XML 96 R16.htm IDEA: XBRL DOCUMENT v2.4.0.6
Commitments And Contingencies
3 Months Ended
Mar. 31, 2012
Commitments And Contingencies

(11) COMMITMENTS AND CONTINGENCIES

(a) Operating Expense Purchase Obligations—Alliant Energy, IPL and WPL have entered into various commodity supply, transportation and storage contracts to meet their obligations to deliver electricity and natural gas to IPL's and WPL's utility customers. Alliant Energy, IPL and WPL also enter into other operating expense purchase obligations with various vendors for other goods and services. At March 31, 2012, minimum future commitments related to these operating expense purchase obligations were as follows (in millions):

 

Alliant Energy      IPL      WPL  

Purchased power (a):

        

Duane Arnold Energy Center (DAEC) (IPL)

   $ 364       $ 364       $ —     

Kewaunee Nuclear Power Plant (Kewaunee) (WPL)

     131         —           131   

Other

     41         9         32   
  

 

 

    

 

 

    

 

 

 
     536         373         163   

Natural gas

     255         120         135   

Coal (b)

     274         88         61   

Sulfur dioxide (SO2) emission allowances

     34         34         —     

Other (c)

     41         19         22   
  

 

 

    

 

 

    

 

 

 
   $ 1,140       $ 634       $ 381   
  

 

 

    

 

 

    

 

 

 

 

  (a) Includes payments required by purchased power agreements (PPAs) for capacity rights and minimum quantities of MWhs required to be purchased. Excludes contracts that are considered operating leases.
  (b) Corporate Services entered into system-wide coal contracts on behalf of IPL and WPL that include minimum future commitments of $125 million that have not been directly assigned to IPL and WPL since the specific needs of each utility were not yet known as of March 31, 2012.
  (c) Includes individual commitments incurred during the normal course of business that exceeded $1 million at March 31, 2012.

 

(b) Legal Proceedings—

Air Permitting Violation ClaimsIn September 2010, Sierra Club filed in the U.S. District Court for the Western District of Wisconsin a complaint against WPL, as owner and operator of the Nelson Dewey Generating Station (Nelson Dewey) and the Columbia Energy Center (Columbia), based on allegations that modifications were made at the facilities without complying with the Prevention of Significant Deterioration (PSD) program requirements, Title V Operating Permit requirements of the Clean Air Act (CAA) and state regulatory counterparts contained within the Wisconsin state implementation plan (SIP) designed to implement the CAA. In October 2010, WPL responded to these claims related to Nelson Dewey and Columbia by filing with the U.S. District Court an answer denying the Columbia allegations and a motion to dismiss the Nelson Dewey allegations based on statute of limitations arguments. In November 2010, WPL filed a motion to dismiss the Nelson Dewey and Columbia allegations based on lack of jurisdiction. Sierra Club has responded to the motions. In January 2012, the Court reset the trial date to Dec. 10, 2012 and scheduled a status conference for Feb. 15, 2012 to receive an update on settlement progress. At the Feb. 15, 2012 status conference, the Court reaffirmed the Dec. 10, 2012 trial date and set a pre-trial schedule that allows the parties to work toward settlement.

In September 2010, Sierra Club filed in the U.S. District Court for the Eastern District of Wisconsin a complaint against WPL, as owner and operator of the Edgewater Generating Station (Edgewater), which contained similar allegations regarding air permitting violations at Edgewater. In the Edgewater complaint, additional allegations were made regarding violations of emission limits for visible emissions. In February 2011, WPL responded to these claims related to Edgewater by filing with the U.S. District Court an answer denying the allegations and a motion to dismiss the allegations based on lack of jurisdiction. In December 2011, the Court stayed all discovery and scheduling deadlines for 60 days (through Feb. 15, 2012) so that the Parties may continue settlement negotiations. In February 2012, the Court extended the stay. In April 2012, WPL and Sierra Club filed a joint settlement status report requesting the Court to stay all case management deadlines and agreeing to file a settlement status report by July 15, 2012, if no consent decree is filed by that date. WPL and Sierra Club are currently engaged in settlement discussions regarding the Nelson Dewey, Columbia and Edgewater air permitting violation claims.

In 2009, the EPA sent a Notice of Violation (NOV) to WPL as an owner and the operator of Edgewater, Nelson Dewey and Columbia. The NOV alleges that the owners failed to comply with appropriate pre-construction review and permitting requirements and as a result violated the PSD program requirements, Title V Operating Permit requirements of the CAA and the Wisconsin SIP. WPL is engaged in settlement negotiations with the EPA in conjunction with the settlement negotiations with the Sierra Club discussed above.

In response to similar EPA CAA enforcement initiatives, certain utilities have elected to settle with the EPA, while others have elected to litigate. If the EPA and/or Sierra Club successfully prove their claims that projects completed in the past at Edgewater, Nelson Dewey and Columbia required either a state or federal CAA permit, WPL may, under the applicable statutes, be required to pay civil penalties in amounts of up to $37,500 per day for each violation and/or complete actions for injunctive relief. Payment of fines and/or injunctive relief could be included in a settlement outcome. Injunctive relief contained in settlements or court-ordered remedies for other utilities required the installation of emission control technology, changed operating conditions including use of alternative fuels other than coal, caps for emissions and limitations on generation including retirement of generating units, and other beneficial environmental projects. If similar remedies are required for final resolution of these matters at Edgewater, Nelson Dewey and Columbia, Alliant Energy and WPL would incur additional capital and operating expenditures. Alliant Energy and WPL are continuing to analyze the allegations and are unable to predict the impact of the allegations on their financial condition or results of operations, but believe that the outcome could be significant. WPL and the other owners of Edgewater and Columbia are exploring settlement options while simultaneously defending against these allegations. Alliant Energy and WPL believe the projects at Edgewater, Nelson Dewey and Columbia were routine or not projected to increase emissions and therefore did not violate the permitting requirements of the CAA.

Alliant Energy and WPL do not currently believe any material losses from these air permitting violation claims are both probable and reasonably estimated and therefore have not recognized any material related loss contingency amounts as of March 31, 2012. Alliant Energy and WPL are not able to estimate the possible loss or range of possible loss related to these air permit violation claims given the various litigation and settlement scenarios being pursued to resolve this contingency as well as uncertainty regarding which, if any, allegations will be determined to be violations and the nature and cost of any fines and injunctive relief that could be required to resolve any violations.

 

Alliant Energy Cash Balance Pension Plan (Plan)In February 2008, a class action lawsuit was filed against the Plan in the U.S. District Court for the Western District of Wisconsin (Court). The complaint alleged that certain Plan participants who received distributions prior to their normal retirement age did not receive the full benefit to which they were entitled in violation of ERISA because the Plan applied an improper interest crediting rate to project the cash balance account to their normal retirement age. These Plan participants were limited to individuals who, prior to normal retirement age, received a lump sum distribution or an annuity payment. The Court certified two subclasses of plaintiffs that in aggregate include all persons vested or partially vested in the Plan who received these distributions from Jan. 1, 1998 to Aug. 17, 2006 including: (1) persons who received distributions from Jan. 1, 1998 through Feb. 28, 2002; and (2) persons who received distributions from March 1, 2002 to Aug. 17, 2006.

In June 2010, the Court issued an opinion and order that granted the plaintiffs' motion for summary judgment on liability in the lawsuit and decided with respect to damages that prejudgment interest on damages would be allowed. In December 2010, the Court issued an opinion and order that decided the interest crediting rate that the Plan used to project the cash balance accounts of the plaintiffs during the class period should have been 8.2% and that a pre-retirement mortality discount would not be applied to the damages calculation. In March 2011, the Court issued an opinion and order that prejudgment interest on damages would be calculated using the average prime rate from the date that the Plan failed to make the total payment to a particular participant through the date of the final judgment (which has not yet been issued). In September 2011, plaintiffs filed a motion for leave to file a supplemental complaint to assert that the 2011 amendment to the Plan, made to conform with the IRS determination letter (described below), was itself an ERISA violation. In November 2011, the Court allowed the filing of the plaintiffs' supplemental complaint and denied a separate motion for reconsideration filed by the Plan arguing that certain of plaintiffs' claims were time-barred. Following the November 2011 ruling, plaintiffs filed a supplemental complaint and the Plan filed an answer and an amended answer. In March 2012, the Plan and the plaintiffs each filed motions for summary judgment related to the supplemental complaint, and the plaintiffs filed a motion for class certification, seeking to amend the class definition and for reappointment of class representatives and class counsel. In April 2012, both the Plan and the plaintiffs filed briefs opposing the other party's motion for summary judgment. The Plan also filed a brief opposing the plaintiffs' motion for class certification.

Based on opinions and orders issued by the Court to date and the $10.2 million of IRS-related offset benefits paid by the Plan in 2011, the Plan currently estimates that the trial court judgment of damages, after offsetting the additional benefits paid to participants by the Plan, will be at least $17 million, which includes prejudgment interest through March 31, 2012, but does not include any award for plaintiffs' attorney's fees or costs. The trial court judgment of damages related to the additional claims newly asserted in the supplemental complaint by the plaintiffs in November 2011 is uncertain. Following resolution of the supplemental complaint, the Plan may appeal the trial court judgment of damages to the Seventh Circuit Court of Appeals. As a result, Alliant Energy, IPL and WPL do not currently believe any material losses related to the final judgment of damages from this class action lawsuit are both probable and reasonably estimated, and therefore have not recognized any material loss contingency amounts for the final judgment of damages as of March 31, 2012. Alliant Energy, IPL and WPL are currently unable to predict the final outcome of the class action lawsuit or the ultimate impact on their financial condition or results of operations but believe the outcome could have a material effect on their retirement plan funding and expense.

The IRS also considered the interest crediting rate used to project the cash balance account to participants' normal retirement age as part of its review of Alliant Energy's request for a favorable determination letter with respect to the tax-qualified status of the Plan. Alliant Energy reached an agreement with the IRS, which resulted in a favorable determination letter for the Plan in 2011. The agreement with the IRS required Alliant Energy to amend the Plan in 2011 resulting in $10.2 million of aggregate additional benefits paid by Alliant Energy to certain former participants in the Plan in 2011. The $10.2 million of aggregate payments by Alliant Energy are an offset against any final judgment of damages by the Court in the case discussed above, in whole or in part, depending on the scope of the final judgment.

RMT Contract Disputes—In September 2011, RMT filed a lawsuit in the U.S. District Court for the Western District of Wisconsin alleging, among other things, breach of contract against Cable System Installation (CSI), a subcontractor to RMT on several solar projects in New Jersey. The complaint alleges that CSI breached its contract with RMT by failing to complete the work, by failing to complete the work in a timely manner, by failing to perform work according to the contract, for abandonment of work, and for other related claims. RMT incurred additional costs to replace CSI and to complete CSI's work with alternative subcontractors, incurred liquidated damages assessed by the project owners due to project delays, and had liens filed by CSI's vendors that CSI has not paid. The lawsuit seeks to recover all costs incurred by RMT as a result of the breaches of contract by CSI. CSI filed an answer and counterclaims against RMT asserting that RMT owes CSI additional amounts for work performed under the contract that have not been paid to date. CSI also filed a motion requesting the case be transferred to New Jersey. CSI has filed liens against the projects based on claims that they have not been paid for work performed under the contract with RMT and vendors of CSI have filed liens against the projects based on claims that they have not been paid as required under their agreements with CSI. Two vendors of CSI have also filed lawsuits in New Jersey including claims against both CSI and RMT resulting from work allegedly performed by the two vendors but not paid by CSI or RMT. As of March 31, 2012, RMT has posted bonds of $17 million to discharge the liens filed against the New Jersey project sites by CSI and CSI's vendors. Alliant Energy does not currently believe any material losses from these claims are both probable and reasonably estimated and therefore has not recognized any material related loss contingency amounts as of March 31, 2012. Alliant Energy is currently not able to estimate the possible loss or range of possible loss related to these claims given the early state of the lawsuits. Alliant Energy also has not recognized any material benefits from the lawsuit filed by RMT against CSI as of March 31, 2012.

(c) Guarantees and Indemnifications—Alliant Energy provided an indemnification associated with the 2007 sale of its Mexico business for losses resulting from potential breach of the representations and warranties made by Alliant Energy on the sale date and for the breach of its obligations under the sale agreement. The indemnification has a maximum limit of $20 million and expires in June 2012. Alliant Energy believes the likelihood of having to make any material cash payments under this indemnification is remote. Alliant Energy has not recognized any material liabilities related to this indemnification as of March 31, 2012.

Alliant Energy also continues to guarantee the abandonment obligations of Whiting Petroleum Corporation (Whiting) under the Point Arguello partnership agreements following the sale of Alliant Energy's remaining interest in Whiting in 2004. The guarantee does not include a maximum limit. As of March 31, 2012, the present value of the abandonment obligations is estimated at $29 million. Alliant Energy believes that no payments will be made under this guarantee. Alliant Energy has not recognized any material liabilities related to this guarantee as of March 31, 2012.

RMT provides renewable energy services to clients throughout the U.S., including facility siting, permitting, design, procurement, construction and high voltage connection services for wind and solar projects. Alliant Energy has guaranteed RMT's performance obligations related to certain of these projects. As of March 31, 2012, Alliant Energy had $609 million of performance guarantees outstanding with $101 million, $325 million and $183 million expiring in 2012, 2013 and 2014, respectively. RMT has also provided surety bonds in support of the payment and performance obligations of certain of these projects and Alliant Energy has guaranteed RMT's indemnity obligations to the surety company. As of March 31, 2012, Alliant Energy had $114 million in surety bonds and related Alliant Energy performance guarantees outstanding with $112 million expiring in 2012 and $2 million expiring in 2013. Alliant Energy currently believes that no material cash payments will be made under any of these obligations. Alliant Energy has not recognized any material liabilities related to these obligations as of March 31, 2012.

 

(d)

Environmental Matters—

Manufactured Gas Plant (MGP) SitesIPL and WPL have current or previous ownership interests in 40 and 14 sites, respectively, previously associated with the production of gas for which they may be liable for investigation, remediation and monitoring costs. IPL and WPL have received letters from state environmental agencies requiring no further action at 11 and 9 of these sites, respectively. Additionally, IPL has met state environmental agency expectations at 3 additional sites requiring no further action for soil remediation. IPL and WPL are working pursuant to the requirements of various federal and state agencies to investigate, mitigate, prevent and remediate, where necessary, the environmental impacts to property, including natural resources, at and around the sites in order to protect public health and the environment.

Alliant Energy, IPL and WPL record environmental liabilities related to these MGP sites based upon periodic studies. Such amounts are based on the best current estimate of the remaining amount to be incurred for investigation, remediation and monitoring costs for those sites where the investigation process has been or is substantially completed, and the minimum of the estimated cost range for those sites where the investigation is in its earlier stages. There are inherent uncertainties associated with the estimated remaining costs for MGP projects primarily due to unknown site conditions and potential changes in regulatory agency requirements. It is possible that future cost estimates will be greater than current estimates as the investigation process proceeds and as additional facts become known. The amounts recognized as liabilities are reduced for expenditures incurred and are adjusted as further information develops or circumstances change. Costs of future expenditures for environmental remediation obligations are not discounted. Management currently estimates the range of remaining costs to be incurred for the investigation, remediation and monitoring of these sites to be $21 million ($18 million for IPL and $3 million for WPL) to $45 million ($41 million for IPL and $4 million for WPL). At March 31, 2012, Alliant Energy, IPL and WPL recorded $31 million, $28 million and $3 million, respectively, in current and non-current environmental liabilities for their remaining costs to be incurred for these MGP sites.

 

Other Environmental ContingenciesIn addition to the environmental liabilities discussed above, Alliant Energy, IPL and WPL are also monitoring various environmental regulations that may have a significant impact on their future operations. Given uncertainties regarding the outcome, timing and compliance plans for these environmental matters, Alliant Energy, IPL and WPL are currently not able to determine the complete financial impact of these regulations but do believe that future capital investments and/or modifications to their electric generating facilities to comply with these regulations could be significant. Specific current, proposed or potential environmental matters that may require significant future expenditures by Alliant Energy, IPL and WPL include, among others: CAIR, CSAPR, Clean Air Visibility Rule, Utility Maximum Achievable Control Technology (MACT) Rule, Wisconsin State Mercury Rule, Wisconsin RACT Rule, Ozone National Ambient Air Quality Standards (NAAQS) Rule, Fine Particle NAAQS Rule, Nitrogen Dioxide NAAQS Rule, SO2 NAAQS Rule, Industrial Boiler and Process Heater MACT Rule, Federal Clean Water Act including Section 316(b), Wisconsin and Iowa State Thermal Rules, Hydroelectric Fish Passage Device, Coal Combustion Residuals, Polychlorinated Biphenyls, and various legislation and EPA regulations to monitor and regulate the emission of greenhouse gases (GHG) including the EPA New Source Performance Standard (NSPS) for GHG Emissions from Electric Utilities and the EPA GHG Tailoring Rule. Some recent developments concerning these environmental matters are included below:

Water Quality—

Hydroelectric Fish Passages Device—In March 2012, the Federal Energy Regulatory Commission (FERC) extended the deadline to install an agency-approved fish passage device at WPL's Prairie du Sac hydro plant to July 1, 2015.

GHG Emissions—

EPA NSPS for GHG Emissions from Electric Utilities—In April 2012, the EPA published proposed NSPS for GHG, including carbon dioxide (CO2) emissions from new fossil-fueled electric generating units (EGUs) larger than 25 MW with an output-based emissions rate limitation of 1,000 pounds of CO2 per MWh. This emissions rate limitation is expected to be effective upon the EPA's issuance of the final rule in the second quarter of 2013.

IPL [Member]
 
Commitments And Contingencies

(11) COMMITMENTS AND CONTINGENCIES

(a) Operating Expense Purchase Obligations—Alliant Energy, IPL and WPL have entered into various commodity supply, transportation and storage contracts to meet their obligations to deliver electricity and natural gas to IPL's and WPL's utility customers. Alliant Energy, IPL and WPL also enter into other operating expense purchase obligations with various vendors for other goods and services. At March 31, 2012, minimum future commitments related to these operating expense purchase obligations were as follows (in millions):

 

     Alliant Energy      IPL      WPL  

Purchased power (a):

        

Duane Arnold Energy Center (DAEC) (IPL)

   $ 364       $ 364       $ —     

Kewaunee Nuclear Power Plant (Kewaunee) (WPL)

     131         —           131   

Other

     41         9         32   
  

 

 

    

 

 

    

 

 

 
     536         373         163   

Natural gas

     255         120         135   

Coal (b)

     274         88         61   

Sulfur dioxide (SO2) emission allowances

     34         34         —     

Other (c)

     41         19         22   
  

 

 

    

 

 

    

 

 

 
   $ 1,140       $ 634       $ 381   
  

 

 

    

 

 

    

 

 

 

 

  (a) Includes payments required by purchased power agreements (PPAs) for capacity rights and minimum quantities of MWhs required to be purchased. Excludes contracts that are considered operating leases.
  (b) Corporate Services entered into system-wide coal contracts on behalf of IPL and WPL that include minimum future commitments of $125 million that have not been directly assigned to IPL and WPL since the specific needs of each utility were not yet known as of March 31, 2012.
  (c) Includes individual commitments incurred during the normal course of business that exceeded $1 million at March 31, 2012.

 

(b) Legal Proceedings—

Air Permitting Violation ClaimsIn September 2010, Sierra Club filed in the U.S. District Court for the Western District of Wisconsin a complaint against WPL, as owner and operator of the Nelson Dewey Generating Station (Nelson Dewey) and the Columbia Energy Center (Columbia), based on allegations that modifications were made at the facilities without complying with the Prevention of Significant Deterioration (PSD) program requirements, Title V Operating Permit requirements of the Clean Air Act (CAA) and state regulatory counterparts contained within the Wisconsin state implementation plan (SIP) designed to implement the CAA. In October 2010, WPL responded to these claims related to Nelson Dewey and Columbia by filing with the U.S. District Court an answer denying the Columbia allegations and a motion to dismiss the Nelson Dewey allegations based on statute of limitations arguments. In November 2010, WPL filed a motion to dismiss the Nelson Dewey and Columbia allegations based on lack of jurisdiction. Sierra Club has responded to the motions. In January 2012, the Court reset the trial date to Dec. 10, 2012 and scheduled a status conference for Feb. 15, 2012 to receive an update on settlement progress. At the Feb. 15, 2012 status conference, the Court reaffirmed the Dec. 10, 2012 trial date and set a pre-trial schedule that allows the parties to work toward settlement.

In September 2010, Sierra Club filed in the U.S. District Court for the Eastern District of Wisconsin a complaint against WPL, as owner and operator of the Edgewater Generating Station (Edgewater), which contained similar allegations regarding air permitting violations at Edgewater. In the Edgewater complaint, additional allegations were made regarding violations of emission limits for visible emissions. In February 2011, WPL responded to these claims related to Edgewater by filing with the U.S. District Court an answer denying the allegations and a motion to dismiss the allegations based on lack of jurisdiction. In December 2011, the Court stayed all discovery and scheduling deadlines for 60 days (through Feb. 15, 2012) so that the Parties may continue settlement negotiations. In February 2012, the Court extended the stay. In April 2012, WPL and Sierra Club filed a joint settlement status report requesting the Court to stay all case management deadlines and agreeing to file a settlement status report by July 15, 2012, if no consent decree is filed by that date. WPL and Sierra Club are currently engaged in settlement discussions regarding the Nelson Dewey, Columbia and Edgewater air permitting violation claims.

In 2009, the EPA sent a Notice of Violation (NOV) to WPL as an owner and the operator of Edgewater, Nelson Dewey and Columbia. The NOV alleges that the owners failed to comply with appropriate pre-construction review and permitting requirements and as a result violated the PSD program requirements, Title V Operating Permit requirements of the CAA and the Wisconsin SIP. WPL is engaged in settlement negotiations with the EPA in conjunction with the settlement negotiations with the Sierra Club discussed above.

In response to similar EPA CAA enforcement initiatives, certain utilities have elected to settle with the EPA, while others have elected to litigate. If the EPA and/or Sierra Club successfully prove their claims that projects completed in the past at Edgewater, Nelson Dewey and Columbia required either a state or federal CAA permit, WPL may, under the applicable statutes, be required to pay civil penalties in amounts of up to $37,500 per day for each violation and/or complete actions for injunctive relief. Payment of fines and/or injunctive relief could be included in a settlement outcome. Injunctive relief contained in settlements or court-ordered remedies for other utilities required the installation of emission control technology, changed operating conditions including use of alternative fuels other than coal, caps for emissions and limitations on generation including retirement of generating units, and other beneficial environmental projects. If similar remedies are required for final resolution of these matters at Edgewater, Nelson Dewey and Columbia, Alliant Energy and WPL would incur additional capital and operating expenditures. Alliant Energy and WPL are continuing to analyze the allegations and are unable to predict the impact of the allegations on their financial condition or results of operations, but believe that the outcome could be significant. WPL and the other owners of Edgewater and Columbia are exploring settlement options while simultaneously defending against these allegations. Alliant Energy and WPL believe the projects at Edgewater, Nelson Dewey and Columbia were routine or not projected to increase emissions and therefore did not violate the permitting requirements of the CAA.

Alliant Energy and WPL do not currently believe any material losses from these air permitting violation claims are both probable and reasonably estimated and therefore have not recognized any material related loss contingency amounts as of March 31, 2012. Alliant Energy and WPL are not able to estimate the possible loss or range of possible loss related to these air permit violation claims given the various litigation and settlement scenarios being pursued to resolve this contingency as well as uncertainty regarding which, if any, allegations will be determined to be violations and the nature and cost of any fines and injunctive relief that could be required to resolve any violations.

 

Alliant Energy Cash Balance Pension Plan (Plan)In February 2008, a class action lawsuit was filed against the Plan in the U.S. District Court for the Western District of Wisconsin (Court). The complaint alleged that certain Plan participants who received distributions prior to their normal retirement age did not receive the full benefit to which they were entitled in violation of ERISA because the Plan applied an improper interest crediting rate to project the cash balance account to their normal retirement age. These Plan participants were limited to individuals who, prior to normal retirement age, received a lump sum distribution or an annuity payment. The Court certified two subclasses of plaintiffs that in aggregate include all persons vested or partially vested in the Plan who received these distributions from Jan. 1, 1998 to Aug. 17, 2006 including: (1) persons who received distributions from Jan. 1, 1998 through Feb. 28, 2002; and (2) persons who received distributions from March 1, 2002 to Aug. 17, 2006.

In June 2010, the Court issued an opinion and order that granted the plaintiffs' motion for summary judgment on liability in the lawsuit and decided with respect to damages that prejudgment interest on damages would be allowed. In December 2010, the Court issued an opinion and order that decided the interest crediting rate that the Plan used to project the cash balance accounts of the plaintiffs during the class period should have been 8.2% and that a pre-retirement mortality discount would not be applied to the damages calculation. In March 2011, the Court issued an opinion and order that prejudgment interest on damages would be calculated using the average prime rate from the date that the Plan failed to make the total payment to a particular participant through the date of the final judgment (which has not yet been issued). In September 2011, plaintiffs filed a motion for leave to file a supplemental complaint to assert that the 2011 amendment to the Plan, made to conform with the IRS determination letter (described below), was itself an ERISA violation. In November 2011, the Court allowed the filing of the plaintiffs' supplemental complaint and denied a separate motion for reconsideration filed by the Plan arguing that certain of plaintiffs' claims were time-barred. Following the November 2011 ruling, plaintiffs filed a supplemental complaint and the Plan filed an answer and an amended answer. In March 2012, the Plan and the plaintiffs each filed motions for summary judgment related to the supplemental complaint, and the plaintiffs filed a motion for class certification, seeking to amend the class definition and for reappointment of class representatives and class counsel. In April 2012, both the Plan and the plaintiffs filed briefs opposing the other party's motion for summary judgment. The Plan also filed a brief opposing the plaintiffs' motion for class certification.

Based on opinions and orders issued by the Court to date and the $10.2 million of IRS-related offset benefits paid by the Plan in 2011, the Plan currently estimates that the trial court judgment of damages, after offsetting the additional benefits paid to participants by the Plan, will be at least $17 million, which includes prejudgment interest through March 31, 2012, but does not include any award for plaintiffs' attorney's fees or costs. The trial court judgment of damages related to the additional claims newly asserted in the supplemental complaint by the plaintiffs in November 2011 is uncertain. Following resolution of the supplemental complaint, the Plan may appeal the trial court judgment of damages to the Seventh Circuit Court of Appeals. As a result, Alliant Energy, IPL and WPL do not currently believe any material losses related to the final judgment of damages from this class action lawsuit are both probable and reasonably estimated, and therefore have not recognized any material loss contingency amounts for the final judgment of damages as of March 31, 2012. Alliant Energy, IPL and WPL are currently unable to predict the final outcome of the class action lawsuit or the ultimate impact on their financial condition or results of operations but believe the outcome could have a material effect on their retirement plan funding and expense.

The IRS also considered the interest crediting rate used to project the cash balance account to participants' normal retirement age as part of its review of Alliant Energy's request for a favorable determination letter with respect to the tax-qualified status of the Plan. Alliant Energy reached an agreement with the IRS, which resulted in a favorable determination letter for the Plan in 2011. The agreement with the IRS required Alliant Energy to amend the Plan in 2011 resulting in $10.2 million of aggregate additional benefits paid by Alliant Energy to certain former participants in the Plan in 2011. The $10.2 million of aggregate payments by Alliant Energy are an offset against any final judgment of damages by the Court in the case discussed above, in whole or in part, depending on the scope of the final judgment.

RMT Contract Disputes—In September 2011, RMT filed a lawsuit in the U.S. District Court for the Western District of Wisconsin alleging, among other things, breach of contract against Cable System Installation (CSI), a subcontractor to RMT on several solar projects in New Jersey. The complaint alleges that CSI breached its contract with RMT by failing to complete the work, by failing to complete the work in a timely manner, by failing to perform work according to the contract, for abandonment of work, and for other related claims. RMT incurred additional costs to replace CSI and to complete CSI's work with alternative subcontractors, incurred liquidated damages assessed by the project owners due to project delays, and had liens filed by CSI's vendors that CSI has not paid. The lawsuit seeks to recover all costs incurred by RMT as a result of the breaches of contract by CSI. CSI filed an answer and counterclaims against RMT asserting that RMT owes CSI additional amounts for work performed under the contract that have not been paid to date. CSI also filed a motion requesting the case be transferred to New Jersey. CSI has filed liens against the projects based on claims that they have not been paid for work performed under the contract with RMT and vendors of CSI have filed liens against the projects based on claims that they have not been paid as required under their agreements with CSI. Two vendors of CSI have also filed lawsuits in New Jersey including claims against both CSI and RMT resulting from work allegedly performed by the two vendors but not paid by CSI or RMT. As of March 31, 2012, RMT has posted bonds of $17 million to discharge the liens filed against the New Jersey project sites by CSI and CSI's vendors. Alliant Energy does not currently believe any material losses from these claims are both probable and reasonably estimated and therefore has not recognized any material related loss contingency amounts as of March 31, 2012. Alliant Energy is currently not able to estimate the possible loss or range of possible loss related to these claims given the early state of the lawsuits. Alliant Energy also has not recognized any material benefits from the lawsuit filed by RMT against CSI as of March 31, 2012.

(c) Guarantees and Indemnifications—Alliant Energy provided an indemnification associated with the 2007 sale of its Mexico business for losses resulting from potential breach of the representations and warranties made by Alliant Energy on the sale date and for the breach of its obligations under the sale agreement. The indemnification has a maximum limit of $20 million and expires in June 2012. Alliant Energy believes the likelihood of having to make any material cash payments under this indemnification is remote. Alliant Energy has not recognized any material liabilities related to this indemnification as of March 31, 2012.

Alliant Energy also continues to guarantee the abandonment obligations of Whiting Petroleum Corporation (Whiting) under the Point Arguello partnership agreements following the sale of Alliant Energy's remaining interest in Whiting in 2004. The guarantee does not include a maximum limit. As of March 31, 2012, the present value of the abandonment obligations is estimated at $29 million. Alliant Energy believes that no payments will be made under this guarantee. Alliant Energy has not recognized any material liabilities related to this guarantee as of March 31, 2012.

RMT provides renewable energy services to clients throughout the U.S., including facility siting, permitting, design, procurement, construction and high voltage connection services for wind and solar projects. Alliant Energy has guaranteed RMT's performance obligations related to certain of these projects. As of March 31, 2012, Alliant Energy had $609 million of performance guarantees outstanding with $101 million, $325 million and $183 million expiring in 2012, 2013 and 2014, respectively. RMT has also provided surety bonds in support of the payment and performance obligations of certain of these projects and Alliant Energy has guaranteed RMT's indemnity obligations to the surety company. As of March 31, 2012, Alliant Energy had $114 million in surety bonds and related Alliant Energy performance guarantees outstanding with $112 million expiring in 2012 and $2 million expiring in 2013. Alliant Energy currently believes that no material cash payments will be made under any of these obligations. Alliant Energy has not recognized any material liabilities related to these obligations as of March 31, 2012.

 

(d) Environmental Matters—

Manufactured Gas Plant (MGP) SitesIPL and WPL have current or previous ownership interests in 40 and 14 sites, respectively, previously associated with the production of gas for which they may be liable for investigation, remediation and monitoring costs. IPL and WPL have received letters from state environmental agencies requiring no further action at 11 and 9 of these sites, respectively. Additionally, IPL has met state environmental agency expectations at 3 additional sites requiring no further action for soil remediation. IPL and WPL are working pursuant to the requirements of various federal and state agencies to investigate, mitigate, prevent and remediate, where necessary, the environmental impacts to property, including natural resources, at and around the sites in order to protect public health and the environment.

Alliant Energy, IPL and WPL record environmental liabilities related to these MGP sites based upon periodic studies. Such amounts are based on the best current estimate of the remaining amount to be incurred for investigation, remediation and monitoring costs for those sites where the investigation process has been or is substantially completed, and the minimum of the estimated cost range for those sites where the investigation is in its earlier stages. There are inherent uncertainties associated with the estimated remaining costs for MGP projects primarily due to unknown site conditions and potential changes in regulatory agency requirements. It is possible that future cost estimates will be greater than current estimates as the investigation process proceeds and as additional facts become known. The amounts recognized as liabilities are reduced for expenditures incurred and are adjusted as further information develops or circumstances change. Costs of future expenditures for environmental remediation obligations are not discounted. Management currently estimates the range of remaining costs to be incurred for the investigation, remediation and monitoring of these sites to be $21 million ($18 million for IPL and $3 million for WPL) to $45 million ($41 million for IPL and $4 million for WPL). At March 31, 2012, Alliant Energy, IPL and WPL recorded $31 million, $28 million and $3 million, respectively, in current and non-current environmental liabilities for their remaining costs to be incurred for these MGP sites.

 

Other Environmental ContingenciesIn addition to the environmental liabilities discussed above, Alliant Energy, IPL and WPL are also monitoring various environmental regulations that may have a significant impact on their future operations. Given uncertainties regarding the outcome, timing and compliance plans for these environmental matters, Alliant Energy, IPL and WPL are currently not able to determine the complete financial impact of these regulations but do believe that future capital investments and/or modifications to their electric generating facilities to comply with these regulations could be significant. Specific current, proposed or potential environmental matters that may require significant future expenditures by Alliant Energy, IPL and WPL include, among others: CAIR, CSAPR, Clean Air Visibility Rule, Utility Maximum Achievable Control Technology (MACT) Rule, Wisconsin State Mercury Rule, Wisconsin RACT Rule, Ozone National Ambient Air Quality Standards (NAAQS) Rule, Fine Particle NAAQS Rule, Nitrogen Dioxide NAAQS Rule, SO2 NAAQS Rule, Industrial Boiler and Process Heater MACT Rule, Federal Clean Water Act including Section 316(b), Wisconsin and Iowa State Thermal Rules, Hydroelectric Fish Passage Device, Coal Combustion Residuals, Polychlorinated Biphenyls, and various legislation and EPA regulations to monitor and regulate the emission of greenhouse gases (GHG) including the EPA New Source Performance Standard (NSPS) for GHG Emissions from Electric Utilities and the EPA GHG Tailoring Rule. Some recent developments concerning these environmental matters are included below:

Water Quality—

Hydroelectric Fish Passages Device—In March 2012, the Federal Energy Regulatory Commission (FERC) extended the deadline to install an agency-approved fish passage device at WPL's Prairie du Sac hydro plant to July 1, 2015.

GHG Emissions—

EPA NSPS for GHG Emissions from Electric Utilities—In April 2012, the EPA published proposed NSPS for GHG, including carbon dioxide (CO2) emissions from new fossil-fueled electric generating units (EGUs) larger than 25 MW with an output-based emissions rate limitation of 1,000 pounds of CO2 per MWh. This emissions rate limitation is expected to be effective upon the EPA's issuance of the final rule in the second quarter of 2013.

WPL [Member]
 
Commitments And Contingencies

(11) COMMITMENTS AND CONTINGENCIES

(a) Operating Expense Purchase Obligations—Alliant Energy, IPL and WPL have entered into various commodity supply, transportation and storage contracts to meet their obligations to deliver electricity and natural gas to IPL's and WPL's utility customers. Alliant Energy, IPL and WPL also enter into other operating expense purchase obligations with various vendors for other goods and services. At March 31, 2012, minimum future commitments related to these operating expense purchase obligations were as follows (in millions):

 

     Alliant Energy      IPL      WPL  

Purchased power (a):

        

Duane Arnold Energy Center (DAEC) (IPL)

   $ 364       $ 364       $ —     

Kewaunee Nuclear Power Plant (Kewaunee) (WPL)

     131         —           131   

Other

     41         9         32   
  

 

 

    

 

 

    

 

 

 
     536         373         163   

Natural gas

     255         120         135   

Coal (b)

     274         88         61   

Sulfur dioxide (SO2) emission allowances

     34         34         —     

Other (c)

     41         19         22   
  

 

 

    

 

 

    

 

 

 
   $ 1,140       $ 634       $ 381   
  

 

 

    

 

 

    

 

 

 

 

  (a) Includes payments required by purchased power agreements (PPAs) for capacity rights and minimum quantities of MWhs required to be purchased. Excludes contracts that are considered operating leases.
  (b) Corporate Services entered into system-wide coal contracts on behalf of IPL and WPL that include minimum future commitments of $125 million that have not been directly assigned to IPL and WPL since the specific needs of each utility were not yet known as of March 31, 2012.
  (c) Includes individual commitments incurred during the normal course of business that exceeded $1 million at March 31, 2012.

 

(b) Legal Proceedings—

Air Permitting Violation ClaimsIn September 2010, Sierra Club filed in the U.S. District Court for the Western District of Wisconsin a complaint against WPL, as owner and operator of the Nelson Dewey Generating Station (Nelson Dewey) and the Columbia Energy Center (Columbia), based on allegations that modifications were made at the facilities without complying with the Prevention of Significant Deterioration (PSD) program requirements, Title V Operating Permit requirements of the Clean Air Act (CAA) and state regulatory counterparts contained within the Wisconsin state implementation plan (SIP) designed to implement the CAA. In October 2010, WPL responded to these claims related to Nelson Dewey and Columbia by filing with the U.S. District Court an answer denying the Columbia allegations and a motion to dismiss the Nelson Dewey allegations based on statute of limitations arguments. In November 2010, WPL filed a motion to dismiss the Nelson Dewey and Columbia allegations based on lack of jurisdiction. Sierra Club has responded to the motions. In January 2012, the Court reset the trial date to Dec. 10, 2012 and scheduled a status conference for Feb. 15, 2012 to receive an update on settlement progress. At the Feb. 15, 2012 status conference, the Court reaffirmed the Dec. 10, 2012 trial date and set a pre-trial schedule that allows the parties to work toward settlement.

In September 2010, Sierra Club filed in the U.S. District Court for the Eastern District of Wisconsin a complaint against WPL, as owner and operator of the Edgewater Generating Station (Edgewater), which contained similar allegations regarding air permitting violations at Edgewater. In the Edgewater complaint, additional allegations were made regarding violations of emission limits for visible emissions. In February 2011, WPL responded to these claims related to Edgewater by filing with the U.S. District Court an answer denying the allegations and a motion to dismiss the allegations based on lack of jurisdiction. In December 2011, the Court stayed all discovery and scheduling deadlines for 60 days (through Feb. 15, 2012) so that the Parties may continue settlement negotiations. In February 2012, the Court extended the stay. In April 2012, WPL and Sierra Club filed a joint settlement status report requesting the Court to stay all case management deadlines and agreeing to file a settlement status report by July 15, 2012, if no consent decree is filed by that date. WPL and Sierra Club are currently engaged in settlement discussions regarding the Nelson Dewey, Columbia and Edgewater air permitting violation claims.

In 2009, the EPA sent a Notice of Violation (NOV) to WPL as an owner and the operator of Edgewater, Nelson Dewey and Columbia. The NOV alleges that the owners failed to comply with appropriate pre-construction review and permitting requirements and as a result violated the PSD program requirements, Title V Operating Permit requirements of the CAA and the Wisconsin SIP. WPL is engaged in settlement negotiations with the EPA in conjunction with the settlement negotiations with the Sierra Club discussed above.

In response to similar EPA CAA enforcement initiatives, certain utilities have elected to settle with the EPA, while others have elected to litigate. If the EPA and/or Sierra Club successfully prove their claims that projects completed in the past at Edgewater, Nelson Dewey and Columbia required either a state or federal CAA permit, WPL may, under the applicable statutes, be required to pay civil penalties in amounts of up to $37,500 per day for each violation and/or complete actions for injunctive relief. Payment of fines and/or injunctive relief could be included in a settlement outcome. Injunctive relief contained in settlements or court-ordered remedies for other utilities required the installation of emission control technology, changed operating conditions including use of alternative fuels other than coal, caps for emissions and limitations on generation including retirement of generating units, and other beneficial environmental projects. If similar remedies are required for final resolution of these matters at Edgewater, Nelson Dewey and Columbia, Alliant Energy and WPL would incur additional capital and operating expenditures. Alliant Energy and WPL are continuing to analyze the allegations and are unable to predict the impact of the allegations on their financial condition or results of operations, but believe that the outcome could be significant. WPL and the other owners of Edgewater and Columbia are exploring settlement options while simultaneously defending against these allegations. Alliant Energy and WPL believe the projects at Edgewater, Nelson Dewey and Columbia were routine or not projected to increase emissions and therefore did not violate the permitting requirements of the CAA.

Alliant Energy and WPL do not currently believe any material losses from these air permitting violation claims are both probable and reasonably estimated and therefore have not recognized any material related loss contingency amounts as of March 31, 2012. Alliant Energy and WPL are not able to estimate the possible loss or range of possible loss related to these air permit violation claims given the various litigation and settlement scenarios being pursued to resolve this contingency as well as uncertainty regarding which, if any, allegations will be determined to be violations and the nature and cost of any fines and injunctive relief that could be required to resolve any violations.

 

Alliant Energy Cash Balance Pension Plan (Plan)In February 2008, a class action lawsuit was filed against the Plan in the U.S. District Court for the Western District of Wisconsin (Court). The complaint alleged that certain Plan participants who received distributions prior to their normal retirement age did not receive the full benefit to which they were entitled in violation of ERISA because the Plan applied an improper interest crediting rate to project the cash balance account to their normal retirement age. These Plan participants were limited to individuals who, prior to normal retirement age, received a lump sum distribution or an annuity payment. The Court certified two subclasses of plaintiffs that in aggregate include all persons vested or partially vested in the Plan who received these distributions from Jan. 1, 1998 to Aug. 17, 2006 including: (1) persons who received distributions from Jan. 1, 1998 through Feb. 28, 2002; and (2) persons who received distributions from March 1, 2002 to Aug. 17, 2006.

In June 2010, the Court issued an opinion and order that granted the plaintiffs' motion for summary judgment on liability in the lawsuit and decided with respect to damages that prejudgment interest on damages would be allowed. In December 2010, the Court issued an opinion and order that decided the interest crediting rate that the Plan used to project the cash balance accounts of the plaintiffs during the class period should have been 8.2% and that a pre-retirement mortality discount would not be applied to the damages calculation. In March 2011, the Court issued an opinion and order that prejudgment interest on damages would be calculated using the average prime rate from the date that the Plan failed to make the total payment to a particular participant through the date of the final judgment (which has not yet been issued). In September 2011, plaintiffs filed a motion for leave to file a supplemental complaint to assert that the 2011 amendment to the Plan, made to conform with the IRS determination letter (described below), was itself an ERISA violation. In November 2011, the Court allowed the filing of the plaintiffs' supplemental complaint and denied a separate motion for reconsideration filed by the Plan arguing that certain of plaintiffs' claims were time-barred. Following the November 2011 ruling, plaintiffs filed a supplemental complaint and the Plan filed an answer and an amended answer. In March 2012, the Plan and the plaintiffs each filed motions for summary judgment related to the supplemental complaint, and the plaintiffs filed a motion for class certification, seeking to amend the class definition and for reappointment of class representatives and class counsel. In April 2012, both the Plan and the plaintiffs filed briefs opposing the other party's motion for summary judgment. The Plan also filed a brief opposing the plaintiffs' motion for class certification.

Based on opinions and orders issued by the Court to date and the $10.2 million of IRS-related offset benefits paid by the Plan in 2011, the Plan currently estimates that the trial court judgment of damages, after offsetting the additional benefits paid to participants by the Plan, will be at least $17 million, which includes prejudgment interest through March 31, 2012, but does not include any award for plaintiffs' attorney's fees or costs. The trial court judgment of damages related to the additional claims newly asserted in the supplemental complaint by the plaintiffs in November 2011 is uncertain. Following resolution of the supplemental complaint, the Plan may appeal the trial court judgment of damages to the Seventh Circuit Court of Appeals. As a result, Alliant Energy, IPL and WPL do not currently believe any material losses related to the final judgment of damages from this class action lawsuit are both probable and reasonably estimated, and therefore have not recognized any material loss contingency amounts for the final judgment of damages as of March 31, 2012. Alliant Energy, IPL and WPL are currently unable to predict the final outcome of the class action lawsuit or the ultimate impact on their financial condition or results of operations but believe the outcome could have a material effect on their retirement plan funding and expense.

The IRS also considered the interest crediting rate used to project the cash balance account to participants' normal retirement age as part of its review of Alliant Energy's request for a favorable determination letter with respect to the tax-qualified status of the Plan. Alliant Energy reached an agreement with the IRS, which resulted in a favorable determination letter for the Plan in 2011. The agreement with the IRS required Alliant Energy to amend the Plan in 2011 resulting in $10.2 million of aggregate additional benefits paid by Alliant Energy to certain former participants in the Plan in 2011. The $10.2 million of aggregate payments by Alliant Energy are an offset against any final judgment of damages by the Court in the case discussed above, in whole or in part, depending on the scope of the final judgment.

RMT Contract Disputes—In September 2011, RMT filed a lawsuit in the U.S. District Court for the Western District of Wisconsin alleging, among other things, breach of contract against Cable System Installation (CSI), a subcontractor to RMT on several solar projects in New Jersey. The complaint alleges that CSI breached its contract with RMT by failing to complete the work, by failing to complete the work in a timely manner, by failing to perform work according to the contract, for abandonment of work, and for other related claims. RMT incurred additional costs to replace CSI and to complete CSI's work with alternative subcontractors, incurred liquidated damages assessed by the project owners due to project delays, and had liens filed by CSI's vendors that CSI has not paid. The lawsuit seeks to recover all costs incurred by RMT as a result of the breaches of contract by CSI. CSI filed an answer and counterclaims against RMT asserting that RMT owes CSI additional amounts for work performed under the contract that have not been paid to date. CSI also filed a motion requesting the case be transferred to New Jersey. CSI has filed liens against the projects based on claims that they have not been paid for work performed under the contract with RMT and vendors of CSI have filed liens against the projects based on claims that they have not been paid as required under their agreements with CSI. Two vendors of CSI have also filed lawsuits in New Jersey including claims against both CSI and RMT resulting from work allegedly performed by the two vendors but not paid by CSI or RMT. As of March 31, 2012, RMT has posted bonds of $17 million to discharge the liens filed against the New Jersey project sites by CSI and CSI's vendors. Alliant Energy does not currently believe any material losses from these claims are both probable and reasonably estimated and therefore has not recognized any material related loss contingency amounts as of March 31, 2012. Alliant Energy is currently not able to estimate the possible loss or range of possible loss related to these claims given the early state of the lawsuits. Alliant Energy also has not recognized any material benefits from the lawsuit filed by RMT against CSI as of March 31, 2012.

(c) Guarantees and Indemnifications—Alliant Energy provided an indemnification associated with the 2007 sale of its Mexico business for losses resulting from potential breach of the representations and warranties made by Alliant Energy on the sale date and for the breach of its obligations under the sale agreement. The indemnification has a maximum limit of $20 million and expires in June 2012. Alliant Energy believes the likelihood of having to make any material cash payments under this indemnification is remote. Alliant Energy has not recognized any material liabilities related to this indemnification as of March 31, 2012.

Alliant Energy also continues to guarantee the abandonment obligations of Whiting Petroleum Corporation (Whiting) under the Point Arguello partnership agreements following the sale of Alliant Energy's remaining interest in Whiting in 2004. The guarantee does not include a maximum limit. As of March 31, 2012, the present value of the abandonment obligations is estimated at $29 million. Alliant Energy believes that no payments will be made under this guarantee. Alliant Energy has not recognized any material liabilities related to this guarantee as of March 31, 2012.

RMT provides renewable energy services to clients throughout the U.S., including facility siting, permitting, design, procurement, construction and high voltage connection services for wind and solar projects. Alliant Energy has guaranteed RMT's performance obligations related to certain of these projects. As of March 31, 2012, Alliant Energy had $609 million of performance guarantees outstanding with $101 million, $325 million and $183 million expiring in 2012, 2013 and 2014, respectively. RMT has also provided surety bonds in support of the payment and performance obligations of certain of these projects and Alliant Energy has guaranteed RMT's indemnity obligations to the surety company. As of March 31, 2012, Alliant Energy had $114 million in surety bonds and related Alliant Energy performance guarantees outstanding with $112 million expiring in 2012 and $2 million expiring in 2013. Alliant Energy currently believes that no material cash payments will be made under any of these obligations. Alliant Energy has not recognized any material liabilities related to these obligations as of March 31, 2012.

 

(d) Environmental Matters—

Manufactured Gas Plant (MGP) SitesIPL and WPL have current or previous ownership interests in 40 and 14 sites, respectively, previously associated with the production of gas for which they may be liable for investigation, remediation and monitoring costs. IPL and WPL have received letters from state environmental agencies requiring no further action at 11 and 9 of these sites, respectively. Additionally, IPL has met state environmental agency expectations at 3 additional sites requiring no further action for soil remediation. IPL and WPL are working pursuant to the requirements of various federal and state agencies to investigate, mitigate, prevent and remediate, where necessary, the environmental impacts to property, including natural resources, at and around the sites in order to protect public health and the environment.

Alliant Energy, IPL and WPL record environmental liabilities related to these MGP sites based upon periodic studies. Such amounts are based on the best current estimate of the remaining amount to be incurred for investigation, remediation and monitoring costs for those sites where the investigation process has been or is substantially completed, and the minimum of the estimated cost range for those sites where the investigation is in its earlier stages. There are inherent uncertainties associated with the estimated remaining costs for MGP projects primarily due to unknown site conditions and potential changes in regulatory agency requirements. It is possible that future cost estimates will be greater than current estimates as the investigation process proceeds and as additional facts become known. The amounts recognized as liabilities are reduced for expenditures incurred and are adjusted as further information develops or circumstances change. Costs of future expenditures for environmental remediation obligations are not discounted. Management currently estimates the range of remaining costs to be incurred for the investigation, remediation and monitoring of these sites to be $21 million ($18 million for IPL and $3 million for WPL) to $45 million ($41 million for IPL and $4 million for WPL). At March 31, 2012, Alliant Energy, IPL and WPL recorded $31 million, $28 million and $3 million, respectively, in current and non-current environmental liabilities for their remaining costs to be incurred for these MGP sites.

 

Other Environmental ContingenciesIn addition to the environmental liabilities discussed above, Alliant Energy, IPL and WPL are also monitoring various environmental regulations that may have a significant impact on their future operations. Given uncertainties regarding the outcome, timing and compliance plans for these environmental matters, Alliant Energy, IPL and WPL are currently not able to determine the complete financial impact of these regulations but do believe that future capital investments and/or modifications to their electric generating facilities to comply with these regulations could be significant. Specific current, proposed or potential environmental matters that may require significant future expenditures by Alliant Energy, IPL and WPL include, among others: CAIR, CSAPR, Clean Air Visibility Rule, Utility Maximum Achievable Control Technology (MACT) Rule, Wisconsin State Mercury Rule, Wisconsin RACT Rule, Ozone National Ambient Air Quality Standards (NAAQS) Rule, Fine Particle NAAQS Rule, Nitrogen Dioxide NAAQS Rule, SO2 NAAQS Rule, Industrial Boiler and Process Heater MACT Rule, Federal Clean Water Act including Section 316(b), Wisconsin and Iowa State Thermal Rules, Hydroelectric Fish Passage Device, Coal Combustion Residuals, Polychlorinated Biphenyls, and various legislation and EPA regulations to monitor and regulate the emission of greenhouse gases (GHG) including the EPA New Source Performance Standard (NSPS) for GHG Emissions from Electric Utilities and the EPA GHG Tailoring Rule. Some recent developments concerning these environmental matters are included below:

Water Quality—

Hydroelectric Fish Passages Device—In March 2012, the Federal Energy Regulatory Commission (FERC) extended the deadline to install an agency-approved fish passage device at WPL's Prairie du Sac hydro plant to July 1, 2015.

GHG Emissions—

EPA NSPS for GHG Emissions from Electric Utilities—In April 2012, the EPA published proposed NSPS for GHG, including carbon dioxide (CO2) emissions from new fossil-fueled electric generating units (EGUs) larger than 25 MW with an output-based emissions rate limitation of 1,000 pounds of CO2 per MWh. This emissions rate limitation is expected to be effective upon the EPA's issuance of the final rule in the second quarter of 2013.