addition, during any such period Tenant is entitled to and provides janitorial services, equipment and supplies to the Premises in accordance with this Section 6.1.5, Tenant shall be responsible for providing any breakrooms and changing rooms for Tenant’s janitorial service provider and shall store all supplies and equipment in connection with such janitorial services within the Premises or within a storage area leased by Tenant within the Project (provided that if any full floor of the Premises contains a janitorial closet, Tenant shall use the same during any such period during which Tenant provides janitorial services, equipment and supplies to the Premises). If at any time during the Lease Term, Tenant is no longer providing and paying directly for janitorial services, equipment and supplies to the Premises as provided herein, then Operating Expenses for the applicable Base Year with respect to the Premises and for any applicable Expense Year during which Tenant is not providing all such janitorial services, equipment and supplies to the Premises (prorated for any partial year) shall be adjusted to include the cost of janitorial services payable by Landlord for providing janitorial services, equipment and supplies to the Premises and the cost of janitorial services, equipment and supplies provided to any other office tenant spaces in the Building.

6.1.5.2 So long as Tenant is providing janitorial services to any portion of the Premises pursuant to this Section 6.1.5, Landlord shall give to Tenant on or before May 1 following the end of each Expense Year, a statement (the "Janitorial Credit Statement") which shall state the actual costs and expenses incurred or accrued for the particular Expense Year by Landlord for the provision of janitorial services, equipment and supplies to the other office tenant spaces in the Building, and which shall indicate the actual amount of the Janitorial Credit for such Expense Year. Upon request from Tenant (which shall be provided, if at all, within one hundred eighty (180) days after Tenant’s receipt of the Janitorial Credit Statement), Landlord shall provide more detailed information with respect to the expenses incurred by Landlord with respect to any of the costs and expenses on the Janitorial Credit Statement. Upon receipt of the Janitorial Credit Statement for each Expense Year commencing or ending during the Lease Term, if the actual amount of the Janitorial Credit is less than the estimated Janitorial Credit credited to Tenant during such Expense Year, Tenant shall pay, within thirty (30) days after receipt of the Janitorial Credit Statement, the full amount of the discrepancy for such Expense Year, and if the actual amount of the Janitorial Credit is greater than the estimated Janitorial Credit credited to Tenant during such Expense Year, Tenant shall receive a credit in the amount of such discrepancy against Rent next due under this Lease. The failure of Landlord to timely furnish the Janitorial Credit Statement for any Expense Year shall not prejudice Landlord or Tenant from enforcing its rights under this Section 6.1.5. Even though the Lease Term has expired and Tenant has vacated the Premises, when the final determination is made of the actual Janitorial Credit for the Expense Year in which this Lease terminates, if the actual amount of the Janitorial Credit is less than the estimated Janitorial Credit credited to Tenant during such Expense Year, Tenant shall, within thirty (30) days after receipt of the Janitorial Credit Statement, pay to Landlord such discrepancy, and if the actual amount of the Janitorial Credit is greater than the estimated Janitorial Credit credited to Tenant during such Expense Year, Landlord shall, within thirty (30) days, deliver a check payable to Tenant in the amount of the discrepancy. The provisions of this Section 6.1.5.2 shall survive the expiration or earlier termination of the Lease Term.

6.2 Overstandard Tenant Use. If Tenant uses electricity in excess of that supplied by Landlord pursuant to Section 6.1 of this Lease, Tenant shall pay to Landlord, upon billing, the cost of such excess consumption, the cost of the installation, operation, and maintenance of equipment which is installed in order to supply such excess consumption, and the reasonable cost of the increased wear and tear on existing equipment caused by such excess consumption (provided that in no event shall any such amount include any other mark-up or overhead added thereto); and Landlord may install devices to separately meter any increased use and in such event Tenant shall pay the increased cost directly to Landlord, including the cost of such additional metering devices. Tenant's use of electricity shall never exceed the capacity of the feeders to the Project or the risers or wiring installation. If Tenant desires to use HVAC during non-Building Hours, Tenant shall give Landlord such prior notice, if any, as Landlord shall from time to time establish as appropriate, of Tenant's desired use in order to supply such HVAC, and Landlord shall provide such HVAC to Tenant at such hourly cost to Tenant (which shall be treated as Additional Rent) as Landlord shall from time to time establish. As of the date of this Lease, Landlord’s charge for after hours heating and air conditioning service is $300.00 per hour per three (3) floor increments selected by Tenant in Tenant’s sole discretion (subject to change from time to time only due to and to the extent of changes in the actual costs to Landlord without markup), and Landlord’s charge for after hours ventilation is $90.00 per hour per floor for fans (subject to change from time to time only due to and to the extent of changes in the actual costs to Landlord without markup), with a minimum of two (2) hours per request.

6.4 Abatement Event. If (i) Landlord fails to perform the obligations required of Landlord under the TCCs of this Lease, (ii) such failure causes all or a portion of the Premises to be untenantable and unusable by Tenant, and (iii) such failure relates to (A) the nonfunctioning of the HVAC system in the Premises, the electricity in the Premises, the nonfunctioning of the elevator service to the Premises, or (B) a failure to provide access to the Premises (the "Abatement Event"), Tenant shall give Landlord notice (the "Abatement Notice"), specifying such failure to perform by Landlord. If Landlord has not cured such Abatement Event within five (5) business days after the receipt of the Abatement Notice (or within five (5) days after the date Landlord otherwise had actual knowledge of such Abatement Event as reasonably demonstrated by Tenant) (the "Eligibility Period"), Tenant may immediately abate Rent payable under this Lease for that portion of the Premises rendered untenantable and not used by Tenant, for the period from the commencement of such Abatement Event until the earlier of the date Landlord cures such Abatement Event or the date Tenant recommences the use of such portion of the Premises; provided that if the entire Premises has not been rendered untenantable and unusable by the Abatement Event, the amount of abatement that Tenant is entitled to receive shall be prorated based upon the percentage of the Premises (which shall be based on a ratio of the square feet of rentable area rendered untenantable and unusable to all of the rentable area leased by Tenant) so rendered untenantable and unusable and not used by Tenant. Notwithstanding the foregoing, in the event there is a disruption of services to the Premises, Landlord agrees to promptly use commercially reasonable efforts to resolve such failure of such services. Such right to abate Rent shall be Tenant's sole and exclusive remedy at law or in equity for an Abatement Event. Except as provided in this Section 6.4, nothing contained herein shall be interpreted to mean that Tenant is excused from paying Rent due hereunder.

6.5 Rooftop Rights. In accordance with, and subject to, the terms and conditions set forth in Article 8, below, and this Section 6.5, Tenant, on an non-exclusive basis, may use the Building’s roof for the installation and maintenance, at Tenant’s sole cost and expense, of one (1) satellite dish/antenna on the roof of the Building (and reasonable equipment and cabling related thereto), for receiving of signals or broadcasts (as opposed to the generation or transmission of any such signals or broadcasts) (all such equipment is defined collectively as the “Telecommunications Equipment”). In the event Tenant desires to install one (1) additional satellite dish/antenna on the roof of the Building (and reasonable equipment related thereto), Tenant may request in writing Landlord’s consent to the same and Landlord shall grant such request if Landlord determines in its reasonable judgment that reasonable additional space is available for such use. The physical appearance and all specifications of the Telecommunications Equipment shall be subject to Landlord’s reasonable approval, the location of any such installation of the Telecommunications Equipment shall be designated by Landlord, and Landlord may require Tenant to install screening around such Telecommunications Equipment, at Tenant’s sole cost and expense, as reasonably designated by Landlord. Landlord makes no representations or warranties whatsoever with respect to the condition of the roof of the Building, or the fitness or suitability of

6.6 Supplemental HVAC Units. Notwithstanding anything to the contrary contained in this Lease (but subject to any limitations on electricity capacity to the Premises as set forth in this Article 6), at any time during the Lease Term, Tenant shall have the right but not the obligation to install, in accordance with, and subject to, the terms and conditions set forth in Article 8, below (or in accordance with the Work Letter if installed as part of the Improvements), in the Premises, at Tenant’s sole cost and expense, subject to the application of the Improvement Allowance, as applicable, one (1) or more "Supplemental HVAC Unit" (defined below) in order to provide Tenant’s computer rooms, NOC, data center and/or other area(s) in the Premises with additional heating and cooling capacity. For purposes of clarification, Landlord shall only have a right to approve the manner and location in which Supplement HVAC Unit(s) are installed in the Premises (and Landlord shall not altogether disapprove of installation of Supplement HVAC Unit(s)). As used herein, the term “Supplemental HVAC Unit” shall mean, collectively, one or more self-enclosed electric heating and cooling unit of the size and tonnage, and having the specifications, approved by Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. Tenant shall have access to and use of the then available capacity of the Building’s distributed water (i.e., water not used in the operation of the Base Building) for the use of tenants for such facilities and Tenant shall pay to Landlord an amount equal to the actual costs to supply such distributed water, including any increased depreciation of the Building Systems used to supply distributed water. At the end of the Lease Term, at Landlord’s option, Tenant shall either: (1) remove, at Tenant’s sole cost and expense, any Supplemental HVAC Unit and restore all portions of the Premises and the Building affected by such removal to their condition immediately prior to the installation of such equipment, ordinary wear and tear excepted; or (2) leave any such Supplemental HVAC Unit in place, in which event the Supplemental HVAC Unit shall be the property of Landlord.

Landlord shall maintain in good condition and operating order and keep in good repair and condition, in a manner commensurate with the Comparable Buildings and in a clean, safe and neat condition, the structural portions of the Building, including the foundation, floor/ceiling slabs, roof structure (as opposed to roof membrane), curtain wall, exterior glass and mullions, columns, beams, shafts (including elevator shafts), stairs, stairwells, elevator cab, men's and women's washrooms, Building mechanical, electrical and telephone closets, and all common and public areas servicing the Building, including the parking areas, landscaping and exterior Project signage (collectively, "Building Structure") and the Base Building mechanical, electrical, life safety, plumbing, sprinkler systems and HVAC systems which were not constructed by Tenant Parties (collectively, the "Building Systems") and the Project Common Areas. The term “Building Systems”, for the avoidance of doubt, shall expressly exclude any heat pumps and variable air volume (“VAV”) boxes on any floor of the Premises (including, without limitation, any heat pumps and VAV boxes existing on any floor of the Premises as of the Effective Date). Notwithstanding anything in this Lease to the contrary, Tenant shall be liable for the reasonable, actual, out-of-pocket costs and expenses incurred by Landlord to repair the Building Structure and/or the Building Systems to the extent caused due to Tenant's use of the Premises for other than normal and customary business office operations, unless and to the extent such damage is covered by insurance carried or required to be carried by Landlord pursuant to Article 10 and to which the waiver of subrogation is applicable (such obligation to the extent applicable to Tenant as qualified and conditioned will hereinafter be defined as the "BS/BS Exception"). Tenant shall, at Tenant's own expense, keep the Premises, including all improvements, fixtures, equipment, interior window coverings, and furnishings therein, and the floor or floors of the Building on which the Premises is located, in a manner consistent with first class office standards in the market in which the Project is located at all times during the Lease Term, but such obligation shall not extend to the Building Structure and the Building Systems except pursuant to the BS/BS Exception as applicable to the Premises. If Tenant fails to make such repairs, Landlord may, after written notice to Tenant and Tenant's failure to repair within ten (10) business days thereafter, but need not, make such repairs and replacements, and Tenant shall pay Landlord the reasonable and actual cost thereof (plus a five percent (5%) administrative fee) within thirty (30) days after Tenant's receipt of an invoice therefor together with reasonable supporting evidence. Landlord may, but shall not be required to, enter the Premises to make such repairs, alterations, improvements or additions to the Premises or to the Project or to any equipment located in the Project as Landlord shall desire or deem necessary or as Landlord may be required to do by governmental or quasi-governmental authority or court order or decree; provided, however, except for (i) emergencies, (ii) repairs, alterations, improvements or additions required by governmental or quasi-governmental authorities or court order or decree, or (iii) repairs which are the obligation of Tenant hereunder, any such entry into the Premises by Landlord shall be performed in a manner so as not to materially interfere with Tenant's use of, or access to, the Premises; provided that, with respect to items (ii) and (iii) above, Landlord shall enter the Premises pursuant to Article 27 of this Lease and shall otherwise use commercially reasonable efforts to not materially interfere with Tenant's use of, or access to, the Premises. Tenant hereby waives any and all rights under and

8.1 Landlord's Consent to Alterations. Tenant may not make any improvements, alterations, additions or changes to the Premises or any mechanical, plumbing or HVAC facilities or systems pertaining to the Premises (collectively, the "Alterations") without first procuring the prior written consent of Landlord to such Alterations, and which consent shall not be unreasonably withheld by Landlord, provided it shall be deemed reasonable for Landlord to withhold its consent to any Alteration which adversely affects the Building Structure portions or the Building Systems or is visible from the exterior of the Building. If Landlord disapproves of any proposed Alterations, Landlord shall respond, in writing, stating the grounds for such disapproval, within ten (10) business days after receipt of Tenant’s request for approval of the proposed Alterations. If Landlord fails to respond with its approval or disapproval within ten (10) business days after receipt of Tenant’s request, then Tenant may send Landlord a reminder notice setting forth such failure containing the following sentence at the top of such notice in bold, capitalized font at least twelve (12) points in size: "LANDLORD'S FAILURE TO RESPOND TO THIS NOTICE WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN LANDLORD'S DEEMED APPROVAL OF TENANT'S ALTERATION" (the "Reminder Notice"). Any such Reminder Notice shall include a complete copy of Tenant's plans and specification for such Alteration. If Landlord fails to respond within five (5) business days after receipt of a Reminder Notice, then Tenant’s Alteration for which Tenant requested Landlord's approval shall be deemed approved by Landlord. Notwithstanding the foregoing, Tenant shall be permitted to make Alterations following ten (10) business days’ notice to Landlord, but without Landlord's prior consent, to the extent that such Alterations do not (i) adversely affect the Building System or Building Structure, or effect the exterior appearance of the Building, or (ii) cost more than One Hundred Fifty Thousand and 00/100 Dollars ($150,000.00) per floor in any one (1) calendar year (the "Cosmetic Alterations"). The construction of the initial improvements to the Premises, the Must-Take Space and any First Offer Space shall be governed by the terms of the Work Letter and not the terms of this Article 8.

following sentence at the top of such request in bold, capitalized font at least twelve (12) points in size: "LANDLORD'S FAILURE TO RESPOND TO THIS NOTICE WITHIN TWO (2) BUSINESS DAYS SHALL RESULT IN LANDLORD'S DEEMED APPROVAL OF TENANT'S CONTRACTOR" (the "Contractor Reminder Notice"). If Landlord fails to respond within two (2) business days after receipt of a Contractor Reminder Notice, then Tenant’s contractor for which Tenant requested Landlord's approval shall be deemed approved by Landlord. If Landlord shall give its consent, the consent shall be deemed conditioned upon Tenant acquiring a permit to do the work from appropriate governmental agencies, the furnishing of a copy of such permit to Landlord prior to the commencement of the work, and the compliance by Tenant with all conditions of said permit in a prompt and expeditious manner. If such Alterations will involve the use of or disturb hazardous materials or substances existing in the Premises, Tenant shall comply with Landlord's reasonable rules and regulations concerning such hazardous materials or substances. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable Laws and pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority), all in conformance with the Construction Rules (as defined in the Work Letter attached hereto). In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the "Base Building," as that term is defined below, then Landlord shall, at Tenant's expense, make such changes to the Base Building. Since all or a portion of the Project is or may become in the future certified under the LEED rating system (or other applicable certification standard) (all in Landlord's sole and absolute discretion), Tenant expressly acknowledges and agrees that without limitation as to other grounds for Landlord withholding its consent to any proposed Alteration, Landlord shall have the right to withhold its consent to any proposed Alteration in the event that such Alteration is not compatible with such certification or recertification of the Project under such LEED rating system (or other applicable certification standard). The "Base Building" shall include the structural portions of the Building, and the public restrooms, elevators, exit stairwells and the systems and equipment located in the internal core of the Building on the floor or floors on which the Premises is located. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to materially obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to materially obstruct the business of Landlord or other tenants in the Project. Tenant shall retain any union trades to the extent reasonably designated by Landlord. Further, Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of San Francisco in accordance with Section 8182 of the Civil Code of the State of California or any successor statute and Tenant shall deliver to Landlord a reproducible copy of the "as built" and CAD drawings of the Alterations, to the extent applicable, as well as copies of all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.

releases and waivers in connection with Tenant's payment for work to contractors, and (ii) sign Landlord's standard contractor's rules and regulations. If payment is made directly to contractors, Tenant shall comply with Landlord's reasonable requirements for final lien releases and waivers in connection with Tenant's payment for work to contractors. Tenant shall pay to Landlord, as Additional Rent, the reasonable costs of Landlord’s third party engineers and other third party consultants (but not Landlord’s on-site management personnel) which are reasonably required to be engaged by Landlord for review of all plans, specifications and working drawings for the Alterations, within thirty (30) days after Tenant’s receipt of invoices from Landlord together with reasonable supporting evidence. Landlord shall not be entitled to receive an administrative or supervision fee with regard to repairs, Alterations or any other work arising from or related to this Lease except as expressly set forth herein unless Tenant hires Landlord to perform the Alterations, in which case, an administrative fee will be negotiated between Landlord and Tenant at that time. In connection with any Alterations (but not with respect to the Improvements which shall be governed by the Work Letter), Tenant shall pay Landlord an oversight fee equal to (a) three percent (3%) of the hard cost of the work up to Two Million Dollars ($2,000,000.00), (b) two percent (2%) of the portion of the hard cost of the work in excess of Two Million Dollars ($2,000,000.00) and up to Three Million Dollars ($3,000,000.00) and (c) one percent (1%) of the portion of hard cost of the work in excess of Three Million Dollars ($3,000,000.00).

8.5 Landlord's Property. Landlord and Tenant hereby acknowledge and agree that (i) all Alterations, improvements, fixtures, equipment and/or appurtenances which may be installed or placed in or about the Premises (excluding Tenant's removable trade fixtures, furniture or non-affixed office equipment), from time to time, shall be at the sole cost of Tenant and shall be and become part of the Premises and the property of Landlord and (ii) the "Improvements" (as that term is defined in the Work Letter) to be constructed in the Premises pursuant to the TCCs of the Work Letter shall, upon completion of the same, be and become a part of the Premises and the property of Landlord. Furthermore, Landlord may, by written notice to Tenant prior to the end of the Lease Term, or given following any earlier termination of this Lease, require Tenant, at Tenant's expense, to remove any Alterations or improvements in the Premises (including, without limitation, the Improvements), and to repair any damage to the Premises and Building caused by such removal and return the affected portion of the Premises to the Restoration Condition; provided, however, if, in connection with its notice to Landlord with respect to consent or approval of any such Alterations, (x) Tenant requests Landlord's decision with regard to the removal and restoration of such Alterations, and (y) Landlord thereafter agrees in writing to waive the removal and restoration requirement with regard to such Alterations, then Tenant shall not be required to so remove such

Alterations; provided further, however, that if Tenant requests such a determination from Landlord and Landlord, within ten (10) business days following Landlord's receipt of such request from Tenant with respect to Alterations, fails to address the removal and restoration requirement with regard to such Alterations, Landlord shall be deemed to have agreed to waive the removal and restoration requirement with regard to such Alterations. If Tenant is required to remove and restore an Alteration and fails to complete such removal and/or to repair any damage caused by the removal of such Alteration, and/or to return the affected portion of the Premises to the Restoration Condition, then at Landlord's option, either (A) Tenant shall be deemed to be holding over in the Premises and Rent shall continue to accrue in accordance with the terms of Article 16, below, until such work shall be completed, and/or (B) Landlord may do so and may charge the actual, reasonable out-of-pocket costs thereof to Tenant, which costs shall be paid to Landlord within thirty (30) days after receipt of invoice together with reasonable supporting evidence. Notwithstanding the foregoing, Tenant shall not be required to remove any Cosmetic Alterations, any Typical Office Improvements (defined below), other than Lines (as defined in Section 29.32 below), or, to the extent existing as of the date of this Lease, any Specialty Alterations within the Premises, upon the expiration or earlier termination of this Lease. The term “Typical Office Improvements” shall mean any Alterations that are, when constructed, meet Building Standards and are otherwise customary for general office use in similar Class A office buildings in San Francisco, including office improvements such as gypsum board, partitions, ceiling grids and tiles, lighting, paint, carpet and doors but shall in all events exclude any Specialty Alterations (defined below). As used herein, the term “Specialty Alterations” shall include, without limitation, internal staircases (other than any existing as of the date hereof), raised flooring, vaults, showers (other than any existing as of the date hereof), rolling file systems, fitness centers (except the Existing Fitness Center as provided in Section 5.5), commercial kitchens and cafeteria equipment, and any alterations or improvements which affect the Building Structure or Building Systems, involve material plumbing connections (including, without limitation, showers and kitchens), perforate, penetrate or require reinforcement of a floor slab (such as interior stairwells) or high-density filing or racking systems), extend or increase the size of the existing electrical infrastructure (i.e., transformers, etc.) or are visible from outside the Premises. For the avoidance of doubt, at the expiration or earlier termination of this Lease, Tenant shall not be required to remove any Water Sensors (whether existing in the Premises as of the Effective Date or subsequently installed by Tenant during the Lease Term) or any of the Alterations and/or Specialty Alterations which exist in any Phase of the Premises at the time that Landlord delivers such Phase of the Premises to Tenant, including, for the avoidance of doubt: (i) the Existing Fitness Center, (ii) the existing extra set of women’s restrooms on the fifth (5^th), sixth (6^th), seventh (7^th), eighth (8^th) and eleventh (11^th) floors of the Building, (iii) the existing showers on the eighth (8^th) floor of the Building, (iv) the existing extra set of men’s restrooms on the eighth (8^th) floor of the Building, (v) the interconnecting stairwell between the fifth (5^th) and sixth (6^th) floors of the Building, and (vi) the interconnecting stairwell from the thirteenth (13^th) to the fifteenth (15^th) floors of the Building. Landlord shall not unreasonably withhold or delay its approval with respect to what Improvements or Alterations Landlord may require Tenant to remove at the expiration of the Lease. Except as otherwise expressly provided in this Section 8.5, Tenant, at its sole cost and expense, shall remove any Specialty Alterations in the Premises (including, without limitation, any portions of the Improvements that constitute Specialty Alterations) on or before the expiration or sooner termination of this Lease, and repair any damage to the Premises and

Tenant shall keep the Project and Premises free from any liens or encumbrances arising out of the work performed, materials furnished or obligations incurred by or on behalf of Tenant, and shall protect, defend, indemnify and hold Landlord harmless from and against any claims, liabilities, judgments or costs (including, without limitation, reasonable attorneys' fees and costs) arising out of same or in connection therewith. Tenant shall give Landlord notice at least ten (10) business days prior to the commencement of any such work on the Premises (or such additional time as may be necessary under applicable Laws) to afford Landlord the opportunity of posting and recording appropriate notices of non-responsibility. Tenant shall remove any such lien or encumbrance by bond or otherwise within twenty (20) days after notice by Landlord, and if Tenant shall fail to do so, Landlord may pay the amount necessary to remove such lien or encumbrance, without being responsible for investigating the validity thereof. The amount so paid shall be deemed Additional Rent under this Lease payable upon demand, without limitation as to other remedies available to Landlord under this Lease. Nothing contained in this Lease shall authorize Tenant to do any act which shall subject Landlord's title to the Building or Premises to any liens or encumbrances whether claimed by operation of law or express or implied contract. Any claim to a lien or encumbrance upon the Building or Premises arising in connection with any such work or respecting the Premises not performed by or at the request of Landlord shall be null and void, or at Landlord's option shall attach only against Tenant's interest in the Premises and shall in all respects be subordinate to Landlord's title to the Project, Building and Premises.

about the Premises; (b) the use or occupancy of the Premises by Tenant or any person claiming under Tenant; (c) any activity, work, or thing done, or permitted or suffered by Tenant in or about the Premises; (d) any negligence or willful misconduct of Tenant or any person claiming under Tenant, or the contractors, agents, employees, invitees, or visitors of Tenant or any such person, in, on or about the Project (collectively, "Tenant Parties"); (e) any violation by Tenant or any Tenant Party, acting within the scope of such Tenant Party’s work or engagement at the Project, of any Law with respect to the Premises, the Project and/or Tenant’s leasehold estate hereunder; (f) any injury or damage to the person, property, or business of Tenant, its employees, agents, contractors, invitees, visitors, or any other person entering upon the Premises under the express or implied invitation of Tenant; or (g) the placement of any personal property or other items within the Premises. Landlord shall indemnify, defend, protect, and hold harmless Tenant and the Tenant Parties from and against any and all loss, cost, damage, expense and liability (including without limitation court costs and reasonable attorneys' fees) incurred in connection with or arising from (1) the negligence or willful misconduct of Landlord or any Landlord Party and/or any of their affiliates in, on or about the Project or (2) any violation by Landlord or any Landlord Party, acting within the scope of such Landlord Party’s work or engagement at the Project, of any Law with respect to the Project. Each party's agreement to indemnify the other pursuant to this Section 10.1 is not intended and shall not relieve any insurance carrier of its obligations under policies required to be carried by such party pursuant to the provisions of this Lease, to the extent such policies cover the matters subject to such party’s indemnification obligations; nor shall they supersede any inconsistent agreement of the parties set forth in any other provision of this Lease. The provisions of this Section 10.1 shall survive the expiration or sooner termination of this Lease with respect to any claims or liability arising in connection with any event occurring prior to such expiration or termination.

10.3.5.2 Property Insurance Subrogation. Landlord and Tenant intend that their respective property loss risks shall be borne by insurance carriers to the extent above provided (and, in the case of Tenant, by an insurance carrier satisfying the requirements of Section 10.4(i) below), and Landlord and Tenant hereby agree to look solely to, and seek recovery only from, their respective insurance carriers in the event of a property loss to the extent that such coverage is agreed to be provided hereunder. The parties each hereby waive all rights and claims against each other for such losses, and waive all rights of subrogation of their respective insurers. Landlord and Tenant hereby represent and warrant that their respective "special form" property insurance policies include a waiver of (i) subrogation by the insurers, and (ii) all rights based upon an assignment from its insured, against Landlord and/or any of the Landlord Parties or Tenant and/or any of the Tenant Parties (as the case may be) in connection with any property loss risk thereby insured against. Tenant will cause all subtenants and licensees of the Premises claiming by, under, or through Tenant to execute and deliver to Landlord a waiver of claims similar to the waiver in this Section 10.3.2.4 and to obtain such waiver of subrogation rights endorsements (and Landlord shall deliver to all subtenants and licensees of the Premises a reciprocal waiver of claims similar to the waiver in this Section 10.5). If either party hereto fails to maintain the waivers set forth in items (i) and (ii) above, the party not maintaining the requisite waivers shall indemnify, defend, protect, and hold harmless the other party for, from and against any and all claims, losses, costs, damages, expenses and liabilities (including, without limitation, court costs and reasonable attorneys' fees) arising out of, resulting from, or relating to, such failure.

10.4 Landlord’s Insurance. Landlord shall insure the Project during the Lease Term against loss or damage due to fire and other casualties covered within the classification of fire and extended coverage, vandalism coverage and malicious mischief, sprinkler leakage, water damage and special extended coverage. Such coverage shall be in such amounts, from such companies, and on such other terms and conditions, as Landlord may from time to time reasonably determine. Landlord shall also carry rent continuation insurance. Additionally, at the option of Landlord, such insurance coverage may include the risks of earthquakes and/or flood damage and additional hazards, a rental loss endorsement and one or more loss payee endorsements in favor of the holders of any mortgages or deeds of trust encumbering the interest of Landlord in the Project or the ground or underlying lessors of the Project, or any portion thereof. Notwithstanding the foregoing provisions of this Section 10.2, the coverage and amounts of insurance carried by Landlord in connection with the Project shall be materially comparable to the coverage and amounts of insurance which are carried by landlords of Comparable Buildings (provided that in no event shall Landlord be required to carry earthquake insurance). Landlord shall carry commercial general liability insurance with a combined single limit coverage of at least $3,000,000.00 per occurrence. All such insurance shall be obtained from insurers which meet the requirements of Section 10.5 below. This policy shall include coverage for liabilities assumed under this Lease as an insured contract. Duly executed certificates showing the material terms for the same, shall be deposited with Tenant on the date Tenant first occupies the Premises and upon renewals of such policies upon written request. Any failure of Landlord to obtain and maintain the insurance policies and

10.5 Form of Policies. The minimum limits of policies of insurance required of each party under this Lease shall in no event limit the liability of such party under this Lease. Such insurance shall (i) be issued by an insurance company having an AM Best rating of not less than A-VII (or to the extent AM Best ratings are no longer available, then a similar rating from another comparable rating agency) and licensed to do business in the State of California, (ii) be in a commercially reasonable form and content and complying with the requirements of Section 10.3 (including, Sections 10.3.1 through 10.3.5), (iii) neither party shall do or permit to be done anything which invalidates the required insurance policies. If such policies of insurance do not contain a provision that the company writing said policy will give Landlord ten (10) days written notice in the event of non-payment of premium, then Tenant shall provide such written notice to Landlord within such ten (10) day period. Tenant shall deliver certificates thereof and applicable endorsements or policy excerpts which meet the requirements of this Article 10 to Landlord on or before (I) the earlier to occur of: (x) the Lease Commencement Date, and (y) the date Tenant and/or its employees, contractors and/or agents first enter the Premises for occupancy, construction of improvements, alterations, or any other move-in activities, and (II) ten (10) business days after the renewal of such policies. In the event Tenant shall fail to procure such insurance, or to deliver such certificates, and applicable endorsements or policy excerpts, Landlord may, at its option, after written notice to Tenant and Tenant's failure to obtain such insurance within ten (10) business days thereafter, procure such policies for the account of Tenant and the sole benefit of Landlord, and the cost thereof shall be paid to Landlord within thirty (30) days after delivery to Tenant of bills therefor.

11.1 Repair of Damage to Premises. If the Base Building or any Common Areas shall be damaged by a fire or any other casualty (collectively, a "Casualty"), Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or Force Majeure delays, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the Casualty, except for modifications required by zoning and building codes and other Laws. Within forty-five (45) days after the occurrence of any Casualty, Landlord shall cause to be delivered to Tenant an estimate (the “Casualty Repair Estimate”), prepared by a qualified, independent, experienced and reputable architect and/or general contractor and addressed to Tenant, of the number of days (assuming no Force Majeure delay), measured from the date of the Casualty, that will be required for Landlord to substantially complete the repair and restoration of the Base Building and the Common Areas (when such repairs are made without the payment of overtime or other premiums). Tenant shall promptly notify Landlord upon the occurrence of any damage to the Premises resulting from a Casualty, and Tenant shall promptly inform its insurance carrier of any such damage. Tenant shall, at its sole cost and expense, repair any injury or damage to the Improvements and Alterations installed in the Premises in accordance with Article 8, above; provided, however, that Tenant shall not be obligated to (i) repair any injury or damage to the Existing Fitness Center or (ii) if the Casualty occurs in the last three (3) years of the Lease Term, expend more than One Hundred and 00/100 Dollars ($100.00) per rentable square foot of the Premises. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof, but shall use commercially reasonable efforts to minimize interference with Tenant’s business during any such repairs. If such Casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises or any portion thereof is not occupied by Tenant as a result thereof, then during the time and to the extent the Premises is unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises. If a portion of a floor of the Premises is unusable for the Permitted Use and Tenant cannot conduct business therein as a result thereof, it shall be reasonable for Tenant to terminate all business operations on such floor and therefore the entire floor shall be deemed unfit for occupancy for purposes of this Section 11.1. Tenant's right to rent abatement pursuant to the preceding sentence shall terminate as of the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.

11.2 Termination Rights. Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Base Building and Common Areas, and instead terminate this Lease, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice to include a termination date giving Tenant sixty (60) days to vacate the Premises, but Landlord may so elect only if one or more of the following conditions is present: (i) according to the Casualty Repair Estimate, repairs to the Base Building and Common Areas cannot be completed within twelve (12) months after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be and all other leases for other tenants in the Project similarly impacted by the Casualty (excluding any portion of the Project leased by Landlord or a Landlord Affiliate) are terminated by Landlord acting in good faith; (iii) the damage occurs during the last twelve (12) months of the Lease Term (as may be extended by Option Term exercised by Tenant prior to the Casualty) and according to the Casualty Repair Estimate restoration and repair of the Base Building and Common Areas cannot be completed within sixty (60) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums). Notwithstanding the terms of Section 11.1 of this Lease, Tenant may elect to terminate this Lease by notifying Landlord in writing of such termination within thirty (30) days after receipt of the Casualty Repair Estimate, such notice to include a termination date giving Tenant up to sixty (60) days to vacate the Premises, but Tenant may so elect only if one or more of the following conditions is present: (A) according to the Casualty Repair Estimate, repairs to the Base Building and Common Areas cannot be completed within twelve (12) months after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums) or (B) the damage occurs during the last twelve (12) months of the Lease Term (as may be extended by Option Term exercised by Tenant prior to the Casualty) and according to the Casualty Repair Estimate restoration and repair of the Base Building and Common Areas cannot be completed within sixty (60) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums). Furthermore, if neither Landlord nor Tenant has terminated this Lease, and the repairs are not actually completed within ninety (90) days of the period of time set forth in the Casualty Repair Estimate, Tenant shall have the right to terminate this Lease by written notice to Landlord (the "Damage Termination Notice"), effective as of a date set forth in the Damage Termination Notice (the "Damage Termination Date"), which Damage Termination Date may be up to sixty (60) days after delivery of the Damage Termination Notice. Notwithstanding the foregoing, if Tenant delivers a Damage Termination Notice to Landlord, then Landlord shall have the right to suspend the occurrence of the Damage Termination Date for a period ending thirty (30) days after the Damage Termination Date set forth in the Damage Termination Notice by delivering to Tenant, within five (5) business days of Landlord's receipt of the Damage Termination Notice, a certificate of Landlord's contractor responsible for the repair of the damage certifying that it is such contractor's good faith judgment that the repairs shall be substantially completed within thirty (30) days after the Damage Termination Date. If repairs shall be substantially completed prior to the expiration of such thirty-day period, then the Damage Termination Notice shall be of no force or effect, but if the repairs shall not be substantially completed within such thirty (30) day period, then this Lease shall terminate upon the expiration of such thirty (30) day period. At any time, from time to time,

after the date occurring sixty (60) days after the date of the damage, Tenant may request that Landlord inform Tenant of Landlord's reasonable opinion of the date of completion of the repairs and Landlord shall respond to such request within five (5) business days. If only the Premises and no other part of the Project is damaged by a Casualty and sufficient insurance proceeds to fully cover the repair and restoration in excess of Three Million Dollars ($3,000,000) (not including deductibles) are not received by Landlord (excepting any applicable deductibles), and, solely due to the failure to receive such receipt of insufficient proceeds in excess of Three Million Dollars ($3,000,000) Landlord elects to terminate this Lease and so notifies Tenant, Tenant may elect to pay all of the cost of repair and restoration (less available insurance proceeds and deductible, which shall be paid for in accordance with the terms and conditions of this Lease) in excess of Three Million Dollars ($3,000,000) (the “Tenant Contribution”) by delivering written notice of such election, together with payment of such Tenant Contribution, to Landlord within thirty (30) days after delivery of Landlord’s notice of election to terminate this Lease solely due to Landlord’s receipt of insufficient insurance proceeds to complete the repair and restoration work. In the event Tenant fails to timely tender notice to Landlord or deliver the Tenant Contribution to Landlord, Tenant shall be deemed to waive its right to elect to pay the same and Landlord’s termination of the Lease shall remain in full force and effect. Upon receipt of such notice and Landlord’s receipt of payment by Tenant of the Tenant Contribution, Landlord’s termination shall be deemed rescinded and, following Tenant’s delivery to Landlord of the Tenant Contribution, Landlord shall promptly proceed with the repair and restoration of the Premises and Landlord shall have no further ability to terminate the Lease due to Landlord’s receipt of insufficient insurance proceeds. If Landlord elects to terminate this Lease under this Section 11.2 and Tenant does not elect to pay the Tenant Contribution, this Lease shall terminate as of the date set forth in Landlord’s notice of election to terminate this Lease; provided, however, that Landlord may only elect to terminate this Lease pursuant to this Section 11.2 if all other Leases for other tenants in the Project similarly impacted by the Casualty (excluding any portion of the Project leased by Landlord or a Landlord Affiliate) are terminated by Landlord acting in good faith. In the event this Lease is terminated in accordance with the terms of this Section 11.2, Tenant shall assign to Landlord (or to any party designated by Landlord) the portion of insurance proceeds payable to Tenant under Tenant’s insurance required under items (ii) of Section 10.3.2 of this Lease.

No provision of this Lease shall be deemed waived by either party hereto unless expressly waived in a writing signed thereby. The waiver by either party hereto of any breach of any term, covenant or condition herein contained shall not be deemed to be a waiver of any subsequent breach of same or any other term, covenant or condition herein contained. The subsequent acceptance of Rent hereunder by Landlord shall not be deemed to be a waiver of any preceding breach by Tenant of any term, covenant or condition of this Lease, other than the failure of Tenant to pay the particular Rent so accepted, regardless of Landlord's knowledge of such preceding breach at the time of acceptance of such Rent. No acceptance of a lesser amount than the Rent herein stipulated shall be deemed a waiver of Landlord's right to receive the full amount due, nor shall any endorsement or statement on any check or payment or any letter accompanying such check or payment be deemed an accord and satisfaction, and Landlord may accept such check or payment without prejudice to Landlord's right to recover the full amount due. No receipt of monies by Landlord from Tenant after the termination of this Lease shall in any way alter the length of the Lease Term or of Tenant's right of possession hereunder, or after the giving of any notice shall reinstate, continue or extend the Lease Term or affect any notice given Tenant prior to the receipt of such monies, it being agreed that after the service of notice or the commencement of a suit, or after final judgment for possession of the Premises, Landlord may receive and collect any Rent due, and the payment of said Rent shall not waive or affect said notice, suit or judgment.

more than ten percent (10%) of the rentable square feet of the Premises is taken, or if access to the Premises is substantially impaired, in each case for a period in excess of one hundred eighty (180) days, Tenant shall have the option to terminate this Lease effective as of the date possession is required to be surrendered to the authority. Tenant shall not because of such taking assert any claim against Landlord or the authority for any compensation because of such taking and Landlord shall be entitled to the entire award or payment in connection therewith, except that Tenant shall have the right to file any separate claim available to Tenant for any taking of Tenant's personal property and fixtures belonging to Tenant and removable by Tenant upon expiration of the Lease Term pursuant to the terms of this Lease, any Improvement and Alterations paid for by Tenant without reimbursement, and for moving expenses, so long as such claims do not diminish the award available to Landlord, its ground lessor with respect to the Building or Project or its mortgagee, and such claim is payable separately to Tenant. All Rent shall be apportioned as of the date of such termination. If any part of the Premises shall be taken, and this Lease shall not be so terminated, the Rent shall be proportionately abated in proportion to the ratio that the amount of rentable square footage of the Premises taken bears to the total rentable square footage of the Premises. Tenant hereby waives any and all rights it might otherwise have pursuant to Section 1265.130 of The California Code of Civil Procedure. Notwithstanding anything to the contrary contained in this Article 13, in the event of a temporary taking of all or any portion of the Premises for a period of one hundred and eighty (180) days or less, then this Lease shall not terminate but the Base Rent and the Additional Rent shall be abated for the period of such taking in proportion to the ratio that the amount of rentable square feet of the Premises taken bears to the total rentable square feet of the Premises. Landlord shall be entitled to receive the entire award made in connection with any such temporary taking.

14.1 Transfers. Tenant shall not, without the prior written consent of Landlord, assign, mortgage, pledge, hypothecate, encumber, or permit any lien to attach to, or otherwise transfer, this Lease or any interest hereunder, permit any assignment, or other transfer of this Lease or any interest hereunder by operation of law, sublet the Premises or any part thereof, or enter into any license or concession agreements or otherwise permit the occupancy or use of the Premises or any part thereof by any persons other than Tenant and its employees and contractors (all of the foregoing are hereinafter sometimes referred to collectively as "Transfers" and any person or entity to whom any Transfer is made or sought to be made is hereinafter sometimes referred to as a "Transferee"). If Tenant desires Landlord's consent to any Transfer, Tenant shall notify Landlord in writing, which notice (the "Transfer Notice") shall include (i) the proposed effective date of the Transfer, which shall not be less than fifteen (15) days nor more than one hundred eighty (180) days after the date of delivery of the Transfer Notice, (ii) a description of the portion of the Premises to be transferred (the "Subject Space"), (iii) a calculation of the "Transfer Premium", as that term is defined in Section 14.3 below, in connection with such Transfer, the name and address of the proposed Transferee, and a copy of all existing executed documentation pertaining to the proposed Transfer (including, without limitation, any executed sublease or assignment agreement, as the case may be), including all existing operative documents to be executed to evidence such Transfer or the agreements incidental or related to such Transfer, and (iv) if Tenant proposes to assign the Lease

other than to a Permitted Transferee Assignee, current financial statements of the proposed Transferee certified by an officer, partner or owner thereof and (v) an executed estoppel certificate from Tenant in the form attached hereto as Exhibit E. Notwithstanding the foregoing, in the event that (A) stock in the entity which constitutes the proposed Transferee (as opposed to an entity that "controls" or is otherwise an "affiliate" of the proposed Transferee, as those terms are defined in Section 14.7 of this Lease) is publicly traded on a national stock exchange, and (B) the proposed Transferee has its own, separate and distinct 10K and 10Q filing requirements (as opposed joint or cumulative filings with an entity that controls the proposed Transferee or with entities which are otherwise affiliates of the proposed Transferee) and such entity’s financial information is readily available in the public domain, then Tenant's obligation to provide Landlord with a copies of financial statement pursuant to clause (iv) of the preceding sentence shall be deemed satisfied. Any Transfer made without Landlord's prior written consent shall, at Landlord's option, be null, void and of no effect, and shall, at Landlord's option, constitute a default by Tenant under this Lease. Whether or not Landlord consents to any proposed Transfer, Tenant shall pay Landlord's reasonable review and processing fees, as well as any reasonable professional fees (including, without limitation, attorneys', accountants', architects', engineers' and consultants' fees) incurred by Landlord, not to exceed $3,500.00 for a particular Transfer, within thirty (30) days after written request by Landlord.

14.2 Landlord's Consent. Landlord shall not unreasonably withhold, condition or delay its consent to any proposed Transfer of the Subject Space to the Transferee on the terms specified in the Transfer Notice. Landlord shall approve or reasonably disapprove of any proposed Transfer within ten (10) business days after receipt of request for approval. If Landlord fails to respond within such ten (10) business day period, then Tenant may send Landlord a reminder notice setting forth such failure containing the following sentence at the top of such notice in bold, capitalized font at least twelve (12) points in size: "LANDLORD'S FAILURE TO RESPOND TO THIS NOTICE WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN LANDLORD'S DEEMED APPROVAL OF TENANT'S REQUEST FOR TRANSFER" (the "Transfer Reminder Notice"). Any such Transfer Reminder Notice shall include a complete copy of Tenant's Transfer Notice. If Landlord fails to respond within five (5) business days after receipt of a Transfer Reminder Notice, then Tenant’s Transfer for which Tenant requested Landlord's approval shall be deemed approved by Landlord. The parties hereby agree that it shall only be reasonable under this Lease and under any applicable Law for Landlord to withhold consent to any proposed Transfer where one or more of the following apply:

14.2.6 Either the proposed Transferee, or any person or entity which directly or indirectly, controls, is controlled by, or is under common control with, the proposed Transferee, (i) occupies space in the Project at the time of the request for consent, or (ii) is negotiating with Landlord to lease space in the Project at such time, or (iii) has actively negotiated with Landlord within the previous three (3) months to become a tenant of the Office Space (each of the foregoing referred to herein as a “Conflicted Tenant Transferee”); provided, however, Landlord must be able to accommodate such Conflicted Tenant Transferee with available office space in the Building which is comparable in size and within four (4) floors vertically of the Subject Space. If Landlord and any particular Conflicted Tenant Transferee do not enter into a lease of any portion of the Office Space for any reason (including, without limitation, the Conflicted Tenant Transferee’s determination that the portion of the Office Space offered by Landlord is not comparable to the Subject Space or is unacceptable for any reason) within ninety (90) days following Landlord’s disapproval of Tenant’s Transfer to such Conflicted Tenant Transferee pursuant to this Section 14.2.5, then, subject to the requirements of this Article 14, Tenant may Transfer the Subject Space to such Conflicted Tenant Transferee and Landlord shall have no further right to offer alternative space to the Conflicted Tenant Transferee or withhold its consent to such Transfer pursuant to this Section 14.2.5.

by such Transferee in connection with the Transfer in excess of the Rent and Additional Rent payable by Tenant under this Lease during the term of the Transfer on a per rentable square foot basis if less than all of the Premises is transferred. The Transfer Premium shall be calculated after first deducting the reasonable expenses incurred by Tenant for (i) any changes, alterations and improvements to the Premises in connection with the Transfer, (ii) any free base rent or other economic concessions reasonably provided to the Transferee, and (iii) any brokerage commissions or legal fees in connection with the Transfer (“Transfer Costs”). "Transfer Premium" shall also include, but not be limited to, key money, bonus money or other cash consideration paid by Transferee to Tenant in connection with such Transfer, and any payment in excess of fair market value for services rendered by Tenant to Transferee or for assets, fixtures, inventory, equipment, or furniture transferred by Tenant to Transferee in connection with such Transfer. Tenant shall first recoup all Transfer Costs from the Transferee before any Transfer Premium must be paid to Landlord. Notwithstanding anything set forth herein to the contrary, in no event shall Tenant be required to pay a Transfer Premium in connection with a Transfer pursuant to Section 14.8 of this Lease, below.

14.4 Landlord's Option as to Subject Space. Notwithstanding anything to the contrary contained in this Article 14, except in the case of a Transfer pursuant to Section 14.8 below and subject to the terms and conditions of this Section 14.4, Landlord shall have the option, by giving written notice to Tenant (the “Recapture Notice”) within thirty (30) days after receipt of any Transfer Notice in the event of a proposed assignment of this Lease or a proposed sublease of any portion of the Premises for a term of seventy-five percent (75%) or more of the then-remaining Lease Term (including any exercised Option Term) pursuant to the proposed Transfer described in the Transfer Notice, to recapture the Subject Space. Such Recapture Notice shall cancel and terminate this Lease with respect to the Subject Space as of the date stated in the Transfer Notice as the effective date of the proposed Transfer. In the event of a recapture by Landlord, if this Lease shall be canceled with respect to less than the entire Premises, the Rent reserved herein shall be prorated on the basis of the number of rentable square feet retained by Tenant in proportion to the number of rentable square feet contained in the Premises, and this Lease as so amended shall continue thereafter in full force and effect, and upon request of either party, the parties shall execute written confirmation of the same. If Landlord declines, or fails to elect in a timely manner to recapture the Subject Space under this Section 14.4, then, provided Landlord has consented to the proposed Transfer, Tenant shall be entitled to proceed to Transfer the Subject Space to the proposed Transferee, subject to provisions of this Article 14.

14.5 Effect of Transfer. If Landlord consents to a Transfer, (i) the TCCs of this Lease shall in no way be deemed to have been waived or modified, (ii) such consent shall not be deemed consent to any further Transfer by either Tenant or a Transferee, (iii) Tenant shall deliver to Landlord, promptly after execution, an original executed copy of all documentation pertaining to the Transfer in form reasonably acceptable to Landlord, (iv) Tenant shall furnish upon Landlord's request a complete statement, certified by an independent certified public accountant, or Tenant's chief financial officer, setting forth in detail the computation of any Transfer Premium Tenant has derived and shall derive from such Transfer, and (v) no Transfer relating to this Lease or agreement entered into with respect thereto, whether with or without Landlord's consent, shall relieve Tenant or any guarantor of the Lease from any liability under this Lease, including, without limitation, in connection with the Subject Space. Notwithstanding anything to the contrary set forth in this Lease, the Original Tenant shall not be bound by any amendment or agreement which is not expressly executed and delivered by the Original Tenant, and Landlord is not authorized or entitled to rely upon any assignee or subtenant to the contrary, whether or not the same is a Permitted Transferee. Tenant shall provide Landlord with a detailed statement setting forth the calculation of any Transfer Premium Tenant either has or will derive from such Transfer (which statement shall include reasonable documentation evidencing such calculation of Transfer Premium, if any). If the Transfer Premium respecting any Transfer shall be found understated, Tenant shall, within thirty (30) days after demand, pay the deficiency, and if understated by more than three percent (3%), Tenant shall pay Landlord's reasonable costs of such audit up to a maximum of Five Thousand Dollars ($5,000.00).

14.7 Occurrence of Default. Any Transfer hereunder shall be subordinate and subject to the provisions of this Lease, and if this Lease shall be terminated during the term of any Transfer, Landlord shall have the right to: (i) treat such Transfer as cancelled and repossess the Subject Space by any lawful means, or (ii) require that such Transferee attorn to and recognize Landlord as its landlord under any such Transfer. If Tenant shall be in default under this Lease, beyond all applicable notice and cure periods expressly set forth in this Lease, Landlord is hereby irrevocably authorized to direct any Transferee to make all payments under or in connection with the Transfer directly to Landlord (which Landlord shall apply towards Tenant's obligations under this Lease) until such default is cured. Such Transferee shall rely on any representation by Landlord that Tenant is in default hereunder, without any need for confirmation thereof by Tenant. Upon any assignment, the assignee shall assume in writing all obligations and covenants of Tenant thereafter to be performed or observed under this Lease. No collection or acceptance of rent by Landlord from any Transferee shall be deemed a waiver of any provision of this Article 14 or the approval of any Transferee or a release of Tenant from any obligation under this Lease, whether theretofore or thereafter accruing. In no event shall Landlord's enforcement of any provision of this Lease

14.8 Deemed Consent Transfers. Notwithstanding anything to the contrary contained in this Lease, (A) an assignment or subletting of all or a portion of the Premises to an affiliate of Tenant (an entity which is controlled by, controls, or is under common control with, Tenant), (B) a sale of corporate shares of capital stock in Tenant in connection with an initial public offering of Tenant's stock on a nationally-recognized stock exchange, (C) an assignment of the Lease to an entity which acquires all or substantially all of the stock or assets of Tenant, (D) an assignment of the Lease to an entity which is the resulting entity of a merger or consolidation of Tenant during the Lease Term, or (E) an assignment or sublease to an entity acquiring and continuing Tenant’s business operations at or from the Premises, shall not be deemed a Transfer requiring Landlord's consent under this Article 14 (any such assignee or sublessee described in items (A) through (E) of this Section 14.8 hereinafter referred to as a "Permitted Transferee"), provided that (i) Tenant notifies Landlord at least ten (10) business days prior to the effective date of any such assignment or sublease (or at least ten (10) business days after the effective date of such assignment or sublease if Tenant is prevented by Law or confidentiality requirements from disclosing such transaction to Landlord prior to the consummation thereof) and promptly supplies Landlord with any documents or information reasonably requested by Landlord regarding such Transfer or Permitted Transferee as set forth above, (ii) such assignment or sublease is not a subterfuge by Tenant to avoid its obligations under this Lease, (iii) either Tenant or such Permitted Transferee shall have a tangible net worth (not including goodwill as an asset) computed in accordance with generally accepted accounting principles ("Net Worth") at least equal to $150,000,000, (iv) no assignment or sublease relating to this Lease, whether with or without Landlord's consent, shall relieve Tenant from any liability under this Lease, and (v) the liability of such Permitted Transferee under an assignment shall be joint and several with Tenant. An assignee of Tenant's entire interest in this Lease who qualifies as a Permitted Transferee may also be referred to herein as a "Permitted Transferee Assignee." "Control," as used in this Section 14.8, shall mean the ownership, directly or indirectly, of more than fifty percent (50%) of the voting securities of, or possession of the right to vote, in the ordinary direction of its affairs, of more than fifty percent (50%) of the voting interest in, any person or entity.

15.2 Removal of Tenant Property by Tenant. Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in good order and condition given the length of the Lease Term, reasonable wear and tear, damage from casualty and condemnation and repairs which are specifically made the responsibility of Landlord hereunder excepted. For purposes of clarification, upon the expiration of the Lease Term, Tenant shall have no obligation to “refresh” or upgrade the Premises, such as by painting or carpeting or modifying any fixtures. Upon such expiration or termination, in addition to Tenant's obligations under Section 29.32, below, except as otherwise set forth in this Lease, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, server and telephone equipment, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.

If Tenant holds over after the expiration of the Lease Term or earlier termination thereof, with or without the express or implied consent of Landlord, such tenancy shall be a tenancy at sufferance only, and shall not constitute a renewal hereof or an extension for any further term, and in such case Base Rent shall be payable at a monthly rate equal to the product of (A) the Base Rent applicable during the last rental period of the Lease Term under this Lease, and (B) a percentage equal to one hundred fifty percent (150%). Such tenancy at sufferance shall be subject to every other applicable term, covenant and agreement contained herein. Tenant’s payment of Rent as set forth in this Article 16 shall be proportionately reduced for every floor of the Premises vacated by Tenant during any holdover period such that Tenant shall only pay Rent for those floor(s) of the Building actually not surrendered by Tenant in accordance with the terms and conditions of this Lease during all or any portion of any month of any holdover period on a per diem basis; provided, however, to the extent that Landlord has entered into a third-party lease with respect to a portion of the Premises (and Landlord has provided to Tenant notice of such lease at least sixty (60) days prior to the applicable Lease Expiration Date), and such third-party lease is applicable to one or more floors that Tenant has vacated and one or more floor that Tenant has failed to vacate, then Tenant shall be deemed to be holding over is all of the space governed by such third-party lease. Nothing contained in this Article 16 shall be construed as consent by Landlord to any holding over by Tenant, and Landlord expressly reserves the right to require Tenant to vacate and deliver

possession of the Premises to Landlord as provided in this Lease upon the expiration or other termination of this Lease. The provisions of this Article 16 shall not be deemed to limit or constitute a waiver of any other rights or remedies of Landlord provided herein or at law. If Tenant holds over without Landlord's express written consent, and tenders payment of rent for any period beyond the expiration of the Lease Term by way of check (whether directly to Landlord, its agents, or to a lock box) or wire transfer, Tenant acknowledges and agrees that the cashing of such check or acceptance of such wire shall be considered inadvertent and not be construed as creating a month-to-month tenancy, provided Landlord refunds such payment to Tenant promptly upon learning that such check has been cashed or wire transfer received. Tenant acknowledges that any holding over without Landlord’s express written consent may compromise or otherwise affect Landlord's ability to enter into new leases with prospective tenants regarding the Premises. Therefore, if Tenant fails to vacate and deliver the Premises upon the termination or expiration of this Lease, in addition to any other liabilities to Landlord accruing therefrom, Tenant shall protect, defend, indemnify and hold Landlord harmless from and against all claims made by any succeeding tenant founded upon such failure to vacate and deliver, and any losses suffered by Landlord, including lost profits, resulting from such failure to vacate and deliver. Tenant agrees that any proceedings necessary to recover possession of the Premises, whether before or after expiration of the Lease Term, shall be considered an action to enforce the terms of this Lease for purposes of the awarding of any attorney’s fees in connection therewith.

17.1 Tenant Estoppel. Within ten (10) business days following a request in writing by Landlord, Tenant shall execute, acknowledge and deliver to Landlord an estoppel certificate, which, as submitted by Landlord, shall be in the form of Exhibit E, attached hereto, indicating therein any exceptions thereto that may exist at that time and shall also contain any other factual information reasonably requested by Landlord or Landlord's mortgagee or prospective mortgagee. If Tenant fails to timely execute, acknowledge and deliver such estoppel certificate (or provide written comments to any proposed certificate delivered by Landlord), Landlord may provide to Tenant a second written request with respect to such estoppel certificate which written notice must state in bold and all caps “FAILURE TO RESPOND TO THIS WRITTEN NOTICE WITHIN FIVE (5) BUSINESS DAYS AFTER DELIVERY HEREOF IN ACCORDANCE WITH THE LEASE SHALL CONSTITUTE ACCEPTANCE OF AN ESTOPPEL CERTIFICATE”. If Tenant fails to execute and deliver such certificate (or provide written comments to any proposed certificate delivered by Landlord) within a five (5) business day period following the receipt of Landlord’s second written request therefor, such failure shall constitute an acceptance of the Premises and an acknowledgment by Tenant that statements included in the estoppel certificate are true and correct, without exception. Any such certificate may be relied upon by any prospective mortgagee or purchaser of all or any portion of the Project. If Tenant provides written comments to any estoppel certificate received from Landlord, then Tenant shall have five (5) business days following receipt of a revised estoppel certificate to execute, acknowledge and deliver to Landlord such revised estoppel certificate (or provide written comments to any such revised estoppel certificate delivered by Landlord) and the same process described above shall apply with respect

17.2 Landlord Estoppel. Landlord hereby agrees to provide to Tenant an estoppel certificate signed by Landlord, containing the same types of information, and within the same periods of time, as set forth above, with such changes as are reasonably necessary to reflect that the estoppel certificate is being granted and signed by Landlord to Tenant, rather than from Tenant to Landlord or a lender, and shall also contain any other factual information reasonably requested by Tenant. If Landlord fails to timely execute, acknowledge and deliver such estoppel certificate (or provide written comments to any proposed certificate delivered by Tenant), Tenant may provide to Landlord a second written request with respect to such estoppel certificate which written notice must state in bold and all caps “FAILURE TO RESPOND TO THIS WRITTEN NOTICE WITHIN FIVE (5) BUSINESS DAYS AFTER DELIVERY HEREOF IN ACCORDANCE WITH THE LEASE SHALL CONSTITUTE ACCEPTANCE OF AN ESTOPPEL CERTIFICATE”. If Landlord fails to execute and deliver such certificate (or provide written comments to any proposed certificate delivered by Tenant) within a five (5) business day period following the receipt of Tenant’s second written request therefor, such failure shall constitute an acknowledgment by Landlord that statements included in the estoppel certificate are true and correct, without exception. Any such certificate may be relied upon by any prospective assignee, lender, subtenant or investor of Tenant. If Landlord provides written comments to any estoppel certificate received from Tenant, then Landlord shall have five (5) business days following receipt of a revised estoppel certificate to execute, acknowledge and deliver to Tenant such revised estoppel certificate (or provide written comments to any such revised estoppel certificate delivered by Tenant) and the same process described above shall apply with respect to Landlord’s failure to timely execute, acknowledge and deliver such revised estoppel certificate (or provide written comments to any proposed certificate delivered by Tenant).

17.3 Financial Information. At any time during the Lease Term but in any event not more than once per Lease Year, Landlord may require Tenant to provide Landlord with a current financial statement and financial statements of the two (2) years prior to the current financial statement year. Such statements shall be prepared in accordance with generally accepted accounting principles and, if such is the normal practice of Tenant, shall be audited by an independent certified public accountant. Landlord agrees that Tenant’s financial statements are deemed to be Tenant’s confidential information. Landlord hereby agrees to maintain Tenant’s financial statements as proprietary and confidential and will take reasonable measures to avoid disclosure and unauthorized use of the financial statements (including, without limitation, measures at least as stringent as it takes to protect its own confidential information of a similar nature). Landlord agrees not to disclose Tenant’s financial statements to any third party other than as-needed to any lender, prospective lender, or purchaser and to Landlord’s attorneys, accountants, investment advisors and similar business advisors, provided that in the case of each such disclosure: (a) such disclosures are for bona fide business purposes related to the Project; (b) all such third parties have signed a commercially reasonable non-disclosure agreement prior to receiving any of Tenant's financial statements; and (c) in case of any breach by any such third party of the applicable non-disclosure agreement, Landlord shall not be liable to Tenant for such breach, but Landlord shall reasonably cooperate with Tenant, at Tenant's sole cost and expense, to enforce the terms of such non-disclosure

agreement, including, without limitation, assigning Landlord's rights to enforce such non-disclosure agreement to Tenant. Notwithstanding the foregoing, the obligation of confidentiality provided for with respect to Tenant’s financial statements shall not apply to the extent the financial statements: (i) are required to be disclosed by applicable Laws after giving reasonable notice to Tenant to allow Tenant time to seek a protective order, to the extent permitted by applicable Laws, (ii) are, at the time of delivery, already in the lawful possession of the receiving party, (iii) are, at the time of disclosure, in a public offering or in the public domain, or, after disclosure by a person or entity not subject to the confidentiality obligations herein, has become part of the public domain, (iv) are independently developed (1) by the receiving party without breaching the confidentiality obligations herein, or (2) by parties who have not had, either directly or indirectly, access to or knowledge of the financial statements; or (v) are disclosed with Tenant’s prior written consent. Notwithstanding the foregoing, in the event that (A) stock in the entity which constitutes Tenant under this Lease (as opposed to an entity that "controls" Tenant or is otherwise an "affiliate" of Tenant, as those terms are defined in Section 14.7 of this Lease) is publicly traded on a national stock exchange, and (B) Tenant has its own, separate and distinct 10K and 10Q filing requirements (as opposed joint or cumulative filings with an entity that controls Tenant or with entities which are otherwise affiliates of Tenant), then Tenant's obligation to provide Landlord with a copy of its most recent current financial statement shall be deemed satisfied

This Lease shall be subject and subordinate to all present and future ground or underlying leases of the Building or Project and to the lien of any mortgage, trust deed, ground lease or other security documents now or hereafter in force against the Building or Project or any part thereof, if any, and to all renewals, extensions, modifications, consolidations and replacements thereof (collectively, “Security Documents”), and to all advances made or hereafter to be made upon the security of such mortgages or trust deeds, unless the holders of such mortgages, trust deeds or other encumbrances, or the lessors under such ground lease or underlying leases, require in writing that this Lease be superior thereto. Tenant’s agreement to subordinate this Lease to any Security Document shall be subject to Tenant’s receipt of an SNDA Agreement (as hereinafter defined). An “SNDA Agreement” shall mean a commercially reasonable subordination, non-disturbance and attornment agreement between Landlord, Tenant and the holder of such Security Document, which provides, among other things, that, so long as Tenant is paying the rent due under the Lease and is not otherwise in default under the Lease beyond any applicable cure period, its right to possession and the other terms of the Lease shall remain in full force and effect. Any SNDA Agreement shall expressly provide that (i) upon any party succeeding to the interest of Landlord under this Lease, such party shall be liable for the performance of Landlord’s construction obligations under this Lease, (ii) upon any party succeeding to the interest of Landlord under this Lease, such party shall be liable for the payment of any unpaid portion of the Improvement Allowance, (iii) the provisions of this Lease regarding any casualty or condemnation shall control notwithstanding any conflicting provisions in the Security Document, and (iv) Tenant’s right of set-off pursuant to Section 2.6 of the Work Letter below for failure to pay the Improvement Allowance or Section 29.24 below for failure to pay brokerage commissions shall remain in effect and upon any party succeeding to the

interest of Landlord under this Lease, any accumulated amounts which Tenant may have to set-off against Rent and other amounts due under this Lease shall continue in full force and effect and be binding against such party and Tenant shall have the continued right to set-off such amounts against rent and other amounts due under this Lease (or, in lieu of the SNDA Agreement providing such express recognition of Tenant's right of set-off pursuant to Section 2.6 of the Work Letter for failure to pay the Improvement Allowance or Section 29.24 below for failure to pay brokerage commissions, Landlord may deliver to Tenant an unconditional, irrevocable standby letter of credit in the form and from an issuing bank meeting the requirements of the L-C to be delivered by Tenant to Landlord pursuant to Article 21 of this Lease and all of the other provisions of Article 21 below (other than the provisions regarding reductions in the L-C Amount) shall apply to such letter of credit (with such changes as necessary to reflect that the letter of credit is being delivered by Landlord to Tenant), in an amount equal to the sum of the then undisbursed amount, if any, of the Improvement Allowance and the unpaid commissions owed to Tenant's Broker, as protection for Tenant's ability to receive the Improvement Allowance pursuant to the terms of the Work Letter and for payment of commissions owed to Tenant's broker, and if the party succeeding to the interest of Landlord under this Lease fails to disburse the Improvement Allowance or to pay the commissions owed to Tenant's Broker, then Tenant may draw on the letter of credit in the amount and to the extent Tenant would have been able to off-set such amount pursuant to the terms of Section 2.6 of the Work Letter or Section 29.24 below, respectively). Tenant covenants and agrees in the event any proceedings are brought for the foreclosure of any such mortgage or deed in lieu thereof (or if any ground lease is terminated), to attorn to the lienholder or purchaser or any successors thereto upon any such foreclosure sale or deed in lieu thereof (or to the ground lessor), if so requested to do so by such purchaser or lienholder or ground lessor, and to recognize such purchaser or lienholder or ground lessor as the lessor under this Lease, provided such lienholder or purchaser or ground lessor shall agree to accept this Lease and not disturb Tenant's occupancy, so long as Tenant timely pays the rent and observes and performs the TCCs of this Lease to be observed and performed by Tenant. Landlord's interest herein may be assigned as security at any time to any lienholder. Tenant shall, within five (5) business days of request by Landlord, execute an SNDA Agreement. If Tenant fails to timely execute such SNDA Agreement (or provide written comments to any proposed SNDA Agreement delivered by Landlord), Landlord may provide to Tenant a second written request with respect to such SNDA Agreement which written notice must state in bold and all caps “FAILURE TO RESPOND TO THIS WRITTEN NOTICE WITHIN FIVE (5) BUSINESS DAYS AFTER RECEIPT HEREOF SHALL CONSTITUTE AN EVENT OF DEFAULT”. If Tenant fails to execute such SNDA (or provide written comments to any proposed SNDA Agreement delivered by Landlord) with such five (5) business day period shall be deemed to be a material event of default hereunder (subject to additional notice and cure set forth in Section 19.1.1 below). Tenant waives the provisions of any current or future Law which may give or purport to give Tenant any right or election to terminate or otherwise adversely affect this Lease and the obligations of Tenant hereunder in the event of any foreclosure proceeding or sale. If Tenant provides commercially reasonable written comments to any SNDA Agreement received from Landlord, then Tenant shall have five (5) business days following receipt of a revised SNDA Agreement to execute, acknowledge and deliver to Landlord such revised SNDA Agreement (or provide commercially reasonable written comments to any such revised SNDA Agreement delivered by Landlord) and the same process described above shall apply with respect to Tenant’s failure to timely execute, acknowledge and deliver such revised

Premises as a result thereof, Landlord shall be in default of this Lease if Landlord fails to commence to perform such obligation within five (5) business days (or such lesser period of time as is reasonable under the circumstances or in the event of an emergency) after the receipt of notice from Tenant specifying in reasonable detail Landlord's failure to perform; provided, however, if the nature of Landlord's obligation is such that more than five (5) business days (or such lesser period of time as is reasonable under the circumstances or in the event of an emergency) are required for its commencement of performance, then Landlord shall not be in default under this Lease if it shall commence such performance within such five (5) business day period (or such lesser period of time as is reasonable under the circumstances or in the event of an emergency) and thereafter diligently pursues the same to completion. As used in this Section 19.6.1, the term “emergency” means any event which threatens immediate injury or health threat to individuals or damage to property Upon any such default by Landlord under this Lease, Tenant may, except as otherwise specifically provided in this Lease to the contrary, exercise any of its rights provided at law or in equity. Any final award, which is not subject to appeal, from a court or arbitrator in favor of Tenant requiring payment by Landlord under this Lease which is not paid by Landlord within the time period directed by such award (plus interest on the amount of such award from the date incurred at the Interest Rate until such amount is offset by Tenant as provided herein) may, in addition to all other remedies available to Tenant at law or in equity by statute or otherwise, be offset by Tenant from Rent next due and payable under this Lease; provided, however, Tenant may not deduct the amount of the award against more than fifty percent (50%) of Base Rent next due and owing (until such time as the entire amount of such judgment is deducted) to the extent following a foreclosure or a deed-in-lieu of foreclosure.

requirements of this Article 21, including, without limitation, all of the requirements of Section 21.2 below, all as set forth more particularly hereinbelow. Tenant shall pay all expenses, points and/or fees incurred by Tenant in obtaining the L-C. Landlord hereby approves the following as the Bank, if selected by Tenant: JP Morgan Chase, Wells Fargo Bank, Bank of America Merrill Lynch, Union Bank, PNC Bank, Comerica Bank, Sumitomo Corporation, Barclays Capital and Silicon Valley Bank. Landlord acknowledges and agrees that Silicon Valley Bank (the California bank subsidiary of SVB Financial Group) is approved as the Bank as of the Effective Date; provided, however, that if Silicon Valley Bank’s Bank’s Credit Rating Threshold falls to (i) a long term issuer credit rating from Standard and Poor’s Professional Rating Service of BBB or below or (ii) a long term issuer credit rating from Moody’s Professional Rating Service of BAA1 or below, then Landlord may elect for Tenant to replace the L-C with a L-C from a Bank that meets the Bank’s Credit Rating Threshold as set forth herein and Tenant shall, within thirty (30) days after written notice from Landlord of such election, provide Landlord with a replacement L-C which shall comply with all of the provisions of this Article 21. In the event of an assignment by Tenant of its interest in the Lease (and irrespective of whether Landlord's consent is required for such assignment), any replacement or substitute letter of credit from the assignee shall be subject to Landlord's prior written approval in accordance with the requirements of this Article 21.

shall have occurred or be applicable: (A) such amount is due to Landlord under the terms and conditions of this Lease, or (B) Tenant has filed a voluntary petition under the U. S. Bankruptcy Code or any state bankruptcy code (collectively, "Bankruptcy Code"), or (C) an involuntary petition has been filed against Tenant under the Bankruptcy Code, or (D) the Bank has notified Landlord that the L-C will not be renewed or extended through the L‑C Expiration Date, or (E) a Bank Credit Threat or Receivership (as those terms are defined in Section 21.2.5 above and Section 21.6.1 below, respectively) has occurred and Tenant has failed to comply with the requirements of either Section 21.2.5 above or 21.6 below, as applicable. If Tenant shall breach any provision of this Lease or otherwise be in default hereunder or if any of the foregoing events identified in Sections 21.3(B) through (E) shall have occurred, Landlord may, but without obligation to do so, and without notice to Tenant, draw upon the L-C, in part or in whole, and the proceeds may be applied by Landlord (i) to cure any breach or default of Tenant, (ii) against any Rent payable by Tenant under this Lease that is not paid when due and/or (iii) to pay for all losses and damages that Landlord has suffered (including, without limitation, damages that may be granted to Landlord under California Civil Code Section 1951.2) as a result of any breach or default by Tenant under this Lease. The use, application or retention of the L-C, or any portion thereof, by Landlord shall not prevent Landlord from exercising any other right or remedy provided by this Lease or by any applicable Law, it being intended that Landlord shall not first be required to proceed against the L-C, and shall not operate as a limitation on any recovery to which Landlord may otherwise be entitled. Tenant agrees not to interfere in any way with payment to Landlord of the proceeds of the L-C, either prior to or following a "draw" by Landlord of any portion of the L-C, regardless of whether any dispute exists between Tenant and Landlord as to Landlord's right to draw upon the L-C. No condition or term of this Lease shall be deemed to render the L-C conditional to justify the issuer of the L-C in failing to honor a drawing upon such L-C in a timely manner. Tenant agrees and acknowledges that (1) the L-C constitutes a separate and independent contract between Landlord and the Bank, (2) Tenant is not a third party beneficiary of such contract, and (3) in the event Tenant becomes a debtor under any chapter of the Bankruptcy Code, neither Tenant, any trustee, nor Tenant's bankruptcy estate shall have any right to restrict or limit Landlord's claim and/or rights to the L-C and/or the proceeds thereof by application of Section 502(b)(6) of the U. S. Bankruptcy Code or otherwise.

pay for all losses and damages that Landlord has suffered (including, without limitation, damages that may be granted to Landlord under California Civil Code Section 1951.2) as a result of any breach or default by Tenant under this Lease. Any unused proceeds shall constitute the property of Landlord and need not be segregated from Landlord's other assets. Landlord agrees that the amount of any proceeds of the L-C received by Landlord, and not (a) applied against any Rent payable by Tenant under this Lease that was not paid when due or (b) used to pay for any losses and/or damages suffered by Landlord (including, without limitation, damages that may be granted to Landlord under California Civil Code Section 1951.2) as a result of any breach or default by Tenant under this Lease (the “Unused L-C Proceeds”), shall be paid by Landlord to Tenant (x) upon receipt by Landlord of a replacement L-C in the full L-C Amount, which replacement L-C shall comply in all respects with the requirements of this Article 21, or (y) within thirty (30) days after the L‑C Expiration Date; provided, however, that if prior to the L‑C Expiration Date a voluntary petition is filed by Tenant, or an involuntary petition is filed against Tenant by any of Tenant's creditors, under the Bankruptcy Code, then Landlord shall not be obligated to make such payment in the amount of the Unused L-C Proceeds until either all preference issues relating to payments under this Lease have been resolved in such bankruptcy or reorganization case or such bankruptcy or reorganization case has been dismissed.

21.6.1 Bank Placed Into Receivership. In the event the Bank is placed into receivership or conservatorship (any such event, a “Receivership”) by the Federal Deposit Insurance Corporation or any successor or similar entity (the “FDIC”), then, effective as of the date such Receivership occurs, the L-C shall be deemed to not meet the requirements of this Article 21, and, within ten (10) business days following Landlord's notice to Tenant of such Receivership (the "LC Replacement Notice"), Tenant shall (i) replace the L-C with a substitute L-C from a different issuer reasonably acceptable to Landlord and that complies in all respects with the requirements of this Article 21, or (ii) in the event Tenant demonstrates to Landlord that Tenant is reasonably unable to obtain a substitute L-C from a different issuer reasonably acceptable to Landlord and that complies in all respects with the requirements of this Article 21 within the foregoing ten (10) business day period, deposit with Landlord cash in the L-C Amount (the “Interim Cash Amount”); provided, however, that, in the case of the foregoing sub-clause (ii), Tenant shall, within sixty (60) days after the LC Replacement Notice, replace the L-C with a substitute L-C from a different issuer reasonably acceptable to Landlord and that complies in all respects with the requirements of this Article 21, and upon Landlord’s receipt and acceptance of such replacement L-C, Landlord shall return to Tenant the Interim Cash Amount, with no obligation on the part of Landlord to pay any interest thereon. If Tenant fails to comply in any respect with the requirements of this Section 21.6.1, then, notwithstanding anything in this Lease to the contrary, Landlord shall have the right to (i) declare Tenant in default of this Lease for which there shall be no notice or grace or cure periods being applicable thereto other than the aforesaid ten (10) business day and sixty (60) day periods, (b) if applicable, retain such Interim Cash Amount until such time as such default is cured by Tenant, which retention shall not constitute a waiver of any right or remedy available to Landlord under the terms of this Lease or at law, and (c) pursue any and all remedies available to it under this Lease and at law, including, without limitation, if Tenant has failed to provide the Interim Cash Amount, treating any Receivership as a Bank Credit Threat and exercising Landlord’s remedies under Section

21.6.2 Interim Cash Amount. During any period that Landlord remains in possession of the Interim Cash Amount (any such period, a “Deposit Period”), it is understood by the parties that such Interim Cash Amount shall be held by Landlord as security for the full and faithful performance of Tenant’s covenants and obligations under this Lease. The Interim Cash Amount shall not constitute an advance of any Rent, an advance payment of any other kind, nor a measure of Landlord’s damages in case of Tenant’s default. If, during any such Deposit Period, Tenant defaults with respect to any provisions of this Lease, as amended, including, but not limited to, the provisions relating to the payment of Rent, the removal of property and the repair of resultant damage, then Landlord may but shall not be required to, from time to time, without notice to Tenant and without waiving any other remedy available to Landlord, use the Interim Cash Amount, or any portion of it, to the extent necessary to cure or remedy such default or failure or to compensate Landlord for all damages sustained by Landlord resulting from Tenant’s default or failure to comply fully and timely with its obligations pursuant to this Lease, as amended. Tenant shall immediately pay to Landlord on demand any amount so applied in order to restore the Interim Cash Amount to its original amount, and Tenant’s failure to immediately do so shall constitute a default under this Lease, as amended. In the event Landlord is in possession of the Interim Cash Amount at the expiration or earlier termination of this Lease, as amended, and Tenant is in compliance with the covenants and obligations set forth in this Lease, as amended, at the time of such expiration or termination, then Landlord shall return to Tenant the Interim Cash Amount, less any amounts deducted by Landlord to reimburse Landlord for any sums to which Landlord is entitled under the terms of this Lease, as amended, within sixty (60) days following both such expiration or termination and Tenant’s vacation and surrender of the Premises. Landlord’s obligations with respect to the Interim Cash Amount are those of a debtor and not a trustee. Landlord shall not be required to maintain the Interim Cash Amount separate and apart from Landlord’s general or other funds, and Landlord may commingle the Interim Cash Amount with any of Landlord’s general or other funds. Tenant shall not at any time be entitled to interest on the Interim Cash Amount. In the event of a transfer of Landlord's interest in the Building, Landlord shall transfer the Interim Cash Amount, in whole or in part, to the transferee and thereupon Landlord shall, without any further agreement between the parties, be released by Tenant from all liability therefor, and it is agreed that the provisions hereof shall apply to every transfer or assignment of the whole or any portion of said Interim Cash Amount to a new landlord. Tenant hereby waives the provisions of Section 1950.7 of the California Civil Code, or any successor statute.

of delivery of the First L-C Reduction Notice and the expiration of the Fixed Period (such effective date being the “First Reduction Effective Date”). If at any time following the First Reduction Effective Date, Tenant tenders to Landlord documentation evidencing that Tenant has fully satisfied the L-C Reduction Conditions following the First Reduction Effective Date (the “Second L-C Reduction Notice”), the then current L-C Amount shall be reduced (the “Second L-C Reduction”) by an additional Two Million Dollars ($2,000,000) as of the later of the delivery of the Second L-C Reduction Notice and twelve (12) months following the First Reduction Effective Date (such effective date being the “Second Reduction Effective Date” and, together with the First Reduction Effective Date, each a “Reduction Effective Date”). For purposes of this Section 21.7, the “L-C Reduction Conditions” shall mean the following: (A) Tenant is not then in default under this Lease for which Tenant has received written notice pursuant to the TCCs of Section 29.18, (B) Tenant’s Financial Information reflects an average market capitalization that is no less than Two Billion Dollars ($2,000,000,000) during the trailing twelve (12) full consecutive calendar months immediately preceding the applicable Reduction Effective Date, (C) Tenant’s Financial Information reflects a tangible net worth (not including goodwill and other intangible assets) that is no less than Seventy-Five Million Dollars ($75,000,000), (D) with respect to the Second L-C Reduction only, the First Reduction Effective Date has not previously occurred during the twelve (12) consecutive full calendar months immediately preceding the Second Reduction Effective Date, and (E) Tenant has at least Five Million Dollars ($5,000,000) in free cash flow (i.e., net cash used in operating activities, less capital expenditures and capitalized software development costs) during the trailing twelve (12) consecutive calendar months immediately preceding the applicable Reduction Effective Date. Concurrent with Tenant’s delivery of the First L-C Reduction Notice or the Second L-C Reduction Notice (each, a “Reduction Notice”), Tenant shall deliver to Landlord for its review Tenant’s financial statements prepared in accordance with generally accepted accounting principles and audited by a public accounting firm reasonably acceptable to Landlord and otherwise in compliance with Article 17 evidencing Tenant’s full satisfaction of the L-C Reduction Conditions (“Tenant’s Financial Information”). Tenant’s Financial Information shall be certified as true, correct and complete by Tenant's chief financial officer, and at a minimum shall include an income statement, balance sheet and cash flow, and applicable notes thereto. Notwithstanding the foregoing, in the event that (A) stock in the entity which constitutes Tenant under this Lease (as opposed to an entity that "controls" Tenant or is otherwise an "affiliate" of Tenant, as those terms are defined in Section 14.7 of this Lease) is publicly traded on a national stock exchange, and (B) Tenant has its own, separate and distinct 10K and 10Q filing requirements (as opposed joint or cumulative filings with an entity that controls Tenant or with entities which are otherwise affiliates of Tenant) which are readily available in the public domain, then Tenant’s obligation to provide Tenant’s Financial Information shall be deemed satisfied by the publicly available financial information for Tenant. As of the applicable Reduction Effective Date on which Tenant is entitled to a reduction of the L-C Amount pursuant to this Section 21.7, any reductions of the L-C Amount shall be accomplished by Tenant providing Landlord, at Tenant’s sole cost and expense, with an amendment to the existing L-C or a replacement L-C that fully complies in all respect to the requirements set forth in this Article 21 in the amount of the applicable reduced L-C as of such Reduction Effective Date. In the event that Tenant fails to deliver evidence demonstrating that Tenant has fully satisfied the applicable Reduction Conditions or if Tenant fails to deliver an amendment to the L-C or replacement L-C as required herein on or prior to the applicable Reduction Effective Date, then the L-C Amount shall not be reduced as of such Reduction

21.8 L-C for Must-Take. Notwithstanding anything to the contrary contained in Section 1.4.4, if Tenant’s Financial Information reflects (i) an average market capitalization that is more than Three Billion Five Hundred Million Dollars ($3,500,000,000) during the trailing twelve (12) consecutive calendar months immediately preceding the date on which Tenant is required to deliver the amendment to the existing L-C or a new or replacement L-C pursuant to Section 1.4.4 above (such date is hereinafter referred to as the “Additional Must-Take L-C Delivery Date”); and (ii) that Tenant has at least Six Million Dollars ($6,000,000) in free cash flow (i.e., net cash used in operating activities, less capital expenditures and capitalized software development costs) during the trailing twelve (12) consecutive calendar months immediately preceding the Additional Must-Take L-C Delivery Date (collectively, the “Must-Take L-C Withdrawal Conditions”), then Tenant shall have no obligation to deliver such amendment to the existing L-C or a new or replacement L-C pursuant to Section 1.4.4. In addition, if Tenant does not meet the Must-Take L-C Withdrawal Conditions prior to the Additional Must-Take L-C Delivery Date and therefore delivers the amendment to the existing L-C or a new or replacement L-C pursuant to Section 1.4.4, if at any time following the Additional Must-Take L-C Delivery Date, Tenant meets the Must-Take L-C Withdrawal Conditions and Tenant is not then in default under this Lease beyond applicable notice and cure periods, Tenant may provide Landlord with written notice requesting that the L-C Amount be reduced by the Additional Must-Take L-C Amount (the “Must-Take L-C Reduction Notice”). Concurrent with Tenant’s delivery of the Must-Take L-C Reduction Notice, Tenant shall deliver to Landlord for its review Tenant’s Financial Information evidencing Tenant’s satisfaction of the Must-Take L-C Withdrawal Conditions. Provided that Tenant meets such Must-Take L-C Withdrawal Conditions as evidenced by Tenant’s Financial Information, reduction of the L-C Amount by the Additional Must-Take L-C Amount shall be accomplished by Tenant providing Landlord, at Tenant’s sole cost and expense, with an amendment to the existing L-C or a replacement L-C that fully complies in all respect to the requirements set forth in this Article 21. For the avoidance of doubt, Tenant may exercise its rights pursuant to this Section 21.8 at any time Tenant meets the Must-Take L-C Withdrawal Conditions regardless of whether Tenant has previously or is concurrently seeking a reduction in the L-C Amount pursuant to Section 21.7.

23.4.1 General. Subject to the TCCs of this Section 23.4, commencing as of the date which is six (6) weeks prior to the Phase II Premises Lease Commencement Date, Tenant, at Tenant's sole cost and expense, shall have (a) the exclusive right (except to the extent provided below) to install, repair and maintain a single sign depicting Tenant's name and/or logo on the exterior of the south side of the Building facing the Salesforce Transit Center at a location to be mutually agreed upon by the parties higher on the Building than the height of the Salesforce Transit Center (“Tenant’s Transbay Signage”), and (b) the non-exclusive right (in common with Landlord and other third parties) to install, repair and maintain a single sign depicting Tenant's name and/or logo on the exterior of the north side of the Building facing Mission Street at a location to be mutually agreed upon by the parties (“Tenant’s Mission Street Signage”). Tenant’s Transbay Signage and Tenant’s Mission Street Signage are individually and collectively referred to herein as “Tenant's Signage”. Notwithstanding anything to the contrary set forth herein, Landlord shall only have the right to install the following signage on the side of the Building where Tenant’s Transbay Signage is located: (i) any customary operational signage and signage identifying Landlord (or any Landlord Affiliates) or as required by applicable Laws, (ii) signage for any ground-floor retail tenants, including, eyebrow signage, and façade signage (not to extend higher than the second floor), provided that the location of any retail tenant signage is limited to the façade above the storefront and (iii) signage on the interior and exterior of the Parking Garage, if applicable. Tenant

23.4.2 Tenant's Signage Specifications and Permits. The graphics, materials, color, design, method of illumination, lettering, size, specifications, exact location of Tenant's Signage and the manner in which Tenant’s Signage is installed shall be subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord hereby approves of Tenant's name and logo and other specifications with respect to Tenant’s signage, as generally depicted on Exhibit I-1 attached hereto. Without limiting the foregoing, the size of Tenant’s Mission Street Signage shall not exceed fifty percent (50%) of the total square footage of signage space on the exterior of the Building facing Mission Street permitted by applicable Laws, including without limitation, any applicable Laws promulgated by the City and County of San Francisco from time to time, with respect to such exterior building signage; provided, however, if Landlord has approved Tenant’s Signage pursuant to this Section 23.4.2, the size of Tenant’s Mission Street Signage shall not be reduced if there is a subsequent reduction in the total square footage of signage space permitted by applicable Laws on the exterior of the Building facing Mission Street unless following such reduction in the total square footage of signage space permitted by applicable Laws Tenant replaces Tenant’s Mission Street Signage, then the new sign installed as Tenant’s Mission Street Signage shall not exceed fifty percent (50%) of such reduced total square footage permitted by applicable Laws. In addition, Tenant's Signage shall be subject to Tenant's receipt, at its sole cost and expense, of all required governmental permits and approvals (including, without limitation, any governmental permits and approvals required by applicable Laws with respect to the illumination of Tenant’s Signage) and shall be subject to all applicable Laws. Landlord shall use commercially reasonable efforts, at no cost or expense to Landlord, to assist Tenant in obtaining all necessary governmental permits and approvals for Tenant’s Signage. Tenant hereby acknowledges that, notwithstanding Landlord's approval of Tenant's Signage, Landlord has made no representation or warranty to Tenant with respect to the probability of obtaining all necessary governmental approvals and permits for Tenant's Signage. In the event Tenant does not receive the necessary governmental approvals and permits for Tenant's Signage initially, Tenant may continue its pursuit thereof and Tenant's and Landlord's rights and obligations under the remaining TCCs of this Lease shall be unaffected. To the extent permitted by applicable Law, Tenant assumes all risk of defacement, damage, theft, loss and destruction of Tenant’s Signage due to any cause, including but not limited to, casualty, vandalism or any act or neglect of any other tenant, guest or occupant of the Project or any member of the public, and Landlord shall not be liable for any of the foregoing or obligated to carry insurance covering any of the foregoing.

23.4.4 Termination of Right to Tenant's Signage. The rights contained in this Section 23.4 shall remain in full force and effect (a) during such time as Tenant and/or its Permitted Transferees leases and is in continuous Occupancy of at least 155,300 of the rentable square feet of the Premises leased by Tenant under this Lease; (b) there exists no Tenant default that Tenant does not reasonably dispute, for the longer of (i) thirty (30) days and (ii) any applicable notice and cure period; and (c) so long as Tenant installs such Tenant’s Signage prior to the twenty-fifth (25^th) full calendar month following the Phase II Premises Lease Commencement Date (collectively, “Tenant’s Signage Conditions”). Upon the earlier to occur of (A) the expiration or earlier termination of this Lease or (B) ninety (90) days following the date that Landlord notifies Tenant that Tenant no longer satisfies Tenant’s Signage Conditions, (1) Landlord shall have the right to permit the installation of other signage on the exterior of the Building, subject to the TCCs of this Section 23.4.4, and (2) Tenant shall, at its sole cost and expense, cause Tenant's Signage to be removed and shall cause the areas in which such Tenant's Signage was located to be restored to the condition existing immediately prior to the placement of such Tenant's Signage except for ordinary wear and tear. If Tenant fails to timely remove such Tenant's Signage or to restore the areas in which such Tenant's Signage was located, as provided in the immediately preceding sentence, then Landlord may perform such work, and all reasonable, actual costs incurred by Landlord in so performing (including an administrative fee equal to five percent (5%)) shall be reimbursed by Tenant to Landlord within thirty (30) days after Tenant's receipt of an invoice therefor together with reasonable supporting evidence. In addition, if Tenant’s right to exclusive signage on the side of the Building on which Tenant’s Transbay Signage is located terminates following the date that Landlord notifies Tenant that Tenant no longer satisfies the Tenant’s Signage Conditions, such right to exclusive signage shall be of no further force and effect from and after the date of Tenant’s receipt of such notice from Landlord, regardless of whether Tenant once again satisfies Tenant’s Signage Conditions. Landlord acknowledges and agrees that if Tenant’s right to Tenant’s Signage terminates due to Tenant’s failure to meet the Tenant’s Signage Conditions set forth in item (a) or (c) above, Landlord shall not permit any other tenant, occupant or third party to install signage in the Tenant’s Signage locations unless such other tenant, occupant or third party directly leases and is in Occupancy of at least 155,300 rentable square feet of the Building. The TCCs of this Section 23.4.5 shall survive the expiration or earlier termination of this Lease.

23.4.5 Cost and Maintenance. Tenant shall at all times maintain Tenant’s Signage in good order, repair and condition to Landlord’s reasonable satisfaction. The costs of the actual sign comprising Tenant's Signage and the installation, design, construction, and any and all other costs associated with Tenant's Signage, including, without limitation, permits, and maintenance (including, if Tenant’s Signage is illuminated, relamping at reasonable intervals) and repair costs, shall be the sole responsibility of Tenant. Should Tenant's Signage require repairs and/or maintenance, as determined in Landlord's reasonable judgment, Landlord shall have the right to provide notice thereof to Tenant and Tenant shall cause such repairs and/or maintenance to commence within five (5) business days after receipt of such notice from Landlord and be completed within ten (10) business days after receipt of such notice from Landlord, at Tenant's sole cost and expense; provided, however, if such repairs and/or maintenance are reasonably expected to require longer than ten (10) business days to perform, Tenant shall commence such repairs and/or maintenance within such five (5) business day period and shall diligently prosecute such repairs and maintenance to completion. Should Tenant fail to perform such repairs and/or maintenance

23.5.1 General. Subject to the TCCs of this Section 23.5, commencing as of the date which is six (6) weeks prior to the Phase II Premises Lease Commencement Date, Tenant shall have the non-exclusive right to install, at Tenant's sole cost and expense, a single Tenant identification electronic video sign (the “Tenant’s Lobby Sign”) on one wall located in the ground floor lobby of the Building. So long as Tenant satisfies the “Dominant Lobby Sign Location Condition,” as that term is defined in Section 23.5.4 below, Tenant’s Lobby Sign may be placed in the dominant position (but at all times subject and subordinate to Landlord’s signage which may be installed in a position dominant to Tenant’s Lobby Sign) at the location as generally depicted on Exhibit I-2 attached hereto (the “Lobby Signage Area”). Tenant acknowledges and agrees that Landlord shall have the right to temporarily remove, relocate and replace Tenant’s Lobby Sign at Landlord’s cost to the extent necessary in connection with and during the course of any repairs, changes, alterations, modifications, renovations or additions to the lobby of the Building or the Project and provided that Landlord shall provide reasonably commensurate temporary signage and restore Tenant’s Lobby Sign to its original location as soon as reasonably practicable.

23.5.4 Termination of Right to Tenant’s Lobby Sign. The rights contained in this Section 23.5 shall remain in full force and effect (a) during such time as Tenant and/or its Permitted Transferee leases and is in Occupancy of at least 155,300 of the rentable square feet of the Premises leased by Tenant under this Lease; (b) there exists no Tenant default that Tenant does not dispute, for the longer of (i) thirty (30) days and (ii) any applicable notice and cure period; and (c) so long as Tenant installs such Tenant’s Lobby Sign prior to the twenty-fifth (25^th) full calendar month following the Phase II Premises Lease Commencement Date (collectively, “Tenant’s Lobby Sign Conditions”). In addition, Tenant’s right to maintain Tenant’s Lobby Sign in the dominant position in the Lobby Signage Area as provided above shall terminate upon written notice from Landlord (which shall include reasonably documentation of such termination of Tenant’s right) and be of no further force and effect in the event that Tenant (inclusive of any Permitted Transferees of Tenant) is no longer leasing more of the Office Space than any other tenant of the Building (taking into account the permitted transferees of any other tenants or occupants of the Project) or if at any time during the Lease Term Tenant no longer satisfies Tenant’s Lobby Sign Conditions (collectively, the “Dominant Lobby Sign Location Conditions”). In such event, Landlord shall have the right, at Landlord’s sole cost and expense, to relocate Tenant’s Lobby Sign (in which case Landlord shall also be responsible for repairing and restoring the Building to the condition existing prior to the installation of Tenant’s Lobby Sign) to a less dominant position commensurate with the number of rentable square feet leased by Tenant (inclusive of any Permitted Transferees of Tenant) as compared to other tenants in the Building. Upon the earlier to occur of (i) the expiration or earlier termination of this Lease or (ii) forty-five (45) days following the date

that Landlord notifies Tenant that Tenant’s right to Tenant’s Lobby Sign shall terminate pursuant to this Section 23.5, Tenant shall, at its sole cost and expense, cause Tenant’s Lobby Sign to be removed and shall cause the areas in which such Tenant’s Lobby Sign was located to be restored to the condition existing immediately prior to the placement of such Tenant’s Lobby Sign except for ordinary wear and tear. If Tenant fails to timely remove such Tenant’s Lobby Sign or to restore the areas in which such Tenant’s Lobby Sign was located, as provided in the immediately preceding sentence, then Landlord may perform such work, and all reasonable, actual costs incurred by Landlord in so performing (including an administrative fee equal to five percent (5%)) shall be reimbursed by Tenant to Landlord within thirty (30) days after Tenant's receipt of an invoice therefor together with reasonable supporting evidence. Landlord acknowledges and agrees that if Tenant’s right to Tenant’s Lobby Sign terminates due to Tenant’s failure to meet the Tenant’s Lobby Sign Conditions as set forth in item (a) or (c) above, Landlord shall not permit any other tenant, occupant or third party to install signage in the Tenant’s Lobby Sign location unless such other tenant, occupant or third party leases and is in occupancy of at least 155,300 rentable square feet of the Building. Further, if Tenant’s right to the dominant position in the Lobby Signage Area terminates due to Tenant’s failure to meet the Dominant Lobby Sign Location Conditions, Landlord shall not permit any other tenant, occupant or third party to install signage in such dominant position in the Lobby Signage Area unless such tenant, occupant or third party leases and is in occupancy of at least 155,300 rentable square feet of the Building and is the largest tenant of the Project. In addition, if Tenant’s right to the dominant position in the Lobby Signage Area terminates following the date that Landlord notifies Tenant that Tenant no longer satisfies the Dominant Lobby Sign Location Conditions, such right to dominant signage in the Lobby Signage Area shall be of no further force and effect from and after the date of Tenant’s receipt of such notice from Landlord, regardless of whether Tenant once again satisfies the Dominant Lobby Sign Location Conditions. The TCCs of this Section 23.5.4 shall survive the expiration or earlier termination of this Lease.

23.5.5 Cost and Maintenance. Tenant shall at all times maintain Tenant’s Lobby Sign in first-class order, condition and repair to Landlord reasonable satisfaction; provided, that, Landlord shall grant Tenant exclusive access to and use of all of Tenant’s apparatus, devices and equipment necessary to program, operate, use and maintain the Tenant’s Lobby Sign and access to the portions of the Project wherein such apparatus, devices and equipment are or may be located. The costs of the actual signs comprising Tenant’s Lobby Sign and the installation, design, construction, and any and all other costs associated with Tenant’s Lobby Sign, including, without limitation, permits and maintenance and repair costs, shall be the sole responsibility of Tenant. Tenant shall be solely responsible for the costs of providing electricity to Tenant’s Lobby Sign according to a separate submeter installed at Tenant’s Lobby Sign at Tenant’s expense. Should Tenant’s Lobby Sign require repairs and/or maintenance, as determined in Landlord's reasonable judgment, Landlord shall have the right to provide notice thereof to Tenant and Tenant shall cause such repairs and/or maintenance to commence within five (5) business days after receipt of such notice from Landlord and be completed within ten (10) business days after receipt of such notice from Landlord, at Tenant's sole cost and expense; provided, however, if such repairs and/or maintenance are reasonably expected to require longer than ten (10) business days to perform, Tenant shall commence such repairs and/or maintenance within such five (5) business day period and shall diligently prosecute such repairs and maintenance to completion. Should Tenant fail to perform such repairs and/or maintenance within the periods described in the immediately preceding

CASp inspection of the subject premises for the occupancy or potential occupancy of the lessee or tenant, if requested by the lessee or tenant. The parties shall mutually agree on the arrangements for the time and manner of the CASp inspection, the payment of the fee for the CASp inspection, and the cost of making any repairs necessary to correct violations of construction-related accessibility standards within the premises." In furtherance of the foregoing, Landlord and Tenant hereby agree as follows: (a) any CASp inspection requested by Tenant shall be conducted, at Tenant's sole cost and expense, by a CASp approved in advance by Landlord, subject to Landlord’s reasonable rules and requirements; (b) Tenant, at its sole cost and expense, shall be responsible for making any improvements or repairs within the Premises to correct violations of construction-related accessibility standards; and (c) if anything done by or for Tenant in its use or occupancy of the Premises shall require any improvements or repairs to the Building or Project (outside the Premises) to correct violations of construction-related accessibility standards, then Tenant shall reimburse Landlord within thirty (30) days after Tenant's receipt of an invoice therefor together with reasonable supporting evidence, as Additional Rent, for the cost to Landlord of performing such improvements or repairs. The foregoing verification is included in this Lease solely for the purpose of complying with California Civil Code Section 1938 and the terms of this Section 24.1 regarding the parties’ liability for construction related accessibility requirements shall apply only in the event Tenant exercises a right to conduct a CASp inspection and shall not in any manner otherwise affect Landlord's and Tenant's respective responsibilities for compliance with construction-related accessibility standards as are expressly set forth in the Lease.

24.2 Compliance. Tenant shall not do anything or suffer anything to be done in or about the Premises or the Project which will in any way conflict with any Law now in force or which may hereafter be enacted or promulgated. Subject to the terms and conditions of the Work Letter, at its sole cost and expense, Tenant shall promptly comply with all such applicable Laws (including the making of any alterations to the Premises required by applicable Laws) which relate to (i) Tenant's use of the Premises, (ii) the Alterations or the Improvements in the Premises, including, without limitation, for any Ancillary Uses, or (iii) the Base Building, but, as to the Base Building, only to the extent such obligations are triggered by Tenant's Alterations, the Improvements, or use of the Premises for the Ancillary Uses and for non-general office use, including, without limitation, for any Ancillary Uses. Should any standard or regulation now or hereafter be imposed on Landlord or Tenant by a state, federal or local governmental body charged with the establishment, regulation and enforcement of occupational, health or safety standards for employers, employees, landlords or tenants, then Tenant shall, at its sole cost and expense, comply promptly with such standards or regulations as it relates to the Premises or Tenant’s use of the Premises. The judgment of any court of competent jurisdiction or the admission of Tenant in any judicial action, regardless of whether Landlord is a party thereto, that Tenant has violated any of said governmental measures, shall be conclusive of that fact as between Landlord and Tenant. Except as provided in Section 24.1, Tenant shall not be required to comply with applicable Laws which require structural alterations, capital improvements or the installation of new or additional mechanical, electrical, plumbing or fire/life safety systems on a Project-wide basis without reference to Tenant’s specific use of the Premises (other than Building standard office use) or any Alterations performed by or on behalf of Tenant. To Landlord’s actual knowledge, except for any violations cured or remedied on or before the date of this Lease, if any, Landlord has not received any written notice from any governmental authority of any violation of any applicable Laws with respect to the Premises.

If any installment of Rent or any other sum due from Tenant shall not be received by Landlord or Landlord's designee when due, then Tenant shall pay to Landlord a late charge equal to three percent (3%) of the overdue amount; provided, however, with regard to the first such failure in any twelve (12) month period, Landlord will waive such late charge to the extent Tenant cures such failure within five (5) business days following Tenant's receipt of written notice from Landlord that the same was not received when due. The late charge shall be deemed Additional Rent and the right to require it shall be in addition to all of Landlord's other rights and remedies hereunder or at law and shall not be construed as liquidated damages or as limiting Landlord's remedies in any manner. In addition to the late charge described above, any Rent or other amounts owing hereunder which are not paid within ten (10) business days after the date they are due shall bear interest from the date when due until paid at the "Interest Rate." For purposes of this Lease, the "Interest Rate" shall be an annual rate equal to the lesser of (i) the annual "Bank Prime Loan" rate cited in the Federal Reserve Statistical Release Publication H.15(519), published weekly (or such other comparable index as Landlord and Tenant shall reasonably agree upon if such rate ceases to be published), plus three (3) percentage points, and (ii) the highest rate permitted by applicable Law.

Landlord reserves the right at all reasonable times (during Building Hours with respect to items (i) and (ii) below) and upon at least one (1) business day prior notice to Tenant (except in the case of an emergency) to enter the Premises to (i) inspect them; (ii) show the Premises to prospective purchasers, or to current or prospective mortgagees, ground or underlying lessors or insurers or during the last fifteen (15) months of the Lease Term, to prospective tenants; (iii) post notices of nonresponsibility; or (iv) alter, improve or repair the Premises or the Building, or for structural alterations, repairs or improvements to the Building or the Building's systems and equipment, to the extent permitted under this Lease. Landlord shall use commercially reasonable efforts to minimize interference with the operation of Tenant’s business at the Premises during any entry by Landlord unto the Premises. Notwithstanding anything to the contrary contained in this Article 27, Landlord may enter the Premises at any time to (A) perform services required of Landlord, including janitorial service to the extent Tenant has not elected to perform such janitorial service pursuant to Section 6.1.5; (B) take possession due to any breach of this Lease in the manner provided herein; and (C) perform any covenants of Tenant which Tenant fails to perform. Landlord may make any such entries without the abatement of Rent, except as otherwise provided in this Lease, and may take such reasonable steps as required to accomplish the stated purposes. For each of the above purposes, Landlord shall at all times have a key with which to unlock all the doors in the Premises, excluding Tenant's vaults, safes and special security areas designated in advance by Tenant. In an emergency, Landlord shall have the right to use any means that Landlord may deem proper to open the doors in and to the Premises. Any entry into the Premises by Landlord in the manner hereinbefore described shall not be deemed to be a forcible or unlawful entry into, or a detainer of, the Premises, or an actual or constructive eviction of Tenant from any portion of the Premises. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decorations other than those repairs, alterations or decorations that Landlord has expressly agreed to perform under this Lease. Tenant may reasonably restrict access by any visitor whom Landlord intends to bring onto the Premises who is, or may reasonably be suspected by Tenant to be, a competitor of Tenant. Tenant shall at all times, except in the case of emergencies, have the right to escort Landlord or any Landlord Parties while the same are in the Premises. Notwithstanding anything to the contrary set forth in this Article 27, Tenant may reasonably designate in writing certain reasonable areas of the Premises as "Secured Areas" should Tenant require such areas for the purpose of securing certain valuable property or confidential information. In connection with the foregoing, Landlord shall not enter such Secured Areas except in the event of an emergency. Landlord need not clean any area designated by Tenant as a Secured Area and shall only maintain or repair such secured areas to the extent (1) such repair or maintenance is required in order to maintain and repair the Base Building; (2) as required by applicable Law, or (3) in response to specific requests by Tenant and in accordance with a schedule reasonably designated by Tenant, subject to Landlord's reasonable approval. Access to the Premises by Landlord shall be in accordance with the reasonable security, safety and confidentiality requirements that Tenant may reasonably adopt from time to time,

28.1 Tenant Parking. Tenant may elect to rent from Landlord, on a monthly basis, during the period commencing on the Phase I Premises Lease Commencement Date and continuing through the Parking Election Deadline (as defined below), the amount of valet parking passes set forth in Section 9 of the Summary (“Tenant’s Initial Parking Allocation”), which parking passes shall pertain to the Parking Garage. Within thirty (30) days after the Phase II Premises Lease Commencement Date (such date is hereinafter referred to as the “Parking Election Deadline”), Tenant shall deliver written notice to Landlord (a “Parking Election Notice”) specifying how many of the parking passes in Tenant’s Initial Parking Allocation Tenant has elected to rent for the remainder of the Lease Term. If Tenant fails to deliver the Parking Election Notice by the Parking Election Deadline, Tenant shall be deemed to have elected to rent all of Tenant’s Initial Parking Allocation. If Tenant delivers a Parking Election Notice on or before the Parking Election Deadline (or is deemed to have elected to rent all of Tenant’s Initial Parking Allocation as set forth above), Tenant shall lease the number of spaces indicated in the Parking Election Notice from Landlord (or all of Tenant’s Initial Parking Allocation, as the case may be); provided, that on or before thirty (30) days prior to each annual anniversary of the Phase II Premises Lease Commencement Date, Tenant may provide Landlord with notice (a “Parking Reduction Notice”) that Tenant elects to reduce the spaces leased from Landlord (which reduction shall in no event be greater than the number of parking spaces equal to ten percent (10%) of the total parking spaces rented hereunder for the immediately previous period) effective on such annual anniversary of the Phase II Premises Lease Commencement Date. If Tenant indicates in Tenant’s Parking Election Notice or in any Parking Reduction Notice that it desires to rent less than Tenant’s Initial Parking Allocation (subject to the limit on any reduction as set forth above), then Tenant shall have no further right to rent or use any such relinquished parking passes. Notwithstanding Tenant’s relinquishment of any such parking passes, in the event that Tenant desires to rent additional parking spaces after the Parking Election Deadline or after the delivery of any Parking Reduction Notice, as applicable, then Tenant may request additional parking passes to be rented on the terms hereof by delivering written notice to Landlord (a “Parking Request Notice”) no later than thirty (30) days prior to the date Tenant desires to rent such parking passes. Such Parking Request Notice shall specify the number of additional parking passes requested. Tenant shall only be entitled to rent any such additional parking passes subject to availability of such passes at the time Tenant desires such passes pursuant to the express terms and conditions hereof (i.e., on a first come, first served basis and as available as determined by Landlord provided that the monthly parking charges for any such passes shall be at the prevailing rate). In the event that, due to unavailability of spaces, Landlord is unable to provide Tenant with additional parking passes (whether or not previously relinquished by Tenant) pursuant to this Article 28, such inability shall not subject Landlord to any liability for any loss or damage resulting therefrom or entitle Tenant to any credit, abatement or adjustment of Rent or other sums payable under this Lease. Tenant shall pay to Landlord (or its designee) for all parking

passes leased by Tenant hereunder (whether as part of Tenant’s Initial Parking Allocation or pursuant to a subsequent Parking Request Notice) on a monthly basis at the prevailing rate charged from time to time at the location of such parking passes. Except to the extent included as Operating Expenses pursuant to Section 4.2.4, Tenant shall not be responsible for the payment of any taxes imposed by any governmental authority in connection with the renting of such parking passes by Tenant or the use of the Parking Garage by Tenant. Tenant’s continued right to use the parking passes is conditioned upon Tenant abiding by all reasonable rules and regulations which are prescribed from time to time for the orderly operation and use of the Parking Garage, including any valet service (it being understood that the parking within the Parking Garage is not intended to be self-parking) and any sticker or other identification system established by Landlord, Tenant's cooperation in seeing that Tenant's employees and visitors also comply with such reasonable rules and regulations. Landlord specifically reserves the right to change the size, configuration, design, layout and all other aspects of the Parking Garage at any time (without any reduction to the number of parking passes then leased by Tenant, except to the extent required by applicable Law) and Tenant acknowledges and agrees that Landlord may, without incurring any liability to Tenant and without any abatement of Rent under this Lease, from time to time, temporarily close-off or restrict access to the Parking Garage for purposes of permitting or facilitating any such construction, alteration or improvements; provided that (i) Landlord shall use commercially reasonable efforts (without any obligation to engage overtime labor or commence any litigation) to minimize the extent and duration of any resulting interference with Tenant’s parking rights and (ii) Landlord shall provide, at Tenant’s sole cost and expense (up to the amount Tenant would have paid under this Lease for parking then-leased by Tenant that becomes unavailable due to such closure), reasonable alternative parking for Tenant during the continuation of any work which causes the Parking Garage to close for more than thirty (30) days. Landlord may delegate its responsibilities hereunder to a parking operator in which case such parking operator shall have all the rights of control attributed hereby to Landlord. Landlord may, at any time, institute valet assisted parking, tandem parking stalls, "stack" parking, or other parking program within the Parking Garage, the cost of which shall be included in Operating Expenses. Landlord may delegate its responsibilities hereunder to a parking operator in which case such parking operator shall have all the rights of control attributed hereby to Landlord. The parking passes rented by Tenant pursuant to this Article 28 are provided to Tenant solely for use by Tenant's own personnel and visitors and such passes may not be transferred, assigned, subleased or otherwise alienated by Tenant without Landlord's prior approval, except to an Permitted Transferee or another assignee or subtenant consented to by Landlord in accordance with Article 14 above. Tenant may validate visitor parking by such method or methods as Landlord may establish, at the validation rate from time to time generally applicable to visitor parking.

regulations (including rules regarding hours of use) established from time to time by Landlord, in its reasonable discretion, and/or by the operator of the Parking Garage, and shall be further subject to compliance with the Building’s standard security procedures. Landlord may refuse to permit any person who violates such rules and regulations to use the Bicycle Storage Area, and any violation of the rules and regulations shall subject the bicycle to removal from the Bicycle Storage Area. Landlord shall have the right to relocate, from time to time, the location of the Bicycle Storage Area provided that the overall bicycle parking capacity is not reduced below the amount available as of the Effective Date. Tenant acknowledges that the Bicycle Storage Area may be closed entirely or in part in order to make repairs or perform maintenance services, or to alter, modify or renovate the Building or the Bicycle Storage Area, if required by casualty, strike, condemnation, act of God, governmental law or requirement or other reason beyond Landlord’s reasonable control or for any other reason whatsoever. No expansion, contraction, elimination, unavailability or modification of the Bicycle Storage Area, and no termination of or interference with Tenant’s rights to the Bicycle Storage Area, shall entitle Tenant to an abatement or reduction in Rent or constitute a constructive eviction or an event of default by Landlord under this Lease; provided, however, that if the Bicycle Storage Area is temporarily (i.e., for more than three (3) business days) or permanently reduced or eliminated, Landlord shall provide to Tenant, at no additional cost, a storage area in the Project for Tenant’s storage of bicycles at least equal to the size of the Bicycle Storage Area so reduced or eliminated. Landlord and Tenant acknowledge that the use of the Bicycle Storage Area shall be at the sole risk of Tenant and any Tenant Parties and neither Landlord nor any Landlord Parties shall have any liability for any personal injury or damage to or theft of any bicycles or other property occurring in, on or about the Bicycle Storage Area or otherwise in connection with any use of the Bicycle Storage Area by Tenant or any Tenant Parties (collectively, “Bike Storage Area Claims”) except to the extent such Bike Storage Area Claims arise directly from or are the direct result of the gross negligence or willful misconduct of Landlord or any Landlord Party. The costs of operating, maintaining and repairing the Bicycle Storage Area shall be included as part of Operating Expenses.

29.13 Landlord Exculpation. The liability of Landlord or the Landlord Parties to Tenant for any default by Landlord under this Lease or arising in connection herewith or with Landlord's operation, management, leasing, repair, renovation, alteration or any other matter relating to the Project or the Premises shall be limited solely and exclusively to the interest of Landlord in the Project, including any sales, insurance, condemnation or rental proceeds received by Landlord or the Landlord Parties in connection with the Project, Building or Premises. Neither Landlord, nor any of the Landlord Parties shall have any personal liability therefor, and Tenant hereby expressly waives and releases such personal liability on behalf of itself and all persons claiming by, through or under Tenant. The limitations of liability contained in this Section 29.13 shall inure to the benefit of Landlord's and the Landlord Parties' present and future partners, beneficiaries, officers, directors, trustees, shareholders, agents and employees, and their respective partners, heirs, successors and assigns. Under no circumstances shall any present or future partner of Landlord (if Landlord is a partnership), or trustee or beneficiary (if Landlord or any partner of Landlord is a trust), have any liability for the performance of Landlord's obligations under this Lease. Notwithstanding any contrary provision herein, neither Landlord nor the Landlord Parties shall be liable under any circumstances for injury or damage to, or interference with, Tenant's business, including but not limited to, loss of profits, loss of rents or other revenues, loss of business opportunity, loss of goodwill or loss of use, in each case, however occurring.

29.18 Notices. All notices, demands, statements, designations, approvals or other communications (collectively, "Notices") given or required to be given by either party to the other hereunder shall be in writing, shall be (A) delivered by a nationally recognized overnight courier, or (B) delivered personally. Any such Notice shall be delivered (i) to Tenant at the appropriate address set forth in Section 10 of the Summary, or to such other place as Tenant may from time to time designate in a Notice to Landlord; or (ii) to Landlord at the addresses set forth in Section 11 of the Summary, or to such other firm or to such other place as Landlord may from time to time designate in a Notice to Tenant. Any Notice will be deemed given on the date of receipted delivery, of refusal to accept delivery, or when delivery is first attempted but cannot be made due to a change of address for which no Notice was given. Notwithstanding anything to the contrary contained herein, if any breach of security in the Building or the Premises shall occur, then Landlord shall as immediately as practical provide notice to Tenant via e-mail to workplace@okta.com or such other email address(es) as Tenant shall from time to time notify Landlord in writing. If Tenant is notified of the identity and address of Landlord's mortgagee or ground or underlying lessor, Tenant shall give to such mortgagee or ground or underlying lessor written notice of any default by Landlord under the terms of this Lease by registered or certified mail. The party delivering Notice shall use commercially reasonable efforts to provide a courtesy copy of each such Notice to the receiving party via electronic mail.

29.30 Building Renovations. It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter. However, Tenant hereby acknowledges that Landlord may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Common Areas. In connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, temporarily limit or eliminate access to portions of the Common Areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall use commercially reasonable efforts to minimize interference with Tenant’s use of the Premises in making any Renovations.

29.32.1 Tenant may install, maintain, replace, remove or use any communications or computer wires, cables and related devices (collectively, the "Lines") at the Project in or serving the Premises, provided that (i) Tenant shall obtain Landlord's prior written consent, not to be unreasonably withheld, conditioned or delayed, and use an experienced and qualified contractor reasonably approved in writing by Landlord, and comply with all of the other provisions of Articles 7 and 8 of this Lease, (ii) the Lines therefor (including riser cables) shall be (x) appropriately insulated to prevent excessive electromagnetic fields or radiation, (y) surrounded by a protective conduit reasonably acceptable to Landlord, and (z) identified in accordance with the "Identification Requirements," as that term is set forth herein below, (iii) any Lines servicing the Premises shall comply with all applicable Laws, and (iv) Tenant shall pay all costs in connection therewith. All Lines shall be clearly marked with adhesive plastic labels (or plastic tags attached to such Lines with wire) to show Tenant's name, suite number, telephone number and the name of the person to contact in the case of an emergency (A) every four feet (4') outside the Premises (specifically including, but not limited to, the electrical room risers and other Common Areas), and (B) at the Lines' termination point(s) (collectively, the "Identification Requirements"). Upon the expiration of the Lease Term, or immediately following any earlier termination of this Lease, Tenant shall, at Tenant's sole cost and expense, remove all Lines installed by Tenant, and repair any damage caused by such removal. In the event that Tenant fails to complete such removal and/or fails to repair any damage caused by the removal of any Lines, Landlord may do so and may charge the actual, out-of-pocket cost thereof to Tenant within thirty (30) days after receipt of invoice together with reasonable supporting evidence. Landlord reserves the right to require that Tenant remove any Lines located in or serving the Premises which are installed in violation of these provisions, or which at any time represent a dangerous or potentially dangerous condition.

29.33.1 Definitions. For purposes of this Lease, the following definitions shall apply: "Hazardous Material(s)" shall mean any solid, liquid or gaseous substance or material that is described or characterized as a toxic or hazardous substance, waste, material, pollutant, contaminant or infectious waste, or any matter that in certain specified quantities would be injurious to the public health or welfare, or words of similar import, in any of the "Environmental Laws," as that term is defined below, or any other words which are intended to define, list or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity or reproductive toxicity and includes, without limitation, asbestos, petroleum (including crude oil or any fraction thereof, natural gas, natural gas liquids, liquefied natural gas, or synthetic gas usable for fuel, or any mixture thereof), petroleum products, polychlorinated biphenyls, urea formaldehyde, radon gas, nuclear or radioactive matter, medical waste, soot, vapors, fumes, acids, alkalis, chemicals, microbial matters (such as molds, fungi or other bacterial matters), biological agents and chemicals which may cause adverse health effects, including but not limited to, cancers

29.33.3 Tenant Hazardous Materials. Tenant will (i) obtain and maintain in full force and effect all Environmental Permits (as defined below) that may be required from time to time under any Environmental Laws applicable to Tenant or the Premises, and (ii) be and remain in compliance with all terms and conditions of all such Environmental Permits and with all other Environmental Laws. "Environmental Permits" means, collectively, any and all permits, consents, licenses, approvals and registrations of any nature at any time required pursuant to, or in order to comply with any Environmental Law. Within thirty (30) days following Tenant's receipt of a reasonable request from Landlord, Tenant agrees to deliver to Landlord a list of all Hazardous Materials anticipated to be used by Tenant in the Premises other than reasonable quantities of janitorial and general office use supplies and the quantities thereof but not more often than once in any given twelve (12) calendar month period. Upon the expiration or earlier termination of this Lease, Tenant agrees to promptly remove from the Premises, the Building and the Project, at its sole cost and expense, any and all Hazardous Materials, including any equipment or systems containing Hazardous Materials, which are installed, brought upon, stored, used, generated or released upon, in, under or about the Premises, the Building, and/or the Project or any portion thereof by Tenant and/or any Tenant Parties (such obligation to survive the expiration or sooner termination of this Lease). Nothing in this Lease shall impose any liability on Tenant for any Hazardous Materials in existence on the Premises, Building or Project prior to the Lease Commencement Date or brought onto the Premises, Building or Project after the Lease Commencement Date by any third parties not under Tenant's control.

environmental inspector or auditor may be chosen by Landlord, in its sole discretion, and be performed at Landlord's sole expense and not as an Operating Expense. Such auditor shall use commercially reasonable efforts to minimize interference with the operation of Tenant’s business at the Premises during any entry by Landlord unto the Premises. To the extent that the report prepared upon such inspection, assessment or audit, indicates the presence of Hazardous Materials in violation of Environmental Laws, or provides recommendations or suggestions to prohibit the release, discharge, escape or emission of any Hazardous Materials at, upon, under or within the Premises, or to comply with any Environmental Laws, Tenant shall promptly, at Tenant's sole expense, comply with such recommendations or suggestions, including, but not limited to performing such additional investigative or subsurface investigations or remediation(s) as recommended by such inspector or auditor. Notwithstanding the above, if at any time, Landlord has actual notice or reasonable cause to believe that Tenant has violated, or permitted any violations of any Environmental Law, then Landlord will be entitled to perform its environmental inspection, assessment or audit at any time, notwithstanding the above mentioned annual limitation, and if such inspection, assessment or audit reveals that Tenant has violated the terms of this Lease, then Tenant must reimburse Landlord for the reasonable cost or fees incurred for such as Additional Rent within thirty (30) days after receipt of invoice together with reasonable supporting evidence.

29.35 Water Sensors. Tenant shall, at Tenant's sole cost and expense, be responsible for promptly installing web-enabled wireless water leak sensor devices designed to alert the Tenant on a twenty-four (24) hour seven (7) day per week basis if a water leak is occurring in the Premises (which water sensor device(s) located in the Premises shall be referred to herein as "Water Sensors"). The Water Sensors shall be installed at any waterlines connected to equipment such as refrigerators and coffee machines, and at toilets, sinks, showers, water dispensers (but in any event excluding any core Building restrooms) (the "Sensor Areas"). In connection with any Alterations affecting or relating to any Sensor Areas, Landlord may require Water Sensors to be installed or updated in Landlord's reasonable discretion, provided, however, that Landlord shall not require Tenant to install Water Sensors at any currently existing improvements in the Premises unless any alterations, additions and or modifications are made thereto. With respect to the installation of any such Water Sensors, Tenant shall obtain Landlord's prior written consent, use an experienced and qualified contractor reasonably approved by Landlord, and comply with all of the other provisions of Article 8 of this Lease. Tenant shall, at Tenant's sole cost and expense, pursuant to Article 7 of this Lease keep any Water Sensors located in the Premises (whether installed by Tenant or someone else) in good working order, repair and condition at all times during the Lease Term and comply with all of the other provisions of Article 7 of this Lease. Notwithstanding any provision to the contrary contained herein, Landlord has neither an obligation to monitor, repair or otherwise maintain the Water Sensors, nor an obligation to respond to any alerts it may receive from the Water Sensors or which may be generated from the Water Sensors. Tenant shall have no obligation to remove or restore any Water Sensor (whether existing in the Premises as of the Effective Date or subsequently installed by Tenant during the Lease Term) upon the expiration of the Lease Term or any earlier termination of this Lease. Tenant shall leave the Water Sensors in place together with all necessary user information such that the same may be used by a future occupant of the Premises (e.g., the Water Sensors shall be unblocked and ready for use by a third-party).

29.37 LEED Certification. Landlord may, in Landlord's sole and absolute discretion, elect to apply to obtain or maintain a LEED certification for the Project (or portion thereof), or other applicable certification in connection with Landlord’s sustainability practices for the Project (as such sustainability practices are to be determined by Landlord, in its sole discretion, from time to time); provided, however, that Landlord agrees to use commercially reasonable efforts to maintain LEED Gold certification for the Building. Tenant shall, at Tenant's sole cost and expense, cooperate with the Landlord's efforts in connection with Landlord’s maintenance of LEED Gold certification for the Building and provide Landlord with any reasonable documentation it may need in order to maintain the aforementioned certification (which cooperation may include the sharing of documentation pertaining to any Alterations or improvements undertaken by Tenant in the Project with Landlord, and the sharing of Tenant's billing information pertaining to trash removal and recycling related to Tenant's operations in the Project); provided, however, that except as required by applicable Laws, Tenant shall not be required to incur costs or expenses related to Landlord’s obtaining any LEED certification.

29.38 Tenant Competitors. Provided that this Lease is then in full force and effect, Tenant is not in default of this Lease beyond applicable notice and cure periods, and Occupies no less than 155,300 rentable square feet (collectively, the “Exclusivity Conditions”), Landlord agrees that Landlord shall not, without the prior written consent of Tenant, in Tenant’s sole discretion, enter into any lease, license or other similar use agreement relating to leasing space in the Building for a term scheduled to commence during the Term of this Lease (each, an “Occupancy Agreement”) with any Tenant Competitor (hereinafter defined) or, consent to any tenant, subtenant, licensee or other occupant of the Building under an Occupancy Agreement to assign its lease, license or other such agreement for space in the Building or sublet any portion of its premises to a Tenant Competitor where Landlord’s consent would be required for such assignment or subleasing. For purposes hereof, the term “Tenant Competitor” shall mean the list of no more than five (5) persons and entities identified by Tenant from time to time by written notice to Landlord. Notwithstanding the foregoing, Tenant Competitors shall also include any person, corporation, limited liability company, association, trust or partnership which (i) controls, is controlled by or is under common control with such entity or (ii) which results from a merger or consolidation with such entity or (iii) which succeeds to the business and assets of such entity (each, a “Competitor Affiliate”); provided that Tenant Competitors shall only include Competitor Affiliates pursuant to items (i), (ii) and (iii) solely to the extent such Competitor Affiliate is the tenant under the Occupancy Agreement as a subterfuge by Landlord or any Tenant Competitor to avoid or circumvent the restrictions of this Section 29.38. Notwithstanding anything to the contrary set forth herein, the term (a) “Occupancy Agreement” specifically excludes any lease, license or other similar use agreement relating to leasing space in the Building dated prior to the Effective Date; and (b) “Tenant Competitor” specifically excludes any assignee, subtenant, licensee, or other occupant or transferee of or from the tenant or a subtenant under an existing Occupancy Agreement if Landlord did not have the right, in its reasonable discretion, to withhold consent to the applicable assignment, sublease, license, occupancy or transfer under the terms of such existing Occupancy Agreement; provided, however, that Landlord shall not enter into any Occupancy Agreement from and after the Effective Date and continuing throughout the Lease Term which would prevent Landlord from withholding consent to any Tenant Competitor. No more than once during each twelve (12) month period during the Lease Term within thirty (30) days of the annual anniversary of the Phase II Premises Lease Commencement Date, Tenant shall be entitled to replace up to five (5) of the Tenant Competitors previously provided to Landlord upon thirty (30) days’ prior written notice to Landlord. Any change in the list of Tenant Competitors shall be effective only on a prospective basis and shall not apply if any such entity is currently in active negotiations with Landlord to lease or license space in the Building, and Landlord shall not be liable to Tenant for any Occupancy Agreement entered into by Landlord with respect to such new entity prior to receipt of Tenant’s notice adding such entity to the list of Tenant Competitors. Notwithstanding anything herein to the contrary, Landlord shall not be deemed to have violated the terms of this Section if any tenant or occupant of the Building, whether existing as of the Effective Date or any future tenant or occupant, merges or consolidates with or into, or acquires or is acquired by, any of the afore described Tenant Competitors, provided, that such transaction was not consummated for the purpose of circumventing this Section. If at any time Tenant fails to satisfy any of the Exclusivity Conditions, then, effective as of the date on which such failure first occurs, the terms of this Section 29.38 shall be null and void and of no further force or effect. The provisions of this Section 29.38 are personal to the originally named Tenant under this Lease and are not transferable.

29.41 Shuttle Service. Subject to the provisions of this Section 29.40, so long as this Lease remains in effect, and so long as Landlord, in Landlord's sole and absolute discretion, permits a shuttle service (the "Shuttle Service") to operate at the Project, Tenant's employees ("Shuttle Service Riders") shall be entitled to use the Shuttle Service operated at the Project. The use of the Shuttle Service shall be subject to the reasonable rules and regulations (including rules regarding hours of use) established from time to time by Landlord, in its sole and absolute discretion, and/or the operator of the Shuttle Service. Landlord and Tenant acknowledge that the use of the Shuttle Service by the Shuttle Service Riders shall be at their own risk and that the terms and provisions of Section 10.1 of this Lease shall apply to Tenant and the Shuttle Service Rider's use of the Shuttle Service. The costs of operating, maintaining and repairing the Shuttle Service shall be included as part of Operating Expenses, subject to the terms of Section 4.2.4 above. Tenant acknowledges that the provisions of this Section 29.40 shall not be deemed to be a representation by Landlord that Landlord shall continuously maintain the Shuttle Service (or any other shuttle service) throughout the Lease Term, and Landlord shall have the right, at Landlord's sole discretion, to expand, contract, eliminate or otherwise modify all Shuttle Services provided by it. Landlord or the operator of the Shuttle Service shall have a right to charge a reasonable fee to the users of the Shuttle Service, which fee shall be commensurate with the fees charged by landlords of Comparable Buildings. No expansion, contraction, elimination or modification of any or all Shuttle Services, and no termination of Tenant's or the Shuttle Service Rider's rights to the Shuttle Service shall entitle Tenant to an abatement or reduction in Rent, constitute a constructive eviction, or result in an event of default by Landlord under this Lease.

through the floor above the Premises (which may penetrate through the ceiling of the Premises and be visible within the Premises during the course of construction and upon completion thereof) (as applicable, the "Penetrating Work"), as Landlord may determine in its reasonable discretion and with no approval rights being afforded to Tenant with respect thereto; provided, however, that Tenant shall have approval rights as to the manner of such Penetrating Work and Tenant’s privacy and security concerns, only with respect to Penetrating Work on floors contiguous to the Premises. Moreover, there shall be no obligation by Landlord or any such third party to enclose or otherwise screen any of such Penetrating Work from view within the Premises, whether during the course of construction or upon completion thereof, except to the extent necessary to protect Tenant and Tenant Parties and their respective personal property from injury or damage or as otherwise reasonably requested by Tenant. Since Tenant is anticipated to be occupying the Premises at the time the Penetrating Work is being performed, Landlord agrees that it shall (and shall cause third parties to) use commercially reasonable efforts to perform the Penetrating Work in a manner so as to attempt to minimize interference with Tenant's use of the Premises; provided, however, such Penetrating Work may be performed during normal business hours, without any obligation to pay overtime or other premiums. Tenant hereby acknowledges that, notwithstanding Tenant’s occupancy of the Premises during the performance of any such Penetrating Work, Tenant hereby agrees that the performance of such Penetrating Work shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of rent. Neither Landlord nor any of the Landlord Parties or any third parties performing the Penetrating Work shall be responsible for any direct or indirect injury to or interference with Tenant’s business arising from the performance of such Penetrating Work, nor shall Tenant be entitled to any compensation or damages from Landlord or any of the Landlord Parties or any third parties performing the Penetrating Work for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the performance of the Penetrating Work, or for any inconvenience or annoyance occasioned by the Penetrating Work. In addition, Tenant hereby agrees to promptly and diligently cooperate with Landlord and any of the third parties performing the Penetrating Work to the extent reasonably necessary in order to facilitate the applicable party's performance of the particular Penetrating Work.

29.44 Foreign Corrupt Practices Act and Anti-Money Laundering. It is the intent of the parties that no payments or transfers of anything of value shall be made which have the purpose or effect of public or commercial bribery, acceptance of or acquiescence in extortion, kickbacks, or other unlawful or improper means of obtaining business or any improper advantage. The parties shall comply with all international anti-corruption laws, such as the Foreign Corrupt Practices Act 15 U.S.C. § 78dd-1, et seq. and with respect to the parties’ obligations under this Lease, each party will not at any time, directly or indirectly, pay, offer, authorize or promise to pay, offer, or authorize the payment of, any monies or any other thing of value to: (i) any officer or employee of any government, department, agency or instrumentality thereof; (ii) any other person acting in an official capacity for or on behalf of any government, department, agency or instrumentality thereof; (iii) any political party or any official or employee thereof; (iv) any candidate for political office; (v) any other person, firm, corporation or other entity at the suggestion, request or direction of, or for the benefit of, any government officer or employee, political party or official or employee thereof, or candidate for political office; or (vi) any other person, firm, corporation or other entity with knowledge that some or all of those monies or other thing of value will be paid over to any officer or employee of any government department, agency or instrumentality, political party or officer or employee thereof, or candidate for political office.

29.46 Sun Terrace. So long as Tenant is not in default under this Lease beyond any applicable notice and cure period, then during the Lease Term and subject to availability, Tenant shall have the right, at no additional cost (except as provide herein), to hold up to twelve (12) private events per calendar year of the Lease Term at the sun terrace that is a part of the Common Area of the Building (the “Sun Terrace”), subject to the TCCs set forth herein. Tenant shall comply with the reservation system for the Sun Terrace established by Landlord from time to time with respect to the use of the Sun Terrace. Tenant shall be entitled to (i) reserve use of the Sun Terrace with at least six (6) months’ prior written notice to Landlord for up to two (2) private events during any calendar year of the Lease Term (the “Two Private Events”), and (ii) subject to availability, reserve the use of the Sun Terrace with at least ninety (90) days’ prior written notice to Landlord for the remaining ten (10) private events per calendar year of the Lease Term. In the event another party desires to reserve the Sun Terrace for a date more than six (6) months from the date of such request, Landlord shall offer Tenant the opportunity to reserve the Sun Terrace for either of the Two Private Events and Tenant may exercise its right to reserve the Sun Terrace for such date by providing written notice to Landlord no later than three (3) business days from the date Landlord tenders such opportunity to Tenant. If Tenant fails to respond to Landlord’s written notice or elects not to reserve the Sun Terrace for such date, Tenant shall be deemed to have waived its right to reserve the Sun Terrace for such date. Tenant’s use of the Sun Terrace shall be further subject to the reasonable rules and regulations (including rules regarding hours of use and priorities for the tenants, set up and clean up charges, etc.) established from time to time by Landlord for the Sun Terrace. Tenant acknowledges that Landlord may from time to time establish a standard, commercially reasonable license agreement (the "License Agreement") with respect to the use of Sun Terrace by tenants of the Building. Tenant, upon request of Landlord and as a condition to Tenant’s right to use the Sun Terrace pursuant to this Section 29.45, shall enter into such commercially reasonable License Agreement and fully comply with the terms and conditions set forth in the License Agreement; provided, however, that Landlord and Tenant shall agree upon the form of License Agreement the first time Landlord requires such License Agreement and for the remainder of the Lease Term, if Landlord requires Tenant to execute a license for use of the Sun Terrace, Landlord and Tenant shall use the same mutually agreed upon form of License Agreement. Tenant’s waiver and indemnity obligations pursuant to Section 10.1 of this Lease shall apply to Tenant’s use of the Sun Terrace. Tenant’s insurance required pursuant to Section 10.3 above shall apply to the use of the Sun Terrace by Tenant and any Tenant Parties. In the event that alcohol is served or utilized at the Sun Terrace, subject to applicable Laws, Tenant shall provide Landlord with written notice thereof and obtain and maintain at its expense, host liquor liability insurance or dram shop liability insurance (as applicable) with combined single limits of not less than $5,000,000 per occurrence and such additional or higher commercially reasonable insurance coverage as may be reasonably required pursuant to the License Agreement, covering any claims relating to the manufacture, storage, sale, use or giving away of any alcoholic or other intoxicating liquor or beverage, which claims could be asserted against Landlord, any Landlord Parties, Tenant or the Project. In addition, as a condition to Tenant’s use of Sun Terrace, Tenant shall provide

Landlord with insurance certificates acceptable to Landlord, evidencing that Tenant’s insurance required under this Lease and pursuant to the License Agreement covers Tenant’s use of the Sun Terrace. Prior to any use of the Sun Terrace, Tenant shall secure all security, janitorial services and other related services with respect to Tenant’s use of the Sun Terrace. Except to the extent expressly set forth in this Section 29.46, neither Landlord nor any Landlord Parties shall have any liability whatsoever with respect to the existence, condition or availability of the Sun Terrace for Tenant’s use nor shall Landlord nor any Landlord Parties have any obligation whatsoever to ensure the availability or suitability of the Sun Terrace for Tenant’s use. Tenant shall reimburse Landlord for all reasonable out-of-pocket costs incurred by Landlord in connection with Tenant’s use of the Sun Terrace pursuant to this Section 29.45, which costs shall be paid to Landlord as Additional Rent under this Lease within thirty (30) days following Landlord’s demand therefor. Tenant acknowledges that the provisions of this Section 29.45 shall not be deemed a guaranty by Landlord that Landlord will not contract, eliminate or otherwise modify the Sun Terrace. No expansion, contraction, elimination or modification of the Sun Terrace shall modify Tenant’s obligations under this Lease or entitle Tenant to an abatement or reduction in Rent or constitute a default by Landlord under this Lease. Tenant may transfer Tenant’s rights to the Sun Terrace to any Transferee not requiring Landlord approval pursuant to Section 14.8 or any Transferee approved by Landlord to the extent Landlord’s approval is required pursuant to Section 14.2; provided, that Tenant or any Transferee leases 155,300 rentable square feet in the Building and such Transferee Occupies 155,300 rentable square feet of the Building.

29.48 Storage Space. Upon no less than thirty (30) days prior written request by Tenant (the “Storage Space Request”), and subject to availability on a first come, first-served basis, except to the extent expressly set forth herein, Tenant shall have an option to lease storage space in Project (each, a “Potential Storage Space”) during the Lease Term. Following Landlord’s receipt of Tenant’s Storage Space Request, Landlord shall notify Tenant in writing (“Landlord’s Storage Notice”) as to what Potential Storage Space(s), if any, is available for Lease, and the size and then-current Building standard rental rate applicable for such Potential Storage Space (the “Storage Space Rent”), which Storage Space Rent shall be subject to escalation of three percent (3%) per annum during the remainder of the then current Lease Term. Tenant may lease any Potential Storage Space described in Landlord’s Storage Notice by delivering written notice to Landlord of Tenant’s election to lease such Potential Storage Space (“Tenant’s Storage Acceptance Notice”) delivered to Landlord within ten (10) business days following Landlord’s delivery of Landlord’s Storage Notice to Tenant. In the event that Landlord’s Storage Notice provided that more than one Potential Storage Space was available for lease by Tenant, then Tenant’s Storage Acceptance Notice shall identify which Potential Storage Space(s) Tenant has elected to lease. In the event that Tenant delivers a Tenant’s Storage Acceptance Notice to Landlord, the term for the applicable Potential Storage Space shall be co-terminus with the then-current Lease Term of this Lease. Landlord and Tenant shall enter into Landlord’s standard commercially reasonable storage space lease agreement (the “Storage Agreement”) with respect to Tenant’s lease of any Potential Storage Space, or, in the event that Tenant and Landlord have already entered into a Storage Agreement, then the parties shall enter into an amendment thereto adding such additional Potential Storage Space to any storage space previously leased by Tenant pursuant to this Section 29.48. Tenant shall execute and return the Storage Agreement (or amendment thereto, as applicable) to Landlord within thirty (30) days after receiving it. If Tenant fails to execute and deliver the Storage Agreement within such thirty (30) day period, then Landlord may lease such Potential Storage Space to any third party. In the event that Tenant delivers a Storage Space Request but, due to unavailability of any Potential Storage Space, Landlord is unable to provide Tenant with any Potential Storage Space at such time, Landlord shall so notify Tenant. Subject to Landlord’s compliance with the TCCs of this Section 29.48, the unavailability of such Potential Storage Space for Tenant’s use shall not subject Landlord to any liability for any loss or damage resulting therefrom or entitle Tenant to any credit, abatement or adjustment of rent or other sums payable under this Lease but Tenant may once again deliver a Storage Request pursuant to the terms of this Section 29.48. Landlord hereby acknowledges that the following storage spaces are available for lease as of the Effective Date at a Storage Space Rent of Thirty and No/100 Dollars ($30.00) per square foot: Unit 00BD (245 square feet), Unit 00BF (194 square feet), Unit 00BG (196 square feet), Unit 00BI (373 square feet), Unit 00BK (166 square feet), Unit 00BX (128 square feet) and Unit STRI (133 square feet) (collectively, the “Initially Available Storage Space”). Notwithstanding anything to the contrary in the foregoing, within thirty (30) days after the Phase II Premises Lease Commencement Date (such date is hereinafter referred to as the “Initial Storage Election Deadline”), Tenant shall deliver written notice to Landlord (a “Initial Storage Election Notice”) specifying which Initially Available Storage Space Tenant has elected to rent. If Tenant fails to timely deliver an Initial Storage Election Notice, Tenant’s rights to any Potential Storage Space (including any Initially Available Storage Space) shall be as otherwise set forth in this Section 29.48. Landlord shall not lease any of the Initially Available Storage Space to any other party during the period commencing as of the Phase II Premises Lease Commencement Date

29.51 Waiver of Consequential and Special Damages. Neither party shall be liable to the other party for any special or consequential damages, loss of profits, loss of business opportunity or loss of goodwill from the failure of such party to meet its obligations under the Lease. The parties acknowledge and agree that (i) if Landlord is required to abate the rent of another tenant at the Project under the terms and conditions of such tenant’s lease, or as required by Law, as the result of any Alteration constructed by or on behalf of Tenant, or in connection with any repair or maintenance performed by or on behalf of Tenant, which interferes with such tenant’s use of its premises, then such rental abatement shall not be deemed consequential damages, loss of profits, loss of business opportunity or loss of goodwill within the limitation set forth in the preceding sentence, and (ii) any claims made by any succeeding tenant founded upon Tenant's failure to surrender all or any portion of the Premises within sixty (60) days following the applicable Lease Expiration Date of such Phase, and any lost profits to Landlord resulting therefrom, shall not be deemed consequential damages, loss of profits, loss of business opportunity or loss of goodwill within the limitation set forth in the preceding sentence. Tenant shall have the right to request that Landlord provide to Tenant a written notice setting forth Landlord’s good faith estimate of the maximum amount of consequential damages (including loss of profits, loss of business opportunity, loss of goodwill and loss of use) ("Holding Over Damages") that Landlord will incur as the result of Tenant’s failure to surrender the Premises following the expiration of this Lease. Within ten (10) business days after receipt of such request, Landlord shall provide Tenant a written notice setting forth Landlord’s good faith estimate of Holding Over Damages. Notwithstanding anything set forth in this Lease to the contrary, Landlord's good faith estimate of Holding Over Damages shall be provided to Tenant solely as an accommodation and Landlord's actual Holding Over Damages shall not be limited by such good faith estimate.

This Work Letter shall set forth the terms and conditions relating to the construction of the Phase I Premises, the Phase II Premises, the Must-Take Space and any First Offer Space, as applicable. All references in the Work Letter to (i) "Premises," "Phase," or "floor of the Premises" shall be deemed to be references to the Phase I Premises, the Phase II Premises, the Must-Take Space and any First Offer Space (except as otherwise expressly set forth in this Work Letter or in the Lease), as applicable, (ii) the "Improvements" shall be deemed to be references to the Improvements in each of the Phase I Premises, the Phase II Premises, the Must-Take Space and any First Offer Space (except as otherwise expressly set forth in this Work Letter or in the Lease), as applicable, (iii) the "Improvement Allowance" shall be deemed to be references to the Improvement Allowance for each of the Phase I Premises, the Phase II Premises, the Must-Take Space and any First Offer Space (to the extent Landlord provides an improvement allowance in connection with Tenant’s leasing of such First Offer Space), as applicable, (iv) “Delivery Date” shall be deemed to be references to the delivery of each of the Phase I Premises, the Phase II Premises, the Must-Take Space and any First Offer Space, as applicable, and (v) the "Lease Commencement Date" shall be deemed to be references to the Lease Commencement Date for each of the Phase I Premises, the Phase II Premises, the Must-Take Space (defined in the Lease as the “Must-Take Effective Date”) and any First Offer Space (defined in the Lease as the “First Offer Commencement Date”), as applicable. This Work Letter is essentially organized chronologically and addresses the issues of the construction of the Premises, in sequence, as such issues will arise during the actual construction of the Premises. All references in this Work Letter to Articles or Sections of "this Lease" shall mean the relevant portions of Articles 1 through 29 of the Office Lease to which this Work Letter is attached as Exhibit B and of which this Work Letter forms a part, and all references in this Work Letter to Sections of "this Work Letter" shall mean the relevant portion of Sections 1 through 5 of this Work Letter.

1.2.1 In connection with Tenant’s construction of the “Improvements”, as that term is defined in Section 2.1 below, Landlord shall be responsible, at Landlord’s sole cost and expense, for any work (the “Landlord Work”) required to correct any existing violations of applicable Laws (as interpreted and enforced as of the Delivery Dates of each of the applicable Premises) relating to (any such work is hereinafter referred to as “Required Compliance Corrections”): (i) the restrooms located on any full floor of the Premises (such Required Compliance Corrections located within any such restrooms are hereinafter referred to as the “Required Restroom Compliance Corrections”), (ii) the path of travel to the Premises, and (iii) the Common Areas of the Building outside of the Premises, to the extent the performance of any such work in the Common Areas of the Building (other than in (i) above) is necessary in order for Tenant to obtain (x) a building permit for the Improvements (provided that the Improvements are Typical Office Improvements, and are not Specialty Alterations or “Ancillary Use Improvements”, as that term is defined below), or (y) a certificate of occupancy or similar governmental approval necessary for Tenant to occupy the Premises for general office use; provided, however, that in no event shall the Landlord Work be deemed to include any Required Compliance Corrections to the extent the same are triggered by the specialized use of the Premises (other than for general office use) by Tenant or any Tenant Parties (including, without limitation, for the Ancillary Uses, as defined in the Lease) or any Alterations performed in the Premises by or on behalf of Tenant (other than any Typical Office Improvements). Notwithstanding the foregoing, in no event shall Tenant be obligated to perform any structural alterations, capital improvements or the installation of new or additional mechanical, electrical, plumbing or fire/life safety systems on a Building-wide basis, including to correct any violations of applicable Laws triggered by Tenant’s construction of the Improvements; provided, however, that any such structural alterations, capital improvements and/or installation of new or additional mechanical, electrical, plumbing or fire/life safety systems installed on behalf of Tenant may be included as part of Operating Expenses, subject to and in accordance with the TCCs of Section 4.2.4 of the Lease. The Landlord Work shall be completed using Building Standard (as defined below) methods, materials and finishes.

below) on or before the later of (i) the applicable Lease Commencement Date for the portion of the Premises relating to such Required Compliance Corrections; or (ii) Tenant’s Substantial Completion of the Phase II Premises Improvements in any portion of the Phase II Premises. The Required Compliance Corrections, if any, shall be performed by Landlord in conjunction with the performance of the Improvements by Tenant and Landlord and Tenant agree to cooperate with each other in order to enable the Required Compliance Corrections to be performed in a timely manner and Tenant shall continue its planning, demolition and construction of the Improvements during the period of such Required Compliance Corrections to the extent practicable and permitted by applicable Laws. So long as the same does not delay Landlord’s performance of the Required Restroom Compliance Corrections, Landlord shall reasonably coordinate Landlord’s performance of the Required Restroom Compliance Corrections with Tenant’s construction schedule for the Improvements. With respect to the Required Restroom Compliance Corrections on any floor of the Premises, Landlord shall substantially complete the applicable Required Restroom Compliance Corrections within six (6) weeks after the later of (y) the Delivery Date applicable to the portion of the Premises in which the Required Restroom Compliance Corrections are being performed; or (z) Tenant’s commencement of construction of the Improvements on the floor on which the Required Restroom Compliance Corrections are being performed.

“Phase I Premises Improvements”); (ii) a one-time improvement allowance (the “Phase II Premises Improvement Allowance”) in the amount of up to Eighteen Million Eight Hundred Thousand Six Hundred and 00/100 Dollars ($18,800,600.00) (i.e., One Hundred Dollars ($100.00) per rentable square foot of the Phase II Premises) for the costs relating to the initial design and construction of the improvements, which are permanently affixed to the Phase II Premises (the “Phase II Premises Improvements”); and (iii) the Must-Take Allowance (as defined in Section 1.4.5 of the Lease) (the Must-Take Allowance, the Phase I Premises Improvement Allowance and the Phase II Premises Improvement Allowance are, collectively, referred to herein as the “Improvement Allowance”) in the amount determined in accordance with Section 1.4.5 of the Lease for the Must-Take Improvements (as defined in Section 1.4.5 of the Lease) (the Must-Take Improvements, the Phase I Premises Improvements and the Phase II Premises Improvements are, collectively, referred to herein as the "Improvements"). In no event shall any portion of the Phase I Premises Improvement Allowance be applied toward Improvement Allowance Items, as defined in Section 2.2.1 below, in the Phase II Premises, and in no event shall any portion of the Phase II Premises Improvement Allowance be applied toward Improvement Allowance Items in the Phase I Premises. Landlord shall not be obligated to pay a total amount which exceeds the Improvement Allowance. Notwithstanding the foregoing or any contrary provision of this Lease, all Improvements shall be deemed Landlord's property under the terms of this Lease. Except as expressly set forth below with respect to a Completion Delay (as defined in Section 5.1 below), any unused portion of the (a) Phase I Premises Improvement Allowance remaining as of the date that is thirteen (13) months following the Phase I Premises Lease Commencement Date (the “Phase I Premises Improvement Allowance Sunset Date”); (b) Phase II Premises Improvement Allowance remaining as of the date that is thirteen (13) months following the Phase II Premises Lease Commencement Date (the “Phase II Premises Improvement Allowance Sunset Date”); and/or (c) the Must-Take Allowance remaining as of the date that is thirteen (13) months following the Must-Take Effective Date (the “Must-Take Allowance Sunset Date”), shall remain with Landlord and Tenant shall have no further right thereto; provided, however, to the extent Tenant timely requested disbursement for any Improvement Allowance Items for the Phase I Premises, the Phase II Premises and/or the Must-Take Space, as applicable, in accordance with the TCCs of this Work Letter prior to the Phase I Premises Improvement Allowance Sunset Date, the Phase II Premises Improvement Allowance Sunset Date or the Must-Take Allowance Sunset Date, as applicable, Landlord shall provide such disbursement subject to and in accordance with Section 2.2. Notwithstanding anything to the contrary herein, Tenant’s failure to request disbursement of the applicable Improvement Allowance by the applicable sunset date for such Improvement Allowance shall not be deemed a Tenant default under the Lease. Landlord and Tenant acknowledge and agree that the Phase I Premises Improvement Allowance Sunset Date, the Phase II Premises Improvement Allowance Sunset Date and the Must-Take Allowance Sunset Date shall each be postponed by the number of days that Tenant’s Substantial Completion (as defined in Section 5.3 below) of the Improvements is delayed due to a Completion Delay.

liens or otherwise have lien rights under California Civil Code Sections 8120 through 8138 which shall comply with the appropriate provisions, as reasonably determined by Landlord, of California Civil Code Sections 8132, 8134, 8136 and 8138; and (iv) the items listed on Schedule 1 that are expressly identified to be tendered in connection with the disbursement of any portion of the applicable Improvement Allowance. Tenant's request for payment shall be deemed Tenant's acceptance and approval of the work furnished and/or the materials supplied as set forth in Tenant's payment request. Within ten (10) days thereafter, and provided that Tenant has paid the applicable percentage of the Over-Allowance Amount specified in Section 4.2.1 below, Landlord shall deliver a check to Tenant made jointly payable to the applicable Contractor and Tenant, or directly to such Contractor at Landlord's reasonable discretion, in payment of the lesser of: (A) the amounts so requested by Tenant, as set forth in this Section 2.2.2.1, above, less a ten percent (10%) retention (the aggregate amount of such retentions to be known as the "Final Retention"), and (B) the balance of any remaining available portion of the applicable Improvement Allowance (not including the Final Retention), provided that Landlord does not dispute any request for payment based on non-compliance of any work with the "Approved Working Drawings," as that term is defined in Section 3.4 below, or due to any substandard work, or for any other reason. Notwithstanding the foregoing, the Final Retention withheld by Landlord shall not be deemed to prohibit Tenant from withholding any sum from Contractor pursuant to Tenant’s contract with Contractor. Landlord's payment of such amounts shall not be deemed Landlord's approval or acceptance of the work furnished or materials supplied as set forth in Tenant's payment request.

2.2.2.2 Final Retention. Subject to the provisions of this Work Letter, a check for the Final Retention payable jointly to Tenant and the applicable Contractor, or directly to such Contractor at Landlord's reasonable discretion, shall be delivered by Landlord to Tenant within thirty (30) days following the completion of construction of the applicable Improvements, provided that (i) Tenant delivers to Landlord (a) paid invoices for all applicable Improvements and related costs for which the applicable portion of the Improvement Allowance is to be dispersed, (b) signed permits for all Improvements completed within the applicable portion of the Premises, and (c) properly executed unconditional mechanics lien releases in compliance with both California Civil Code Section 8134 and either Section 8136 or Section 8138 from Tenant's contractor, subcontractors and material suppliers and any other party which has lien rights in connection with the construction of the applicable Improvements, (ii) Landlord has determined that no substandard work exists which adversely affects the mechanical, electrical, plumbing, heating, ventilating and air conditioning, life-safety or other systems of the Building, the curtain wall of the Building, the structure or exterior appearance of the Building, or any other tenant's use of such other tenant's leased premises in the Building, (iii) Architect delivers to Landlord a "Certificate of Substantial Completion", in a form reasonably acceptable to Landlord, certifying that the construction of the applicable Improvements has been Substantially Completed, (iv) Tenant delivers to Landlord a "close-out package" in both paper and electronic forms (including, as-built drawings, and final record CADD files for the associated plans, warranties and guarantees from all contractors, subcontractors and material suppliers, and an independent air balance report); (v) Tenant causes a Notice of Completion to be recorded in the office of the Recorder of the county in which the Building is located pursuant to Section 4.3 below; and (vi) a certificate of occupancy, a temporary certificate of occupancy or its equivalent is issued to Tenant for the applicable portion of the Premises.

2.3 Building Standards. Landlord has established or may establish specifications for certain Building standard components to be used in the construction of the Landlord Work and Improvements attached hereto as Schedule 2 (“Building Standards”). The quality of Landlord Work and Improvements shall be equal to or of greater quality than the quality of such Building Standards. Landlord may make commercially reasonable changes to the Building Standards from time to time; provided, however, that (i) the Building Standards as attached shall apply to the Phase I Premises Improvements and the Phase II Premises Improvements; (ii) the Building Standards in effect as of the date on which Tenant submits any Construction Drawings for the Must-Take Space shall apply to the Must-Take Improvements and (iii) the Building Standards in effect as of the date on which Tenant submits any Construction Drawings for the First Offer Space shall apply to the applicable Improvements therefor. Notwithstanding anything to the contrary in the foregoing, (a) any doors installed by Tenant on multi-tenant floors within the Premises shall be Building Standard and (b) all window coverings installed by Tenant within the Premises shall be consistent throughout the Premises and shall be equal to or of greater quality than the quality of the Building Standards with respect to window coverings notwithstanding any subsequent change to the Building Standards.

of the applicable Improvement Allowance within the timeframe set forth in Section 2.1 above, and (b) Landlord fails to either pay the Improvement Allowance (or the applicable portion thereof) owed to Tenant or provide Tenant with written notice of any Disbursement Condition that Tenant has failed to satisfy within thirty (30) days following Tenant’s written request (a “Refusal Notice”), Tenant shall have the right to provide Landlord with a second Request for Disbursement, which second Request for Disbursement must state the following in bold and capped font: “THIS IS TENANT’S SECOND REQUEST FOR DISBURSEMENT TO LANDLORD. LANDLORD FAILED TO DISBURSE THE IMPROVEMENT ALLOWANCE TO TENANT IN ACCORDANCE WITH THE TERMS OF THE WORK LETTER ATTACHED TO THE LEASE. IF LANDLORD FAILS TO DISBURSE THE IMPROVEMENT ALLOWANCE OR SPECIFY IN WRITING WHICH DISBURSEMENT CONDITIONS TENANT HAS FAILED TO SATISFY WITHIN 20 DAYS FOLLOWING TENANT’S DELIVERY OF THIS NOTICE PURSUANT TO THE TCCs OF SECTION 29.18 OF THE LEASE, TENANT SHALL HAVE THE RIGHT TO DEDUCT THE PORTION OF THE IMPROVEMENT ALLOWANCE PAYABLE TO TENANT FROM THE NEXT INSTALLMENT OF BASE RENT PAYABLE BY TENANT UNDER THE LEASE.” If Tenant’s second Request for Disbursement complies with the terms of this Section 2.6 and Landlord’s failure to respond continues for twenty (20) days after Tenant’s delivery of such Request for Disbursement pursuant to the TCCs of Section 29.18 of the Lease, so long as the Disbursement Conditions have been fully satisfied, Tenant shall be entitled to offset the amount of the Improvement Allowance due to Tenant set forth in the Request for Disbursement (or if Landlord delivers a Refusal Notice but only with respect to a portion of the amount set forth in the Request for Disbursement and Landlord fails to pay such undisputed amount as required by the next succeeding sentence, the undisputed amount so owed to Tenant) with interest at the Interest Rate from the date due (i.e. the date payable under Sections 2.2.2.1 or 2.2.2.2 above) against up to fifty percent (50%) of Base Rent next due and owing until such time as the entire unpaid amount is reimbursed in full. Notwithstanding the foregoing, Landlord hereby agrees that if Landlord delivers a Refusal Notice disputing a portion of the amount set forth in Tenant's Request for Disbursement, in order for the Refusal Notice to be valid, Landlord shall pay to Tenant, concurrently with the delivery of the Refusal Notice, the undisputed portion of the amount set forth in the Refusal Notice. If Landlord delivers a Refusal Notice, and if Landlord and Tenant are not able to agree on the disputed amounts to be so paid by Landlord, if any, within ten (10) business days after Tenant's receipt of a Refusal Notice, Tenant shall not be entitled to make such offset with respect to the disputed portion of the amount set forth in the Refusal Notice until the earlier of (i) the date the disputed amount is no longer disputed by Landlord and (ii) the date on which Tenant prevails in any legal action against Landlord regarding any disputed amount of the Improvement Allowance and Tenant is awarded a final award, which is not subject to appeal, from a court or arbitrator in favor of Tenant requiring payment by Landlord which is not paid by Landlord within the time period directed by such award (each of clauses (i) and (ii) referred to herein as a “Disputed Offset Amount”). If Tenant is entitled to a Disputed Offset Amount in accordance with the preceding sentence, Tenant may offset such Disputed Offset Amount (plus interest on the amount of such Disputed Offset Amount from the date incurred at the Interest Rate until such amount is offset by Tenant as provided herein) from Rent next due and payable under this Lease; provided, however, Tenant may not deduct the amount of the Disputed Offset Amount against more than fifty percent (50%) of Base Rent next due and owing (until such time as the entire amount of such Disputed Offset Amount is deducted). Notwithstanding anything to the contrary contained herein, if Tenant

2.7 Stairwell Work. As part of the Phase II Premises Improvements, Tenant shall have the right, at its sole cost and expense, to remove the existing sheetrock (the “Stairwell Work”) that currently encases the internal stairwell between the fourteenth (14^th) and fifteenth (15^th) floors of the Building. If Tenant elects to perform such Stairwell Work, Tenant shall also be required to block off such stairwell access to the thirteenth (13^th) floor of the Building. Notwithstanding anything to the contrary contained in Section 1.3.4 of the Lease, if Tenant elects to perform the Stairwell Work, the rentable square footage of the stairwell area (which is 137 rentable square feet) shall be included in the Premises as of the Phase II Premises Lease Commencement Date (subject to Tenant’s Deferred Delivery Right set forth in Section 2.1 of the Lease) at the same rental rate then in effect for the remainder of the Premises as of such date. In the event Tenant performs the Stairwell Work and subsequently exercises its Offer Right pursuant to Section 1.3 of the Lease and leases the entire thirteenth (13^th) floor of the Building, then Tenant shall have the right, pursuant to the TCCs of the Lease, to remove the stairwell blockage preventing access to the thirteenth (13^th) floor of the Building. Landlord agrees to reimburse Tenant for the actual and reasonable costs incurred by Tenant in connection with the Stairwell Work (in an amount not to exceed Five Thousand and 00/100 Dollars ($5,000.00)) within thirty (30) days after receipt of invoice together with reasonable supporting evidence.

3.1 Selection of Architect/Construction Drawings. Tenant shall retain an architect/space planner designated by Tenant and reasonably approved by Landlord (the "Architect") to prepare the "Construction Drawings," as that term is defined in this Section 3.1. Landlord hereby approves IA Interior Architect as the Architect if selected by Tenant, in Tenant’s sole and absolute discretion. If Tenant desires to use an architect/space planner other than IA Interior Architect, then Landlord shall approve such architect/space planner, such approval not to be unreasonably withheld, conditioned or delayed. Landlord shall approve or reasonably disapprove any architect/space planner proposed by Tenant within five (5) business days. If Landlord fails to respond to any such request within the five (5) business day period set forth above, Tenant shall have the right to provide Landlord with a second request. Tenant’s second request must specifically state that Landlord’s failure to respond within a period of two (2) business days shall be deemed to be an approval by Landlord of the proposed architect/space planner. If Landlord’s failure to respond continues for two (2) business days after Tenant’s delivery of the second request pursuant to the TCCs of Section 29.18 of the Lease, the architect/space planner proposed by Tenant for which Tenant has requested such consent shall be deemed to have been approved by Landlord. Tenant shall retain an engineering consultant reasonably approved by Landlord to prepare all plans and engineering working drawings relating to mechanical, electrical, plumbing, lifesafety and sprinkler work in the Premises. Landlord hereby approves AlfaTech Consulting Enterprises as Tenant’s mechanical, electrical and plumbing engineering consultant (the “MEP Engineer”) if selected by Tenant, in Tenant’s sole and absolute discretion. If Tenant desires to use a MEP Engineer other than AlfaTech, then Landlord shall approve

such MEP Engineer, such approval not to be unreasonably withheld, conditioned or delayed. Landlord shall approve or reasonably disapprove any MEP Engineer or engineer to perform lifesafety and sprinkler work in the Premises (the “LifeSafety Consultant”) proposed by Tenant within five (5) business days following Tenant’s delivery of such request pursuant to the TCCs of Section 29.18 of the Lease. If Landlord fails to respond to any such request within the five (5) business day period set forth above, Tenant shall have the right to provide Landlord with a second request. Tenant’s second request must specifically state that Landlord’s failure to respond within a period of two (2) business days following Tenant’s delivery of such second notice pursuant to the TCCs of Section 29.18 of the Lease shall be deemed to be an approval by Landlord of the proposed MEP Engineer or LifeSafety Consultant. If Landlord’s failure to respond continues for two (2) business days after Tenant’s delivery of the second request pursuant to the TCCs of Section 29.18 of the Lease, the MEP Engineer or LifeSafety Consultant proposed by Tenant for which Tenant has requested such consent shall be deemed to have been approved by Landlord. The plans and drawings to be prepared by the Architect and any structural, mechanical, electrical, plumbing, lifesafety or HVAC consultants retained by Tenant (including the MEP Engineer and the LifeSafety Consultant) (collectively, the “Engineers”) shall be known collectively as the "Construction Drawings". The Construction Drawings may be prepared and submitted to Landlord independently for each portion of the Premises (on no less than on a floor by floor basis) and Landlord shall review the Construction Drawings so submitted. All Construction Drawings shall comply with the drawing format and specifications determined by Landlord, and shall be subject to Landlord's reasonable approval, which shall not be withheld except in the case of a “Design Problem,” as that term is defined below. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord's review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord's review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord's space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant's waiver and indemnity set forth in this Lease shall specifically apply to the Construction Drawings. A “Design Problem” is defined as, and will be deemed to exist if such Improvements may (i) affect the exterior appearance of the Premises or Building; (ii) adversely affect the Building Structure; (iii) adversely affect the Building Systems; (iv) fail to comply with applicable Laws, (v) reduce the availability of points needed by Landlord to maintain Landlord's LEED Gold certification for the Building, or (vi) adversely affect any other tenant premises in the Building that are directly adjacent and/or contiguous to the Premises.

space plan (the "Final Space Plan") shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Tenant’s delivery of a Final Space Plan pursuant to the TCCs of Section 29.18 of the Lease if there is a Design Problem with respect to such Final Space Plan otherwise Landlord shall approve such Final Space Plan within such five (5) business day period. If Tenant is so advised, Tenant shall cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require. In addition, Tenant shall have the right to include with its delivery of any Final Space Plan a request to be notified whether the Improvements set forth thereon (or any portion thereof) constitute Specialty Alterations pursuant to Section 3.7. In connection with Landlord’s review of any revision(s) to the proposed Final Space Plan, Landlord shall not raise objections to any portion of the Final Space Plan that were not raised in Landlord’s prior review(s) (unless such objections relate to a portion of revised Final Space Plan that were not shown on previously reviewed draft of the Final Space Plan). In addition, Landlord shall not disapprove any portion of the Final Space Plan which is substantially similar to any Final Space Plan previously approved by Landlord for any other floors of the Premises unless there is a Design Problem with respect to such newly submitted Final Space Plan. If Landlord fails to respond to any initial request for consent to the Final Space Plan within five (5) business days, Tenant shall have the right to provide Landlord with a second request for consent, which second notice must state the following in bold and capped font: “THIS IS TENANT’S SECOND NOTICE TO LANDLORD. LANDLORD FAILED TO RESPOND TO TENANT’S FIRST NOTICE REQUESTING CONSENT TO THE FINAL SPACE PLAN IN ACCORDANCE WITH THE TERMS OF THE WORK LETTER ATTACHED TO THE LEASE. IF LANDLORD FAILS TO RESPOND TO THIS NOTICE WITHIN FIVE (5) BUSINESS DAYS FOLLOWING TENANT’S DELIVERY OF THIS NOTICE PURSUANT TO THE TCCs OF SECTION 29.18 OF THE LEASE, LANDLORD SHALL BE DEEMED TO HAVE CONSENTED TO THE PROPOSED FINAL SPACE PLAN.” If Tenant’s second notice complies with the terms of this Section and Landlord’s failure to respond continues for five (5) business days after Tenant’s delivery of the second request for consent pursuant to the TCCs of Section 29.18, the Final Space Plan delivered to Landlord shall be deemed to have been approved by Landlord. Landlord shall approve any re-submittal of a Final Space Plan within two (2) business days after Tenant’s delivery thereof pursuant to the TCCs of Section 29.18 of the Lease and Landlord’s failure to respond within such two (2) business day period shall be deemed to be Landlord’s approval of such Final Space Plan.

Drawings a request to be notified whether the Improvements set forth thereon (or any portion thereof) constitute Specialty Alterations pursuant to Section 3.7. Landlord shall advise Tenant within ten (10) business days after Tenant’s delivery of the Final Working Drawings pursuant to the TCCs of Section 29.18 if there is a Design Problem with respect to such Final Working Drawings otherwise Landlord shall approve or disapprove such Final Working Drawings within such ten (10) business day period. If Landlord fails to respond to any request for consent to the Final Working Drawings within such ten (10) business day period, Tenant shall have the right to provide Landlord with a second request for consent, which second notice must state the following in bold and capped font: “THIS IS TENANT’S SECOND NOTICE TO LANDLORD. LANDLORD FAILED TO RESPOND TO TENANT’S FIRST NOTICE REQUESTING CONSENT TO THE FINAL WORKING DRAWINGS IN ACCORDANCE WITH THE TERMS OF THE WORK LETTER ATTACHED TO THE LEASE. IF LANDLORD FAILS TO RESPOND TO THIS NOTICE WITHIN FIVE (5) BUSINESS DAYS FOLLOWING TENANT’S DELIVERY OF THIS NOTICE PURSUANT TO THE TCCS OF SECTION 29.18 OF THE LEASE, LANDLORD SHALL BE DEEMED TO HAVE CONSENTED TO THE PROPOSED FINAL WORKING DRAWINGS.” If Tenant’s second notice complies with the terms of this Section and Landlord’s failure to respond continues for five (5) business days after its delivery of the second request for consent pursuant to the TCCs of Section 29.18 of the Lease, the Final Working Drawings delivered to Landlord shall be deemed to have been approved by Landlord. If Tenant is so advised, Tenant shall revise the Final Working Drawings in accordance with such review and any disapproval of Landlord in connection therewith. In addition, if the Final Working Drawings or any amendment thereof or supplement thereto shall require alterations in the Base Building (as contrasted with the Improvements), and if Landlord in its sole and exclusive discretion agrees to any such alterations, and notifies Tenant of the need and cost for such alterations, then Tenant shall pay the reasonable and cost of such required changes in advance upon receipt of notice thereof.

3.4 Approved Working Drawings. Construction of the Improvements shall not commence until the Final Working Drawings therefor shall be approved by Landlord (the "Approved Working Drawings"). Tenant shall submit the Final Working Drawings to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord's consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant's responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings (“Changes”) which constitute a Design Problem (provided that in such event Tenant shall provide reasonable prior notice of any such Change) may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld. Landlord shall advise Tenant within five (5) business days after Tenant’s delivery of a Change request pursuant to the TCCs of Section 29.18 of the Lease if there is a Design Problem with respect to such Change request otherwise Landlord shall approve such Change request. In addition, Landlord shall not disapprove any Change to a floor of the Premises which Landlord has previously approved with respect to another floor of the Premises unless there is a Design Problem with respect to such Change. If Landlord fails to respond within such five (5) business day period, then Tenant shall have the right to deliver a second notice to Landlord requesting Landlord's approval of such Change (which

3.6 Space Planning Allowance. Tenant shall be entitled to a one-time allowance (the “Space Planning Allowance”) in the amount of $12,698.40 to reimburse Tenant’s reasonable costs of designing the Improvements. Landlord shall disburse the Space Planning Allowance to Tenant within thirty (30) days after Tenant’s delivery of copies of paid invoices pursuant to the TCCs of Section 29.18 of the Lease from Tenant’s space planner and/or other design consultants for the amounts covered by the disbursement. Notwithstanding any contrary provision of this Lease, if, for any reason other than a breach by Landlord of its obligations under this Lease, the entire Space Planning Allowance is not used within thirteen (13) months of the Phase II Premises Delivery Date, then the unused amount shall revert to Landlord and Tenant shall have no further rights with respect thereto. Notwithstanding anything to the contrary contained herein, this Section 3.6 shall in no event apply to any First Offer Space, it being agreed that Landlord shall have no obligation to provide a space planning allowance to reimburse any costs incurred by Tenant in connection with designing any improvements therefor unless otherwise agreed by the parties at the time Tenant leases the First Offer Space.

3.7 Specialty Alterations. Tenant shall have the right, at any time prior to the completion of the Improvements for each portion of the Premises, to provide notice to Landlord pursuant to the TCCs of Section 29.18 of the Lease (either in the notices provided pursuant to Section 3.3 or 3.4 above or pursuant to a separate notice) (a “Specialty Alterations Notice”), which such Specialty Alterations Notice shall include a request to be notified whether the Improvements set forth in such Specialty Alterations Notice (or any portion thereof) constitute Specialty Alterations. If Tenant submits such Specialty Alterations Notice, Landlord shall notify Tenant whether the any portion of the Improvements set forth on such Specialty Alterations Notice (or any portion thereof) constitute Specialty Alterations. Landlord shall advise Tenant within ten (10) business days after Tenant’s delivery of the Specialty Alterations Notice pursuant to the TCCs of Section 29.18 whether the Improvements set forth in such Specialty Alterations Notice (or any portion thereof) constitute Specialty Alterations. If Landlord fails to respond to any Specialty Alterations Notice within such ten (10) business day period, Tenant shall have the right to provide Landlord with a second Specialty Alterations Notice, which second Specialty Alterations Notice must state the following in bold and capped font: “LANDLORD FAILED TO RESPOND TO TENANT’S FIRST NOTICE

4.1.1 The Contractor. A general contractor (“Contractor”) shall be retained by Tenant to construct the Improvements. Landlord hereby approves NOVO Construction as the Contractor if selected by Tenant in Tenant’s sole and absolute discretion. Tenant shall use commercially reasonable efforts to cause the Contractor to perform the Improvements; provided, however, (i) Tenant's failure to cause the Contractor to perform the Improvements shall not be deemed a breach or default of the Lease, and (ii) Tenant’s failure to use commercially reasonable efforts to cause the Contractor to perform the Improvements shall not be deemed a breach or default of the Lease. There shall be no implied covenant of good faith or fair dealing (and the parties hereby disclaim any such covenant) with respect to the preceding sentence. If Tenant desires to use a general contractor other than NOVO Construction, then Landlord shall approve or reasonably disapprove such general contractor proposed by Tenant within five (5) business days. If Landlord fails to respond to any such request within the five (5) business day period set forth above, Tenant shall have the right to provide Landlord with a second request. Tenant’s second request must specifically state that Landlord’s failure to respond within a period of five (5) business days shall be deemed to be an approval by Landlord of the proposed general contractor. If Landlord’s failure to respond continues for five (5) business days after Tenant’s delivery of the second request pursuant to the TCCs of Section 29.18 of the Lease, the general contractor proposed by Tenant for which Tenant has requested such consent shall be deemed to have been approved by Landlord.

4.2.1.1 Tenant shall execute a construction contract (which Contract shall incorporate Landlord’s general conditions, attached hereto as Schedule 3) with the Contractor (each, a "Contract") for the Phase I Premises Improvements, the Phase II Premises Improvements, the Must-Take Space Improvements and, in the event Tenant exercises its Deferred Delivery Right pursuant to Section 2.1 of the Lease, the portion of the Phase II Premises Improvements applicable to the Deferred Space. Prior to the commencement of the construction of the applicable Improvements, and after Tenant has accepted all bids for such Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through 2.2.1.8, above, in connection with the design and construction of the applicable Improvements to be performed by or at the direction of Tenant or the Contractor, which costs form a basis for the amount of the applicable Contract (the "Final Costs"). Landlord may elect by written notice to Tenant (“Landlord’s Construction Risk Notice”) to Tenant no later than ten (10) business days following Tenant’s delivery of the applicable Final Costs and construction schedule pursuant to the TCCs of Section 29.18 of the Lease to apply the Construction Risk Alternative (as defined below) for each Contract in order that Landlord may satisfy its REIT related obligations with respect to timely recognizing revenue from this Lease (as determined by Landlord in its sole discretion), and in such case the provisions of the Construction Risk Alternative shall automatically apply to the applicable Improvements and be binding upon Tenant. The term "Construction Risk Alternative" means that Tenant shall bifurcate the applicable Contract into two separate schedules of values, with one schedule of values (the “100% Improvements Schedule”), including specific identifiable assets / trades equal to the applicable Improvement Allowance, for one hundred percent (100%) of the applicable Improvement Allowance (the "100% Threshold"), and with the other schedule of values (the "Remaining Schedule") covering the remaining tenant related work to construct the applicable Improvements. Tenant shall deliver both resulting schedules of value to Landlord within thirty (30) days following delivery of Landlord’s Construction Risk Notice. In the event that Landlord elects the Construction Risk Alternative, then notwithstanding any contrary provision of this Work Letter,

4.2.1.2 If Landlord does not exercise the Construction Risk Alternative, Landlord and Tenant hereby agree that Landlord and Tenant shall pay for their respective obligations with respect to the cost of the Improvements on a pari passu basis. Accordingly, if an Over-Allowance Amount (as defined below) exists, then in connection with each of Landlord's monthly disbursements of the applicable Improvement Allowance, Tenant shall concurrently pay a percentage of each amount disbursed by Landlord to Tenant under this Work Letter or otherwise disbursed under this Work Letter directly to the appropriate person or entity, which percentage shall be equal to the amount of the Over-Allowance Amount (as defined below) relating to the applicable portion of the Premises divided by the amount of the Final Costs relating to the applicable portion of the Premises (“Tenant’s Contribution”), and such payment by Tenant shall be a condition to Landlord’s obligation to pay any amounts of the applicable Improvement Allowance. For purposes hereof, the "Over-Allowance Amount" shall be equal to the difference, if any, between the amount of the Final Costs for the applicable Improvements and the amount of the applicable Improvement Allowance (as calculated based upon the applicable portion of the Premises to be constructed under the applicable Contract, less any portion thereof already disbursed by Landlord, or in the process of being disbursed by Landlord, on or before the commencement of construction of the applicable Improvements). Notwithstanding the foregoing, Landlord, in its sole and absolute discretion, by providing written notice to Tenant upon Landlord’s determination of the applicable Final Costs, shall have the option to require application of the applicable Improvement Allowance toward the Improvement Allowance Items prior to Tenant’s application of Tenant’s Contribution toward the applicable Improvements (it being agreed that if Landlord fails to provide such notice, the Over-Allowance Amount, if any, shall be paid by Tenant on a pari passu basis). In the event that, after the Final Costs for the applicable Improvements have been delivered by Tenant to Landlord, any revisions, changes or substitutions shall be made to the applicable Final Working Drawings or the applicable Improvements, or the costs relating to the design and construction of the applicable Improvements shall change, the above amounts shall be adjusted as equitable to reflect any additional or reduced costs which arise in connection therewith. Tenant shall provide Landlord with updated construction schedules and budgets on a regular basis during the course of construction of the applicable Improvements, and in any event within fifteen (15) days after request by Landlord. In connection with any Over-Allowance payments made by Tenant pursuant to this Section 4.2.1.2, Tenant shall provide Landlord with the documents described in Sections 2.2.2.1 (i), (ii), (iii) and (iv) of this Work Letter, above, for Landlord's approval, prior to Tenant paying such costs.

4.2.2.1 Landlord's General Conditions for Tenant's Agents and Improvement Work. Tenant's and Tenant's Agent's construction of the Improvements shall comply with the following: (i) the Improvements shall be constructed in accordance with the applicable Approved Working Drawings (as modified by any Changes) and (ii) Tenant shall abide by Landlord’s construction rules a copy of which is attached hereto as Schedule 4 (“Construction Rules”). Tenant shall pay a logistical coordination fee (the "Coordination Fee") to Landlord in an amount equal to One Hundred Fifty Thousand and 00/100 Dollars ($150,000.00), which Coordination Fee shall be for all services relating to the coordination of the construction of the Improvements and shall be deducted from the Improvement Allowance for each of the Phase I Premises and the Phase II Premises on a pro rata basis based on the rentable square footage of each of the Phase I Premises and the Phase II Premises (however, for the avoidance of doubt, no such Coordination Fee shall be payable in connection with Tenant’s performance of the Must-Take Space Improvements). In addition, Tenant shall reimburse Landlord for all actual and reasonable costs incurred by Landlord in connection with the third-party review of any plans for the Improvements, which costs shall be payable to Landlord within thirty (30) days after Landlord’s invoice therefor together with reasonable supporting evidence.

4.2.2.3 Requirements of Contractor. Contractor shall guarantee to Tenant and for the benefit of Landlord that the portion of the Improvements for which it is responsible shall be free from any defects in workmanship and materials for a period of not less than one (1) year from the date of completion thereof. Each of Tenant's Agents shall be responsible for the replacement or repair, without additional charge, of all work done or furnished in accordance with its contract that shall become defective within one (1) year after the completion of the work (including any punch list items) performed by Contractor. The correction of such work shall include, without additional charge, all additional expenses and damages incurred in connection with such removal or replacement of all or any part of the Improvements, and/or the Building and/or Common Areas that may be damaged or disturbed thereby. All such warranties or guarantees as to materials or workmanship of or with respect to the Improvements shall be contained in each Contract or subcontract and shall be written such that such guarantees or warranties shall inure to the benefit of both Landlord and Tenant, as their respective interests may appear, and can be directly enforced by either. Tenant covenants to give to Landlord any assignment or other assurances which may be necessary to effect such right of direct enforcement.

4.2.2.4.3 General Terms. Certificates for all insurance carried pursuant to this Section 4.2.2.3 shall be delivered to Landlord before the commencement of construction of any portion of the Improvements and before the Contractor's equipment is moved onto the site. If such policies of insurance do not contain a provision that the company writing said policy will give Landlord ten (10) days written notice in the event of non-payment of premium, then Tenant shall provide such written notice to Landlord within such ten (10) day period. Tenant's Agents shall maintain all of the foregoing insurance coverage in force until the Improvements are fully completed and accepted by Landlord, except for any Products and Completed Operation Coverage insurance required by Landlord written on a claims made basis, which is to be maintained for five (5) years following completion of the work and acceptance by Landlord and Tenant. All policies carried under this Section 4.2.2.3 shall insure Landlord and Tenant, as their interests may appear, as well as each Contractor and Tenant's Agents. All insurance, except Workers' Compensation, maintained by Tenant's Agents shall preclude subrogation claims by the insurer against anyone insured thereunder. Such insurance shall provide that it is primary insurance as respects the owner and that any other insurance maintained by owner is excess and noncontributing with the insurance required hereunder. The requirements for the foregoing insurance shall not derogate from the provisions for indemnification of Landlord by Tenant under Section 4.2.2.2 of this Work Letter.

4.2.4 Inspection by Landlord. During construction, Landlord shall have the right to inspect the Improvements at all reasonable times, provided however, that Landlord's failure to inspect the Improvements shall in no event constitute a waiver of any of Landlord's rights hereunder nor shall Landlord's inspection of the Improvements constitute Landlord's approval of the same. Should Landlord disapprove any portion of the Improvements as not being in accordance with the Approved Working Drawings, Landlord shall notify Tenant in writing of such disapproval and shall specify the items disapproved. Any defects or deviations in, and/or disapproval by Landlord of, the Improvements shall be rectified by Tenant at no expense to Landlord, provided however, that in the event Landlord determines that a defect or deviation exists or disapproves of any matter in connection with any portion of the Improvements and such defect, deviation or matter adversely affects the mechanical, electrical, plumbing, heating, ventilating and air conditioning or life-safety systems of the Building, the structure or exterior appearance of the Building or any other tenant's use of such other tenant's leased premises, following notice to Tenant and Tenant’s right to cure the same within the time periods set forth in the Lease, Landlord may, take such action as Landlord

4.3 Notice of Completion; Copy of Record Set of Plans. Within fifteen (15) days after completion of construction of the Improvements for each Phase, Tenant shall cause a Notice of Completion to be recorded in the office of the Recorder of the county in which the Building is located in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and shall furnish a copy thereof to Landlord upon such recordation. If Tenant fails to do so, Landlord may execute and file the same as Tenant's agent for such purpose, at Tenant's sole cost and expense. At the conclusion of construction, (i) Tenant shall cause the Architect and Contractor (A) to update the Approved Working Drawings as necessary to reflect all changes made to the Approved Working Drawings during the course of construction, (B) to certify to the best of their knowledge that the "record-set" of as-built drawings are true and correct, which certification shall survive the expiration or termination of this Lease, and (C) to deliver to Landlord two (2) sets of copies of such record set of drawings within ninety (90) days following issuance of a certificate of occupancy for the applicable portion of the Premises, and (ii) Tenant shall deliver to Landlord a copy of all warranties, guaranties, and operating manuals and information relating to the improvements, equipment, and systems in the Premises.

Improvements set forth on Tenant’s construction schedule for the applicable portion of the Phase II Premises, (c) with respect to the Must-Take Space, the later of (y) the date that is one hundred fifty (150) days following the Must-Take Delivery Date, or (z) the date of Substantial Completion of the Must-Take Improvements set forth on Tenant’s construction schedule for the applicable portion of the Must-Take Space and (d) with respect to any First Offer Space, after the later of (I) the anticipated Lease Commencement Date for such First Offer Space, as set forth in the applicable First Offer Notice, or (II) the date of Substantial Completion of the applicable Improvements set forth on Tenant’s construction schedule for the applicable portion of the First Offer Space. As used herein, the term "Completion Delay" shall mean only a "Force Majeure Delay" or a "Landlord Caused Delay," as those terms are defined below in this Section 5.1 of this Work Letter. "Force Majeure Delay" shall mean only an actual delay resulting from strikes, fire, wind, damage or destruction to the Building, explosion, casualty, flood, hurricane, tornado, the elements, acts of God or the public enemy, sabotage, war, terrorist acts, invasion, insurrection, rebellion, civil unrest, riots, or earthquakes. "Landlord Caused Delay" shall mean actual delays to the extent resulting from (i) the failure of Landlord to timely complete any Landlord Work subject to and in accordance with the TCCs of Section 1.2 of the Work Letter; (ii) the failure of Landlord to timely approve or disapprove any "Construction Drawings," as that term is defined in Section 3.1 of this Work Letter; (iii) interference (when judged in accordance with industry custom and practice) by Landlord, its agents or employees (except as otherwise allowed under this Work Letter) with the Substantial Completion of the Improvements and which objectively preclude or delay (A) the construction of improvements in the Building by any person and (B) Tenant’s ability to occupy and commence business operations in the applicable portion of the Premises; or (iv) delays due to the acts or failures to act of Landlord, its agents or employees with respect to the proper payment of the Improvement Allowance (except as otherwise allowed under this Work Letter) but Tenant shall have a right to suspend its design and construction of the Improvements, if Landlord fails to reimburse Tenant all or any part of the Improvement Allowance when due in accordance with the terms and conditions of this Work Letter.

3.Landlord reserves the right to close and keep locked all entrance and exit doors of the Building during such hours as are customary for comparable buildings in the San Francisco, California area; provided, however, subject to the terms of the Lease, Tenant shall be provided access to the Project, Building and Common Areas twenty-four (24) hours per day, seven (7) days per week. Tenant, its employees and agents must be sure that the doors to the Building are securely closed and locked when leaving the Premises if it is after the normal hours of business for the Building. Any tenant, its employees, agents or any other persons entering or leaving the Building at any time when it is so locked, or at any time that is considered to be after normal business hours for the Building, may be required to sign the Building register. Access to the Building may be refused unless the person seeking access has proper identification or has a previously arranged pass for access to the Building. Landlord will furnish passes to persons for whom Tenant requests same in writing. In case of invasion, mob, riot, public excitement, or other commotion, Landlord reserves the right to temporarily prevent access to the Building or the Project during the continuance thereof by any means it deems appropriate for the safety and protection of life and property.

1. RELEVANT FACTORS. The "Market Rent," as used in this Lease, shall be derived from an analysis (as such derivation and analysis are set forth in this Exhibit H) of the "Net Equivalent Lease Rates," of the "Comparable Transactions" (as that term is defined below). The Market Rent, as used in this Lease, shall be equal to the annual rent per rentable square foot, at which tenants, are, pursuant to transactions consummated within twelve (12) months prior to the commencement of the Option Term or the First Offer Space Term, as applicable, leasing non-sublease, non-encumbered space comparable in location and quality to the Premises or the subject First Offer Space, as applicable, containing a square footage comparable to that of the Premises or the subject First Offer Space, as applicable, for a term of five (5) years, in an arm's-length transaction, which comparable space is located in "Comparable Buildings" (transactions satisfying the foregoing criteria shall be known as the "Comparable Transactions"). The terms of the Comparable Transactions shall be calculated as a "Net Equivalent Lease Rate" pursuant to the terms of this Exhibit H, and shall take into consideration only the following terms and concessions (“Concessions”): (i) the rental rate and escalations for the Comparable Transactions, (ii) the amount of parking rent per parking permit paid in the Comparable Transactions, if any, (iii) operating expense and tax protection granted in such Comparable Transactions such as a base year or expense stop (although for each such Comparable Transaction the base rent shall be adjusted to a triple net base rent using reasonable estimates of operating expenses and taxes as determined by Landlord for each such Comparable Transaction); (iv) rental abatement concessions, if any, being granted such tenants in connection with such comparable space, including, without limitation, any free rent construction periods, (v) any "Market Allowance," as defined herein below, to be provided by Landlord in connection with an Option Term or a First Offer Space Term, as applicable, as compared to the improvements or allowances provided or to be provided in the Comparable Transactions taking into account the contributory value of the existing improvements in the Premises, such value to be based upon the age, design, quality of finishes, and layout of the existing improvements, (vi) all other monetary concessions (including the value of any signage), if any, being granted such Tenant or to tenants in connection with such Comparable Transactions, (vii) the size of the Phase of the Premises as compared to the size the premises leased in the Comparable Transaction, (viii) the Option Term as compared to the term of the Comparable Transaction, (ix) views and (x) timing adjustments to reflect changes (if any) in the Market Rent following the date of any particular Comparable Transaction up to the date of the commencement of the applicable Option Term or First Offer Space Term. As Tenant may not be entitled to any tenant improvement allowance, free rent period, brokerage commission or other economic concession during the Option Term, the Concessions available in Comparable Transactions which are not received by Tenant hereunder shall be reflected in the Market Rent payable by Tenant (which Market Rent shall take into consideration the total dollar value of such Concessions as amortized on a straight-line basis over the applicable term of the Comparable Transaction). The Market Rent shall include adjustment of

THIS LETTER OF CREDIT IS TRANSFERABLE ONE OR MORE TIMES, BUT IN EACH INSTANCE ONLY TO A SINGLE BENEFICIARY AS TRANSFEREE AND ONLY UP TO THE THEN AVAILABLE AMOUNT, ASSUMING SUCH TRANSFER TO SUCH TRANSFEREE WOULD BE IN COMPLIANCE WITH THEN APPLICABLE LAW AND REGULATION, INCLUDING BUT NOT LIMITED TO THE REGULATIONS OF THE U. S. DEPARTMENT OF TREASURY AND U. S. DEPARTMENT OF COMMERCE. AT THE TIME OF TRANSFER, THE ORIGINAL LETTER OF CREDIT AND ORIGINAL AMENDMENT(S), IF ANY, MUST BE SURRENDERED TO US AT OUR ADDRESS INDICATED IN THIS LETTER OF CREDIT TOGETHER WITH OUR TRANSFER FORM ATTACHED HERETO AS EXHIBIT “A” DULY EXECUTED. THE CORRECTNESS OF THE SIGNATURE AND TITLE OF THE PERSON SIGNING THE TRANSFER FORM MUST BE VERIFIED BY BENEFICIARY’S BANK. PROVIDED THAT IN LIEU OF SUCH BANK AUTHENTICATION, BENEFICIARY MAY PROVIDE THE ISSUING BANK WITH AN INCUMBENCY CERTIFICATE (OR OTHER DOCUMENTATION REASONABLY SATISFACTORY TO THE ISSUING BANK) TO EVIDENCE THE SIGNER'S AUTHORITY TO EXECUTE THE TRANSFER INSTRUMENT ON BEHALF OF THE BENEFICIARY. APPLICANT SHALL PAY OUR TRANSFER FEE OF US$5,000.00 PER TRANSFER UNDER THIS LETTER OF CREDIT. PAYMENT OF ANY TRANSFER FEES AND/OR ANY TRANSFER COST SHALL NOT BE A CONDITION PRECEDENT TO TRANSFER. EACH TRANSFER SHALL BE EVIDENCED BY OUR ENDORSEMENT ON THE REVERSE OF THE LETTER OF CREDIT AND WE SHALL FORWARD THE ORIGINAL OF THE LETTER OF CREDIT SO ENDORSED TO THE TRANSFEREE.

PRESENTATION OF A DRAWING UNDER THIS LETTER OF CREDIT MAY BE MADE ON OR PRIOR TO THE THEN CURRENT EXPIRATION DATE HEREOF BY HAND DELIVERY, COURIER SERVICE, OVERNIGHT MAIL, OR FACSIMILE. PRESENTATION BY FACSIMILE TRANSMISSION SHALL BE BY TRANSMISSION OF THE ABOVE REQUIRED SIGHT DRAFT DRAWN ON US TOGETHER WITH BENEFICIARY’S SIGNED STATEMENT AS SPECIFIED ABOVE TO OUR FACSIMILE NUMBER, (408) 496-2418, 2418 OR (408) 969-6510; ATTENTION: STANDBY LETTER OF CREDIT NEGOTIATION SECTION, WITH TELEPHONIC CONFIRMATION OF OUR RECEIPT OF SUCH FACSIMILE TRANSMISSION AT OUR TELEPHONE NUMBER (408)654-6274 OR (408) 654-7716 OR (408) 654-3035 OR TO SUCH OTHER FACSIMILE OR TELEPHONE NUMBERS, AS TO WHICH YOU HAVE RECEIVED WRITTEN NOTICE FROM US AS BEING THE APPLICABLE SUCH NUMBER. WE AGREE TO NOTIFY YOU IN WRITING, BY NATIONALLY RECOGNIZED OVERNIGHT COURIER SERVICE SUCH AS UPS OR FED-EX, OF ANY CHANGE IN SUCH DIRECTION. SHOULD BENEFICIARY WISH TO MAKE PRESENTATIONS UNDER THIS LETTER OF CREDIT ENTIRELY BY FACSIMILE TRANSMISSION IT NEED NOT TRANSMIT THIS LETTER OF CREDIT AND AMENDMENT(S), IF ANY. EACH FACSIMILE TRANSMISSION SHALL BE MADE AT OUR FACSIMILE NUMBERS SHOWN ABOVE WITH ORIGINALS TO FOLLOW BY OVERNIGHT COURIER SERVICE; PROVIDED, HOWEVER, THE BANK WILL DETERMINE HONOR OR DISHONOR ON THE BASIS OF PRESENTATION BY FACSIMILE ALONE, AND WILL NOT EXAMINE THE ORIGINALS. IN ADDITION, ABSENCE OF THE AFORESAID TELEPHONE ADVICE SHALL NOT AFFECT OUR OBLIGATION TO HONOR ANY DRAW REQUEST.



ARTICLE 1 PREMISES, BUILDING, PROJECT, AND COMMON AREAS	10
ARTICLE 2 LEASE TERM; OPTION TERMS	20
ARTICLE 3 BASE RENT	29
ARTICLE 4 ADDITIONAL RENT	30
ARTICLE 5 USE OF PREMISES	44
ARTICLE 6 SERVICES AND UTILITIES	50
ARTICLE 7 REPAIRS	57
ARTICLE 8 ADDITIONS AND ALTERATIONS	58
ARTICLE 9 COVENANT AGAINST LIENS	62
ARTICLE 10 INDEMNIFICATION AND INSURANCE	62
ARTICLE 11 DAMAGE AND DESTRUCTION	67
ARTICLE 12 NONWAIVER	70
ARTICLE 13 CONDEMNATION	70
ARTICLE 14 ASSIGNMENT AND SUBLETTING	71
ARTICLE 15 SURRENDER OF PREMISES; OWNERSHIP AND REMOVAL OF TRADE FIXTURES	76
ARTICLE 16 HOLDING OVER	77
ARTICLE 17 ESTOPPEL CERTIFICATES; FINANCIAL INFORMATION	78
ARTICLE 18 SUBORDINATION	80
ARTICLE 19 DEFAULTS; REMEDIES	82
ARTICLE 20 COVENANT OF QUIET ENJOYMENT	85
ARTICLE 21 LETTER OF CREDIT	85
ARTICLE 22 [Intentionally Omitted]	93
ARTICLE 23 SIGNS	93
ARTICLE 24 COMPLIANCE WITH LAW	99
ARTICLE 25 LATE CHARGES	101
ARTICLE 26 LANDLORD'S RIGHT TO CURE DEFAULT; PAYMENTS BY TENANT	101
ARTICLE 27 ENTRY BY LANDLORD	102
ARTICLE 28 TENANT PARKING; BICYCLE STORAGE AREA	103
ARTICLE 29 MISCELLANEOUS PROVISIONS	105

Abatement Event	55
Accelerated Must-Take Delivery Date	19
Accelerated Must-Take Notice	19
Accountant	43
Additional Must-Take L-C Amount	17
Additional Must-Take L-C Delivery Date	92
Additional Rent	30
Advocate Arbitrators	24
Alterations	58



Delaware (State or other jurisdiction of incorporation or organization)	001-38044 (Commission File Number)	26-4175727 (I.R.S. Employer Identification Number)
301 Brannan Street San Francisco, California 94107
(Address of principal executive offices and zip code)
(888) 722-7871
(Registrant's telephone number, including area code)
___________________________________



¨	Written communications pursuant to Rule 425 under the Securities Act (17 CFR 230.425)
¨	Soliciting material pursuant to Rule 14a-12 under the Exchange Act (17 CFR 240.14a-12)
¨	Pre-commencement communications pursuant to Rule 14d-2(b) under the Exchange Act (17 CFR 240.14d-2(b))
¨	Pre-commencement communications pursuant to Rule 13e-4(c) under the Exchange Act (17 CFR 240.13e-4(c))




Exhibit Number		Description
10.1		Office Lease Agreement dated December 2, 2017 between the Registrant and KR 100 First Street Owner, LLC.
99.1		Press release dated December 6, 2017, issued by Okta, Inc.





	Okta, Inc.

	By:	/s/ William E. Losch
	Name:	William E. Losch
	Title:	Chief Financial Officer




Exhibit Number		Description

10.1		Office Lease Agreement dated December 2, 2017 between the Registrant and KR 100 First Street Owner, LLC.
99.1		Press release dated December 6, 2017, issued by Okta, Inc.



TERMS OF LEASE			DESCRIPTION
11. Address of Landlord (Section 29.18):			Kilroy Realty, L.P. c/o Kilroy Realty Corporation 12200 West Olympic Boulevard, Suite 200 Los Angeles, California 90064 Attention: Legal Department with copies to: Kilroy Realty Corporation 100 First Street Office of the Building, Suite 250 San Francisco, California 94105 Attention: Senior Vice President, Asset Management and Kilroy Realty Corporation 100 First Street Office of the Building, Suite 150 San Francisco, California 94105 Attention: Senior Property Manager and SSL Law Firm LLP 575 Market Street, Suite 2700 San Francisco, California 94105 Attention: Sally Shekou, Esq.
12. Broker(s) (Section 29.24): Representing Tenant: Colliers International			Representing Landlord: CBRE, Inc.
13. Improvement Allowance: (Section 2 of Exhibit B):			$100.00 per rentable square foot of the Premises for a total of $20,706,600.00.
14. Guarantor:			None.



Bodily Injury and Property Damage Liability	$16,000,000 each occurrence
Personal Injury and Advertising Liability	$16,000,000 each occurrence
Tenant Legal Liability/Damage to Rented Premises Liability	$1,000,000


By:	100 First Street Member, LLC, a Delaware limited liability company, its Manager


By:	Kilroy Realty, L.P., a Delaware limited partnership, its Managing Member


By:	Kilroy Realty Corporation, a Maryland corporation, its General Partner



By:	/s/ Rick Buziak
Name:	Rick Buziak
Title:	SVP Asset Management


•	As used herein, the term "Contractor Party" means Contractor, Contractor's Subcontractors of every tier, consultants and/or material suppliers and their respective employees, agents and/or representatives.


•	Except as otherwise expressly set forth herein, the indemnification obligations of the Contractor under the Agreement shall be limited only to the extent required by the laws of the State in which the Project is located.


o	Workers' Compensation including Occupational Disease insurance meeting the statutory requirements of the state in which the Work is performed and


§	In addition to the foregoing, Contractor shall provide a Certificate of Insurance evidencing Umbrella Liability coverage in an amount not less than $Select Liability Amount,000,000.00 for Bodily Injury and Property Damage combined.


o	Commercial Automobile Liability on occurrence basis covering all Owned, Non-Owned, and Hired Vehicles in a minimum amount of $1,000,000.00, combined single limit, bodily injury and property damage.


o	In addition to other insurance required by statute or under provisions of the Contract, to the extent Contractor is to provide any design-build work in


o	Certificates of above insurance must not be canceled, not renewed or materially changed before thirty (30) days written notice by mail to the Owner, and certificates of insurance shall so state said notice will be furnished. Renewals shall be forwarded to Owner not less than ten (10) business days prior to expiration thereof.


o	It is understood and agreed that the insurance coverages and limits required above shall not limit the extent of the Contractor’s, or any Subcontractor’s, responsibilities and liabilities with respect to the Project.


o	Contractor waives all rights against Owner for damages to Contractor's personal property caused by fire or other perils covered under an All Risk Physical Damage Insurance Policy, and similar waivers shall be obtained from all consultants performing any of the services required hereunder.


o	KRC Entity, and the Indemnitees for the Project (collectively, the "Owner Parties") shall be named additional insureds (pursuant to ISO Form 20 10 11


o	In addition to the above, the Contractor shall assure that the above-referenced insurance includes the following types of coverage:


§	Claims under workers’ compensation, disability benefit and other similar employee benefit acts that are applicable to the Work to be performed;


§	Claims for damages because of bodily injury, occupational sickness or disease, or death of the Contractor’s employees;


§	Claims for damages insured by usual personal injury liability coverage;


§	Claims for damages, other than to the Work itself, because of injury to or destruction of tangible property, including loss of use resulting therefrom;


§	Claims for bodily injury or property damage arising out of completed operations, which coverage shall be maintained for no less than ten (10) years following final payment;


§	Claims involving contractual liability insurance applicable to the Contractor’s obligations under the Contract Documents, including, without limitation, those indemnity obligations set forth in these Landlord General Conditions; and


§	Claims on account of design errors and/or omissions provided by Subcontractors and consultants, if any.


•	If the Contractor fails to purchase and maintain, or require to be purchased and maintained, any insurance required under these Landlord General Conditions, the


•	The aggregate limit under the Contractor’s Comprehensive/Commercial General Liability insurance shall, by endorsement, be reserved as Project specific coverage and apply to this Project separately.


•	The obligations described in Landlord General Conditions shall survive the termination of the Contract.