10-Q

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

FORM 10-Q

ý Quarterly Report Pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934

For the quarterly period ended September 30, 2014

OR

¨ Transition Report Pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934 for the transition period from             to

Commission File Number: 1-33146

KBR, Inc.

(Exact name of registrant as specified in its charter)

Delaware	20-4536774
(State of incorporation)	(I.R.S. Employer Identification No.)
601 Jefferson Street, Suite 3400, Houston, Texas	77002
(Address of principal executive offices)	(Zip Code)

(713) 753-3011

(Registrant's telephone number including area code)

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.     Yes  ý    No  ¨

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files).     Yes  ý    No  ¨

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act.

Large accelerated filer	ý	Accelerated filer	¨
Non-accelerated filer	¨ (Do not check if a smaller reporting company)	Smaller reporting company	¨

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).     Yes  ¨    No  ý

As of October 16, 2014, there were 145,078,983 shares of KBR, Inc. common stock, $0.001 par value per share, outstanding.

TABLE OF CONTENTS

	Page
PART I. FINANCIAL INFORMATION
Item 1. Financial Information	4
Condensed Consolidated Statements of Income (Loss)	4
Condensed Consolidated Statements of Comprehensive Income (Loss)	5
Condensed Consolidated Balance Sheets	6
Condensed Consolidated Statements of Cash Flows	7
Notes to Condensed Consolidated Financial Statements	9
Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations	37
Item 3. Quantitative and Qualitative Disclosures About Market Risk	53
Item 4. Controls and Procedures	54
PART II. OTHER INFORMATION
Item 1. Legal Proceedings	56
Item 1A. Risk Factors	56
Item 2. Unregistered Sales of Equity Securities and Use of Proceeds	57
Item 3. Defaults Upon Senior Securities	57
Item 4. Mine Safety Disclosures	57
Item 5. Other Information	57
Item 6. Exhibits	58
SIGNATURES	59

2

Forward-Looking and Cautionary Statements

This report contains certain statements that are, or may be deemed to be, “forward-looking statements” within the meaning of Section 27A of the Securities Act of 1933, as amended, and Section 21E of the Securities Exchange Act of 1934, as amended. The Private Securities Litigation Reform Act of 1995 provides safe harbor provisions for forward-looking information. Some of the statements contained in this quarterly report are forward-looking statements. All statements other than statements of historical fact are, or may be deemed to be, forward-looking statements. The words “believe,” “may,” “estimate,” “continue,” “anticipate,” “intend,” “plan,” “expect” and similar expressions are intended to identify forward-looking statements. Forward-looking statements include information concerning our possible or assumed future financial performance and results of operations.

We have based these statements on our assumptions and analyses in light of our experience and perception of historical trends, current conditions, expected future developments and other factors we believe are appropriate in the circumstances. Forward-looking statements by their nature involve substantial risks and uncertainties that could significantly affect expected results, and actual future results could differ materially from those described in such statements. While it is not possible to identify all factors, factors that could cause actual future results to differ materially include the risks and uncertainties disclosed in our 2013 Annual Report on Form 10-K/A contained in Part I under "Risk Factors."

Many of these factors are beyond our ability to control or predict. Any of these factors, or a combination of these factors, could materially and adversely affect our future financial condition or results of operations and the ultimate accuracy of the forward-looking statements. These forward-looking statements are not guarantees of our future performance, and our actual results and future developments may differ materially and adversely from those projected in the forward-looking statements. We caution against putting undue reliance on forward-looking statements or projecting any future results based on such statements or on present or prior earnings levels. In addition, each forward-looking statement speaks only as of the date of the particular statement, and we undertake no obligation to publicly update or revise any forward-looking statement.

3

PART I. FINANCIAL INFORMATION

Item 1. Financial Statements

KBR, Inc.

Condensed Consolidated Statements of Income (Loss)

(In millions, except for per share data)

(Unaudited)

	Three Months Ended						Nine Months Ended
	September 30,						September 30,
	2014			2013			2014			2013
				As Restated						As Restated
Revenues	$	1,657		$	1,755		$	4,949		$	5,534
Cost of revenues	(1,627		)	(1,641		)	(4,852		)	(5,124		)
Gross profit	30			114			97			410
Equity in earnings of unconsolidated affiliates	38			31			118			107
General and administrative expenses	(58		)	(66		)	(178		)	(181		)
Gain (loss) on disposition of assets	—			—			8			(1		)
Operating income	10			79			45			335
Interest income (expense), net	3			(1		)	(1		)	(3		)
Foreign currency gains (losses)	7			(2		)	(4		)	(2		)
Other non-operating income (expenses)	24			(1		)	23			(2		)
Income before income taxes and noncontrolling interests	44			75			63			328
Benefit (provision) for income taxes	1			(60		)	(30		)	(105		)
Net income	45			15			33			223
Net income attributable to noncontrolling interests	(15		)	(62		)	(54		)	(92		)
Net income (loss) attributable to KBR	$	30		$	(47	)	$	(21	)	$	131
Net income (loss) attributable to KBR per share:
Basic	$	0.21		$	(0.32	)	$	(0.14	)	$	0.88
Diluted	$	0.21		$	(0.32	)	$	(0.14	)	$	0.88
Basic weighted average common shares outstanding	145			148			145			148
Diluted weighted average common shares outstanding	145			148			145			149
Cash dividends declared per share	$	0.08		$	0.08		$	0.24		$	0.16

See accompanying notes to condensed consolidated financial statements.

4

KBR, Inc.

Condensed Consolidated Statements of Comprehensive Income (Loss)

(In millions)

(Unaudited)

	Three Months Ended						Nine Months Ended
	September 30,						September 30,
	2014			2013			2014			2013
				As Restated						As Restated
Net income	$	45		$	15		$	33		$	223
Other comprehensive income (loss), net of tax:
Cumulative translation adjustments (“CTA”):
Cumulative translation adjustments, net of tax	(49		)	16			(27		)	(36		)
Reclassification adjustment for CTA included in net income	—			—			1			1
Net cumulative translation adjustment, net of taxes	(49		)	16			(26		)	(35		)
Pension liability adjustments, net of tax:
Pension liability adjustments, net of tax	—			—			—			—
Reclassification adjustment for pension liability gains included in net income	8			4			25			20
Net pension liability adjustments, net of taxes	8			4			25			20
Unrealized (losses) on derivatives:
Unrealized holding (losses) on derivatives, net of tax	—			—			(1		)	—
Reclassification adjustment for losses included in net income	(1		)	—			(1		)	—
Net unrealized loss on derivatives, net of taxes	(1		)	—			(2		)	—
Other comprehensive income (loss), net of tax	(42		)	20			(3		)	(15		)
Comprehensive income, net of tax	3			35			30			208
Less: Comprehensive income attributable to noncontrolling interests	(16		)	(64		)	(55		)	(99		)
Comprehensive income (loss) attributable to KBR	$	(13	)	$	(29	)	$	(25	)	$	109

See accompanying notes to condensed consolidated financial statements.

5

KBR, Inc.

Condensed Consolidated Balance Sheets

(In millions, except share data)

	September 30,			December 31,
	2014			2013
	(Unaudited)
Assets
Current assets:
Cash and cash equivalents	$	1,048		$	1,106
Accounts receivable, net of allowance for doubtful accounts of $21 and $18	964			1,056
Costs and estimated earnings in excess of billings on uncompleted contracts ("CIE")	509			399
Deferred income taxes	151			168
Other current assets	151			196
Total current assets	2,823			2,925
Property, plant, and equipment, net of accumulated depreciation of $426 and $397 (including net PPE of $61 and $67 owned by a variable interest entity)	410			415
Goodwill	771			772
Intangible assets, net of accumulated amortization of $120 and $112	76			85
Equity in and advances to unconsolidated affiliates	149			156
Deferred income taxes	367			344
Claims and accounts receivable	598			628
Other assets	192			113
Total assets	$	5,386		$	5,438
Liabilities and Shareholders’ Equity
Current liabilities:
Accounts payable	$	698		$	747
Payable to former parent	81			105
Billings in excess of costs and estimated earnings on uncompleted contracts ("BIE")	456			401
Accrued salaries, wages and benefits	213			235
Nonrecourse project debt	10			10
Other current liabilities	438			409
Total current liabilities	1,896			1,907
Pension obligations	423			477
Employee compensation and benefits	121			114
Income tax payable	118			70
Deferred income taxes	91			86
Nonrecourse project debt	70			78
Deferred income from unconsolidated affiliates	102			—
Other liabilities	248			267
Total liabilities	3,069			2,999
KBR shareholders’ equity:
Preferred stock, $0.001 par value, 50,000,000 shares authorized, 0 shares issued and outstanding	—			—
Common stock, $0.001 par value, 300,000,000 shares authorized, 174,459,008 and 173,924,509 shares issued, and 145,078,797 and 148,195,208 shares outstanding	—			—
Paid-in capital in excess of par ("PIC")	2,085			2,065
Accumulated other comprehensive loss ("AOCL")	(744		)	(740		)
Retained earnings	1,692			1,748
Treasury stock, 29,380,211 shares and 25,729,301 shares, at cost	(708		)	(610		)
Total KBR shareholders’ equity	2,325			2,463
Noncontrolling interests ("NCI")	(8		)	(24		)
Total shareholders’ equity	2,317			2,439
Total liabilities and shareholders’ equity	$	5,386		$	5,438

See accompanying notes to condensed consolidated financial statements.

6

KBR, Inc. Condensed Consolidated Statements of Cash Flows (In millions) (Unaudited)
	Nine Months Ended September 30,
	2014			2013
				As Restated
Cash flows from operating activities:
Net income	$	33		$	223
Adjustments to reconcile net income to net cash provided by operating activities:
Depreciation and amortization	55			49
Equity in earnings of unconsolidated affiliates	(118		)	(107		)
Deferred income tax (benefit) expense	(2		)	61
Gain on negotiated settlement with former parent	(24		)	—
Other	25			18
Changes in operating assets and liabilities:
Accounts receivable, net of allowance for doubtful accounts	66			124
Costs and estimated earnings in excess of billings on uncompleted contracts	(109		)	(41		)
Accounts payable	(43		)	(64		)
Billings in excess of costs and estimated earnings on uncompleted contracts	53			(101		)
Accrued salaries, wages and benefits	(16		)	(14		)
Reserve for loss on uncompleted contracts	13			30
Receipts of advances from unconsolidated affiliates, net	14			12
Distributions of earnings from unconsolidated affiliates	212			151
Payment on performance bonds for EPC 1 project in Mexico	—			(108		)
Income taxes payable	22			(168		)
Pension funding	(37		)	(26		)
Other assets and liabilities	34			42
Total cash flows provided by operating activities	178			81
Cash flows from investing activities:
Purchases of property, plant and equipment	(46		)	(57		)
Proceeds from sale of assets and investments	9			7
Total cash flows used in investing activities	$	(37	)	$	(50	)

7

KBR, Inc. Condensed Consolidated Statements of Cash Flows (In millions) (Unaudited)
	Nine Months Ended September 30,
	2014			2013
				As Restated
Cash flows from financing activities:
Payments to reacquire common stock	$	(102	)	$	(7	)
Distributions to noncontrolling interests, net of investments	(39		)	(49		)
Payments of dividends to shareholders	(35		)	(24		)
Net proceeds from issuance of common stock	4			5
Payments on short-term and long-term borrowings	(7		)	(9		)
Other	1			1
Total cash flows used in financing activities	(178		)	(83		)
Effect of exchange rate changes on cash	(21		)	(42		)
Decrease in cash and equivalents	(58		)	(94		)
Cash and equivalents at beginning of period	1,106			1,053
Cash and equivalents at end of period	$	1,048		$	959
Supplemental disclosure of cash flows information:
Cash paid for interest	$	9		$	9
Cash paid for income taxes (net of refunds)	$	13		$	107
Noncash operating activities
Other assets change for Barracuda arbitration (Note 13)	$	—		$	(219	)
Other liabilities change for Barracuda arbitration (Note 13)	$	—		$	219
Noncash financing activities
Dividends declared	$	12		$	12

See accompanying notes to condensed consolidated financial statements.

8

KBR, Inc.

Notes to Condensed Consolidated Financial Statements

(Unaudited)

Note 1. Description of Company and Significant Accounting Policies

KBR, Inc., a Delaware corporation, was formed on March 21, 2006 and is headquartered in Houston, Texas. KBR, Inc. and its wholly owned and majority-owned subsidiaries (collectively referred to herein as "KBR", the "Company", "we", "us" or "our") is a global engineering, procurement, construction, and services company supporting the energy, hydrocarbons, power, industrial, civil infrastructure, minerals, government services and commercial markets. Our capabilities include engineering, procurement, construction and construction management, technology licensing, operations and maintenance and other support services for a diverse, global customer base, including international and national oil and gas companies, independent refiners, petrochemical producers, fertilizer producers, regulated utilities, manufacturers, power and mining companies and domestic and foreign governments.

Strategic Review

Following the June 2014 appointment of Mr. Stuart Bradie, our CEO, we announced plans to undertake a global strategic review of our business. We are currently performing this review with a view to enhancing shareholder value.  At the conclusion of the strategic review, we expect to make recommendations and seek approval from the Board of Directors as to a proposed course of action. We are targeting substantial completion of this review in the fourth quarter of 2014. It is possible that the outcome of our strategic review could result in the restructuring of our business and a reorganization of our reportable business segments. It is possible that as a result of decisions reached as part of the strategic review, we may have a different perspective on our reporting units and the forecasts of cash flow used in estimating the fair value of our reporting units as part of our annual testing of goodwill and other intangibles for impairment. These changes could impact the outcome of our annual goodwill impairment analysis and may result in other restructuring charges.

Principles of Consolidation

Our condensed consolidated financial statements have been prepared in accordance with accounting principles generally accepted in the United States ("U.S. GAAP") and include the accounts of KBR and our wholly owned and majority-owned, controlled subsidiaries and variable interest entities of which we are the primary beneficiary. We account for investments over which we have significant influence but not a controlling financial interest using the equity method of accounting. See Note 7 to our condensed consolidated financial statements for further discussion on our equity investments and variable interest entities. The cost method is used when we do not have the ability to exert significant influence. All material intercompany balances and transactions are eliminated in consolidation. For the nine months ended September 30, 2014, we recorded $8 million for an error originating in 2013 related to the gain from receipts of insurance proceeds. The net effect of the correction was a decrease in 2014 net loss of $8 million.

Certain prior year amounts have been reclassified to conform to the current year presentation on the condensed consolidated statement of income, condensed consolidated balance sheets and the condensed consolidated statements of cash flows. Effective December 31, 2013, we reclassified equity in earnings of unconsolidated affiliates from revenues to a separate component of operating income on our condensed consolidated statement of income. We reclassified the three months and nine months ended September 30, 2013 amounts to conform to our revised presentation as a component of operating income but not a component of revenues.

We have evaluated all events and transactions occurring after the balance sheet date but before the financial statements were issued and have made the appropriate adjustments and included the appropriate disclosures.

Restatement of Previously Reported Condensed Consolidated Financial Statements

As indicated in our 2013 Annual Report on Form 10-K/A, we have restated our Condensed Consolidated Statements of Income, Condensed Consolidated Statements of Comprehensive Income and Condensed Consolidated Statements of Cash Flows and the related notes for the three and nine months ended September 30, 2013. We determined the restatement was necessary due to the materiality of the $89 million of additional estimated costs to complete our Canadian pipe fabrication and module assembly contracts within our Services business segment which we identified subsequent to filing our Form 10-K on February 27, 2014 and which we corrected in our Form 10-K/A filed on May 30, 2014.

9

The restatement had the following impact on the condensed consolidated statements of income for the three and nine months ended September 30, 2013:

• a reduction in "revenues" of $25 million consisting of a $28 million decrease related to the error on the contracts within our Services business segment, a $4 million increase related to an error on a long-term construction project in our Gas Monetization business segment and a $1 million decrease related to the correction of several immaterial errors;

• an increase in "cost of revenues" of $62 million due to the recognition of a $61 million reserve for losses on uncompleted contracts related to the error on the contracts within our Services business segment and $1 million related to other immaterial corrections; and

• a $15 million tax benefit consisting of a $9 million tax benefit related to the error in our Services business segment and a $6 million tax benefit representing the tax effect of the correction of several immaterial errors.

Use of Estimates

The preparation of our condensed consolidated financial statements in conformity with U.S. GAAP requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosures of contingent assets and liabilities and the reported amounts of revenues and expenses during the reporting period, including:

• project revenues, costs and profits on engineering, construction, pipe fabrication and module assembly, and government services contracts, including recognition of estimated losses on uncompleted contracts,

• uncollectible receivables, claims to and from customers, recoveries of costs from subcontractors, vendors and others,

• provisions for income taxes, recoverability of deferred tax assets and valuation of uncertain tax positions,

• recoverability of goodwill, other intangibles and long-lived assets and related estimated lives,

• recoverability of equity method and cost method investments,

• valuation of pension obligations,

• accruals for estimated liabilities and litigation outcomes,

• consolidation of variable interest entities, and

• valuation of stock-based compensation.

In accordance with normal practice in the construction industry, we include in current assets and current liabilities amounts related to construction contracts realizable and payable over a period in excess of one year. Actual amounts may differ from those included in the accompanying condensed consolidated financial statements, if the underlying estimates and assumptions upon which the financial statements are based change in the future.

Gross Profit

Gross profit represents revenues less the cost of revenues, which includes overhead costs directly attributable to the business segment. See Note 2 to our condensed consolidated financial statements for presentation of our gross profit by reportable segment.

Accounts Receivable

Accounts receivable are recorded at the invoiced amount based on contracted prices. Amounts collected on accounts receivable are included in net cash provided by operating activities in the condensed consolidated statements of cash flows.

We establish an allowance for doubtful accounts based on the assessment of the customers’ willingness and ability to pay. In addition to such allowances, there are often items in dispute or being negotiated that may require us to make an estimate as to the ultimate outcome. Past due receivable balances are written off when our internal collection efforts have been unsuccessful in collecting the amounts due. See Note 4 to our condensed consolidated financial statements for our discussion on accounts receivable.

Retainage, included in accounts receivable, represents amounts withheld from billings by our customers pursuant to provisions in the contracts and may not be paid to us until the completion of specific tasks on the project. Retainage may also be subject to restrictive conditions such as performance guarantees. Our retainage receivable excludes amounts withheld by the United States ("U.S.") government on certain contracts. See Note 11 to our condensed consolidated financial statements for our discussion on U.S. government receivables.

10

Costs and Estimated Earnings in Excess of Billings on Uncompleted Contracts (including Claims) and Advanced Billings and Billings in Excess of Costs and Estimated Earnings on Uncompleted Contracts

Costs and estimated earnings in excess of billings on uncompleted contracts ("CIE") represent the excess of contract costs and profits recognized to date using the percentage-of-completion method over billings to date on certain contracts. Billings in excess of costs and estimated earnings on uncompleted contracts ("BIE") represents the excess of billings to date over the amount of contract costs and profits recognized to date using the percentage-of-completion method on certain contracts. See Note 5 to our condensed consolidated financial statements for our discussion on CIE and BIE.

Unapproved Change Orders and Claims

When estimating the amount of total gross profit or loss on a contract, we sometimes include unapproved change orders and claims to our customers as adjustments to revenues when the criteria under ASC 605-35 is met. We also include estimates of claims to vendors, subcontractors and others as adjustments to total estimated costs. Unapproved change orders and claims are recorded to the extent of the lesser of the amounts management expects to recover or to costs incurred and include no profit until they are finalized or approved.

Goodwill

Effective January 1, 2014, we reorganized four of the five reporting units in the Infrastructure, Government and Power ("IGP") business segment into three geographic-based units. This reorganization allows the IGP business segment to focus its engineering, procurement, construction and defense services to customers on a more local level. We have concluded that each of these geographic-based units will be considered a separate reporting unit for goodwill impairment testing purposes. As a result, we performed an additional impairment test on the three newly reorganized reporting units on January 1, 2014 as required by ASC 350-20, utilizing the same methodology as our annual goodwill impairment test, and no indication of impairment was identified. For more detail on our methodology and assumptions, see "Critical Accounting Policies" in our 2013 Annual Report on Form 10-K/A.

Share-based Compensation

Effective January 1, 2014, we changed our methodology for estimating the expected term of our option awards from the simplified method and now measure subsequent stock option awards using an expected term based on KBR’s historical experience.

Reserve for Estimated Losses on Uncompleted Contracts

Our reserve for estimated losses on uncompleted contracts is included in "other current liabilities" on our condensed consolidated balance sheet. Our total reserve as of September 30, 2014 and December 31, 2013 is $118 million and $109 million, respectively, including $87 million and $97 million, respectively, related to our Canadian pipe fabrication and module assembly projects. Based on current contracts and work authorizations, we anticipate completion of these Canadian pipe fabrication and module assembly projects in 2015. See Note 2 to our condensed consolidated financial statements for additional information on changes in estimates related to our Canadian pipe fabrication and module assembly projects.

Note 2. Business Segment Information

Our business segment information has been prepared in accordance with ASC 280 - Segment Reporting. Certain reporting units meet the definition of operating segments contained in ASC 280 - Segment Reporting, but individually do not meet the quantitative thresholds as a reportable segment, nor do they share a majority of the aggregation criteria with another operating segment. These operating segments are reported on a combined basis as “Other” and include our Ventures and Technical Staffing Resources (formerly a part of Allstates Technical Services) lines of business as well as corporate expenses not included in the operating segments’ results.

Reportable segment performance is evaluated by our Chief Operating Decision Maker ("CODM") using reportable segment gross profit (loss) which is defined as business segment revenues less the cost of revenues, which includes overhead costs directly attributable to the segment, but excludes equity in earnings of unconsolidated affiliates.

11

The following table presents revenues, gross profit (loss), equity in earnings of unconsolidated affiliates and operating income (loss) by reporting segment.

Operations by Reportable Segment

	Three Months Ended						Nine Months Ended
	September 30,						September 30,
Dollars in millions	2014			2013			2014			2013
				As Restated						As Restated
Revenues:
Gas Monetization	$	343		$	537		$	1,105		$	1,725
Hydrocarbons	559			364			1,544			1,050
Infrastructure, Government and Power	342			373			994			1,147
Services	405			465			1,277			1,563
Other	8			16			29			49
Total	$	1,657		$	1,755		$	4,949		$	5,534
Gross profit (loss):
Gas Monetization	$	41		$	136		$	184		$	305
Hydrocarbons	18			40			74			133
Infrastructure, Government and Power	(40		)	17			(80		)	44
Services	2			(73		)	(98		)	(42		)
Other	6			4			16			12
Labor cost absorption not allocated to the business segments - favorable (unfavorable)	3			(10		)	1			(42		)
Total	$	30		$	114		$	97		$	410
Equity in earnings of unconsolidated affiliates:
Gas Monetization	$	23		$	19		$	57		$	46
Hydrocarbons	—			—			—			—
Infrastructure, Government and Power	7			9			40			35
Services	4			1			4			11
Other	4			2			17			15
Total	$	38		$	31		$	118		$	107
Segment operating income (loss):
Gas Monetization	$	64		$	155		$	241		$	351
Hydrocarbons	18			40			74			133
Infrastructure, Government and Power	(33		)	26			(40		)	79
Services	6			(72		)	(94		)	(31		)
Other	10			6			41			26
Labor cost absorption not allocated to the business segments - favorable (unfavorable)	3			(10		)	1			(42		)
Corporate general and administrative expense not allocated to the business segments	(58		)	(66		)	(178		)	(181		)
Total operating income	$	10		$	79		$	45		$	335

Changes in Estimates

There are many factors, including, but not limited to, the availability and costs of labor, materials and equipment, and resources, productivity, and weather, that can affect the accuracy of our cost estimates, and ultimately, our future profitability. In the past, we have realized both lower and higher than expected margins and have incurred losses as a result of unforeseen changes in our project costs. However, historically, our estimates have been reasonably dependable regarding the recognition of revenues and profit on percentage of completion contracts.

12

Our Services business segment recognized revisions in our estimates of losses at completion on our Canadian pipe fabrication and module assembly projects of $80 million during the nine months ended September 30, 2014. All of these projects were in loss positions at September 30, 2014 and December 31, 2013. Our estimates of revenues and costs at completion on these projects have been, and may continue to be, impacted by our performance, the performance of our subcontractors, the Canadian labor market, the nature, complexity and material quantities of modules outlined on drawings submitted by our customers, our contractual arrangements and our ability to accumulate information and negotiate final contract settlements with our customers. We recognize revisions of revenues and costs in the period in which the revisions are known. This may result in the recognition of costs before the recognition of related revenue recovery, if any. Our estimated losses as of September 30, 2014 on these projects represent our best estimate based on current information. Actual results could differ from the estimates we have used to account for these projects as of September 30, 2014.

During the three and nine months ended September 30, 2014, our IGP business segment recognized revisions in estimates of costs at completion of $33 million and $47 million, respectively, on a power project in North America. Additionally, our Hydrocarbons business segment recognized revisions in estimates of costs at completion of $18 million in the three and nine months ended September 30, 2014 on a North American EPC project reflecting higher estimated costs at completion. Both of these projects were in loss positions at September 30, 2014.

We recognized revisions in estimates primarily associated with approved man hours which resulted in a $21 million positive impact on the gross profit of our Gas Monetization business segment. Additionally, our Gas Monetization business segment recognized revisions in estimates resulting from a favorable settlement of claims which had a $33 million net positive impact on gross profit. Both of these revisions to estimates were recognized in the first quarter of 2014.

Significant revisions to contract estimates as a result of client-driven revised project man-hour estimates had a $90 million positive impact during the three months ended September 30, 2013 and a $141 million positive impact during the nine months ended September 30, 2013 on the gross profit of our Gas Monetization business segment.

Note 3. Cash and Cash Equivalents

We consider all highly liquid investments with an original maturity of three months or less to be cash equivalents. Cash and cash equivalents include cash balances held by our wholly-owned subsidiaries as well as cash held by joint ventures that we consolidate. Joint venture cash balances are limited to joint venture activities and are not available for other projects, general cash needs or distribution to us without approval of the board of directors of the respective joint ventures. We expect to use joint venture cash for project costs and distributions of earnings related to joint venture operations. However, some of the earnings distributions may be paid to other KBR entities where the cash can be used for general corporate needs.

The components of our cash and cash equivalents balance are as follows:

	September 30, 2014
Dollars in millions	International (a)		Domestic (b)		Total
Operating cash	$	362	$	215	$	577
Time deposits	348		43		391
Cash held in joint ventures	64		16		80
Total	$	774	$	274	$	1,048

	December 31, 2013
Dollars in millions	International (a)		Domestic (b)		Total
Operating cash	$	197	$	215	$	412
Time deposits	478		140		618
Cash held in joint ventures	67		9		76
Total	$	742	$	364	$	1,106

(a) Includes deposits held in non-U.S. operating accounts considered to be permanently reinvested outside the U.S. and for which no incremental U.S. tax has been provisioned or paid.

(b) Includes U.S. dollar and foreign currency deposits held in operating accounts that constitute onshore cash for tax purposes but may reside either in the U.S. or in a foreign country.

13

Our international cash balances are primarily held in Australia, the United Kingdom ("U.K.") and Canada. We generally do not provide for U.S. federal and state income taxes on the accumulated undistributed earnings of non-U.S. subsidiaries except for certain entities in Mexico and certain other joint ventures, as well as for approximately 50% of our earnings from our operations in Australia since 2012. Taxes are provided as necessary with respect to earnings that are considered not permanently reinvested. We will continue to provide for U.S. federal and state taxes on 50% of the earnings of our Australian operations as we no longer intend to permanently reinvest these amounts. In determining whether earnings would be considered permanently invested, we considered future non-U.S. cash needs such as: 1) our anticipated foreign working capital requirements, including funding of our U.K. pension plan; 2) the expected growth opportunities across all geographical markets; and 3) our plans to invest in strategic growth opportunities that may include acquisitions around the world. For all other non-U.S. subsidiaries, no U.S. taxes are provided because such earnings are intended to be permanently reinvested to finance foreign activities. These accumulated but undistributed foreign earnings could be subject to additional tax if remitted, or deemed remitted, as a dividend. If any portion of the unremitted earnings were ever foreseen to not be permanently reinvested outside the U.S., or if we elect to repatriate a portion of current year foreign earnings, U.S. income tax expense would be required to be recognized and that expense could be material.

Restricted Cash

Restricted cash included in "other current assets" on our condensed consolidated balance sheets was $17 million and $1 million as of September 30, 2014 and December 31, 2013, respectively. This was primarily related to amounts held in foreign banks for which we have restrictions of use for general business purposes.

Note 4. Accounts Receivable

The components of our accounts receivable, net of allowance for doubtful accounts balance are as follows:

	September 30, 2014
Dollars in millions	Trade		Retainage		Total
Gas Monetization	$	126	$	—	$	126
Hydrocarbons	319		21		340
Infrastructure, Government and Power	188		29		217
Services	239		40		279
Other	2		—		2
Total	$	874	$	90	$	964

	December 31, 2013
Dollars in millions	Trade		Retainage		Total
Gas Monetization	$	255	$	—	$	255
Hydrocarbons	284		31		315
Infrastructure, Government and Power	137		15		152
Services	278		54		332
Other	2		—		2
Total	$	956	$	100	$	1,056

In addition, noncurrent retainage receivable included in "other assets" on our condensed consolidated balance sheets was $7 million and $14 million as of September 30, 2014 and December 31, 2013, respectively, primarily related to an EPC contract for a gas fired electric power generation project in the U.S. in 2014 and a power project in North America in 2013, both in our IGP business segment.

14

Note 5. Costs and Estimated Earnings in Excess of Billings on Uncompleted Contracts and Billings in Excess of Costs and Estimated Earnings on Uncompleted Contracts

Our CIE balances by business segment are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Gas Monetization	$	5	$	34
Hydrocarbons	255		146
Infrastructure, Government and Power	100		131
Services	144		83
Other	5		5
Total	$	509	$	399

Our BIE balances by business segment are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Gas Monetization	$	40	$	30
Hydrocarbons	185		139
Infrastructure, Government and Power	211		199
Services	20		33
Other	—		—
Total	$	456	$	401

Unapproved Change Orders and Claims

The amounts of unapproved change orders and claims included in determining the profit or loss on contracts are as follows:

Dollars in millions	2014			2013
Amounts included in estimated project revenues at completion at January 1,	$	115		$	167
Increase in estimated project revenues at completion	81			69
Approved by client	(134		)	(26		)
Amounts included in estimated project revenues at completion at September 30,	$	62		$	210
Amounts recorded in revenues on a percentage-of-completion basis at September 30,	$	53		$	165

In 2014, approved change orders reflect approvals on an air quality project in the U.S. and an EPC contract for a gas fired electric power generation project in U.S. and a construction project in our Services business segment for which the client routinely issues scope changes which are subsequently followed with a change order.

Included in our 2013 estimated project revenues are increases related to the construction project in our Services business segment mentioned above.

The table above excludes unapproved change orders and claims related to our unconsolidated subsidiaries. Our proportionate share of unapproved change orders and claims on a percentage-of-completion basis were $84 million as of September 30, 2014 and $54 million as of September 30, 2013 on a project in our Gas Monetization business segment.

15

Liquidated Damages

Some of our engineering and construction contracts have schedule dates and performance obligations that if not met could subject us to penalties for liquidated damages. These generally relate to specified activities that must be completed by a set contractual date or by achievement of a specified level of output or throughput. Each contract defines the conditions under which a customer may make a claim for liquidated damages. However, in some instances, liquidated damages are not asserted by the customer, but the potential to do so is used in negotiating or settling claims and closing out the contract.

Based upon our evaluation of our performance and other legal analysis, we have not accrued for possible but not probable liquidated damages related to several projects totaling $12 million at September 30, 2014 and $10 million at December 31, 2013 that we could incur based upon completing the projects as currently forecasted.

Advances

We may receive customer advances in the normal course of business, most of which are applied to invoices usually within one to three months. In addition, we hold advances from customers to assist us in financing project activities, including subcontractor costs. As of September 30, 2014 and December 31, 2013, $42 million and $50 million, respectively, of these finance-related advances are included in BIE on our condensed consolidated balance sheets.

Note 6. Claims and Accounts Receivable

The components of our claims and accounts receivable account balance not expected to be collected within the next 12 months are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Hydrocarbons	$	401	$	401
Infrastructure, Government and Power	196		226
Other	1		1
Total	$	598	$	628

Hydrocarbons claims and accounts receivable includes $401 million related to the EPC 1 arbitration award. We expect this legal judgment of $465 million to be recovered from Petróleos Mexicanos ("PEMEX") Exploration and Production ("PEP"), which includes the original confirmation of the 2009 arbitration award and approximately $106 million for 2013 performance bonds recovery and post judgment interest. See Note 12 to our condensed consolidated financial statements for further discussion on our EPC 1 arbitration.

IGP claims and accounts receivable includes $196 million of claims for costs incurred under various U.S. government contracts. See "Other Matters" in Note 11 to our condensed consolidated financial statements for further discussion on our U.S. government matters.

16

Note 7. Equity Method Investments and Variable Interest Entities

We conduct some of our operations through joint ventures which operate through partnership, corporate, undivided interest and other business forms and are principally accounted for using the equity method of accounting. Additionally, the majority of our joint ventures are also variable interest entities which are further described under ASC 810 - Consolidations - Variable Interest Entities.

The following table presents a rollforward of our equity in and advances to unconsolidated affiliates:

Dollars in millions	2014			2013
Balance at January 1,	$	156		$	217
Equity in earnings of unconsolidated affiliates	118			107
Dividends received (a)	(212		)	(151		)
Advances	(14		)	(12		)
Cumulative translation adjustment	(1		)	(7		)
Balance at September 30, before reclassification	47			154
Reclassification of excess distributions (a)	102			—
Balance at September 30,	$	149		$	154

(a) During the third quarter of 2014, we received dividend distributions in excess of the carrying value of our investments by $102 million. We have no obligation to return any portion of the dividends received. We reclassified the excess distribution to “deferred income from unconsolidated affiliates” on our condensed consolidated balance sheets and this amount will be reduced as we recognize our share of future earnings.

Related Party Transactions

We often provide engineering, construction management and other services, as a subcontractor to the joint ventures in which we participate. The amounts included in our revenues represent revenues from services we provide directly to the joint ventures. As of September 30, 2014 and 2013, our revenues included $228 million and $186 million, respectively, primarily related to services we provided to our Ichthys LNG project joint venture.

Amounts included in our condensed consolidated balance sheets related to services we provided to our joint ventures as of September 30, 2014 and December 31, 2013 are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Accounts receivable, net of allowance for doubtful accounts	$	2	$	6
Costs and estimated earnings in excess of billings on uncompleted contracts	$	2	$	2
Billings in excess of costs and estimated earnings on uncompleted contracts	$	23	$	24

Our related party accounts payable for both periods were immaterial.

17

Equity Method Investments

Summarized financial information for all jointly owned operations including variable interest entities that are accounted for using the equity method of accounting is as follows:

Balance Sheets

	September 30,		December 31,
Dollars in millions	2014		2013
Current assets	$	3,968	$	4,114
Noncurrent assets	4,212		4,222
Total assets	$	8,180	$	8,336
Current liabilities	$	3,597	$	3,679
Noncurrent liabilities	4,273		4,400
Total liabilities	$	7,870	$	8,079

Statements of Operations

	Three Months Ended				Nine Months Ended
	September 30,				September 30,
Dollars in millions	2014		2013		2014		2013
Revenues	$	1,728	$	1,400	$	4,336	$	3,548
Operating income	$	175	$	135	$	503	$	434
Net income	$	101	$	81	$	307	$	276

Unconsolidated Variable Interest Entities

The following summarizes the total assets and total liabilities as reflected in our condensed consolidated balance sheets as well as our maximum exposure to losses related to our unconsolidated variable interest entities ("VIEs") in which we have a significant variable interest but are not the primary beneficiary. Generally, our maximum exposure to loss is limited to our equity investment in the joint venture and any amounts payable to us for services we provided to the joint venture, reduced for any unearned revenues on the projects.

	September 30, 2014
Dollars in millions	Total assets		Total liabilities		Maximum exposure to  loss
Aspire Defence project	$	17	$	126	$	17
Ichthys LNG project	$	30	$	37	$	30
U.K. Road projects	$	35	$	12	$	35
EBIC Ammonia project	$	43	$	2	$	27
Fermoy Road project	$	4	$	5	$	4

Dollars in millions	December 31, 2013
	Total assets		Total liabilities
Aspire Defence project	$	20	$	2
Ichthys LNG project	$	1	$	18
U.K. Road projects	$	34	$	8
EBIC Ammonia project	$	47	$	2
Fermoy Road project	$	1	$	2

18

On the Aspire Defence project, in addition to the maximum exposure to loss indicated in the table above, we have exposure to any losses incurred by the construction or operating joint ventures under their respective subcontract arrangements with the project company. Our exposure is, however, limited to our equity participation in these entities. The Ichthys LNG project joint venture executes a project that has a lump sum component; in addition to the maximum exposure to loss indicated in the table above, we have an exposure to losses if the project exceeds the lump sum component to the extent of our ownership percentage in the joint venture. Our maximum exposure to loss on the EBIC Ammonia project reflects our 65% ownership of the development corporation which owns 25% of the company that consolidates the ammonia plant.

Consolidated Variable Interest Entities

We consolidate VIEs if we determine we are the primary beneficiary of the project entity because we control the activities that most significantly impact the economic performance of the entity. The following is a summary of the significant VIEs where we are the primary beneficiary:

Dollars in millions	September 30, 2014
	Total assets		Total liabilities
Gorgon LNG project	$	372	$	399
Escravos Gas-to-Liquids project	$	32	$	52
Fasttrax Limited project	$	90	$	89

Dollars in millions	December 31, 2013
	Total assets		Total liabilities
Gorgon LNG project	$	446	$	476
Escravos Gas-to-Liquids project	$	43	$	72
Fasttrax Limited project	$	96	$	98

Note 8. Nonrecourse Project Debt

Fasttrax Limited, a joint venture in which we indirectly own a 50% equity interest with an unrelated partner, was awarded a concession contract in 2001 with the U.K. Ministry of Defence ("MoD") to provide a Heavy Equipment Transporter Service to the British Army. Under the terms of the arrangement, Fasttrax Limited operates and maintains 91 heavy equipment transporters ("HETs") for a term of 22 years. The purchase of the HETs by the joint venture was financed through two series of bonds secured by the assets of Fasttrax Limited and a bridge loan totaling approximately £84.9 million (approximately $120 million at the exchange rate on the date of the transaction). The secured bonds are an obligation of Fasttrax Limited and are not a debt obligation of KBR as they are nonrecourse to the joint venture partners. Accordingly, in the event of a default on the notes, the lenders may only look to the assets of Fasttrax Limited for repayment. The bridge loan of approximately £12.2 million (approximately $17 million at the exchange rate on the date of the transaction) was replaced when the joint venture partners funded their equity and subordinated debt contributions in 2005.

The secured bonds were issued in two classes consisting of a Class A 3.5% Index Linked Bonds in the amount of £56 million (approximately $79 million at the exchange rate on the date of the transaction) and a Class B 5.9% Fixed Rate Bonds in the amount of £16.7 million (approximately $24 million at the exchange rate on the date of the transaction).  Semi-annual payments on both classes of bonds commenced in March 2005 and will continue through maturity in 2021. The subordinated notes payable to each of the partners initially bear interest at 11.25% increasing to 16% over the term of the notes until maturity in 2025. Semi-annual payments on the subordinated notes commenced in March 2006. For financial reporting purposes, only our partner's portion of the subordinated notes appears in the condensed consolidated financial statements. 

19

Note 9. Pension Plans

The components of net periodic benefit cost related to pension benefits for the three and nine months ended September 30, 2014 and 2013 were as follows:

	Three Months Ended September 30,
	2014						2013
Dollars in millions	United States			Int’l			United States			Int’l
Components of net periodic benefit cost
Service cost	$	—		$	1		$	—		$	1
Interest cost	1			23			1			18
Expected return on plan assets	(1		)	(26		)	(2		)	(19		)
Recognized actuarial loss	1			10			1			7
Net periodic benefit cost	$	1		$	8		$	—		$	7

	Nine Months Ended September 30,
	2014						2013
Dollars in millions	United States			Int’l			United States			Int’l
Components of net periodic benefit cost
Service cost	$	—		$	2		$	—		$	2
Interest cost	2			68			2			59
Expected return on plan assets	(3		)	(78		)	(4		)	(64		)
Recognized actuarial loss	3			29			2			24
Net periodic benefit cost	$	2		$	21		$	—		$	21

For the nine months ended September 30, 2014, we have contributed approximately $35 million of the $46 million we currently expect to contribute to our international plans in 2014, and we have contributed approximately $2 million of the $3 million we currently expect to contribute to our domestic plans in 2014.

Note 10. Income Taxes

Our estimated annual effective tax rate for the years 2014 and 2013 reconciled to the 35% U.S. statutory federal rate is as follows:

	2014		2013
U.S. statutory federal rate	35.0	%	35.0	%
Rate differentials on foreign earnings	(8.5	)%	(6.6	)%
Taxes on unincorporated joint ventures	(10.1	)%	(7.6	)%
Taxes on unconsolidated affiliates	(10.9	)%	(4.6	)%
U.S. taxes provided on foreign earnings	12.1	%	2.2	%
State taxes	0.3	%	0.5	%
Other	4.4	%	3.7	%
Estimated annual effective tax rate	22.3	%	22.6	%

The effective tax rate was approximately (2)% for the three months ended September 30, 2014. The effective tax rate for the three months ended September 30, 2014 was less than our estimated annual effective tax rate shown in the table above because of discrete tax benefits recognized during the quarter primarily related to expiration of statute of limitations in certain tax jurisdictions.

The effective tax rate was approximately 48% for the nine months ended September 30, 2014. The effective tax rate for the nine months ended September 30, 2014 was greater than our estimated annual effective tax rate shown in the table above primarily due to discrete items including the recording of a valuation allowance on the losses recognized on our Canadian pipe

20

fabrication and module assembly projects offset by the benefit of expiration of statute of limitations in certain tax jurisdictions.

For the three months ended September 30, 2013, our effective tax rate reflected in our condensed consolidated statements of income (loss) is not reflective of our estimated annual effective tax rate shown in the table above as a result of unfavorable discrete items including a charge of $38 million as a result of an unfavorable ruling with respect to a tax dispute with our former parent and $13 million due to changes in the U.K. enacted tax rates.

For the nine months ended September 30, 2013, the effective tax rate was approximately 32%. Our effective tax rate for the nine months ended September 30, 2013 was higher than our estimated annual effective rate of 22.6% due to discrete items. In the first nine months of 2013, we recognized discrete net tax expense of approximately $31 million which included a charge of $38 million as a result of an unfavorable ruling with respect to a tax dispute with our former parent and $13 million due to changes in the U.K. enacted tax rates partially offset by benefits related to the recognition of previously unrecognized tax benefits related to tax positions in prior years, primarily as a result of the resolution of transfer pricing issues involving our U.K. subsidiaries.

We generally do not provide for U.S. federal and state income taxes on the accumulated undistributed earnings of non-U.S. subsidiaries except for certain entities in Mexico and certain other joint ventures, and since 2012, for approximately 50% of our earnings from our operations in Australia. See Note 3 to our condensed consolidated financial statements for additional information regarding our accumulated undistributed earnings. Due to historical and forecasted losses for certain state jurisdictions and non-U.S. affiliates, we are not allowed to record a tax benefit for current period net operating losses recognized by these affiliates.

The valuation allowance for deferred tax assets as of September 30, 2014 and December 31, 2013 was $118 million and $83 million, respectively. The net change in the total valuation allowance was an increase of $35 million from December 31, 2013, including an increase of $3 million during the three months ended September 30, 2014. The valuation allowance as of September 30, 2014 and December 31, 2013 was primarily related to Canada, other foreign and state net operating loss carryforwards that, in the judgment of management, are not more-likely-than-not to be realized.

In assessing the realizability of our deferred tax assets, which include net operating loss carryforwards and foreign tax credit carryforwards, management considers whether it is more-likely-than-not that some portion or all of the deferred tax assets will not be realized. The ultimate realization of deferred tax assets is dependent upon the generation of future taxable income during the periods in which those temporary differences become deductible. Management considers the scheduled reversal of deferred tax liabilities (including the impact of available carryback and carryforward periods), projected future taxable income and tax-planning strategies in making this assessment. The amount of the deferred tax asset considered realizable, however, could be reduced in the near term if estimates of future taxable income during the carryforward period are reduced.

The reserve for uncertain tax positions as of September 30, 2014 and December 31, 2013 was $125 million and $68 million, respectively. The net change in the uncertain tax position for both the full year and the quarter was an increase of $57 million from December 31, 2013. The net change in the uncertain tax position was primarily related to the benefit of the expiration of statute of limitations of $5 million offset by a $62 million increase related to a 2009 amended tax return position.

Note 11. U.S. Government Matters

We provide services to various U.S. governmental agencies, which include the U.S. Department of Defense (“DoD”), the Department of State and others. We may have disagreements or experience performance issues on our U.S. government contracts. When performance issues arise under any of these contracts, the government retains the right to pursue various remedies, including challenges to expenditures, suspension of payments, fines and suspensions or debarment from future business with the government.

Our work with the U.S. government in the Iraq war zone has ended. We have been in the process of closeout with these contracts since 2011, and we expect the closeout process to continue through at least 2018. As a result of our work in a war zone from 2002 to 2011, there are multiple claims and disputes pending between us and the government, all of which need to be resolved to close the contracts. The closeout process includes resolving objections raised by the government through a billing dispute process referred to as Form 1s and Memorandums for Record ("MFRs") and resolving results from government audits. We continue to work with the government to resolve these issues and are engaged in efforts to reach mutually acceptable resolution of these outstanding matters. However, for certain of these matters, we have filed claims with the Armed Services Board of Contract Appeals ("ASBCA") or the U.S. Court of Federal Claims ("COFC"). We also have matters related to ongoing litigation or investigations involving U.S. government contracts. We anticipate billing additional labor, vendor resolution and litigation costs as we resolve the open matters. At this time, we cannot determine the timing or net amounts to be collected or paid to close out these contracts.

21

Form 1s

The government has issued Form 1s questioning or objecting to costs we billed to them. We believe the amounts we have invoiced the customer are in compliance with our contract terms; however, we continue to evaluate our ability to recover these amounts from our customer as new information becomes known. A summary of our Form 1s received and amounts associated with our Form 1s is as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Form 1s issued by the government and outstanding (a)	$	229	$	274
Amounts withheld by government (included in the Form 1s amount above) (b)	137		137
Amounts withheld from subcontractors by us	33		50
Claims loss accruals (c)	62		74

(a) Included in the amounts shown is $56 million related to our Private Security matter discussed below in which KBR was granted full recovery of the amounts claimed. The September 30, 2014 balance excludes amounts related to H-29 as we have settled this matter. See discussion below.

(b) Recorded in "claims and accounts receivable" on our condensed consolidated balance sheets. We believe these amounts are probable of collection.

(c) Recorded as a reduction to "claims and accounts receivable" and in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe the likelihood we would incur a loss related to this matter in excess of the loss accruals we have recorded is remote.

Summarized below are some of the details associated with individual Form 1s as part of the total explained above.

Private Security. Starting in February 2007, we received a series of Form 1s from the Defense Contract Audit Agency ("DCAA") informing us of the government's intent to deny reimbursement to us under the LogCAP III contract for amounts related to the use of private security contractors ("PSCs") by KBR and a subcontractor in connection with its work for KBR providing dining facility services in Iraq between 2003 and 2006. The government challenged $56 million in billings. The government had previously paid $11 million and has withheld payments of $45 million, which, as of September 30, 2014, we have recorded as due from the government related to this matter in "claims and accounts receivable" on our condensed consolidated balance sheets.

On June 16, 2014, we received a decision from the ASBCA which agreed with the KBR's position that the LogCAP III contract did not prohibit the use of PSCs to provide force protection to KBR or subcontractor personnel, that there was a need for force protection and that the costs were reasonable. The ASBCA also found that the Army breached its obligation to provide force protection. Accordingly, we believe that we are entitled to reimbursement by the Army for the amounts charged by our subcontractors, even if they incurred costs for PSCs. The Army had 120 days to appeal and on October 14, 2014 gave notice of its intent to appeal. We believe the likelihood that we will incur a loss related to this matter is remote, and therefore we have not accrued any loss provisions related to this matter.

Containers. In June 2005, the DCAA questioned billings on costs associated with providing containerized housing for soldiers and supporting civilian personnel in Iraq. The Defense Contract Management Agency ("DCMA") recommended that payment for the billings be withheld pending receipt of additional explanation or documentation to support the subcontract costs. The Form 1 was issued for $51 million in billings. Of this amount, the government had previously paid $25 million and has withheld payments of $26 million, which as of September 30, 2014, we have recorded in "claims and accounts receivable" on our condensed consolidated balance sheets.

Included in "other liabilities" on our condensed consolidated balance sheets is $31 million of payments withheld from subcontractors related to pay-when-paid contractual terms. Of this amount, $2 million is due from the government and recorded in "claims and accounts receivable" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have withheld from subcontractors and the loss accruals we have recorded is remote.

There are three related actions stemming from the DCMA's action to disallow and withhold funds. First, in April 2008 we filed a counterclaim in arbitration against our LogCAP III subcontractor, First Kuwaiti Trading Company, to recover the amounts we paid to the subcontractor for containerized housing if we should lose the contract dispute with the government over the allowability of the container claims. Second, during the first quarter of 2011 we filed a complaint before the ASBCA to contest

22

the Form 1s and to recover the amounts withheld from us by the government. At the request of the government, that complaint was dismissed without prejudice in January 2013 so that the government could pursue its False Claims Act ("FCA") suit described below. We are free to re-file the complaint in the future. Third, this matter is also the subject of a separate claim filed by the Department of Justice ("DOJ") for alleged violation of the FCA as discussed further below under the heading “Investigations, Qui Tams and Litigation.”

CONCAP III. From February 2009 through September 2010, we received Form 1s from the DCAA disapproving billed costs related to work performed under our CONCAP III contract with the U.S. Navy to provide emergency construction services primarily to government facilities damaged by Hurricanes Katrina and Wilma. The Form 1 was issued for $25 million in billings. The government had previously paid $15 million and has withheld payments of $10 million.

As of September 30, 2014, we have recorded $10 million due from the government related to these matters in "claims and accounts receivable" on our condensed consolidated balance sheets. As of September 30, 2014, we have accrued our estimate of probable loss related to an unfavorable settlement of this matter recorded in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have accrued is remote.

In February 2012, the Contracting Officer rendered a Contracting Officer Final Determination (“COFD”) disallowing $15 million of direct costs. We filed an appeal with the ASBCA in June 2012. Trial was held before the ASBCA in September 2014, and post hearing briefs are due in November 2014. We expect it will take several months before a ruling is issued on this matter. We believe we undertook adequate and reasonable steps to ensure that proper bidding procedures were followed and the amounts billed to the government were reasonable and not in violation of the Federal Acquisition Regulations ("FAR") and that the ASBCA will rule in our favor.

Other. The government has issued Form 1s for other matters questioning $29 million of billed costs. For these matters, the government previously paid $16 million and has withheld payment of $13 million, which we have recorded in "claims and accounts receivable" on our condensed consolidated balance sheets. We have accrued our estimate of probable loss in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have accrued is remote.

We have other matters in dispute with the government either in the COFC or before the ASBCA. These claims represent $12 million in claimed costs primarily associated with the pass-through of subcontractor claims associated with a termination for convenience in Iraq. We have accrued $4 million as our estimate of probable loss in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to these matters in excess of the amounts we have accrued is remote.

Matters Concluded During the Fiscal Year

Tamimi.

Tamimi - Form 1. In 2006, the DCAA questioned the price reasonableness of billed costs related to dining facilities in Iraq. We responded to the DCMA that we believe our costs are reasonable. The prices obtained for these services were from our subcontractor Tamimi. The Form 1 was issued for $68 million in billings. The government had previously paid $25 million and has withheld payments of $43 million.

In April 2012, the COFC ruled that KBR's negotiated price for certain dining facility services was not reasonable and that we were entitled to only $12 million of the amounts withheld from us by the government plus any applicable interest ($2 million). In addition, while this matter was before the court the U.S. government withheld an additional $1 million. As a result of this ruling, we recognized a pre-tax charge of $28 million as a reduction to revenues. We appealed the U.S. COFC ruling and in September 2013, a three judge panel of the Federal Circuit Court of Appeals issued its opinion upholding the ruling. In June 2014, we filed a joint petition for certiorari with the U.S. Supreme Court for this litigation and in a related case involving another subcontractor.

At September 30, 2014, we have recorded $43 million due from the government related to these matters in "claims and accounts receivable" on our condensed consolidated balance sheets and accrued our estimate related to any probable loss in "other liabilities" on our condensed consolidated balance sheets. The Supreme Court denied our petition in October 2014, leaving us with no further legal recourse. At this time, we believe the likelihood we would incur a loss related to this matter in excess of the loss accruals we have recorded is remote.

23

Tamimi - DOJ. In March 2011, the DOJ filed a counterclaim in the COFC alleging KBR employees accepted bribes from Tamimi in exchange for awarding a master agreement for dining facilities services to Tamimi. The April 2012 ruling on the Tamimi matter discussed above dismissed the DOJ claims as lacking merit. On appeal, the DOJ's efforts to overturn the trial court ruling have been denied, and the DOJ's request for Supreme Court review was also denied.

Fly America. In 2007, the DCAA questioned costs related to our compliance with the provisions of the Fly America Act. Subject to certain exceptions, the Fly America Act requires Federal employees and others performing U.S. government-financed contracts to travel by U.S. flag air carriers. There were times when we transported personnel in connection with our services for the U.S. military where we may not have been in compliance with the Fly America Act and its interpretations through the FAR and the Comptroller General. In October 2011, at the request of the DCMA, we submitted an estimate of the impact of our non-compliance with the Fly America Act for 2003 and 2004. In May 2014, the Contracting Officer rendered a COFD disallowing $3 million in billings. We have settled with the government on this matter. The resolution of this matter did not have a material impact on our results of operations for the period presented. We consider this matter concluded.

H-29. In 2011, we received a Form 1 from the DCAA disapproving certain transportation costs associated with replacing employees who were deployed in Iraq and Afghanistan for less than 179 days. No payments have been withheld by the government for this matter.  The DCAA claimed these replacement costs violated the terms of the LogCAP III contract which expressly disallow certain costs associated with the contractor rotation of employees who have deployed less than 179 days including costs for transportation, lodging, meals, orientation and various forms of per diem allowances.  We disagreed with the DCAA’s interpretation and application of the contract terms as it was applied to circumstances outside of our control including war risks, sickness, death, termination for cause or resignation and that such costs should be allowable. We filed a declaratory judgment to have the clause interpreted before the COFC. On July 9, 2014, we reached agreement with the Army on the matter of an interpretation of the clause that essentially confirms KBR's interpretation and rejects that of the DCAA. On July 18, 2014, the ASBCA granted our motion to dismiss the appeal with prejudice. The resolution of this matter did not have a material impact on our results of operations for the periods presented. We consider this matter concluded. There is a parallel qui tam further described under the caption "Chillcott qui tam" below.

Audits

In addition to reviews being performed by the U.S. government through the Form 1 process, the negotiation, administration and settlement of our contracts, consisting primarily of DoD contracts, are subject to audit by the DCAA, which serves in an advisory role to the DCMA. The DCMA is responsible for the administration of our contracts. The scope of these audits include, among other things, the allowability, allocability and reasonableness of incurred costs, provisional approval of annual billing rates, approval of annual overhead rates, compliance with the FAR and Cost Accounting Standards (“CAS”), compliance with certain unique contract clauses and audits of certain aspects of our internal control systems. We attempt to resolve all issues identified in audit reports by working directly with the DCAA and the Administrative Contracting Officers ("ACOs").

As a result of these audits, there are risks that what we have billed as recoverable costs may be assessed by the government to be unallowable. We believe our billings are in compliance with our contract terms. In some cases, we may not reach agreement with the DCAA or the ACOs regarding potentially unallowable costs which may result in our filing of claims in various courts such as the ASBCA or the COFC. We have accrued our estimate of potentially unallowable costs using a combination of specific estimates and our settlement rate experience with the government. As of September 30, 2014, we have accrued $50 million as our estimate of probable loss as a reduction to "claims and accounts receivable" and in "other liabilities" on our condensed consolidated balance sheets. These accrued amounts are associated with years for which we have or do not have audit reports. We have received audit reports for 2004 through 2007 and 2009. We have not yet received completed audit reports for 2008 or 2010 through 2012. Additionally, we have not reached an agreement with the government on definitive incurred cost rates after 2003 except for 2007 and 2009.

We only include amounts in revenues related to disputed and potentially unallowable costs when we determine it is probable that such costs will result in the collection of revenues. We generally do not recognize additional revenues for disputed or potentially unallowable costs for which revenues have been previously reduced until we reach agreement with the DCAA and/or the ACOs that such costs are allowable.

In addition to audits of our incurred costs, the government also reviews our compliance with the CAS and the adequacy and compliance of our CAS disclosure statements. We are working with the government to resolve several outstanding alleged CAS non-compliance issues.

24

Investigations, Qui Tams and Litigation

The following matters relate to ongoing litigation or investigations involving U.S. government contracts.

First Kuwaiti Trading Company arbitration. In April 2008, First Kuwaiti Trading Company ("FKTC" ), one of our LogCAP III subcontractors, filed for arbitration with the American Arbitration Association of all its claims under various LogCAP III subcontracts. FKTC sought damages in the amount of $134 million. After completing hearings on all of FKTC's claims, an arbitration panel awarded $17 million and interest to FKTC for claims involving damages on lost or unreturned vehicles. In addition, we have determined that we owe FKTC $30 million in connection with five other subcontracts. We have an agreement with FKTC that no damages will be paid until our counterclaim is decided, but FKTC filed a motion with the arbitration panel to compel KBR to pay all amounts outstanding. We paid FKTC $15 million in the third quarter of 2014 and will pay $7 million on pay-when-paid terms. Consequently, FKTC withdrew its motion with the arbitration panel.

We believe any damages ultimately awarded to FKTC will be billable under the LogCAP III contract. Accordingly, we have accrued amounts in "accounts payable" and "other current liabilities" on our condensed consolidated balance sheets and related amounts in "claims and accounts receivable" on our condensed consolidated balance sheets for the amounts awarded to FKTC pursuant to the terms of the contract. At this time, we do not believe we face a risk of material loss in excess of the accruals we have recorded. We also have a counterclaim still pending for any funds we should have to return or refund to the government in the container litigation discussed above.

Electrocution litigation. During 2008, a lawsuit was filed against KBR in Pittsburgh, PA, in the Allegheny County Common Pleas Court alleging that the Company was responsible for an electrical incident which resulted in the death of a soldier. This incident occurred at the Radwaniyah Palace Complex near Baghdad, Iraq. It is alleged in the suit that the electrocution incident was caused by improper electrical maintenance or other electrical work. KBR denies that its conduct was the cause of the event and denies legal responsibility. Plaintiffs are claiming unspecified damages for personal injury, death and loss of consortium by the parents. On July 13, 2012, the Court granted our motions to dismiss, concluding that the case is barred by the Political Question Doctrine and preempted by the Combatant Activities Exception to the Federal Tort Claims Act. The plaintiffs appealed to the Third Circuit Court of Appeals. In August 2013, the Third Circuit Court of Appeals issued an opinion reversing the trial court's dismissal and remanding for further discovery and legal rulings. KBR filed its motion for rehearing en banc, which was denied, and we have filed an application for writ of certiorari to the U.S. Supreme Court. Four amicus briefs have been filed in support of KBR's legal arguments. On June 16, 2014, the U.S. Supreme Court issued an order inviting the Solicitor General to file briefs in the electrocution litigation, expressing the views of the United States as to KBR's pending applications for writ of certiorari. We anticipate these briefs will not be filed until the fourth quarter of 2014. At this time, we believe the likelihood we would incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

Burn Pit litigation. From November 2008 through March 2013, KBR was served with over 50 lawsuits in various states alleging exposure to toxic materials resulting from the operation of burn pits in Iraq or Afghanistan in connection with services provided by KBR under the LogCAP III contract. Each lawsuit has multiple named plaintiffs and seeks class certification. The lawsuits primarily allege negligence, willful and wanton conduct, battery, intentional infliction of emotional harm, personal injury and failure to warn of dangerous and toxic exposures which has resulted in alleged illnesses for contractors and soldiers living and working in the bases where the pits were operated. The plaintiffs are claiming unspecified damages. All of the pending cases were removed to Federal Court and have been consolidated for multi-district litigation treatment before the U.S. Federal District Court in Baltimore, Maryland.

In February 2013, the Court dismissed the case against KBR, accepting all of KBR's defense claims including the Political Question Doctrine; the Combatant Activities Exception to the Federal Tort Claims Act; and Derivative Sovereign Immunity. The plaintiffs appealed to the Fourth Circuit Court of Appeals on March 27, 2013. On March 6, 2014, the Fourth Circuit Court vacated the order of dismissal and remanded this multi-district litigation for further action, including a ruling on state tort law and its impact upon the "Contractor on the Battlefield" defenses. KBR has filed a petition for certiorari with the U.S. Supreme Court. Three amicus briefs have been filed in support of KBR's legal arguments. On June 16, 2014, the U.S. Supreme Court issued an order inviting the Solicitor General to file briefs in the burn pit litigation, expressing the views of the United States as to KBR's pending applications for writ of certiorari. We anticipate these briefs will not be filed until the fourth quarter of 2014. At this time we believe the likelihood that we would incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

25

Sodium Dichromate litigation. From December 2008 through September 2009, five cases were filed in various Federal District Courts against KBR by national guardsmen and other military personnel alleging exposure to sodium dichromate at the Qarmat Ali Water Treatment Plant in Iraq in 2003. The majority of the cases were re-filed and consolidated into two cases, with one pending in the U.S. District Court for the Southern District of Texas and one pending in the U.S. District Court for the District of Oregon.  A single plaintiff case was filed on November 30, 2012 in the District of Oregon Eugene Division. Collectively, the suits represent approximately 170 individual plaintiffs all of which are current and former national guardsmen or British soldiers who claim they were exposed to sodium dichromate while providing security services or escorting KBR employees who were working at the water treatment plant, claim that the defendants knew or should have known that the potentially toxic substance existed and posed a health hazard, and claim that the defendants negligently failed to protect the plaintiffs from exposure.  The plaintiffs are claiming unspecified damages. The U.S. Army Corps of Engineers (“USACE”) was contractually obligated to provide a benign site free of war and environmental hazards before KBR's commencement of work on the site. KBR notified the USACE within two days after discovering the potential sodium dichromate issue and took effective measures to remediate the site.  Services provided by KBR to the USACE were under the direction and control of the military and therefore, KBR believes it has adequate defenses to these claims.  KBR also has asserted the Political Question Doctrine and other government contractor defenses. Additionally, studies by the U.S. government and others on the effects of exposure to the sodium dichromate contamination at the water treatment plant have found no long term harm to the soldiers.

Texas Proceedings. On August 16, 2012, the court in the case pending in the U.S. District Court for the Southern District of Texas Court denied KBR's motion to dismiss plaintiffs' claims. On August 29, 2012, the court certified its order for immediate appeal under 28 U.S.C. § 1292(b) to the U.S. Court of Appeals for the Fifth Circuit, and stayed proceedings in the District Court pending the appeal. On November 28, 2012, the Fifth Circuit granted KBR permission to appeal. On November 7, 2013, a three judge panel of the Court returned the case to the trial court, holding the interlocutory appeal was improperly granted. We sought review by the entire court on this opinion which was denied. The trial court has agreed to stay the trial while we seek review by the U.S. Supreme Court. KBR has filed a petition for certiorari with the U.S. Supreme Court. At this time we believe the likelihood that we would incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

Oregon Proceedings. On November 2, 2012 in the Oregon case, a jury in the U.S. District Court for the District of Oregon issued a verdict in favor of the plaintiffs on their claims, and awarded them approximately $10 million in actual damages and $75 million in punitive damages. We filed post-verdict motions asking the court to overrule the verdict or order a new trial. On April 26, 2013, the court ruled for plaintiffs on all issues except one, reducing the total damages to $81 million which consists of $6 million in actual damages and $75 million in punitive damages. Trials for the remaining plaintiffs in Oregon will not take place until the appellate process is concluded. The court issued a final judgment on May 10, 2013, which was consistent with the previous ruling. KBR appealed the ruling. Briefing is complete and oral arguments have not yet been scheduled by the court. Additionally, five amicus curiae briefs have been filed in support of our arguments. Our basis for appeal include the trial court's denial of the Political Question Doctrine, the Combat Activities Exception in the Federal Tort Claims Act, a lack of personal jurisdiction over KBR in Oregon and numerous other legal issues stemming from the court's rulings before and during the trial. We have already filed proceedings to enforce our rights to reimbursement and payment pursuant to the FAR under the Restore Iraqi Oil contract ("RIO contract") with the USACE as referenced below.

In the U.S. Court of Appeals for the Ninth Circuit, we have also filed a motion for summary reversal of the court's decision on personal jurisdiction due to a recently issued Supreme Court decision which supports our position that the Oregon court did not have jurisdiction in the case because KBR did not have contact with the state. The U.S. Court of Appeals for the Ninth Circuit has consolidated the motion with our pending appeal.

At this time we believe the likelihood that we will ultimately incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

COFC/ASBCA Claims. During the period of time since the first litigation was filed against us, we have incurred legal defense costs that we believe are reimbursable under the related government contract. We have billed for these costs and filed claims to recover the associated costs incurred to date. In late 2012 and early 2013, we filed suits against the U.S. government in the COFC for denying indemnity in the sodium dichromate cases, for reimbursement of legal fees pursuant to our contract with the government and for breach of contract by the government for failure to provide a benign site as required by our contract.  The RIO contract required KBR personnel to begin work in Iraq as soon as the invasion began in March 2003. Due to KBR's inability to procure adequate insurance coverage for this work, the Secretary of the Army approved the inclusion of an indemnification provision in the RIO Contract pursuant to Public Law 85-804.

On March 7, 2014, the COFC issued a ruling on the government's motion dismissing KBR's claims on procedural grounds. The decision did not prohibit us from resubmitting the claims to the contracting officer which we did. On April 4, 2014, we submitted a supplemental certified claim to the RIO contracting officer for additional legal fees incurred in defending the sodium

26

dichromate cases. On June 9, 2014, we filed an appeal to the ASBCA due to the contracting officer's failure to issue a final decision on claims totaling approximately $30 million. The USACE filed an answer, denying our claims. We filed a motion for judgment on the pleadings, asking the court to rule in KBR's favor on the 85-804 indemnity clause based on the admissions made by the USACE in its answer. The court has agreed to stay our other claims while we conduct limited discovery on the 85-804 indemnity.

Qui Tams. Of the active qui tams for which we are aware, the government has joined one of them (see DOJ FCA complaint - Iraq Subcontractor below). We believe the likelihood that we would incur a loss in the qui tams the government has not joined is remote and as of September 30, 2014, no amounts have been accrued. Costs incurred in defending the qui tams cannot be billed to the government until those matters are successfully resolved in our favor. If successfully resolved, we can bill 80% of the costs to the government under the controlling provisions of the FAR. As of September 30, 2014, we have incurred $10 million in legal costs to date in defending ourselves in qui tams.

Barko qui tam. Relator Harry Barko was a KBR subcontracts administrator in Iraq for a year in 2004/2005. He filed a qui tam lawsuit in June 2005 in the U.S. District Court for the District of Columbia (D.C.), alleging violations of the FCA by KBR and KBR subcontractors Daoud & Partners and Eamar Combined for General Trading and Contracting. The claim was unsealed in March of 2009. Barko alleges that KBR fraudulently charged the government for the purchase of laundry facilities from Daoud, that KBR paid Daoud for the construction of a substandard man-camp, that Daoud double-billed KBR for labor, that KBR improperly awarded well-drilling subcontracts to Daoud, and that Daoud charged excessive prices for these services and did not satisfactorily complete them. Barko also alleges fraudulent charges arising out of Eamar’s well-drilling services.

The DOJ investigated Barko’s allegations and elected not to intervene. KBR filed a Motion to Dismiss alleging that the complaint was legally insufficient to state a case under the FCA and this motion was denied. KBR filed its Answer to the First Amended Complaint and a Motion for Summary Judgment. On February 3, 2014, Barko filed a Motion to Compel production of privileged investigative files, which KBR opposed. On March 6, 2014, in an unprecedented opinion, the District Court granted the motion and ordered KBR to produce the records, thereafter also denying KBR’s motions to stay the order and for interlocutory appeal. On March 12, 2014, KBR filed its Petition for Mandamus with the D.C. Circuit Court, seeking an order reversing the trial court’s order of production. A hearing on the mandamus was argued on May 7, 2014 and on June 27, 2014, the Circuit Court granted KBR's Petition for Mandamus and vacated the trial court's order of production. On July 28, 2014, Barko appealed the mandamus ruling and on September 2, 2014 the appeal was denied. Barko has indicated that he will file a petition for certiorari with the U.S. Supreme Court. All other scheduled activity, including a ruling on KBR’s Motion for Summary Judgment, had been stayed pending the outcome of the mandamus appeal. Following the loss on appeal with the Circuit Court, Barko asked the District Court to extend the stay of proceedings and on September 15, 2014 that motion was denied. The trial court has ordered briefing as to whether KBR has waived its privilege and briefing was completed on October 20, 2014. We believe the likelihood that we will incur a loss related to this matter is remote, and therefore as of September 30, 2014 we have not accrued any loss provisions related to this matter.

Chillcott qui tam. On September 25, 2014, Chillcott's counsel advised that they would dismiss the suit described below with prejudice subject to resolution of ancillary issues. On October 28, 2014, Chillcott filed to dismiss the suit with prejudice. We consider this matter concluded.

On November 21, 2011, KBR was advised of the partial unsealing of a qui tam suit brought by a former KBR employee, Karen Chillcott, in the U.S. District Court for the Central District of Illinois, Rock Island Division, alleging that KBR committed fraud in billing the government for unallowable mobilization and demobilization costs for LogCAP III and IV personnel. Chillcott alleges that these costs are unallowable under Clause H-29 of the LogCAP III Contract and Clause H-26 of the LogCAP IV Contract (the “Tour of Duty” clauses). The government declined to intervene in this suit. Although this matter is in the early stages, we have been addressing issues surrounding the H-29 clause for several years. We do not believe the complaint raises new factual issues. The case was partially unsealed on September 10, 2013.  The DOJ investigated Chillcott’s allegations and declined to intervene. On June 28, 2013, KBR filed a Motion to Dismiss which was denied on October 25, 2013. On June 10, 2014, KBR notified Chillcott of the interpretation agreement with the Army as described in more detail above in the H-29 Form 1 discussion.

DOJ False Claims Act complaint - Containers. In November 2012, the DOJ filed a complaint in the U.S. District Court for the Central District of Illinois in Rock Island, IL, related to our settlement of delay claims by our subcontractor, FKTC, in connection with FKTC's provision of living trailers for the bed down mission in Iraq in 2003-2004. The DOJ alleges that KBR knew that FKTC had submitted inflated costs; that KBR did not verify the costs; that FKTC had contractually assumed the risk for the costs which KBR submitted to the government; that KBR concealed information about FKTC's costs from the government; that KBR claimed that an adequate price analysis had been done when in fact one had not been done; and that KBR submitted false claims for reimbursement to the government in connection with FKTC's services during the bed down mission. Our contractual dispute with the Army over this settlement has been ongoing since 2005. We believe these sums were properly billed under our contract with the Army and are not prohibited under the LogCAP III contract. We strongly contend that no fraud was committed.

27

On May 6, 2013, KBR filed a motion to dismiss and in March 2014 the motion to dismiss was denied. We filed our answer on May 2, 2014 and on May 23, 2014 the government filed a Motion to Strike certain affirmative defenses. We are contesting that motion and proceeding with discovery. On September 30, 2014, the District Court granted FKTC's motion to dismiss for lack of personal jurisdiction. A scheduling conference has been set for December 5, 2015. At this time, we believe the likelihood that we would incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

DOJ False Claims Act complaint - Iraq Subcontractor. In January 2014, the DOJ filed a complaint in the U.S. District Court for the Central District of Illinois in Rock Island, IL, against KBR and two former KBR subcontractors alleging that three former KBR employees were offered and accepted kickbacks from these subcontractors in exchange for favorable treatment in the award and performance of subcontracts to be awarded during the course of KBR's performance of the LogCAP III contract in Iraq. The complaint alleges that as a result of the kickbacks, we submitted invoices with inflated or unjustified subcontract prices, resulting in alleged violations of the FCA and the Anti-Kickback Act. While the suit is new, the DOJ's investigation dates back to 2004. We self-reported most of the violations and tendered credits to the government as appropriate. On April 22, 2014, we filed our answer and on May 13, 2014 the government filed a Motion to Strike certain affirmative defenses. We are contesting this motion. As of September 30, 2014, we have accrued our best estimate of probable loss related to an unfavorable settlement of this matter recorded in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe the likelihood that we would incur a loss related to this matter in excess of the amounts we have accrued is remote.

Other Matters

Claims. We have filed claims with the government related to payments not yet received for costs incurred under various government contracts. Included in our condensed consolidated balance sheets are claims for costs incurred under various government contracts totaling $216 million at September 30, 2014. These claims relate to disputed costs and/or contracts where our costs have exceeded the government's funded value on the task order. We have $118 million of claims primarily from de-obligated funding on certain task orders that were also subject to Form 1s relating to certain DCAA audit issues discussed above.  We believe such disputed costs will be resolved in our favor at which time the government will be required to obligate funds from appropriations for the year in which resolution occurs. These claims are recorded in "claims and accounts receivable" on our condensed consolidated balance sheets.  Of the remaining claims balance of $98 million, $90 million is recorded in "claims and accounts receivable" and the remaining is recorded in "CIE" on our condensed consolidated balance sheets. The amounts recorded in CIE represent costs for which incremental funding is pending in the normal course of business. The claims outstanding at September 30, 2014 are considered to be probable of collection and have been previously recognized as revenues.

Note 12. Other Commitments, Contingencies and Disputes

Litigation and regulatory matters related to the Company’s restatement of its 2013 annual financial statements

After the Company announced it would be restating its 2013 annual financial statements, three complaints were filed in the United States District Court for the Southern District of Texas against the Company, our former chief executive officer and our current and former chief financial officers. Two of those complaints were voluntarily dismissed by the plaintiffs, and four parties, including the plaintiff in the remaining case, moved to be appointed lead plaintiff. In September 2014, the court appointed Arkansas Public Employees Retirement System and Local 58/NECA Funds as lead plaintiffs and ordered any new cases arising from the same matters to be consolidated together as In re KBR, Inc. Securities Litigation, Master File No. 14-cv01287. Lead plaintiffs filed an amended and consolidated complaint on October 20, 2014, adding our former chief accounting officer as a defendant. The amended complaint seeks class action status on behalf of our shareholders, alleges violations of Sections 10(b) and 20(a) of the Securities Exchange Act of 1934 arising out of the restatement of our 2013 annual financial statements and seeks undisclosed damages. The defendants intend to file a motion to dismiss the consolidated complaint and to vigorously defend against these claims. As this matter is at a very early stage, we are not able at this time to determine the likelihood of loss, if any, arising from this matter.

In addition, a shareholder derivative complaint, Butorin v. Blount et al, was filed on May 27, 2014 in the United States District Court for the Southern District of Texas on behalf of the Company naming certain current and former members of the Company's board of directors as defendants and the Company as a nominal defendant. The complaint alleges that the named directors breached their fiduciary duties by permitting the Company's internal controls to be inadequate. In August 2014, we filed a motion to dismiss the matter based on the mandatory forum selection clause in the Company's bylaws, which requires, among other things, that all shareholder derivative suits be filed in Delaware. The plaintiff filed his opposition on October 6, 2014 to which we replied on October 21, 2014; the motion is currently pending. As this matter is at a very early stage, we are not able at this time to determine the likelihood of loss, if any, arising from this matter.

28

We have also received requests for information from the Securities Exchange Commission ("SEC") regarding the restatement of our 2013 annual financial statements. We have been and intend to continue providing our full cooperation with the SEC.

Foreign Corrupt Practices Act (“FCPA”) Investigations

In February 2009, KBR LLC, entered a guilty plea to violations of the FCPA in the United States District Court, Southern District of Texas, Houston Division, related to the Bonny Island investigation. The plea agreement reached with the DOJ resolved all criminal charges in the DOJ’s investigation and called for the payment of a criminal penalty. In addition, we settled a civil enforcement action by the SEC. We also agreed to a period of probation for a three year period that ended on February 17, 2012, after which the monitor certified that KBR’s current anti-corruption compliance program has been appropriately designed and implemented to ensure future compliance with the FCPA and other applicable anti-corruption laws.

In February 2011, M.W. Kellogg Limited (“MWKL”) reached a settlement with the U.K. Serious Fraud Office (“SFO”) in which the SFO accepted that MWKL was not party to any unlawful conduct and assessed a civil penalty. The settlement terms included a full release of all claims against MWKL, its current and former parent companies, subsidiaries and other related parties including their respective current or former officers, directors and employees with respect to the Bonny Island project.

On March 18, 2013, we received a letter from the African Development Bank Group ("ADBG") stating they are in the process of opening a formal investigation into corruption related to the Bonny Island project discussed above. We have entered into a Negotiated Resolution Agreement with the ADBG that includes a financial penalty equivalent to approximately $6.6 million of which $0.3 million has been paid and the remainder is in process. We have also agreed to a three-year debarment from ADBG-sponsored contracts of three inactive Madeira, Portugal-based companies that KBR and its three joint venture partners used to participate in the Bonny Island project.

PEMEX and PEP Arbitration

In 1997 and 1998, we entered into three contracts with PEP, the project owner, to build offshore platforms, pipelines and related structures in the Bay of Campeche, offshore Mexico. PEP is part of PEMEX, the national oil company of Mexico. The three contracts were known as EPC 1, EPC 22 and EPC 28. All three projects encountered significant schedule delays and increased costs due to problems with design work, late delivery and defects in equipment, increases in scope and other changes. During 2008, we were successful in litigating and collecting on valid international arbitration awards against PEP on the EPC 22 and EPC 28 projects.

EPC 1

U.S. Proceedings. PEP took possession of the offshore facilities of EPC 1 in March 2004 after having achieved oil production but prior to our completion of our scope of work pursuant to the contract. As a result of the ensuing dispute, we filed for arbitration with the International Chamber of Commerce ("ICC") in 2004 claiming recovery of damages of approximately $323 million for the EPC 1 project. PEP subsequently filed counterclaims totaling $157 million. In December 2009, the ICC ruled in our favor, and we were awarded a total of approximately $351 million including legal and administrative recovery fees as well as interest. PEP was awarded approximately $6 million on counterclaims, plus interest on a portion of that sum. In connection with this award, we recognized a gain of $117 million net of tax in 2009.

Our collection efforts have been ongoing and have involved multiple actions. On November 2, 2010, we received a judgment in our favor in the U.S. District Court for the Southern District of New York to recognize the award in the U.S. of approximately $356 million plus Mexican value added tax and interest thereon until paid. PEP initiated an appeal to the U.S. Court of Appeals for the Second Circuit. On February 16, 2012, the Second Circuit issued an order remanding the case to the District Court to consider if the decision of the Collegiate Court in Mexico, described below, would have affected the trial court’s ruling. The District Court Judge held a three day hearing on April 10 -12, 2013 to hear evidence about the Collegiate Court decision, which annulled the arbitration award and about whether we have a full and fair remedy in Mexico.

On August 27, 2013, the District Court entered an order stating it would confirm the award even though it had been annulled in Mexico. On September 25, 2013, the District Court entered the signed final judgment of $465 million to be recovered, which includes the original confirmation of the arbitration award and approximately $106 million for performance bonds discussed below, plus interest. The judgment also requires that each party pay value added tax on the amounts each has been ordered to pay. PEP filed a notice of appeal to the U.S. Court of Appeals for the Second Circuit on October 16, 2013 and posted cash for the judgment pending appeal. The case is now on appeal before the U.S. Court of Appeals. Briefing is now closed and oral argument is scheduled for November 20, 2014.

29

Mexico Proceedings. PEP's attempt to nullify the award in Mexico was rejected by the Mexican trial court in June 2010. PEP then filed an “amparo” action on the basis that its constitutional rights had been violated and this action was denied by the Mexican court in October 2010. PEP subsequently appealed the adverse decision with the Collegiate Court in Mexico on the grounds that the arbitration tribunal did not have jurisdiction and that the award violated the public order of Mexico. Although these arguments were presented in the initial nullification and amparo action, and were rejected in both cases, in September 2011, the Collegiate Court ruled that PEP, by administratively rescinding the contract in 2004, deprived the arbitration panel of jurisdiction thereby nullifying the arbitration award. The Collegiate Court's decision is contrary to the ruling received from the ICC as well as the other Mexican courts which have denied PEP's repeated attempts to nullify the arbitration award. We also believe the Collegiate Court's decision is contrary to Mexican law governing contract arbitration. However, we do not expect the Collegiate Court's decision to affect our ability to ultimately collect the ICC arbitration award in the U.S. due to the posting of cash for the judgment pending appeal and significant assets of PEP in the U.S.

Luxembourg Collection Proceedings. In 2013, we petitioned the Luxembourg court to issue two seizure orders on the assets of PEP and PEMEX that have been served on a number of banks and financial institutions in that country, as we believe these institutions may have PEP and PEMEX assets that are subject to seizure which could be used to satisfy our award. However, under Luxembourg procedure, we will not find out the value of the seized assets until the proceeding is validated. The first seizure order is for the New York award confirmation; the second seizure order is for the performance bonds payment discussed below. PEP and PEMEX contested the first seizure order and the matter was heard on May 27, 2013 where their petition to lift the seizure order was denied. PEP and PEMEX filed an appeal and on December 18, 2013, the Luxembourg Court of Appeals stated it was dissolving the first seizure order against both PEP and PEMEX. This decision is being appealed to the Luxembourg Supreme Court.

Concurrent with our filing of the seizure order, we filed an action in Luxembourg seeking to enforce the ICC award. In March 2013, we received an order from the Luxembourg court recognizing the award. On June 25, 2013, PEMEX and PEP filed an appeal challenging the enforcement order. We are awaiting scheduling of the hearing on the appeal. We cannot begin the validation proceeding until the appeal is concluded.

North American Free Trade Agreement ("NAFTA") Collection Proceedings. We filed arbitration under NAFTA against Mexico and asserted a claim to have our award paid. The parties have selected the arbitrators, a chairman has been named and the first procedural order has been entered.

We will continue to pursue our remedies in the U.S., Luxembourg and other jurisdictions that we determine have assets which can be used to pay the award.

Performance Bonds

In connection with the EPC 1 project, we had approximately $80 million in outstanding performance bonds furnished to PEP when the project was awarded. The bonds were written by a Mexican bond company and backed by a U.S. insurance company which is indemnified by KBR. As a result of the ICC arbitration award in December 2009, the panel determined that KBR had performed on the project, and we believe recovery on the bonds by PEP was precluded by the ICC Award.  PEP filed an action in Mexico in June 2010 against the Mexican bond company to collect the bonds even though the arbitration award determined the limited amounts to be paid to PEP on their counterclaims and offset those claims against the award in favor of KBR.

On June 17, 2013, after multiple proceedings in various Mexican courts and following a demand for payment, we paid $108 million to the Mexican bond company. The $108 million consists of the $80 million in outstanding bonds, plus $26 million in related interest and other expenses and $2 million in legal and banking fees.

On June 21, 2013, we filed a supplemental writ in Luxembourg to cover the amounts paid to the bonding company on the performance bonds. That writ was granted and served on Luxembourg banks. PEP and PEMEX have refused service in Luxembourg and we are currently serving that writ on PEP and PEMEX. Since the decision by the Luxembourg Court of Appeals dissolved the first writ as to PEMEX, we have lifted the second writ as to PEMEX. The second writ remains in effect as to PEP.

On September 25, 2013, the U.S. District Court for the Southern District of New York entered the signed final judgment which included the amount paid on the bonds plus interest. We will pursue reimbursement of the sums paid in the current enforcement action in the U.S. District Court for the Southern District of New York, the courts of Luxembourg, or by our recently filed NAFTA arbitration seeking to recover the bonds as an unlawful expropriation of assets by the government of Mexico.

30

Consistent with our treatment of claims, we have recorded $401 million, net of advances, in "claims and accounts receivable" on the condensed consolidated balance sheets as we believe it is probable we will recover the amounts awarded to us, including interest, expenses and the amounts we paid on the bonds. PEP has sufficient assets in the U.S. and Luxembourg, which we believe we will be able to attach as a result of the recognition of the ICC arbitration award. Although it is possible we could resolve and collect the amounts due from PEP in the next 12 months, we believe the timing of the collection of the award is uncertain; therefore, consistent with our prior practice, as of September 30, 2014, we continue to classify the amount due from PEP, including the amounts paid on the performance bonds as long term.

ENI Holdings, Inc. (the Roberts & Schaefer Company)

In the third quarter of 2014, KBR and ENI Holdings, Inc. ("ENI") reached agreement to settle the case described below. KBR received $0.8 million from the escrow fund and will retain any tax refunds for the pre-closing period. We consider this matter concluded.

On December 21, 2010, we completed the acquisition of 100% of the outstanding common shares of ENI. ENI was the parent to the Roberts & Schaefer Company, a privately held EPC services company acquired by us in 2010. The purchase price was $280 million plus estimated working capital of $17 million which included cash acquired of $8 million. The total net cash paid at closing of $289 million is subject to an escrowed holdback. As of September 30, 2014, the remaining escrowed holdback was $25 million and primarily related to security for indemnification obligations.

KBR withheld the $25 million in escrow due to KBR's claims under the indemnification provisions of the stock purchase agreement. In December 2012, ENI filed a lawsuit in Delaware Chancery Court alleging KBR is wrongfully withholding the escrowed funds. KBR filed a counterclaim for indemnity and fraud under the terms of the stock purchase agreement. In March 2013, ENI filed a motion to dismiss. The Court denied in part ENI's motion to dismiss KBR's counterclaims in their entirety.

Note 13. Transactions with Former Parent

We have now settled the tax disputes described below and have agreed to pay Halliburton $81 million. As a result, during the third quarter of 2014 we recognized a gain on negotiated settlement of $24 million. This settlement amount continues to be reflected in "Payable to former parent" on our condensed consolidated balance sheets. Pursuant to the settlement agreement, we will pay Halliburton five equal installments of $12.4 million over four quarters starting in the fourth quarter of 2014 and ending in the third quarter of 2015, with a final payment to made upon, and in the amount of $19 million, receipt by KBR of a future foreign tax credit or refund from the IRS. All related litigation and disputes have been dismissed by agreement of the parties. We consider this matter concluded.

In connection with our initial public offering in November 2006 and the separation of our business from Halliburton, we entered into various agreements, including, among others, a master separation agreement, transition services agreements and a tax sharing agreement. The tax sharing agreement provides for certain allocations of U.S. income tax liabilities and other agreements between us and Halliburton with respect to tax matters.

During the fourth quarter of 2011, Halliburton provided notice and demanded payment for $256 million that it alleged we owed under the tax sharing agreement for various other tax-related transactions pertaining to periods prior to our separation from Halliburton.

On July 3, 2012, KBR requested an arbitration panel be appointed to resolve certain intercompany issues arising under the master separation agreement before issues in dispute under the tax sharing agreement were submitted to the designated accounting referee as provided for under the terms of the tax sharing agreement.  We believe these intercompany issues were settled and released as a result of our separation from Halliburton in 2007. Halliburton subsequently challenged the arbitration panel's jurisdiction over this dispute in Texas State Court. The Texas State Court denied Halliburton's request and Halliburton filed an appeal which was decided to affirm KBR's position that the demanded payment claimed was barred as explained below.

In May 2013, an arbitration hearing was held on the matters related to the master separation agreement. On June 24, 2013 the arbitration panel ruled that claims brought by Halliburton against KBR under the tax sharing agreement were required to have been brought before an arbitration panel within two years of the date the claim arose or would reasonably have been discovered by the claimant and that the parties were to return to the accounting referee within thirty days for determination of the remaining claims under the tax sharing agreement.  The remaining tax-related issues in dispute were referred to the accounting referee as provided for under the terms of the tax sharing agreement.

31

On October 9, 2013, the accounting referee issued a report stating that KBR owed Halliburton approximately $105 million with each party bearing its own costs related to the matter. As a result, we increased our tax provision by $38 million, reduced paid-in capital by $7 million and recognized a deferred tax asset of $29 million for available foreign tax credits. Halliburton filed a motion requesting the Texas State Court to confirm the accounting referee's decision and KBR responded requesting that the decision be vacated. KBR filed a motion requesting the Texas State Court to confirm the arbitration panel's June 24, 2013 ruling and Halliburton responded requesting that the arbitration panel's ruling be vacated.

Barracuda-Caratinga Project Tax

In June 2000, we entered into a contract with Barracuda & Caratinga Leasing Company B.V. ("BCLC"), the project owner and claimant, to develop the Barracuda and Caratinga crude oilfields, which are located off the coast of Brazil. Petrobras is a contractual representative that controls the project owner. In November 2007, we executed a settlement agreement with the project owner to settle all outstanding project issues except for the bolts arbitration discussed below.

In March 2006, Petrobras notified us they had submitted a claim to arbitration of $220 million plus interest for the cost of monitoring and replacing defective stud bolts and, in addition, all of the costs and expenses of the arbitration including the cost of attorneys’ fees. The arbitration was conducted in New York under the guidelines of the United Nations Commission on International Trade Law. In September 2011, the arbitration panel awarded the claimant approximately $193 million.

In January 2013, Halliburton paid $219 million to the claimant in payment of the award plus interest and the matter is considered concluded. We believe the arbitration award to Petrobras is deductible by KBR for tax purposes and the indemnification payment will be treated by KBR for tax purposes as a contribution to capital and accordingly is not taxable. In 2011 and 2012, we recorded discrete tax benefits of $71 million and $8 million, respectively. We have reviewed this matter in light of the direct payment by Halliburton to BCLC and its public announcement that they have recorded a tax benefit related to this transaction. Based on advice from outside legal counsel, we have determined that it is more likely than not that we are the proper taxpayer to recognize this benefit although the underlying uncertainties with respect to the tax treatment of the transaction may ultimately lead the Internal Revenue Service to alternate conclusions.

32

Note 14. Shareholders’ Equity

The following tables summarize our activity in shareholders’ equity:

Dollars in millions	Total			PIC			Retained Earnings			Treasury Stock			AOCL			NCI
Balance at December 31, 2013	$	2,439		$	2,065		$	1,748		$	(610	)	$	(740	)	$	(24	)
Share-based compensation	16			16			—			—			—			—
Common stock issued upon exercise of stock options	4			4			—			—			—			—
Dividends declared to shareholders	(35		)	—			(35		)	—			—			—
Repurchases of common stock	(102		)	—			—			(102		)	—			—
Issuance of ESPP shares	4			—			—			4			—			—
Investments by noncontrolling interests	10			—			—			—			—			10
Distributions to noncontrolling interests	(49		)	—			—			—			—			(49		)
Net income (loss)	33			—			(21		)	—			—			54
Other comprehensive income (loss), net of tax	(3		)	—			—			—			(4		)	1
Balance at September 30, 2014	$	2,317		$	2,085		$	1,692		$	(708	)	$	(744	)	$	(8	)
Dollars in millions	Total			PIC			Retained Earnings			Treasury Stock			AOCL			NCI
Balance at December 31, 2012	$	2,511		$	2,049		$	1,709		$	(606	)	$	(610	)	$	(31	)
Share-based compensation	13			13			—			—			—			—
Common stock issued upon exercise of stock options	5			5			—			—			—			—
Adjustment pursuant to Accounting Referee's report on tax sharing agreement	(7		)	(7		)	—			—			—			—
Dividends declared to shareholders	(24		)	—			(24		)	—			—			—
Repurchases of common stock	(7		)	—			—			(7		)	—			—
Issuance of ESPP shares	4			1			—			3			—			—
Investments by noncontrolling interests	9			—			—			—			—			9
Distributions to noncontrolling interests	(58		)	—			—			—			—			(58		)
Change in NCI due to consolidation of previously unconsolidated JV and other transactions	2			—			—			—			—			2
Net income	223			—			131			—			—			92
Other comprehensive income (loss), net of tax	(8		)	—			—			—			(15		)	7
Balance at September 30, 2013	$	2,663		$	2,061		$	1,816		$	(610	)	$	(625	)	$	21

Accumulated other comprehensive loss, net of tax

	September 30,
Dollars in millions	2014			2013
Accumulated CTA, net of tax	$	(158	)	$	(123	)
Accumulated pension liability adjustments, net of tax	(583		)	(501		)
Accumulated unrealized losses on derivatives, net of tax	(3		)	(1		)
Total accumulated other comprehensive loss	$	(744	)	$	(625	)

33

Changes in accumulated other comprehensive loss, net of tax, by component

Dollars in millions	Accumulated CTA			Accumulated pension liability adjustments			Accumulated unrealized losses on derivatives			Total
Balance at December 31, 2013	$	(131	)	$	(608	)	$	(1	)	$	(740	)
Other comprehensive income (loss) adjustments before reclassifications	(28		)	—			(1		)	(29		)
Amounts reclassified from accumulated other comprehensive income (loss)	1			25			(1		)	25
Balance at September 30, 2014	$	(158	)	$	(583	)	$	(3	)	$	(744	)

Dollars in millions	Accumulated CTA			Accumulated pension liability adjustments			Accumulated unrealized losses on derivatives			Total
Balance at December 31, 2012	$	(88	)	$	(521	)	$	(1	)	$	(610	)
Other comprehensive income (loss) adjustments before reclassifications	(36		)	—			—			(36		)
Amounts reclassified from accumulated other comprehensive income (loss)	1			20			—			21
Balance at September 30, 2013	$	(123	)	$	(501	)	$	(1	)	$	(625	)

Reclassifications out of accumulated other comprehensive loss, net of tax, by component

	Nine Months Ended September 30,						Affected line item in the Condensed Consolidated Statements of Income
Dollars in millions	2014			2013
Accumulated pension liability adjustments
Amortization of actuarial loss (a)	$	(32	)	$	(26	)	See (a) below
Tax benefit	7			6			Provision for income taxes
Net pension liability adjustment realized	$	(25	)	$	(20	)	Net of tax

(a) This item is included in the computation of net periodic pension cost. See Note 9 to our condensed consolidated financial statements for further discussion.

34

Note 15. Share Repurchases

On February 25, 2014, our Board of Directors authorized a plan to repurchase up to $350 million of our outstanding common shares, which replaces and terminates the August 26, 2011 share repurchase program. The authorization does not obligate the company to acquire any particular number of common shares and may be commenced, suspended or discontinued without prior notice. The newly authorized share repurchase program operates alongside the existing share maintenance program which we may use to repurchase shares vesting as part of employee compensation programs. The share repurchases are intended to be funded through the company’s current and future cash and the authorization does not have an expiration date. The table below presents information on our share repurchase activities under the share repurchase authorization.

	Dollars in Millions				Number of Shares Repurchased
	Three Months Ended		Nine Months Ended		Three Months Ended	Nine Months Ended
	September 30, 2014		September 30, 2014		September 30, 2014	September 30, 2014
Repurchases under the $350 million authorized share repurchase program	$	4	$	85	175,522	3,149,151
Repurchases under the existing share maintenance program	2		17		131,300	661,020
Total	$	6	$	102	306,822	3,810,171

Repurchases under the authorized share repurchase program were made at an average price of $20.78 and $26.89 for the three and nine months ended September 30, 2014, respectively. Repurchases under the existing share maintenance program were made at an average price of $20.84 and $26.31 for the three and nine months ended September 30, 2014, respectively.

Note 16. Income (loss) per Share

Basic income (loss) per share is based upon the weighted average number of common shares outstanding during the period. Dilutive income (loss) per share includes additional common shares that would have been outstanding if potential common shares with a dilutive effect had been issued using the treasury stock method.

A reconciliation of the number of shares used for the basic and diluted income per share calculations is as follows:

	Three Months Ended		Nine Months Ended
	September 30,		September 30,
Millions of shares	2014	2013	2014	2013
Basic weighted average common shares outstanding	145	148	145	148
Stock options and restricted shares	—	—	—	1
Diluted weighted average common shares outstanding	145	148	145	149

For purposes of applying the two-class method in computing earnings per share, net earnings allocated to participating securities for the three months and nine months ended September 30, 2014 was approximately $0.2 million and none, respectively. Net earnings allocated to participating securities for the three and nine months ended September 30, 2013 was none and $0.4 million, respectively. The diluted earnings per share calculation did not include 3.4 million and 2.8 million antidilutive weighted average shares for the three and nine months ended September 30, 2014, respectively. The diluted earnings per share calculation did not include 1.9 million and 1.8 million antidilutive weighted average shares for the three and nine months ended September 30, 2013, respectively.

Note 17. Recent Accounting Pronouncements

On August 27, 2014, the Financial Accounting Standards Board ("FASB") issued Accounting Standards Update ("ASU") No. 2014-15, Presentation of Financial Statements - Going Concern. This ASU provides guidance on management's responsibility to evaluate whether there is substantial doubt about a company's ability to continue as a going concern and about related footnote disclosures. For each reporting period, management will be required to evaluate whether there are conditions or events that raise substantial doubt about a company's ability to continue as a going concern within one year from the date the financial statements are issued. Substantial doubt exists when relevant conditions and events indicate that it is probable that the entity will be unable to meet its obligations as they become due within the time frame specified earlier. This ASU is effective for annual reporting periods beginning after December 15, 2016 and interim periods within those annual periods. The adoption of ASU 2014-15 is not expected to have a material impact on our financial position, results of operations or cash flows.

35

On May 28, 2014, the FASB issued ASU No. 2014-09, Revenue from Contracts with Customers. This ASU supersedes the revenue recognition requirements in Accounting Standards Codification 605 - Revenue Recognition and most industry-specific guidance throughout the Codification. The standard requires that an entity recognizes revenue to depict the transfer of promised goods or services to customers in an amount that reflects the consideration to which the company expects to be entitled in exchange for those goods or services. This ASU is effective on January 1, 2017 and should be applied retrospectively to each prior reporting period presented or retrospectively with the cumulative effect of initially applying the ASU recognized at the date of initial application. We are in the process of assessing the impact of the adoption of ASU 2014-09 on our financial position, results of operations or cash flows. We have not yet selected a transition method nor have we determined the effect of the standard on our ongoing financial reporting.

On January 24, 2014, the FASB issued ASU No. 2014-05, Service Concession Arrangements. A service concession agreement is an arrangement between a public-sector entity and an operating entity under which the operating entity operates the grantor's infrastructure. This ASU specifies that an operating entity should not account for a service concession arrangement within the scope of this ASU as a lease in accordance with ASC 840 - Leases. An operating entity should refer to other ASUs as applicable to account for various aspects of a service concession arrangement. The amendments also specify that the infrastructure used in a service concession agreement should not be recognized as property, plant and equipment of the operating entity. The amendments in this ASU are effective using a modified retrospective approach for annual reporting periods beginning after December 15, 2014 and interim periods within those annual periods. We are in the process of adopting ASU 2014-05 for the next fiscal year beginning January 1, 2015 and the adoption of this standard could have a material impact on our financial position or results of operations.

36

Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

Introduction

The purpose of management’s discussion and analysis (“MD&A”) is to disclose material changes in our financial condition since the most recent fiscal year-end and results of operations during the current fiscal period as compared to the corresponding period of the preceding fiscal year. The MD&A should be read in conjunction with the condensed consolidated financial statements and accompanying notes and our 2013 Annual Report on Form 10-K/A.

Executive Overview

Restatement

As indicated in our 2013 Annual Report on Form 10-K/A, we have restated our Condensed Consolidated Statements of Income, Condensed Consolidated Statements of Comprehensive Income and Condensed Consolidated Statements of Cash Flows and the related notes for the three and nine months ended September 30, 2013. We determined the restatement was necessary primarily due to the materiality of the additional estimated costs to complete seven Canadian pipe fabrication and module assembly contracts within our Services business segment which we identified subsequent to filing our Form 10-K on February 27, 2014 and which we corrected in our Form 10-K/A filed on May 30, 2014.

The restatement had the following impact on the condensed consolidated statements of income for the three and nine months ended September 30, 2013:

• a reduction in "revenues" of $25 million consisting of a $28 million decrease related to the error on the contracts within our Services business segment, a $4 million increase related to an error on a long-term construction project in our Gas Monetization business segment and a $1 million decrease related to the correction of several immaterial errors;

• an increase in "cost of revenues" of $62 million due to the recognition of a $61 million reserve for losses on uncompleted contracts related to the error on the contracts within our Services business segment and $1 million related to other immaterial corrections; and

• a $15 million tax benefit consisting of a $9 million tax benefit related to the error in our Services business segment and a $6 million tax benefit representing the tax effect of the correction of several immaterial errors.

Strategic Review

Following the June 2014 appointment of Mr. Stuart Bradie, our CEO, we announced plans to undertake a global strategic review of our business. We are currently performing this review with a view to enhancing shareholder value.  At the conclusion of the strategic review, we expect to make recommendations and seek approval from the Board of Directors as to a proposed course of action. We are targeting substantial completion of this review in the fourth quarter of 2014. It is possible that the outcome of our strategic review could result in the restructuring of our business and a reorganization of our reportable business segments. It is possible that as a result of decisions reached as part of the strategic review, we may have a different perspective on our reporting units and the forecasts of cash flow used in estimating the fair value of our reporting units as part of our annual testing of goodwill and other intangibles for impairment. These changes could impact the outcome of our annual goodwill impairment analysis and may result in other restructuring charges.

Business Environment

Demand for our services depends primarily on the level of capital expenditures in our market sectors, which is driven generally by global and regional economic growth and more specifically by the demand for energy products. While the recent decline in oil prices may have a near term adverse impact on our business, we see long-term growth in energy projects, including demand for related licensed process technologies, offshore oil and gas production, refining, chemicals, petrochemicals and fertilizers.  Upstream and downstream investment plans are advancing in resource-rich areas such as North America, the Middle East, Russia, Asia, Australia, the North Sea and East and West Africa.  Each of these trends lends to our particular capability to deliver large projects in remote locations and austere environments.

Gas Monetization. Our Gas Monetization business segment designs and constructs liquefied natural gas ("LNG") and gas-to-liquids ("GTL") facilities that allow for the development and transportation of energy resources around the world. We provide our customers with a full range of services from front-end engineering design ("FEED") through engineering, procurement and construction ("EPC"), commissioning and start-up for world-class LNG and GTL projects, along with solutions related to advancing gas processing development, equipment design and innovative construction methods.

37

Gas Monetization is actively pursuing new LNG prospects but is not expecting an EPC award on these prospects until 2015 and beyond. The new projects for LNG liquefaction and GTL facilities tend to be located near large natural gas resources. World LNG demand growth is projected to support a number of new projects and capacity expansions. The current growth in shale gas production in North America has led to a number of major LNG project developments where we are working in early contract phases in the United States Gulf Coast and Western Canada. We also continue to pursue EPC opportunities for new LNG projects in East Africa and Russia as well as capacity expansions at existing LNG facilities in Asia and Australia.

Hydrocarbons. Our Hydrocarbons business segment provides services ranging from pre-feasibility studies and FEED through construction and commissioning of process facilities in a variety of remote and developed locations around the world. We design and construct oil and natural gas production facilities including fixed and floating platforms and floating LNG facilities. In addition, we provide specialty consulting services that include field development studies and planning, structural integrity management and proprietary designs for ship and semi-submersible hulls. We also own and license our technologies and provide basic engineering and design packages for highly efficient differentiated proprietary process technologies related to the oil and gas, refining, chemicals, petrochemical, biofuels, fertilizers, coal gasification and syngas markets.  

The abundant shale gas supplies in North America have also been driving renewed interest in petrochemical project investments utilizing KBR's process technology offerings and EPC project capabilities.  We continue to be engaged in early-stage activities, FEED work, detailed design projects and EPC projects in our traditional downstream and upstream market sectors worldwide and for a floating LNG project in West Africa. We expect the global hydrocarbons markets to continue to be driven by long-term global energy consumption and petrochemical feedstock demand reflecting long-term global GDP growth and energy commodity prices.

Infrastructure, Government & Power. Our Infrastructure, Government & Power ("IGP") business segment designs and executes projects for industrial, commercial and governmental agencies worldwide. These projects range from basic deliverables to complex infrastructure initiatives including aviation, road, rail, maritime, water, wastewater and pipeline projects. Our capabilities include operations, maintenance, logistics and field support, facilities management and border security, and design or build services. Our suite of services includes project management, construction management, training, and visualization software, as well as engineering, construction and project management services across the world.

Industries served by this segment include support for the U.S., United Kingdom ("U.K.") and Australian government operations, as well as diverse infrastructure markets including electric power generation, transportation and water facilities and industrial markets including mining, minerals and other industrial customers. In addition, we continue to believe opportunities for our services are growing with non-U.S. governments.

On January 1, 2014, we reorganized four of the five reporting units in the IGP business segment into three geographic-based units. This reorganization allows the IGP business segment to focus its engineering, procurement, construction and defense services to customers on a more local level.

Services. Our Services business segment delivers direct-hire construction and construction management for stand-alone construction projects in a variety of global markets as well as construction execution support on our U.S. EPC projects. We provide module assembly, fabrication and maintenance services, commissioning/startup and turnaround expertise worldwide to a broad variety of markets including the oil and gas, petrochemicals, mining, power, pulp and paper, industrial, manufacturing and consumer products industries. Our Services business segment also provides global maintenance, on-call construction, turnaround and specialty services at more than 90 locations which have embedded KBR personnel that provide commercial general contractor services for education, food and beverage, manufacturing, health care, hospitality and entertainment, life science and technology and mixed-use building customers. Our Services business segment periodically works on projects with our other business segments.

Other. Our business segment information has been prepared in accordance with ASC 280 - Segment Reporting. Certain of our reporting units meet the definition of operating segments contained in ASC 280 - Segment Reporting, but individually do not meet the quantitative thresholds as a reportable segment, nor do they share a majority of the aggregation criteria with another operating segment. These operating segments are reported on a combined basis as "Other" and include our Ventures and Technical Staffing Resources (formerly a part of Allstates Technical Services) lines of business as well as corporate expenses not included in the operating segments’ results.

Ventures invests capital, together with customers, lenders and other sources, in projects where one or more of KBR’s other business segments has a direct role in technology supply, engineering, construction, construction management or operations and maintenance. Project investments have been made in business sectors including defense equipment and housing, toll roads and petrochemicals. On an ongoing basis, the Company continues to evaluate opportunities for investment in government privatization,

38

infrastructure and hydrocarbon projects where other KBR services are expected to be utilized.

Three Months Ended September 30, 2014 Compared to the Three Months Ended September 30, 2013

Overview of Financial Results

The financial results for the third quarter of 2014 improved from the second quarter of 2014 and the third quarter of 2013 but remain less than what we consider acceptable. Our Gas Monetization segment continued to perform very well on two mega LNG projects, our Hydrocarbons segment recorded strong bookings of new orders during the quarter, and our Services segment's operations were profitable. However, our IGP segment continued to under perform as a result of increased forecast costs to complete a major power generation project and the continued lack of new awards from the U.S. government and clients in the infrastructure and mining industries. Cash flow from operating activities was strong during the quarter driven primarily from dividend distributions from our unconsolidated joint ventures.

As indicated in our Form 10-K/A for the year ended December 31, 2013, one of the Canadian pipe fabrication and module assembly contracts in our Services business segment that is in a loss position is a master services-type agreement that provides our client with the right, but not the obligation, to place new pipe fabrication and module assembly orders until 2017. We have not received any new orders under this agreement in 2014.

The information below is an analysis of our consolidated results for the three months ended September 30, 2014. See Results of Operations by Business Segment below for additional information describing the performance of each of our reportable segments.

Revenues	Three Months Ended September 30,
					2014 vs. 2013
Dollars in millions	2014		2013		$			%
Revenues	$	1,657	$	1,755	$	(98	)	(6	)%

Consolidated revenues decreased in the third quarter of 2014 compared to the same period of the prior year. This decrease was primarily driven by reduced volumes resulting from the completion or near completion of projects in our Gas Monetization and Services business segments and lower overall volumes associated with our U.S. government support and logistics activities in Iraq within our IGP business segment. This decrease was partially offset by higher revenues in our Hydrocarbons business segment related to EPC contracts for ammonia, urea and ethylene projects in North America.

Gross Profit	Three Months Ended September 30,
					2014 vs. 2013
Dollars in millions	2014		2013		$			%
Gross profit	$	30	$	114	$	(84	)	(74	)%

Consolidated gross profit decreased in the third quarter of 2014 compared to the same period of the prior year. This decrease was primarily attributable to a renegotiation of fees and increased cost recoveries which we recognized in the third quarter of 2013 but did not recur in the third quarter of 2014 and reduced volume as we reached peak activity in 2013 on a project in our Gas Monetization business segment. The decrease was also attributable to a charge due to higher estimated costs at completion on a power project in our IGP business segment and on an EPC project in our Hydrocarbons business segment. These decreases were offset by losses in the third quarter of 2013 which did not recur in the third quarter of 2014 related to increases in estimated losses at completion on certain Canadian pipe fabrication and module assembly projects.

39

Equity in Earnings of Unconsolidated Affiliates	Three Months Ended September 30,
					2014 vs. 2013
Dollars in millions	2014		2013		$		%
Equity in earnings of unconsolidated affiliates	$	38	$	31	$	7	23	%

Equity in earnings of unconsolidated affiliates increased in the third quarter of 2014 compared to the same period of the prior year primarily due to increased activity and higher progress on an LNG project in Australia in our Gas Monetization business segment and improved utilization of our MMM joint venture maintenance vessels in Mexico in our Services business segment.

General and Administrative Expenses	Three Months Ended September 30,
							2014 vs. 2013
Dollars in millions	2014			2013			$		%
General and administrative expenses	$	(58	)	$	(66	)	$	8	12	%

General and administrative expenses decreased in the third quarter of 2014 compared to the same period of the prior year primarily due to lower information technology support costs and lower incentive compensation costs. The decrease was also due to reduced overhead costs resulting from headcount reductions and cost savings initiatives implemented at the end of 2013. Our general and administrative expenses for the three months ended September 30, 2014 and 2013 included $13 million and $14 million, respectively, related to our enterprise resource planning ("ERP") project. These amounts include $4 million and $3 million, respectively, of amortization on the completed phase of the project.

Interest Income (Expense), net	Three Months Ended September 30,
						2014 vs. 2013
Dollars in millions	2014		2013			$		%
Interest income (expense), net	$	3	$	(1	)	$	4	400	%

In the third quarter of 2014, we had interest income, net compared to interest expense, net in the same period of the prior year. This increase was primarily attributable to the reversal of interest on amounts payable to our former parent under a tax sharing agreement. See Note 13 to our condensed consolidated financial statements for further discussion related to transactions with our former parent.

Foreign Currency	Three Months Ended September 30,
						2014 vs. 2013
Dollars in millions	2014		2013			$		%
Foreign currency gains (losses)	$	7	$	(2	)	$	9	450	%

In the third quarter of 2014, we had foreign currency gains compared to foreign currency losses in the same period of the prior year. These gains were primarily attributable to the strengthening of the U.S. dollar against the majority of project currencies in the third quarter of 2014 along with favorable performance of our hedges.

Other Non-operating Income (Expenses)	Three Months Ended September 30,
						2014 vs. 2013
Dollars in millions	2014		2013			$		%
Other non-operating income (expenses)	$	24	$	(1	)	$	25	2,500	%

Other non-operating income (expenses) increased in the third quarter of 2014 compared to the same period of the prior year. This increase was primarily attributable to the $24 million gain related to a negotiated settlement with our former parent. See Note 13 to our condensed consolidated financial statements for further discussion related to transactions with our former parent.

40

Provision for Income Taxes	Three Months Ended September 30,
						2014 vs. 2013
Dollars in millions	2014		2013			$			%
Income before provision for income taxes	$	44	$	75		$	(31	)	(41	)%
Benefit (provision) for income taxes	$	1	$	(60	)	$	61		102	%

In the third quarter of 2014, we had a benefit for income taxes compared to a provision for income taxes in the same period of the prior year. The decline in income tax expense was primarily a result of the decline in income before provision for income taxes and recognition of discrete tax items in each period of 2014 and 2013. Our estimated annual effective tax rate for 2014 and 2013 was approximately 22% and 23%, respectively. Tax expense for the three months ending September 30, 2014 included a $5 million benefit from the settlement of a previously unrecognized tax benefit. Tax expense for the three months ended September 30, 2013 included a discrete charge of $38 million as a result of an unfavorable ruling with respect to a tax dispute with our former parent and $13 million due to changes in the U.K. enacted tax rates.

A reconciliation of our effective tax rates for the three months ended September 30, 2014 and September 30, 2013 to the U.S. statutory federal rate is described in Note 10 to our condensed consolidated financial statements. Information regarding permanently reinvested amounts is presented in Note 3 to our condensed consolidated financial statements.

Net Income Attributable to Noncontrolling Interests	Three Months Ended September 30,
							2014 vs. 2013
Dollars in millions	2014			2013			$		%
Net income attributable to noncontrolling interests	$	(15	)	$	(62	)	$	47	76	%

Net income attributable to noncontrolling interests decreased in the third quarter of 2014 compared to the same period of the prior year. This decrease is primarily due to a renegotiation of fees and cost recoveries which were recognized in our Gas Monetization business segment in the third quarter of 2013 but did not recur in the third quarter of 2014.

41

Results of Operations by Business Segment

We analyze the financial results for each of our five business segments, which are consistent with our reportable segments presented in Note 2 to our condensed consolidated financial statements.

For purposes of reviewing the results of operations, gross profit is calculated as business segment revenues less cost of revenues, which includes overhead costs directly attributable to the business segment.

	Three Months Ended September 30,
							2014 vs. 2013
Dollars in millions	2014			2013			$			%
Revenues
Gas Monetization	$	343		$	537		$	(194	)	(36	)%
Hydrocarbons	559			364			195			54	%
Infrastructure, Government and Power	342			373			(31		)	(8	)%
Services	405			465			(60		)	(13	)%
Other	8			16			(8		)	(50	)%
Total	$	1,657		$	1,755		$	(98	)	(6	)%
Gross profit (loss)
Gas Monetization	$	41		$	136		$	(95	)	(70	)%
Hydrocarbons	18			40			(22		)	(55	)%
Infrastructure, Government and Power	(40		)	17			(57		)	(335	)%
Services	2			(73		)	75			103	%
Other	6			4			2			50	%
Labor cost not allocated to the business segments - favorable (unfavorable)	3			(10		)	13			130	%
Total	$	30		$	114		$	(84	)	(74	)%
Equity in earnings of unconsolidated affiliates
Gas Monetization	$	23		$	19		$	4		21	%
Hydrocarbons	—			—			—			—	%
Infrastructure, Government and Power	7			9			(2		)	(22	)%
Services	4			1			3			300	%
Other	4			2			2			100	%
Total	$	38		$	31		$	7		23	%
Gain on disposition of assets	$	—		$	—		$	—		—	%
Amounts not allocated to the business segments
General and administrative expenses	$	(58	)	$	(66	)	$	8		12	%
Total operating income	$	10		$	79		$	(69	)	(87	)%

42

Gas Monetization

Gas Monetization revenues decreased by $194 million, or 36%, to $343 million in the third quarter of 2014 compared to $537 million in the same period of the prior year primarily as a result of reduced volumes on a GTL project in Nigeria and an LNG project in Algeria as these projects were completed or neared completion. There was also a reduction in volume on one of our LNG projects in Australia as we reached peak activity in the same period of the prior year. These decreases were partially offset by increased activity due to continued ramp-up on another LNG project in Australia.

Gas Monetization gross profit decreased by $95 million, or 70%, to $41 million in the third quarter of 2014 compared to $136 million in the same period of the prior year primarily due to $71 million of renegotiated fees and increased cost recoveries recognized on an LNG project in Australia in the third quarter of 2013, which did not recur in the third quarter of 2014. Also contributing to the decline was reduced progress as we reached peak activity in 2013 on this LNG project in Australia as well as higher proposal costs on large LNG pursuits in 2014.

Gas Monetization equity in earnings of unconsolidated affiliates increased by $4 million, or 21%, to $23 million in the third quarter of 2014 compared to $19 million in the same period of the prior year, primarily due to increased activity and higher progress on an LNG project in Australia.

Hydrocarbons

Hydrocarbons revenues increased by $195 million, or 54%, to $559 million in the third quarter of 2014 compared to $364 million in the same period of the prior year. This increase in revenues was primarily driven by progress on EPC contracts for ammonia, urea and ethylene projects in North America and technical services projects in the Middle East and North America.

Hydrocarbons gross profit decreased by $22 million, or 55%, to $18 million in the third quarter of 2014 compared to $40 million in the same period of the prior year. This decrease in gross profit was driven primarily by an $18 million charge related to a welding issue on one EPC project in North America.

Infrastructure, Government and Power

IGP revenues decreased by $31 million, or 8%, to $342 million in the third quarter of 2014 compared to $373 million in the same period of the prior year. This decline was driven by a $66 million reduction in revenues following the March 31, 2014 completion of activities on the LogCAP IV contract supporting the U.S. military and the U.S. Department of State in Iraq and a $30 million reduction in revenues resulting from the impact of additional estimated costs to complete a power project in North America. The decline in revenues was also attributable to a final settlement on a project in Indonesia. In addition, there was reduced activity on projects in the infrastructure and minerals markets affected by the continuing weak market conditions in the Asia Pacific region as well as projects nearing completion in our other markets. These decreases were partially offset by a $29 million award fee settlement and recovery of previously expensed legal fees on one of our IGP Legacy Projects as well as progress on new awards including an EPC contract for a gas fired electric power generation project in the U.S and a U.S. government construction contract in Europe.

IGP gross profit decreased by $57 million, or 335%, to a loss of $40 million in the third quarter of 2014 compared to gross profit of $17 million in the same period of the prior year. The reduction in gross profit was primarily due to a $33 million charge related to an increase in estimated costs to complete and a resulting loss provision on a power project in North America. We also recognized a net $8 million gain on settlements and legal reserves related to our dispute resolution activities. Additionally, there was a $9 million reduction to gross profit resulting from the completion of activities on the LogCAP IV contract discussed above and $4 million of legal fees associated with ongoing disputes.

IGP equity in earnings of unconsolidated affiliates fell modestly compared to the same period of the prior year driven by reduction of volume as we near completion of construction activities on a U.K. MoD project.

Services

Services revenues decreased by $60 million, or 13%, to $405 million in the third quarter of 2014 compared to $465 million in the same period of the prior year. This change was primarily driven by declining construction volume due to the completion or near completion of several construction projects in the U.S., partially offset by increased activity on the Canadian pipe fabrication and module assembly projects.

43

Services gross profit increased by $75 million, or 103%, to a profit of $2 million in the third quarter of 2014 compared to a loss of $73 million in the same period of the prior year. This change was primarily driven by $89 million in losses in the third quarter of 2013 which did not recur in the third quarter of 2014 related to increases in estimated losses at completion on certain Canadian pipe fabrication and module assembly projects.

Services equity in earnings of unconsolidated affiliates increased$3 million in the third quarter of 2014 compared to the same period of the prior year primarily due to improved utilization of our MMM joint venture maintenance vessels in Mexico.

Other

Other revenues decreased by $8 million, or 50%, in the third quarter of 2014 compared to the same period of the prior year, primarily driven by the loss of revenues due to the sale of the external portion of our former Allstates Technical Services business in the fourth quarter of 2013. Gross profit increased by $2 million, or 50%, to $6 million in the third quarter of 2014 compared to $4 million in the same period of the prior year, primarily due to lower overheads as a result of the sale previously mentioned. Other equity in earnings of unconsolidated affiliates was fairly flat compared to the same period of the prior year.

Changes in Estimates

Information relating to our changes in estimates is discussed in Note 2 to our condensed consolidated financial statements.

Labor Cost not Allocated to the Business Segments	Three Months Ended September 30,
						2014 vs. 2013
Dollars in millions	2014		2013			$		%
Labor cost not allocated to the business segments - favorable (unfavorable)	$	3	$	(10	)	$	13	130	%

Labor cost not allocated to the business segments represents costs incurred by our central labor and resource departments net of the amounts charged to the business segments. Labor cost absorption improved primarily due to a combination of increased chargeability and cost reductions.

Nine Months Ended September 30, 2014 Compared to the Nine Months Ended September 30, 2013

Overview of Financial Results

The financial results for the first nine months of 2014 did not meet our expectations largely due to the under-performance of our Services and IGP business segments. Our Gas Monetization and Hydrocarbons business segments continued to benefit from low natural gas costs, which is driving activity in LNG, upstream, downstream and technology related projects. Our Hydrocarbons segment continued to experience a shift in the project mix resulting in an increase in lower margin EPC projects compared to higher margin technical services projects in the prior year. The IGP business segment’s results were impacted by a lack of new awards and a decline in overall volumes in our U.S. government support and logistics and infrastructure and minerals businesses. The IGP business segment results were also impacted by charges relating to legacy commercial disputes where we have decided, in certain cases, to seek commercial resolution rather than rely on recovery through the legal process and from lower margins on one of our North American power projects. The Services business segment’s pipe fabrication and module assembly business in Canada and its U.S. construction business experienced increases in estimated project costs.

    As indicated in our Form 10-K/A for the year ended December 31, 2013, one of the Canadian pipe fabrication and module assembly contracts in our Services business segment that is in a loss position is a master services-type agreement that provides our client with the right, but not the obligation, to place new pipe fabrication and module assembly orders until 2017. We have not received any new orders under this agreement in 2014.

The information below is an analysis of our consolidated results for the nine months ended September 30, 2014. See Results of Operations by Business Segment below for additional information describing the performance of each of our reportable segments.

44

Revenues	Nine Months Ended September 30,
					2014 vs. 2013
Dollars in millions	2014		2013		$			%
Revenues	$	4,949	$	5,534	$	(585	)	(11	)%

Consolidated revenues decreased in the nine months ended September 30, 2014 compared to the same period of the prior year. This decrease was primarily driven by reduced volumes resulting from the completion or near completion of projects in our Gas Monetization and Services business segments and lower overall volumes associated with our U.S. government support and logistics activities in Iraq within our IGP business segment. This decrease was partially offset by higher revenues in our Hydrocarbons business segment related to EPC contracts for ammonia, urea and ethylene projects in North America.

Gross Profit	Nine Months Ended September 30,
					2014 vs. 2013
Dollars in millions	2014		2013		$			%
Gross profit	$	97	$	410	$	(313	)	(76	)%

Consolidated gross profit decreased in the nine months ended September 30, 2014 compared to the same period of the prior year. This decrease was primarily attributable to a renegotiation of fees and increased cost recoveries which we recognized in the third quarter of 2013 but did not recur in the third quarter of 2014 and reduced volume as we reached peak activity in 2013 on a project in our Gas Monetization business segment. The decrease was also attributable to charges due to higher expected costs at completion on a power project in our IGP business segment and on an EPC project in our Hydrocarbons business segment.

Equity in Earnings of Unconsolidated Affiliates	Nine Months Ended September 30,
					2014 vs. 2013
Dollars in millions	2014		2013		$		%
Equity in earnings of unconsolidated affiliates	$	118	$	107	$	11	10	%

Equity in earnings of unconsolidated affiliates increased in the third quarter of 2014 compared to the same period of the prior year. This change was primarily due to increased activity and higher progress on an LNG project in Australia in our Gas Monetization business segment and by an insurance recovery and reduced costs on a joint venture project in our IGP business segment offset by a reduction in volume as we near completion of construction activities on this project.

General and Administrative Expenses	Nine Months Ended September 30,
							2014 vs. 2013
Dollars in millions	2014			2013			$		%
General and administrative expenses	$	(178	)	$	(181	)	$	3	2	%

General and administrative expenses decreased in the nine months ended September 30, 2014 compared to the same period of the prior year. The decrease was primarily due to lower information technology support costs and overall reduced overhead costs resulting from headcount reductions and cost savings initiatives implemented at the end of 2013. The decrease was partially offset by higher ERP project expenses. Our general and administrative expenses for the nine months ended September 30, 2014 and 2013 included $37 million and $31 million, respectively, related to our ERP project. These amounts include $12 million and $3 million, respectively, of amortization on the completed phase of the project.

45

Interest Expense, net of Interest Income	Nine Months Ended September 30,
							2014 vs. 2013
Dollars in millions	2014			2013			$		%
Interest expense, net of interest income	$	(1	)	$	(3	)	$	2	67	%

Interest expense, net of interest income decreased in the nine months ended September 30, 2014 compared to the same period of the prior year. This decrease was primarily attributable to the reversal of interest on amounts payable to our former parent under a tax sharing agreement. See Note 13 to our condensed consolidated financial statements for further discussion related to transactions with our former parent.

Foreign Currency	Nine Months Ended September 30,
							2014 vs. 2013
Dollars in millions	2014			2013			$			%
Foreign currency losses	$	(4	)	$	(2	)	$	(2	)	(100	)%

Foreign currency losses increased in the nine months ended September 30, 2014 compared to the same period of the prior year. This increase was primarily attributable to unfavorable shifts in USD positions on our Gas Monetization business segment projects in the first nine months of 2014. These losses were partially offset by the strengthening of the U.S. dollar against the majority of project currencies in the third quarter of 2014 along with favorable performance of our hedges.

Other Non-operating Income (Expenses)	Nine Months Ended September 30,
						2014 vs. 2013
Dollars in millions	2014		2013			$		%
Other non-operating income (expenses)	$	23	$	(2	)	$	25	1,250	%

Other non-operating income (expenses) increased in the nine months ended September 30, 2014 compared to the same period of the prior year. This increase was primarily attributable to the $24 million gain related to a negotiated settlement with our former parent. See Note 13 to our condensed consolidated financial statements for further discussion related to transactions with our former parent.

Provision for Income Taxes	Nine Months Ended September 30,
							2014 vs. 2013
Dollars in millions	2014			2013			$			%
Income before provision for income taxes	$	63		$	328		$	(265	)	(81	)%
Provision for income taxes	$	(30	)	$	(105	)	$	75		71	%

The decline in income tax expense was primarily a result of the decline in income before provision for income taxes and recognition of discrete tax items in each period of 2014 and 2013. Our estimated annual effective tax rate for 2014 and 2013 was approximately 22% and 23%, respectively. Tax expense for the nine months ending September 30, 2014 included $22 million of discrete charges for an increase in our valuation allowance on losses related to our Canadian pipe fabrication and module assembly projects. Tax expense for the nine months ended September 30, 2013 included discrete charges of $38 million as a result of an unfavorable ruling with respect to a tax dispute with our former parent and $13 million due to changes in the U.K. enacted tax rates. Additionally, 2013 includes a tax benefit of $23 million primarily as a result of the resolution of transfer pricing issues involving our U.K. subsidiaries.

A reconciliation of our effective tax rates for the nine months ended September 30, 2014 and September 30, 2013 to the U.S. statutory federal rate is presented in Note 10 to our condensed consolidated financial statements. Information regarding permanently reinvested amounts is described in Note 3 to our condensed consolidated financial statements.

46

Net Income Attributable to Noncontrolling Interests	Nine Months Ended September 30,
							2014 vs. 2013
Dollars in millions	2014			2013			$		%
Net income attributable to noncontrolling interests	$	(54	)	$	(92	)	$	38	41	%

Net income attributable to noncontrolling interests decreased in the nine months ended September 30, 2014 compared to the same period of the prior year. This decrease is primarily due to a renegotiation of fees and cost recoveries which were recognized in our Gas Monetization business segment in 2013 but did not recur in 2014.

Results of Operations by Business Segment

We analyze the financial results for each of our five business segments, which are consistent with our reportable segments presented in Note 2 to our condensed consolidated financial statements.

For purposes of reviewing the results of operations, gross profit is calculated as business segment revenues less cost of revenues, which includes overhead costs directly attributable to the business segment.

	Nine Months Ended September 30,
							2014 vs. 2013
Dollars in millions	2014			2013			$			%
Revenues
Gas Monetization	$	1,105		$	1,725		$	(620	)	(36	)%
Hydrocarbons	1,544			1,050			494			47	%
Infrastructure, Government and Power	994			1,147			(153		)	(13	)%
Services	1,277			1,563			(286		)	(18	)%
Other	29			49			(20		)	(41	)%
Total	$	4,949		$	5,534		$	(585	)	(11	)%
Gross profit (loss)
Gas Monetization	$	184		$	305		$	(121	)	(40	)%
Hydrocarbons	74			133			(59		)	(44	)%
Infrastructure, Government and Power	(80		)	44			(124		)	(282	)%
Services	(98		)	(42		)	(56		)	(133	)%
Other	16			12			4			33	%
Labor cost not allocated to the business segments - favorable (unfavorable)	1			(42		)	43			102	%
Total	$	97		$	410		$	(313	)	(76	)%
Equity in earnings of unconsolidated affiliates
Gas Monetization	$	57		$	46		$	11		24	%
Hydrocarbons	—			—			—			—	%
Infrastructure, Government and Power	40			35			5			14	%
Services	4			11			(7		)	(64	)%
Other	17			15			2			13	%
Total	$	118		$	107		$	11		10	%
Gain (loss) on disposition of assets	$	8		$	(1	)	$	9		900	%
Amounts not allocated to the business segments
General and administrative expenses	$	(178	)	$	(181	)	$	3		2	%
Total operating income	$	45		$	335		$	(290	)	(87	)%

47

Gas Monetization

Gas Monetization revenues decreased by $620 million, or 36%, to $1.1 billion in the nine months ended September 30, 2014 compared to $1.7 billion in the same period of the prior year primarily as a result of reduced volumes on a GTL project in Nigeria and an LNG project in Algeria as these projects were completed or neared completion. There was also a reduction in volume on one of our LNG projects in Australia, as we reached peak activity in the same period of the prior year.

Gas Monetization gross profit decreased by $121 million, or 40%, to $184 million in the nine months ended September 30, 2014 compared to $305 million in the same period of the prior year primarily due to $71 million of renegotiated fees and increased cost recoveries recognized on an LNG project in Australia in 2013, which did not recur in 2014, as well as higher proposal costs on large LNG pursuits in 2014. Gross profit for the nine months ended September 30, 2014 included a $33 million net favorable settlement of certain claims on an LNG project, while gross profit for the same period of the prior year included costs savings of $30 million on this LNG project.

Gas Monetization equity in earnings of unconsolidated affiliates increased by $11 million, or 24%, to $57 million in the nine months ended September 30, 2014 compared to $46 million in the same period of the prior year, primarily due to increased activity and higher progress on an LNG project in Australia.

Hydrocarbons

Hydrocarbons revenues increased by $494 million, or 47%, to $1.5 billion in the nine months ended September 30, 2014 compared to $1.1 billion in the same period of the prior year. This increase in revenues was primarily driven by progress on EPC contracts for ammonia, urea and ethylene projects in North America and technical services projects in the Middle East and North America.

Hydrocarbons gross profit decreased by $59 million, or 44%, to $74 million in the nine months ended September 30, 2014 compared to $133 million in the same period of the prior year. This decrease in gross profit was driven by the completion of technical services projects in prior periods and higher proposal costs. This decrease was also driven by an $18 million charge related to higher estimated costs to complete and a resulting loss provision on an EPC project in North America.

Infrastructure, Government and Power

IGP revenues decreased by $153 million, or 13%, to $994 million in the nine months ended September 30, 2014 compared to $1.1 billion in the same period of the prior year. This decline was driven by a $195 million reduction in revenues following the March 31, 2014 completion of activities on the LogCAP IV contract supporting the U.S. military and the U.S. Department of State in Iraq. There was also decreased activity on projects in the infrastructure and minerals markets affected by the continuing weak market conditions in the Asia Pacific region as well as large projects nearing completion in our other regions. These decreases were partially offset by increased activity on an air quality control project in the U.S. and new awards including an EPC contract for a gas fired electric power generation project in the U.S. and U.S. government construction and base support contracts in Europe and Africa.

IGP gross profit decreased by $124 million, or 282%, to a loss of $80 million in the nine months ended September 30, 2014 compared to gross profit of $44 million in the same period of the prior year. The reduction in gross profit was primarily due to a $47 million charge related to an increase in estimated costs to complete and a resulting loss provision on a power project in North America. Additionally, there were $30 million in charges related to settlements and legal reserves as we continue to work towards resolution on a number of commercial disputes. The decrease was also driven by the completion or near completion of several projects in the Asia-Pacific region and other markets including a $25 million reduction resulting from the completion of activities on the LogCAP IV contract discussed above.

IGP equity in earnings of unconsolidated affiliates increased by $5 million, or 14%, to $40 million in the nine months ended September 30, 2014 compared to $35 million in the same period of the prior year. This increase was driven primarily by an insurance recovery and reduced costs of $15 million on a joint venture for a U.K. MoD project, offset by a reduction in volume as we near completion of construction activities on this joint venture project.

48

Services

Services revenues decreased by $286 million, or 18%, to $1.3 billion in the nine months ended September 30, 2014 compared to $1.6 billion in the same period of the prior year. This change was primarily driven by declining construction volume due to the completion or near completion of several construction projects in the U.S., partially offset by increased activity on Canadian pipe fabrication and module assembly projects.

Services gross loss increased by $56 million, or (133)%, to a loss of $98 million in the nine months ended September 30, 2014 compared to a loss of $42 million in the same period of the prior year. This change was primarily attributable to a decline in the volume of construction projects in the U.S. and Canada. Additional project costs of $12 million due to schedule delays and liquidated damages were also recognized on construction projects in North America. Losses on our Canadian pipe fabrication and module assembly projects totaled $80 million and $89 million for the nine months ended September 30, 2014 and 2013, respectively.

Services equity in earnings of unconsolidated affiliates decreased$7 million in the nine months ended September 30, 2014 compared to the same period of the prior year primarily because the vessels for MMM were out of contract for a significant portion of the nine months ended September 30, 2014. The vessels returned to service and improved utilization is expected in the future.

Other

Other revenues decreased by $20 million, or 41%, in the nine months ended September 30, 2014 compared to the same period of the prior year, primarily driven by the loss of revenues due to the sale of the external portion of our former Allstates Technical Services business in the fourth quarter of 2013. Gross profit increased by $4 million, or 33%, in the nine months ended September 30, 2014 compared to the same period of the prior year, primarily due to lower overheads as a result of the sale previously mentioned. Other equity in earnings of unconsolidated affiliates was flat compared to the same period of the prior year.

Changes in Estimates

Information relating to our changes in estimates is described in Note 2 to our condensed consolidated financial statements.

Labor Cost not Allocated to the Business Segments	Nine Months Ended September 30,
						2014 vs. 2013
Dollars in millions	2014		2013			$		%
Labor cost not allocated to the business segments - favorable (unfavorable)	$	1	$	(42	)	$	43	102	%

Labor cost not allocated to the business segments represents costs incurred by our central labor and resource departments net of the amounts charged to the business segments. Labor cost absorption improved primarily due to a combination of increased chargeability, reduced headcount and cost reductions. In addition, labor cost absorption benefited from an office closure in North America in the first nine months of 2013.

Backlog of Unfilled Orders

Backlog generally represents the dollar amount of revenues and our pro-rata share of work to be performed by unconsolidated joint ventures we expect to realize in the future as a result of performing work on contracts. We generally include total expected revenues in backlog when a contract is awarded under a legally binding commitment. In many instances, arrangements included in backlog are complex, nonrepetitive in nature and may fluctuate depending on estimated revenues and contract duration. Where contract duration is indefinite, projects included in backlog are limited to the estimated amount of expected revenues within the following twelve months. Certain contracts provide maximum dollar limits, with actual authorization to perform work under the contract agreed upon on a periodic basis with the customer. In these arrangements, only the amounts authorized are included in backlog. For projects where we act solely in a project management capacity, we only include the value of our services of each project in backlog. For certain long-term service contracts with a defined contract term, such as those associated with privately financed projects, the amount included in backlog is limited to five years.

49

Included in the backlog table below is our proportionate share of unconsolidated joint ventures estimated revenues. However, because these projects are accounted for under the equity method, only our share of future earnings from these projects will be recorded in our results of operations. Our backlog for projects related to unconsolidated joint ventures totaled $4.9 billion as of September 30, 2014 and $5.5 billion as of December 31, 2013. We consolidate joint ventures which are majority-owned and controlled or are variable interest entities in which we are the primary beneficiary. Our backlog included in the table below for projects related to consolidated joint ventures with noncontrolling interests includes 100% of the backlog associated with those joint ventures and totaled $1.0 billion as of September 30, 2014 and $1.5 billion as of December 31, 2013. Backlog attributable to unfunded government orders was $34 million as of September 30, 2014 and $166 million as of December 31, 2013. The following table summarizes our backlog by business segment.

	December 31,				Changes in scope on existing contracts (a)						September 30,
Dollars in millions	2013		New Awards					Net Workoff (b)			2014
Gas Monetization	$	6,169	$	50	$	(348	)	$	(1,163	)	$	4,708
Hydrocarbons	2,619		1,163		535			(1,546		)	2,771
Infrastructure, Government and Power	2,079		785		278			(1,050		)	2,092
Services	2,254		391		289			(1,280		)	1,654
Other	997		—		(50		)	(28		)	919
Total backlog	$	14,118	$	2,389	$	704		$	(5,067	)	$	12,144

(a) - In addition to changes in scope, these amounts reflect the elimination of our proportionate share of non-partner costs related to our unconsolidated joint ventures

(b) - These amounts include the net workoff of our projects as well as our proportionate share of the net workoff of our unconsolidated joint ventures projects.

We estimate that as of September 30, 2014, 57% of our backlog will be executed within one year. As of September 30, 2014, 38% of our backlog was attributable to fixed-price contracts and 62% of our backlog was attributable to cost-reimbursable contracts. For contracts that contain both fixed-price and cost-reimbursable components, we classify the components as either fixed-price or cost-reimbursable according to the composition of the contract; however, except for smaller contracts, we characterize the entire contract based on the predominant component.

Liquidity and Capital Resources

Cash and cash equivalents totaled $1.0 billion as of September 30, 2014 and $1.1 billion as of December 31, 2013 and consisted of the following:

	September 30,		December 31,
Dollars in Millions	2014		2013
Domestic U.S. cash	$	258	$	355
International cash	710		675
Joint venture cash	80		76
Total	$	1,048	$	1,106

Cash generated from operations is our primary source of operating liquidity. Our cash balances are held in numerous locations throughout the world. We believe that our liquidity needs for the next 12 months will be met from existing cash balances and internally generated cash flows.

Domestic cash relates to cash balances held by U.S. entities and is largely used to support obligations of those businesses as well as general corporate needs, such as the implementation of our new ERP systems, payment of dividends to shareholders and repurchases of our common stock.

International cash balances may be available for general corporate purposes, but are subject to local restrictions such as capital adequacy requirements and local obligations such as the funding of our underfunded U.K. pension plan and other obligations incurred in the normal course of business by those foreign entities. Additionally, repatriated foreign cash may be subject to U.S. income taxes.

50

We generally do not provide for U.S. federal and state income taxes on the accumulated undistributed earnings of non-U.S. subsidiaries except for certain entities in Mexico and certain other joint ventures, as well as for approximately 50% of our earnings from our operations in Australia.  Information relating to our accumulated undistributed earnings is described in Note 3 to our condensed consolidated financial statements.

Joint venture cash balances reflect the amounts held by joint venture entities we consolidate for financial reporting purposes. Such amounts are limited to joint venture activities and are not readily available to us for general purposes. However, portions of such amounts may become available to us in the future should there be distribution of dividends to the joint venture partners. We expect the majority of the joint venture cash balances will be utilized for the corresponding joint venture projects.

Summary of Cash Flow Activity
	Nine Months Ended September 30,
Dollars in millions	2014			2013
Cash flows provided by operating activities	$	178		$	81
Cash flows used in investing activities	(37		)	(50		)
Cash flows used in financing activities	(178		)	(83		)
Effect of exchange rate changes on cash	(21		)	(42		)
Decrease in cash and equivalents	$	(58	)	$	(94	)

Operating activities. Cash provided by operations totaled $178 million in the first nine months of 2014 and was primarily attributable to $212 million of distributions of earnings from unconsolidated affiliates and fluctuations in our working capital accounts. This increase was partially offset by contributions of approximately $37 million to our pension funds.

Cash provided by operations totaled $81 million in the first nine months of 2013 and was primarily attributable to fluctuations in our working capital accounts. This increase was partially offset by our payment of $108 million in outstanding performance bonds to PEMEX Exploration and Production ("PEP") (see Note 12 to our condensed consolidated financial statements). In addition, we contributed approximately $26 million to our pension funds.

Investing activities. Cash used in investing activities totaled $37 million in the first nine months of 2014 and was primarily due to purchases of property, plant and equipment associated with information technology projects.

Cash used in investing activities totaled $50 million in the first nine months of 2013 and was primarily due to capital expenditures associated with information technology projects.

Financing activities. Cash used in financing activities totaled $178 million in the first nine months of 2014 and included $102 million for the purchase of treasury stock, $35 million for the payments of dividends to common shareholders, $39 million for distributions to noncontrolling interests and $7 million for principal payments on short-term and long-term borrowings, which consists primarily of nonrecourse debt of our Fasttrax variable interest entity. The uses of cash were partially offset by $4 million of proceeds from the exercise of stock options.

Cash used in financing activities totaled $83 million in the first nine months of 2013 and included $49 million for distributions to noncontrolling interests, $24 million for the payments of dividends to common shareholders, $9 million for principal payments on short-term and long-term borrowings, which consists primarily of nonrecourse debt of our Fasttrax variable interest entity, and $7 million for the purchase of treasury stock. The uses of cash were partially offset by $5 million of proceeds from the exercise of stock options.

Future sources of cash. Future sources of cash include cash flows from operations, including cash advances from our customers, cash derived from working capital management and cash borrowings under our Credit Agreement as well as potential litigation proceeds.

Future uses of cash. Future uses of cash will primarily relate to working capital requirements, including any payments on the Halliburton award, capital expenditures, dividends, share repurchases and strategic investments. In addition, we will use cash to fund pension obligations, payments under operating leases and various other obligations, including potential litigation payments, as they arise. Our capital expenditures will be focused primarily on information technology, real estate, facilities and equipment.

51

Other Factors Potentially Affecting Liquidity

Canada project losses. As disclosed in Note 1 to our condensed consolidated financial statements, our reserve for estimated losses on uncompleted contracts included in "other current liabilities" on our condensed consolidated balance sheet consists of $87 million related to our Canadian pipe fabrication and module assembly projects. These accrued losses will result in future cash expenditures in excess of customer receipts. Based on current contracts and work authorizations, we anticipate completion of these projects in 2015.

Liquidated damages. Information relating to our liquidated damages is described in Note 5 to our condensed consolidated financial statements.

Credit Agreement

On December 2, 2011, we entered into a $1 billion, five-year unsecured revolving credit agreement (the “Credit Agreement”) with a syndicate of international banks. The Credit Agreement is available for cash borrowings and the issuance of letters of credit related to general corporate needs.  The Credit Agreement expires in December 2016; however, given that projects generally require letters of credit that extend beyond one year in length, we will likely need to enter into a new or amended credit agreement no later than 2015. Amounts drawn under the Credit Agreement will bear interest at variable rates, per annum, based either on (1) the London interbank offered rate (“LIBOR”) plus an applicable margin of 1.50% to 1.75%, or (2) a base rate plus an applicable margin of 0.50% to 0.75%, with the base rate equal to the highest of (a) reference bank’s publicly announced base rate, (b) the Federal Funds Rate plus 0.5%, or (c) LIBOR plus 1%. The amount of the applicable margin to be applied will be determined by our ratio of consolidated debt to consolidated EBITDA for the prior four fiscal quarters, as defined in the Credit Agreement. The Credit Agreement provides for fees on letters of credit issued under the Credit Agreement at a rate equal to the applicable margin for LIBOR-based loans, except for performance letters of credit, which are priced at 50% of such applicable margin. We pay an issuance fee of 0.15% of the face amount of a letter of credit. We also pay a commitment fee of 0.25% per annum on any unused portion of the commitment under the Credit Agreement. As of September 30, 2014, there were $184 million in letters of credit and no cash borrowings outstanding.

The Credit Agreement contains customary covenants, including financial covenants requiring maintenance of a ratio of consolidated debt to consolidated EBITDA not greater than 3.5 to 1 and a minimum consolidated net worth of $2 billion plus 50% of consolidated net income for each quarter beginning December 31, 2011 and 100% of any increase in shareholders’ equity attributable to the sale of equity interests. As of September 30, 2014, we were in compliance with our financial covenants.

The Credit Agreement contains a number of other covenants restricting, among other things, our ability to incur additional liens and indebtedness, enter into asset sales, repurchase our equity shares and make certain types of investments. Our subsidiaries are restricted from incurring indebtedness, except if such indebtedness relates to purchase money obligations, capitalized leases, refinancing or renewals secured by liens upon or in property acquired, constructed or improved in an aggregate principal amount not to exceed $200 million at any time outstanding. Additionally, our subsidiaries may incur unsecured indebtedness not to exceed $200 million in aggregate outstanding principal amount at any time. We are also permitted to repurchase our equity shares, provided that no such repurchases shall be made from proceeds borrowed under the Credit Agreement, and that the aggregate purchase price and dividends paid after December 2, 2011, does not exceed the Distribution Cap (equal to the sum of $750 million plus the lesser of (1) $400 million and (2) the amount received by us in connection with the arbitration and subsequent litigation of the PEP contracts as discussed in Note 12 to our condensed consolidated financial statements). As of September 30, 2014, the remaining availability under the Distribution Cap was approximately $483 million.

Pursuant to the terms of the Credit Agreement, an event of default is triggered if any certificate furnished to the bank syndicate is incorrect or proves to have been incorrect, when made or deemed made. In our Current Report on Form 8-K filed May 5, 2014, we announced that the previously issued consolidated financial statements as of and for the year ended December 31, 2013 as filed on February 27, 2014 should no longer be relied upon. At that time the management certifications to our financial institutions under the Credit Agreement were no longer valid. In our Current Report on Form 8-K filed May 13, 2014, we announced that we received a waiver under our Credit Agreement, providing for the waiver of compliance with certain representations, warranties and covenants of the Credit Agreement. The waiver relates to certain defaults triggered, or which might have been triggered, by our restatement of the December 31, 2013 financial statements and related documents. After giving effect to the waiver and the fact that our filings of our financial results are now current, no event of default exists under the Credit Agreement as a result of the restatement and we may request the issuance of new letters of credit and loan advances under the Credit Agreement in accordance with its terms.

52

Nonrecourse Project Debt

Information relating to our nonrecourse project debt is described in Note 8 to our condensed consolidated financial statements.

Off-Balance Sheet Arrangements

Letters of credit, surety bonds and guarantees. In connection with certain projects, we are required to provide letters of credit, surety bonds or guarantees to our customers. Letters of credit are provided to certain customers and counterparties in the ordinary course of business as credit support for contractual performance guarantees, advanced payments received from customers and future funding commitments. We have approximately $2.3 billion in committed and uncommitted lines of credit to support the issuance of letters of credit and, as of September 30, 2014, we have utilized $655 million of our present capacity under lines of credit. Surety bonds are also posted under the terms of certain contracts to guarantee our performance. The letters of credit outstanding included $184 million issued under our Credit Agreement and $471 million issued under uncommitted bank lines as of September 30, 2014. Of the letters of credit outstanding under our Credit Agreement, approximately $1 million letters of credit have expiry dates beyond the maturity date of the Credit Agreement. Of the total letters of credit outstanding, $246 million relate to our joint venture operations where the letters of credit are posted using our capacity to support our pro-rata share of obligations under various contracts executed by joint ventures of which we are a member. As the need arises, future projects will be supported by letters of credit issued under our Credit Agreement or other lines of credit arranged on a bilateral, syndicated or other basis. We believe we have adequate letter of credit capacity under our Credit Agreement and bilateral lines of credit to support our operations for the next twelve months.

Transactions with Former Parent

Information relating to our transactions with former parent is described in Note 13 to our condensed consolidated financial statements.

Transactions with Joint Ventures

We perform many of our projects through incorporated and unincorporated joint ventures. In addition to participating as a joint venture partner, we often provide engineering, procurement, construction, operations or maintenance services to the joint venture as a subcontractor. Where we provide services to a joint venture that we control and therefore consolidate for financial reporting purposes, we eliminate intercompany revenues and expenses on such transactions. In situations where we account for our interest in the joint venture under the equity method of accounting, we do not eliminate any portion of our revenues or expenses. We recognize the profit on our services provided to joint ventures that we consolidate and joint ventures that we record under the equity method of accounting primarily using the percentage-of-completion method.

Legal Proceedings

Information related to various commitments and contingencies is described in Notes 11 and 12 to our condensed consolidated financial statements.

Item 3. Quantitative and Qualitative Discussion about Market Risk

We have foreign currency exchange rate risk resulting from our international operations. We selectively manage our exposure to currency rate changes through the use of derivative instruments to mitigate our market risk from these exposures. The objective of our risk management is to protect our cash flows related to sales or purchases of goods or services from market fluctuations in currency rates. Our use of derivative instruments includes the following types of market risk:

• volatility of the currency rates;

• time horizon of the derivative instruments;

• market cycles; and

• the type of derivative instruments used.

We do not use derivative instruments for speculative trading purposes. We do not consider any of these risk management activities to be material.

53

Item 4. Controls and Procedures

Management’s Evaluation of Disclosure Controls and Procedures

In accordance with Rules 13a-15 and 15d-15 under the Securities Exchange Act of 1934 as amended (the “Exchange Act”), we carried out an evaluation, under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer, of the effectiveness of the design and operation of our disclosure controls and procedures as of the end of the period covered by this report.

In conducting our evaluation, we concluded there are material weaknesses in the operating effectiveness of our internal control over financial reporting, as described below.

As a result of the foregoing, we have concluded that as of September 30, 2014, our disclosure controls and procedures were not effective in providing reasonable assurance that information required to be disclosed in our reports filed under the Exchange Act was recorded, processed, summarized and reported within the time periods specified in the Securities and Exchange Commission’s rules and regulations, and that such information was accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, to allow timely decisions regarding required disclosure.

Management does not expect that our disclosure controls and procedures will prevent all errors and all fraud. A control system, no matter how well designed and operated, can provide only reasonable, not absolute, assurance that the control system's objectives will be met. Further, the design of a control system must reflect the fact that there are resource constraints, and the benefits of controls must be considered relative to their costs. Because of the inherent limitations in all control systems, no evaluation of controls can provide absolute assurance that all control issues and instances of fraud, if any, have been detected. These inherent limitations include the realities that judgments in decision-making can be faulty, and that breakdowns can occur because of simple error or mistake. The design of any system of controls is based in part upon certain assumptions about the likelihood of future events, and there can be no assurance that any design will succeed in achieving its stated goals under all potential future conditions.

In light of the material weaknesses identified below, we performed additional analysis and other post-closing procedures to ensure our condensed consolidated financial statements were prepared in accordance with U.S. GAAP and reflect our financial position and results of operations as of and for the quarter ended September 30, 2014. As a result, notwithstanding the material weaknesses as described below, management concluded that the condensed consolidated financial statements included in this Form 10-Q present fairly, in all material respects, our financial position, results of operations and cash flows for the periods presented.

A material weakness is a deficiency, or a combination of deficiencies, in internal control over financial reporting, such that there is a reasonable possibility that a material misstatement of our annual or interim financial statements will not be prevented or detected on a timely basis.

Material weakness related to project reporting over the completeness and accuracy of estimates of revenues, costs and profit at completion for certain long-term construction projects with multiple currencies. We determined that a material weakness in internal control over financial reporting existed within our Gas Monetization business segment because controls were not properly designed to determine that actual and estimated foreign currency effects were included in our estimates of revenues, costs and profit at completion for long-term construction contracts that contain multiple currencies. Additionally, our control to monitor the inclusion of foreign currency effects in our estimates of revenues, costs and profit at completion was not properly designed.

 This material weakness resulted in misstatements in the accounting for the foreign currency effects on long-term construction contracts. The misstatements were corrected prior to issuance of the Company’s December 31, 2013 Annual Report on Form 10-K and in the restatement of the consolidated financial statements as of and for the year ended December 31, 2013 in the Company’s Annual Report on Form 10-K/A.

54

Material weakness related to control environment for our Canadian pipe fabrication and module assembly business. We determined that a material weakness in internal control over financial reporting existed in our Canadian pipe fabrication and module assembly business within our Services business segment resulting from the Company having insufficiently trained project managers, project controls, accounting and executive management professionals to perform project oversight reviews and monitor compliance with the Company’s standard processes and controls. Furthermore, the control environment was ineffective in that the culture at the Canadian pipe fabrication and module assembly business facilitated delayed identification and communication of project concerns and the proper preparation of complete and accurate estimates of revenues, costs and profit at completion. As a result, controls over the completeness and accuracy of information used in preparation of estimates and control procedures and controls over the reviews of such estimates to complete for our Canadian pipe fabrication and module assembly business also were not effective.

This material weakness resulted in pre-tax charges, consisting of the reversal of previously recognized pre-tax profits and the recognition of pre-tax estimated losses at completion. To correct this and to address matters related to the foregoing with respect to our disclosure controls and procedures, we restated our consolidated financial statements as of and for the year ended December 31, 2013 in the Company’s Annual Report on Form 10-K/A.

Management’s Plans for Remediation of the Material Weaknesses

Material weakness related to project reporting over the completeness and accuracy of estimates of revenues, costs and profit at completion for certain long-term construction projects with multiple currencies. In response to this material weakness, we have developed a plan with the oversight of the Audit Committee of the Board of Directors and commenced implementation to remediate this material weakness. As part of our plan to remediate this material weakness during fiscal year 2014 we have:

• Continuing to implement a control to include the actual and estimated foreign currency effects in the estimates of revenues, costs and profit at completion on projects with multiple currencies by enhancing the design of our project status templates and our procedures for completion of our project status templates.

• Continuing to enhance the design of our monitoring controls over the completeness and accuracy of estimated revenues, costs and profit at completion for long-term construction projects with multiple currencies to specifically include a process for monitoring and reviewing project status reports for proper application of foreign currency effects in project estimates.

• Continuing to provide training to our personnel involved in the estimation of revenues, costs and profit at completion on projects with multiple currencies.

Material weakness related to control environment for our Canadian pipe fabrication and module assembly business. In response to this material weakness, we have developed a plan with the oversight of the Audit Committee of the Board of Directors and commenced implementation to remediate this material weakness. As part of our plan to remediate this material weakness during fiscal year 2014 in our Canada pipe fabrication and module assembly business we have/are:

• Conducted town hall meetings throughout the Company's worldwide organization led by executive management to reinforce the requirement for employees to follow the Company's corporate culture, policies and procedures.

• Changed certain management personnel and increase the number of qualified professionals.

• Continuing to provide training to new and key personnel on roles and responsibilities, including line of communications in the event of concerns.

• Continuing to provide training to new and key personnel on Company standard processes and systems across all project operations, oversight and support functions, including project management and module yard management.

• Implemented and are actively monitoring execution of KBR standard project controls work processes and systems across the Canada pipe fabrication and module assembly projects.

• Implemented standard project management oversight from corporate management.

We can give no assurance that the measures we take will remediate the material weaknesses that we have identified or that any additional material weaknesses will not arise in the future. We will continue to monitor the effectiveness of these and other processes, procedures and controls and will make any further changes management determines appropriate.

55

Changes in Internal Control Over Financial Reporting

There were no changes in our internal controls over financial reporting during the three months ended September 30, 2014 that have materially affected, or are reasonably likely to affect, our internal controls over financial reporting.

As a result of the material weaknesses described above, the company continues to make progress in the completion of our remediation plan activities to enhance our internal control over financial reporting. Specific activities completed are described above.

PART II. OTHER INFORMATION

Item 1.Legal Proceedings

Information related to various commitments and contingencies is described in Notes 11 and 12 to our condensed consolidated financial statements and in "Management's Discussion and Analysis of Financial Condition and Results of Operations – Legal Proceedings" and the information discussed therein is incorporated herein.

Item 1A. Risk Factors

We have updated certain risk factors affecting our business since those presented in our Annual Report on Form 10-K/A, Part I, Item 1A, for the fiscal year ended December 31, 2013. Except for the risk factors updated, there have been no material changes in our assessment of our risk factors from those set forth in our Annual Report on Form 10-K/A, which is incorporated herein by reference, for the year ended December 31, 2013. Our updated risk factors are included below.

Risks Related to Operations of our Business

Crude oil and natural gas prices are extremely volatile. A substantial or extended decline in the price of crude oil and natural gas could adversely affect our results of operations.

Our business segment revenues are highly dependent on capital expenditures for LNG, refining and distribution facilities and other investments by large oil and gas companies.  The demand for these facilities and the ability of our customers to borrow and obtain additional capital on attractive terms is also substantially dependent upon crude oil and natural gas prices. As seen in the recent decline in crude prices, prices for crude oil and natural gas are subject to large fluctuations in response to relatively minor changes in supply and demand, market uncertainty and a variety of other factors that are beyond our control.  Demand for the services we provide could decrease in the event of a sustained reduction in demand for crude oil or natural gas, while perceptions of long-term decline in crude oil and natural gas prices by oil and gas companies (our customers) can similarly reduce or defer major expenditures given the long-term nature of many large-scale projects. 

A portion of our revenues is generated by large, recurring business from certain significant customers. A loss, cancellation or delay in projects by our significant customers in the future could negatively affect our revenues.

We provide services to a diverse customer base, including international and national oil and gas companies, independent refiners, petrochemical producers, fertilizer producers and domestic and foreign governments. A considerable percentage of revenues is generated from transactions with Chevron, primarily from our Gas Monetization business segment. Revenues from Chevron represented 17% of our total consolidated revenues for the nine months ended September 30, 2014.

56

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds

(a) None.

(b) None.

(c) On February 25, 2014, our Board of Directors authorized a new $350 million share repurchase program, which replaces and terminates the August 26, 2011 share repurchase program. The authorization does not specify an expiration date for the share repurchase program. The following is a summary of share repurchases of our common stock settled during the nine months ended September 30, 2014. We also have a share maintenance program to repurchase shares based on vesting and other activity under our equity compensation plans. Shares purchased under "Employee transactions" in the table below reflects shares acquired from employees in connection with the settlement of income tax and related benefit-withholding obligations arising from vesting of restricted stock units.

Purchase Period	Total Number of Shares Purchased (1)		Average Price Paid per Share		Total Number of Shares  Purchased as Part of Publicly Announced Plans or Programs		Dollar Value of Shares  that May Yet Be Purchased Under the Plans or Programs (1)
July 1 – 31, 2014
Repurchase program (2) (3)	(97,868	)	$	20.78	(97,868	)	$	271,011,384
Maintenance program (2) (3)	97,868		$	20.78	—		—
Employee transactions	3,201		$	23.54	—		—
August 1 – 29, 2014
Repurchase program	274,119		$	20.78	274,119		$	265,315,027
Maintenance program	26,481		$	20.78	—		—
Employee transactions	1,713		$	21.60	—		—
September 1 – 30, 2014
Repurchase program (2) (3)	(729	)	$	20.78	(729	)	$	265,330,176
Maintenance program (2) (3)	729		$	20.78	—		—
Employee transactions	1,308		$	19.28	—		—
Total
Repurchase program	175,522		$	20.78	175,522		$	265,330,176
Maintenance program	125,078		$	20.78	—		—
Employee transactions	6,222		$	22.11	—		—

(1) Represents remaining authorization that may be used for repurchases pursuant to the share repurchase program authorized and announced on February 25, 2014.

(2) There were no shares repurchased during this period; however, share grants under our equity compensation plans vested and shares were issued in accordance with those plans.

(3) In a given fiscal year, we allocate repurchased shares first to our maintenance program and second to our Board-authorized repurchase program.  Negative values reflect repurchased shares in excess of available maintenance shares in previous periods that have been reallocated in the current period as repurchases under the maintenance program from repurchases under the Board-authorized repurchase program.

Item 3. Defaults Upon Senior Securities

None.

Item 4.Mine Safety Disclosures

Not applicable.

Item 5. Other Information

None.

57

Item 6. Exhibits

Exhibit Number	Description
3.1	KBR Amended and Restated Certificate of Incorporation (incorporated by reference to Exhibit 3.1 to KBR’s current report on Form 8-K filed June 7, 2012; File No. 1-33146)
3.2	Amended and Restated Bylaws of KBR, Inc. (incorporated by reference to Exhibit 3.2 to KBR’s annual report on Form 10-K for the year ended December 31, 2013; File No. 1-33146)
*10.1+	Form of revised Restricted Stock Unit Agreement (U.S. Employee - 3 Year Vesting) pursuant to KBR, Inc. 2006 Stock and Incentive Plan
*10.2+	Form of revised Restricted Stock Unit Agreement (International Employee - 3 Year Vesting) pursuant to KBR, Inc. 2006 Stock and Incentive Plan
*10.3+	Form of revised Restricted Stock Unit Agreement (U.S. Employee - 3 Year Vesting; Involuntary Termination Trigger) pursuant to KBR, Inc. 2006 Stock and Incentive Plan
*10.4+	Form of revised Restricted Stock Unit Agreement (U.S. Employee - 5 Year Vesting; TSR Requirement) pursuant to KBR, Inc. 2006 Stock and Incentive Plan
*31.1	Certification of the Chief Executive Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
*31.2	Certification of the Chief Financial Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
**32.1	Certification Furnished Pursuant to 18 U.S.C. Section 1350 as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
**32.2	Certification Furnished Pursuant to 18 U.S.C. Section 1350 as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
***101.INS	XBRL Instance Document
***101.SCH	XBRL Taxonomy Extension Schema Document
***101.CAL	XBRL Taxonomy Extension Calculation Linkbase Document

+	Management contracts or compensatory plans or arrangements
*	Filed herewith
**	Furnished herewith
***	Interactive data files

Pursuant to Rule 406T of Regulation S-T, interactive data files (i) are not deemed filed or part of a registration statement or prospectus for purposes of Sections 11 or 12 of the Securities Act of 1933, are not deemed filed for purposes of Section 18 of the Securities Exchange Act of 1934, irrespective of any general incorporation language included in any such filings, and otherwise are not subject to liability under these sections; and (ii) are deemed to have complied with Rule 405 of Regulation S-T (“Rule 405”) and are not subject to liability under the anti-fraud provisions of the Section 17(a)(1) of the Securities Act of 1933, Section 10(b) of the Securities Exchange Act of 1934 or under any other liability provision if we have made a good faith attempt to comply with Rule 405 and, after we become aware that the interactive data files fail to comply with Rule 405, we promptly amend the interactive data files.

58

Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

KBR, INC.

/s/  Brian K. Ferraioli	/s/   Nelson E. Rowe
Brian K. Ferraioli	Nelson E. Rowe
Executive Vice President and Chief Financial Officer	Vice President and Chief Accounting Officer

Date:November 3, 2014

59

EX-10.1

US EMPLOYEE – 3-Year Vesting

RESTRICTED STOCK UNIT AGREEMENT

AGREEMENT by and between KBR, Inc., a Delaware corporation (the “Company”) and ________________ (“Employee”) made effective as of ____________________ (the “Grant Date”).

1.Grant of Restricted Stock Units.

(a)Units. Pursuant to the KBR, Inc. 2006 Stock and Incentive Plan, as amended and restated (the “Plan”), units evidencing the right to receive __________ shares of the Company’s common stock (“Stock”), are awarded to Employee, subject to the conditions of the Plan and this Agreement (the “Restricted Stock Units”).

(b)Plan Incorporated. Employee acknowledges receipt of a copy of the Plan, and agrees that this award of Restricted Stock Units shall be subject to all of the terms and conditions set forth in the Plan, including future amendments thereto, if any, pursuant to the terms thereof, which is incorporated herein by reference as a part of this Agreement. Except as defined herein, capitalized terms shall have the same meanings ascribed to them under the Plan.

2.Terms of Restricted Stock Units. Employee hereby accepts the Restricted Stock Units and agrees with respect thereto as follows:

(a)Forfeiture of Restricted Stock Units. In the event of termination of Employee’s employment with the Company or any employing Subsidiary of the Company for any reason other than (i) normal retirement on or after age 70, (ii) death or (iii) disability (disability being defined as being physically or mentally incapable of performing either the Employee’s usual duties as an Employee or any other duties as an Employee that the Company reasonably makes available and such condition is likely to remain continuously and permanently, as determined by the Company or employing Subsidiary), or except as otherwise provided in the second and third sentences of subparagraph (c) of this Paragraph 2, Employee shall, for no consideration, forfeit all Restricted Stock Units to the extent they are not fully vested.

(b)Assignment of Award. The Restricted Stock Units may not be sold, assigned, pledged, exchanged, hypothecated or otherwise transferred, encumbered or disposed of unless transferable by will or the laws of descent and distribution or pursuant to a “qualified domestic relations order” as defined by the U.S. Internal Revenue Code (the “Code”).

(c)Vesting Schedule. The Restricted Stock Units shall vest in accordance with the following schedule provided that Employee has been continuously employed by the Company from the date of this Agreement through the applicable vesting date.

Vesting Date	Vested Percentage of Total Number of Restricted Stock Units
1st Anniversary of Grant Date	33 ⅓%
2nd Anniversary of Grant Date	66 ⅔%
3rd Anniversary of Grant Date	100%

Notwithstanding the foregoing, unless otherwise provided in an Other Agreement pursuant to Paragraph 8, the Restricted Stock Units shall become fully vested on the earliest of (i) the occurrence of your Involuntary Termination or termination for Good Reason within two years following a Corporate Change (as such terms are defined in the Plan), (ii) the date Employee’s employment with the Company is terminated by reason of death or disability (as determined above), or (iii) Employee’s attainment of age 70 while employed with the Company. In the event Employee’s employment is terminated for any other reason, including retirement prior to age 70 with the approval of the Company or employing Subsidiary, the Committee which administers the Plan (the “Committee”) or its delegate, as appropriate, may, in the Committee’s or such delegate’s sole discretion, approve the acceleration of the vesting of any or all Restricted Stock Units still subject to restrictions, such vesting acceleration to be effective on the date of such approval or Employee’s termination date, if later. Notwithstanding the foregoing, in no event shall the Restricted Stock Units become fully vested prior to the expiration of one month from the Grant Date.

(d)Stockholder Rights. Employee shall have no rights of a stockholder with respect to shares of Stock subject to this Award unless and until such time as the Award has been settled by the transfer of shares of Stock to Employee, except that Employee shall have the right to receive payments equal to the dividends or distributions declared or paid on a share of Stock at the same time as those dividends or distributions are paid to holders of Stock.

(e)Settlement and Delivery of Shares. Payment of vested Restricted Stock Units shall be made as soon as administratively practicable after vesting, but in no event later than thirty days after the vesting date. Settlement will be made by payment in shares of Stock. Notwithstanding the foregoing, the Company shall not be obligated to deliver any shares of Stock if counsel to the Company determines that such sale or delivery would violate any applicable law or any rule or regulation of any governmental authority or any rule or regulation of, or agreement of the Company with, any securities exchange or association upon which the Stock is listed or quoted.

(f)Recovery of Shares. The Company shall seek recovery of any benefits provided hereunder to Employee if such recovery is required by any clawback policy adopted by the Company, which may be amended from time to time, including, but not limited to, any clawback policy adopted to satisfy the minimum clawback requirements adopted under the Dodd-Frank Wall Street Reform and Consumer Protection Act of 2010 and the regulations thereunder or any other applicable law.

3.Withholding of Tax.The Committee may make such provisions as it may deem appropriate for the withholding of any taxes which it determines is required in connection with this Award. Unless the Committee provides otherwise, the Company shall reduce the number of shares of Stock that would have otherwise been delivered to Employee by a number of shares of Stock having a Fair Market Value equal to the amount required to be withheld.

4.Employment Relationship. For purposes of this Agreement, Employee shall be considered to be in the employment of the Company as long as Employee remains an employee of the Company, a Parent Corporation or Subsidiary of the Company, or a corporation or a Parent Corporation or subsidiary of such corporation assuming or substituting a new award for this Award. Any question as to whether and when there has been a termination of such employment, and the cause of such termination, shall be determined by the Committee, or its delegate, as appropriate, and its determination shall be final.

5.Committee’s Powers. No provision contained in this Agreement shall in any way terminate, modify or alter, or be construed or interpreted as terminating, modifying or altering any of the powers, rights or authority vested in the Committee or, to the extent delegated, in its delegate pursuant to the terms of the Plan or resolutions adopted in furtherance of the Plan, including, without limitation, the right to make certain determinations and elections with respect to the Restricted Stock Units.

6.Binding Effect. This Agreement shall be binding upon and inure to the benefit of any successors to the Company and all persons lawfully claiming under Employee.

7.Compliance with Law. Notwithstanding any other provision of the Plan or this Agreement, unless there is an available exemption from any registration, qualification or other legal requirement applicable to the shares of Stock, the Company shall not be required to deliver any shares issuable upon settlement of the Restricted Stock Units prior to the completion of any registration or qualification of the shares under any local, state, federal or foreign securities or exchange control law or under rulings or regulations of the U.S. Securities and Exchange Commission (“SEC”) or of any other governmental regulatory body, or prior to obtaining any approval or other clearance from any local, state, federal or foreign governmental agency, which registration, qualification or approval the Company shall, in its absolute discretion, deem necessary or advisable. Employee understands that the Company is under no obligation to register or qualify the shares with the SEC or any state or foreign securities commission or to seek approval or clearance from any governmental authority for the issuance or sale of the shares. Further, Employee agrees that the Company shall have unilateral authority to amend the Plan and the Agreement without Employee's consent to the extent necessary to comply with securities or other laws applicable to issuance of shares.

8.Other Agreements. The terms of this Agreement shall be subject to, and shall not modify, the terms and conditions of any employment, severance, and/or change-in-control agreement between the Company (or a Subsidiary) and Employee concerning equity-based awards (“Other Agreement”), except that the Restricted Stock Units shall become fully vested on Employee’s attainment of age 70 while employed with the Company or a Subsidiary, and notwithstanding anything in such Other Agreement to the contrary, any normal retirement age of 65 or other retirement-based vesting provisions in such Other Agreement shall be of no force or effect for purposes of the vesting of these Restricted Stock Units.

9.Governing Law and Venue. This Agreement shall be governed by, and construed in accordance with, the laws of the State of Texas, U.S.A., except to the extent that it implicates matters that are the subject of the General Corporation Law of the State of Delaware, which matters shall be governed by the latter law notwithstanding any conflicts of laws principles that may be applied or invoked directing the application of the laws of another jurisdiction. Exclusive venue for any action, lawsuit or other proceedings brought to enforce this Agreement, relating to it or arising from it, or dispute resolution proceeding arising hereunder for any claim or dispute, the parties hereby submit to and consent to the sole and exclusive jurisdiction of Houston, Harris County, Texas, notwithstanding any conflicts of laws principles that may direct the jurisdiction of any other court, venue, or forum, including the jurisdiction of Employee’s home country.

10.Section 409A. Notwithstanding anything in this Agreement to the contrary, if any provision in this Agreement would result in the imposition of an applicable tax under Section 409A of the Code and related regulations and United States Department of the Treasury pronouncements (“Section 409A”), that provision will be reformed to avoid imposition of the applicable tax and no action taken to comply with Section 409A shall be deemed to adversely affect Employee’s rights under this Agreement.

IN WITNESS WHEREOF, the Company has caused this Agreement to be duly executed by an officer thereunto duly authorized, and Employee has executed this Agreement, all as of the date first above written.

KBR, INC.

By:

Employee

1

EX-10.2

INTERNATIONAL EMPLOYEE – 3-Year Vesting

RESTRICTED STOCK UNIT AGREEMENT

AGREEMENT by and between KBR, Inc., a Delaware corporation (the “Company”) and ________________ (“Employee”) made effective as of ____________________ (the “Grant Date”).

1.Grant of Restricted Stock Units.

(a)Units. Pursuant to the KBR, Inc. 2006 Stock and Incentive Plan, as amended and restated (the “Plan”), units evidencing the right to receive __________ shares of the Company’s common stock (“Stock”), are awarded to Employee, subject to the conditions of the Plan and this Agreement (the “Restricted Stock Units”).

(b)Plan Incorporated. Employee acknowledges receipt of a copy of the Plan, and agrees that this award of Restricted Stock Units shall be subject to all of the terms and conditions set forth in the Plan, including future amendments thereto, if any, pursuant to the terms thereof, which is incorporated herein by reference as a part of this Agreement. Except as defined herein, capitalized terms shall have the same meanings ascribed to them under the Plan.

2.Terms of Restricted Stock Units. Employee hereby accepts the Restricted Stock Units and agrees with respect thereto as follows:

(a)Forfeiture of Restricted Stock Units. In the event of termination of Employee’s employment with the Company or any employing Subsidiary of the Company for any reason other than (i) normal retirement on or after age 70, (ii) death or (iii) disability (disability being defined as being physically or mentally incapable of performing either the Employee’s usual duties as an Employee or any other duties as an Employee that the Company or employing Subsidiary reasonably makes available and such condition is likely to remain continuously and permanently, as determined by the Company or employing Subsidiary), or except as otherwise provided in the second and third sentences of subparagraph (c) of this Paragraph 2, Employee shall, for no consideration, forfeit all Restricted Stock Units to the extent they are not fully vested. Notwithstanding the foregoing, if the Company determines that there has been a legal judgment and/or legal development in Employee’s jurisdiction that likely would result in the favorable treatment that applies to the Restricted Stock Units under the Plan being deemed unlawful and/or discriminatory, the provision above regarding termination of employment related to normal retirement on or after age 70 shall not be applicable to Employee.

(b)Assignment of Award. The Restricted Stock Units may not be sold, assigned, pledged, exchanged, hypothecated or otherwise transferred, encumbered or disposed of unless transferable by will or the laws of descent and distribution or pursuant to a “qualified domestic relations order” as defined by the U.S. Internal Revenue Code (the “Code”).

(c)Vesting Schedule. The Restricted Stock Units shall vest in accordance with the following schedule provided that Employee has been continuously employed by the Company from the date of this Agreement through the applicable vesting date.

Vesting Date	Vested Percentage of Total Number of Restricted Stock Units
1st Anniversary of Grant Date	33 ⅓%
2nd Anniversary of Grant Date	66 ⅔%
3rd Anniversary of Grant Date	100%

Notwithstanding the foregoing, unless otherwise provided in an Other Agreement pursuant to Paragraph 11, the Restricted Stock Units shall become fully vested on the earliest of (i) the occurrence of Employee’s Involuntary Termination or termination for Good Reason within two years following a Corporate Change (as such terms are defined in the Plan), (ii) the date Employee’s employment with the Company is terminated by reason of death or disability (as determined above), or (iii) Employee’s attainment of age 70 while employed with the Company. In the event Employee’s employment is terminated for any other reason, including retirement prior to age 70 with the approval of the Company or employing Subsidiary, the Committee which administers the Plan (the “Committee”) or its delegate, as appropriate, may, in the Committee’s or such delegate’s sole discretion, approve the acceleration of the vesting of any or all Restricted Stock Units still subject to restrictions, such vesting acceleration to be effective on the date of such approval or Employee’s termination date, if later. Notwithstanding the foregoing, in no event shall the Restricted Stock Units become fully vested prior to the expiration of one month from the Grant Date.

Notwithstanding the foregoing, if the Company determines that there has been a legal judgment and/or legal development in Employee’s jurisdiction that likely would result in the favorable retirement treatment that applies to the Restricted Stock Units under the Plan being deemed unlawful and/or discriminatory, Restricted Stock Units shall not become fully vested on Employee's attainment of age 70 while still employed by the Company. Instead, Restricted Stock Units shall become fully vested when Employee's employment is terminated for any reason with at least 25 years of service at the Company or employing Subsidiary (or such lesser number of years of service under special circumstances as may be determined in the Committee’s (or its delegate’s) sole discretion) subject, however, to this being considered nondiscriminatory by legal counsel and to the Committee's (or its delegate’s) sole discretion to approve such acceleration of vesting.

(d)Stockholder Rights. Employee shall have no rights of a stockholder with respect to shares of Stock subject to this Award unless and until such time as the Award has been settled by the transfer of shares of Stock to Employee.

(e)Settlement and Delivery of Shares. Payment of vested Restricted Stock Units shall be made as soon as administratively practicable after vesting, but in no event later than thirty days after the vesting date. Settlement will be made by payment in shares of Stock. Notwithstanding the foregoing, the Company shall not be obligated to deliver any shares of Stock if counsel to the Company determines that such sale or delivery would violate any applicable law or any rule or regulation of any governmental authority or any rule or regulation of, or agreement of the Company with, any securities exchange or association upon which the Stock is listed or quoted.

(f)Recovery of Shares. The Company shall seek recovery of any benefits provided hereunder to Employee if such recovery is required by any clawback policy adopted by the Company, which may be amended from time to time, including, but not limited to, any clawback policy adopted to satisfy the minimum clawback requirements adopted under the Dodd-Frank Wall Street Reform and Consumer Protection Act of 2010 and the regulations thereunder or any other applicable law.

3.Responsibility for Taxes.Employee acknowledges that, regardless of any action taken by the Company, or if different, Employee’s employer (“Employer”), the ultimate liability for all income tax, social insurance, payroll tax, fringe benefits tax, payment on account or other tax-related items related to Employee’s participation in the Plan and legally applicable to Employee (“Tax-Related Items”), is and remains Employee’s responsibility and may exceed the amount actually withheld by the Company and/or the Employer. Employee further acknowledges that the Company and/or the Employer (i) make no representations or undertakings regarding the treatment of any Tax-Related Items in connection with any aspect of the Restricted Stock Units, including but not limited to, the grant, vesting or settlement of the Restricted Stock Units, the subsequent sale of Stock acquired pursuant to such settlement and the receipt of any dividends; and (ii) do not commit to and are under no obligation to structure the terms of the grant or any aspect of the Restricted Stock Units to reduce or eliminate the Employee’s liability for Tax-Related Items or achieve any particular tax result. Further, if Employee is subject to Tax-Related Items in more than one jurisdiction between the Grant Date and the date of any relevant taxable event, Employee acknowledges that the Company and/or the Employer (or former employer, as applicable) may be required to withhold or account for Tax-Related Items in more than one jurisdiction.

Prior to any relevant taxable or tax withholding event, as applicable, Employee agrees to pay or make adequate arrangements satisfactory to the Company and/or the Employer to satisfy all Tax-Related Items. In this regard, Employee authorizes the Company and/or the Employer, or their respective agents, at their discretion, to satisfy the obligations with regard to all Tax-Related Items by one or a combination of the following:

(a)withholding from Employee’s wages or other cash compensation paid to Employee by the Company and/or the Employer; or

(b)withholding from proceeds of the sale of shares of Stock acquired upon settlement of the Restricted Stock Units either through a voluntary sale or through a mandatory sale arranged by the Company (on Employee’s behalf pursuant to this authorization without further consent); or

(c)withholding in shares of Stock to be issued upon settlement of the Restricted Stock Units.

Depending on the withholding method, the Company may withhold or account for Tax-Related Items by considering applicable minimum statutory withholding amounts or other applicable withholding rates, including maximum applicable rates, in which case Employee will receive a refund of any over-withheld amount in cash and will have no entitlement to the Stock equivalent. If the obligation for Tax-Related Items is satisfied by withholding in Stock, for tax purposes, Employee is deemed to have been issued the full number of shares of Stock subject to the vested Restricted Stock Units, notwithstanding that a number of the shares of Stock are held back solely for the purpose of paying the Tax-Related Items.

Employee agrees to pay to the Company or the Employer, including through withholding from Employee's wages or other cash compensation paid to Employee by the Company and/or the Employer, any amount of Tax-Related Items that the Company or the Employer may be required to withhold or account for as a result of Employee’s participation in the Plan that cannot be satisfied by the means previously described. The Company may refuse to issue or deliver the Stock or the proceeds of the sale of Stock, if Employee fails to comply with Employee’s obligations in connection with the Tax-Related Items.

Notwithstanding the preceding provisions of this Paragraph 3, Employee’s liability with respect to Tax-Related Items shall be subject to any international tax assignment agreement then in effect between Employee and the Company, the Employer or any of their respective affiliates or any tax policies or procedures applicable to the Employee’s home country, and in the event of any conflict between the terms of this Paragraph 3 and the terms of such international tax assignment agreement or such tax policies or procedures, the terms of such international tax assignment agreement or such tax policies or procedures, as applicable, shall control.

4.Employment Relationship. For purposes of this Agreement, Employee shall be considered to be in the employment of the Company as long as Employee remains an employee of the Company, a Parent Corporation or Subsidiary of the Company, or a corporation or a Parent Corporation or subsidiary of such corporation assuming or substituting a new award for this Award. Any question as to whether and when there has been a termination of such employment, and the cause of such termination, shall be determined by the Committee, or its delegate, as appropriate, and its determination shall be final.

5.Committee’s Powers. No provision contained in this Agreement shall in any way terminate, modify or alter, or be construed or interpreted as terminating, modifying or altering any of the powers, rights or authority vested in the Committee or, to the extent delegated, in its delegate pursuant to the terms of the Plan or resolutions adopted in furtherance of the Plan, including, without limitation, the right to make certain determinations and elections with respect to the Restricted Stock Units.

6.Data Privacy Notice and Consent.Employee hereby explicitly and unambiguously consents to the collection, use and transfer, in electronic or other form, of Employee’s personal data as described in this Agreement and any other Restricted Stock Unit grant materials by and among, as applicable, Employee’s employer, the Company, and its Subsidiaries for the exclusive purpose of implementing, administering and managing Employee’s participation in the Plan.

Employee understands that the Company and Employer may hold certain personal information about Employee, including, but not limited to, Employee’s name, home address and telephone number, date of birth, social insurance number or other identification number, salary, nationality, job title, any shares of Stock or directorships held in the Company, details of all Restricted Stock Units or any other entitlement to Stock awarded, canceled, vested, unvested or outstanding in Employee’s favor, for the purpose of implementing, administering and managing the Plan (“Data”). Employee understands that Data will be transferred to Morgan Stanley Smith Barney or such other stock plan service provider as may be selected by the Company in the future which is assisting the Company with the implementation, administration and management of the Plan. Employee understands that the recipients of the Data may be located in the United States or elsewhere, and that the recipient’s country (e.g., the United States) may have different data privacy laws and protections than Employee’s country. Employee understands that if he or she resides outside the United States, he or she may request a list with the names and addresses of any potential recipients of the Data by contacting Employee’s local human resources representative. Employee authorizes the Company, Morgan Stanley Smith Barney and any other possible recipients which may assist the Company (presently or in the future) with implementing, administering, and managing the Plan to receive, possess, use, retain and transfer the Data, in electronic or other form for the sole purpose of implementing, administering and managing Employee’s participation in the Plan. Employee understands that Data will be held only as long as is necessary to implement, administer and manage Employee’s participation in the Plan. Employee understands that if he or she resides outside the United States, he or she may, at any time, view Data, request additional information about the storage and processing of Data, require any necessary amendments to Data or refuse or withdraw the consents herein, in any case without cost, by contacting in writing Employee’s local human resources representative. Further, Employee understands that he or she is providing the consents herein on a purely voluntary basis. If Employee does not consent, or if Employee later seeks to revoke his or her consent, Employee's employment status or service and career with the Employer will not be adversely affected; the only consequence of refusing or withdrawing Employee's consent is that the Company would not be able to grant to Employee Restricted Stock Units or other equity awards or administer or maintain such awards. Therefore, Employee understands that refusal or withdrawal of consent may affect Employee’s ability to participate in the Plan. For more information on the consequences of Employee’s refusal to consent or withdrawal of consent, Employee understands that Employee may contact Employee’s local human resources representative.

7.Nature of Grant. By accepting the grant of the Restricted Stock Units, the Employee acknowledges, understands and agrees that:

(a)the Plan is established voluntarily by the Company, it is discretionary in nature, and it may be modified, amended, suspended or terminated by the Company at any time, to the extent permitted by the Plan;

(b)the grant of Restricted Stock Units is voluntary and occasional and does not create any contractual or other right to receive future awards of Restricted Stock Units, or benefits in lieu of Restricted Stock Units even if Restricted Stock Units have been awarded in the past;

(c)all decisions with respect to future Restricted Stock Units or other grants, if any, will be at the sole discretion of the Company;

(d)the grant of Restricted Stock Units and Employee’s participation in the Plan will not create a right to employment or be interpreted as forming an employment or service contract with the Company, the Employer or any Subsidiary of the Company and shall not interfere with the ability of the Company, the Employer or any Subsidiary of the Company, as applicable to terminate Employee’s employment or service relationship (if any);

(e)Employee’s participation in the Plan is voluntary;

(f)the Restricted Stock Units and the Stock underlying the Restricted Stock Units are not intended to replace any pension rights or compensation;

(g)Restricted Stock Units and the income and value of the same are not part of normal or expected compensation for purposes of calculation of any severance, resignation, termination, redundancy or end-of-service payments, bonuses, long-service awards, pension or retirement benefits, or similar payments;

(h)the future value of the Stock is unknown, indeterminable and cannot be predicted with certainty;

(i)no claim or entitlement to compensation or damages shall arise from forfeiture of Restricted Stock Units resulting from Employee ceasing to provide employment or other services to the Company or the Employer (for any reason whatsoever, and whether or not later found to be invalid or in breach of employment laws in the jurisdiction where Employee is employed or the terms of Employee's employment agreement, if any) and in consideration of the grant of Restricted Stock Units to which Employee is not otherwise entitled, Employee irrevocably agrees never to institute any claim against the Company, any of its Subsidiaries or the Employer;

(j)in the event of termination of Employee’s employment or other services (for any reason whatsoever, whether or not later found to be invalid, or in breach of employment laws in the jurisdiction where Employee is employed or the terms of Employee's employment agreement, if any), unless otherwise provided in this Agreement or determined by the Company, Employee’s right to vest in the Restricted Stock Units under the Plan, if any, will terminate effective as of the date that Employee is no longer actively providing services and will not be extended by any notice period (e.g., active services would not include any contractual notice period or any period of “garden leave” or similar period mandated under employment laws in the jurisdiction where Employee is employed or the terms of Employee's employment agreement, if any); the Committee shall have the exclusive discretion to determine when Employee is no longer actively providing services for purposes of the Award (including whether Employee may still be considered to be providing services while on an approved leave of absence);

(k)unless otherwise provided in the Plan or by the Company in its discretion, the Restricted Stock Units and the benefits evidenced by this Agreement do not create any entitlement to have the Restricted Stock Units or any such benefits transferred to, or assumed by, another company nor to be exchanged, cashed out or substituted for, in connection with any corporate transaction affecting the shares of the Company; and

(l)the following provisions apply only if Employee is providing services outside the United States: (i) the Restricted Stock Units and the shares of Stock subject to the Restricted Stock Units are not part of normal or expected compensation or salary for any purpose; and (ii) Employee acknowledges and agrees that neither the Company, the Employer nor any Subsidiary of the Company shall be liable for any foreign exchange rate fluctuation between Employee's local currency and the United States Dollar that may affect the value of the Restricted Stock Units or of any amounts due to Employee pursuant to the settlement of the Restricted Stock Units or the subsequent sale of any shares of Stock acquired upon settlement.

8.No Advice Regarding Grant. The Company is not providing any tax, legal or financial advice, nor is the Company making any recommendations regarding Employee's participation in the Plan, or Employee's acquisition or sale of the underlying shares of Stock. Employee is hereby advised to consult with his or her own personal tax, legal and financial advisors regarding his or her participation in the Plan before taking any action related to the Plan.

9.Binding Effect. This Agreement shall be binding upon and inure to the benefit of any successors to the Company and all persons lawfully claiming under Employee.

10.Compliance with Law. Notwithstanding any other provision of the Plan or this Agreement, unless there is an available exemption from any registration, qualification or other legal requirement applicable to the shares of Stock, the Company shall not be required to deliver any shares issuable upon settlement of the Restricted Stock Units prior to the completion of any registration or qualification of the shares under any local, state, federal or foreign securities or exchange control law or under rulings or regulations of the U.S. Securities and Exchange Commission (“SEC”) or of any other governmental regulatory body, or prior to obtaining any approval or other clearance from any local, state, federal or foreign governmental agency, which registration, qualification or approval the Company shall, in its absolute discretion, deem necessary or advisable. Employee understands that the Company is under no obligation to register or qualify the shares with the SEC or any state or foreign securities commission or to seek approval or clearance from any governmental authority for the issuance or sale of the shares. Further, Employee agrees that the Company shall have unilateral authority to amend the Plan and the Agreement without Employee's consent to the extent necessary to comply with securities or other laws applicable to issuance of shares.

11.Other Agreements. The terms of this Agreement shall be subject to, and shall not modify, the terms and conditions of any employment, severance, and/or change-in-control agreement between the Company (or a Subsidiary) and Employee concerning equity-based awards (“Other Agreement”), except that the Restricted Stock Units shall become fully vested on Employee’s attainment of age 70 while employed with the Company or a Subsidiary, and notwithstanding anything in such Other Agreement to the contrary, any normal retirement age of 65 or other retirement-based vesting provisions in such Other Agreement shall be of no force or effect for purposes of the vesting of these Restricted Stock Units (except as provided in the last paragraph of Paragraph 2(c) above).

12.Governing Law and Venue. This Agreement shall be governed by, and construed in accordance with, the laws of the State of Texas, U.S.A., except to the extent that it implicates matters that are the subject of the General Corporation Law of the State of Delaware, which matters shall be governed by the latter law notwithstanding any conflicts of laws principles that may be applied or invoked directing the application of the laws of another jurisdiction. Exclusive venue for any action, lawsuit or other proceedings brought to enforce this Agreement, relating to it or arising from it, or dispute resolution proceeding arising hereunder for any claim or dispute, the parties hereby submit to and consent to the sole and exclusive jurisdiction of Houston, Harris County, Texas, notwithstanding any conflicts of laws principles that may direct the jurisdiction of any other court, venue, or forum, including the jurisdiction of Employee’s home country.

13.Language. If Employee has received this Agreement or any other document related to the Plan translated into a language other than English and if the translated version is different from the English version, the English version will control.

14.Insider Trading/Market Abuse Laws. Employee acknowledges that, depending on Employee’s country of residence, Employee may be subject to insider trading restrictions and/or market abuse laws, which may affect Employee’s ability to acquire or sell shares of Stock or rights to shares of Stock (e.g., Restricted Stock Units) under the Plan during such times as Employee is considered to have “inside information” regarding the Company (as defined by the laws in Employee’s country). Any restrictions under these laws or regulations are separate from and in addition to any restrictions that may be imposed under any applicable Company insider trading policy. Employee acknowledges that it is his or her responsibility to be informed of and compliant with such regulations, and is advised to speak to his or her personal advisor on this matter.

15.Electronic Delivery and Acceptance. The Company may, in its sole discretion, decide to deliver any documents related to current or future participation in the Plan by electronic means. Employee hereby consents to receive such documents by electronic delivery and agrees to participate in the Plan through an on-line or electronic system established and maintained by the Company or a third party designated by the Company.

16.Severability. If one or more of the provisions of this Agreement shall be held invalid, illegal or unenforceable in any respect, the validity, legality and enforceability of the remaining provisions shall not in any way be affected or impaired thereby and the invalid, illegal or unenforceable provisions shall be deemed null and void; however, to the extent permissible by law, any provisions which could be deemed null and void shall first be construed, interpreted or revised retroactively to permit this Agreement to be construed so as to foster the intent of this Agreement and the Plan.

17.Section 409A. Notwithstanding anything in this Agreement to the contrary, if any provision in this Agreement would result in the imposition of an applicable tax under Section 409A of the Code and related regulations and United States Department of the Treasury pronouncements (“Section 409A”), that provision will be reformed to avoid imposition of the applicable tax and no action taken to comply with Section 409A shall be deemed to adversely affect Employee’s rights under this Agreement.

18.Addendum. Notwithstanding any provision in this Agreement or the Plan to the contrary, the Restricted Stock Units shall be subject to the special terms and provisions set forth in the Addendum to this Agreement for Employee’s country. Moreover, if Employee relocates to one of the countries included in the Addendum, the special terms and conditions for such country will apply to Employee, to the extent the Company determines that the application of such terms and conditions is necessary or advisable for legal or administrative reasons. The Addendum constitutes part of this Agreement.

19.Imposition of Other Requirements. The Company reserves the right to impose other requirements on Employee’s participation in the Plan, on the Restricted Stock Units and on any shares of Stock acquired under the Plan, to the extent the Company determines it is necessary or advisable for legal or administrative reasons, and to require the Employee to sign any additional agreements or undertakings that may be necessary to accomplish the foregoing.

20.Waiver. Employee acknowledges that a waiver by the Company of breach of any provision of this Agreement shall not operate or be construed as a waiver of any other provision of this Agreement, or any subsequent breach by Employee or any other Employee.

IN WITNESS WHEREOF, the Company has caused this Agreement to be duly executed by an officer thereunto duly authorized, and Employee has executed this Agreement, all as of the date first above written.

KBR, INC.

By:

Employee

Addendum

KBR, INC.

Terms and Conditions of Restricted Stock Unit Grant

SPECIAL PROVISIONS OF RESTRICTED STOCK UNITS

IN CERTAIN COUNTRIES

This Addendum includes special country-specific terms that apply to residents in countries listed below. This Addendum is part of the Agreement. Unless otherwise provided below, capitalized terms used but not defined herein shall have the same meanings assigned to them in the Plan and the Agreement.

This Addendum also includes information regarding exchange controls and certain other issues of which Employee should be aware with respect to Employee’s participation in the Plan. The information is based on the securities, exchange control and other laws in effect in the respective countries as of February 2014. Such laws are often complex, change frequently, certain individual exchange control reporting requirements may apply upon vesting of Restricted Stock Units and/or sale of Stock and results may be different based on the particular facts and circumstances. As a result, the Company strongly recommends that Employee does not rely on the information noted herein as the only source of information relating to the consequences of Employee’s participation in the Plan because the information may be out of date at the time Employee’s Restricted Stock Units vest or Employee sells shares of Stock acquired under the Plan.

In addition, the information is general in nature and may not apply to Employee’s particular situation, and the Company is not in a position to assure Employee of any particular result. Accordingly, Employee is advised to seek appropriate professional advice as to how the relevant laws in Employee’s country may apply to Employee’s situation.

If Employee is a citizen or resident of a country other than the country in which Employee is working, or if Employee transfers employment after the Restricted Stock Units are granted to Employee, the information contained in this Addendum for the country Employee works in at the time of grant may not be applicable to Employee and the Company, in its discretion, determines to what extent the terms and conditions contained herein shall be applicable to Employee. If Employee transfers residency and/or employment to another country or is considered a resident of another country listed in the Addendum after the Restricted Stock Units are granted to Employee, the terms and/or information contained for that new country (rather than the original grant country) may be applicable to Employee.

ALGERIA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Restricted Stock Units Only Payable in Cash.

Due to exchange control regulations in Algeria, Employee, or in the event of Employee’s death, the Employee’s legal representative, shall receive only a cash payment in an amount equal to the value of the shares of Stock on each vesting date, as provided in Paragraph 2(c) of the Agreement. Any provisions in the Agreement referring to the issuance of shares of Stock pursuant to vested Restricted Stock Units shall not be applicable to Employee so long as Employee is a resident of Algeria. So long as the Employee is a resident of Algeria, Employee may not receive or hold shares of Stock in connection with the Restricted Stock Units awarded under the Plan.

Employee acknowledges that, even though Employee receives only a cash payment upon vesting of the Restricted Stock Units, he or she may still be subject to certain exchange control requirements under local laws. The cash payment and the receipt of any dividends must be repatriated to Algeria. Employee is advised to consult with his or her personal consultant to ensure compliance with any exchange control obligations arising from Employee’s participation in the Plan.

ANGOLA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Exchange Control Information.

Employee may need to obtain prior approval from the Angolan central bank prior to opening a non-Angolan bank or brokerage account and receiving shares of Stock or proceeds from the sale of shares of Stock into such account. Proceeds from the sale of shares of Stock and the receipt of any dividends must be repatriated to Angola. Employee is advised to consult with his or her personal consultant to ensure compliance with any exchange control obligations arising from Employee’s participation in the Plan.

AUSTRALIA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Australian Addendum.

Employee’s right to participate in the Plan and receive Restricted Stock Units granted under the Plan are subject to an Australian Addendum to the Plan. Employee’s right to receive Restricted Stock Units is subject to the terms and conditions as stated in the Australian Addendum, the specific relief instrument granted by the Australian Securities and Investment Commission, the Plan and the Agreement.

Exchange Control Information.

Exchange control reporting is required for cash transactions exceeding AUD10,000 and for international fund transfers. The Australian bank assisting with the transaction will file the report for Employee. If there is no Australian bank involved in the transfer, Employee will have to file the report.

Securities Law Information.

If Employee acquires shares of Stock under the Plan and offers the shares of Stock for sale to a person or entity resident in Australia, the offer may be subject to disclosure requirements under Australian law. Employee should obtain legal advice on disclosure obligations prior to making any such offer.

AZERBAIJAN

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Securities Law Information.

Shares of Stock to be issued when Employee vests in his or her Restricted Stock Units shall be delivered to Employee through a bank or brokerage account in the U.S. Any disposition or sale of such Stock must take place outside Azerbaijan, which will be the case if the shares of Stock are sold on the New York Stock Exchange on which shares of Stock are currently listed.

BRAZIL

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Compliance with Laws.

By accepting the Restricted Stock Units, Employee agrees that he or she will comply with Brazilian law when he or she vests in the Restricted Stock Units and sells shares of Stock. Employee also agrees to report any and all taxes associated with the vesting of the Restricted Stock Units, the sale of shares of Stock acquired pursuant to the Plan and the receipt of any dividends.

Exchange Control Information.

Employee must prepare and submit a declaration of assets and rights held outside Brazil to the Central Bank on an annual basis if he or she holds assets or rights valued at more than US$100,000. The assets and rights that must be reported include shares of Stock.

CANADA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Restricted Stock Units Payable Only in Stock.

Notwithstanding any discretion in the Plan or anything to the contrary in the Agreement, the award of Restricted Stock Units does not provide any right for Employee to receive a cash payment and shall be paid in shares of Stock only.

Foreign Account/Asset Tax Reporting Information.

Employee may be required to report his or her foreign property on Form T1135 (Foreign Income Verification Statement) if the total cost of his or her foreign property exceeds C$100,000 at any time in the year. Foreign property includes shares of Stock acquired under the Plan.

The following provisions shall apply if Employee is a resident of Quebec:

Termination of Employment.

The following provision supplements Paragraph 2 of the Agreement:

In the event of Employee’s termination of employment for any reason (whether or not in breach of local labor laws), unless otherwise provided in this Agreement or the Plan, Employee’s right to vest in the Restricted Stock Units, if any, will terminate effective as of the date that is the earlier of (1) the date upon which Employee’s employment with the Company or any of its Subsidiaries is terminated; (2) the date Employee is no longer actively providing services to the Company or any of its Subsidiaries; or (3) the date Employee receives written notice of termination of employment from the Employer, regardless of any notice period or period of pay in lieu of such notice required under applicable laws (including, but not limited to statutory law, regulatory law and/or common law); the Company shall have the exclusive discretion to determine when the Employee is no longer actively employed for purposes of the Restricted Stock Units (including whether Employee may be considered to be providing services while on a leave of absence).

Data Privacy.

This provision supplements Paragraph 6 of the Agreement:

Employee hereby authorizes the Company and representatives of any Subsidiary to discuss with and obtain all relevant information from all personnel, professional or not, involved in the administration and operation of the Plan. Employee further authorizes the Company and any Subsidiary and the administrators of the Plan to disclose and discuss the Plan with their advisors. Employee further authorizes the Company and any Subsidiary to record such information and to keep such information in Employee’s file.

Language Consent.

The parties acknowledge that it is their express wish that the Agreement, including this Addendum, as well as all documents, notices and legal proceedings entered into, given or instituted pursuant hereto or relating directly or indirectly hereto, be drawn up in English.

Consentement relatif à la langue utilisée. Les parties reconnaissent avoir expressément souhaité que la convention («Agreement») ainsi que cette Annexe, ainsi que tous les documents, avis et procédures judiciares, éxécutés, donnés ou intentés en vertu de, ou liés directement ou indirectement à la présente convention, soient rédigés en langue anglaise.‬

CHINA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

The following provisions apply if Employee is subject to the exchange control regulations in China, as determined by the Company in its sole discretion:

Settlement of Restricted Stock Units and Sale of Stock.

Due to local regulatory requirements, upon vesting of the Restricted Stock Units, Employee agrees to the immediate sale of any shares of Stock to be issued to him or her upon vesting and settlement of the Restricted Stock Units. Employee further agrees that the Company is authorized to instruct its designated broker to assist with the mandatory sale of such shares of Stock (on Employee’s behalf pursuant to this authorization) and Employee expressly authorizes the Company’s designated broker to complete the sale of such shares of Stock. Employee acknowledges that the Company’s designated broker is under no obligation to arrange for the sale of shares of Stock at any particular price. Upon sale of shares of Stock, the Company agrees to pay Employee the cash proceeds from the sale of shares of Stock, less any brokerage fees or commissions and subject to any obligation to satisfy the Tax-Related Items.

Exchange Control Information.

Employee understands and agrees that, to facilitate compliance with exchange control requirements, Employee will be required to immediately repatriate to China the cash proceeds from the immediate sale of shares of Stock issued upon the vesting of the Restricted Stock Units. Employee further understands that, under local law, such repatriation of the cash proceeds may need to be effectuated through a special exchange control account established by the Company or its Subsidiaries, and Employee hereby consents and agrees that the proceeds from the sale of shares of Stock acquired under the Plan may be transferred to such special account prior to being delivered to Employee. The Company may deliver the proceeds to Employee in U.S. dollars or local currency at the Company’s discretion. If the proceeds are paid in U.S. dollars, Employee understands that he or she will be required to set up a U.S. dollar bank account in China so that the proceeds may be deposited into this account. If the proceeds are converted to local currency, there may be delays in delivering the proceeds to Employee and due to fluctuations in the Stock trading price and/or the U.S. dollar/PRC exchange rate between the vesting/sale date and (if later) when the sale proceeds can be converted into local currency, the sale proceeds that Employee receives may be more or less than the market value of the shares of Stock on the vesting/sale date (which is the amount relevant to determining Employee’s tax liability). Employee agrees to bear the risk of any currency fluctuation between the date the Restricted Stock Units vest and the date of conversion of the proceeds into local currency.

Employee further agrees to comply with any other requirements that may be imposed by the Company in the future to facilitate compliance with exchange control requirements in China.

INDIA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Exchange Control Information.

Employee must repatriate the proceeds from the sale of shares of Stock and any dividends received in relation to the shares of Stock and convert the proceeds into local currency within a reasonable timeframe (i.e., within 90 days of receipt). Employee will receive a foreign inward remittance certificate (“FIRC”) from the bank where Employee deposits the foreign currency. Employee should maintain the FIRC received from the bank as evidence of the repatriation of the funds in the event that the Reserve Bank of India or the Employer requests proof of repatriation. It is Employee’s responsibility to comply with applicable exchange control laws in India.

Foreign Account/Asset Tax Reporting Information.

Employee is required to declare in his or her annual tax return (a) any foreign assets held by him or her or (b) any foreign bank accounts for which he or she has signing authority.

INDONESIA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Exchange Control Information.

If Employee remits funds into or out of Indonesia, the Indonesian Bank through which the transaction is made will submit a report on the transaction to the Bank of Indonesia for statistical reporting purposes. For transactions of US$10,000 or more, a description of the transaction must be included in the report. Although the bank through which the transaction is made is required to make the report, Employee must complete a “Transfer Report Form.” The Transfer Report Form will be provided to Employee by the bank through with the transaction is to be made.

IRAQ

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

There are no country-specific provisions.

ITALY

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Data Privacy Notice.

This section replaces Paragraph 6 of the Agreement.

Employee understands that the Employer, the Company and any Subsidiary may hold certain personal information about Employee, including, but not limited to, Employee’s name, home address and telephone number, date of birth, social insurance (to the extent permitted under Italian law) or other identification number, salary, nationality, job title, any shares of Stock or directorships held in the Company or any Subsidiary, details of all Restricted Stock Units or other entitlement to shares of Stock granted, awarded, canceled, exercised, vested, unvested or outstanding in Employee’s favor, for the exclusive purpose of implementing, managing and administering the Plan (“Data”).

Employee also understands that providing the Company with Data is necessary for the performance of the Plan and that Employee’s refusal to provide such Data would make it impossible for the Company to perform its contractual obligations and may affect Employee’s ability to participate in the Plan. The Controller of personal data processing is KBR Inc., with registered offices at 601 Jefferson Street, Suite 3400, Houston, Texas 77002, U.S.A, and, pursuant to Legislative Decree no. 196/2003, its representative in Italy is Kellogg Brown & Root Projects Limited, with registered offices at Deloitte & Touche, Via Tortona 25, Milan, Italy.

Employee understands that Data will not be publicized, but it may be transferred to banks, other financial institutions, or brokers involved in the management and administration of the Plan. Employee understands that Data may also be transferred to the Company’s stock plan service provider, Morgan Stanley Smith Barney, or such other administrator that may be engaged by the Company in the future. Employee further understands that the Company and/or any Subsidiary will transfer Data among themselves as necessary for the purpose of implementing, administering and managing Employee’s participation in the Plan, and that the Company and/or any Subsidiary may each further transfer Data to third parties assisting the Company in the implementation, administration, and management of the Plan. Such recipients may receive, possess, use, retain, and transfer Data in electronic or other form, for the purposes of implementing, administering, and managing Employee’s participation in the Plan. Employee understands that these recipients may be located in or outside theEuropean Economic Area, such as in the United States or elsewhere. Should the Company exercise its discretion in suspending all necessary legal obligations connected with the management and administration of the Plan, it will delete Data as soon as it has completed all the necessary legal obligations connected with the management and administration of the Plan.

Employee understands that Data-processing related to the purposes specified above shall take place under automated or non-automated conditions, anonymously when possible, that comply with the purposes for which Data is collected and with confidentiality and security provisions, as set forth by applicable laws and regulations, with specific reference to Legislative Decree no. 196/2003.

The processing activity, including communication, the transfer of Data abroad, including outside of the European Economic Area, as herein specified and pursuant to applicable laws and regulations, does not require Employee’s consent thereto as the processing is necessary to performance of contractual obligations related to implementation, administration, and management of the Plan. Employee understands that, pursuant to Section 7 of the Legislative Decree no. 196/2003, Employee has the right to, including but not limited to, access, delete, update, correct, or terminate, for legitimate reason, the Data processing. Furthermore, Employee is aware that Data will not be used for direct marketing purposes. In addition, Data provided can be reviewed and questions or complaints can be addressed by contacting Employee’s local human resources representative.

Plan Document Acknowledgment.

In accepting the Restricted Stock Units, Employee acknowledges that he or she has received a copy of the Plan and the Agreement and has reviewed the Plan and the Agreement, including this Addendum, in their entirety and fully understands and accepts all provisions of the Plan and the Agreement, including this Addendum. Employee further acknowledges that he or she has read and specifically and expressly approves the following Paragraphs of the Agreement: Paragraph 2: Terms of the Restricted Stock Units; Paragraph 3: Responsibility for Taxes; Paragraph 4: Employment Relationship; Paragraph 7: Nature of Grant; Paragraph 10: Compliance with Law; Paragraph 12: Governing Law and Venue; Paragraph 14: Insider Trading/Market Abuse Laws; Paragraph 15: Electronic Delivery and Acceptance; Paragraph 16: Severability; Paragraph 18: Addendum; Paragraph 19: Imposition of Other Requirements and the Data Privacy Notice in this Addendum.

Foreign Account/Asset Tax Reporting Information.

Starting from tax returns filed in 2014 for fiscal year 2013, if Employee is an Italian resident who, at any time during the fiscal year, holds foreign financial assets (including cash and shares of Stock) which may generate income taxable in Italy, Employee is required to report these assets on his or her annual tax return for the year during which the assets are held, or on a special form if no tax return is due. These reporting obligations also apply if Employee is the beneficial owner of foreign financial assets under Italian money laundering provisions.

Foreign Financial Assets Tax Information.

As from 2011, Italian residents may be subject to tax on the value of financial assets held outside of Italy. The taxable amount will be the fair market value of the financial assets. The fair market value is considered to be the value of the shares of Stock on the stock market on December 31 of each year or on the last day of holding the shares of Stock (in such case, or when the shares of Stock are acquired during the course of the year, the tax is levied in proportion to the actual days of holding over the calendar year).

JAPAN

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Foreign Account/Asset Tax Reporting Information.

If Employee is a resident of Japan or a foreign national who has established permanent residency in Japan, Employee will be required to report details of any assets (including any Stock acquired under the Plan) held outside Japan as of December 31st of each year, to the extent such assets have a total net fair market value exceeding ¥50,000,000. Such report will be due by March 15th of the following year. The penalty for fraudulent reporting is imprisonment up to one year or a fine up to ¥500,000. Employee should consult with his or her personal tax advisor as to whether the reporting obligation applies to him or her and whether he or she will be required to report details of any outstanding Restricted Stock Units or shares of Stock held by him or her in the report.

KAZAKHSTAN

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Exchange Control Information.

If Employee is a resident of Kazakhstan, he or she will be required to notify the National Bank of Kazakhstan if the value of the shares of Stock upon vesting of the Restricted Stock Units exceeds US$100,000. Employee is responsible for complying with applicable exchange control regulations in Kazakhstan. As the exchange control regulations in Kazakhstan may change without notice, Employee should consult a legal advisor to ensure compliance with the regulations.

KOREA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Exchange Control Information.

Exchange control laws require Korean residents who realize US$500,000 or more from the sale of shares of Stock or receipt of dividends in a single transaction are required to repatriate the proceeds to Korea within 18 months of receipt.

Foreign Account/Asset Tax Reporting Information.

Employee will be required to declare all foreign accounts (i.e., non-Korean bank accounts, brokerage accounts, etc.) to the Korean tax authorities and file a report if the monthly balance of such accounts exceeds a certain limit (currently KRW 1 billion or an equivalent amount in foreign currency).

MEXICO

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Acknowledgement of the Agreement.

In accepting the award of Restricted Stock Units, Employee acknowledges that Employee has received a copy of the Plan, has reviewed the Plan and the Agreement in their entirety and fully understands and accepts all provisions of the Plan and the Agreement. Employee further acknowledges that Employee has read and specifically and expressly approves the terms and conditions of Paragraph 7 of the Agreement, in which the following is clearly described and established:

(1) Employee’s participation in the Plan does not constitute an acquired right.

(2) The Plan and Employee’s participation in the Plan are offered by the Company on a wholly discretionary basis.

(3) Employee’s participation in the Plan is voluntary.

(4) The Company and its Subsidiaries are not responsible for any decrease in the value of the underlying Shares.

Labor Law Acknowledgement and Policy Statement.

In accepting the award of Restricted Stock Units, Employee expressly recognizes that KBR, Inc., with registered offices at 601 Jefferson Street, Suite 3400, Houston, Texas 77002, U.S.A., is solely responsible for the administration of the Plan and that Employee’s participation in the Plan and acquisition of shares of Stock does not constitute an employment relationship between Employee and KBR, Inc. since Employee is participating in the Plan on a wholly commercial basis and Employee’s sole employer is KBR in Mexico (“KBR-Mexico”), not KBR, Inc. in the U.S. Based on the foregoing, Employee expressly recognizes that the Plan and the benefits that Employee may derive from participation in the Plan do not establish any rights between Employee and Employee’s employer, KBR-Mexico, and do not form part of the employment conditions and/or benefits provided by KBR-Mexico and any modification of the Plan or its termination shall not constitute a change or impairment of the terms and conditions of Employee’s employment.

Employee further understands that Employee’s participation in the Plan is as a result of a unilateral and discretionary decision of KBR, Inc.; therefore, KBR, Inc. reserves the absolute right to amend and/or discontinue Employee’s participation at any time without any liability to Employee.

Finally, Employee hereby declares that Employee does not reserve to Employee any action or right to bring any claim against KBR, Inc. for any compensation or damages regarding any provision of the Plan or the benefits derived under the Plan, and Employee therefore grants a full and broad release to KBR, Inc., its Subsidiary, branches, representation offices, its shareholders, officers, agents or legal representatives with respect to any claim that may arise.

Reconocimiento del Convenio.

Aceptando este Premio(Award), el Participante (Employee) reconoce que ha recibido una copia del Plan, que lo ha revisado como así también el Convenio en su totalidad, y comprende y está de acuerdo con todas las disposiciones tanto del Plan como del Convenio. Asimismo, el Participante reconoce que ha leído y específicamente y expresamente manifiesta la conformidad del Participante con los términos y condiciones establecidos en la cláusula 7 de dicho Convenio, en el cual se establece claramente que:

(1) La participación del Participante en el Plan de ninguna manera constituye un derecho adquirido.

(2) Que el Plan y la participación del Participante en el mismo es una oferta por parte de KBR, Inc. de forma completamente discrecional.

(3) Que la participación del Participante en el Plan es voluntaria.

(4) Que KBR, Inc. y sus Entidades Relacionadas no son responsables por cualquier pérdida en el valor de el Premio y/o Acciones otorgadas mediante el Plan.

Reconocimiento de Ausencia de Relación Laboral y Declaración de la Política.

Aceptando este Premio, el Participante reconoce que KBR, Inc. y sus oficinas registradas en 601 Jefferson Street, Suite 3400, Houston, Texas 77002, U.S.A., es el único responsable de la administración del Plan y que la participación del Participante en el mismo y la adquisicion de Acciones no constituye de ninguna manera una relación laboral entre el Participante y KBR, Inc., toda vez que la participación del Participante en el Plan deriva únicamente de una relación comercial con KBR, Inc., reconociendo expresamente que el único empleador del Participante lo es KBR en Mexico(“KBR-Mexico”), no es KBR, Inc. en los Estados Unidos.Derivado de lo anterior, el Participante expresamente reconoce que el Plan y los beneficios que pudieran derivar del mismo no establecen ningún derecho entre el Participante y su empleador, KBR-México, y no forman parte de las condiciones laborales y/o prestaciones otorgadas por KBR-México, y expresamente el Participante reconoce que cualquier modificación al Plan o la terminación del mismo de manera alguna podrá ser interpretada como una modificación de los condiciones de trabajo del Participante.

Asimismo, el Participante entiende que su participación en el Plan es resultado de la decisión unilateral y discrecional de KBR, Inc., por lo tanto, KBR, Inc. se reserva el derecho absoluto para modificar y/o terminar la participación del Participante en cualquier momento, sin ninguna responsabilidad para el Participante.

Finalmente, el Participante manifiesta que no se reserva ninguna acción o derecho que origine una demanda en contra de KBR, Inc., por cualquier compensación o daño en relación con cualquier disposición del Plan o de los beneficios derivados del mismo, y en consecuencia el Participante otorga un amplio y total finiquito a KBR, Inc., sus Entidades Relacionadas, afiliadas, sucursales, oficinas de representación, sus accionistas, directores, agentes y representantes legales con respecto a cualquier demanda que pudiera surgir.

NIGERIA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

There are no country specific provisions.

PHILIPPINES

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Securities Law Information.

The sale or disposal of shares of Stock acquired under the Plan may be subject to certain restrictions under Philippine securities laws. Those restrictions should not apply if the offer and resale of the shares of Stock takes place outside of the Philippines through the facilities of a stock exchange on which the shares of Stock are listed. The shares of Stock currently are listed on the New York Stock Exchange in the United States of America.

QATAR

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

There are no country specific provisions.

RUSSIA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

U.S. Transaction.

Any shares of Stock issued pursuant to the Restricted Stock Units shall be delivered to Employee through a brokerage account in the U.S. Employee may hold shares of Stock in Employee’s brokerage account in the U.S.; however, in no event will shares of Stock issued to Employee and/or share certificates or other instruments be delivered to Employee in Russia. Employee is not permitted to make any public advertising or announcements regarding the Restricted Stock Units in Russia, or promote these to other Russian legal entities or individuals, and Employee is not permitted to sell or otherwise dispose of shares of Stock directly to other Russian legal entities or individuals. Employee is permitted to sell shares of Stock only on the New York Stock Exchange and only through a U.S. broker.

Exchange Control Information.

Within a reasonably short time after the sale of shares of Stock, the cash proceeds must be initially credited to Employee through a foreign currency account at an authorized bank in Russia. After the cash proceeds are initially received in Russia, they may be further remitted to foreign banks subject to the following limitations: (i) the foreign account may be opened only for individuals; (ii) the foreign account may not be used for business activities; and (iii) the Russian tax authorities must be given notice about the opening/closing of each foreign account within one month of the account opening/closing. Employee is encouraged to contact his or her personal advisor before remitting proceeds from participation in the Plan to Russia, as exchange control requirements may change.

Securities Law Information.

Employee acknowledges that the Agreement, the grant of the Restricted Stock Units, the Plan and all other materials Employee may receive regarding participation in the Plan do not constitute advertising or an offering of securities in Russia. Absent any requirement under local law, the issuance of securities pursuant to the Plan has not and will not be registered in Russia and therefore, the securities described in any Plan-related documents may not be used for offering or public circulation in Russia.

Termination of Employment.

If Employee continues to hold shares of Stock acquired at vesting of the Restricted Stock Units after an involuntary termination of employment, Employee will not be eligible to receive unemployment benefits in Russia.

Data Privacy Notice and Consent.

The following provisions supplement Paragraph 6: Data Privacy Notice and Consent provision in the Agreement and to the extent inconsistent, the below language for Russia supersedes Paragraph 6: Data Privacy Notice and Consent:

Employee understands and agrees that the Company may require Employee to complete and return a Consent to Processing of Personal Data form (the “Consent”) to the Company. If a Consent is required by the Company but Employee fails to provide such Consent to the Company, Employee understands and agrees that the Company will not be able to administer or maintain the Option or any other awards. Therefore, Employee understands that refusing to complete any required Consent or withdrawing his or her consent may affect Employee’s ability to participate in the Plan. For more information on any required Consent or withdrawal of consent, Employee understands he or she may contact the U.S. human resources representative/U.S. stock administration.

SAUDI ARABIA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Securities Law Information.

This document may not be distributed in the Kingdom of Saudi Arabia except to such persons as are permitted under the Offers of Securities Regulations issued by the Capital Market Authority.

The Capital Market Authority does not make any representation as to the accuracy or completeness of this document, and expressly disclaims any liability whatsoever for any loss arising from, or incurred in reliance upon, any part of this document. Prospective purchasers of securities offered hereby should conduct their own due diligence on the accuracy of the information relating to the securities. If Employee does not understand the contents of this document, Employee should consult his or her own advisor or an authorized financial advisor.

SINGAPORE

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Restricted Stock Units Payable Only in Stock.

Notwithstanding any discretion in the Plan or anything to the contrary in the Agreement, the Restricted Stock Units do not provide any right for Employee to receive a cash payment and shall be paid in shares of Stock only.

Securities Law Information.

The grant of Restricted Stock Units is being made in reliance of section 273(1)(f) of the Securities and Futures Act (Chap. 289) (“SFA”) for which it is exempt from the prospectus and registration requirements under the SFA and is not made to Employee with a view of the Restricted Stock Units being subsequently offered to any other party. The Plan has not been lodged or registered as a prospectus with the Monetary Authority of Singapore. Employee should note that the Restricted Share Units are subject to section 257 of the SFA and Employee will not be able to make (i) any subsequent sale of the shares of Stock in Singapore or (ii) any offer of such subsequent sale of the shares of Stock subject to the Restricted Share Units in Singapore, unless such sale or offer in is made pursuant to the exemptions under Part XIII Division (1) Subdivision (4) (other than section 280) of the SFA.

Director Notification Information.

If Employee is a director of a Singapore Subsidiary, Employee must notify the Singapore Subsidiary in writing within two business days of Employee receiving or disposing of an interest (e.g., Restricted Stock Units, shares of Stock) in the Company or any Subsidiary or within two business days of Employee becoming a director if such an interest exists at the time. This notification requirement also applies to an associate director of the Singapore Subsidiary and to a shadow director of the Singapore Subsidiary (i.e., an individual who is not on the board of directors of the Singapore Subsidiary but who has sufficient control so that the board of directors of the Singapore Subsidiary acts in accordance with the “directions and instructions” of the individual).

SOUTH AFRICA

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Tax Withholding Notification.

By Employee’s acceptance of the Restricted Stock Units and the Agreement, Employee agrees to notify his or her Employer of the amount of Employee’s gain at vesting. Once the notification is made, Employee’s Employer will obtain a directive from the South African Revenue Service as to the correct amount of tax to be withheld. If Employee fails to advise Employee’s employer of any gain Employee receives, Employee may be liable for a fine. Employee will be responsible for paying any difference between the actual tax liability and the amount withheld.

Exchange Control Information.

Employee is solely responsible for complying with applicable South African exchange control regulations.Because the exchange control regulations change frequently and without notice, Employee should consult Employee’s legal advisor prior to the acquisition or sale of shares of Stock under the Plan to ensure compliance with current regulations. It is Employee’s responsibility to comply with South African exchange control laws, and neither the Company nor the Employer will be liable for any fines or penalties resulting from failure to comply with applicable laws.

SWEDEN

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

There are no country specific provisions.

THAILAND

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Exchange Control Information.

If proceeds from the sale of shares of Stock or the receipt of dividends are equal to or greater than US$50,000 or more in a single transaction, Employee must repatriate the proceeds to Thailand immediately upon receipt and convert the funds to Thai Baht or deposit the proceeds in a foreign currency deposit account maintained by a bank in Thailand within 360 days of repatriation. In addition, Employee must report the inward remittance to the Bank of Thailand on a foreign exchange transaction form. If Employee fails to comply with these obligations, he or she may be subject to penalties assessed by the Bank of Thailand. Because exchange control regulations change frequently and without notice, Employee should consult his or her personal advisor before selling shares of Stock to ensure compliance with current regulations. Employee is responsible for ensuring compliance with all exchange control laws in Thailand and neither the Company nor any of its Subsidiaries will be liable for any fines or penalties resulting from his or her failure to comply with applicable laws.

TURKEY

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Securities Law Information.

Employee understands and agrees that he or she is not permitted to sell any shares of Stock acquired under the Plan in Turkey. The shares of Stock are currently traded on the New York Stock Exchange, which is located outside of Turkey, under the ticker symbol “KBR” and the shares of Stock may be sold through this exchange.

Exchange Control Information.

Turkish residents are permitted to acquire or sell securities or derivatives traded on foreign (i.e., non-Turkish) exchanges only through a financial intermediary licensed in Turkey. Therefore, Employee may be required to appoint a Turkish broker to assist Employee with the sale of any shares of Stock acquired under the Plan. Employee should consult his or her personal legal advisor before selling any shares of Stock acquired under the Plan to confirm the applicability of this requirement to Employee.

UNITED ARAB EMIRATES

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Securities Law Information.

The Plan is only being offered to qualified Employees and is in the nature of providing equity incentives to employees of the Company’s affiliate in the United Arab Emirates (“UAE”). Any documents related to the Plan, including the Plan, Plan prospectus and other grant documents (“Plan Documents”), are intended for distribution only to such Employees and must not be delivered to, or relied on by, any other person. Prospective stockholders should conduct their own due diligence on the securities. If Employee does not understand the contents of the Plan Documents, Employee should consult an authorized financial adviser.

The Emirates Securities and Commodities Authority has no responsibility for reviewing or verifying any Plan Documents nor taken steps to verify the information set out in them, and thus, are not responsible for such documents.

UNITED KINGDOM

KBR, INC. 2006 STOCK AND INCENTIVE PLAN

Withholding of Taxes.

The section supplements Paragraph 3 of the Agreement.

Notwithstanding Paragraph 3 of the Agreement, Employee agrees that if he or she do not pay or the Employer or the Company does not withhold from Employee the full amount of Tax-Related Items that Employee owes due to the vesting of the Restricted Stock Units, or the release or assignment of the Restricted Stock Units for consideration, or the receipt of any other benefit in connection with the Restricted Stock Units (the “Taxable Event”) within 90 days after the Taxable Event, or such other period specified in Section 222(1)(c) of the U.K. Income Tax (Earnings and Pensions) Act 2003, then the amount of income tax that should have been withheld shall constitute a loan owed by Employee to the Employer, effective 90 days after the Taxable Event. Employee agrees that the loan will bear interest at Her Majesty’s Revenue & Customs (“HMRC”) official rate and will be immediately due and repayable by Employee, and the Company and/or the Employer may recover it at any time thereafter by withholding the funds from salary, bonus or any other funds due to Employee by the Employer, by withholding in shares of Stock issued upon vesting and settlement of the Restricted Stock Units or from the cash proceeds from the sale of shares of Stock or by demanding cash or a cheque from Employee. Employee also authorizes the Company to delay the issuance of any shares of Stock to Employee unless and until the loan is repaid in full.

Notwithstanding the foregoing, if Employee is an officer or executive director (as within the meaning of Section 13(k) of the U.S. Securities and Exchange Act of 1934, as amended), the terms of the immediately foregoing provision will not apply. In the event that Employee is an officer or executive director and the amount necessary to satisfy Tax-Related Items is not collected from or paid by Employee within 90 days of the Taxable Event, any uncollected amounts of income tax may constitute a benefit to Employee on which additional income tax and national insurance contributions may be payable. Employee acknowledges that Employee ultimately will be responsible for reporting and paying any income tax due on this additional benefit directly to HMRC under the self-assessment regime and for reimbursing the Company or the Employer (as appropriate) for the value of any national insurance contributions due on this additional benefit. Employee acknowledges that the Company or the Employer may recover any such additional income tax and national insurance contributions at any time thereafter by any of the means referred to in Paragraph 3 of the Agreement.

1

EX-10.3

US EMPLOYEE – 3-Year Vesting with Involuntary Termination Trigger

RESTRICTED STOCK UNIT AGREEMENT

AGREEMENT by and between KBR, Inc., a Delaware corporation (the “Company”), and _________________________ (“Employee”) made effective as of _________________ (the “Grant Date”).

1.Grant of Restricted Stock Units.

(a)Units. Pursuant to the KBR, Inc. 2006 Stock and Incentive Plan, as amended and restated (the “Plan”), units evidencing the right to receive _________ shares of the Company’s common stock (“Stock”), are awarded to Employee, subject to the conditions of the Plan and this Agreement (the “Restricted Stock Units”).

(b)Plan Incorporated. Employee acknowledges receipt of a copy of the Plan, and agrees that this award of Restricted Stock Units shall be subject to all of the terms and conditions set forth in the Plan, including future amendments thereto, if any, pursuant to the terms thereof, which is incorporated herein by reference as a part of this Agreement. Except as defined herein, capitalized terms shall have the same meanings ascribed to them under the Plan.

2.Terms of Restricted Stock Units. Employee hereby accepts the Restricted Stock Units and agrees with respect thereto as follows:

(a)Forfeiture of Restricted Stock Units. In the event of termination of Employee’s employment with the Company or any employing Subsidiary of the Company for any reason other than (i) an Involuntary Termination (as such term is defined in that certain Severance and Change in Control Agreement dated effective _________________, by and among Employee, the Company and KBR Technical Services, Inc. (the “Severance Agreement”)), (ii) normal retirement on or after age 70, or (iii) Death or Disability (as such term is defined in the Severance Agreement), or except as otherwise provided in the second and third sentences of subparagraph (c) of this Paragraph 2, Employee shall, for no consideration, forfeit all Restricted Stock Units to the extent they are not fully vested.

(b)Assignment of Award. The Restricted Stock Units may not be sold, assigned, pledged, exchanged, hypothecated or otherwise transferred, encumbered or disposed of unless transferable by will or the laws of descent and distribution or pursuant to a “qualified domestic relations order” as defined by the U.S. Internal Revenue Code (the “Code”).

(c)Vesting Schedule. The Restricted Stock Units shall vest in accordance with the following schedule provided that Employee has been continuously employed by the Company from the date of this Agreement through the applicable vesting date.

Vesting Date	Vested Percentage of Total Number of Restricted Stock Units
First Anniversary of Grant Date	33 ⅓%
Second Anniversary of Grant Date	66 ⅔%
Third Anniversary of Grant Date	100%

Notwithstanding the foregoing, unless otherwise provided in an Other Agreement pursuant to Paragraph 8, the Restricted Stock Units shall become fully vested on the earliest of (i) the occurrence of Employee’s Involuntary Termination (as such term is defined in the Severance Agreement), (ii) the occurrence of Employee’s termination for Good Reason within two years following a Change in Control (as such terms are defined in the Severance Agreement), (iii) the date Employee’s employment with the Company is terminated by reason of Death or Disability (as such term is defined in the Severance Agreement), or (iv) Employee’s attainment of age 70 while employed with the Company. In the event Employee’s employment is terminated for any other reason, including retirement prior to age 70 with the approval of the Company or employing Subsidiary, the Committee which administers the Plan (the “Committee”) or its delegate, as appropriate, may, in the Committee’s or such delegate’s sole discretion, approve the acceleration of the vesting of any or all Restricted Stock Units still subject to restrictions, such vesting acceleration to be effective on the date of such approval or Employee’s termination date, if later. Notwithstanding the foregoing, in no event shall the Restricted Stock Units become fully vested prior to the expiration of one month from the Grant Date.

(d)Stockholder Rights. Employee shall have no rights of a stockholder with respect to shares of Stock subject to this Award unless and until such time as the Award has been settled by the transfer of shares of Stock to Employee, except that Employee shall have the right to receive payments equal to the dividends or distributions declared or paid on a share of Stock at the same time as those dividends or distributions are paid to holders of Stock.

(e)Settlement and Delivery of Shares. Payment of vested Restricted Stock Units shall be made as soon as administratively practicable after vesting, but in no event later than thirty days after the vesting date. Settlement will be made by payment in shares of Stock. Notwithstanding the foregoing, the Company shall not be obligated to deliver any shares of Stock if counsel to the Company determines that such sale or delivery would violate any applicable law or any rule or regulation of any governmental authority or any rule or regulation of, or agreement of the Company with, any securities exchange or association upon which the Stock is listed or quoted.

(f)Recovery of Shares. The Company shall seek recovery of any benefits provided hereunder to Employee if such recovery is required by any clawback policy adopted by the Company, which may be amended from time to time, including, but not limited to, any clawback policy adopted to satisfy the minimum clawback requirements adopted under the Dodd-Frank Wall Street Reform and Consumer Protection Act of 2010 and the regulations thereunder or any other applicable law.

3.Withholding of Tax.The Committee may make such provisions as it may deem appropriate for the withholding of any taxes which it determines is required in connection with this Award. Unless the Committee provides otherwise, the Company shall reduce the number of shares of Stock that would have otherwise been delivered to Employee by a number of shares of Stock having a Fair Market Value equal to the amount required to be withheld.

4.Employment Relationship. For purposes of this Agreement, Employee shall be considered to be in the employment of the Company as long as Employee remains an employee of the Company, a Parent Corporation or Subsidiary of the Company, or a corporation or a Parent Corporation or subsidiary of such corporation assuming or substituting a new award for this Award. Any question as to whether and when there has been a termination of such employment, and the cause of such termination, shall be determined by the Committee, or its delegate, as appropriate, and its determination shall be final.

5.Committee’s Powers. No provision contained in this Agreement shall in any way terminate, modify or alter, or be construed or interpreted as terminating, modifying or altering any of the powers, rights or authority vested in the Committee or, to the extent delegated, in its delegate pursuant to the terms of the Plan or resolutions adopted in furtherance of the Plan, including, without limitation, the right to make certain determinations and elections with respect to the Restricted Stock Units.

6.Binding Effect. This Agreement shall be binding upon and inure to the benefit of any successors to the Company and all persons lawfully claiming under Employee.

7.Compliance with Law. Notwithstanding any other provision of the Plan or this Agreement, unless there is an available exemption from any registration, qualification or other legal requirement applicable to the shares of Stock, the Company shall not be required to deliver any shares issuable upon settlement of the Restricted Stock Units prior to the completion of any registration or qualification of the shares under any local, state, federal or foreign securities or exchange control law or under rulings or regulations of the U.S. Securities and Exchange Commission (“SEC”) or of any other governmental regulatory body, or prior to obtaining any approval or other clearance from any local, state, federal or foreign governmental agency, which registration, qualification or approval the Company shall, in its absolute discretion, deem necessary or advisable. Employee understands that the Company is under no obligation to register or qualify the shares with the SEC or any state or foreign securities commission or to seek approval or clearance from any governmental authority for the issuance or sale of the shares. Further, Employee agrees that the Company shall have unilateral authority to amend the Plan and the Agreement without Employee's consent to the extent necessary to comply with securities or other laws applicable to issuance of shares.

8.Other Agreements. The terms of this Agreement shall be subject to, and shall not modify, the terms and conditions of any employment, severance, and/or change-in-control agreement between the Company (or a Subsidiary) and Employee concerning equity-based awards (“Other Agreement”), except that the Restricted Stock Units shall become fully vested on Employee’s attainment of age 70 while employed with the Company or a Subsidiary, and notwithstanding anything in such Other Agreement to the contrary, any normal retirement age of 65 or other retirement-based vesting provisions in such Other Agreement shall be of no force or effect for purposes of the vesting of these Restricted Stock Units.

9.Governing Law and Venue. This Agreement shall be governed by, and construed in accordance with, the laws of the State of Texas, U.S.A., except to the extent that it implicates matters that are the subject of the General Corporation Law of the State of Delaware, which matters shall be governed by the latter law notwithstanding any conflicts of laws principles that may be applied or invoked directing the application of the laws of another jurisdiction. Exclusive venue for any action, lawsuit or other proceedings brought to enforce this Agreement, relating to it or arising from it, or dispute resolution proceeding arising hereunder for any claim or dispute, the parties hereby submit to and consent to the sole and exclusive jurisdiction of Houston, Harris County, Texas, notwithstanding any conflicts of laws principles that may direct the jurisdiction of any other court, venue, or forum, including the jurisdiction of Employee’s home country.

10.Section 409A. Notwithstanding anything in this Agreement to the contrary, if any provision in this Agreement would result in the imposition of an applicable tax under Section 409A of the Code and related regulations and United States Department of the Treasury pronouncements (“Section 409A”), that provision will be reformed to avoid imposition of the applicable tax and no action taken to comply with Section 409A shall be deemed to adversely affect Employee’s rights under this Agreement.

IN WITNESS WHEREOF, the Company has caused this Agreement to be duly executed by an officer thereunto duly authorized, and Employee has executed this Agreement, all as of the date first above written.

KBR, INC.

By:

Employee

1

EX-10.4

US EMPLOYEE – 5-Year Vesting with TSR Requirement

RESTRICTED STOCK UNIT AGREEMENT

AGREEMENT by and between KBR, Inc., a Delaware corporation (the “Company”), and __________________ (“Employee”) made effective as of _______________ (the “Grant Date”).

1.Grant of Restricted Stock Units.

(a)Units. Pursuant to the KBR, Inc. 2006 Stock and Incentive Plan, as amended and restated (the “Plan”), units evidencing the right to receive __________ shares of the Company’s common stock (“Stock”), are awarded to Employee, subject to the conditions of the Plan and this Agreement (the “Restricted Stock Units”).

(b)Plan Incorporated. Employee acknowledges receipt of a copy of the Plan, and agrees that this award of Restricted Stock Units shall be subject to all of the terms and conditions set forth in the Plan, including future amendments thereto, if any, pursuant to the terms thereof, which is incorporated herein by reference as a part of this Agreement. Except as defined herein, capitalized terms shall have the same meanings ascribed to them under the Plan.

2.Terms of Restricted Stock Units. Employee hereby accepts the Restricted Stock Units and agrees with respect thereto as follows:

(a)Forfeiture of Restricted Stock Units. In the event of termination of Employee’s employment with the Company or any employing Subsidiary of the Company for any reason other than (i) normal retirement on or after age 70 or (ii) Death or Disability (as such term is defined in that certain Severance and Change in Control Agreement dated effective _______________, by and among Employee, the Company and KBR Technical Services, Inc. (the “Severance Agreement”)), or except as otherwise provided in the second and third sentences of subparagraph (c) of this Paragraph 2, Employee shall, for no consideration, forfeit all Restricted Stock Units to the extent they are not fully vested.

(b)Assignment of Award. The Restricted Stock Units may not be sold, assigned, pledged, exchanged, hypothecated or otherwise transferred, encumbered or disposed of unless transferable by will or the laws of descent and distribution or pursuant to a “qualified domestic relations order” as defined by the U.S. Internal Revenue Code (the “Code”).

(c)Vesting Schedule. Subject to Paragraph 2(d) below, the Restricted Stock Units shall vest in accordance with the following schedule provided that Employee has been continuously employed by the Company from the date of this Agreement through the applicable vesting date (each such date, a “Vesting Date”):

Vesting Date	Vested Percentage of Total Number of Restricted Stock Units
First Anniversary of Grant Date	20%
Second Anniversary of Grant Date	40%
Third Anniversary of Grant Date	60%
Fourth Anniversary of Grant Date	80%
Fifth Anniversary of Grant Date	100%

Notwithstanding the foregoing or Paragraph 2(d) below, unless otherwise provided in an Other Agreement pursuant to Paragraph 8, the Restricted Stock Units shall become fully vested on the earliest of (i) the occurrence of your Involuntary Termination or termination for Good Reason within two years following a Change in Control (as such terms are defined in the Severance Agreement), (ii) the date Employee’s employment with the Company is terminated by reason of Death or Disability (as such term is defined in the Severance Agreement), or (iii) Employee’s attainment of age 70 while employed with the Company. In the event Employee’s employment is terminated for any other reason, including retirement prior to age 70 with the approval of the Company or employing Subsidiary, the Committee which administers the Plan (the “Committee”) or its delegate, as appropriate, may, in the Committee’s or such delegate’s sole discretion, approve the acceleration of the vesting of any or all Restricted Stock Units still subject to restrictions, such vesting acceleration to be effective on the date of such approval or Employee’s termination date, if later. Notwithstanding the foregoing, in no event shall the Restricted Stock Units become fully vested prior to the expiration of one month from the Grant Date.

(d)Total Shareholder Return. Restricted Stock Units shall not vest on any Vesting Date in accordance with the schedule set forth in the first sentence of Paragraph 2(c) above if the Company’s Total Shareholder Return (the “TSR”) for the 12 full calendar months immediately preceding such Vesting Date is less than 6%. If the TSR for the 12 full calendar months immediately preceding a Vesting Date is less than 6%, then Employee shall, for no consideration, forfeit on such Vesting Date 100% of the Restricted Stock Units that would have otherwise vested on such Vesting Date in accordance with the schedule set forth in the first sentence of Paragraph 2(c) above (to the extent then subject to restrictions). The forfeiture of 100% of the Restricted Stock Units on such Vesting Date shall not affect the vesting of any Restricted Stock Units on future Vesting Dates under this Agreement. For purposes of this Paragraph 2(d), the term “TSR” shall mean, with respect to any 12 full calendar month period, (((A minus B) plus C) divided byB) and multiplied by 100%, where:

A means the Fair Market Value of a share of Stock on the last day of such period;

B means the Fair Market Value of a share of Stock on the day immediately preceding the first day of such period; and

C means the aggregate amount of dividends per share of Stock paid over such period by the Company. Dividends per share of Stock paid other than in the form of cash shall have a value equal to the amount of such dividends reported by the Company to is shareholders for purposes of Federal income taxation.

(e)Stockholder Rights. Employee shall have no rights of a stockholder with respect to shares of Stock subject to this Award unless and until such time as the Award has been settled by the transfer of shares of Stock to Employee; provided, however, that, with respect to each outstanding Restricted Stock Unit that has not become vested or been forfeited, the Company shall credit a book entry account with an amount equal to the amount of any dividends or distributions declared or paid on one share of Stock, and the amount credited to such book entry account shall be payable to Employee at the same time, and subject to the same terms and conditions as are applicable to, the vesting of such Restricted Stock Unit pursuant to Paragraphs 2(c) and (d) above. If a Restricted Stock Unit does not vest pursuant to Paragraphs 2(c) and (d) above and such Restricted Stock Unit is forfeited, then the amount credited to the book entry account described in the preceding sentence that is attributable to such Restricted Stock Unit shall also be forfeited at the time of the forfeiture of such Restricted Stock Unit.

(f)Settlement and Delivery of Shares. Payment of vested Restricted Stock Units shall be made as soon as administratively practicable after vesting, but in no event later than thirty days after the vesting date. Settlement will be made by payment in shares of Stock. Notwithstanding the foregoing, the Company shall not be obligated to deliver any shares of Stock if counsel to the Company determines that such sale or delivery would violate any applicable law or any rule or regulation of any governmental authority or any rule or regulation of, or agreement of the Company with, any securities exchange or association upon which the Stock is listed or quoted.

(g)Recovery of Shares. The Company shall seek recovery of any benefits provided hereunder to Employee if such recovery is required by any clawback policy adopted by the Company, which may be amended from time to time, including, but not limited to, any clawback policy adopted to satisfy the minimum clawback requirements adopted under the Dodd-Frank Wall Street Reform and Consumer Protection Act of 2010 and the regulations thereunder or any other applicable law.

3.Withholding of Tax.The Committee may make such provisions as it may deem appropriate for the withholding of any taxes which it determines is required in connection with this Award. Unless the Committee provides otherwise, the Company shall reduce the number of shares of Stock that would have otherwise been delivered to Employee by a number of shares of Stock having a Fair Market Value equal to the amount required to be withheld.

4.Employment Relationship. For purposes of this Agreement, Employee shall be considered to be in the employment of the Company as long as Employee remains an employee of the Company, a Parent Corporation or Subsidiary of the Company, or a corporation or a Parent Corporation or subsidiary of such corporation assuming or substituting a new award for this Award. Any question as to whether and when there has been a termination of such employment, and the cause of such termination, shall be determined by the Committee, or its delegate, as appropriate, and its determination shall be final.

5.Committee’s Powers. No provision contained in this Agreement shall in any way terminate, modify or alter, or be construed or interpreted as terminating, modifying or altering any of the powers, rights or authority vested in the Committee or, to the extent delegated, in its delegate pursuant to the terms of the Plan or resolutions adopted in furtherance of the Plan, including, without limitation, the right to make certain determinations and elections with respect to the Restricted Stock Units.

6.Binding Effect. This Agreement shall be binding upon and inure to the benefit of any successors to the Company and all persons lawfully claiming under Employee.

7.Compliance with Law. Notwithstanding any other provision of the Plan or this Agreement, unless there is an available exemption from any registration, qualification or other legal requirement applicable to the shares of Stock, the Company shall not be required to deliver any shares issuable upon settlement of the Restricted Stock Units prior to the completion of any registration or qualification of the shares under any local, state, federal or foreign securities or exchange control law or under rulings or regulations of the U.S. Securities and Exchange Commission (“SEC”) or of any other governmental regulatory body, or prior to obtaining any approval or other clearance from any local, state, federal or foreign governmental agency, which registration, qualification or approval the Company shall, in its absolute discretion, deem necessary or advisable. Employee understands that the Company is under no obligation to register or qualify the shares with the SEC or any state or foreign securities commission or to seek approval or clearance from any governmental authority for the issuance or sale of the shares. Further, Employee agrees that the Company shall have unilateral authority to amend the Plan and the Agreement without Employee's consent to the extent necessary to comply with securities or other laws applicable to issuance of shares.

8.Other Agreements. The terms of this Agreement shall be subject to, and shall not modify, the terms and conditions of any employment, severance, and/or change-in-control agreement between the Company (or a Subsidiary) and Employee concerning equity-based awards (“Other Agreement”), except that the Restricted Stock Units shall become fully vested on Employee’s attainment of age 70 while employed with the Company or a Subsidiary, and notwithstanding anything in such Other Agreement to the contrary, any normal retirement age of 65 or other retirement-based vesting provisions in such Other Agreement shall be of no force or effect for purposes of the vesting of these Restricted Stock Units.

9.Governing Law and Venue. This Agreement shall be governed by, and construed in accordance with, the laws of the State of Texas, U.S.A., except to the extent that it implicates matters that are the subject of the General Corporation Law of the State of Delaware, which matters shall be governed by the latter law notwithstanding any conflicts of laws principles that may be applied or invoked directing the application of the laws of another jurisdiction. Exclusive venue for any action, lawsuit or other proceedings brought to enforce this Agreement, relating to it or arising from it, or dispute resolution proceeding arising hereunder for any claim or dispute, the parties hereby submit to and consent to the sole and exclusive jurisdiction of Houston, Harris County, Texas, notwithstanding any conflicts of laws principles that may direct the jurisdiction of any other court, venue, or forum, including the jurisdiction of Employee’s home country.

10.Section 409A. Notwithstanding anything in this Agreement to the contrary, if any provision in this Agreement would result in the imposition of an applicable tax under Section 409A of the Code and related regulations and United States Department of the Treasury pronouncements (“Section 409A”), that provision will be reformed to avoid imposition of the applicable tax and no action taken to comply with Section 409A shall be deemed to adversely affect Employee’s rights under this Agreement.

IN WITNESS WHEREOF, the Company has caused this Agreement to be duly executed by an officer thereunto duly authorized, and Employee has executed this Agreement, all as of the date first above written.

KBR, INC.

By:

Employee

1

EX-31.1

EXHIBIT 31.1

CERTIFICATION OF CHIEF EXECUTIVE OFFICER PURSUANT TO RULE 13A-14(A) AND RULE 15D-14(A) OF THE SECURITIES EXCHANGE ACT OF 1934, AS AMENDED

I, Stuart Bradie, certify that:

1.I have reviewed this quarterly report on Form 10-Q of KBR, Inc. (the “registrant”);

2. Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

3.Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;

4.The registrant’s other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the registrant and have:

a)Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;

b)Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;

c)Evaluated the effectiveness of the registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and

d)Disclosed in this report any change in the registrant’s internal control over financial reporting that occurred during the registrant’s most recent fiscal quarter (the registrant’s fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the registrant’s internal control over financial reporting; and

5.The registrant’s other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant’s auditors and the audit committee of the registrant’s board of directors (or persons performing the equivalent functions):

a)All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant’s ability to record, process, summarize and report financial information; and

b)Any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant’s internal control over financial reporting.

Date: November 3, 2014

/s/ Stuart Bradie

Stuart Bradie

Chief Executive Officer

EX-31.2

EXHIBIT 31.2

CERTIFICATION OF CHIEF FINANCIAL OFFICER PURSUANT TO RULE 13A-14(A) AND RULE 15D-14(A) OF THE SECURITIES EXCHANGE ACT OF 1934, AS AMENDED

I, Brian K. Ferraioli, certify that:

1.I have reviewed this quarterly report on Form 10-Q of KBR, Inc. (the “registrant”);

2. Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

3.Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;

4.The registrant’s other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the registrant and have:

a)Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;

b)Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;

c)Evaluated the effectiveness of the registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and

d)Disclosed in this report any change in the registrant’s internal control over financial reporting that occurred during the registrant’s most recent fiscal quarter (the registrant’s fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the registrant’s internal control over financial reporting; and

5.The registrant’s other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant’s auditors and the audit committee of the registrant’s board of directors (or persons performing the equivalent functions):

a)All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant’s ability to record, process, summarize and report financial information; and

b)Any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant’s internal control over financial reporting.

Date: November 3, 2014

/s/ Brian K. Ferraioli

Brian K. Ferraioli

Chief Financial Officer

EX-32.1

EXHIBIT 32.1

CERTIFICATION OF CHIEF EXECUTIVE OFFICER

UNDER SECTION 906 OF THE SARBANES OXLEY ACT OF 2002, 18 U.S.C 2002

The undersigned, the Chief Executive Officer of KBR, Inc. (the “Company”), hereby certifies that to his knowledge, on the date hereof:

a) the Form 10-Q of the Company for the period ended September 30, 2014, filed on the date hereof with the Securities and Exchange Commission (the “Report”) fully complies with the requirements of Section l3(a) or 15(d) of the Securities Exchange Act of 1934 as amended; and

b) the information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

/s/ Stuart Bradie

Stuart Bradie

Chief Executive Officer

Date: November 3, 2014

EX-32.2

EXHIBIT 32.2

CERTIFICATION OF CHIEF FINANCIAL OFFICER

UNDER SECTION 906 OF THE SARBANES OXLEY ACT OF 2002, 18 U.S.C 2002

The undersigned, the Chief Financial Officer of KBR, Inc. (the “Company”), hereby certifies that to his knowledge, on the date hereof:

a) the Form 10-Q of the Company for the period ended September 30, 2014, filed on the date hereof with the Securities and Exchange Commission (the “Report”) fully complies with the requirements of Section l3(a) or 15(d) of the Securities Exchange Act of 1934 as amended; and

b) the information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

/s/ Brian K. Ferraioli

Brian K. Ferraioli

Chief Financial Officer

Date: November 3, 2014

XML

Cash and Equivalents (Details) (USD $) In Millions, unless otherwise specified																											9 Months Ended
	Sep. 30, 2014	Dec. 31, 2013	Sep. 30, 2013	Dec. 31, 2012	Sep. 30, 2014 Cash [Member]	Dec. 31, 2013 Cash [Member]	Sep. 30, 2014 Bank Time Deposits [Member]	Dec. 31, 2013 Bank Time Deposits [Member]	Sep. 30, 2014 Cash Held in Joint Venture [Member]	Dec. 31, 2013 Cash Held in Joint Venture [Member]	Sep. 30, 2014 International [Member]		Dec. 31, 2013 International [Member]		Sep. 30, 2014 International [Member] Cash [Member]		Dec. 31, 2013 International [Member] Cash [Member]		Sep. 30, 2014 International [Member] Bank Time Deposits [Member]		Dec. 31, 2013 International [Member] Bank Time Deposits [Member]		Sep. 30, 2014 International [Member] Cash Held in Joint Venture [Member]		Dec. 31, 2013 International [Member] Cash Held in Joint Venture [Member]		Sep. 30, 2014 Australia	Sep. 30, 2014 Domestic [Member]		Dec. 31, 2013 Domestic [Member]		Sep. 30, 2014 Domestic [Member] Cash [Member]		Dec. 31, 2013 Domestic [Member] Cash [Member]		Sep. 30, 2014 Domestic [Member] Bank Time Deposits [Member]		Dec. 31, 2013 Domestic [Member] Bank Time Deposits [Member]		Sep. 30, 2014 Domestic [Member] Cash Held in Joint Venture [Member]		Dec. 31, 2013 Domestic [Member] Cash Held in Joint Venture [Member]
Cash and Cash Equivalents [Line Items]
Deferred Tax Liability Not Recognized, Percentage Of Undistributed Earnings Of Foreign Subsidiaries																											50.00%
Tax on undistributed earnings of non-US subsidiaries	$ 0
Cash and equivalents	1,048	1,106	959	1,053	577	412	391	618	80	76	774	[1]	742	[1]	362	[1]	197	[1]	348	[1]	478	[1]	64	[1]	67	[1]		274	[2]	364	[2]	215	[2]	215	[2]	43	[2]	140	[2]	16	[2]	9	[2]
Restricted Cash and Cash Equivalents	$ 17	$ 1

[1] Includes deposits held in non-U.S. operating accounts considered to be permanently reinvested outside the U.S. and for which no incremental U.S. tax has been provisioned or paid

[2] Includes U.S. dollar and foreign currency deposits held in operating accounts that constitute onshore cash for tax purposes but may reside either in the U.S. or in a foreign country

XML

Income Taxes (Reconciliations) (Details)	9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013
Income Tax Disclosure [Abstract]
United States Statutory Rate	35.00%	35.00%
Rate differentials on foreign earnings	(8.50%)	(6.60%)
Taxes on unincorporated joint ventures	(10.10%)	(7.60%)
Effective Income Tax Rate Reconciliation, Taxes on Unconsolidated Affiliates	(10.90%)	(4.60%)
Effective Income Tax Rate Reconciliation, Repatriation of Foreign Earnings, Percent	12.10%	2.20%
State income taxes	0.30%	0.50%
Effective Income Tax Rate Reconciliation, Other Adjustments, Percent	4.40%	3.70%
Effective Income Tax Rate Reconciliation, Estimate, Percent	22.30%	22.60%

XML

Equity Method Investments And Variable Interest Entities (Consolidated Summarized Financial Information) (Details) (USD $) In Millions, unless otherwise specified	Sep. 30, 2014	Dec. 31, 2013
Equity Method Investments and Joint Ventures [Abstract]
Current assets	$ 3,968	$ 4,114
Noncurrent assets	4,212	4,222
Total assets	8,180	8,336
Current liabilities	3,597	3,679
Noncurrent liabilities	4,273	4,400
Equity Method Investment, Summarized Financial Information, Liabilities	$ 7,870	$ 8,079

XML

Income Taxes (Narrative) (Details) (USD $) In Millions, unless otherwise specified	3 Months Ended	9 Months Ended			1 Months Ended	9 Months Ended
	Sep. 30, 2014	Sep. 30, 2014	Sep. 30, 2013	Dec. 31, 2013	Oct. 24, 2013 Halliburton [Member]	Sep. 30, 2014 Australia	Sep. 30, 2013 Halliburton [Member]
Operating Loss Carryforwards [Line Items]
Deferred Tax Liability Not Recognized, Percentage Of Undistributed Earnings Of Foreign Subsidiaries						50.00%
Valuation allowance	$ 118	$ 118		$ 83
Change in valuation allowance	3	35
Unrecognized Tax Benefits	125	125		68
Unrecognized Tax Benefits, Increase Resulting from Prior Period Tax Positions		57
Unrecognized Tax Benefits, Reduction Resulting from Lapse of Applicable Statute of Limitations		5
Effective tax rate	(2.30%)	47.60%	32.00%
Estimated annual effective tax rate		22.30%	22.60%
Effective Income Tax Rate Reconciliation, Other Reconciling Items, Amount			31
Effective Income Tax Rate Reconciliation, Other Adjustments, Amount					38		38
Effective Income Tax Rate Reconciliation, Change in Enacted Tax Rate, Amount			13
Discrete Income Tax Benefit	$ 62

XML

Equity Method Investments And Variable Interest Entities Equity Method Investments and Variable Interest Entities (Schedule of Equity in Earnings of Unconsolidated Affiliates) (Details) (USD $) In Millions, unless otherwise specified	Dec. 31, 2013 Beginning Balance [Member]	Dec. 31, 2012 Beginning Balance [Member]	Sep. 30, 2014 Joint Venture Earnings [Member]	Sep. 30, 2013 Joint Venture Earnings [Member]	Sep. 30, 2014 Dividends Paid by Joint Venture [Member]	Sep. 30, 2013 Dividends Paid by Joint Venture [Member]	Sep. 30, 2014 Advances [Member]	Sep. 30, 2013 Advances [Member]	Sep. 30, 2014 Cumulative Translation Adjustment [Member]	Sep. 30, 2013 Cumulative Translation Adjustment [Member]	Sep. 30, 2014 Subtotal Before Reclassification [Member]	Sep. 30, 2013 Subtotal Before Reclassification [Member]	Sep. 30, 2014 Reclassification of excess distribution [Member]	Sep. 30, 2013 Reclassification of excess distribution [Member]	Sep. 30, 2014 Ending Balance [Member]	Sep. 30, 2013 Ending Balance [Member]
Equity In Earnings of Unconsolidated Affiliates [Line Items]
Equity Method Investments	$ 156	$ 217	$ 118	$ 107	$ (212)	$ (151)	$ (14)	$ (12)	$ (1)	$ (7)	$ 47	$ 154	$ 102	$ 0	$ 149	$ 154

XML

Shareholders' Equity (Tables)

9 Months Ended

Sep. 30, 2014

Sep. 30, 2013

Stockholders' Equity Note [Abstract]

Shareholders' Equity Activities

Dollars in millions	Total			PIC			Retained Earnings			Treasury Stock			AOCL			NCI
Balance at December 31, 2013	$	2,439		$	2,065		$	1,748		$	(610	)	$	(740	)	$	(24	)
Share-based compensation	16			16			—			—			—			—
Common stock issued upon exercise of stock options	4			4			—			—			—			—
Dividends declared to shareholders	(35		)	—			(35		)	—			—			—
Repurchases of common stock	(102		)	—			—			(102		)	—			—
Issuance of ESPP shares	4			—			—			4			—			—
Investments by noncontrolling interests	10			—			—			—			—			10
Distributions to noncontrolling interests	(49		)	—			—			—			—			(49		)
Net income (loss)	33			—			(21		)	—			—			54
Other comprehensive income (loss), net of tax	(3		)	—			—			—			(4		)	1
Balance at September 30, 2014	$	2,317		$	2,085		$	1,692		$	(708	)	$	(744	)	$	(8	)
Dollars in millions	Total			PIC			Retained Earnings			Treasury Stock			AOCL			NCI
Balance at December 31, 2012	$	2,511		$	2,049		$	1,709		$	(606	)	$	(610	)	$	(31	)
Share-based compensation	13			13			—			—			—			—
Common stock issued upon exercise of stock options	5			5			—			—			—			—
Adjustment pursuant to Accounting Referee's report on tax sharing agreement	(7		)	(7		)	—			—			—			—
Dividends declared to shareholders	(24		)	—			(24		)	—			—			—
Repurchases of common stock	(7		)	—			—			(7		)	—			—
Issuance of ESPP shares	4			1			—			3			—			—
Investments by noncontrolling interests	9			—			—			—			—			9
Distributions to noncontrolling interests	(58		)	—			—			—			—			(58		)
Change in NCI due to consolidation of previously unconsolidated JV and other transactions	2			—			—			—			—			2
Net income	223			—			131			—			—			92
Other comprehensive income (loss), net of tax	(8		)	—			—			—			(15		)	7
Balance at September 30, 2013	$	2,663		$	2,061		$	1,816		$	(610	)	$	(625	)	$	21

Accumulated Other Comprehensive Income (Loss)

Changes in accumulated other comprehensive loss, net of tax, by component

Dollars in millions	Accumulated CTA			Accumulated pension liability adjustments			Accumulated unrealized losses on derivatives			Total
Balance at December 31, 2013	$	(131	)	$	(608	)	$	(1	)	$	(740	)
Other comprehensive income (loss) adjustments before reclassifications	(28		)	—			(1		)	(29		)
Amounts reclassified from accumulated other comprehensive income (loss)	1			25			(1		)	25
Balance at September 30, 2014	$	(158	)	$	(583	)	$	(3	)	$	(744	)

Dollars in millions	Accumulated CTA			Accumulated pension liability adjustments			Accumulated unrealized losses on derivatives			Total
Balance at December 31, 2012	$	(88	)	$	(521	)	$	(1	)	$	(610	)
Other comprehensive income (loss) adjustments before reclassifications	(36		)	—			—			(36		)
Amounts reclassified from accumulated other comprehensive income (loss)	1			20			—			21
Balance at September 30, 2013	$	(123	)	$	(501	)	$	(1	)	$	(625	)

	September 30,
Dollars in millions	2014			2013
Accumulated CTA, net of tax	$	(158	)	$	(123	)
Accumulated pension liability adjustments, net of tax	(583		)	(501		)
Accumulated unrealized losses on derivatives, net of tax	(3		)	(1		)
Total accumulated other comprehensive loss	$	(744	)	$	(625	)

Reclassification out of Accumulated Other Comprehensive Income [Table Text Block]

Reclassifications out of accumulated other comprehensive loss, net of tax, by component

	Nine Months Ended September 30,						Affected line item in the Condensed Consolidated Statements of Income
Dollars in millions	2014			2013
Accumulated pension liability adjustments
Amortization of actuarial loss (a)	$	(32	)	$	(26	)	See (a) below
Tax benefit	7			6			Provision for income taxes
Net pension liability adjustment realized	$	(25	)	$	(20	)	Net of tax

Shares of Treasury Stock

	Dollars in Millions				Number of Shares Repurchased
	Three Months Ended		Nine Months Ended		Three Months Ended	Nine Months Ended
	September 30, 2014		September 30, 2014		September 30, 2014	September 30, 2014
Repurchases under the $350 million authorized share repurchase program	$	4	$	85	175,522	3,149,151
Repurchases under the existing share maintenance program	2		17		131,300	661,020
Total	$	6	$	102	306,822	3,810,171

Repurchases under the authorized share repurchase program were made at an average price of $20.78 and $26.89 for the three and nine months ended September 30, 2014, respectively. Repurchases under the existing share maintenance program were made at an average price of $20.84 and $26.31 for the three and nine months ended September 30, 2014, respectively.

XML

Other Commitments And Contingencies (Foreign Corrupt Practices Act) (Narrative) (Details) (USD $) In Millions, unless otherwise specified	0 Months Ended		9 Months Ended
	Feb. 28, 2009	Sep. 30, 2014	Sep. 30, 2014 African Development Bank Group [Member]
Loss Contingencies [Line Items]
Organizational probation period (in years)	3 years		3 years
Loss Contingency, Estimate of Possible Loss		$ 50.0	$ 6.6
Loss Contingency, Damages Paid, Value			$ 0.3

XML

Business Segment Information (Tables)

9 Months Ended

Sep. 30, 2014

Segment Reporting [Abstract]

Schedule of Operations by Reportable Segment

Operations by Reportable Segment

	Three Months Ended						Nine Months Ended
	September 30,						September 30,
Dollars in millions	2014			2013			2014			2013
				As Restated						As Restated
Revenues:
Gas Monetization	$	343		$	537		$	1,105		$	1,725
Hydrocarbons	559			364			1,544			1,050
Infrastructure, Government and Power	342			373			994			1,147
Services	405			465			1,277			1,563
Other	8			16			29			49
Total	$	1,657		$	1,755		$	4,949		$	5,534
Gross profit (loss):
Gas Monetization	$	41		$	136		$	184		$	305
Hydrocarbons	18			40			74			133
Infrastructure, Government and Power	(40		)	17			(80		)	44
Services	2			(73		)	(98		)	(42		)
Other	6			4			16			12
Labor cost absorption not allocated to the business segments - favorable (unfavorable)	3			(10		)	1			(42		)
Total	$	30		$	114		$	97		$	410
Equity in earnings of unconsolidated affiliates:
Gas Monetization	$	23		$	19		$	57		$	46
Hydrocarbons	—			—			—			—
Infrastructure, Government and Power	7			9			40			35
Services	4			1			4			11
Other	4			2			17			15
Total	$	38		$	31		$	118		$	107
Segment operating income (loss):
Gas Monetization	$	64		$	155		$	241		$	351
Hydrocarbons	18			40			74			133
Infrastructure, Government and Power	(33		)	26			(40		)	79
Services	6			(72		)	(94		)	(31		)
Other	10			6			41			26
Labor cost absorption not allocated to the business segments - favorable (unfavorable)	3			(10		)	1			(42		)
Corporate general and administrative expense not allocated to the business segments	(58		)	(66		)	(178		)	(181		)
Total operating income	$	10		$	79		$	45		$	335

XML

Equity Method Investments And Variable Interest Entities (Schedule Of Variable Interest Entities) (Details) (USD $) In Millions, unless otherwise specified	Sep. 30, 2014	Dec. 31, 2013
Variable Interest Entity, Not Primary Beneficiary [Member] | Aspire Defence Project [Member]
Schedule of Equity Method Investments [Line Items]
Variable Interest Entity, Nonconsolidated, Carrying Amount, Assets	$ 17	$ 20
Variable Interest Entity, Nonconsolidated, Carrying Amount, Liabilities	126	2
Maximum exposure to loss	17
Variable Interest Entity, Not Primary Beneficiary [Member] | Ichthys LNG Project [Member]
Schedule of Equity Method Investments [Line Items]
Variable Interest Entity, Nonconsolidated, Carrying Amount, Assets	30	1
Variable Interest Entity, Nonconsolidated, Carrying Amount, Liabilities	37	18
Maximum exposure to loss	30
Variable Interest Entity, Not Primary Beneficiary [Member] | U.K. Road Projects [Member]
Schedule of Equity Method Investments [Line Items]
Variable Interest Entity, Nonconsolidated, Carrying Amount, Assets	35	34
Variable Interest Entity, Nonconsolidated, Carrying Amount, Liabilities	12	8
Maximum exposure to loss	35
Variable Interest Entity, Not Primary Beneficiary [Member] | EBIC Ammonia Project [Member]
Schedule of Equity Method Investments [Line Items]
Variable Interest Entity, Nonconsolidated, Carrying Amount, Assets	43	47
Variable Interest Entity, Nonconsolidated, Carrying Amount, Liabilities	2	2
Maximum exposure to loss	27
Variable Interest Entity, Not Primary Beneficiary [Member] | Fermoy Road Project [Member]
Schedule of Equity Method Investments [Line Items]
Variable Interest Entity, Nonconsolidated, Carrying Amount, Assets	4	1
Variable Interest Entity, Nonconsolidated, Carrying Amount, Liabilities	5	2
Maximum exposure to loss	4
Variable Interest Entity, Primary Beneficiary [Member] | Gorgon LNG Project [Member]
Schedule of Equity Method Investments [Line Items]
Consolidated VIEs, Total assets	372	446
Consolidated VIEs, Total liabilities	399	476
Variable Interest Entity, Primary Beneficiary [Member] | Escravos Gas-To-Liquids Project [Member]
Schedule of Equity Method Investments [Line Items]
Consolidated VIEs, Total assets	32	43
Consolidated VIEs, Total liabilities	52	72
Variable Interest Entity, Primary Beneficiary [Member] | Fasttrax Limited Project [Member]
Schedule of Equity Method Investments [Line Items]
Consolidated VIEs, Total assets	90	96
Consolidated VIEs, Total liabilities	$ 89	$ 98

XML

CIE and BIE BIE (Details) (USD $) In Millions, unless otherwise specified	Sep. 30, 2014	Dec. 31, 2013
Billings in Excess of Cost	$ 456	$ 401
Gas Monetization [Member]
Billings in Excess of Cost	40	30
Hydrocarbons [Member]
Billings in Excess of Cost	185	139
Infrastructure, Government And Power [Member]
Billings in Excess of Cost	211	199
Services [Member]
Billings in Excess of Cost	20	33
Other Segments [Member]
Billings in Excess of Cost	$ 0	$ 0

XML

Business Segment Information (Schedule Of Operations By Reportable Segment) (Details) (USD $) In Millions, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013
Segment Reporting Information [Line Items]
Revenue	$ 1,657	$ 1,755	$ 4,949	$ 5,534
Segment operating income	10	79	45	335
General and administrative expenses	(58)	(66)	(178)	(181)
Gross Profit	30	114	97	410
Equity in earnings of unconsolidated affiliates	38	31	118	107
Gas Monetization [Member]
Segment Reporting Information [Line Items]
Revenue	343	537	1,105	1,725
Segment operating income	64	155	241	351
Gross Profit	41	136	184	305
Equity in earnings of unconsolidated affiliates	23	19	57	46
Hydrocarbons [Member]
Segment Reporting Information [Line Items]
Revenue	559	364	1,544	1,050
Segment operating income	18	40	74	133
Gross Profit	18	40	74	133
Equity in earnings of unconsolidated affiliates	0	0	0	0
Infrastructure, Government And Power [Member]
Segment Reporting Information [Line Items]
Revenue	342	373	994	1,147
Segment operating income	(33)	26	(40)	79
Gross Profit	(40)	17	(80)	44
Equity in earnings of unconsolidated affiliates	7	9	40	35
Services [Member]
Segment Reporting Information [Line Items]
Revenue	405	465	1,277	1,563
Segment operating income	6	(72)	(94)	(31)
Gross Profit	2	(73)	(98)	(42)
Equity in earnings of unconsolidated affiliates	4	1	4	11
Other Segment [Member]
Segment Reporting Information [Line Items]
Revenue	8	16	29	49
Segment operating income	10	6	41	26
Gross Profit	6	4	16	12
Equity in earnings of unconsolidated affiliates	4	2	17	15
Non Allocated Labor Cost Absorption [Member]
Segment Reporting Information [Line Items]
Segment operating income	3	(10)	1	(42)
Operating Segments [Member]
Segment Reporting Information [Line Items]
Segment operating income	30	114	97	410
Segment Reconciling Items [Member]
Segment Reporting Information [Line Items]
General and administrative expenses	$ (58)	$ (66)	$ (178)	$ (181)

XML

Pension and Postretirement Plans (Schedule Of Changes In Projected Benefit Obligations) (Details) (USD $) In Millions, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013
United States Pension Benefits [Member]
Defined Benefit Plan Disclosure [Line Items]
Service cost	$ 0	$ 0	$ 0	$ 0
Interest cost	1	1	2	2
Expected return on plan assets	(1)	(2)	(3)	(4)
Recognized actuarial loss	1	1	3	2
Net periodic benefit cost	1	0	2	0
International Pension Benefits [Member]
Defined Benefit Plan Disclosure [Line Items]
Service cost	1	1	2	2
Interest cost	23	18	68	59
Expected return on plan assets	(26)	(19)	(78)	(64)
Recognized actuarial loss	10	7	29	24
Net periodic benefit cost	$ 8	$ 7	$ 21	$ 21

XML

Shareholders' Equity (Accumulated Other Comprehensive Income (Loss)) (Details) (USD $) In Millions, unless otherwise specified	9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013
Accumulated Other Comprehensive Income (Loss) [Line Items]
Beginning balance	$ (740)	$ (610)
Other comprehensive income adjustments before reclassifications	(29)	(36)
Amounts reclassified from accumulated other comprehensive income	25	21
Ending balance	(744)	(625)
Accumulated CTA, net of tax	(158)	(123)
Accumulated pension liability adjustments, net of tax	(583)	(501)
Accumulated unrealized losses on derivatives, net of tax	(3)	(1)
Total accumulated other comprehensive loss	(744)	(625)
Accumulated CTA
Accumulated Other Comprehensive Income (Loss) [Line Items]
Beginning balance	(131)	(88)
Other comprehensive income adjustments before reclassifications	(28)	(36)
Amounts reclassified from accumulated other comprehensive income	1	1
Ending balance	(158)	(123)
Total accumulated other comprehensive loss	(158)	(123)
Accumulated pension liability adjustments
Accumulated Other Comprehensive Income (Loss) [Line Items]
Beginning balance	(608)	(521)
Other comprehensive income adjustments before reclassifications	0	0
Amounts reclassified from accumulated other comprehensive income	25	20
Ending balance	(583)	(501)
Total accumulated other comprehensive loss	(583)	(501)
Accumulated unrealized losses on derivatives
Accumulated Other Comprehensive Income (Loss) [Line Items]
Beginning balance	(1)	(1)
Other comprehensive income adjustments before reclassifications	(1)	0
Amounts reclassified from accumulated other comprehensive income	(1)	0
Ending balance	(3)	(1)
Total accumulated other comprehensive loss	$ (3)	$ (1)

XML

Equity Method Investments And Variable Interest Entities Equity Method Investments and Variable Interest Entities (Related Party Disclosures) (Details) (USD $) In Millions, unless otherwise specified	9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Dec. 31, 2013
Schedule of Related Party Transactions Included In Our Consolidated Balance Sheets [Line Items]
Costs in Excess of Billings, Current	$ 509		$ 399
Transactions with Related Parties [Member]
Schedule of Related Party Transactions Included In Our Consolidated Balance Sheets [Line Items]
Revenue from Related Parties	228	186
Due from Related Parties, Current	2		6
Costs in Excess of Billings, Current	2		2
Billings in Excess of Cost	$ 23		$ 24

XML

Cash and Equivalents (Notes)

9 Months Ended

Sep. 30, 2014

Cash and Cash Equivalents [Abstract]

Cash and Cash Equivalents

Cash and Cash Equivalents

We consider all highly liquid investments with an original maturity of three months or less to be cash equivalents. Cash and cash equivalents include cash balances held by our wholly-owned subsidiaries as well as cash held by joint ventures that we consolidate. Joint venture cash balances are limited to joint venture activities and are not available for other projects, general cash needs or distribution to us without approval of the board of directors of the respective joint ventures. We expect to use joint venture cash for project costs and distributions of earnings related to joint venture operations. However, some of the earnings distributions may be paid to other KBR entities where the cash can be used for general corporate needs.

The components of our cash and cash equivalents balance are as follows:

	September 30, 2014
Dollars in millions	International (a)		Domestic (b)		Total
Operating cash	$	362	$	215	$	577
Time deposits	348		43		391
Cash held in joint ventures	64		16		80
Total	$	774	$	274	$	1,048

	December 31, 2013
Dollars in millions	International (a)		Domestic (b)		Total
Operating cash	$	197	$	215	$	412
Time deposits	478		140		618
Cash held in joint ventures	67		9		76
Total	$	742	$	364	$	1,106

(a) Includes deposits held in non-U.S. operating accounts considered to be permanently reinvested outside the U.S. and for which no incremental U.S. tax has been provisioned or paid.

(b) Includes U.S. dollar and foreign currency deposits held in operating accounts that constitute onshore cash for tax purposes but may reside either in the U.S. or in a foreign country.

Our international cash balances are primarily held in Australia, the United Kingdom ("U.K.") and Canada. We generally do not provide for U.S. federal and state income taxes on the accumulated undistributed earnings of non-U.S. subsidiaries except for certain entities in Mexico and certain other joint ventures, as well as for approximately 50% of our earnings from our operations in Australia since 2012. Taxes are provided as necessary with respect to earnings that are considered not permanently reinvested. We will continue to provide for U.S. federal and state taxes on 50% of the earnings of our Australian operations as we no longer intend to permanently reinvest these amounts. In determining whether earnings would be considered permanently invested, we considered future non-U.S. cash needs such as: 1) our anticipated foreign working capital requirements, including funding of our U.K. pension plan; 2) the expected growth opportunities across all geographical markets; and 3) our plans to invest in strategic growth opportunities that may include acquisitions around the world. For all other non-U.S. subsidiaries, no U.S. taxes are provided because such earnings are intended to be permanently reinvested to finance foreign activities. These accumulated but undistributed foreign earnings could be subject to additional tax if remitted, or deemed remitted, as a dividend. If any portion of the unremitted earnings were ever foreseen to not be permanently reinvested outside the U.S., or if we elect to repatriate a portion of current year foreign earnings, U.S. income tax expense would be required to be recognized and that expense could be material.

Restricted Cash

Restricted cash included in "other current assets" on our condensed consolidated balance sheets was $17 million and $1 million as of September 30, 2014 and December 31, 2013, respectively. This was primarily related to amounts held in foreign banks for which we have restrictions of use for general business purposes.

XML

Shareholders' Equity (Reclassification out of AOCI) (Details) (USD $) In Millions, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013
Reclassification Adjustment out of Accumulated Other Comprehensive Income [Line Items]
Loss (gain) on disposition of assets, net	$ 0	$ 0	$ (8)	$ 1
Amortization of loss	44	75	63	328
Tax expense (benefit)	1	(60)	(30)	(105)
Net CTA realized	0	0	(1)	(1)
Accumulated pension liability adjustments | Reclassification out of Accumulated Other Comprehensive Income [Member]
Reclassification Adjustment out of Accumulated Other Comprehensive Income [Line Items]
Amortization of loss			(32)	(26)
Tax expense (benefit)			7	6
Net pension liability adjustment realized			$ (25)	$ (20)

XML

Percentage-Of-Completion Contracts (Schedule Of Unapproved Claims And Change Orders) (Details) (USD $) In Millions, unless otherwise specified	9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Dec. 31, 2013	Dec. 31, 2012
Contractors [Abstract]
Changes in Estimates at Completion	$ 81	$ 69
Change Orders Approved by Customer	(134)	(26)
Unapproved change orders	62	210	115	167
Unapproved Change Orders And Claims Recorded In Revenues	$ 53	$ 165

XML

Claims and Accounts Receivable (Tables)

9 Months Ended

Sep. 30, 2014

Receivables [Abstract]

Schedule of Contracts Receivable, Claims and Uncertain Amounts

The components of our claims and accounts receivable account balance not expected to be collected within the next 12 months are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Hydrocarbons	$	401	$	401
Infrastructure, Government and Power	196		226
Other	1		1
Total	$	598	$	628

XML

Percentage-Of-Completion Contracts (Tables)

9 Months Ended

Sep. 30, 2014

Contractors [Abstract]

Schedule Of Unapproved Claims And Change Orders

Unapproved Change Orders and Claims

The amounts of unapproved change orders and claims included in determining the profit or loss on contracts are as follows:

Dollars in millions	2014			2013
Amounts included in estimated project revenues at completion at January 1,	$	115		$	167
Increase in estimated project revenues at completion	81			69
Approved by client	(134		)	(26		)
Amounts included in estimated project revenues at completion at September 30,	$	62		$	210
Amounts recorded in revenues on a percentage-of-completion basis at September 30,	$	53		$	165

XML

U.S. Government Matters (Details) (USD $) In Millions, unless otherwise specified	9 Months Ended			3 Months Ended					9 Months Ended			1 Months Ended	3 Months Ended		3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2014 All Defense Contract Audit Agency Audit Issues [Member]	Dec. 31, 2013 All Defense Contract Audit Agency Audit Issues [Member]	Mar. 31, 2011 LogCAP III Contract [Member]	Sep. 30, 2014 Private Security [Member]	Sep. 30, 2014 Containers [Member]	Sep. 30, 2014 Tamimi Dining Facility [Member]	Apr. 30, 2012 Tamimi Dining Facility [Member]	Sep. 30, 2014 Fly America Act [Member]	Sep. 30, 2014 Construction Services [Member]	Sep. 30, 2014 All Other Issues [Member]	Apr. 30, 2008 First Kuwaiti Trading Company Arbitration [Member]	Sep. 30, 2014 First Kuwaiti Trading Company Arbitration [Member] Contracts	Sep. 30, 2014 Burn Pit Litigation [Member] lawsuits	Jun. 30, 2013 Sodium Dichromate Litigation [Member]	Dec. 31, 2012 Sodium Dichromate Litigation [Member]	Sep. 30, 2014 Sodium Dichromate Litigation [Member] lawsuits	Sep. 30, 2014 qui tams [Member] lawsuits	Sep. 30, 2014 Claims [Member]
United States Government Contract Work [Line Items]
Total amount of DCAA Form 1's - Notice of contract costs suspended and/or disapproved issued to the enterprise		$ 229	$ 274		$ 56	$ 51	$ 68			$ 25	$ 29
DCAA Form 1 total withholds of payments from remittances on contract billings		137	137		45	26	43	1		10	13
Loss Contingency, Receivable						2	43			10
Loss Contingency, Estimate of Possible Loss	50.0	62.0	74.0								4.0
Total Amount Of Payments Withheld From Subcontractors As Result Of Disapproved Costs Related To Dcaa Form 1 Issued To Enterprise		33	50			31							7
Amount Awarded by COFC								12
InterestAwardedByCOFC								2
Amount of pre tax charge for disallowed amount by COFC								28
Minimum number of deployment days in the contractor rotation terms under the LogCAP III contract				179 days
Amount of costs deemed unallowable									3	15
Total claim by subcontractor related to leased vehicles											12	134
Partial arbitration award to subcontractor for damages													17
AmountOwedToSubcontractor													30
Subcontracts not subject to arbitration													5
Loss Contingency, Damages Paid, Value													15.0
Loss Contingency, Pending Claims, Number														50			5
Number of Lawsuits Consolidated																	2
qui tam government joined																		1
Loss Contingency, Number of Plaintiffs																	170
Punitive damages relating to the settlement															75	75
AmicusCuriaeBriefs																	5
Amount of claim filed against us ace rio contracting officer																	30
Legal Fees																		10
Loss Contingency, Number of Defendants	0
Damages awarded, value															6	10
Unapproved claims included in accounts receivables related to various government contracts where costs have exceeded the customer's funded value of task orders																			118
Amount of unapproved claims related to de-obligation of funding																			98
Claims Outstanding Considered to be Probable																			$ 90

XML

Percentage-Of-Completion Contracts (Narrative) (Details) (USD $) In Millions, unless otherwise specified	Sep. 30, 2014	Dec. 31, 2013	Sep. 30, 2014 Parent Share of Probable Unapproved Claims of Unconsolidated Subsidiary [Member]	Sep. 30, 2013 Parent Share of Probable Unapproved Claims of Unconsolidated Subsidiary [Member]
Contracts Receivable, Claims and Uncertain Amounts			$ 84	$ 54
Liquidated damages	12	10
Customer Advances, Current	$ 42	$ 50

XML

Equity Method Investments And Variable Interest Entities (Tables)

9 Months Ended

Sep. 30, 2014

Equity Method Investments and Joint Ventures [Abstract]

Schedule of Related Party Transactions [Table Text Block]

Amounts included in our condensed consolidated balance sheets related to services we provided to our joint ventures as of September 30, 2014 and December 31, 2013 are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Accounts receivable, net of allowance for doubtful accounts	$	2	$	6
Costs and estimated earnings in excess of billings on uncompleted contracts	$	2	$	2
Billings in excess of costs and estimated earnings on uncompleted contracts	$	23	$	24

Equity Method Investments [Table Text Block]

Summarized financial information for all jointly owned operations including variable interest entities that are accounted for using the equity method of accounting is as follows:

Balance Sheets

	September 30,		December 31,
Dollars in millions	2014		2013
Current assets	$	3,968	$	4,114
Noncurrent assets	4,212		4,222
Total assets	$	8,180	$	8,336
Current liabilities	$	3,597	$	3,679
Noncurrent liabilities	4,273		4,400
Total liabilities	$	7,870	$	8,079

Statements of Operations

	Three Months Ended				Nine Months Ended
	September 30,				September 30,
Dollars in millions	2014		2013		2014		2013
Revenues	$	1,728	$	1,400	$	4,336	$	3,548
Operating income	$	175	$	135	$	503	$	434
Net income	$	101	$	81	$	307	$	276

Equity In Earnings of Unconsolidated Affiliates [Table Text Block]

The following table presents a rollforward of our equity in and advances to unconsolidated affiliates:

Dollars in millions	2014			2013
Balance at January 1,	$	156		$	217
Equity in earnings of unconsolidated affiliates	118			107
Dividends received (a)	(212		)	(151		)
Advances	(14		)	(12		)
Cumulative translation adjustment	(1		)	(7		)
Balance at September 30, before reclassification	47			154
Reclassification of excess distributions (a)	102			—
Balance at September 30,	$	149		$	154

Schedule Of Variable Interest Entities

Unconsolidated Variable Interest Entities

The following summarizes the total assets and total liabilities as reflected in our condensed consolidated balance sheets as well as our maximum exposure to losses related to our unconsolidated variable interest entities ("VIEs") in which we have a significant variable interest but are not the primary beneficiary. Generally, our maximum exposure to loss is limited to our equity investment in the joint venture and any amounts payable to us for services we provided to the joint venture, reduced for any unearned revenues on the projects.

	September 30, 2014
Dollars in millions	Total assets		Total liabilities		Maximum exposure to  loss
Aspire Defence project	$	17	$	126	$	17
Ichthys LNG project	$	30	$	37	$	30
U.K. Road projects	$	35	$	12	$	35
EBIC Ammonia project	$	43	$	2	$	27
Fermoy Road project	$	4	$	5	$	4

Dollars in millions	December 31, 2013
	Total assets		Total liabilities
Aspire Defence project	$	20	$	2
Ichthys LNG project	$	1	$	18
U.K. Road projects	$	34	$	8
EBIC Ammonia project	$	47	$	2
Fermoy Road project	$	1	$	2

On the Aspire Defence project, in addition to the maximum exposure to loss indicated in the table above, we have exposure to any losses incurred by the construction or operating joint ventures under their respective subcontract arrangements with the project company. Our exposure is, however, limited to our equity participation in these entities. The Ichthys LNG project joint venture executes a project that has a lump sum component; in addition to the maximum exposure to loss indicated in the table above, we have an exposure to losses if the project exceeds the lump sum component to the extent of our ownership percentage in the joint venture. Our maximum exposure to loss on the EBIC Ammonia project reflects our 65% ownership of the development corporation which owns 25% of the company that consolidates the ammonia plant.

Consolidated Variable Interest Entities

We consolidate VIEs if we determine we are the primary beneficiary of the project entity because we control the activities that most significantly impact the economic performance of the entity. The following is a summary of the significant VIEs where we are the primary beneficiary:

Dollars in millions	September 30, 2014
	Total assets		Total liabilities
Gorgon LNG project	$	372	$	399
Escravos Gas-to-Liquids project	$	32	$	52
Fasttrax Limited project	$	90	$	89

Dollars in millions	December 31, 2013
	Total assets		Total liabilities
Gorgon LNG project	$	446	$	476
Escravos Gas-to-Liquids project	$	43	$	72
Fasttrax Limited project	$	96	$	98

XML

Pension and Postretirement Plans (Tables) (Pension Benefits [Member])

9 Months Ended

Sep. 30, 2014

Pension Benefits [Member]

Defined Benefit Plan Disclosure [Line Items]

Components Of Net Periodic Benefit Cost

The components of net periodic benefit cost related to pension benefits for the three and nine months ended September 30, 2014 and 2013 were as follows:

	Three Months Ended September 30,
	2014						2013
Dollars in millions	United States			Int’l			United States			Int’l
Components of net periodic benefit cost
Service cost	$	—		$	1		$	—		$	1
Interest cost	1			23			1			18
Expected return on plan assets	(1		)	(26		)	(2		)	(19		)
Recognized actuarial loss	1			10			1			7
Net periodic benefit cost	$	1		$	8		$	—		$	7

	Nine Months Ended September 30,
	2014						2013
Dollars in millions	United States			Int’l			United States			Int’l
Components of net periodic benefit cost
Service cost	$	—		$	2		$	—		$	2
Interest cost	2			68			2			59
Expected return on plan assets	(3		)	(78		)	(4		)	(64		)
Recognized actuarial loss	3			29			2			24
Net periodic benefit cost	$	2		$	21		$	—		$	21

XML

Business Segment Information

9 Months Ended

Sep. 30, 2014

Segment Reporting [Abstract]

Business Segment Information

Business Segment Information

Our business segment information has been prepared in accordance with ASC 280 - Segment Reporting. Certain reporting units meet the definition of operating segments contained in ASC 280 - Segment Reporting, but individually do not meet the quantitative thresholds as a reportable segment, nor do they share a majority of the aggregation criteria with another operating segment. These operating segments are reported on a combined basis as “Other” and include our Ventures and Technical Staffing Resources (formerly a part of Allstates Technical Services) lines of business as well as corporate expenses not included in the operating segments’ results.

Reportable segment performance is evaluated by our Chief Operating Decision Maker ("CODM") using reportable segment gross profit (loss) which is defined as business segment revenues less the cost of revenues, which includes overhead costs directly attributable to the segment, but excludes equity in earnings of unconsolidated affiliates.

The following table presents revenues, gross profit (loss), equity in earnings of unconsolidated affiliates and operating income (loss) by reporting segment.

Operations by Reportable Segment

	Three Months Ended						Nine Months Ended
	September 30,						September 30,
Dollars in millions	2014			2013			2014			2013
				As Restated						As Restated
Revenues:
Gas Monetization	$	343		$	537		$	1,105		$	1,725
Hydrocarbons	559			364			1,544			1,050
Infrastructure, Government and Power	342			373			994			1,147
Services	405			465			1,277			1,563
Other	8			16			29			49
Total	$	1,657		$	1,755		$	4,949		$	5,534
Gross profit (loss):
Gas Monetization	$	41		$	136		$	184		$	305
Hydrocarbons	18			40			74			133
Infrastructure, Government and Power	(40		)	17			(80		)	44
Services	2			(73		)	(98		)	(42		)
Other	6			4			16			12
Labor cost absorption not allocated to the business segments - favorable (unfavorable)	3			(10		)	1			(42		)
Total	$	30		$	114		$	97		$	410
Equity in earnings of unconsolidated affiliates:
Gas Monetization	$	23		$	19		$	57		$	46
Hydrocarbons	—			—			—			—
Infrastructure, Government and Power	7			9			40			35
Services	4			1			4			11
Other	4			2			17			15
Total	$	38		$	31		$	118		$	107
Segment operating income (loss):
Gas Monetization	$	64		$	155		$	241		$	351
Hydrocarbons	18			40			74			133
Infrastructure, Government and Power	(33		)	26			(40		)	79
Services	6			(72		)	(94		)	(31		)
Other	10			6			41			26
Labor cost absorption not allocated to the business segments - favorable (unfavorable)	3			(10		)	1			(42		)
Corporate general and administrative expense not allocated to the business segments	(58		)	(66		)	(178		)	(181		)
Total operating income	$	10		$	79		$	45		$	335

Changes in Estimates

There are many factors, including, but not limited to, the availability and costs of labor, materials and equipment, and resources, productivity, and weather, that can affect the accuracy of our cost estimates, and ultimately, our future profitability. In the past, we have realized both lower and higher than expected margins and have incurred losses as a result of unforeseen changes in our project costs. However, historically, our estimates have been reasonably dependable regarding the recognition of revenues and profit on percentage of completion contracts.

Our Services business segment recognized revisions in our estimates of losses at completion on our Canadian pipe fabrication and module assembly projects of $80 million during the nine months ended September 30, 2014. All of these projects were in loss positions at September 30, 2014 and December 31, 2013. Our estimates of revenues and costs at completion on these projects have been, and may continue to be, impacted by our performance, the performance of our subcontractors, the Canadian labor market, the nature, complexity and material quantities of modules outlined on drawings submitted by our customers, our contractual arrangements and our ability to accumulate information and negotiate final contract settlements with our customers. We recognize revisions of revenues and costs in the period in which the revisions are known. This may result in the recognition of costs before the recognition of related revenue recovery, if any. Our estimated losses as of September 30, 2014 on these projects represent our best estimate based on current information. Actual results could differ from the estimates we have used to account for these projects as of September 30, 2014.

During the three and nine months ended September 30, 2014, our IGP business segment recognized revisions in estimates of costs at completion of $33 million and $47 million, respectively, on a power project in North America. Additionally, our Hydrocarbons business segment recognized revisions in estimates of costs at completion of $18 million in the three and nine months ended September 30, 2014 on a North American EPC project reflecting higher estimated costs at completion. Both of these projects were in loss positions at September 30, 2014.

We recognized revisions in estimates primarily associated with approved man hours which resulted in a $21 million positive impact on the gross profit of our Gas Monetization business segment. Additionally, our Gas Monetization business segment recognized revisions in estimates resulting from a favorable settlement of claims which had a $33 million net positive impact on gross profit. Both of these revisions to estimates were recognized in the first quarter of 2014.

Significant revisions to contract estimates as a result of client-driven revised project man-hour estimates had a $90 million positive impact during the three months ended September 30, 2013 and a $141 million positive impact during the nine months ended September 30, 2013 on the gross profit of our Gas Monetization business segment.

XML

Income Taxes (Tables)

9 Months Ended

Sep. 30, 2014

Income Tax Disclosure [Abstract]

Reconciliations

	2014		2013
U.S. statutory federal rate	35.0	%	35.0	%
Rate differentials on foreign earnings	(8.5	)%	(6.6	)%
Taxes on unincorporated joint ventures	(10.1	)%	(7.6	)%
Taxes on unconsolidated affiliates	(10.9	)%	(4.6	)%
U.S. taxes provided on foreign earnings	12.1	%	2.2	%
State taxes	0.3	%	0.5	%
Other	4.4	%	3.7	%
Estimated annual effective tax rate	22.3	%	22.6	%

XML

Accounts Receivable (Details) (USD $) In Millions, unless otherwise specified	Sep. 30, 2014	Dec. 31, 2013
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	$ 964	$ 1,056
Trade Accounts Receivable [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	874	956
Retainage [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	90	100
Gas Monetization [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	126	255
Gas Monetization [Member] | Trade Accounts Receivable [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	126	255
Gas Monetization [Member] | Retainage [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	0	0
Hydrocarbons [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	340	315
Hydrocarbons [Member] | Trade Accounts Receivable [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	319	284
Hydrocarbons [Member] | Retainage [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	21	31
Infrastructure, Government And Power [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	217	152
Infrastructure, Government And Power [Member] | Trade Accounts Receivable [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	188	137
Infrastructure, Government And Power [Member] | Retainage [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	29	15
Services [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	279	332
Services [Member] | Trade Accounts Receivable [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	239	278
Services [Member] | Retainage [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	40	54
Other Segments [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	2	2
Other Segments [Member] | Trade Accounts Receivable [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	2	2
Other Segments [Member] | Retainage [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Account receivable, current	0	0
Other Assets [Member] | Retainage [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Accounts receivable, non current	$ 7	$ 14

XML

Pension and Postretirement Plans (Narrative) (Details) (USD $) In Millions, unless otherwise specified	9 Months Ended
	Sep. 30, 2014
International Pension Benefits [Member]
Defined Benefit Plan Disclosure [Line Items]
Defined Benefit Plan, Contributions by Employer	$ 35
Defined Benefit Plans, Estimated Future Employer Contributions in Current Fiscal Year	46
United States Pension Benefits [Member]
Defined Benefit Plan Disclosure [Line Items]
Defined Benefit Plan, Contributions by Employer	2
Defined Benefit Plans, Estimated Future Employer Contributions in Current Fiscal Year	$ 3

XML

Consolidated Statements Of Income (USD $) In Millions, except Per Share data, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013
Income Statement [Abstract]
Revenue	$ 1,657	$ 1,755	$ 4,949	$ 5,534
Cost of services	(1,627)	(1,641)	(4,852)	(5,124)
Gross profit	30	114	97	410
Equity in earnings of unconsolidated affiliates	38	31	118	107
General and administrative expenses	(58)	(66)	(178)	(181)
Gain (loss) on disposition of assets	0	0	(8)	1
Operating income	10	79	45	335
Interest income (expense), net	3	(1)	(1)	(3)
Foreign currency gains (losses), net	7	(2)	(4)	(2)
Other non-operating income (expense)	24	(1)	23	(2)
Income before income taxes and noncontrolling interests	44	75	63	328
Tax benefit (expense)	1	(60)	(30)	(105)
Net income	45	15	33	223
Net income attributable to noncontrolling interests	(15)	(62)	(54)	(92)
Net income attributable to KBR	$ 30	$ (47)	$ (21)	$ 131
Net income attributable to KBR per share:
Basic	$ 0.21	$ (0.32)	$ (0.14)	$ 0.88
Diluted	$ 0.21	$ (0.32)	$ (0.14)	$ 0.88
Basic weighted average common shares outstanding	145	148	145	148
Diluted weighted average common shares outstanding	145	148	145	149
Cash dividends declared per share	$ 0.08	$ 0.08	$ 0.24	$ 0.16

XML

Claims and Accounts Receivable (Details) (USD $) In Millions, unless otherwise specified	Sep. 30, 2014	Dec. 31, 2013
Accounts, Notes, Loans and Financing Receivable [Line Items]
Claims receivable	$ 598	$ 628
Hydrocarbons [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Claims receivable	401	401
Infrastructure, Government And Power [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Claims receivable	196	226
Other Segments [Member]
Accounts, Notes, Loans and Financing Receivable [Line Items]
Claims receivable	$ 1	$ 1

XML

Consolidated Statements Of Cash Flows (USD $) In Millions, unless otherwise specified	9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013
Cash flows from operating activities:
Net income	$ 33	$ 223
Adjustments to reconcile net income to net cash provided by (used in) operating activities:
Depreciation and amortization	55	49
Equity in earnings of unconsolidated affiliates	(118)	(107)
Deferred income tax (benefit) expense	(2)	61
Other Noncash Income	(24)	0
Other	25	18
Changes in operating assets and liabilities:
Accounts Receivable, net	66	124
Cost in Excess of Billing on Uncompleted Contract	(109)	(41)
Accounts payable	(43)	(64)
Billings in excess of cost on uncompleted contracts	53	(101)
Accrued salaries, wages and benefits	(16)	(14)
Reserve for loss on uncompleted contracts	13	30
Reserve for loss on uncompleted contracts	118
Collection (repayment) of advances from (to) unconsolidated affiliates, net	14	12
Distributions of earnings from unconsolidated affiliates	212	151
Payment on performance bonds	0	(108)
Income taxes payable	22	(168)
Pension funding	(37)	(26)
Other, net	34	42
Total cash flows provided by operating activities	178	81
Cash flows from investing activities:
Capital expenditures	(46)	(57)
Proceeds from Sale of Property, Plant, and Equipment	9	7
Total cash flows provided by (used in) investing activities	(37)	(50)
Cash flows from financing activities:
Payments to reacquire common stock	(102)	(7)
Distributions to noncontrolling interests, net	39	49
Payments of dividends to shareholders	(35)	(24)
Net proceeds from issuance of stock	4	5
Payments on short-term and long-term borrowings	(7)	(9)
Other	1	1
Total cash flows used in financing activities	(178)	(83)
Effect of exchange rate changes on cash	(21)	(42)
Increase (decrease) in cash and equivalents	(58)	(94)
Cash and equivalents at beginning of period	1,106	1,053
Cash and equivalents at end of period	1,048	959
Supplemental disclosure of cash flow information:
Cash paid for interest	9	9
Cash paid for income taxes (net of refunds)	13	107
Noncash operating activities
Other assets change for Barracuda arbitration (Note 13)	0	(219)
Other liabilities change for Barracuda arbitration (Note 13)	0	219
Dividends Payable	$ 12	$ 12

XML

Transactions With Former Parent (Narrative) (Details) (USD $) In Millions, unless otherwise specified	3 Months Ended	9 Months Ended	0 Months Ended	1 Months Ended	3 Months Ended		9 Months Ended		9 Months Ended	1 Months Ended			12 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Jun. 24, 2013 Halliburton [Member]	Oct. 24, 2013 Halliburton [Member]	Jun. 30, 2013 Halliburton [Member]	Dec. 31, 2011 Halliburton [Member]	Sep. 30, 2014 Halliburton [Member]	Dec. 31, 2013 Halliburton [Member]	Sep. 30, 2013 Additional Paid-in Capital [Member]	Oct. 24, 2013 Additional Paid-in Capital [Member] Halliburton [Member]	Sep. 30, 2011 Barracuda-Caratinga Project [Member]	Mar. 31, 2006 Barracuda-Caratinga Project [Member]	Dec. 31, 2012 Barracuda-Caratinga Project [Member] Halliburton [Member]	Dec. 31, 2011 Barracuda-Caratinga Project [Member] Halliburton [Member]
Deferred Tax Assets, Other				$ 29
Demanded Payment						256
Total amount due to former parent, net				105			81
Gain (Loss) Related to Litigation Settlement							24.0
Indemnification receivable due from related parties								219
Discrete income tax benefit	62												(8)	(71)
Maximum years by which claims were required to be arbitrated			2 years
Number of days to return to accounting referee					30 days
Effective Income Tax Rate Reconciliation, Other Adjustments, Amount				38
Adjustments to Additional Paid in Capital, Other		(7)							(7)	7
Loss Contingency, Damages Sought, Value												220
Amount Awarded By Arbitration Panel											$ 193

XML

Income Per Share (Tables)

9 Months Ended

Sep. 30, 2014

Earnings Per Share [Abstract]

Schedule Of Basic And Diluted Weighted Average Common Shares Outstanding

	Three Months Ended		Nine Months Ended
	September 30,		September 30,
Millions of shares	2014	2013	2014	2013
Basic weighted average common shares outstanding	145	148	145	148
Stock options and restricted shares	—	—	—	1
Diluted weighted average common shares outstanding	145	148	145	149

XML

Income Per Share (Narrative) (Details) (USD $) In Millions, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013
Earnings Per Share [Abstract]
Undistributed Earnings (Loss) Allocated to Participating Securities, Basic	$ 0.2			$ 0.4
Antidilutive weighted average shares	3.4	1.9	2.8	1.8

XML

Income Per Share

9 Months Ended

Sep. 30, 2014

Earnings Per Share [Abstract]

Income Per Share

Income (loss) per Share

Basic income (loss) per share is based upon the weighted average number of common shares outstanding during the period. Dilutive income (loss) per share includes additional common shares that would have been outstanding if potential common shares with a dilutive effect had been issued using the treasury stock method.

A reconciliation of the number of shares used for the basic and diluted income per share calculations is as follows:

	Three Months Ended		Nine Months Ended
	September 30,		September 30,
Millions of shares	2014	2013	2014	2013
Basic weighted average common shares outstanding	145	148	145	148
Stock options and restricted shares	—	—	—	1
Diluted weighted average common shares outstanding	145	148	145	149

For purposes of applying the two-class method in computing earnings per share, net earnings allocated to participating securities for the three months and nine months ended September 30, 2014 was approximately $0.2 million and none, respectively. Net earnings allocated to participating securities for the three and nine months ended September 30, 2013 was none and $0.4 million, respectively. The diluted earnings per share calculation did not include 3.4 million and 2.8 million antidilutive weighted average shares for the three and nine months ended September 30, 2014, respectively. The diluted earnings per share calculation did not include 1.9 million and 1.8 million antidilutive weighted average shares for the three and nine months ended September 30, 2013, respectively.

XML

Description Of Company And Significant Accounting Policies (Narrative) (Details) (USD $) In Millions, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013	Dec. 31, 2013
Description Of Company And Significant Accounting Policies [Line Items]
Quantifying Misstatement in Current Year Financial Statements, Amount			$ 8
Income before income taxes and noncontrolling interests	44	75	63	328
Reserve for loss on uncompleted contracts	118		118		109
Revenue	1,657	1,755	4,949	5,534
Cost of Services	1,627	1,641	4,852	5,124
Income Tax Expense (Benefit)	(1)	60	30	105
Canadian Pipe Fabrication And Module Assembly Projects [Member]
Description Of Company And Significant Accounting Policies [Line Items]
Reserve for loss on uncompleted contracts	87		87		97
Gas Monetization Project Revenue Recognition Error [Member] | Restatement Adjustment [Member]
Description Of Company And Significant Accounting Policies [Line Items]
Revenue	4
Canadian Pipe Fabrication And Module Assembly Projects [Member] | Restatement Adjustment [Member]
Description Of Company And Significant Accounting Policies [Line Items]
Income before income taxes and noncontrolling interests	89
Revenue	28
Cost of Services	61
Income Tax Expense (Benefit)	9
Other Aggregated Immaterial Errors [Member] | Restatement Adjustment [Member]
Description Of Company And Significant Accounting Policies [Line Items]
Revenue	1
Cost of Services	1
Income Tax Expense (Benefit)	$ 6

XML

Description Of Company And Significant Accounting Policies (Policy)

9 Months Ended

Sep. 30, 2014

Accounting Policies [Abstract]

Principles of consolidation

Principles of Consolidation

Our condensed consolidated financial statements have been prepared in accordance with accounting principles generally accepted in the United States ("U.S. GAAP") and include the accounts of KBR and our wholly owned and majority-owned, controlled subsidiaries and variable interest entities of which we are the primary beneficiary. We account for investments over which we have significant influence but not a controlling financial interest using the equity method of accounting. See Note 7 to our condensed consolidated financial statements for further discussion on our equity investments and variable interest entities. The cost method is used when we do not have the ability to exert significant influence. All material intercompany balances and transactions are eliminated in consolidation. For the nine months ended September 30, 2014, we recorded $8 million for an error originating in 2013 related to the gain from receipts of insurance proceeds. The net effect of the correction was a decrease in 2014 net loss of $8 million.

Certain prior year amounts have been reclassified to conform to the current year presentation on the condensed consolidated statement of income, condensed consolidated balance sheets and the condensed consolidated statements of cash flows. Effective December 31, 2013, we reclassified equity in earnings of unconsolidated affiliates from revenues to a separate component of operating income on our condensed consolidated statement of income. We reclassified the three months and nine months ended September 30, 2013 amounts to conform to our revised presentation as a component of operating income but not a component of revenues.

We have evaluated all events and transactions occurring after the balance sheet date but before the financial statements were issued and have made the appropriate adjustments and included the appropriate disclosures.

Use of estimates

Use of Estimates

The preparation of our condensed consolidated financial statements in conformity with U.S. GAAP requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosures of contingent assets and liabilities and the reported amounts of revenues and expenses during the reporting period, including:

• project revenues, costs and profits on engineering, construction, pipe fabrication and module assembly, and government services contracts, including recognition of estimated losses on uncompleted contracts,

• uncollectible receivables, claims to and from customers, recoveries of costs from subcontractors, vendors and others,

• provisions for income taxes, recoverability of deferred tax assets and valuation of uncertain tax positions,

• recoverability of goodwill, other intangibles and long-lived assets and related estimated lives,

• recoverability of equity method and cost method investments,

• valuation of pension obligations,

• accruals for estimated liabilities and litigation outcomes,

• consolidation of variable interest entities, and

• valuation of stock-based compensation.

In accordance with normal practice in the construction industry, we include in current assets and current liabilities amounts related to construction contracts realizable and payable over a period in excess of one year. Actual amounts may differ from those included in the accompanying condensed consolidated financial statements, if the underlying estimates and assumptions upon which the financial statements are based change in the future.

Gross Profit [Policy Text Block]

Gross Profit

Gross profit represents revenues less the cost of revenues, which includes overhead costs directly attributable to the business segment. See Note 2 to our condensed consolidated financial statements for presentation of our gross profit by reportable segment.

Allowance for bad debts

Accounts Receivable

Accounts receivable are recorded at the invoiced amount based on contracted prices. Amounts collected on accounts receivable are included in net cash provided by operating activities in the condensed consolidated statements of cash flows.

We establish an allowance for doubtful accounts based on the assessment of the customers’ willingness and ability to pay. In addition to such allowances, there are often items in dispute or being negotiated that may require us to make an estimate as to the ultimate outcome. Past due receivable balances are written off when our internal collection efforts have been unsuccessful in collecting the amounts due. See Note 4 to our condensed consolidated financial statements for our discussion on accounts receivable.

Retainage, included in accounts receivable, represents amounts withheld from billings by our customers pursuant to provisions in the contracts and may not be paid to us until the completion of specific tasks on the project. Retainage may also be subject to restrictive conditions such as performance guarantees. Our retainage receivable excludes amounts withheld by the United States ("U.S.") government on certain contracts. See Note 11 to our condensed consolidated financial statements for our discussion on U.S. government receivables.

Costs In Excess Of Billings And Billings In Excess Of Costs [Policy Text Block]

Costs and Estimated Earnings in Excess of Billings on Uncompleted Contracts (including Claims) and Advanced Billings and Billings in Excess of Costs and Estimated Earnings on Uncompleted Contracts

Costs and estimated earnings in excess of billings on uncompleted contracts ("CIE") represent the excess of contract costs and profits recognized to date using the percentage-of-completion method over billings to date on certain contracts. Billings in excess of costs and estimated earnings on uncompleted contracts ("BIE") represents the excess of billings to date over the amount of contract costs and profits recognized to date using the percentage-of-completion method on certain contracts. See Note 5 to our condensed consolidated financial statements for our discussion on CIE and BIE.

Unapproved Change Orders and Claims

When estimating the amount of total gross profit or loss on a contract, we sometimes include unapproved change orders and claims to our customers as adjustments to revenues when the criteria under ASC 605-35 is met. We also include estimates of claims to vendors, subcontractors and others as adjustments to total estimated costs. Unapproved change orders and claims are recorded to the extent of the lesser of the amounts management expects to recover or to costs incurred and include no profit until they are finalized or approved.

Goodwill and other intangibles

Goodwill

Effective January 1, 2014, we reorganized four of the five reporting units in the Infrastructure, Government and Power ("IGP") business segment into three geographic-based units. This reorganization allows the IGP business segment to focus its engineering, procurement, construction and defense services to customers on a more local level. We have concluded that each of these geographic-based units will be considered a separate reporting unit for goodwill impairment testing purposes. As a result, we performed an additional impairment test on the three newly reorganized reporting units on January 1, 2014 as required by ASC 350-20, utilizing the same methodology as our annual goodwill impairment test, and no indication of impairment was identified. For more detail on our methodology and assumptions, see "Critical Accounting Policies" in our 2013 Annual Report on Form 10-K/A.

Share-based Compensation, Option and Incentive Plans Policy [Policy Text Block]

Share-based Compensation

Effective January 1, 2014, we changed our methodology for estimating the expected term of our option awards from the simplified method and now measure subsequent stock option awards using an expected term based on KBR’s historical experience.

XML

Description Of Company And Significant Accounting Policies

9 Months Ended

Sep. 30, 2014

Accounting Policies [Abstract]

Description of Company and Significant Accounting Policies

Description of Company and Significant Accounting Policies

KBR, Inc., a Delaware corporation, was formed on March 21, 2006 and is headquartered in Houston, Texas. KBR, Inc. and its wholly owned and majority-owned subsidiaries (collectively referred to herein as "KBR", the "Company", "we", "us" or "our") is a global engineering, procurement, construction, and services company supporting the energy, hydrocarbons, power, industrial, civil infrastructure, minerals, government services and commercial markets. Our capabilities include engineering, procurement, construction and construction management, technology licensing, operations and maintenance and other support services for a diverse, global customer base, including international and national oil and gas companies, independent refiners, petrochemical producers, fertilizer producers, regulated utilities, manufacturers, power and mining companies and domestic and foreign governments.

Strategic Review

Following the June 2014 appointment of Mr. Stuart Bradie, our CEO, we announced plans to undertake a global strategic review of our business. We are currently performing this review with a view to enhancing shareholder value.  At the conclusion of the strategic review, we expect to make recommendations and seek approval from the Board of Directors as to a proposed course of action. We are targeting substantial completion of this review in the fourth quarter of 2014. It is possible that the outcome of our strategic review could result in the restructuring of our business and a reorganization of our reportable business segments. It is possible that as a result of decisions reached as part of the strategic review, we may have a different perspective on our reporting units and the forecasts of cash flow used in estimating the fair value of our reporting units as part of our annual testing of goodwill and other intangibles for impairment. These changes could impact the outcome of our annual goodwill impairment analysis and may result in other restructuring charges.

Principles of Consolidation

Our condensed consolidated financial statements have been prepared in accordance with accounting principles generally accepted in the United States ("U.S. GAAP") and include the accounts of KBR and our wholly owned and majority-owned, controlled subsidiaries and variable interest entities of which we are the primary beneficiary. We account for investments over which we have significant influence but not a controlling financial interest using the equity method of accounting. See Note 7 to our condensed consolidated financial statements for further discussion on our equity investments and variable interest entities. The cost method is used when we do not have the ability to exert significant influence. All material intercompany balances and transactions are eliminated in consolidation. For the nine months ended September 30, 2014, we recorded $8 million for an error originating in 2013 related to the gain from receipts of insurance proceeds. The net effect of the correction was a decrease in 2014 net loss of $8 million.

Certain prior year amounts have been reclassified to conform to the current year presentation on the condensed consolidated statement of income, condensed consolidated balance sheets and the condensed consolidated statements of cash flows. Effective December 31, 2013, we reclassified equity in earnings of unconsolidated affiliates from revenues to a separate component of operating income on our condensed consolidated statement of income. We reclassified the three months and nine months ended September 30, 2013 amounts to conform to our revised presentation as a component of operating income but not a component of revenues.

We have evaluated all events and transactions occurring after the balance sheet date but before the financial statements were issued and have made the appropriate adjustments and included the appropriate disclosures.

Restatement of Previously Reported Condensed Consolidated Financial Statements

As indicated in our 2013 Annual Report on Form 10-K/A, we have restated our Condensed Consolidated Statements of Income, Condensed Consolidated Statements of Comprehensive Income and Condensed Consolidated Statements of Cash Flows and the related notes for the three and nine months ended September 30, 2013. We determined the restatement was necessary due to the materiality of the $89 million of additional estimated costs to complete our Canadian pipe fabrication and module assembly contracts within our Services business segment which we identified subsequent to filing our Form 10-K on February 27, 2014 and which we corrected in our Form 10-K/A filed on May 30, 2014.

The restatement had the following impact on the condensed consolidated statements of income for the three and nine months ended September 30, 2013:

• a reduction in "revenues" of $25 million consisting of a $28 million decrease related to the error on the contracts within our Services business segment, a $4 million increase related to an error on a long-term construction project in our Gas Monetization business segment and a $1 million decrease related to the correction of several immaterial errors;

• an increase in "cost of revenues" of $62 million due to the recognition of a $61 million reserve for losses on uncompleted contracts related to the error on the contracts within our Services business segment and $1 million related to other immaterial corrections; and

• a $15 million tax benefit consisting of a $9 million tax benefit related to the error in our Services business segment and a $6 million tax benefit representing the tax effect of the correction of several immaterial errors.

Use of Estimates

The preparation of our condensed consolidated financial statements in conformity with U.S. GAAP requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosures of contingent assets and liabilities and the reported amounts of revenues and expenses during the reporting period, including:

• project revenues, costs and profits on engineering, construction, pipe fabrication and module assembly, and government services contracts, including recognition of estimated losses on uncompleted contracts,

• uncollectible receivables, claims to and from customers, recoveries of costs from subcontractors, vendors and others,

• provisions for income taxes, recoverability of deferred tax assets and valuation of uncertain tax positions,

• recoverability of goodwill, other intangibles and long-lived assets and related estimated lives,

• recoverability of equity method and cost method investments,

• valuation of pension obligations,

• accruals for estimated liabilities and litigation outcomes,

• consolidation of variable interest entities, and

• valuation of stock-based compensation.

In accordance with normal practice in the construction industry, we include in current assets and current liabilities amounts related to construction contracts realizable and payable over a period in excess of one year. Actual amounts may differ from those included in the accompanying condensed consolidated financial statements, if the underlying estimates and assumptions upon which the financial statements are based change in the future.

Gross Profit

Gross profit represents revenues less the cost of revenues, which includes overhead costs directly attributable to the business segment. See Note 2 to our condensed consolidated financial statements for presentation of our gross profit by reportable segment.

Accounts Receivable

Accounts receivable are recorded at the invoiced amount based on contracted prices. Amounts collected on accounts receivable are included in net cash provided by operating activities in the condensed consolidated statements of cash flows.

We establish an allowance for doubtful accounts based on the assessment of the customers’ willingness and ability to pay. In addition to such allowances, there are often items in dispute or being negotiated that may require us to make an estimate as to the ultimate outcome. Past due receivable balances are written off when our internal collection efforts have been unsuccessful in collecting the amounts due. See Note 4 to our condensed consolidated financial statements for our discussion on accounts receivable.

Retainage, included in accounts receivable, represents amounts withheld from billings by our customers pursuant to provisions in the contracts and may not be paid to us until the completion of specific tasks on the project. Retainage may also be subject to restrictive conditions such as performance guarantees. Our retainage receivable excludes amounts withheld by the United States ("U.S.") government on certain contracts. See Note 11 to our condensed consolidated financial statements for our discussion on U.S. government receivables.

Costs and Estimated Earnings in Excess of Billings on Uncompleted Contracts (including Claims) and Advanced Billings and Billings in Excess of Costs and Estimated Earnings on Uncompleted Contracts

Costs and estimated earnings in excess of billings on uncompleted contracts ("CIE") represent the excess of contract costs and profits recognized to date using the percentage-of-completion method over billings to date on certain contracts. Billings in excess of costs and estimated earnings on uncompleted contracts ("BIE") represents the excess of billings to date over the amount of contract costs and profits recognized to date using the percentage-of-completion method on certain contracts. See Note 5 to our condensed consolidated financial statements for our discussion on CIE and BIE.

Unapproved Change Orders and Claims

When estimating the amount of total gross profit or loss on a contract, we sometimes include unapproved change orders and claims to our customers as adjustments to revenues when the criteria under ASC 605-35 is met. We also include estimates of claims to vendors, subcontractors and others as adjustments to total estimated costs. Unapproved change orders and claims are recorded to the extent of the lesser of the amounts management expects to recover or to costs incurred and include no profit until they are finalized or approved.

Goodwill

Effective January 1, 2014, we reorganized four of the five reporting units in the Infrastructure, Government and Power ("IGP") business segment into three geographic-based units. This reorganization allows the IGP business segment to focus its engineering, procurement, construction and defense services to customers on a more local level. We have concluded that each of these geographic-based units will be considered a separate reporting unit for goodwill impairment testing purposes. As a result, we performed an additional impairment test on the three newly reorganized reporting units on January 1, 2014 as required by ASC 350-20, utilizing the same methodology as our annual goodwill impairment test, and no indication of impairment was identified. For more detail on our methodology and assumptions, see "Critical Accounting Policies" in our 2013 Annual Report on Form 10-K/A.

Share-based Compensation

Effective January 1, 2014, we changed our methodology for estimating the expected term of our option awards from the simplified method and now measure subsequent stock option awards using an expected term based on KBR’s historical experience.

Reserve for Estimated Losses on Uncompleted Contracts

Our reserve for estimated losses on uncompleted contracts is included in "other current liabilities" on our condensed consolidated balance sheet. Our total reserve as of September 30, 2014 and December 31, 2013 is $118 million and $109 million, respectively, including $87 million and $97 million, respectively, related to our Canadian pipe fabrication and module assembly projects. Based on current contracts and work authorizations, we anticipate completion of these Canadian pipe fabrication and module assembly projects in 2015. See Note 2 to our condensed consolidated financial statements for additional information on changes in estimates related to our Canadian pipe fabrication and module assembly projects.

XML

Consolidated Statements Of Comprehensive Income (USD $) In Millions, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013
Statement of Comprehensive Income [Abstract]
Net income	$ 45	$ 15	$ 33	$ 223
Net cumulative translation adjustments (CTA)[Abstract]
Cumulative translation adjustments, net of tax	(49)	16	(27)	(36)
Reclassification adjustment for CTA included in net income	0	0	1	1
Net cumulative translation adjustment, net of taxes	(49)	16	(26)	(35)
Pension liability adjustments, net of tax	0	0	0	0
Reclassification adjustment for pension liability gains included in net income	8	4	25	20
Net pension liability adjustments, net of taxes	8	4	25	20
Unrealized gains (losses) on derivatives:
Unrealized holding (losses) on derivatives, net of tax	0	0	1	0
Reclassification adjustment for losses included in net income	(1)	0	(1)	0
Net unrealized loss on derivatives, net of taxes	(1)	0	(2)	0
Other comprehensive income (loss), net of tax	(42)	20	(3)	(15)
Comprehensive income	3	35	30	208
Less: Comprehensive income attributable to noncontrolling interests	(16)	(64)	(55)	(99)
Comprehensive income attributable to KBR	$ (13)	$ (29)	$ (25)	$ 109

XML

U.S. Government Matters

9 Months Ended

Sep. 30, 2014

United States Government Contract Work [Abstract]

U.S. Government Matters

U.S. Government Matters

We provide services to various U.S. governmental agencies, which include the U.S. Department of Defense (“DoD”), the Department of State and others. We may have disagreements or experience performance issues on our U.S. government contracts. When performance issues arise under any of these contracts, the government retains the right to pursue various remedies, including challenges to expenditures, suspension of payments, fines and suspensions or debarment from future business with the government.

Our work with the U.S. government in the Iraq war zone has ended. We have been in the process of closeout with these contracts since 2011, and we expect the closeout process to continue through at least 2018. As a result of our work in a war zone from 2002 to 2011, there are multiple claims and disputes pending between us and the government, all of which need to be resolved to close the contracts. The closeout process includes resolving objections raised by the government through a billing dispute process referred to as Form 1s and Memorandums for Record ("MFRs") and resolving results from government audits. We continue to work with the government to resolve these issues and are engaged in efforts to reach mutually acceptable resolution of these outstanding matters. However, for certain of these matters, we have filed claims with the Armed Services Board of Contract Appeals ("ASBCA") or the U.S. Court of Federal Claims ("COFC"). We also have matters related to ongoing litigation or investigations involving U.S. government contracts. We anticipate billing additional labor, vendor resolution and litigation costs as we resolve the open matters. At this time, we cannot determine the timing or net amounts to be collected or paid to close out these contracts.

Form 1s

The government has issued Form 1s questioning or objecting to costs we billed to them. We believe the amounts we have invoiced the customer are in compliance with our contract terms; however, we continue to evaluate our ability to recover these amounts from our customer as new information becomes known. A summary of our Form 1s received and amounts associated with our Form 1s is as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Form 1s issued by the government and outstanding (a)	$	229	$	274
Amounts withheld by government (included in the Form 1s amount above) (b)	137		137
Amounts withheld from subcontractors by us	33		50
Claims loss accruals (c)	62		74

(a) Included in the amounts shown is $56 million related to our Private Security matter discussed below in which KBR was granted full recovery of the amounts claimed. The September 30, 2014 balance excludes amounts related to H-29 as we have settled this matter. See discussion below.

(b) Recorded in "claims and accounts receivable" on our condensed consolidated balance sheets. We believe these amounts are probable of collection.

(c) Recorded as a reduction to "claims and accounts receivable" and in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe the likelihood we would incur a loss related to this matter in excess of the loss accruals we have recorded is remote.

Summarized below are some of the details associated with individual Form 1s as part of the total explained above.

Private Security. Starting in February 2007, we received a series of Form 1s from the Defense Contract Audit Agency ("DCAA") informing us of the government's intent to deny reimbursement to us under the LogCAP III contract for amounts related to the use of private security contractors ("PSCs") by KBR and a subcontractor in connection with its work for KBR providing dining facility services in Iraq between 2003 and 2006. The government challenged $56 million in billings. The government had previously paid $11 million and has withheld payments of $45 million, which, as of September 30, 2014, we have recorded as due from the government related to this matter in "claims and accounts receivable" on our condensed consolidated balance sheets.

On June 16, 2014, we received a decision from the ASBCA which agreed with the KBR's position that the LogCAP III contract did not prohibit the use of PSCs to provide force protection to KBR or subcontractor personnel, that there was a need for force protection and that the costs were reasonable. The ASBCA also found that the Army breached its obligation to provide force protection. Accordingly, we believe that we are entitled to reimbursement by the Army for the amounts charged by our subcontractors, even if they incurred costs for PSCs. The Army had 120 days to appeal and on October 14, 2014 gave notice of its intent to appeal. We believe the likelihood that we will incur a loss related to this matter is remote, and therefore we have not accrued any loss provisions related to this matter.

Containers. In June 2005, the DCAA questioned billings on costs associated with providing containerized housing for soldiers and supporting civilian personnel in Iraq. The Defense Contract Management Agency ("DCMA") recommended that payment for the billings be withheld pending receipt of additional explanation or documentation to support the subcontract costs. The Form 1 was issued for $51 million in billings. Of this amount, the government had previously paid $25 million and has withheld payments of $26 million, which as of September 30, 2014, we have recorded in "claims and accounts receivable" on our condensed consolidated balance sheets.

Included in "other liabilities" on our condensed consolidated balance sheets is $31 million of payments withheld from subcontractors related to pay-when-paid contractual terms. Of this amount, $2 million is due from the government and recorded in "claims and accounts receivable" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have withheld from subcontractors and the loss accruals we have recorded is remote.

There are three related actions stemming from the DCMA's action to disallow and withhold funds. First, in April 2008 we filed a counterclaim in arbitration against our LogCAP III subcontractor, First Kuwaiti Trading Company, to recover the amounts we paid to the subcontractor for containerized housing if we should lose the contract dispute with the government over the allowability of the container claims. Second, during the first quarter of 2011 we filed a complaint before the ASBCA to contest the Form 1s and to recover the amounts withheld from us by the government. At the request of the government, that complaint was dismissed without prejudice in January 2013 so that the government could pursue its False Claims Act ("FCA") suit described below. We are free to re-file the complaint in the future. Third, this matter is also the subject of a separate claim filed by the Department of Justice ("DOJ") for alleged violation of the FCA as discussed further below under the heading “Investigations, Qui Tams and Litigation.”

CONCAP III. From February 2009 through September 2010, we received Form 1s from the DCAA disapproving billed costs related to work performed under our CONCAP III contract with the U.S. Navy to provide emergency construction services primarily to government facilities damaged by Hurricanes Katrina and Wilma. The Form 1 was issued for $25 million in billings. The government had previously paid $15 million and has withheld payments of $10 million.

As of September 30, 2014, we have recorded $10 million due from the government related to these matters in "claims and accounts receivable" on our condensed consolidated balance sheets. As of September 30, 2014, we have accrued our estimate of probable loss related to an unfavorable settlement of this matter recorded in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have accrued is remote.

In February 2012, the Contracting Officer rendered a Contracting Officer Final Determination (“COFD”) disallowing $15 million of direct costs. We filed an appeal with the ASBCA in June 2012. Trial was held before the ASBCA in September 2014, and post hearing briefs are due in November 2014. We expect it will take several months before a ruling is issued on this matter. We believe we undertook adequate and reasonable steps to ensure that proper bidding procedures were followed and the amounts billed to the government were reasonable and not in violation of the Federal Acquisition Regulations ("FAR") and that the ASBCA will rule in our favor.

Other. The government has issued Form 1s for other matters questioning $29 million of billed costs. For these matters, the government previously paid $16 million and has withheld payment of $13 million, which we have recorded in "claims and accounts receivable" on our condensed consolidated balance sheets. We have accrued our estimate of probable loss in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have accrued is remote.

We have other matters in dispute with the government either in the COFC or before the ASBCA. These claims represent $12 million in claimed costs primarily associated with the pass-through of subcontractor claims associated with a termination for convenience in Iraq. We have accrued $4 million as our estimate of probable loss in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to these matters in excess of the amounts we have accrued is remote.

Matters Concluded During the Fiscal Year

Tamimi.

Tamimi - Form 1. In 2006, the DCAA questioned the price reasonableness of billed costs related to dining facilities in Iraq. We responded to the DCMA that we believe our costs are reasonable. The prices obtained for these services were from our subcontractor Tamimi. The Form 1 was issued for $68 million in billings. The government had previously paid $25 million and has withheld payments of $43 million.

In April 2012, the COFC ruled that KBR's negotiated price for certain dining facility services was not reasonable and that we were entitled to only $12 million of the amounts withheld from us by the government plus any applicable interest ($2 million). In addition, while this matter was before the court the U.S. government withheld an additional $1 million. As a result of this ruling, we recognized a pre-tax charge of $28 million as a reduction to revenues. We appealed the U.S. COFC ruling and in September 2013, a three judge panel of the Federal Circuit Court of Appeals issued its opinion upholding the ruling. In June 2014, we filed a joint petition for certiorari with the U.S. Supreme Court for this litigation and in a related case involving another subcontractor.

At September 30, 2014, we have recorded $43 million due from the government related to these matters in "claims and accounts receivable" on our condensed consolidated balance sheets and accrued our estimate related to any probable loss in "other liabilities" on our condensed consolidated balance sheets. The Supreme Court denied our petition in October 2014, leaving us with no further legal recourse. At this time, we believe the likelihood we would incur a loss related to this matter in excess of the loss accruals we have recorded is remote.

Tamimi - DOJ. In March 2011, the DOJ filed a counterclaim in the COFC alleging KBR employees accepted bribes from Tamimi in exchange for awarding a master agreement for dining facilities services to Tamimi. The April 2012 ruling on the Tamimi matter discussed above dismissed the DOJ claims as lacking merit. On appeal, the DOJ's efforts to overturn the trial court ruling have been denied, and the DOJ's request for Supreme Court review was also denied.

Fly America. In 2007, the DCAA questioned costs related to our compliance with the provisions of the Fly America Act. Subject to certain exceptions, the Fly America Act requires Federal employees and others performing U.S. government-financed contracts to travel by U.S. flag air carriers. There were times when we transported personnel in connection with our services for the U.S. military where we may not have been in compliance with the Fly America Act and its interpretations through the FAR and the Comptroller General. In October 2011, at the request of the DCMA, we submitted an estimate of the impact of our non-compliance with the Fly America Act for 2003 and 2004. In May 2014, the Contracting Officer rendered a COFD disallowing $3 million in billings. We have settled with the government on this matter. The resolution of this matter did not have a material impact on our results of operations for the period presented. We consider this matter concluded.

H-29. In 2011, we received a Form 1 from the DCAA disapproving certain transportation costs associated with replacing employees who were deployed in Iraq and Afghanistan for less than 179 days. No payments have been withheld by the government for this matter.  The DCAA claimed these replacement costs violated the terms of the LogCAP III contract which expressly disallow certain costs associated with the contractor rotation of employees who have deployed less than 179 days including costs for transportation, lodging, meals, orientation and various forms of per diem allowances.  We disagreed with the DCAA’s interpretation and application of the contract terms as it was applied to circumstances outside of our control including war risks, sickness, death, termination for cause or resignation and that such costs should be allowable. We filed a declaratory judgment to have the clause interpreted before the COFC. On July 9, 2014, we reached agreement with the Army on the matter of an interpretation of the clause that essentially confirms KBR's interpretation and rejects that of the DCAA. On July 18, 2014, the ASBCA granted our motion to dismiss the appeal with prejudice. The resolution of this matter did not have a material impact on our results of operations for the periods presented. We consider this matter concluded. There is a parallel qui tam further described under the caption "Chillcott qui tam" below.

Audits

In addition to reviews being performed by the U.S. government through the Form 1 process, the negotiation, administration and settlement of our contracts, consisting primarily of DoD contracts, are subject to audit by the DCAA, which serves in an advisory role to the DCMA. The DCMA is responsible for the administration of our contracts. The scope of these audits include, among other things, the allowability, allocability and reasonableness of incurred costs, provisional approval of annual billing rates, approval of annual overhead rates, compliance with the FAR and Cost Accounting Standards (“CAS”), compliance with certain unique contract clauses and audits of certain aspects of our internal control systems. We attempt to resolve all issues identified in audit reports by working directly with the DCAA and the Administrative Contracting Officers ("ACOs").

As a result of these audits, there are risks that what we have billed as recoverable costs may be assessed by the government to be unallowable. We believe our billings are in compliance with our contract terms. In some cases, we may not reach agreement with the DCAA or the ACOs regarding potentially unallowable costs which may result in our filing of claims in various courts such as the ASBCA or the COFC. We have accrued our estimate of potentially unallowable costs using a combination of specific estimates and our settlement rate experience with the government. As of September 30, 2014, we have accrued $50 million as our estimate of probable loss as a reduction to "claims and accounts receivable" and in "other liabilities" on our condensed consolidated balance sheets. These accrued amounts are associated with years for which we have or do not have audit reports. We have received audit reports for 2004 through 2007 and 2009. We have not yet received completed audit reports for 2008 or 2010 through 2012. Additionally, we have not reached an agreement with the government on definitive incurred cost rates after 2003 except for 2007 and 2009.

We only include amounts in revenues related to disputed and potentially unallowable costs when we determine it is probable that such costs will result in the collection of revenues. We generally do not recognize additional revenues for disputed or potentially unallowable costs for which revenues have been previously reduced until we reach agreement with the DCAA and/or the ACOs that such costs are allowable.

In addition to audits of our incurred costs, the government also reviews our compliance with the CAS and the adequacy and compliance of our CAS disclosure statements. We are working with the government to resolve several outstanding alleged CAS non-compliance issues.

Investigations, Qui Tams and Litigation

The following matters relate to ongoing litigation or investigations involving U.S. government contracts.

First Kuwaiti Trading Company arbitration. In April 2008, First Kuwaiti Trading Company ("FKTC" ), one of our LogCAP III subcontractors, filed for arbitration with the American Arbitration Association of all its claims under various LogCAP III subcontracts. FKTC sought damages in the amount of $134 million. After completing hearings on all of FKTC's claims, an arbitration panel awarded $17 million and interest to FKTC for claims involving damages on lost or unreturned vehicles. In addition, we have determined that we owe FKTC $30 million in connection with five other subcontracts. We have an agreement with FKTC that no damages will be paid until our counterclaim is decided, but FKTC filed a motion with the arbitration panel to compel KBR to pay all amounts outstanding. We paid FKTC $15 million in the third quarter of 2014 and will pay $7 million on pay-when-paid terms. Consequently, FKTC withdrew its motion with the arbitration panel.

We believe any damages ultimately awarded to FKTC will be billable under the LogCAP III contract. Accordingly, we have accrued amounts in "accounts payable" and "other current liabilities" on our condensed consolidated balance sheets and related amounts in "claims and accounts receivable" on our condensed consolidated balance sheets for the amounts awarded to FKTC pursuant to the terms of the contract. At this time, we do not believe we face a risk of material loss in excess of the accruals we have recorded. We also have a counterclaim still pending for any funds we should have to return or refund to the government in the container litigation discussed above.

Electrocution litigation. During 2008, a lawsuit was filed against KBR in Pittsburgh, PA, in the Allegheny County Common Pleas Court alleging that the Company was responsible for an electrical incident which resulted in the death of a soldier. This incident occurred at the Radwaniyah Palace Complex near Baghdad, Iraq. It is alleged in the suit that the electrocution incident was caused by improper electrical maintenance or other electrical work. KBR denies that its conduct was the cause of the event and denies legal responsibility. Plaintiffs are claiming unspecified damages for personal injury, death and loss of consortium by the parents. On July 13, 2012, the Court granted our motions to dismiss, concluding that the case is barred by the Political Question Doctrine and preempted by the Combatant Activities Exception to the Federal Tort Claims Act. The plaintiffs appealed to the Third Circuit Court of Appeals. In August 2013, the Third Circuit Court of Appeals issued an opinion reversing the trial court's dismissal and remanding for further discovery and legal rulings. KBR filed its motion for rehearing en banc, which was denied, and we have filed an application for writ of certiorari to the U.S. Supreme Court. Four amicus briefs have been filed in support of KBR's legal arguments. On June 16, 2014, the U.S. Supreme Court issued an order inviting the Solicitor General to file briefs in the electrocution litigation, expressing the views of the United States as to KBR's pending applications for writ of certiorari. We anticipate these briefs will not be filed until the fourth quarter of 2014. At this time, we believe the likelihood we would incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

Burn Pit litigation. From November 2008 through March 2013, KBR was served with over 50 lawsuits in various states alleging exposure to toxic materials resulting from the operation of burn pits in Iraq or Afghanistan in connection with services provided by KBR under the LogCAP III contract. Each lawsuit has multiple named plaintiffs and seeks class certification. The lawsuits primarily allege negligence, willful and wanton conduct, battery, intentional infliction of emotional harm, personal injury and failure to warn of dangerous and toxic exposures which has resulted in alleged illnesses for contractors and soldiers living and working in the bases where the pits were operated. The plaintiffs are claiming unspecified damages. All of the pending cases were removed to Federal Court and have been consolidated for multi-district litigation treatment before the U.S. Federal District Court in Baltimore, Maryland.

In February 2013, the Court dismissed the case against KBR, accepting all of KBR's defense claims including the Political Question Doctrine; the Combatant Activities Exception to the Federal Tort Claims Act; and Derivative Sovereign Immunity. The plaintiffs appealed to the Fourth Circuit Court of Appeals on March 27, 2013. On March 6, 2014, the Fourth Circuit Court vacated the order of dismissal and remanded this multi-district litigation for further action, including a ruling on state tort law and its impact upon the "Contractor on the Battlefield" defenses. KBR has filed a petition for certiorari with the U.S. Supreme Court. Three amicus briefs have been filed in support of KBR's legal arguments. On June 16, 2014, the U.S. Supreme Court issued an order inviting the Solicitor General to file briefs in the burn pit litigation, expressing the views of the United States as to KBR's pending applications for writ of certiorari. We anticipate these briefs will not be filed until the fourth quarter of 2014. At this time we believe the likelihood that we would incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

Sodium Dichromate litigation. From December 2008 through September 2009, five cases were filed in various Federal District Courts against KBR by national guardsmen and other military personnel alleging exposure to sodium dichromate at the Qarmat Ali Water Treatment Plant in Iraq in 2003. The majority of the cases were re-filed and consolidated into two cases, with one pending in the U.S. District Court for the Southern District of Texas and one pending in the U.S. District Court for the District of Oregon.  A single plaintiff case was filed on November 30, 2012 in the District of Oregon Eugene Division. Collectively, the suits represent approximately 170 individual plaintiffs all of which are current and former national guardsmen or British soldiers who claim they were exposed to sodium dichromate while providing security services or escorting KBR employees who were working at the water treatment plant, claim that the defendants knew or should have known that the potentially toxic substance existed and posed a health hazard, and claim that the defendants negligently failed to protect the plaintiffs from exposure.  The plaintiffs are claiming unspecified damages. The U.S. Army Corps of Engineers (“USACE”) was contractually obligated to provide a benign site free of war and environmental hazards before KBR's commencement of work on the site. KBR notified the USACE within two days after discovering the potential sodium dichromate issue and took effective measures to remediate the site.  Services provided by KBR to the USACE were under the direction and control of the military and therefore, KBR believes it has adequate defenses to these claims.  KBR also has asserted the Political Question Doctrine and other government contractor defenses. Additionally, studies by the U.S. government and others on the effects of exposure to the sodium dichromate contamination at the water treatment plant have found no long term harm to the soldiers.

Texas Proceedings. On August 16, 2012, the court in the case pending in the U.S. District Court for the Southern District of Texas Court denied KBR's motion to dismiss plaintiffs' claims. On August 29, 2012, the court certified its order for immediate appeal under 28 U.S.C. § 1292(b) to the U.S. Court of Appeals for the Fifth Circuit, and stayed proceedings in the District Court pending the appeal. On November 28, 2012, the Fifth Circuit granted KBR permission to appeal. On November 7, 2013, a three judge panel of the Court returned the case to the trial court, holding the interlocutory appeal was improperly granted. We sought review by the entire court on this opinion which was denied. The trial court has agreed to stay the trial while we seek review by the U.S. Supreme Court. KBR has filed a petition for certiorari with the U.S. Supreme Court. At this time we believe the likelihood that we would incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

Oregon Proceedings. On November 2, 2012 in the Oregon case, a jury in the U.S. District Court for the District of Oregon issued a verdict in favor of the plaintiffs on their claims, and awarded them approximately $10 million in actual damages and $75 million in punitive damages. We filed post-verdict motions asking the court to overrule the verdict or order a new trial. On April 26, 2013, the court ruled for plaintiffs on all issues except one, reducing the total damages to $81 million which consists of $6 million in actual damages and $75 million in punitive damages. Trials for the remaining plaintiffs in Oregon will not take place until the appellate process is concluded. The court issued a final judgment on May 10, 2013, which was consistent with the previous ruling. KBR appealed the ruling. Briefing is complete and oral arguments have not yet been scheduled by the court. Additionally, five amicus curiae briefs have been filed in support of our arguments. Our basis for appeal include the trial court's denial of the Political Question Doctrine, the Combat Activities Exception in the Federal Tort Claims Act, a lack of personal jurisdiction over KBR in Oregon and numerous other legal issues stemming from the court's rulings before and during the trial. We have already filed proceedings to enforce our rights to reimbursement and payment pursuant to the FAR under the Restore Iraqi Oil contract ("RIO contract") with the USACE as referenced below.

In the U.S. Court of Appeals for the Ninth Circuit, we have also filed a motion for summary reversal of the court's decision on personal jurisdiction due to a recently issued Supreme Court decision which supports our position that the Oregon court did not have jurisdiction in the case because KBR did not have contact with the state. The U.S. Court of Appeals for the Ninth Circuit has consolidated the motion with our pending appeal.

At this time we believe the likelihood that we will ultimately incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

COFC/ASBCA Claims. During the period of time since the first litigation was filed against us, we have incurred legal defense costs that we believe are reimbursable under the related government contract. We have billed for these costs and filed claims to recover the associated costs incurred to date. In late 2012 and early 2013, we filed suits against the U.S. government in the COFC for denying indemnity in the sodium dichromate cases, for reimbursement of legal fees pursuant to our contract with the government and for breach of contract by the government for failure to provide a benign site as required by our contract.  The RIO contract required KBR personnel to begin work in Iraq as soon as the invasion began in March 2003. Due to KBR's inability to procure adequate insurance coverage for this work, the Secretary of the Army approved the inclusion of an indemnification provision in the RIO Contract pursuant to Public Law 85-804.

On March 7, 2014, the COFC issued a ruling on the government's motion dismissing KBR's claims on procedural grounds. The decision did not prohibit us from resubmitting the claims to the contracting officer which we did. On April 4, 2014, we submitted a supplemental certified claim to the RIO contracting officer for additional legal fees incurred in defending the sodium dichromate cases. On June 9, 2014, we filed an appeal to the ASBCA due to the contracting officer's failure to issue a final decision on claims totaling approximately $30 million. The USACE filed an answer, denying our claims. We filed a motion for judgment on the pleadings, asking the court to rule in KBR's favor on the 85-804 indemnity clause based on the admissions made by the USACE in its answer. The court has agreed to stay our other claims while we conduct limited discovery on the 85-804 indemnity.

Qui Tams. Of the active qui tams for which we are aware, the government has joined one of them (see DOJ FCA complaint - Iraq Subcontractor below). We believe the likelihood that we would incur a loss in the qui tams the government has not joined is remote and as of September 30, 2014, no amounts have been accrued. Costs incurred in defending the qui tams cannot be billed to the government until those matters are successfully resolved in our favor. If successfully resolved, we can bill 80% of the costs to the government under the controlling provisions of the FAR. As of September 30, 2014, we have incurred $10 million in legal costs to date in defending ourselves in qui tams.

Barko qui tam. Relator Harry Barko was a KBR subcontracts administrator in Iraq for a year in 2004/2005. He filed a qui tam lawsuit in June 2005 in the U.S. District Court for the District of Columbia (D.C.), alleging violations of the FCA by KBR and KBR subcontractors Daoud & Partners and Eamar Combined for General Trading and Contracting. The claim was unsealed in March of 2009. Barko alleges that KBR fraudulently charged the government for the purchase of laundry facilities from Daoud, that KBR paid Daoud for the construction of a substandard man-camp, that Daoud double-billed KBR for labor, that KBR improperly awarded well-drilling subcontracts to Daoud, and that Daoud charged excessive prices for these services and did not satisfactorily complete them. Barko also alleges fraudulent charges arising out of Eamar’s well-drilling services.

The DOJ investigated Barko’s allegations and elected not to intervene. KBR filed a Motion to Dismiss alleging that the complaint was legally insufficient to state a case under the FCA and this motion was denied. KBR filed its Answer to the First Amended Complaint and a Motion for Summary Judgment. On February 3, 2014, Barko filed a Motion to Compel production of privileged investigative files, which KBR opposed. On March 6, 2014, in an unprecedented opinion, the District Court granted the motion and ordered KBR to produce the records, thereafter also denying KBR’s motions to stay the order and for interlocutory appeal. On March 12, 2014, KBR filed its Petition for Mandamus with the D.C. Circuit Court, seeking an order reversing the trial court’s order of production. A hearing on the mandamus was argued on May 7, 2014 and on June 27, 2014, the Circuit Court granted KBR's Petition for Mandamus and vacated the trial court's order of production. On July 28, 2014, Barko appealed the mandamus ruling and on September 2, 2014 the appeal was denied. Barko has indicated that he will file a petition for certiorari with the U.S. Supreme Court. All other scheduled activity, including a ruling on KBR’s Motion for Summary Judgment, had been stayed pending the outcome of the mandamus appeal. Following the loss on appeal with the Circuit Court, Barko asked the District Court to extend the stay of proceedings and on September 15, 2014 that motion was denied. The trial court has ordered briefing as to whether KBR has waived its privilege and briefing was completed on October 20, 2014. We believe the likelihood that we will incur a loss related to this matter is remote, and therefore as of September 30, 2014 we have not accrued any loss provisions related to this matter.

Chillcott qui tam. On September 25, 2014, Chillcott's counsel advised that they would dismiss the suit described below with prejudice subject to resolution of ancillary issues. On October 28, 2014, Chillcott filed to dismiss the suit with prejudice. We consider this matter concluded.

On November 21, 2011, KBR was advised of the partial unsealing of a qui tam suit brought by a former KBR employee, Karen Chillcott, in the U.S. District Court for the Central District of Illinois, Rock Island Division, alleging that KBR committed fraud in billing the government for unallowable mobilization and demobilization costs for LogCAP III and IV personnel. Chillcott alleges that these costs are unallowable under Clause H-29 of the LogCAP III Contract and Clause H-26 of the LogCAP IV Contract (the “Tour of Duty” clauses). The government declined to intervene in this suit. Although this matter is in the early stages, we have been addressing issues surrounding the H-29 clause for several years. We do not believe the complaint raises new factual issues. The case was partially unsealed on September 10, 2013.  The DOJ investigated Chillcott’s allegations and declined to intervene. On June 28, 2013, KBR filed a Motion to Dismiss which was denied on October 25, 2013. On June 10, 2014, KBR notified Chillcott of the interpretation agreement with the Army as described in more detail above in the H-29 Form 1 discussion.

DOJ False Claims Act complaint - Containers. In November 2012, the DOJ filed a complaint in the U.S. District Court for the Central District of Illinois in Rock Island, IL, related to our settlement of delay claims by our subcontractor, FKTC, in connection with FKTC's provision of living trailers for the bed down mission in Iraq in 2003-2004. The DOJ alleges that KBR knew that FKTC had submitted inflated costs; that KBR did not verify the costs; that FKTC had contractually assumed the risk for the costs which KBR submitted to the government; that KBR concealed information about FKTC's costs from the government; that KBR claimed that an adequate price analysis had been done when in fact one had not been done; and that KBR submitted false claims for reimbursement to the government in connection with FKTC's services during the bed down mission. Our contractual dispute with the Army over this settlement has been ongoing since 2005. We believe these sums were properly billed under our contract with the Army and are not prohibited under the LogCAP III contract. We strongly contend that no fraud was committed. On May 6, 2013, KBR filed a motion to dismiss and in March 2014 the motion to dismiss was denied. We filed our answer on May 2, 2014 and on May 23, 2014 the government filed a Motion to Strike certain affirmative defenses. We are contesting that motion and proceeding with discovery. On September 30, 2014, the District Court granted FKTC's motion to dismiss for lack of personal jurisdiction. A scheduling conference has been set for December 5, 2015. At this time, we believe the likelihood that we would incur a loss related to this matter is remote. As of September 30, 2014, no amounts have been accrued.

DOJ False Claims Act complaint - Iraq Subcontractor. In January 2014, the DOJ filed a complaint in the U.S. District Court for the Central District of Illinois in Rock Island, IL, against KBR and two former KBR subcontractors alleging that three former KBR employees were offered and accepted kickbacks from these subcontractors in exchange for favorable treatment in the award and performance of subcontracts to be awarded during the course of KBR's performance of the LogCAP III contract in Iraq. The complaint alleges that as a result of the kickbacks, we submitted invoices with inflated or unjustified subcontract prices, resulting in alleged violations of the FCA and the Anti-Kickback Act. While the suit is new, the DOJ's investigation dates back to 2004. We self-reported most of the violations and tendered credits to the government as appropriate. On April 22, 2014, we filed our answer and on May 13, 2014 the government filed a Motion to Strike certain affirmative defenses. We are contesting this motion. As of September 30, 2014, we have accrued our best estimate of probable loss related to an unfavorable settlement of this matter recorded in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe the likelihood that we would incur a loss related to this matter in excess of the amounts we have accrued is remote.

Other Matters

Claims. We have filed claims with the government related to payments not yet received for costs incurred under various government contracts. Included in our condensed consolidated balance sheets are claims for costs incurred under various government contracts totaling $216 million at September 30, 2014. These claims relate to disputed costs and/or contracts where our costs have exceeded the government's funded value on the task order. We have $118 million of claims primarily from de-obligated funding on certain task orders that were also subject to Form 1s relating to certain DCAA audit issues discussed above.  We believe such disputed costs will be resolved in our favor at which time the government will be required to obligate funds from appropriations for the year in which resolution occurs. These claims are recorded in "claims and accounts receivable" on our condensed consolidated balance sheets.  Of the remaining claims balance of $98 million, $90 million is recorded in "claims and accounts receivable" and the remaining is recorded in "CIE" on our condensed consolidated balance sheets. The amounts recorded in CIE represent costs for which incremental funding is pending in the normal course of business. The claims outstanding at September 30, 2014 are considered to be probable of collection and have been previously recognized as revenues.

XML

Document And Entity Information	9 Months Ended
	Sep. 30, 2014	Oct. 16, 2014
Document and Entity Information [Abstract]
Document Type	10-Q
Amendment Flag	false
Document Period End Date	Sep. 30, 2014
Entity Registrant Name	KBR, INC.
Entity Central Index Key	0001357615
Current Fiscal Year End Date	--12-31
Entity Filer Category	Large Accelerated Filer
Entity Common Stock, Shares Outstanding		145,078,983
Document Fiscal Year Focus	2014
Document Fiscal Period Focus	Q3

XML

Other Commitments And Contingencies

9 Months Ended

Sep. 30, 2014

Commitments and Contingencies Disclosure [Abstract]

Other Commitments and Contingencies

Other Commitments, Contingencies and Disputes

Litigation and regulatory matters related to the Company’s restatement of its 2013 annual financial statements

After the Company announced it would be restating its 2013 annual financial statements, three complaints were filed in the United States District Court for the Southern District of Texas against the Company, our former chief executive officer and our current and former chief financial officers. Two of those complaints were voluntarily dismissed by the plaintiffs, and four parties, including the plaintiff in the remaining case, moved to be appointed lead plaintiff. In September 2014, the court appointed Arkansas Public Employees Retirement System and Local 58/NECA Funds as lead plaintiffs and ordered any new cases arising from the same matters to be consolidated together as In re KBR, Inc. Securities Litigation, Master File No. 14-cv01287. Lead plaintiffs filed an amended and consolidated complaint on October 20, 2014, adding our former chief accounting officer as a defendant. The amended complaint seeks class action status on behalf of our shareholders, alleges violations of Sections 10(b) and 20(a) of the Securities Exchange Act of 1934 arising out of the restatement of our 2013 annual financial statements and seeks undisclosed damages. The defendants intend to file a motion to dismiss the consolidated complaint and to vigorously defend against these claims. As this matter is at a very early stage, we are not able at this time to determine the likelihood of loss, if any, arising from this matter.

In addition, a shareholder derivative complaint, Butorin v. Blount et al, was filed on May 27, 2014 in the United States District Court for the Southern District of Texas on behalf of the Company naming certain current and former members of the Company's board of directors as defendants and the Company as a nominal defendant. The complaint alleges that the named directors breached their fiduciary duties by permitting the Company's internal controls to be inadequate. In August 2014, we filed a motion to dismiss the matter based on the mandatory forum selection clause in the Company's bylaws, which requires, among other things, that all shareholder derivative suits be filed in Delaware. The plaintiff filed his opposition on October 6, 2014 to which we replied on October 21, 2014; the motion is currently pending. As this matter is at a very early stage, we are not able at this time to determine the likelihood of loss, if any, arising from this matter.

We have also received requests for information from the Securities Exchange Commission ("SEC") regarding the restatement of our 2013 annual financial statements. We have been and intend to continue providing our full cooperation with the SEC.

Foreign Corrupt Practices Act (“FCPA”) Investigations

In February 2009, KBR LLC, entered a guilty plea to violations of the FCPA in the United States District Court, Southern District of Texas, Houston Division, related to the Bonny Island investigation. The plea agreement reached with the DOJ resolved all criminal charges in the DOJ’s investigation and called for the payment of a criminal penalty. In addition, we settled a civil enforcement action by the SEC. We also agreed to a period of probation for a three year period that ended on February 17, 2012, after which the monitor certified that KBR’s current anti-corruption compliance program has been appropriately designed and implemented to ensure future compliance with the FCPA and other applicable anti-corruption laws.

In February 2011, M.W. Kellogg Limited (“MWKL”) reached a settlement with the U.K. Serious Fraud Office (“SFO”) in which the SFO accepted that MWKL was not party to any unlawful conduct and assessed a civil penalty. The settlement terms included a full release of all claims against MWKL, its current and former parent companies, subsidiaries and other related parties including their respective current or former officers, directors and employees with respect to the Bonny Island project.

On March 18, 2013, we received a letter from the African Development Bank Group ("ADBG") stating they are in the process of opening a formal investigation into corruption related to the Bonny Island project discussed above. We have entered into a Negotiated Resolution Agreement with the ADBG that includes a financial penalty equivalent to approximately $6.6 million of which $0.3 million has been paid and the remainder is in process. We have also agreed to a three-year debarment from ADBG-sponsored contracts of three inactive Madeira, Portugal-based companies that KBR and its three joint venture partners used to participate in the Bonny Island project.

PEMEX and PEP Arbitration

In 1997 and 1998, we entered into three contracts with PEP, the project owner, to build offshore platforms, pipelines and related structures in the Bay of Campeche, offshore Mexico. PEP is part of PEMEX, the national oil company of Mexico. The three contracts were known as EPC 1, EPC 22 and EPC 28. All three projects encountered significant schedule delays and increased costs due to problems with design work, late delivery and defects in equipment, increases in scope and other changes. During 2008, we were successful in litigating and collecting on valid international arbitration awards against PEP on the EPC 22 and EPC 28 projects.

EPC 1

U.S. Proceedings. PEP took possession of the offshore facilities of EPC 1 in March 2004 after having achieved oil production but prior to our completion of our scope of work pursuant to the contract. As a result of the ensuing dispute, we filed for arbitration with the International Chamber of Commerce ("ICC") in 2004 claiming recovery of damages of approximately $323 million for the EPC 1 project. PEP subsequently filed counterclaims totaling $157 million. In December 2009, the ICC ruled in our favor, and we were awarded a total of approximately $351 million including legal and administrative recovery fees as well as interest. PEP was awarded approximately $6 million on counterclaims, plus interest on a portion of that sum. In connection with this award, we recognized a gain of $117 million net of tax in 2009.

Our collection efforts have been ongoing and have involved multiple actions. On November 2, 2010, we received a judgment in our favor in the U.S. District Court for the Southern District of New York to recognize the award in the U.S. of approximately $356 million plus Mexican value added tax and interest thereon until paid. PEP initiated an appeal to the U.S. Court of Appeals for the Second Circuit. On February 16, 2012, the Second Circuit issued an order remanding the case to the District Court to consider if the decision of the Collegiate Court in Mexico, described below, would have affected the trial court’s ruling. The District Court Judge held a three day hearing on April 10 -12, 2013 to hear evidence about the Collegiate Court decision, which annulled the arbitration award and about whether we have a full and fair remedy in Mexico.

On August 27, 2013, the District Court entered an order stating it would confirm the award even though it had been annulled in Mexico. On September 25, 2013, the District Court entered the signed final judgment of $465 million to be recovered, which includes the original confirmation of the arbitration award and approximately $106 million for performance bonds discussed below, plus interest. The judgment also requires that each party pay value added tax on the amounts each has been ordered to pay. PEP filed a notice of appeal to the U.S. Court of Appeals for the Second Circuit on October 16, 2013 and posted cash for the judgment pending appeal. The case is now on appeal before the U.S. Court of Appeals. Briefing is now closed and oral argument is scheduled for November 20, 2014.

Mexico Proceedings. PEP's attempt to nullify the award in Mexico was rejected by the Mexican trial court in June 2010. PEP then filed an “amparo” action on the basis that its constitutional rights had been violated and this action was denied by the Mexican court in October 2010. PEP subsequently appealed the adverse decision with the Collegiate Court in Mexico on the grounds that the arbitration tribunal did not have jurisdiction and that the award violated the public order of Mexico. Although these arguments were presented in the initial nullification and amparo action, and were rejected in both cases, in September 2011, the Collegiate Court ruled that PEP, by administratively rescinding the contract in 2004, deprived the arbitration panel of jurisdiction thereby nullifying the arbitration award. The Collegiate Court's decision is contrary to the ruling received from the ICC as well as the other Mexican courts which have denied PEP's repeated attempts to nullify the arbitration award. We also believe the Collegiate Court's decision is contrary to Mexican law governing contract arbitration. However, we do not expect the Collegiate Court's decision to affect our ability to ultimately collect the ICC arbitration award in the U.S. due to the posting of cash for the judgment pending appeal and significant assets of PEP in the U.S.

Luxembourg Collection Proceedings. In 2013, we petitioned the Luxembourg court to issue two seizure orders on the assets of PEP and PEMEX that have been served on a number of banks and financial institutions in that country, as we believe these institutions may have PEP and PEMEX assets that are subject to seizure which could be used to satisfy our award. However, under Luxembourg procedure, we will not find out the value of the seized assets until the proceeding is validated. The first seizure order is for the New York award confirmation; the second seizure order is for the performance bonds payment discussed below. PEP and PEMEX contested the first seizure order and the matter was heard on May 27, 2013 where their petition to lift the seizure order was denied. PEP and PEMEX filed an appeal and on December 18, 2013, the Luxembourg Court of Appeals stated it was dissolving the first seizure order against both PEP and PEMEX. This decision is being appealed to the Luxembourg Supreme Court.

Concurrent with our filing of the seizure order, we filed an action in Luxembourg seeking to enforce the ICC award. In March 2013, we received an order from the Luxembourg court recognizing the award. On June 25, 2013, PEMEX and PEP filed an appeal challenging the enforcement order. We are awaiting scheduling of the hearing on the appeal. We cannot begin the validation proceeding until the appeal is concluded.

North American Free Trade Agreement ("NAFTA") Collection Proceedings. We filed arbitration under NAFTA against Mexico and asserted a claim to have our award paid. The parties have selected the arbitrators, a chairman has been named and the first procedural order has been entered.

We will continue to pursue our remedies in the U.S., Luxembourg and other jurisdictions that we determine have assets which can be used to pay the award.

Performance Bonds

In connection with the EPC 1 project, we had approximately $80 million in outstanding performance bonds furnished to PEP when the project was awarded. The bonds were written by a Mexican bond company and backed by a U.S. insurance company which is indemnified by KBR. As a result of the ICC arbitration award in December 2009, the panel determined that KBR had performed on the project, and we believe recovery on the bonds by PEP was precluded by the ICC Award.  PEP filed an action in Mexico in June 2010 against the Mexican bond company to collect the bonds even though the arbitration award determined the limited amounts to be paid to PEP on their counterclaims and offset those claims against the award in favor of KBR.

On June 17, 2013, after multiple proceedings in various Mexican courts and following a demand for payment, we paid $108 million to the Mexican bond company. The $108 million consists of the $80 million in outstanding bonds, plus $26 million in related interest and other expenses and $2 million in legal and banking fees.

On June 21, 2013, we filed a supplemental writ in Luxembourg to cover the amounts paid to the bonding company on the performance bonds. That writ was granted and served on Luxembourg banks. PEP and PEMEX have refused service in Luxembourg and we are currently serving that writ on PEP and PEMEX. Since the decision by the Luxembourg Court of Appeals dissolved the first writ as to PEMEX, we have lifted the second writ as to PEMEX. The second writ remains in effect as to PEP.

On September 25, 2013, the U.S. District Court for the Southern District of New York entered the signed final judgment which included the amount paid on the bonds plus interest. We will pursue reimbursement of the sums paid in the current enforcement action in the U.S. District Court for the Southern District of New York, the courts of Luxembourg, or by our recently filed NAFTA arbitration seeking to recover the bonds as an unlawful expropriation of assets by the government of Mexico.

Consistent with our treatment of claims, we have recorded $401 million, net of advances, in "claims and accounts receivable" on the condensed consolidated balance sheets as we believe it is probable we will recover the amounts awarded to us, including interest, expenses and the amounts we paid on the bonds. PEP has sufficient assets in the U.S. and Luxembourg, which we believe we will be able to attach as a result of the recognition of the ICC arbitration award. Although it is possible we could resolve and collect the amounts due from PEP in the next 12 months, we believe the timing of the collection of the award is uncertain; therefore, consistent with our prior practice, as of September 30, 2014, we continue to classify the amount due from PEP, including the amounts paid on the performance bonds as long term.

ENI Holdings, Inc. (the Roberts & Schaefer Company)

In the third quarter of 2014, KBR and ENI Holdings, Inc. ("ENI") reached agreement to settle the case described below. KBR received $0.8 million from the escrow fund and will retain any tax refunds for the pre-closing period. We consider this matter concluded.

On December 21, 2010, we completed the acquisition of 100% of the outstanding common shares of ENI. ENI was the parent to the Roberts & Schaefer Company, a privately held EPC services company acquired by us in 2010. The purchase price was $280 million plus estimated working capital of $17 million which included cash acquired of $8 million. The total net cash paid at closing of $289 million is subject to an escrowed holdback. As of September 30, 2014, the remaining escrowed holdback was $25 million and primarily related to security for indemnification obligations.

KBR withheld the $25 million in escrow due to KBR's claims under the indemnification provisions of the stock purchase agreement. In December 2012, ENI filed a lawsuit in Delaware Chancery Court alleging KBR is wrongfully withholding the escrowed funds. KBR filed a counterclaim for indemnity and fraud under the terms of the stock purchase agreement. In March 2013, ENI filed a motion to dismiss. The Court denied in part ENI's motion to dismiss KBR's counterclaims in their entirety.

XML

Consolidated Balance Sheets (USD $) In Millions, unless otherwise specified	Sep. 30, 2014	Dec. 31, 2013
Current assets:
Cash and equivalents	$ 1,048	$ 1,106
Accounts receivable, net of allowance for bad debts of $21 and $18	964	1,056
Costs in Excess of Billings, Current	509	399
Current deferred income tax asset	151	168
Other current assets	151	196
Total current assets	2,823	2,925
Property, plant, and equipment, net of accumulated depreciation of $426 and $397 (including net PPE of $61 and $67 owned by a variable interest entity)	410	415
Goodwill	771	772
Intangible assets, net of accumulated amortization of $120 and $112	76	85
Equity in and advances to related companies	149	156
Noncurrent deferred income tax asset	367	344
Noncurrent unbilled receivables on uncompleted contracts	598	628
Other noncurrent assets	192	113
Total assets	5,386	5,438
Current liabilities:
Accounts payable	698	747
Payable to former parent	81	105
Billings in Excess of Cost	456	401
Employee compensation and benefits	213	235
Current Maturities of Non Recourse Long Term Debt	10	10
Other current liabilities	438	409
Total current liabilities	1,896	1,907
Pension obligations	423	477
Noncurrent employee compensation and benefits	121	114
Other noncurrent liabilities	248	267
Noncurrent income tax payable	118	70
Noncurrent deferred tax liability	91	86
Non-Recourse Debt	70	78
Deferred Revenue, Noncurrent	102	0
Total liabilities	3,069	2,999
KBR Shareholders' equity:
Preferred stock, $0.001 par value, 50,000,000 shares authorized, 0 shares issued and outstanding	0	0
Common stock, $0.001 par value, 300,000,000 shares authorized, 174,459,008 and 173,924,509 shares issued, and 145,078,797 and 148,195,208 shares outstanding	0	0
Paid-in capital in excess of par (PIC)	2,085	2,065
Accumulated other comprehensive loss (AOCL)	(744)	(740)
Retained earnings	1,692	1,748
Treasury stock, 29,380,211 shares and 25,729,301 shares, at cost	(708)	(610)
Total KBR shareholders' equity	2,325	2,463
Noncontrolling interests (NCI)	(8)	(24)
Total shareholders' equity	2,317	2,439
Total liabilities and shareholders' equity	$ 5,386	$ 5,438

XML

Claims and Accounts Receivable (Notes)

9 Months Ended

Sep. 30, 2014

Receivables [Abstract]

Claims Receivable

Claims and Accounts Receivable

The components of our claims and accounts receivable account balance not expected to be collected within the next 12 months are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Hydrocarbons	$	401	$	401
Infrastructure, Government and Power	196		226
Other	1		1
Total	$	598	$	628

Hydrocarbons claims and accounts receivable includes $401 million related to the EPC 1 arbitration award. We expect this legal judgment of $465 million to be recovered from Petróleos Mexicanos ("PEMEX") Exploration and Production ("PEP"), which includes the original confirmation of the 2009 arbitration award and approximately $106 million for 2013 performance bonds recovery and post judgment interest. See Note 12 to our condensed consolidated financial statements for further discussion on our EPC 1 arbitration.

IGP claims and accounts receivable includes $196 million of claims for costs incurred under various U.S. government contracts. See "Other Matters" in Note 11 to our condensed consolidated financial statements for further discussion on our U.S. government matters.

XML

Percentage-Of-Completion Contracts

9 Months Ended

Sep. 30, 2013

Contractors [Abstract]

Percentage-of-Completion Contracts

Costs and Estimated Earnings in Excess of Billings on Uncompleted Contracts and Billings in Excess of Costs and Estimated Earnings on Uncompleted Contracts

Our CIE balances by business segment are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Gas Monetization	$	5	$	34
Hydrocarbons	255		146
Infrastructure, Government and Power	100		131
Services	144		83
Other	5		5
Total	$	509	$	399

Our BIE balances by business segment are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Gas Monetization	$	40	$	30
Hydrocarbons	185		139
Infrastructure, Government and Power	211		199
Services	20		33
Other	—		—
Total	$	456	$	401

Unapproved Change Orders and Claims

The amounts of unapproved change orders and claims included in determining the profit or loss on contracts are as follows:

Dollars in millions	2014			2013
Amounts included in estimated project revenues at completion at January 1,	$	115		$	167
Increase in estimated project revenues at completion	81			69
Approved by client	(134		)	(26		)
Amounts included in estimated project revenues at completion at September 30,	$	62		$	210
Amounts recorded in revenues on a percentage-of-completion basis at September 30,	$	53		$	165

In 2014, approved change orders reflect approvals on an air quality project in the U.S. and an EPC contract for a gas fired electric power generation project in U.S. and a construction project in our Services business segment for which the client routinely issues scope changes which are subsequently followed with a change order.

Included in our 2013 estimated project revenues are increases related to the construction project in our Services business segment mentioned above.

The table above excludes unapproved change orders and claims related to our unconsolidated subsidiaries. Our proportionate share of unapproved change orders and claims on a percentage-of-completion basis were $84 million as of September 30, 2014 and $54 million as of September 30, 2013 on a project in our Gas Monetization business segment.

Liquidated Damages

Some of our engineering and construction contracts have schedule dates and performance obligations that if not met could subject us to penalties for liquidated damages. These generally relate to specified activities that must be completed by a set contractual date or by achievement of a specified level of output or throughput. Each contract defines the conditions under which a customer may make a claim for liquidated damages. However, in some instances, liquidated damages are not asserted by the customer, but the potential to do so is used in negotiating or settling claims and closing out the contract.

Based upon our evaluation of our performance and other legal analysis, we have not accrued for possible but not probable liquidated damages related to several projects totaling $12 million at September 30, 2014 and $10 million at December 31, 2013 that we could incur based upon completing the projects as currently forecasted.

Advances

We may receive customer advances in the normal course of business, most of which are applied to invoices usually within one to three months. In addition, we hold advances from customers to assist us in financing project activities, including subcontractor costs. As of September 30, 2014 and December 31, 2013, $42 million and $50 million, respectively, of these finance-related advances are included in BIE on our condensed consolidated balance sheets.

XML

Recent Accounting Pronouncements

9 Months Ended

Sep. 30, 2014

New Accounting Pronouncements and Changes in Accounting Principles [Abstract]

Recent Accounting Pronouncements

Recent Accounting Pronouncements

On August 27, 2014, the Financial Accounting Standards Board ("FASB") issued Accounting Standards Update ("ASU") No. 2014-15, Presentation of Financial Statements - Going Concern. This ASU provides guidance on management's responsibility to evaluate whether there is substantial doubt about a company's ability to continue as a going concern and about related footnote disclosures. For each reporting period, management will be required to evaluate whether there are conditions or events that raise substantial doubt about a company's ability to continue as a going concern within one year from the date the financial statements are issued. Substantial doubt exists when relevant conditions and events indicate that it is probable that the entity will be unable to meet its obligations as they become due within the time frame specified earlier. This ASU is effective for annual reporting periods beginning after December 15, 2016 and interim periods within those annual periods. The adoption of ASU 2014-15 is not expected to have a material impact on our financial position, results of operations or cash flows.

On May 28, 2014, the FASB issued ASU No. 2014-09, Revenue from Contracts with Customers. This ASU supersedes the revenue recognition requirements in Accounting Standards Codification 605 - Revenue Recognition and most industry-specific guidance throughout the Codification. The standard requires that an entity recognizes revenue to depict the transfer of promised goods or services to customers in an amount that reflects the consideration to which the company expects to be entitled in exchange for those goods or services. This ASU is effective on January 1, 2017 and should be applied retrospectively to each prior reporting period presented or retrospectively with the cumulative effect of initially applying the ASU recognized at the date of initial application. We are in the process of assessing the impact of the adoption of ASU 2014-09 on our financial position, results of operations or cash flows. We have not yet selected a transition method nor have we determined the effect of the standard on our ongoing financial reporting.

On January 24, 2014, the FASB issued ASU No. 2014-05, Service Concession Arrangements. A service concession agreement is an arrangement between a public-sector entity and an operating entity under which the operating entity operates the grantor's infrastructure. This ASU specifies that an operating entity should not account for a service concession arrangement within the scope of this ASU as a lease in accordance with ASC 840 - Leases. An operating entity should refer to other ASUs as applicable to account for various aspects of a service concession arrangement. The amendments also specify that the infrastructure used in a service concession agreement should not be recognized as property, plant and equipment of the operating entity. The amendments in this ASU are effective using a modified retrospective approach for annual reporting periods beginning after December 15, 2014 and interim periods within those annual periods. We are in the process of adopting ASU 2014-05 for the next fiscal year beginning January 1, 2015 and the adoption of this standard could have a material impact on our financial position or results of operations.

XML

Transactions With Former Parent

9 Months Ended

Sep. 30, 2014

Related Party Transactions [Abstract]

Transactions with Former Parent

Transactions with Former Parent

We have now settled the tax disputes described below and have agreed to pay Halliburton $81 million. As a result, during the third quarter of 2014 we recognized a gain on negotiated settlement of $24 million. This settlement amount continues to be reflected in "Payable to former parent" on our condensed consolidated balance sheets. Pursuant to the settlement agreement, we will pay Halliburton five equal installments of $12.4 million over four quarters starting in the fourth quarter of 2014 and ending in the third quarter of 2015, with a final payment to made upon, and in the amount of $19 million, receipt by KBR of a future foreign tax credit or refund from the IRS. All related litigation and disputes have been dismissed by agreement of the parties. We consider this matter concluded.

In connection with our initial public offering in November 2006 and the separation of our business from Halliburton, we entered into various agreements, including, among others, a master separation agreement, transition services agreements and a tax sharing agreement. The tax sharing agreement provides for certain allocations of U.S. income tax liabilities and other agreements between us and Halliburton with respect to tax matters.

During the fourth quarter of 2011, Halliburton provided notice and demanded payment for $256 million that it alleged we owed under the tax sharing agreement for various other tax-related transactions pertaining to periods prior to our separation from Halliburton.

On July 3, 2012, KBR requested an arbitration panel be appointed to resolve certain intercompany issues arising under the master separation agreement before issues in dispute under the tax sharing agreement were submitted to the designated accounting referee as provided for under the terms of the tax sharing agreement.  We believe these intercompany issues were settled and released as a result of our separation from Halliburton in 2007. Halliburton subsequently challenged the arbitration panel's jurisdiction over this dispute in Texas State Court. The Texas State Court denied Halliburton's request and Halliburton filed an appeal which was decided to affirm KBR's position that the demanded payment claimed was barred as explained below.

In May 2013, an arbitration hearing was held on the matters related to the master separation agreement. On June 24, 2013 the arbitration panel ruled that claims brought by Halliburton against KBR under the tax sharing agreement were required to have been brought before an arbitration panel within two years of the date the claim arose or would reasonably have been discovered by the claimant and that the parties were to return to the accounting referee within thirty days for determination of the remaining claims under the tax sharing agreement.  The remaining tax-related issues in dispute were referred to the accounting referee as provided for under the terms of the tax sharing agreement.

On October 9, 2013, the accounting referee issued a report stating that KBR owed Halliburton approximately $105 million with each party bearing its own costs related to the matter. As a result, we increased our tax provision by $38 million, reduced paid-in capital by $7 million and recognized a deferred tax asset of $29 million for available foreign tax credits. Halliburton filed a motion requesting the Texas State Court to confirm the accounting referee's decision and KBR responded requesting that the decision be vacated. KBR filed a motion requesting the Texas State Court to confirm the arbitration panel's June 24, 2013 ruling and Halliburton responded requesting that the arbitration panel's ruling be vacated.

Barracuda-Caratinga Project Tax

In June 2000, we entered into a contract with Barracuda & Caratinga Leasing Company B.V. ("BCLC"), the project owner and claimant, to develop the Barracuda and Caratinga crude oilfields, which are located off the coast of Brazil. Petrobras is a contractual representative that controls the project owner. In November 2007, we executed a settlement agreement with the project owner to settle all outstanding project issues except for the bolts arbitration discussed below.

In March 2006, Petrobras notified us they had submitted a claim to arbitration of $220 million plus interest for the cost of monitoring and replacing defective stud bolts and, in addition, all of the costs and expenses of the arbitration including the cost of attorneys’ fees. The arbitration was conducted in New York under the guidelines of the United Nations Commission on International Trade Law. In September 2011, the arbitration panel awarded the claimant approximately $193 million.

In January 2013, Halliburton paid $219 million to the claimant in payment of the award plus interest and the matter is considered concluded. We believe the arbitration award to Petrobras is deductible by KBR for tax purposes and the indemnification payment will be treated by KBR for tax purposes as a contribution to capital and accordingly is not taxable. In 2011 and 2012, we recorded discrete tax benefits of $71 million and $8 million, respectively. We have reviewed this matter in light of the direct payment by Halliburton to BCLC and its public announcement that they have recorded a tax benefit related to this transaction. Based on advice from outside legal counsel, we have determined that it is more likely than not that we are the proper taxpayer to recognize this benefit although the underlying uncertainties with respect to the tax treatment of the transaction may ultimately lead the Internal Revenue Service to alternate conclusions.

XML

Pension and Postretirement Plans

9 Months Ended

Sep. 30, 2014

Compensation and Retirement Disclosure [Abstract]

Pension and Postretirement Plans

Pension Plans

The components of net periodic benefit cost related to pension benefits for the three and nine months ended September 30, 2014 and 2013 were as follows:

	Three Months Ended September 30,
	2014						2013
Dollars in millions	United States			Int’l			United States			Int’l
Components of net periodic benefit cost
Service cost	$	—		$	1		$	—		$	1
Interest cost	1			23			1			18
Expected return on plan assets	(1		)	(26		)	(2		)	(19		)
Recognized actuarial loss	1			10			1			7
Net periodic benefit cost	$	1		$	8		$	—		$	7

	Nine Months Ended September 30,
	2014						2013
Dollars in millions	United States			Int’l			United States			Int’l
Components of net periodic benefit cost
Service cost	$	—		$	2		$	—		$	2
Interest cost	2			68			2			59
Expected return on plan assets	(3		)	(78		)	(4		)	(64		)
Recognized actuarial loss	3			29			2			24
Net periodic benefit cost	$	2		$	21		$	—		$	21

For the nine months ended September 30, 2014, we have contributed approximately $35 million of the $46 million we currently expect to contribute to our international plans in 2014, and we have contributed approximately $2 million of the $3 million we currently expect to contribute to our domestic plans in 2014.

XML

Shareholders' Equity (Shareholders' Equity Activities) (Details) (USD $) In Millions, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013
Shareholders Equity [Line Items]
Beginning Balance			$ 2,439	$ 2,511
Stock-based compensation			16	13
Common stock issued upon exercise of stock options			4	5
Post-closing adjustment related to acquisition of former NCI partner				(7)
Dividends declared to shareholders			(35)	(24)
Repurchases of common stock			(102)	(7)
Issuance of ESPP shares			4	4
Investments by noncontrolling interests			10	9
Distributions to noncontrolling interests			(49)	(58)
Change in NCI due to consolidation of previously unconsolidated JV and other transactions				2
Net income	45	15	33	223
Other comprehensive income (loss), net of tax	(42)	20	(3)	(15)
Ending Balance	2,317	2,663	2,317	2,663
Additional Paid-in Capital [Member]
Shareholders Equity [Line Items]
Beginning Balance			2,065	2,049
Stock-based compensation			16	13
Common stock issued upon exercise of stock options			4	5
Post-closing adjustment related to acquisition of former NCI partner				(7)
Dividends declared to shareholders			0	0
Repurchases of common stock			0	0
Issuance of ESPP shares			0	1
Investments by noncontrolling interests			0	0
Distributions to noncontrolling interests			0	0
Change in NCI due to consolidation of previously unconsolidated JV and other transactions				0
Net income			0	0
Other comprehensive income (loss), net of tax			0	0
Ending Balance	2,085	2,061	2,085	2,061
Retained Earnings [Member]
Shareholders Equity [Line Items]
Beginning Balance			1,748	1,709
Stock-based compensation			0	0
Common stock issued upon exercise of stock options			0	0
Post-closing adjustment related to acquisition of former NCI partner				0
Dividends declared to shareholders			(35)	(24)
Repurchases of common stock			0	0
Issuance of ESPP shares			0	0
Investments by noncontrolling interests			0	0
Distributions to noncontrolling interests			0	0
Change in NCI due to consolidation of previously unconsolidated JV and other transactions				0
Net income			(21)	131
Other comprehensive income (loss), net of tax			0	0
Ending Balance	1,692	1,816	1,692	1,816
Treasury Stock [Member]
Shareholders Equity [Line Items]
Beginning Balance			(610)	(606)
Stock-based compensation			0	0
Common stock issued upon exercise of stock options			0	0
Post-closing adjustment related to acquisition of former NCI partner				0
Dividends declared to shareholders			0	0
Repurchases of common stock			(102)	(7)
Issuance of ESPP shares			4	3
Investments by noncontrolling interests			0	0
Distributions to noncontrolling interests			0	0
Change in NCI due to consolidation of previously unconsolidated JV and other transactions				0
Net income			0	0
Other comprehensive income (loss), net of tax			0	0
Ending Balance	(708)	(610)	(708)	(610)
Accumulated Other Comprehensive Income (Loss) [Member]
Shareholders Equity [Line Items]
Beginning Balance			(740)	(610)
Stock-based compensation			0	0
Common stock issued upon exercise of stock options			0	0
Post-closing adjustment related to acquisition of former NCI partner				0
Dividends declared to shareholders			0	0
Repurchases of common stock			0	0
Issuance of ESPP shares			0	0
Investments by noncontrolling interests			0	0
Distributions to noncontrolling interests			0	0
Change in NCI due to consolidation of previously unconsolidated JV and other transactions				0
Net income			0	0
Other comprehensive income (loss), net of tax			(4)	(15)
Ending Balance	(744)	(625)	(744)	(625)
Noncontrolling Interests [Member]
Shareholders Equity [Line Items]
Beginning Balance			(24)	(31)
Stock-based compensation			0	0
Common stock issued upon exercise of stock options			0	0
Post-closing adjustment related to acquisition of former NCI partner				0
Dividends declared to shareholders			0	0
Repurchases of common stock			0	0
Issuance of ESPP shares			0	0
Investments by noncontrolling interests			10	9
Distributions to noncontrolling interests			(49)	(58)
Change in NCI due to consolidation of previously unconsolidated JV and other transactions				2
Net income			54	92
Other comprehensive income (loss), net of tax			1	7
Ending Balance	(8)	21	(8)	21
Scenario, Previously Reported [Member]
Shareholders Equity [Line Items]
Other comprehensive income (loss), net of tax				$ (8)

XML

Equity Method Investments And Variable Interest Entities

9 Months Ended

Sep. 30, 2014

Equity Method Investments and Joint Ventures [Abstract]

Equity Method Investments And Variable Interest Entities

Equity Method Investments and Variable Interest Entities

We conduct some of our operations through joint ventures which operate through partnership, corporate, undivided interest and other business forms and are principally accounted for using the equity method of accounting. Additionally, the majority of our joint ventures are also variable interest entities which are further described under ASC 810 - Consolidations - Variable Interest Entities.

The following table presents a rollforward of our equity in and advances to unconsolidated affiliates:

Dollars in millions	2014			2013
Balance at January 1,	$	156		$	217
Equity in earnings of unconsolidated affiliates	118			107
Dividends received (a)	(212		)	(151		)
Advances	(14		)	(12		)
Cumulative translation adjustment	(1		)	(7		)
Balance at September 30, before reclassification	47			154
Reclassification of excess distributions (a)	102			—
Balance at September 30,	$	149		$	154

(a) During the third quarter of 2014, we received dividend distributions in excess of the carrying value of our investments by $102 million. We have no obligation to return any portion of the dividends received. We reclassified the excess distribution to “deferred income from unconsolidated affiliates” on our condensed consolidated balance sheets and this amount will be reduced as we recognize our share of future earnings.

Related Party Transactions

We often provide engineering, construction management and other services, as a subcontractor to the joint ventures in which we participate. The amounts included in our revenues represent revenues from services we provide directly to the joint ventures. As of September 30, 2014 and 2013, our revenues included $228 million and $186 million, respectively, primarily related to services we provided to our Ichthys LNG project joint venture.

Amounts included in our condensed consolidated balance sheets related to services we provided to our joint ventures as of September 30, 2014 and December 31, 2013 are as follows:

	September 30,		December 31,
Dollars in millions	2014		2013
Accounts receivable, net of allowance for doubtful accounts	$	2	$	6
Costs and estimated earnings in excess of billings on uncompleted contracts	$	2	$	2
Billings in excess of costs and estimated earnings on uncompleted contracts	$	23	$	24

Our related party accounts payable for both periods were immaterial.

Equity Method Investments

Summarized financial information for all jointly owned operations including variable interest entities that are accounted for using the equity method of accounting is as follows:

Balance Sheets

	September 30,		December 31,
Dollars in millions	2014		2013
Current assets	$	3,968	$	4,114
Noncurrent assets	4,212		4,222
Total assets	$	8,180	$	8,336
Current liabilities	$	3,597	$	3,679
Noncurrent liabilities	4,273		4,400
Total liabilities	$	7,870	$	8,079

Statements of Operations

	Three Months Ended				Nine Months Ended
	September 30,				September 30,
Dollars in millions	2014		2013		2014		2013
Revenues	$	1,728	$	1,400	$	4,336	$	3,548
Operating income	$	175	$	135	$	503	$	434
Net income	$	101	$	81	$	307	$	276

Unconsolidated Variable Interest Entities

The following summarizes the total assets and total liabilities as reflected in our condensed consolidated balance sheets as well as our maximum exposure to losses related to our unconsolidated variable interest entities ("VIEs") in which we have a significant variable interest but are not the primary beneficiary. Generally, our maximum exposure to loss is limited to our equity investment in the joint venture and any amounts payable to us for services we provided to the joint venture, reduced for any unearned revenues on the projects.

	September 30, 2014
Dollars in millions	Total assets		Total liabilities		Maximum exposure to  loss
Aspire Defence project	$	17	$	126	$	17
Ichthys LNG project	$	30	$	37	$	30
U.K. Road projects	$	35	$	12	$	35
EBIC Ammonia project	$	43	$	2	$	27
Fermoy Road project	$	4	$	5	$	4

Dollars in millions	December 31, 2013
	Total assets		Total liabilities
Aspire Defence project	$	20	$	2
Ichthys LNG project	$	1	$	18
U.K. Road projects	$	34	$	8
EBIC Ammonia project	$	47	$	2
Fermoy Road project	$	1	$	2

On the Aspire Defence project, in addition to the maximum exposure to loss indicated in the table above, we have exposure to any losses incurred by the construction or operating joint ventures under their respective subcontract arrangements with the project company. Our exposure is, however, limited to our equity participation in these entities. The Ichthys LNG project joint venture executes a project that has a lump sum component; in addition to the maximum exposure to loss indicated in the table above, we have an exposure to losses if the project exceeds the lump sum component to the extent of our ownership percentage in the joint venture. Our maximum exposure to loss on the EBIC Ammonia project reflects our 65% ownership of the development corporation which owns 25% of the company that consolidates the ammonia plant.

Consolidated Variable Interest Entities

We consolidate VIEs if we determine we are the primary beneficiary of the project entity because we control the activities that most significantly impact the economic performance of the entity. The following is a summary of the significant VIEs where we are the primary beneficiary:

Dollars in millions	September 30, 2014
	Total assets		Total liabilities
Gorgon LNG project	$	372	$	399
Escravos Gas-to-Liquids project	$	32	$	52
Fasttrax Limited project	$	90	$	89

Dollars in millions	December 31, 2013
	Total assets		Total liabilities
Gorgon LNG project	$	446	$	476
Escravos Gas-to-Liquids project	$	43	$	72
Fasttrax Limited project	$	96	$	98

XML

Nonrecourse Project Finance Debt (Notes)

9 Months Ended

Sep. 30, 2014

Debt Disclosure [Abstract]

Debt Disclosure [Text Block]

Nonrecourse Project Debt

Fasttrax Limited, a joint venture in which we indirectly own a 50% equity interest with an unrelated partner, was awarded a concession contract in 2001 with the U.K. Ministry of Defence ("MoD") to provide a Heavy Equipment Transporter Service to the British Army. Under the terms of the arrangement, Fasttrax Limited operates and maintains 91 heavy equipment transporters ("HETs") for a term of 22 years. The purchase of the HETs by the joint venture was financed through two series of bonds secured by the assets of Fasttrax Limited and a bridge loan totaling approximately £84.9 million (approximately $120 million at the exchange rate on the date of the transaction). The secured bonds are an obligation of Fasttrax Limited and are not a debt obligation of KBR as they are nonrecourse to the joint venture partners. Accordingly, in the event of a default on the notes, the lenders may only look to the assets of Fasttrax Limited for repayment. The bridge loan of approximately £12.2 million (approximately $17 million at the exchange rate on the date of the transaction) was replaced when the joint venture partners funded their equity and subordinated debt contributions in 2005.

The secured bonds were issued in two classes consisting of a Class A 3.5% Index Linked Bonds in the amount of £56 million (approximately $79 million at the exchange rate on the date of the transaction) and a Class B 5.9% Fixed Rate Bonds in the amount of £16.7 million (approximately $24 million at the exchange rate on the date of the transaction).  Semi-annual payments on both classes of bonds commenced in March 2005 and will continue through maturity in 2021. The subordinated notes payable to each of the partners initially bear interest at 11.25% increasing to 16% over the term of the notes until maturity in 2025. Semi-annual payments on the subordinated notes commenced in March 2006. For financial reporting purposes, only our partner's portion of the subordinated notes appears in the condensed consolidated financial statements.

XML

Income Taxes

9 Months Ended

Sep. 30, 2014

Income Tax Disclosure [Abstract]

Income Taxes

Income Taxes

Our estimated annual effective tax rate for the years 2014 and 2013 reconciled to the 35% U.S. statutory federal rate is as follows:

	2014		2013
U.S. statutory federal rate	35.0	%	35.0	%
Rate differentials on foreign earnings	(8.5	)%	(6.6	)%
Taxes on unincorporated joint ventures	(10.1	)%	(7.6	)%
Taxes on unconsolidated affiliates	(10.9	)%	(4.6	)%
U.S. taxes provided on foreign earnings	12.1	%	2.2	%
State taxes	0.3	%	0.5	%
Other	4.4	%	3.7	%
Estimated annual effective tax rate	22.3	%	22.6	%

The effective tax rate was approximately (2)% for the three months ended September 30, 2014. The effective tax rate for the three months ended September 30, 2014 was less than our estimated annual effective tax rate shown in the table above because of discrete tax benefits recognized during the quarter primarily related to expiration of statute of limitations in certain tax jurisdictions.

The effective tax rate was approximately 48% for the nine months ended September 30, 2014. The effective tax rate for the nine months ended September 30, 2014 was greater than our estimated annual effective tax rate shown in the table above primarily due to discrete items including the recording of a valuation allowance on the losses recognized on our Canadian pipe fabrication and module assembly projects offset by the benefit of expiration of statute of limitations in certain tax jurisdictions.

For the three months ended September 30, 2013, our effective tax rate reflected in our condensed consolidated statements of income (loss) is not reflective of our estimated annual effective tax rate shown in the table above as a result of unfavorable discrete items including a charge of $38 million as a result of an unfavorable ruling with respect to a tax dispute with our former parent and $13 million due to changes in the U.K. enacted tax rates.

For the nine months ended September 30, 2013, the effective tax rate was approximately 32%. Our effective tax rate for the nine months ended September 30, 2013 was higher than our estimated annual effective rate of 22.6% due to discrete items. In the first nine months of 2013, we recognized discrete net tax expense of approximately $31 million which included a charge of $38 million as a result of an unfavorable ruling with respect to a tax dispute with our former parent and $13 million due to changes in the U.K. enacted tax rates partially offset by benefits related to the recognition of previously unrecognized tax benefits related to tax positions in prior years, primarily as a result of the resolution of transfer pricing issues involving our U.K. subsidiaries.

We generally do not provide for U.S. federal and state income taxes on the accumulated undistributed earnings of non-U.S. subsidiaries except for certain entities in Mexico and certain other joint ventures, and since 2012, for approximately 50% of our earnings from our operations in Australia. See Note 3 to our condensed consolidated financial statements for additional information regarding our accumulated undistributed earnings. Due to historical and forecasted losses for certain state jurisdictions and non-U.S. affiliates, we are not allowed to record a tax benefit for current period net operating losses recognized by these affiliates.

The valuation allowance for deferred tax assets as of September 30, 2014 and December 31, 2013 was $118 million and $83 million, respectively. The net change in the total valuation allowance was an increase of $35 million from December 31, 2013, including an increase of $3 million during the three months ended September 30, 2014. The valuation allowance as of September 30, 2014 and December 31, 2013 was primarily related to Canada, other foreign and state net operating loss carryforwards that, in the judgment of management, are not more-likely-than-not to be realized.

In assessing the realizability of our deferred tax assets, which include net operating loss carryforwards and foreign tax credit carryforwards, management considers whether it is more-likely-than-not that some portion or all of the deferred tax assets will not be realized. The ultimate realization of deferred tax assets is dependent upon the generation of future taxable income during the periods in which those temporary differences become deductible. Management considers the scheduled reversal of deferred tax liabilities (including the impact of available carryback and carryforward periods), projected future taxable income and tax-planning strategies in making this assessment. The amount of the deferred tax asset considered realizable, however, could be reduced in the near term if estimates of future taxable income during the carryforward period are reduced.

The reserve for uncertain tax positions as of September 30, 2014 and December 31, 2013 was $125 million and $68 million, respectively. The net change in the uncertain tax position for both the full year and the quarter was an increase of $57 million from December 31, 2013. The net change in the uncertain tax position was primarily related to the benefit of the expiration of statute of limitations of $5 million offset by a $62 million increase related to a 2009 amended tax return position.

XML

Income Per Share (Schedule Of Basic And Diluted Weighted Average Common Shares Outstanding) (Details) In Millions, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013
Earnings Per Share [Abstract]
Basic weighted average common shares outstanding	145	148	145	148
Stock options and restricted shares	0	0	0	1
Diluted weighted average common shares outstanding	145	148	145	149

XML

Share Repurchases (Details) (USD $) In Millions, except Per Share data, unless otherwise specified	3 Months Ended	9 Months Ended
	Sep. 30, 2014	Sep. 30, 2014	Feb. 25, 2014
Equity, Class of Treasury Stock [Line Items]
Repurchases under the existing share maintenance program	306,822	3,810,171
Shares repurchased during the period	$ 6	$ 102
Share Repurchase Program 2014 [Member]
Equity, Class of Treasury Stock [Line Items]
Share repurchase program, authorized amount			350
Repurchases under the existing share maintenance program	175,522	3,149,151
Shares repurchased during the period	4	85
Shares repurchased, average price per share	$ 20.78	$ 26.89
Share Repurchase Program 2011 [Member]
Equity, Class of Treasury Stock [Line Items]
Repurchases under the existing share maintenance program	131,300	661,020
Shares repurchased during the period	$ 2	$ 17
Shares repurchased, average price per share	$ 20.84	$ 26.31

XML

Share Repurchases (Tables)

9 Months Ended

Sep. 30, 2014

Equity [Abstract]

Schedule of shares repurchased

	Dollars in Millions				Number of Shares Repurchased
	Three Months Ended		Nine Months Ended		Three Months Ended	Nine Months Ended
	September 30, 2014		September 30, 2014		September 30, 2014	September 30, 2014
Repurchases under the $350 million authorized share repurchase program	$	4	$	85	175,522	3,149,151
Repurchases under the existing share maintenance program	2		17		131,300	661,020
Total	$	6	$	102	306,822	3,810,171

Repurchases under the authorized share repurchase program were made at an average price of $20.78 and $26.89 for the three and nine months ended September 30, 2014, respectively. Repurchases under the existing share maintenance program were made at an average price of $20.84 and $26.31 for the three and nine months ended September 30, 2014, respectively.

XML

Nonrecourse Project Finance Debt (Details) In Millions, unless otherwise specified	9 Months Ended										9 Months Ended
	Sep. 30, 2014 USD ($)	Dec. 31, 2013 USD ($)	Sep. 30, 2014 United Kingdom, Pounds GBP (£)	Sep. 30, 2014 United States of America, Dollars USD ($)	Sep. 30, 2014 Class Three Point Five Percentage Index Linked Bonds [Member]	Sep. 30, 2014 Class Three Point Five Percentage Index Linked Bonds [Member] United Kingdom, Pounds GBP (£)	Sep. 30, 2014 Class Three Point Five Percentage Index Linked Bonds [Member] United States of America, Dollars USD ($)	Sep. 30, 2014 Class B Five Point Nine Percentage Fixed Rate Bonds [Member]	Sep. 30, 2014 Class B Five Point Nine Percentage Fixed Rate Bonds [Member] United Kingdom, Pounds GBP (£)	Sep. 30, 2014 Class B Five Point Nine Percentage Fixed Rate Bonds [Member] United States of America, Dollars USD ($)	Sep. 30, 2014 Minimum [Member]	Sep. 30, 2014 Maximum [Member]
Debt Instrument [Line Items]
Debt Instrument, Interest Rate, Effective Percentage					3.50%			5.90%
Non-Recourse Debt	$ 70.0	$ 78.0	£ 84.9	$ 120.0
Non Recourse Debt Bridge Financing			12.2	17.0
Number Of Heavy Equipment Transporters	91
Number Of Heavy Equipment Transporters Term Period	22 years
Current Maturities of Non Recourse Long Term Debt	10	10
Secured Debt						£ 56.0	$ 79.0		£ 16.7	$ 24.0
Subordinated Borrowing, Interest Rate											11.25%	16.00%

XML

Share Repurchase

9 Months Ended

Sep. 30, 2014

Equity [Abstract]

Share Repurchases

Share Repurchases

On February 25, 2014, our Board of Directors authorized a plan to repurchase up to $350 million of our outstanding common shares, which replaces and terminates the August 26, 2011 share repurchase program. The authorization does not obligate the company to acquire any particular number of common shares and may be commenced, suspended or discontinued without prior notice. The newly authorized share repurchase program operates alongside the existing share maintenance program which we may use to repurchase shares vesting as part of employee compensation programs. The share repurchases are intended to be funded through the company’s current and future cash and the authorization does not have an expiration date. The table below presents information on our share repurchase activities under the share repurchase authorization.

	Dollars in Millions				Number of Shares Repurchased
	Three Months Ended		Nine Months Ended		Three Months Ended	Nine Months Ended
	September 30, 2014		September 30, 2014		September 30, 2014	September 30, 2014
Repurchases under the $350 million authorized share repurchase program	$	4	$	85	175,522	3,149,151
Repurchases under the existing share maintenance program	2		17		131,300	661,020
Total	$	6	$	102	306,822	3,810,171

Repurchases under the authorized share repurchase program were made at an average price of $20.78 and $26.89 for the three and nine months ended September 30, 2014, respectively. Repurchases under the existing share maintenance program were made at an average price of $20.84 and $26.31 for the three and nine months ended September 30, 2014, respectively.

XML

Cash and Equivalents (Tables)

9 Months Ended

Sep. 30, 2014

Cash and Cash Equivalents [Abstract]

Schedule of Cash and Cash Equivalents

The components of our cash and cash equivalents balance are as follows:

	September 30, 2014
Dollars in millions	International (a)		Domestic (b)		Total
Operating cash	$	362	$	215	$	577
Time deposits	348		43		391
Cash held in joint ventures	64		16		80
Total	$	774	$	274	$	1,048

	December 31, 2013
Dollars in millions	International (a)		Domestic (b)		Total
Operating cash	$	197	$	215	$	412
Time deposits	478		140		618
Cash held in joint ventures	67		9		76
Total	$	742	$	364	$	1,106

(a) Includes deposits held in non-U.S. operating accounts considered to be permanently reinvested outside the U.S. and for which no incremental U.S. tax has been provisioned or paid.

(b) Includes U.S. dollar and foreign currency deposits held in operating accounts that constitute onshore cash for tax purposes but may reside either in the U.S. or in a foreign country

XML

Equity Method Investments And Variable Interest Entities (Consolidated Summarized Financial Information Statements Of Operations) (Details) (USD $) In Millions, unless otherwise specified	3 Months Ended		9 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Sep. 30, 2014	Sep. 30, 2013
Equity Method Investments and Joint Ventures [Abstract]
Revenue	$ 1,728	$ 1,400	$ 4,336	$ 3,548
Operating income	175	135	503	434
Net income	$ 101	$ 81	$ 307	$ 276

XML

CIE and BIE CIE (Details) (USD $) In Millions, unless otherwise specified	Sep. 30, 2014	Dec. 31, 2013
Costs in Excess of Billings, Current	$ 509	$ 399
Gas Monetization [Member]
Costs in Excess of Billings, Current	5	34
Hydrocarbons [Member]
Costs in Excess of Billings, Current	255	146
Infrastructure, Government And Power [Member]
Costs in Excess of Billings, Current	100	131
Services [Member]
Costs in Excess of Billings, Current	144	83
Other Segments [Member]
Costs in Excess of Billings, Current	$ 5	$ 5

XML

Consolidated Balance Sheets (Parenthetical) (USD $) In Millions, except Share data, unless otherwise specified	Sep. 30, 2014	Dec. 31, 2013
Current assets:
Allowance for bad debts	$ 21	$ 18
Property, plant, and equipment:
Accumulated depreciation	426	397
PP&E owned by a VIE, net	$ 61	$ 67
KBR Shareholders' equity:
Preferred stock, par value	$ 0.001	$ 0.001
Preferred stock, shares authorized	50,000,000	50,000,000
Preferred stock, shares issued	0	0
Preferred stock, shares outstanding	0	0
Common stock, par value	$ 0.001	$ 0.001
Common stock, shares authorized	300,000,000	300,000,000
Common stock, shares issued	174,459,008	173,924,509
Common stock, shares outstanding	145,078,797	148,195,208
Treasury stock, shares	29,380,211	25,729,301

XML

Accounts Receivable (Notes)

9 Months Ended

Sep. 30, 2014

Receivables [Abstract]

Accounts Receivable

Accounts Receivable

The components of our accounts receivable, net of allowance for doubtful accounts balance are as follows:

	September 30, 2014
Dollars in millions	Trade		Retainage		Total
Gas Monetization	$	126	$	—	$	126
Hydrocarbons	319		21		340
Infrastructure, Government and Power	188		29		217
Services	239		40		279
Other	2		—		2
Total	$	874	$	90	$	964

	December 31, 2013
Dollars in millions	Trade		Retainage		Total
Gas Monetization	$	255	$	—	$	255
Hydrocarbons	284		31		315
Infrastructure, Government and Power	137		15		152
Services	278		54		332
Other	2		—		2
Total	$	956	$	100	$	1,056

In addition, noncurrent retainage receivable included in "other assets" on our condensed consolidated balance sheets was $7 million and $14 million as of September 30, 2014 and December 31, 2013, respectively, primarily related to an EPC contract for a gas fired electric power generation project in the U.S. in 2014 and a power project in North America in 2013, both in our IGP business segment.

XML

Other Commitments And Contingencies (Other) (Narrative) (Details) (USD $) In Millions, unless otherwise specified	9 Months Ended		1 Months Ended	0 Months Ended	1 Months Ended	3 Months Ended	12 Months Ended			0 Months Ended	9 Months Ended	12 Months Ended
	Sep. 30, 2014	Sep. 30, 2013	Mar. 31, 2006 Barracuda-Caratinga Project [Member]	Nov. 02, 2010 Pemex [Member]	Dec. 31, 2009 Pemex [Member]	Sep. 30, 2013 Pemex [Member]	Dec. 31, 2013 Pemex [Member]	Dec. 31, 2004 Pemex [Member]	Dec. 31, 1998 Pemex [Member] Contracts	Dec. 21, 2010 E N I Holdings Inc [Member]	Sep. 30, 2014 E N I Holdings Inc [Member]	Dec. 31, 2010 E N I Holdings Inc [Member]
Loss Contingencies [Line Items]
Outstanding performance bonds by enterprise							$ 80
Payment on performance bonds	0	108					108
Customer's arbitration claim			220					157
Number of contracts entered into with project owner									3
Amount of arbitration claim filed by enterprise								323
Amount awarded to enterprise in arbitration					351
Amount of counterclaims awarded to project owner in arbitration					6
Gain recognized					117.0						0.8
Amount of judgment awarded to enterprise				356		465
Performance Bond Recovery Including Interest						106	26
PaymentOnPerformanceBondsOther							2
Business Acquisition, Percentage of Voting Interests Acquired										100.00%
Payments to Acquire Businesses, Gross												280
Business Acquisition Net Working Capital Acquired										17
Cash Acquired from Acquisition										8
Business Acquisition, Purchase Price Allocation Increase Decrease In Noncontrolling Interests, Accumulated Other Comprehensive Income And Additional Paid-In Capital										289
Escrowed Hold Back Amount											$ 25

XML

Accounts Receivable (Tables)

9 Months Ended

Sep. 30, 2014

Receivables [Abstract]

Schedule of Accounts Receivable

The components of our accounts receivable, net of allowance for doubtful accounts balance are as follows:

	September 30, 2014
Dollars in millions	Trade		Retainage		Total
Gas Monetization	$	126	$	—	$	126
Hydrocarbons	319		21		340
Infrastructure, Government and Power	188		29		217
Services	239		40		279
Other	2		—		2
Total	$	874	$	90	$	964

	December 31, 2013
Dollars in millions	Trade		Retainage		Total
Gas Monetization	$	255	$	—	$	255
Hydrocarbons	284		31		315
Infrastructure, Government and Power	137		15		152
Services	278		54		332
Other	2		—		2
Total	$	956	$	100	$	1,056

XML

Business Segment Information Business Segment Information (Narrative) (Details)	3 Months Ended	9 Months Ended				3 Months Ended	9 Months Ended
	Sep. 30, 2013 Australian LNG Project [Member] Gas Monetization [Member]	Sep. 30, 2014 Australian LNG Project [Member] Gas Monetization [Member]	Sep. 30, 2013 Australian LNG Project [Member] Gas Monetization [Member]	Sep. 30, 2014 Algerian LNG Project [Member] Gas Monetization [Member]	Sep. 30, 2014 Canadian Pipe Fabrication And Module Assembly Projects [Member] Services [Member]	Sep. 30, 2014 North American Power Project [Member] Infrastructure, Government And Power [Member]	Sep. 30, 2014 North American Power Project [Member] Infrastructure, Government And Power [Member]	Sep. 30, 2014 EPC Project [Member] Hydrocarbons [Member]
Segment Reporting Information [Line Items]
Use of Estimates, Quarterly Changes in Estimates	90	21	141	33	80	-33	-47	-18

XML

Shareholders' Equity

9 Months Ended

Sep. 30, 2014

Stockholders' Equity Note [Abstract]

Shareholders' Equity

Shareholders’ Equity

The following tables summarize our activity in shareholders’ equity:

Dollars in millions	Total			PIC			Retained Earnings			Treasury Stock			AOCL			NCI
Balance at December 31, 2013	$	2,439		$	2,065		$	1,748		$	(610	)	$	(740	)	$	(24	)
Share-based compensation	16			16			—			—			—			—
Common stock issued upon exercise of stock options	4			4			—			—			—			—
Dividends declared to shareholders	(35		)	—			(35		)	—			—			—
Repurchases of common stock	(102		)	—			—			(102		)	—			—
Issuance of ESPP shares	4			—			—			4			—			—
Investments by noncontrolling interests	10			—			—			—			—			10
Distributions to noncontrolling interests	(49		)	—			—			—			—			(49		)
Net income (loss)	33			—			(21		)	—			—			54
Other comprehensive income (loss), net of tax	(3		)	—			—			—			(4		)	1
Balance at September 30, 2014	$	2,317		$	2,085		$	1,692		$	(708	)	$	(744	)	$	(8	)
Dollars in millions	Total			PIC			Retained Earnings			Treasury Stock			AOCL			NCI
Balance at December 31, 2012	$	2,511		$	2,049		$	1,709		$	(606	)	$	(610	)	$	(31	)
Share-based compensation	13			13			—			—			—			—
Common stock issued upon exercise of stock options	5			5			—			—			—			—
Adjustment pursuant to Accounting Referee's report on tax sharing agreement	(7		)	(7		)	—			—			—			—
Dividends declared to shareholders	(24		)	—			(24		)	—			—			—
Repurchases of common stock	(7		)	—			—			(7		)	—			—
Issuance of ESPP shares	4			1			—			3			—			—
Investments by noncontrolling interests	9			—			—			—			—			9
Distributions to noncontrolling interests	(58		)	—			—			—			—			(58		)
Change in NCI due to consolidation of previously unconsolidated JV and other transactions	2			—			—			—			—			2
Net income	223			—			131			—			—			92
Other comprehensive income (loss), net of tax	(8		)	—			—			—			(15		)	7
Balance at September 30, 2013	$	2,663		$	2,061		$	1,816		$	(610	)	$	(625	)	$	21

Accumulated other comprehensive loss, net of tax

	September 30,
Dollars in millions	2014			2013
Accumulated CTA, net of tax	$	(158	)	$	(123	)
Accumulated pension liability adjustments, net of tax	(583		)	(501		)
Accumulated unrealized losses on derivatives, net of tax	(3		)	(1		)
Total accumulated other comprehensive loss	$	(744	)	$	(625	)

Changes in accumulated other comprehensive loss, net of tax, by component

Dollars in millions	Accumulated CTA			Accumulated pension liability adjustments			Accumulated unrealized losses on derivatives			Total
Balance at December 31, 2013	$	(131	)	$	(608	)	$	(1	)	$	(740	)
Other comprehensive income (loss) adjustments before reclassifications	(28		)	—			(1		)	(29		)
Amounts reclassified from accumulated other comprehensive income (loss)	1			25			(1		)	25
Balance at September 30, 2014	$	(158	)	$	(583	)	$	(3	)	$	(744	)

Dollars in millions	Accumulated CTA			Accumulated pension liability adjustments			Accumulated unrealized losses on derivatives			Total
Balance at December 31, 2012	$	(88	)	$	(521	)	$	(1	)	$	(610	)
Other comprehensive income (loss) adjustments before reclassifications	(36		)	—			—			(36		)
Amounts reclassified from accumulated other comprehensive income (loss)	1			20			—			21
Balance at September 30, 2013	$	(123	)	$	(501	)	$	(1	)	$	(625	)

Reclassifications out of accumulated other comprehensive loss, net of tax, by component

	Nine Months Ended September 30,						Affected line item in the Condensed Consolidated Statements of Income
Dollars in millions	2014			2013
Accumulated pension liability adjustments
Amortization of actuarial loss (a)	$	(32	)	$	(26	)	See (a) below
Tax benefit	7			6			Provision for income taxes
Net pension liability adjustment realized	$	(25	)	$	(20	)	Net of tax

(a) This item is included in the computation of net periodic pension cost. See Note 9 to our condensed consolidated financial statements for further discussion.