-----BEGIN PRIVACY-ENHANCED MESSAGE----- Proc-Type: 2001,MIC-CLEAR Originator-Name: webmaster@www.sec.gov Originator-Key-Asymmetric: MFgwCgYEVQgBAQICAf8DSgAwRwJAW2sNKK9AVtBzYZmr6aGjlWyK3XmZv3dTINen TWSM7vrzLADbmYQaionwg5sDW3P6oaM5D3tdezXMm7z1T+B+twIDAQAB MIC-Info: RSA-MD5,RSA, JLfUhSjow6d4UPUGTuyaNdEEPORyBYtOmIPnboCrP+yG3mlcR0uXrKgE/OCuGelX gXo56vnzWg3g7lX0Q0XjGw== 0000950134-06-009752.txt : 20060512 0000950134-06-009752.hdr.sgml : 20060512 20060512140617 ACCESSION NUMBER: 0000950134-06-009752 CONFORMED SUBMISSION TYPE: 10-Q PUBLIC DOCUMENT COUNT: 4 CONFORMED PERIOD OF REPORT: 20060402 FILED AS OF DATE: 20060512 DATE AS OF CHANGE: 20060512 FILER: COMPANY DATA: COMPANY CONFORMED NAME: LAKES ENTERTAINMENT INC CENTRAL INDEX KEY: 0001071255 STANDARD INDUSTRIAL CLASSIFICATION: SERVICES-MISCELLANEOUS AMUSEMENT & RECREATION [7990] IRS NUMBER: 411913991 STATE OF INCORPORATION: MN FISCAL YEAR END: 1231 FILING VALUES: FORM TYPE: 10-Q SEC ACT: 1934 Act SEC FILE NUMBER: 000-24993 FILM NUMBER: 06833856 BUSINESS ADDRESS: STREET 1: 130 CHESHIERE LANE CITY: MINNETONKA STATE: MN ZIP: 55305 BUSINESS PHONE: 6124499092 MAIL ADDRESS: STREET 1: 130 CHESHIRE LANE CITY: MINNETONKA STATE: MN ZIP: 55305 FORMER COMPANY: FORMER CONFORMED NAME: LAKES GAMING INC DATE OF NAME CHANGE: 19980929 10-Q 1 c05297e10vq.htm FORM 10-Q e10vq
Table of Contents

 
 
UNITED STATES SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
 
Form 10-Q
     
(Mark One)    
þ
  QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
    For the quarterly period ended April 2, 2006
or
 
o
  TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934
    For the transition period from           to
Commission File No. 0-24993
LAKES ENTERTAINMENT, INC.
(Exact name of registrant as specified in its charter)
     
Minnesota   41-1913991
(State or other jurisdiction of
incorporation or organization)
  (I.R.S. Employer
Identification No.)
130 Cheshire Lane, Suite 101   55305
Minnetonka, Minnesota   (Zip Code)
(Address of principal executive offices)    
(952) 449-9092
(Registrant’s telephone number, including area code)
     Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.     Yes þ          No o
      Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, or a non-accelerated filer. See definition of “accelerated filer and large accelerated filer” in Rule 12b-2 of the Exchange Act. (Check one):
Large Accelerated Filer o          Accelerated Filer þ          Non Accelerated Filer o
      Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).     Yes o          No þ
      As of May 4, 2006, there were 22,874,909 shares of Common Stock, $0.01 par value per share, outstanding.
 
 


 

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
INDEX
             
        Page of
        Form 10-Q
         
PART I. FINANCIAL INFORMATION
ITEM 1.
  FINANCIAL STATEMENTS        
     Condensed Consolidated Balance Sheets as of April 2, 2006 (unaudited) and January 1, 2006     3  
     Unaudited Condensed Consolidated Statements of Earnings (Loss) for the three months ended April 2, 2006 and April 3, 2005     4  
     Unaudited Condensed Consolidated Statements of Comprehensive Earnings (Loss) for the three months ended April 2, 2006 and April 3, 2005     5  
     Unaudited Condensed Consolidated Statements of Shareholders’ Equity for the three months ended April 2, 2006     6  
     Unaudited Condensed Consolidated Statements of Cash Flows for the three months ended April 2, 2006 and April 3, 2005     7  
     Notes to Unaudited Condensed Consolidated Financial Statements     8  
   MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS     23  
   QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK     61  
   CONTROLS AND PROCEDURES     62  
 PART II. OTHER INFORMATION
   LEGAL PROCEEDINGS     63  
   RISK FACTORS     65  
   EXHIBITS     65  
 Certification of CEO Pursuant to Section 302
 Certification of CFO Pursuant to Section 302
 Certification of CEO and CFO Pursuant to Section 906

2


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Condensed Consolidated Balance Sheets
April 2, 2006 and January 1, 2006
                   
    April 2,   January 1,
    2006   2006
         
    (Unaudited)    
    (In thousands)
ASSETS
Current Assets:
               
 
Cash and cash equivalents
  $ 19,329     $ 9,912  
 
(balance includes $3.7 million and $1.7 million of WPT Enterprises, Inc. cash)
               
 
Short-term investments
    35,907       26,735  
 
(balance includes $35.9 million and $26.7 million of WPT Enterprises, Inc. short-term investments)
               
 
Accounts receivable, net of allowance of $0.1 million and $0.1 million
    2,633       3,072  
 
Prepaid expenses
    991       614  
 
Other current assets
    2,606       2,130  
             
Total current assets
    61,466       42,463  
             
Property and equipment, net
    13,621       13,451  
             
Long-term assets related to Indian casino projects:
               
 
Notes receivable from Indian tribes
    105,402       87,062  
 
Land held for development
    16,248       16,248  
 
Intangible assets related to acquisition of management contracts, net
    48,528       46,088  
 
Other
    4,807       3,360  
             
Total long-term assets related to Indian casino projects
    174,985       152,758  
             
Other assets:
               
 
Investments
    5,395       10,640  
 
Deferred tax asset
    5,883       6,852  
 
Debt issuance costs, net of amortization of $0.1 million and $0.0 million
    2,611       19  
 
Other long-term assets
    4,502       4,427  
             
Total other assets
    18,391       21,938  
             
Total Assets
  $ 268,463     $ 230,610  
             
 
LIABILITIES AND SHAREHOLDERS’ EQUITY
Current Liabilities:
               
 
Accounts payable
  $ 9,183     $ 8,394  
 
Income taxes payable
    11,353       10,933  
 
Accrued payroll and related costs
    790       1,125  
 
Deferred revenue
    9,400       5,150  
 
Other accrued expenses
    2,326       2,159  
             
Total current liabilities
    33,052       27,761  
             
Long-term Liabilities:
               
 
Long-term debt, related party
          10,000  
 
Long-term debt, other, net of unamortized discount of $4.5 million and $0.0 million
    20,411        
             
Long-term liabilities
    20,411       10,000  
             
Total Liabilities
    53,463       37,761  
             
Commitments and Contingencies
               
Minority interest in subsidiary
    15,133       14,466  
             
Shareholders’ Equity:
               
 
Series A preferred stock, $.01 par value; authorized 7,500,000 shares; 4,457,751 and 0 issued and outstanding at April 2, 2006 and January 1, 2006, respectively
    45        
 
Common stock, $.01 par value; authorized 200,000 shares; 22,850 and 22,300 common shares issued and outstanding at April 2, 2006, and January 1, 2006, respectively
    228       223  
 
Additional paid-in capital
    169,298       154,301  
 
Retained earnings
    25,093       13,410  
 
Accumulated other comprehensive earnings
    5,203       10,449  
             
Total shareholders’ equity
    199,867       178,383  
             
Total Liabilities and Shareholders’ Equity
  $ 268,463     $ 230,610  
             
See notes to condensed consolidated financial statements

3


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Condensed Consolidated Statements of Earnings (Loss)
Three months ended April 2, 2006 and April 3, 2005
                     
    Three Months Ended
     
    April 2, 2006   April 3, 2005
         
    (In thousands, except per
    share data)
    (Unaudited)
Revenues:
               
 
License fee income
  $ 4,677     $ 3,463  
 
Host fees, sponsorship and other
    1,954       641  
             
   
Total Revenues
    6,631       4,104  
             
Costs and Expenses:
               
 
Selling, general and administrative
    9,176       6,463  
 
Production costs
    2,420       3,187  
 
Depreciation and amortization
    269       92  
             
   
Total Costs and Expenses
    11,865       9,742  
             
Net unrealized gain on notes receivable
    15,476       2,836  
             
Earnings (Loss) From Operations
    10,242       (2,802 )
             
Other Income (Expense):
               
 
Interest income
    433       449  
 
Interest expense, related party
    (137 )      
 
Interest expense, other
    (531 )      
 
Realized gain on sale of investment
    5,675        
 
Other
    78        
             
   
Total other income, net
    5,518       449  
             
Earnings (loss) before income taxes, equity in earnings of unconsolidated investees and minority interest in net earnings (loss) of subsidiary
    15,760       (2,353 )
Income taxes
    2,710       355  
             
Earnings (loss) before equity in earnings of unconsolidated investees and minority interest in net earnings (loss) of subsidiary
    13,050       (2,708 )
Equity in earnings of investees, net of tax
          13  
Minority interest in net (earnings) loss of subsidiary
    (1,367 )     576  
             
Net earnings (loss)
  $ 11,683     $ (2,119 )
             
Earnings (loss) per share — basic
  $ 0.52     $ (0.10 )
             
Earnings (loss) per share — diluted
  $ 0.48     $ (0.10 )
             
Weighted average common shares outstanding — basic
    22,406       22,267  
             
Dilutive effect of common stock equivalents
    1,709        
             
Weighted average common shares outstanding — diluted
    24,115       22,267  
             
See notes to condensed consolidated financial statements

4


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Condensed Consolidated Statements of Comprehensive Earnings (Loss)
Three months ended April 2, 2006 and April 3, 2005
                   
    Three Months Ended
     
    April 2,   April 3,
    2006   2005
         
    (In thousands)
    (Unaudited)
Net earnings (loss)
  $ 11,683     $ (2,119 )
Other comprehensive earnings (loss), net of tax:
               
 
Unrealized gains (losses) on marketable securities:
    429       (42 )
             
Comprehensive Earnings (Loss)
  $ 12,112     $ (2,161 )
             
See notes to condensed consolidated financial statements

5


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Condensed Consolidated Statements of Shareholders’ Equity
Three months ended April 2, 2006
                                                                   
                    Accumulated    
    Preferred Stock   Common Stock   Additional       Other   Total
            Paid-In   Retained   Comprehensive   Shareholders’
    Shares   Amount   Shares   Amount   Capital   Earnings   Earnings (Loss)   Equity
                                 
    (In thousands)
    (Unaudited)
Balances, January 1, 2006
                22,300     $ 223     $ 154,301     $ 13,410     $ 10,449     $ 178,383  
 
Other comprehensive earnings
                                        429       429  
 
Realized gain on sale of investment
                                        (5,675 )     (5,675 )
 
Issuance of preferred stock warrants
    4,458     $ 45                   4,709                   4,754  
 
Issuance of stock on options exercised — net
                550       5       3,107                   3,112  
 
Subsidiary stock options issued to consultants and employees
                            1                   1  
 
Shareholder trading settlement
                            2,805                   2,805  
 
Share-based compensation expense
                            2,381                   2,381  
 
Income taxes
                            1,294                   1,294  
 
Net increase in minority interest in subsidiary
                            700                   700  
 
Net earnings
                                  11,683             11,683  
                                                 
Balances, April 2, 2006
    4,458     $ 45       22,850     $ 228     $ 169,298     $ 25,093     $ 5,203     $ 199,867  
                                                 
See notes to condensed consolidated financial statements

6


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Condensed Consolidated Statements of Cash Flows
Three months ended April 2, 2006 and April 3, 2005
                       
    Three Months Ended
     
    April 2,   April 3,
    2006   2005
         
    (In thousands)
    (Unaudited)
OPERATING ACTIVITIES:
               
 
Net earnings (loss)
  $ 11,683     $ (2,119 )
 
Adjustments to reconcile net earnings (loss) to net cash provided by (used in) operating activities:
               
   
Depreciation and amortization
    269       92  
   
Amortization of deferred financing costs and discount on debt
    165        
   
Share-based compensation
    2,381       425  
   
Net unrealized gains on notes receivable
    (15,476 )     (2,836 )
   
Realized gain on sale of investment
    (5,675 )      
   
Minority interest in net earnings (loss) of subsidiary
    1,367       (576 )
   
Equity in earnings of unconsolidated investees
          (13 )
   
Deferred income taxes
    2,264       (29 )
   
Increases in operating (assets) and liabilities:
               
     
Accounts receivable
    440       815  
     
Prepaid expenses
    (377 )     225  
     
Other
    (476 )     (714 )
     
Income taxes payable
    420       4,569  
     
Accounts payable
    (1,122 )     (348 )
     
Deferred revenue
    4,250       321  
     
Accrued expenses
    (167 )     668  
             
Net Cash Provided by (Used in) Operating Activities
    (54 )     480  
             
INVESTING ACTIVITIES:
               
 
Redemption (purchase) of short-term investment securities
    (9,183 )     9,441  
 
Increases in long-term assets related to Indian casino projects
    (4,340 )     (2,074 )
 
Advances to unconsolidated investees
          (10 )
 
Distributions from unconsolidated investees
          850  
 
Proceeds from sale of investment
    5,686        
 
Payments for other long-term assets
    (77 )     (199 )
 
Decrease in other long-term assets
          197  
 
Purchase of property and equipment
    (804 )     (607 )
             
Net Cash Provided by (Used in) Investing Activities
    (8,718 )     7,598  
             
FINANCING ACTIVITIES:
               
 
Proceeds from issuance of common and preferred stock
    3,157       154  
 
Shareholder trading settlement
    2,805        
 
Repayments of long-term debt, related party
    (10,000 )      
 
Proceeds from issuance of long-term debt, other, net
    22,227        
             
Net Cash Provided by Financing Activities
    18,189       154  
             
Net Increase in Cash and Cash Equivalents
    9,417       8,232  
Cash and Cash Equivalents — Beginning of Period
    9,912       28,717  
             
Cash and Cash Equivalents — End of Period
  $ 19,329     $ 36,949  
             
See notes to condensed consolidated financial statements

7


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements
1. Basis of Presentation:
      The unaudited condensed consolidated financial statements of Lakes Entertainment, Inc., a Minnesota corporation (“Lakes” or the “Company”), have been prepared pursuant to the rules and regulations of the Securities and Exchange Commission (“SEC”) applicable to interim financial information. Accordingly, certain information normally included in the annual financial statements prepared in accordance with accounting principles generally accepted in the United States has been condensed or omitted. For further information, please refer to the annual audited consolidated financial statements of the Company, and the related notes included within the Company’s Annual Report on Form 10-K for the year ended January 1, 2006, previously filed with the SEC on March 8, 2006, from which the balance sheet information as of that date is derived.
      In the opinion of management, all adjustments considered necessary for a fair presentation have been included, consisting only of normal recurring adjustments. The results for the current interim period are not necessarily indicative of the results to be expected for the full year.
      Certain minor reclassification to amounts previously reported have been made to conform to the current period presentation.
2. Management’s Financial Plans:
      Lakes’ cash balance, excluding WPT Enterprises, Inc. (“WPTE”) cash, was approximately $15.6 million as of April 2, 2006. During the remainder of fiscal 2006, Lakes’ corporate costs, excluding WPTE which is not expected to require additional capital from Lakes, will approximate $14 million, which includes approximately $3.0 million of interest related to the financing facility entered into on February 15, 2006 (see Note 4). Project development related costs are expected to approximate $45 million during the remainder of fiscal 2006 and include approximately $24 million related to the Pokagon Band of Potawatomi Indians (“Pokagon Band”) casino resort project as construction is estimated to begin in mid 2006. This $24 million includes a $1.0 million non-refundable payment made in April 2006 to the Pokagon Band scholarship fund upon approval of the management contract between Lakes and the Pokagon Band. Additionally, the Company may be required to pay taxes up to approximately $12 million plus interest and penalties in fiscal 2006 related to two tax matters.
      In December 2005, Lakes obtained a $20 million financing facility from the Lyle Berman Family Partnership (the “Partnership”) and received a $10 million draw on this facility on December 16, 2005. On February 15, 2006, Lakes closed on a $50 million financing facility with an affiliate of Prentice Capital Management, LP (see Note 4). An initial draw of $25 million was made under the facility, another $10 million is immediately available under the facility and the remaining $15 million can be drawn in $5 million increments subject to the satisfaction of certain conditions. All amounts drawn against the facility are repayable within three years. Approximately $10.2 million of the initial draw was used to repay in full the loan from the Partnership.
      Lakes will require additional capital through either public or private financings to meet operating expenses and project development-related costs during fiscal 2006, and accordingly, the Company is currently considering various financing alternatives. The Company believes the assets of Lakes, specifically long-term assets related to Indian casino projects, and common shares of WPTE that have an estimated fair value of over $79.7 million as of May 2, 2006, provide sufficient collateral to obtain the necessary financing. The estimated value of the Company’s shares of WPTE is based on the public trading price, which may not be indicative of what Lakes could realize in a sale of its shares. The Company believes the shares of WPTE could be the source or part of the collateral for additional financing.

8


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
3. Long-Term Investments:
      During the quarter ended April 2, 2006, WPTE sold 630,000 common shares of its then 11.7% interest in PokerTek, Inc. (“PokerTek”) at $9.03 per share and received net cash proceeds of approximately $5.7 million. As a result, WPTE realized a gain of approximately $5.7 million and currently owns 450,000 shares, or a 4.75% ownership interest in PokerTek, included in long-term investments in the accompanying balance sheet.
      WPTE accounts for its investment in PokerTek at fair market value and classified it as “available for sale” in accordance with Statement of Financial Accounting Standards (SFAS) No. 115, Accounting for Certain Investments in Debt and Equity Securities. As of April 2, 2006, the fair market value of the remaining investment was $5.4 million.
4. Long-Term Debt:
      On February 15, 2006, Lakes closed on a $50 million financing facility with PLKS Holdings, LLC, an affiliate of Prentice Capital Management, LP (“PLKS”). An initial draw of $25 million was made under the facility, another $10 million is immediately available under the facility and the remaining $15 million can be drawn in $5 million increments subject to certain conditions. Any funds drawn on the facility bear interest at the rate of 12% per annum, payable in arrears monthly, subject to adjustment based on the value of the collateral described in the following paragraph, and are due and payable in full on the third anniversary of the closing date. Lakes may prepay the facility in whole or in part without penalty at any time. Lakes received net proceeds of approximately $12.1 million after repaying the Partnership facility with accrued interest and after costs and fees associated with the PLKS financing facility. Approximately $10.2 million of the initial draw was used to repay in full Lakes’ December 16, 2005 loan from the Partnership. Pursuant to the terms of the financing agreement, Lakes paid a closing fee of $1.5 million. Lakes is also subject to a loan servicing fee of $5,000 per month; audit and field examination fees at the rate of $1,500 per day; and upon the occurrence of certain events, a collateral maintenance fee equal to 2.00% of the aggregate principal amount of the loan outstanding under the financing facility on the date of the first such event and an additional 2% of the aggregate principal amount of the loan outstanding on such date on the date of each such additional event.
      The $50 million financing facility is secured by most of the assets of Lakes and certain of its subsidiaries (other than WPTE), including all of Lakes’ shares of WPTE. Lakes is permitted to sell up to 3 million of the approximate 12.5 million WPTE shares it owns without application to reduction of the amounts owing under the financing facility, subject to certain conditions.
      As consideration for the financing, Lakes issued to PLKS an aggregate of 4.46 million common stock purchase warrants at an exercise price of $7.50 per share that expire in February 2013. The warrants are subject to customary anti-dilution protections. As of April 2, 2006, 1.25 million of the warrants are immediately exercisable and an additional 1.25 million are exercisable as additional draws under the facility are made. The remaining 1.96 million warrants are exercisable only upon the occurrence of certain specified events relating to declines in the value of the collateral in relation to the principal amount outstanding. The lender has demand registration rights with respect to the Lakes common stock underlying the warrants and, upon certain events, the WPTE shares pledged by Lakes to the lender. In certain circumstances, cash penalties are payable if Lakes does not meet the registration deadlines applicable to the pledged WPTE shares and the holders of the warrants can require Lakes to redeem the warrants if Lakes fails to satisfy its registration obligations with respect to the Lakes common stock underlying the warrants. Lakes has agreed to pay substantially all of the costs incurred in the preparation and filing of these registration statements. The 1.25 million warrants to purchase common stock were valued at $4.7 million using a Black-Scholes pricing model and are being amortized as interest expense over the three-year life of the financing facility. The unamortized portion of the warrants are reported as an in-substance debt discount.

9


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
      As part of the PLKS transaction, the Lakes Board of Directors authorized the creation of a new class of Series A Convertible Preferred Stock, par value $0.01 per share. Lakes sold 4,457,751 shares of the preferred stock to PLKS for $44,578. These preferred shares have no dividend rights, have voting rights only if there is a default under the financing agreement, and become convertible into common stock of Lakes (on a fixed one-to-one basis) only if and when the warrants are cancelled in accordance with the terms of the warrants.
5. Development Financing and Services Agreement With The Jamul Tribe:
      Effective March 30, 2006, Lakes entered into a development financing and services agreement with the Jamul Indian Village (“Jamul Tribe”). As part of the agreement, Lakes will use its best efforts to obtain financing from which advances of up to $350 million will be made to the Jamul Tribe to pay for the design and construction of the project. However, there can be no assurance that third party financing will be available, and if Lakes is unable to obtain the appropriate amount of financing for this project, the project may not be completed as planned. This agreement will help assist the Jamul Tribe in developing a casino with related amenities/services (“Jamul Casino”) on its existing six acre reservation which the Jamul Tribe will manage.
      Under the new agreement, Lakes will receive a flat fee of $15 million for its development design services, and a flat fee of $15 million for its construction oversight services, payable evenly over the first five years after the opening date of the Jamul Casino. In connection with Lakes’ financing of the Jamul Casino, the Jamul Tribe will pay interest over a ten year period on sums advanced by Lakes equal to the rate charged to Lakes for obtaining the funds necessary plus 5%. Amounts previously advanced by Lakes to the Jamul Tribe in connection with the Jamul Tribe’s proposed casino resort are included in the development financing and services agreement financing amount.
6. Settlement Agreement with a Beneficial Owner:
      As of March 17, 2006, Lakes entered into a Settlement Agreement with Deephaven Capital Management LLC (“Deephaven”) pursuant to which Deephaven paid Lakes approximately $2.8 million as repayment of short-swing profits under Section 16(b) of the Securities Exchange Act of 1934, as amended, relating to or in connection with one or more funds managed by Deephaven trading in shares of Lakes’ common stock prior to February 14, 2006. The payment has been recorded as an increase in additional paid in capital.
7. Kickapoo Settlement:
      Lakes entered into a Letter of Settlement (“Settlement Agreement”) with the Kickapoo Traditional Tribe of Texas (“Kickapoo Tribe”) pursuant to which Lakes and the Kickapoo Tribe resolved all outstanding issues relating to the parties’ business relationship that was terminated in November 2005. During fiscal 2005, Lakes recorded a loss of approximately $6.3 million as a result of the terminated business relationship. Pursuant to the Settlement Agreement, during April 2006, Lakes received a cash payment of approximately $2.6 million as reimbursement for payments made directly by Lakes to vendors on behalf of the Kickapoo Tribe and the Kickapoo Tribe agreed to pay $0.6 million into an escrow to be released to Lakes at such time as Lakes transfers title to certain land owned by Lakes to the Kickapoo Tribe. The Company and the Kickapoo Tribe have agreed that title will transfer only after the Kickapoo Tribe assumes, settles or pays certain accounts payable to vendors related to the Kickapoo Tribe’s casino that remain on Lakes’ books, and once Lakes receives full releases for any liability thereto. As a result of the $2.6 million payment, Lakes revalued the note receivable from the Kickapoo Tribe at $2.6 million as of April 2, 2006, and a gain of that amount was recognized in the first quarter of 2006. The land transfer and related release of liabilities will be recognized in the period they occur. When the releases are received from the vendors the Company will recognize a gain. The Company does not have an estimate of when or if this will occur.

10


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
8. Regulatory Approval of Management Contract with the Pokagon Band:
      In March 2006, Lakes received notification from the National Indian Gaming Commission (“NIGC”) that it has approved Lakes’ management agreement with the Pokagon Band to develop and manage the Four Winds Casino Resort on the Pokagon Band’s land in New Buffalo Township, Michigan (“Pokagon Casino”). Lakes is in the process of assisting the Pokagon Band with securing financing to begin construction of the casino.
9. Stock Options and Awards:
Lakes Stock Option Plans:
      Lakes has a Stock Option and Compensation Plan and a Director Stock Option Plan, which were carried forward from Lakes’ predecessor Grand Casinos, Inc. (“Grand Casinos”). All options granted under these plans were carried forward with the original terms and vesting and expiration dates.
      Additionally, Lakes has a 1998 Stock Option and Compensation Plan and a 1998 Director Stock Option Plan (the “1998 Plans”), which upon resolution of the Compensation Committee, are approved to grant up to an aggregate of 5.0 million shares and 0.5 million shares, respectively, of incentive and non-qualified stock options to officers, directors, and employees. Stock options granted under the 1998 Plans vest in equal installments over four-year and five-year periods, beginning on the first anniversary of the date of each grant and continue on each subsequent anniversary date until the option is fully vested. The employee must be employed by Lakes on the anniversary date in order to vest in any shares that year. Vested options are exercisable for ten years from the date of grant; however, if the employee is terminated (voluntarily or involuntarily), any unvested options as of the date of termination will be forfeited.
WPTE Stock Option Plans:
      WPTE has adopted the board-approved, 2004 Stock Incentive Plan (the “2004 Plan”) that is authorized to grant stock awards to purchase up to 3,120,000 shares of common stock, including the options to purchase up to 1,120,000 shares of common stock issued to employees and consultants that were previously outstanding under a previous stock incentive plan at the time of conversion to a publicly-traded company. Under the 2004 Plan, the options vest in equal installments over three-year and five-year periods, beginning on the first anniversary of the date of each grant and will continue on each subsequent anniversary date until the option is fully vested. The employee must be employed with WPTE on the anniversary date in order to vest in any shares that year. Vested options are exercisable for ten years from the date of grant; however, if the employee is terminated (voluntarily or involuntarily), any unvested options as of the date of termination will be forfeited.
      Lakes and WPTE issue new shares of common stock upon exercise of options.
Valuation and Expense Information under SFAS 123(R)
      On January 2, 2006, the Company adopted Statement of Financial Accounting Standards No. 123 (revised 2004), Share-Based Payment, (“SFAS 123(R)”) which requires the measurement and recognition of compensation expense for all stock-based payment awards made to employees and directors including employee stock options and employee stock purchases based on estimated fair values. In March 2005, the SEC issued Staff Accounting Bulletin No. 107 (“SAB 107”) relating to SFAS 123(R). The Company has applied certain provisions of SAB 107 in its adoption of SFAS 123(R).
      SFAS 123(R) requires companies to estimate the fair value of share-based payment awards on the date of grant using an option-pricing model. The value of the portion of the award that is ultimately expected to vest is recognized as expense over the requisite service periods in the Company’s consolidated statement of earnings (loss). SFAS 123(R) supersedes the Company’s previous accounting under the provisions of

11


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
SFAS No. 123, Accounting for Stock-Based Compensation (“SFAS 123”). As permitted by SFAS 123, the Company measured compensation cost for options granted prior to January 2, 2006, in accordance with Accounting Principles Board Opinion (APB) No. 25, Accounting for Stock Issued to Employees and related interpretations. Accordingly, no accounting recognition is given to stock options granted at fair market value until they are exercised. Upon exercise, net proceeds, including tax benefits realized, are credited to equity.
      The Company adopted SFAS 123(R) using the modified prospective transition method, which requires the application of the accounting standard as of January 2, 2006, the first day of the Company’s fiscal year 2006. In accordance with the modified prospective transition method, the Company’s consolidated financial statements for prior periods have not been restated to reflect, and do not include, the impact of SFAS 123(R). The effect of the change was to decrease net earnings for the three months ended April 2, 2006 by $2.2 million and basic and diluted earnings per share by $0.10 and $0.09, respectively, as compared to what results for the period would have been had the intrinsic method been used. There was no share-based compensation expense related to employee stock options and employee stock purchases recognized in the financial statements during the three months ended April 3, 2005. The following table summarizes the consolidated share-based compensation expense related to employee stock options and stock purchases and non-vested shares under SFAS 123(R) for the three months ended April 2, 2006, which was allocated as follows:
         
    Three Months Ended
    April 2, 2006
     
    (In thousands)
Total cost of share-based payment plans
  $ 2,252  
Amounts capitalized in deferred television costs
    34  
Amounts charged against income, before income tax benefit
    2,218  
Amount of related income tax benefit recognized in income
     
      For the three months ended April 2, 2006, no income tax benefit was recognized in the statement of earnings (loss) for share-based compensation arrangements. Management assessed the likelihood that deferred tax assets relating to future tax deductions from share-based compensation will be recovered from future taxable income and determined that a valuation allowance was required due to uncertainty of realization.
      The Company uses a Black-Scholes option-pricing model to value stock options, which requires the consideration of historical employee exercise behavior data and the use of a number of assumptions including volatility of the Company’s stock price, the weighted average risk-free interest rate, and the weighted-average expected life of the options. As the Company does not pay dividends, the dividend rate variable in the Black-Scholes model is zero. The following values for the indicated variables were used to value options granted during the three months ended April 2, 2006, and we expect the assumptions used for grants in future quarters of fiscal 2006 to approximate these values.
Lakes’ valuation assumption summary:
         
    Three Months Ended
    April 2, 2006
     
Expected volatility
    66.2 %
Expected dividend yield
     
Average risk-free interest rate
    4.5 %
Expected term (in years)
    8.2 years  
Weighted-average fair value
  $ 7.01  

12


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
      The volatility assumption is based on the historical weekly price data of Lakes’ stock over a two-year period. Management evaluated whether there were factors during that period which were unusual and which would distort the volatility figure if used to estimate future volatility and concluded that there were no such factors.
      The risk-free interest rate assumption is based upon the interpolation of various U.S. Treasury rates determined at the date of option grant.
      The expected term of employee stock options represents the weighted-average period that the stock options are expected to remain outstanding. It is based upon an analysis of the historical behavior of option holders during the period from September 1995 to April 2, 2006. Management believes historical data is representative of future exercise behavior.
      As share-based compensation expense recognized in the consolidated statement of operations pursuant to SFAS 123(R) is based on awards ultimately expected to vest, expense for grants beginning upon adoption of SFAS 123(R) on January 2, 2006 will be reduced for estimated forfeitures. SFAS 123(R) requires forfeitures to be estimated at the time of grant and revised, if necessary, in subsequent periods if actual forfeitures differ from those estimates. The Company has reviewed the historical forfeitures which are minimal and as such will amortize the grants to the end of the vesting period and will adjust for forfeitures at the end of the term. Forfeitures are estimated based partially on historical experience.
WPTE valuation assumption summary:
         
    Three Months Ended
    April 2, 2006
     
Expected volatility
    84.22 %
Expected dividend yield
     
Average risk-free interest rate
    4.31 %
Expected term (in years)
    6.5 years  
Weighted-average fair value
  $ 4.68  
      WPTE uses a Black-Scholes option-pricing model to estimate the fair value and compensation cost associated with employee incentive stock options in accordance with SFAS 123(R). The bases for the key assumptions included in the model are as follows:
  •  Annualized volatility — As WPTE has limited operating history and no definitive peer or peer groups, expected volatility was based on historical volatility of WPTE’s stock price since it began trading
 
  •  Forfeiture rate — WPTE used historical data to estimate employee departure behavior in estimating future forfeitures
 
  •  Expected term — Due to WPTE’s limited operating history including stock option exercises and forfeitures, WPTE calculated expected term using the “Simplified Method” in accordance with Staff Accounting Bulletin 107, Topic 14
 
  •  Risk free interest rate — For periods within the expected term of the share option, risk free interest rate is based on the U.S. Treasury yield curve in effect at the time of grant

13


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
      The status of Lakes’ stock option plans during the three months ended April 2, 2006 and April 3, 2005 is as follows:
                                     
        Number of Common Shares
         
            Weighted
            Avg.
    Options       Available   Exercise
    Outstanding   Exercisable   for Grant   Price
                 
2006
                               
 
Balance at January 1, 2006
    5,307,626       4,153,476       94,500     $ 6.03  
   
Authorized
                               
   
Granted
    30,000               (30,000 )     9.77  
   
Forfeited/cancelled/expired
                         
   
Exercised
    (550,000 )                     5.65  
                         
 
Balance at April 2, 2006
    4,787,626       3,711,626       64,500     $ 6.10  
                         
2005
                               
 
Balance at January 2, 2005
    5,193,676       3,591,276       266,000     $ 5.72  
   
Authorized
                               
   
Granted
    155,000               (155,000 )     15.75  
   
Forfeited/cancelled/expired
                         
   
Exercised
    (57,550 )                     5.67  
                         
 
Balance at April 3, 2005
    5,291,126       3,641,326       111,000     $ 6.01  
                         
      The following table summarizes significant ranges of Lakes outstanding and exercisable options as of April 2, 2006:
                                                         
    Options Outstanding at April 2, 2006   Options Exercisable at April 2, 2006
         
        Weighted-        
        Average       Aggregate       Aggregate
    Number   Remaining   Weighted-Average   Intrinsic   Number   Weighted-   Intrinsic
Range of Exercise Prices   Outstanding   Contractual Life   Exercise Price   Value   Exercisable   Average Price   Value
                             
$ (3.25 —  3.63)
    289,000       5.3 years     $ 3.45     $ 2,146,000       255,600     $ 3.48     $ 1,891,000  
  (3.63 —  5.45)
    2,535,700       3.0 years       4.24       16,840,000       2,499,700       4.24       16,588,000  
  (5.45 —  7.26)
    106,426       4.7 years       6.52       464,000       76,426       6.26       353,000  
  (7.26 —  9.08)
    1,533,000       7.3 years       8.13       4,219,000       814,000       8.13       2,240,000  
  (9.08 — 10.90)
    77,000       8.9 years       10.44       34,000       10,400       10.60       3,000  
 (10.90 — 12.71)
    81,500       8.6 years       11.43             18,750       11.34        
 (12.71 — 14.53)
    95,000       8.9 years       14.00             20,750       14.08        
 (14.53 — 16.34)
    5,000       8.8 years       16.11             1,000       16.11        
 (16.34 — 18.16)
    65,000       8.9 years       17.91             15,000       17.94        
                                           
      4,787,626       4.9 years     $ 6.10     $ 23,703,000       3,711,626     $ 5.25     $ 21,075,000  
                                           
      The aggregate intrinsic value in the preceding table represents the total pre-tax intrinsic value, based on Lakes’ closing stock price of $10.88 on March 31, 2006, which would have been received by the option holders had all option holders exercised their options as of that date. The total intrinsic value of options exercised during the three months ended April 2, 2006 was $2.0 million. As of April 2, 2006, Lakes’ unrecognized share-based compensation related to stock options was approximately $5.3 million. This cost is expected to be expensed over a weighted average period of 2.2 years.

14


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
      The following table summarizes WPTE stock option activity through the three months ended April 2, 2006 and April 3, 2005:
                                   
        Number of Common Shares
         
    Options       Available for   Weighted Avg.
    Outstanding   Exercisable   Grant   Exercise Price
                 
2006
                               
Balance at January 1, 2006
    2,158,000       620,333       283,667     $ 7.14  
 
Authorized
                               
 
Granted
    219,000               (219,000 )     6.20  
 
Forfeited/cancelled/expired
    (159,333 )             159,333       1.44  
 
Exercised
    (115,000 )                     0.0049  
                         
Balance at April 2, 2006
    2,102,667       785,500       224,000     $ 7.36  
                         
2005
                               
Balance at January 2, 2005
    2,561,000       560,000       559,000     $ 4.61  
 
Authorized
                               
 
Granted
    24,500               (24,500 )     19.50  
 
Forfeited/cancelled/expired
    (32,000 )             32,000       8.60  
 
Exercised
    (640,000 )                     0.0049  
                         
Balance at April 3, 2005
    1,913,500       200,000       566,500     $ 6.27  
                         
      The following table summarizes significant ranges of WPTE outstanding and exercisable options as of April 2, 2006:
                                                         
    Options Outstanding   Options Exercisable
         
        Weighted Avg.   Weighted   Aggregate       Weighted   Aggregate
    Number   Remaining   Avg. Exercise   Intrinsic   Number   Avg.   Intrinsic
Range of Exercise Prices   Outstanding   Contractual Life   Price   Value   Exercisable   Price   Value
                             
$0.0049
    330,000       5.90     $ 0.0049     $ 2,427,183       330,000     $ 0.0049     $ 2,427,183  
$6.20 - 9.92
    1,438,167       8.58       7.78       237,800       445,334       8.04        
$11.95 - 14.51
    286,000       9.36       12.18             8,666       14.51        
$15.05 - 19.50
    48,500       9.25       16.32             1,500       19.50        
                                           
$0.0049 - 19.50
    2,102,667       8.28     $ 7.36     $ 2,664,983       785,500     $ 4.76     $ 2,427,183  
                                           
      The aggregate intrinsic value in the preceding table represents the total pre-tax intrinsic value, based on WPTE’s closing stock price of $7.36 on March 31, 2006, which would have been received by the option holders had all option holders exercised their options as of that date. As of April 2, 2006, the total number of “in-the-money” options exercisable was 330,000. The total intrinsic value of options exercised during the three months ended April 2, 2006 was $0.8 million.
      As of April 2, 2006, total compensation cost related to non-vested share-based options not yet recognized was $6.1 million, which is expected to be recognized over the next 33 months on a weighted-average basis. The total fair value of the shares vested during the three months ended April 2, 2006 was $21,150.
WPTE Restricted shares issued
      In 2002, WPTE granted 2,400,000 shares to its President under a management agreement. The shares have been vesting in four equal installments annually beginning February 25, 2003, and were fully vested on February 25, 2006. In connection with this grant, WPTE recorded deferred compensation of $19,200. For the three months ended April 2, 2006 and April 3, 2005, WPTE recognized compensation expense of $736 and $1,200, respectively, for shares earned based upon services provided under the management agreement.

15


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
Consolidated pro forma information required under SFAS 123
      The following table illustrates the consolidated pro forma effect on net loss and net loss per share if the Company had retroactively applied the fair value recognition provisions of SFAS 123.
           
    Three Months Ended
     
    April 3, 2005
     
Net loss:
       
As reported
  $ (2,119 )
Less: total share-based compensation expense determined under the fair value method, net of related tax effects
    (1,007 )
       
Pro forma
  $ (3,126 )
       
Net loss per share, basic and diluted:
       
 
As reported
  $ (0.10 )
       
 
Pro forma
  $ (0.14 )
       
      For purposes of pro forma disclosures, the estimated fair value of options is amortized to expense over the options’ vesting period. The weighted-average fair value of each option granted was estimated on the date of grant using the Black-Scholes option-pricing model with the following assumptions for the period ended April 3, 2005:
Lakes’ stock options:
         
    Three Months Ended
    April 3, 2005
     
Risk free interest rate
    4.3 %
Expected life
    10 years  
Expected dividend yield
     
Weighted-average fair value
  $ 7.89  
Annualized volatility
    30.06 %
WPTE stock options:
         
    Three Months Ended
    April 3, 2005
     
Risk free interest rate
    4.14 %
Expected life
    6 years  
Expected dividend yield
     
Weighted-average fair value
  $ 14.10  
Annualized volatility
    82.14 %
10. Earnings (Loss) Per Share:
      For all periods, basic earnings (loss) per share is calculated by dividing earnings (loss) by the weighted-average number of common shares outstanding. Diluted earnings per share for the three months ended April 2, 2006, reflects the effect of all potentially dilutive common shares outstanding by dividing net earnings by the weighted-average of all common and potentially dilutive shares outstanding. The effects of stock options and warrants have not been included in diluted loss per share for the three months ended April 3, 2005 as the effect would have been anti-dilutive as a result of losses.

16


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
11. Income Taxes:
      Management evaluated its probable ability to utilize deferred tax assets arising from net operating loss carry forwards, deferred tax assets and other ordinary items and determined that a valuation allowance was appropriate at April 2, 2006 and January 1, 2006. Management evaluated all evidence and determined net losses generated over the past three years outweighed the current positive evidence that the Company believes exists surrounding its ability to generate significant income from its long-term assets in Indian casino projects. Therefore the Company recorded a 100% valuation allowance against these items at April 2, 2006 and January 1, 2006. However, the Company has recognized a deferred tax asset related to capital losses during 2001 to 2005. The realization of these benefits is dependant on the generation of capital gains. The Company believes it will have sufficient capital gains in the foreseeable future to utilize these benefits due to significant appreciation in its investment in WPTE, which has a minimal cost basis. The Company owns approximately 12.5 million shares of WPTE common stock valued at approximately $79.7 million as of May 2, 2006, based upon the closing stock price as reported by the Nasdaq National Market on May 2, 2006 of $6.39.
      The Company is currently under examination for income and franchise tax matters. See Note 12 regarding the IRS Tax Audit and the Louisiana Department of Revenue Litigation Tax Matter.
12. Commitments and Contingencies:
Lakes’ Commitments and Contingencies
Operating lease
      The Company leases an airplane, under a non-cancelable operating lease. The airplane lease was amended on May 1, 2005, which allows for a base term of one year and two one-year renewal terms. Under the lease agreement, the Company has the option of renewing the lease, purchasing the airplane at amounts which range from approximately $5.2 million to $5.8 million or facilitating the sale of the aircraft at the end of each term included in the up to three-year lease term; however at the conclusion of the lease, the Company is required to either purchase the airplane or facilitate the sale of the airplane. The Company’s airplane lease contains a residual value guarantee of $5.2 million at the end of the three-year lease term.
IRS tax audit
      The Company is under audit by the Internal Revenue Service (“IRS”) for the fiscal years ended 2001 and 2000. The IRS is challenging the treatment of income categorized as a capital gain. If the Company is unsuccessful in sustaining its position the Company may be required to pay up to approximately $3.2 million plus accrued interest and penalties related to tax on ordinary income. The Company originally carried back capital losses to offset the capital gain. If the Company were to be unsuccessful in sustaining its capital gain position it could use the capital losses in the future to offset future capital gains, if any, prior to their expiration. Management believes that the final outcome of this matter is not likely to have a material adverse effect upon the Company’s future consolidated financial position or results of operations. However, it may have a significant effect on cash flows in the period of settlement.
Grand Casinos, Inc. settlement
      In connection with the establishment of Lakes as a public corporation on December 31, 1998, via a distribution of its common stock to the shareholders of Grand Casinos, the Company and Grand Casinos entered into an agreement governing the sharing or allocation of tax benefits accruing to Grand Casinos and certain affiliated companies of Grand Casinos. Lakes asserted claims against Grand Casinos for amounts to which Lakes believed it was entitled under the tax sharing agreement. On December 1, 2004, Lakes entered into a settlement agreement with Grand Casinos and its parent company, Park Place Entertainment Corporation (now known as “Harrah’s Entertainment, Inc.” or “Harrah’s”), pursuant to which Lakes

17


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
received $11.3 million in December 2004 in satisfaction of its prior claim and its future rights to the tax benefits that were the subject of the dispute. Lakes will be required to provide reimbursement for its share of the disallowed benefits. This settlement income was recorded as other income in the consolidated statement of earnings (loss) in fiscal 2005. Lakes has not recorded any tax related to the settlement payment of $11.3 million, as Lakes believes this settlement is not taxable to Lakes.
Tribal commitments
      The Company’s management contracts with its tribal partners require the Company to provide financial support related to project development, in the form of loans.
Tribal Casino Development Advances/ Commitments
As of April 2, 2006
                         
    Pre-Construction   Land Held for   Remaining
    Advances   Development   Commitment
             
    (In millions)
Jamul Tribe
  $ 17.8     $ 6.7     $  
Shingle Springs Band of Miwok Indians (“Shingle Springs Tribe”)
    39.6       8.8       1.6  
Pokagon Band
    47.3             25.7  
Iowa Tribe of Oklahoma (the “Iowa Tribe”)
    0.9       0.1       1.0  
Wholly-owned subsidiaries of the Pawnee Tribal Development Corporation (“Pawnee TDC” referred to collectively as the “Pawnee Nation”)
    4.5             0.2  
      In March 2006, the Jamul Tribe and Lakes entered into a development financing and services agreement (see Note 5).
      For the Pokagon Casino project, the Company has agreed to provide additional financing from its own funds if financing to the Pokagon Band at an interest rate not to exceed 13% is not available from third parties. If this occurs and Lakes is required to provide all financing, this would be an additional commitment of up to approximately $54 million. Based on discussions with prospective lenders the Company presently believes that third-party financing will be available for this project. However, there can be no assurance that third-party financing will be available at the time the project begins construction. Lakes is not required to fund these amounts; however, if Lakes discontinued the funding prior to fulfilling the obligation, Lakes will forfeit the rights under the management contract. Note that included in the $25.7 million remaining commitment is $1.8 million related to non-gaming land advances which Lakes does not expect to make.
      The Company will be obligated to pay an amount to an unrelated third party once the Pokagon Casino is open and Lakes is the manager of the casino. The amount is payable quarterly for five years and is only payable if Lakes is the manager of the casino. The payment is part of a settlement and release agreement associated with Lakes obtaining the management contract with the Pokagon Band. The maximum liability over the five-year period is approximately $11 million. The Company will also be obligated to pay approximately $3.3 million to a third party on behalf of the Pokagon Band; in accordance with the management contract which is payable once the casino opens over 24 months.
      Lakes may be required to provide a guarantee of tribal debt financing or otherwise provide support for the tribal obligations related to any of the projects. Any guarantees by Lakes or similar off-balance sheet liabilities will increase Lakes’ potential exposure in the event of a default by any of these tribes.

18


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
Legal proceedings
Slot machine litigation
      In 1994, William H. Poulos filed a class-action lawsuit in the United States District Court for the Middle District of Florida against various parties, including Lakes’ predecessor, Grand Casinos, and numerous other parties alleged to be casino operators or slot machine manufacturers. This lawsuit was followed by several additional lawsuits of the same nature against the same, as well as additional defendants, all of which were subsequently consolidated into a single class-action pending in the United States District Court for the District of Nevada. Following a court order dismissing all pending pleadings and allowing the plaintiffs to re-file a single complaint, a complaint has been filed containing substantially identical claims, alleging that the defendants fraudulently marketed and operated casino video poker machines and electronic slot machines, and asserting common law fraud and deceit, unjust enrichment and negligent misrepresentation and claims under the federal Racketeering-Influenced and Corrupt Organizations Act. Various motions were filed by the defendants seeking to have this new complaint dismissed or otherwise limited. In December 1997, the District Court, in general, ruled on all motions in favor of the plaintiffs. The plaintiffs then filed a motion seeking class certification and the defendants opposed it. In June 2002, the District Court entered an order denying class certification. On August 10, 2004, the Ninth Circuit Court of Appeals affirmed the District Court’s denial of class certification. On September 14, 2005, the United States District Court for the District of Nevada granted the defendants’ motions for summary judgment, and judgment was entered against the plaintiffs on that same day. The plaintiffs have appealed the judgment dismissing their claims to the Ninth Circuit Court of Appeals. The briefing of the appeal is scheduled to be completed by early June 2006.
      The Company has not recorded any liability for this matter, as currently an estimate of any possible loss cannot be made. Management currently believes the final outcome of this matter is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
El Dorado County, California litigation
      On January 3, 2003, El Dorado County filed an action in the Superior Court of the State of California, seeking to prevent the construction of a highway interchange that was approved by a California state agency. The action, which was consolidated with a similar action brought by Voices for Rural Living and others, does not seek relief directly against Lakes. However, the interchange is necessary to permit the construction of a casino to be developed and managed by Lakes through a joint venture. The casino will be owned by the Shingle Springs Tribe. The matter was tried to the court on August 22, 2003. On January 2, 2004, Judge Lloyd G. Connelly, Judge of the Superior Court of the State of California, issued his ruling on the matter denying the petition in all respects except one. As to the one exception, the court sought clarification as to whether the transportation conformity determination used to determine the significance of the air quality impact of the interchange operations considered the impact on attainment of the state ambient air quality standard for ozone. The California Department of Transportation (CalTrans) prepared and filed the clarification addendum sought by the court. Prior to the court’s determination of the adequacy of the clarification, El Dorado County and Voices for Rural Living appealed Judge Connelly’s ruling to the California Court of Appeals on all of the remaining issues.
      A ruling with respect to the addendum was issued June 21, 2004 by the Superior Court of the State of California, County of Sacramento. The ruling indicated that the addendum provided to the court by CalTrans did not provide a quantitative showing to satisfy the court’s earlier request for a clarification on meeting the state ambient ozone standard. The court recognized that the information provided by CalTrans does qualitatively show that the project may comply with the state standard, but concluded that a quantitative analysis is necessary even though the court recognized that the methodology for that analysis “is not readily apparent”. In addition, the ruling specifically stated, “Moreover, such methodology appears necessary for the CEQA analysis of transportation projects throughout the state, including transportation projects for which

19


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
respondents (i.e., CalTrans) have approval authority.” CalTrans, the Shingle Springs Tribe and Lakes responded to the court with a revised submission in August 2004. Representatives of the California Air Resources Board and the Sacramento Area Council of Governments filed declarations supporting the revised submission to the court. Opposition to that revised submission was filed, a hearing on the revised submission took place on August 20, 2004 and the court again found the revised submission of CalTrans, the Shingle Springs Tribe and Lakes to be inadequate. That ruling was separately appealed to the California Court of Appeals (the “Court”) and an oral argument for these appeals and the appeals of El Dorado County and Voices of Rural Living was held before the Court on August 29, 2005.
      The Court issued its decision on the appeals on November 8, 2005. The Court ruled in favor of CalTrans’ appeal, rejecting the El Dorado County’s argument that the transportation conformity analysis did not conform to state standards. The Court also rejected all but two of the legal claims asserted in the appeal by El Dorado County and Voices for Rural Living against the environmental impact report (“EIR”) prepared by CalTrans for the interchange that will connect Highway 50 to the Shingle Springs Rancheria. For the remaining two issues, the Court held that CalTrans must supplement its environmental analysis by adding some discussion to the air quality chapter to further explain the project’s contribution to overall vehicular emissions in the region, and that CalTrans also must evaluate whether a smaller casino and hotel would reduce environmental impacts. The Court acknowledged CalTrans lacks jurisdiction to require the Shingle Springs Tribe to develop a smaller casino, but nevertheless required some discussion of this alternative in the interchange EIR. On December 19, 2005, CalTrans filed a Petition for Review with the Supreme Court of the State of California, and on February 8, 2006 the Supreme Court denied the Petition for Review and ordered the Court of Appeals decision to be depublished. CalTrans is now preparing to comply with the Court of Appeals order.
      The Company has not recorded any liability for this matter as management currently believes that the Court’s rulings will ultimately allow the project to commence. However, there can be no assurance that the final outcome of this matter is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
Louisiana Department of Revenue litigation tax matter
      The Louisiana Department of Revenue maintains a position that Lakes owes additional Louisiana corporation income tax for the period ended January 3, 1999 and the tax years ended 1999 through 2001 and additional Louisiana corporation franchise tax for the tax years ended 2000 through 2002. This determination is the result of an audit of Louisiana tax returns filed by Lakes for the tax periods at issue and relates to the reporting of income earned by Lakes in connection with the managing of two Louisiana-based casinos. On December 20, 2004, the Secretary of the Department of Revenue of the State of Louisiana filed a petition to collect taxes in the amount of $8.6 million, excluding interest, against Lakes in the 19th Judicial District Court, East Baton Rouge Parish, Louisiana (Docket No. 527596, Section 23). In the petition to collect taxes the Department of Revenue of the state of Louisiana asserts that additional corporation income tax and corporation franchise tax are due by Lakes for the taxable periods set forth above. Lakes maintains that it has remitted the proper Louisiana corporation income tax and Louisiana corporation franchise tax for the taxable periods at issue. On February 14, 2005, Lakes filed an answer to the petition to collect taxes asserting all proper defenses and maintaining that no additional taxes are owed and that the petition to collect taxes should be dismissed. Management intends to vigorously contest this action by the Louisiana Department of Revenue. Lakes may be required to pay up to the $8.6 million assessment plus interest if Lakes is not successful in this matter. The Company has recorded a provision for its estimated settlement related to this examination including accrued interest, which is included as part of income taxes payable on the Company’s consolidated balance sheets.

20


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
WPTE litigation with TRV
      On September 19, 2005, WPTE filed suit in the California Superior Court seeking to keep the Travel Channel, LLC (“TRV”) from interfering with WPTE’s prospective contractual relationship with third party networks in connection with the sale of the broadcast rights to the Professional Poker Tour (“PPT”), and to clarify and enforce WPTE’s rights with respect to the World Poker Tour television episodes. Under WPTE’s existing agreement with TRV for the World Poker Tour program (the “WPT Agreements”), TRV is afforded the right to negotiate exclusively with WPTE with respect to certain types of programming developed by WPTE during a 60 day period. Pursuant to the WPT Agreements, WPTE submitted the PPT to TRV and began negotiations but failed to reach an agreement with TRV within the allotted negotiation window. Consequently, WPTE began discussions with other networks. While WPTE later revived its attempts to reach a deal with TRV after TRV’s exclusive bargaining window had ended, WPTE ultimately received an offer from ESPN. WPTE submitted this offer to TRV pursuant to TRV’s contractual last right to match the deal as specified under the WPT Agreements. Thereafter, TRV sent letters to WPTE and ESPN asserting, among other things, that WPTE was not entitled to complete a deal for the PPT with a third party. Following TRV’s letters, WPTE filed suit on September 19, 2005, alleging that TRV breached the WPT Agreements and interfered with WPTE’s prospective contractual relationship with ESPN, and seeking a judicial declaration of WPTE’s rights under the WPT Agreements to produce non-World Poker Tour branded programs covering poker tournaments. Subsequent to WPTE filing, ESPN withdrew its offer to WPTE to acquire the broadcast rights to the PPT. On September 22, 2005, TRV and Discovery Communications, Inc. filed an answer and cross-complaint and subsequently filed a motion for judgment on the pleadings and an “anti-SLAPP” motion, both of which were denied on November 10, 2005. On January 25, 2006, the parties settled the lawsuit and TRV entered into an agreement with WPTE to air Season One of the PPT television series (see Note 14).
Other litigation
      Lakes and its subsidiaries are involved in various other inquiries, administrative proceedings, and litigation relating to contracts and other matters arising in the normal course of business. While any proceeding or litigation has an element of uncertainty, management currently believes that the final outcome of these matters, including the matters discussed above, are not likely to have a material adverse effect upon the Company’s consolidated financial statements.
13. Segment Information:
      Lakes’ principal business is the development and management of gaming-related properties. Additionally, the Company is the majority owner of WPTE. Substantially all of Lakes’ and WPTE’s operations are conducted in the United States. Episodes of the World Poker Tour television series are distributed internationally by a third party distributor. Lakes’ segments reported below (in millions) are the segments of the Company for which separate financial information is available and for which operating results are evaluated by the chief operating decision-maker in deciding how to allocate resources and in assessing

21


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Notes to Unaudited Condensed Consolidated Financial Statements — (Continued)
performance. The amounts in Corporate and Eliminations below have not been allocated to the other segments because these costs are not easily allocable and to do so would not be practical.
                                 
    Industry Segments
     
    Casino   WPT   Corporate &   Total
    Projects   Enterprises, Inc.   Eliminations   Consolidated
                 
Total assets as of April 2, 2006
  $ 184.2     $ 51.5     $ 32.8     $ 268.5  
Total assets as of January 1, 2006
  $ 160.6     $ 46.4     $ 23.6     $ 230.6  
For the Three Months Ended April 2, 2006
                               
Revenue
  $ 0.1     $ 6.5     $     $ 6.6  
Earnings (loss) from operations
    15.4       (1.1 )     (4.1 )     10.2  
Depreciation expense
          0.2       0.1       0.3  
For the Three Months Ended April 3, 2005
                               
Revenue
  $     $ 4.1     $     $ 4.1  
Earnings (loss) from operations
    3.0       (1.9 )     (3.9 )     (2.8 )
Depreciation expense
                0.1       0.1  
14. Subsequent Events:
Regulatory approval of management agreement:
      In April 2006, Lakes received notification from the NIGC that it has approved Lakes management agreement with the Iowa Tribe to refurbish and manage the Cimarron Casino project on the Iowa Tribe’s land in Perkins, Oklahoma.
WPTE agreement with the Travel Channel:
      On May 1, 2006, the Travel Channel (TRV) notified WPTE that it had chosen to not exercise its option for Season II and subsequent seasons of the Professional Poker Tour (“PPT”). The PPT’s first season, which includes 24 two-hour episodes, has already been filmed and is scheduled to air on TRV beginning in July 2006. WPTE will immediately begin discussions to find a new broadcast partner for the PPT going forward.
WPTE amendment to lease agreement:
      On May 8, 2006, WPTE executed an Amendment to Lease agreement with RREEF America REIT II Corp. BBB (as successor in interest to Wilshire Courtyard L.L.C.) (“RREEF”), pursuant to which WPTE agreed to lease an additional 9,896 square feet of office space in WPTE’s current office facilities, pursuant to the same terms as WPTE’s current lease with RREEF, including the lease expiration date in June 2011. WPTE is obligated to pay $28,698 per month for the additional space, subject to annual upward adjustments so that in the final year of the lease, WPTE will be obligated to pay $32,932 per month. In addition, WPTE is obligated to increase the size of its letter of credit, as required by its current office space lease to cover certain of its obligations under the lease, to a total amount of $445,422, which is adjusted downward each year during the lease term until, by the last year of the lease term, the letter of credit will be in the amount of $50,069. Lease payments on the new space will begin in July 2006.

22


Table of Contents

ITEM 2. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS
Overview
      Lakes develops/finances Indian-owned casino properties and intends to manage such casinos when applicable regulatory approvals have been received and we have satisfied other contingencies. Lakes currently has development (which includes certain financing requirements) and management agreements with three separate tribes for one new casino development project in Michigan, two in California, and with two separate tribes in Oklahoma for five various casino projects. Lakes is also involved in other business activities including development of a non-Indian casino in Mississippi and the development of new table games for licensing to both Tribal and non-Tribal casinos. In addition, as of April 2, 2006, Lakes owned approximately 62% of WPT Enterprises, Inc (“WPTE”), a separate publicly held media and entertainment company principally engaged in the development, production and marketing of gaming themed televised programming, the licensing and sale of branded products and the sale of corporate sponsorships. Lakes’ consolidated financial statements include the results of operations of WPTE, and in recent periods, the majority of Lakes’ revenues have been derived from WPTE’s business.
      WPTE creates branded entertainment and consumer products driven by the development, production and marketing of televised programming based on gaming themes. WPTE’s World Poker Tour®, or WPT, television series, based on a series of high-stakes poker tournaments, airs in the U.S. on the Travel Channel and in more than 150 territories globally. WPTE has four operating units:
      WPT Studios, WPTE’s multi-media entertainment division, generates revenue through the domestic and international licensing of broadcast and telecast rights and through casino host fees. Since WPTE’s inception, the WPT Studios division has been responsible for approximately 75% of total revenue. WPTE licenses the WPT series to The Travel Channel, L.L.C. (TRV or Travel Channel) for telecast in the U.S. under an exclusive license agreement. WPTE also has license agreements for the distribution of WPTE’s World Poker Tour episodes in over 150 territories, for which WPTE receives license fees, net of WPTE’s agent’s sales fee and agreed upon sales and marketing expenses. In addition, WPTE recently signed a license agreement with TRV to telecast WPTE’s new Professional Poker Tourtm, or PPTtm, series, which is expected to begin airing in the third quarter of 2006. WPTE also collects annual host fees from the member casinos that host World Poker Tour events (WPTE’s member casinos).
      WPTE has entered into a series of agreements with TRV for the U.S. distribution of the World Poker Tour® (WPT) television series (the “WPT Agreements”). Since WPTE’s inception, fees from TRV under the WPT Agreements have been responsible for approximately 59% of WPTE’s total revenue. For each season covered by the WPT Agreements and related options, TRV has exclusive rights to exhibit the episodes in that season an unlimited number of times on its television network (or any other television network owned by Discovery Communications) in the U.S. for four years (three years for the episodes in Season One). WPTE has produced three complete seasons of the World Poker Tour series under the WPT Agreements, and Season Four is currently in production. On March 16, 2006, TRV exercised their option to order a 5th season of the WPT and has options to license the following two seasons (Seasons Six and Seven).

23


Table of Contents

      Under the WPT Agreements, TRV pays fixed license fees for each episode WPTE produces, which are payable at various times during the pre-production, production and post-production process and are recognized upon TRV’s receipt and acceptance of the completed episode. Television production costs related to WPT episodes are generally capitalized and charged to cost of revenues as revenues are recognized. Therefore, the timing and number of episodes involved in the various seasons of the series affect the timing of the revenues and expenses of the WPT Studios business. The following table describes the timing of Seasons One through Five of the World Poker Tour series, including the delivery and exhibition of the episodes each season:
                             
    Date of TRV   Number of        
    Agreement or   Episodes        
World Poker   Option for   (Including   Production Period and   Initial Telecast of
Tour Season   Season   Specials)   Delivery of Episodes to TRV   Episodes in Season
                 
Season One
    January 2003     15     February 2002 — June 2003       March 2003 — June 2003  
Season Two
    August 2003     25     July 2003 — June 2004       December 2003 — September 2004  
Season Three
    May 2004     21     May 2004 — April 2005       October 2004 — August 2005  
Season Four
    March 2005     21     May 2005 — April 2006       October 2005 — June 2006  
Season Five
    March 2006     22
(estimate)
    April 2006 — April 2007
(expected)
  August 2006 — June 2007
(expected)
 
      In January 2006, WPTE also entered into an agreement with TRV for the U.S. distribution of the PPT television series. Similar to the WPT Agreements and related options, TRV has exclusive rights to exhibit the PPT episodes in that season an unlimited number of times on its television network (or any other television network owned by the Discovery Channel) in the U.S. for four years. WPTE is currently in production on Season One of the PPT. Under WPTE’s agreement with TRV regarding PPT, TRV had options to license the following three seasons (Seasons Two through Four); however, TRV has advised WPTE that it does not intend to exercise the options with respect to Season Two and succeeding seasons. In accordance with WPTE’s accounting policy of not capitalizing production costs until a firm commitment for distribution is in place, WPTE expensed approximately $4.3 million of production expenses related to the Professional Poker Tour during fiscal 2005. Now that the agreement to telecast the PPT series has been completed, in the first quarter of 2006, WPTE began capitalizing additional expenses associated with the production of the PPT series that are to be expensed as episodes are delivered to the Travel Channel. During the first quarter of 2006, WPTE capitalized $0.4 million in PPT-related expenses and delivered one episode of the PPT series, resulting in cost of revenues of $67,000.
      Further, under the WPT and PPT Agreements, TRV has the right to receive a percentage of WPTE’s adjusted gross revenues from international television licenses, product licensing and publishing, merchandising and certain other sources, after specified minimum amounts are met. For the three months ended April 2, 2006, WPTE recognized $0.2 million of Travel Channel participation expense that was recorded in cost of revenues.
      WPT Consumer Products, WPTE’s branded consumer products division, generates revenues principally through royalties from the licensing of WPTE’s brand to companies seeking to use the World Poker Tour brand and logo in the retail sales of their consumer products. In addition, this business unit generates revenue from direct sales of company-produced branded merchandise. WPTE has generated significant revenues from existing licensees, including US Playing Card, Hands-On Mobile, and MDI. WPTE also has a number of licensees that are developing new licensed products including electronic casino-based poker related gaming machines from IGT, and interactive television games from Pixel Play.
      WPT Corporate Alliances, WPTE sponsorship and event management division, generates revenue through corporate sponsorship and management of live events. WPTE’s sponsorship program uses the professional sports model as a method to foster entitlement sponsorship opportunities and naming rights to major corporations. Anheuser-Busch has been the largest source of revenues through its sponsorship of Seasons Two and Three of the World Poker Tour series on TRV. During the third quarter of 2005, Anheuser-Busch announced that its sponsorship in Season Four will now feature its largest brand, Budweiser, as the official beer of the World Poker Tour on the Travel Channel.

24


Table of Contents

      WPT Online Gaming, WPTE’s online poker and casino gaming division, generates revenue through WPTE’s agreement with WagerWorks, Inc. (“WagerWorks”) pursuant to which WPTE granted to WagerWorks a license to utilize the WPT brand to create a WPT-branded online gaming website, WPTonline.com, which features an online poker room and an online casino with a broad selection of slots and table games. In exchange for the license to WagerWorks of WPTE’s brand, WagerWorks shares with WPTE a percentage of all net revenue it collects from the operation of the online poker room and online casino. Although any Internet user can access WPTonline.com via the World Wide Web, the website does not permit bets to be made from players in the U.S. and other restricted jurisdictions. WPTonline.com generated approximately $0.9 million in revenue for the three months ended April 2, 2006, compared to costs of revenues of approximately $0.4 million.
Financial Overview
      In the first quarter of the fiscal year ending December 31, 2006 (“2006”) and in the first quarter of the fiscal year ended January 1, 2006 (“2005”), substantially all of Lakes’ consolidated revenues were derived from the WPTE business, mainly from license fees for domestic and international telecast of World Poker Tour television episodes and product licensing fees associated with the World Poker Tour brand and logo. Domestic telecast license fees have depended on the number of episodes delivered in a particular period. Revenues from other parts of the WPTE business are relatively small but continue to grow.
Results of Operations
Three Months Ended April 2, 2006 Compared to the Three Months Ended April 3, 2005
Revenues
      Total revenues increased by $2.5 million (62%) during the three months ended April 2, 2006 compared to the three months ended April 3, 2005. Domestic television licensee fees increased $1.1 million (55%) in the first quarter of 2006 compared to the same period in 2005. The increase was primarily a result of the delivery in the first quarter of fiscal 2006 of six episodes of Season IV of the WPT television series versus the delivery of five episodes of Season III in the same period in 2005, and the delivery of one episode of Season I of the PPT television series in the first quarter versus no episodes of the PPT delivered in the same period in 2005. Product licensing revenues decreased $0.4 million (34%) in the first quarter of 2006 compared to the same period in 2005. The decrease was due, in part, to lower license revenues from WPTE’s lottery game partner, MDI, which were partially offset by increased mobile gaming sales from Hands-On Mobile (formerly Mforma). International television licensee fees increased $0.5 million (116%) due to increased distribution agreements in the first quarter of 2006 compared to the same period in 2005. Specifically WPTE has expanded into additional territories and have agreements now for WPT Seasons One, Two and Three. Online gaming, host fees, sponsorship and merchandise revenues also increased $1.1 million (179%) in the first quarter of 2006 compared to the same period in 2005, of which $0.9 million is due to the online gaming revenue during 2006, which had not yet been launched during the first quarter of 2005.
Costs, expenses and gross margins
      Production costs. Production costs are associated with WPTE operations, which decreased by approximately $0.8 million (24%) in the first quarter of 2006 compared to the same period in 2005. The decrease was primarily due to lower recognized PPT production costs, as WPTE began capitalizing these costs in the first quarter of fiscal 2006 versus previously expensing them. During the quarter, costs of revenues associated with the PPT were $0.1 million compared to $1.4 million in the prior year quarter. The favorable variance was offset by $0.4 million in online gaming cost of revenues during the first quarter of 2006 compared to $0 in the same period in the prior year. Additionally, a decrease of $0.2 million related to non-cash compensation expense related to consultant stock options contributed to the favorable variance. Overall gross margins were 63% in the first quarter of 2006 compared to 22% in the first quarter of 2005. Domestic television licensing margins were 44% in the first quarter compared to negative 60% in the same period of 2005 primarily due to

25


Table of Contents

the expensing of PPT production costs in 2005. Increased revenues from international television distribution and our online gaming operations helped contribute to the higher overall gross margins in 2006.
      Selling and administrative expenses. Selling, general and administrative expenses were $9.2 million for the first quarter of 2006, compared to $6.5 million for the first quarter of 2005. The increase of approximately $2.7 million was primarily due to the adoption of Statement of Financial Accounting Standards No. 123 (revised 2004), Share-Based Payment, (“SFAS 123(R)”) which requires the measurement and recognition of compensation expense for all share-based payment awards made to employees and directors including employee and director stock options and stock purchases based on estimated fair values. For the three months ended April 2, 2006, share-based compensation expense recognized under SFAS 123(R) related to employee and director stock options of approximately $2.2 million, of which approximately $1.5 million related to WPTE and $0.7 million related to Lakes. There was no share-based compensation expense related to employee and director stock options and stock purchases recognized during the three months ended April 3, 2005. The remaining increase in selling, general and administrative expenses in the first quarter of 2006 as compared to the first quarter of 2005 was due primarily to additional headcount related costs.
Net unrealized gains on notes receivable
      Net unrealized gains on notes receivable were $15.5 million and $2.8 million for the three months ended April 2, 2006 and April 3, 2005, respectively, related to the adjustment to estimated fair value of the Company’s notes receivable from Indian tribes. These fair value calculations are determined based on current assumptions related to the projects and management’s evaluation of critical milestones as discussed below under “Critical Accounting Policies and Estimates — Accounting for long-term assets related to Indian casino projects.” Unrealized gains of approximately $12.9 million related primarily to increased probability of opening related to the casino development projects with the Pokagon Band in New Buffalo, Michigan and with the Jamul Tribe near San Diego, California as well as the increased interest rate charged on the notes with the Jamul Tribe as a result of the new development financing and services agreement entered into on March 30, 2006 with the Jamul Tribe. Gains of approximately $2.6 million related to the settlement with the Kickapoo Tribe (see below discussion under — “Liquidity and Capital Resources”).
Other income
      Other income was $5.5 million and $0.4 million for the three months ended April 2, 2006 and April 3, 2005, respectively. WPTE recognized $5.7 million in a gain on sale of investment in the first quarter of 2006, relating to the sale of a portion of WPTE’s stock in PokerTek, which went public in October 2005.
Taxes
      The Company recorded a tax provision of $2.7 million and $0.4 million for the three months ended April 2, 2006 and April 3, 2005, respectively. WPTE recorded a provision of $1.3 million for the three months ended April 2, 2006. WPTE’s provision for income taxes is due to positive taxable income that WPTE expects to generate which would allow WPTE to realize its net operating loss carryforward from 2005. A valuation allowance was previously recorded by WPTE for the net deferred tax asset related to WPTE’s 2005 net operating loss carryforward. During the three months ended April 2, 2006, Lakes reversed approximately $1.0 million of the capital loss related to the Kickapoo Tribe which was reflected as a deferred tax asset, as a result of the settlement. Lakes has recorded a deferred tax asset related to capital losses in the amount of approximately $5.9 million. The realization of these benefits is dependent on the generation of capital gains. The Company believes it will have sufficient capital gains in the future to utilize these benefits. The Company owns approximately 12.5 million shares of WPTE common stock with a minimal cost basis and the capital gain from the sale of a portion of these shares could be used against the capital losses. Additionally, in accordance with Statement of Financial Accounting Standards No. 109, Accounting for Income Taxes (SFAS 109), Lakes evaluated the ability to utilize deferred tax assets arising from net operating loss carry forwards, net deferred tax assets relating to Lakes’ accounting for advances made to Indian tribes and other ordinary items and determined that a valuation allowance was appropriate at April 2, 2006 and January 1, 2006. Lakes evaluated all evidence and determined the negative evidence relating to net losses generated over

26


Table of Contents

the past four years outweighed the current positive evidence that the Company believes exists surrounding its ability to generate significant income from its long-term assets related to Indian casino projects. The Company recorded a 100% valuation allowance against these items at April 2, 2006 and January 1, 2006 based upon the above factors.
Minority interest
      The minority interest portion of WPTE’s earnings was $1.4 million for the three months ended April 2, 2006 compared to losses of $0.6 million for the three months ended April 3, 2005. The amount represents the minority interest portion of WPTE net earnings (losses) of $3.6 million and ($1.6) million for the three months ended April 2, 2006 and April 3, 2005, respectively.
Liquidity and Capital Resources
      At April 2, 2006, Lakes’ unaudited condensed consolidated balance sheet included unrestricted cash and cash equivalents and short-term investment balances of $55.2 million, comprised of Lakes’ cash of $15.6 million, WPTE cash of $3.7 million and WPTE short-term investments of $35.9 million. WPTE cash and investments will not be used in Lakes’ business. As of April 2, 2006, Lakes’ has had minimal operating revenues from casino operations since the expiration of the management contract with the Coushatta Tribe in January 2002.
      Lakes entered into a Settlement Agreement with the Kickapoo Tribe pursuant to which Lakes and the Kickapoo Tribe resolved all outstanding issues relating to the parties’ business relationship that was terminated in November 2005. During fiscal 2005, Lakes recorded a loss of approximately $6.3 million as a result of the terminated business relationship. Pursuant to the Settlement Agreement, during April 2006, Lakes received a cash payment of approximately $2.6 million as reimbursement for payments made directly by Lakes to vendors on behalf of the Kickapoo Tribe and the Kickapoo Tribe agreed to pay $0.6 million into an escrow to be released to Lakes at such time as Lakes transfers title to certain land owned by Lakes to the Kickapoo Tribe. The Company and the Kickapoo Tribe have agreed that title will transfer only after the Kickapoo Tribe assumes, settles or pays certain accounts payable to vendors related to the Kickapoo Tribe’s casino that remain on Lakes’ books, and once Lakes receives full releases for any liability thereto. As a result of the $2.6 million payment, Lakes revalued the note receivable from the Kickapoo Tribe at $2.6 million as of April 2, 2006, and a gain of that amount was recognized in the first quarter of 2006. The land transfer and related release of liabilities will be recognized in the period they occur. When the releases are received from the vendors the Company will recognize a gain. The Company does not have an estimate of when or if this will occur.
      Also during the first quarter ended April 2, 2006, Lakes settled a short-swing profit matter, which resulted in a payment to Lakes of approximately $2.8 million. This settlement did not impact Lakes’ earnings.
      On February 15, 2006 Lakes closed on a $50 million financing facility with an affiliate of Prentice Capital Management, LP. An initial draw of $25 million was made under the facility, another $10 million is immediately available under the facility and the remaining $15 million can be drawn in $5 million increments subject to the satisfaction of certain conditions. All amounts drawn against the facility will be repayable three years from the date of closing. Approximately $10.2 million of the initial draw was used to repay in full our December 16, 2005, loan from the Lyle Berman Family Partnership (the “Partnership”). As a result of repaying the Partnership loan prior to February 28, 2006, the two million common stock purchase warrants previously issued to the Partnership were terminated. Lakes plans to continue pursuing other financing alternatives to fund its operational and development needs, and the Company believes the assets of Lakes provide sufficient collateral to obtain the necessary financing.
      Our agreements with our tribal partners require that we provide certain financing for project development in the form of loans. These loans are interest bearing; however, the loans and related interest are not due until the casino is built and has established profitable operations. In the event that the casinos are not built, our only recourse is to attempt to liquidate assets of the development, if any, excluding any land in trust. Approximately $10.9 million of the loans due from the Pokagon Band were used by the Pokagon Band to purchase the project

27


Table of Contents

site. The Company’s first deed of trust against this property was relinquished when the Bureau of Indian Affairs (“BIA”) placed the land into trust in January 2006. The Company holds a deed of trust against related non-gaming land which has a cost basis of approximately $13.2 million.
      We currently believe that our casino development projects currently in progress and included in the table below will be constructed and achieve profitable operations; however, no assurance can be made that this will occur. If this does not occur, it is likely that Lakes would incur substantial or complete losses on its notes receivable from Indian tribes and related intangible assets associated with the acquisition of the management contracts. In addition, if Lakes’ current casino development projects are not completed or, upon completion, fail to successfully compete in the highly competitive market for gaming activities, Lakes may lack the funds to compete for and develop future gaming or other business opportunities and Lakes’ business could be adversely affected to the extent that it may be forced to cease its operations entirely.
      Following is a table summarizing remaining contractual obligations as of April 2, 2006 (in millions):
                                           
    Payment Due by Period
     
        Less Than       More Than
Contractual Obligations   Total   1 Year   1-3 Years   3-5 Years   5 Years
                     
Remaining Casino Development Commitment(1)(4)
                                       
 
Jamul Tribe(2)
  $     $     $     $     $  
 
Shingle Springs Tribe
    1.6       1.6                    
 
Pokagon Band(3)
    25.7       23.4       0.5              
 
Pawnee Nation — Travel Plaza
    0.2       0.2                    
 
Iowa Tribe of Oklahoma — New Casino
    1.0       1.0                          
Employee obligations(5)
    2.4       0.9       1.5              
Operating leases(6)
    1.4       0.7       0.7              
Prentice financing facility(7)
    25.0             25.0              
WPTE operating leases(8)
    2.6       0.5       1.0       1.0       0.1  
WPTE purchase obligations(9)
    0.1       0.1                    
WPTE employee obligations(10)
    0.4       0.4                    
                               
    $ 60.4     $ 28.8     $ 28.7     $ 1.0     $ 0.1  
                               
 
  (1)  Lakes will require additional capital through public or private financings or the sale of some or all of Lakes’ shares of WPTE to meet the remaining casino development commitments. See the table below detailing tribal casino development commitments.
 
  (2)  Effective March 30, 2006, Lakes entered into a development financing and services agreement with the Jamul Indian Village (“Jamul Tribe”). As part of the agreement, Lakes will use its best efforts to obtain financing from which advances of up to $350 million will be made to the Jamul Tribe to pay for the design and construction of the project. However, there can be no assurance that third party financing will be available, and if Lakes is unable to obtain the appropriate amount of financing for this project, the project may not be completed as planned. This agreement will help assist the Jamul Tribe in developing a casino with related amenities/services (“Jamul Casino”) on its existing six acre reservation which the Jamul Tribe will manage. Under the new agreement, Lakes will receive a flat fee of $15 million for its development design services, and a flat fee of $15 million for its construction oversight services, payable evenly over the first five years after the opening date of the Jamul Casino. In connection with Lakes’ financing of the Jamul Casino, the Jamul Tribe will pay interest over a ten year period on sums advanced by Lakes equal to the rate charged to Lakes for obtaining the funds necessary plus 5%. Amounts previously advanced by Lakes to the Jamul Tribe in connection with the Jamul Tribe’s proposed casino resort are included in the development financing and services agreement financing amount.
 
  (3)  For the Pokagon Casino project, the Company has agreed to provide additional financing from its own funds if financing at an interest rate not to exceed 13% is not available from third parties. If this occurs

28


Table of Contents

  and Lakes is required to provide all financing, this would be an additional commitment of up to approximately $54 million. Currently, it appears that third party financing will be available for this project. However, there can be no assurance that third party financing will be available and that Lakes will not be required to provide this additional financing. The Company will be obligated to pay an amount to an unrelated third party once the Pokagon Casino is open and Lakes is the manager of the casino. The amount is payable quarterly for five years and is only payable if Lakes is the manager of the casino. The payment is part of a settlement and release agreement associated with Lakes obtaining the management contract with the Pokagon Band. The maximum liability over the five-year period is approximately $11 million. The Company will also be obligated to pay approximately $3.3 million to a third party on behalf of the Pokagon Band; in accordance with the management contract which is payable once the casino opens over 24 months. Note that included in the $25.7 million remaining commitment is $1.8 million related to non-gaming land advances which Lakes does not expect to make.

  (4)  Lakes may be required to provide a guarantee of tribal debt financing or otherwise provide support for the tribal obligations related to any of the projects. Any guarantees by Lakes or similar off-balance sheet liabilities will increase Lakes’ potential exposure in the event of a default by any of these tribes. No such guarantees or similar off-balance sheet liabilities existed at April 2, 2006.
 
  (5)  Employee obligations include the base salaries payable to Lyle Berman and Timothy Cope under their respective employment agreements.
 
  (6)  The Company leases an airplane, under a non-cancelable operating lease that expires on May 1, 2008.
 
  (7)  On February 15, 2006, Lakes closed on a $50 million financing facility. Any funds drawn on the facility bear interest at the rate of 12% per annum, interest payable in arrears monthly, subject to adjustment based on the value of the collateral, and are due and payable in full on the third anniversary of the closing date (See Note 4).
 
  (8)  Operating lease obligations include rent payments on WPTE corporate office space. Monthly lease payments began at approximately $38,000 and escalate to approximately $45,000 over the six-year lease term. The amount set forth in the table above assumes monthly lease payments through May 2011.
 
  (9)  Purchase obligations include contractual obligations related to the establishment of WPTE’s Internet gaming site.
(10)  Employee obligations include the base salaries payable to Steven Lipscomb and Robyn Moder under their respective employment agreements.

29


Table of Contents

Casino Development Advances/ Commitments
As of April 2, 2006
                                                         
                            Commitments
                            in Excess of
                        Lakes’   Available
                Total   Remaining   Cash and   Cash and
    Pre-Construction   Land Held for   Total   Funding   Funding   Short-Term   Short-Term
    Advances   Development   Funded   Commitment   Commitment   Investments   Investments
                             
    (In millions)
Jamul Tribe(a)
  $ 17.8     $ 6.7     $ 24.5     $     $                  
Shingle Springs Tribe(b)
    39.6       8.8       48.4       50.0       1.6                  
Pokagon Band(c)
    47.3             47.3       73.0       25.7                  
Iowa Tribe(d)
    0.9       0.1       1.0       2.0       1.0                  
Pawnee Nation — Travel Plaza(e)
    0.8             0.8       1.0       0.2                  
Pawnee Nation — Chilocco(f)
    3.3             3.3       2.0                        
Pawnee Nation — Trading Post(g)
    0.4             0.4       0.4                        
Kickapoo Tribe(h)
    2.5       0.7       3.2       2.0                          
                                           
    $ 112.6     $ 16.3     $ 128.9     $ 130.4     $ 28.5     $ 15.6     $ 12.9  
                                           
 
(a) Effective March 30, 2006, Lakes entered into a development financing and services agreement with the Jamul Tribe. As part of the agreement, Lakes will use its best efforts to obtain financing from which advances of up to $350 million will be made to the Jamul Tribe to pay for the design and construction of the project. However, there can be no assurance that third party financing will be available, and if Lakes is unable to obtain the appropriate amount of financing for this project, the project may not be completed as planned. This agreement will help assist the Jamul Tribe in developing a casino with related amenities/services on its existing six acre reservation which the Jamul Tribe will manage. Under the new agreement, Lakes will receive a flat fee of $15 million for its development design services, and a flat fee of $15 million for its construction oversight services, payable evenly over the first five years after the opening date of the Jamul Casino. In connection with Lakes’ financing of the Jamul Casino, the Jamul Tribe will pay interest over a ten year period on sums advanced by Lakes equal to the rate charged to Lakes for obtaining the funds necessary plus 5%. Amounts previously advanced by Lakes to the Jamul Tribe in connection with the Jamul Tribe’s proposed casino resort are included in the development financing and services agreement financing amount.
 
(b) Lakes plans to continue making advances on the remaining commitment to the Shingle Springs Tribe on a monthly basis until the casino opens.
 
(c) Lakes is currently contractually obligated to make advances of $25.7 million of which $22.3 million is planned to be advanced prior to the start of construction which could begin as early as mid-2006. Note that included in the $25.7 million remaining commitment is $1.8 million related to non-gaming land advances which Lakes does not expect to make.
 
(d) In addition to the information in the above table, additional amounts are expected to be advanced to the Iowa Tribe of Oklahoma (the “Iowa Tribe”) for the new casino project based upon an approved budget yet to be finalized.
 
(e) Lakes made a commitment of $1.0 million to the Pawnee Nation related to the Travel Plaza project based upon an approved budget.
 
(f) In addition to the information in the above table, Lakes has been advancing funds to the Pawnee Nation related to the Chilocco project. The funding amount is based upon an approved budget, yet to be finalized. Additional amounts are expected to be advanced to the Pawnee Nation for the new casino project and Travel Plaza project based upon an approved budget yet to be finalized.

30


Table of Contents

(g) Lakes made a commitment of $1.1 million to the Pawnee Nation related to the Trading Post project based upon an approved budget. This project has been completed and Lakes does not expect to make further advances under this commitment.
 
(h) See discussion below under “Description of each Indian casino project and evaluation of critical milestones — Kickapoo Tribe”.
      The Company has incurred cumulative development costs of approximately $6.4 million relating to the non-Indian casino it is developing in Vicksburg, Mississippi. These costs are included in property and equipment as construction in progress. The Company is working toward obtaining all necessary approvals to move forward with this project. Lakes does not expect to have access to the capital necessary to make this a viable project for the Company until such time that one of its other casino projects is open and therefore, this is now planned to be a 2007 project.
      During the remainder of fiscal 2006, Lakes’ corporate costs, excluding WPTE which is not expected to require additional capital from Lakes, will be approximately $14 million, which includes $3.0 million of interest related to the financing facility entered into on February 15, 2006. Development project-related costs are expected to be approximately $45 million during the remainder of fiscal 2006 and include approximately $24 million related to the Pokagon project as construction is estimated to begin in mid 2006. This $24 million includes a $1.0 non-refundable payment made in April 2006 to the Pokagon Band scholarship fund upon approval of the management contract between Lakes and the Pokagon Band. Lakes’ cash balance, excluding WPTE cash, was approximately $15.6 million as of April 2, 2006. Additionally, the Company may be required to pay taxes up to approximately $12 million plus interest and penalties in fiscal 2006 related to two tax matters. Lakes will require additional capital through public or private financings or the sale of some or all of the Company’s shares of WPTE to meet operating expenses and development project-related costs during fiscal 2006 and the Company is currently considering various financing alternatives. The Company believes the assets of Lakes provide sufficient collateral to obtain the necessary financing. The assets of Lakes include approximately 12.5 million common shares of WPTE that have an estimated fair value of $79.7 million as of May 2, 2006, based on the public trading price, on that date, which may not be indicative of what Lakes could realize in a sale of its shares. The Company believes the shares of WPTE could be the source or part of the collateral for the additional financing.
      Our major use of cash over the past three years has been pre-construction financing provided to our tribal partners. Lakes also anticipates that it will incur additional pre-construction costs which will require the Company to obtain additional sources of financing. These development costs do not include construction-related costs that will be incurred when any of the projects begin construction. Management is pursuing other sources of financing. If the financing is in the form of equity financing it will be dilutive to Lakes’ shareholders, and any debt financing may involve additional restrictive covenants. An inability to raise such funds when needed might require Lakes to delay, scale back or eliminate some of its expansion and development goals.
      In addition, the construction of the Company’s Indian casino projects may depend on the ability of the tribes to obtain financing for the projects. If such financing cannot be obtained on acceptable terms, it may not be possible to complete these projects, which could have a material adverse effect on Lakes’ results of operations and financial condition. In order to assist the tribes, Lakes may be required to guarantee the tribes’ debt financing or otherwise provide support for the tribes’ obligations. Guarantees by Lakes, if any, will increase Lakes’ potential exposure in the event of a default by any of these tribes.
      For the Pokagon Casino project, the Company has agreed to finance all phases of the project entirely from its own funds if financing at an interest rate of 13% or less is not available from the capital markets. If this occurs and Lakes is required to provide all financing, this would be an additional commitment of up to approximately $54 million. Currently, management believes that third party financing will be available for this project. However, there can be no assurance third party financing will be available and that Lakes will not be required to provide this additional financing.

31


Table of Contents

Critical Accounting Policies and Estimates
      This Management’s Discussion and Analysis of Financial Condition and Results of Operations discusses our consolidated financial statements, which have been prepared in accordance with U.S. generally accepted accounting principles. The preparation of these financial statements requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities and the disclosure of contingent assets and liabilities at the balance sheet date and reported amounts of revenue and expenses during the reporting period. On an ongoing basis, we evaluate our estimates and judgments, including those related to revenue recognition, long-term assets related to Indian casino projects, deferred television costs, investments, litigation costs and income taxes. We base our estimates and judgments on historical experience and on various other factors that are reasonable under the circumstances, the results of which form the basis for making judgments about the carrying values of assets and liabilities that are not readily apparent from other sources. Actual results may differ from these estimates under different assumptions or conditions.
      We believe the following critical accounting policies involve the more significant judgments and estimates used in the preparation of our unaudited condensed consolidated financial statements.
      Revenue recognition: Revenue from the management of Indian-owned casino gaming facilities is recognized in accordance with our policy described below under the caption “Accounting for long-term assets related to Indian casino projects.”
      Revenue from the domestic and international distribution of WPTE’s television series is recognized as earned under the following criteria established by the American Institute of Certified Public Accountants Statement of Position (SOP) No. 00-2, Accounting by Producers or Distributors of Films:
  •  Persuasive evidence of an arrangement exists;
 
  •  The show/episode is complete, and in accordance with the terms of the arrangement, has been delivered or is available for immediate and unconditional delivery;
 
  •  The license period has begun and the customer can begin its exploitation, exhibition or sale;
 
  •  The seller’s price to the buyer is fixed and determinable; and
 
  •  Collectibility is reasonably assured.
      In accordance with the terms of the WPT and PPT agreements, WPTE recognizes domestic television license revenues upon the receipt and acceptance of completed episodes. However, due to restrictions and practical limitations applicable to WPTE’s operating relationships with foreign networks, WPTE currently does not consider collectibility of international television license revenues to be reasonably assured until the international distributor has received payment, and accordingly, WPTE does not recognize such revenue until that time. Additionally, WPTE presents international distribution license fee revenues net of the distributor’s fees, as the distributor is the primary obligor in the transaction with the ultimate customer pursuant to Emerging Issues Task Force (EITF) 99-19, Reporting Revenue Gross as a Principal versus Net as an Agent (“EITF 99-9”).
      Product licensing revenues are recognized when the underlying royalties from the sales of the related products are earned. WPTE recognizes minimum revenue guarantees ratably over the term of the license or as earned royalties based on actual sales of the related products, if greater. WPTE presents product licensing fees gross of licensing commissions, which are recorded as selling and administrative expenses as WPTE is the primary obligor in the transaction with the ultimate customer pursuant to EITF 99-19.
      Online gaming revenues are recognized monthly based on detailed statements received from WagerWorks, WPTE’s online gaming partner, for online poker and casino activity throughout the previous month. In accordance with EITF 99-19, WPTE presents online gaming revenues gross of WagerWorks costs, including WagerWorks management fee, royalties, credit card processing and chargebacks that are recorded as cost of revenues, since WPTE has the ability to adjust price and specifications of the online gaming site, WPTE bears the majority of the credit risk and WPTE is responsible for the sales and marketing of the gaming site. The Company includes certain promotional expenses related to free bets and deposit bonuses

32


Table of Contents

along with customer charge backs as deductions of revenue. All other promotional expenses are generally recorded as sales and marketing expenses.
      Event hosting fees are paid by host casinos for the privilege of hosting the events and are recognized as the episodes that feature the host casino are aired, and sponsorship revenues are recognized as the episodes that feature the sponsor are aired. Licensing advances and guaranteed payments collected, but not yet earned, by WPTE, as well as casino host fees and sponsorship receipts collected prior to the airing of episodes, are classified as deferred revenue in the accompanying balance sheets.
      Deferred television costs: WPTE accounts for deferred television costs in accordance with FASB Statement of Position No. 00-2 (“SOP 00-2”). Deferred television costs include capitalizable direct costs, production overhead and development costs related to episodes of the WPT, and are stated at the lower of cost or net realizable value based on anticipated revenue. WPTE has not currently anticipated any revenues in excess of those subject to existing contractual relationships because WPTE has insufficient operating history to enable such anticipation. In January 2006, WPTE signed an agreement for the PPT with Discovery Communications, Inc, the parent company of the Travel Channel, therefore, on-going PPT television costs will be capitalized beginning in the first quarter of fiscal 2006 and will be expensed as episodes are delivered to the Travel Channel. Marketing, distribution and general and administrative costs are expensed as incurred. Capitalized television production costs for each episode are expensed as revenues are recognized upon delivery and acceptance by the Travel Channel of the completed episode. WPTE management currently estimates that 100% of capitalized television costs at April 2, 2006 are expected to be expensed by the end of fiscal 2006.
      Investment: Until October 2005, WPTE had an investment (consisting of a 15% equity interest carried at its nominal cost basis) in and a loan receivable from PokerTek, a company formed in August 2003 to develop and market the PokerPro system, an electronic poker table designed to provide a fully automated poker room environment, to tribal casinos, commercial casinos and card clubs. As a result of PokerTek’s initial public offering in October 2005, WPTE’s ownership interest was diluted to 11.7%. As of April 2, 2006, WPTE’s Executive Chairman of the Board, Lyle Berman, along with his son Bradley Berman, who also sits on the WPTE’s Board of Directors, have personal investments in PokerTek and, hold a combined ownership of approximately 9% in PokerTek. Lyle Berman also serves as Chairman of the Board of PokerTek and received options to purchase 200,000 shares of common stock in that company.
      On January 20, 2006, WPTE entered into an agreement to sell 630,000 shares of PokerTek’s common stock held by WPTE, at a price per share of $9.03. WPTE closed the transaction on February 28, 2006, and received net cash proceeds of approximately $5.7 million. As a result, WPTE currently owns 450,000 shares, or a 4.75% ownership interest in PokerTek.
      WPTE accounted for this investment as “available for sale” pursuant to SFAS 115, Accounting for Certain Investments in Debt and Equity Securities, and adjusted the investment to fair market value of $5.4 million at April 2, 2006, with the change in fair market value accounted for as a component of other comprehensive income in the statement of stockholders’ equity.
      Share-Based Compensation Expense: On January 2, 2006, the Company adopted Statement of Financial Accounting Standards No. 123 (revised 2004), Share-Based Payment, (“SFAS 123(R)”) which requires the measurement and recognition of compensation expense for all share-based payment awards made to employees and directors including employee and director stock options and employee and director stock purchases based on estimated fair values. In March 2005, the SEC issued Staff Accounting Bulletin No. 107 (“SAB 107”) relating to SFAS 123(R). The Company has applied certain provisions of SAB 107 in its adoption of SFAS 123(R).
      SFAS 123(R) requires companies to estimate the fair value of share-based payment awards on the date of grant using an option-pricing model. The value of the portion of the award that is ultimately expected to vest is recognized as expense over the requisite service periods in the Company’s consolidated statement of earnings (loss). SFAS 123(R) supersedes the Company’s previous accounting under the provisions of SFAS No. 123, Accounting for Stock-Based Compensation (“SFAS 123”). As permitted by SFAS 123, the Company measured compensation cost for options granted prior to January 2, 2006, in accordance with

33


Table of Contents

Accounting Principles Board Opinion (APB) No. 25, Accounting for Stock Issued to Employees and related interpretations. Accordingly, no accounting recognition is given to stock options granted at fair market value until they are exercised. Upon exercise, net proceeds, including tax benefits realized, are credited to equity.
      The Company adopted SFAS 123(R) using the modified prospective transition method, which requires the application of the accounting standard as of January 2, 2006, the first day of the Company’s fiscal year 2006. In accordance with the modified prospective transition method, the Company’s consolidated financial statements for prior periods have not been restated to reflect, and do not include, the impact of SFAS 123(R). Share-based compensation expense recognized during the period is based on the value of the portion of share-based payment awards that is ultimately expected to vest during the period. Share-based compensation expense recognized in the Company’s unaudited condensed consolidated statement of earnings was approximately $2.2 million for the three months ended April 2, 2006 and included both compensation expense for share-based payment awards granted prior to, but not yet vested as of January 1, 2006 based on the grant date fair value estimated in accordance with the pro forma provisions of SFAS No. 123 and compensation expense for the share-based payment awards granted subsequent to January 1, 2006. There was no share-based compensation expense related to employee and director stock options and employee and director stock purchases recognized during the three months ended April 3, 2005.
      Upon adoption of SFAS 123(R), the Company also continued the use of the Black-Scholes option pricing method that it had used to establish fair value of options granted prior to January 2, 2006. The Company’s determination of fair value of share-based payment awards on the date of grant using an option-pricing model is affected by the Company’s stock price as well as assumptions regarding a number of highly complex and subjective variables. These variables include, but are not limited to the Company’s expected stock price volatility, and actual and projected employee stock option exercise behaviors. Any changes in these assumptions may materially affect the estimated fair value of the share-based award.
      In November 2005, the FASB issued FSP FAS 123(R)-3, “Transition Election Related to Accounting for the Tax Effects of Share-Based Payment Awards” (“FSP 123R-3”). FSP 123R-3 provides a simplified alternative method to calculate the beginning pool of excess tax benefits against which excess future deferred tax assets (that result when the compensation cost recognized for an award exceeds the ultimate tax deduction) could be written off under Statement 123R. The guidance in FSP 123R-3 was effective on November 10, 2005. We may make a one-time election to adopt the transition method described in FSP 123R-3 before the end of our fiscal year ending December 31, 2006. We are currently evaluating the available transition alternatives of FSP 123R-3.
Accounting for long-term assets related to Indian casino projects:
Notes Receivable:
      Lakes is involved as the exclusive developer and manager or consultant of Indian-owned casino projects. The Company has formal procedures governing its evaluation of opportunities for potential development projects that it follows before entering into agreements to provide financial support for the development of these properties. Lakes determines that there is probable future economic benefit prior to recording any asset related to the Indian casino project. No asset related to an Indian casino project is recognized unless it is considered probable that the project will be built and result in an economic benefit to Lakes sufficient to recover the asset. Lakes initially evaluates the following six factors involving critical milestones that affect the probability of developing and operating a casino:
  •  Has the U.S. Government’s Bureau of Indian Affairs federally recognized the tribe as a tribe?
 
  •  Does the tribe hold or have the right to acquire land to be used for the casino site?
 
  •  Has the Department of the Interior put the land into trust for purposes of being used as a casino site?
 
  •  Has the tribe entered into a gaming agreement with the state in which the land is located, if required by the state?

34


Table of Contents

  •  Has the tribe obtained approval by the National Indian Gaming Commission of the management agreement?
 
  •  Do other legal and political obstacles exist that could block development of the project and, if so, what is the likelihood of the tribe successfully prevailing?
      In addition to the above factors, Lakes also considers economic and qualitative factors affecting Lakes’ future economic benefits from the project, including the following:
  •  An evaluation by Company management of the financial projections of the project given the project’s geographic location and the feasibility of the project’s success given such location;
 
  •  The structure and stability of the tribal government;
 
  •  The scope of the proposed project, including the physical scope of the contemplated facility and the expected financial scope of the related development;
 
  •  An evaluation of the proposed project’s ability to be built as contemplated and the likelihood that financing will be available; and
 
  •  The nature of the business opportunity to Lakes, including whether the project would be a financing, development and/or management opportunity.
      The development phase of each relationship commences with the signing of the respective contracts and continues until the casinos open for business; thereafter, the management phase or consulting phase of the relationship, governed by the contract, continues for a period of up to seven years. Lakes, as developer and/or manager, has the exclusive right and obligation to develop, manage or provide consulting services, operate and maintain the casino and to train tribal members and others in the operation and maintenance of the casino during the term of the contract. The Company also makes advances to the tribes to fund certain portions of the projects, which bear interest generally at prime plus 1% or 2%. Repayment of the advances and accrued interest is only required if the casino is successfully opened and distributable profits are available from the casino operations. Under the management contract Lakes typically earns a management fee calculated as a percentage of the net income of the operations. In addition, repayment of the loans and the manager’s fees under the management contracts are subordinated to certain other financial obligations of the respective operations. Generally, the order of priority of payments from the casinos’ cash flows is as follows: a certain minimum monthly priority payment to the tribe, repayment of various senior debt associated with construction and equipping of the casino with interest accrued thereon, repayment of various debt with interest accrued thereon due to Lakes, management fee to Lakes, and other obligations, with the remaining funds distributed to the tribe.
      The Company accounts for its advances to the tribes and its management or consulting contracts as separate elements. The advances made to the tribes are accounted for as structured notes in accordance with the guidance contained in Emerging Issues Task Force Consensus No. 96-12 Recognition of Interest Income and Balance Sheet Classification of Structured Notes (EITF No. 96-12). Because repayment of the notes is required only if a casino is successfully opened, Lakes’ advances may be at risk for reasons other than failure of the borrower to pay the contractual amounts due because if the casinos are not built the amounts due will not become contractually due. Accordingly, pursuant to the guidance in EITF No. 96-12, Lakes records its advances to tribes at estimated fair value. Because the stated rate of the notes receivable alone is not commensurate with the risk inherent in these projects, the estimated fair value of the notes receivable is generally less than the amount advanced. At the date of each advance, the difference between the estimated fair value of the note receivable and the actual amount advanced is recorded as an intangible asset related to the acquisition of the management, consulting or financing contract. Subsequent to the initial recording, the two assets are accounted for separately.
      Subsequent to its initial recording at estimated fair value, the note receivable portion of the advance is adjusted to its current fair value at each balance sheet date based on current assumptions related to the projects. The notes receivable are not adjusted to an amount in excess of the contractual amount due. Changes

35


Table of Contents

in estimated fair value are recorded as unrealized gains or losses on notes receivable in the Company’s statement of operations.
      The determination of estimated fair value requires that assumptions be made and judgments be applied regarding casino opening dates, interest rates, discount rates and probabilities of the projects opening based on a review of critical milestones. If casino opening dates, interest rates, discount rates or the probabilities of the projects opening change significantly, the estimated fair value of the related note receivable is adjusted accordingly and the Company could experience unrealized gains or losses that could be material.
      Upon opening of the casino Lakes may conclude that it is no longer reasonably possible that the advances to Indian tribes would be at risk to not be repaid for reasons other than failure of the borrower to pay the contractual amounts due. In such situations, the notes receivable will be accounted for under the effective interest method upon opening of the casino and will no longer be adjusted to fair value at each balance sheet date. Any difference between the then fair value of the advances and the amount contractually due under the notes will be amortized into income using the effective interest method over the remaining term of the note. Such notes would then be evaluated for impairment pursuant to Statement of Financial Accounting Standards No. 114 “Accounting by Creditors for Impairment of a Loan.”
Intangible Assets Related to Acquisition of Management Contracts:
      Intangible assets related to the acquisition of the management, consulting or financing contracts are accounted for using the guidance in Statement of Financial Accounting Standards No. 142 Goodwill and Other Intangible Assets (FASB No. 142). Pursuant to that guidance, the assets are periodically evaluated for impairment based on the estimated cash flows from the contract on an undiscounted basis. In the event the carrying value of the intangible assets, in combination with the carrying value of land held for development and other assets associated with the Indian casino projects described below, were to exceed the undiscounted cash flow, an impairment would be recorded. Such an impairment would be measured based on the difference between the fair value and carrying value of the assets. Lakes, in accordance with FASB No. 142, will amortize the intangible assets related to the acquisition of the management, consulting or financing contracts under the straight-line method over the lives of the contracts which will commence when the related casinos open. In addition to the intangible asset associated with the cash advances to tribes described above, these assets include actual costs incurred to acquire Lakes’ interest in the projects from third parties.
Land Held for Development
      Included in land held for development is land held for possible transfer to Indian tribes for use in certain of the future casino resort projects. In the event that this land is not transferred to the tribes, the Company can sell it. Lakes evaluates these assets for impairment in combination with intangible assets related to acquisition of management, consulting or financing contracts and other assets related to the Indian casino projects as discussed above.
Other
      Included in this category are costs incurred related to the Indian casino projects, which have not yet been included as part of the notes receivable because of timing of the payment of these costs. These amounts will ultimately be allocated between notes receivable and intangible assets related to the acquisition of management, consulting or financing contracts and will be evaluated for changes in fair value or impairment, respectively, as described above. These amounts vary from period to period due to timing of payment of these costs.
      In addition, Lakes incurs certain costs related to the projects that are not included in notes receivable, which are expensed as incurred. These costs include salaries, travel and certain legal costs.

36


Table of Contents

      The consolidated balance sheets as of April 2, 2006 and January 1, 2006 include long-term assets related to Indian casino projects of $175.0 million and $152.8 million, respectively, primarily related to three separate projects. The amounts are as follows by project (in thousands):
                                         
    April 2, 2006
     
        Springs    
    Pokagon   Springs   Jamul    
    Band   Tribe   Tribe   Other   Total
                     
Notes receivable, at estimated fair value
  $ 49,858     $ 28,611     $ 20,002     $ 6,931     $ 105,402  
Intangible assets related to acquisition of management contracts
    19,596       19,466       8,155       1,311       48,528  
Land held for development
          8,776       6,677       795       16,248  
Other
    957       1,332       1,255       1,263       4,807  
                               
    $ 70,411     $ 58,185     $ 36,089     $ 10,300     $ 174,985  
                               
                                         
    January 1, 2006
     
        Springs    
    Pokagon   Springs   Jamul    
    Band   Tribe   Tribe   Other   Total
                     
Notes receivable, at estimated fair value
  $ 44,028     $ 26,550     $ 12,957     $ 3,527     $ 87,062  
Intangible assets related to acquisition of management contracts
    18,356       18,755       7,872       1,105       46,088  
Land held for development
          8,836       6,643       769       16,248  
Other
    93       1,600       828       839       3,360  
                               
    $ 62,477     $ 55,741     $ 28,300     $ 6,240     $ 152,758  
                               
      The key assumptions and criteria used in the determination of the estimated fair value of the notes receivable are estimated casino opening date, projected interest rates, discount rates and probability of projects opening. The estimated casino opening date used in the valuation reflects the weighted average of three scenarios: a base case (which is based on the Company’s forecasted casino opening date) and one and two years out from the base case. The projected interest rates are based upon the one year U.S Treasury Bill spot yield curve per Bloomberg and the specific assumptions on contract term, stated interest rate and casino opening date. The discount rate for the projects is based on the yields available on certain financial instruments at the valuation date, the risk level of equity investments in general, and the specific operating risks associated with open and operating gaming enterprises similar to each of the projects. In estimating this discount rate, market data of other public gaming related companies is considered. The probability applied to each project is based upon a weighting of four different scenarios with the fourth scenario assuming the casino never opens. The first three scenarios assume the casino opens but applies different opening dates as discussed above. The probability weighting applied to each scenario captures the element of risk in these projects and is based upon the status of each project, review of the critical milestones and likelihood of achieving the milestones.

37


Table of Contents

      The following table provides the key assumptions used to value the notes receivable at estimated fair value (dollars in thousands):
Pokagon Band:
         
    As of April 2, 2006   As of January 1, 2006
         
Face value of note (principal and interest)
  $63,988   $61,827
    $(47,266 principal and $16,722 interest)   $(46,445 principal and $15,382 interest)
Estimated months until casino opens (weighted average of three scenarios)
  25 months   32 months
Projected interest rate until casino opens
  8.6%   8.2%
Projected interest rate during the loan repayment term
  8.7%   8.2%
Discount rate
  15%   15%
Repayment terms of note
  60 months   60 months
Probability rate of casino opening (weighting of four scenarios)
  97.5%   90%
      See discussion included below under “Description of each Indian casino project and evaluation of critical milestones — Pokagon Band.”
Shingle Springs Tribe:
         
    As of April 2, 2006   As of January 1, 2006
         
Face value of note (principal and interest)
  $49,226   $46,446
    $(39,609 principal and $9,617 interest)   $(37,905 principal and $8,541 interest)
Estimated months until casino opens (weighted average of three scenarios)
  37 months   37 months
Projected interest rate until casino opens
  9.6%   9.2%
Projected interest rate during the loan repayment term
  9.6%   9.1%
Discount rate
  15%   15%
Projected repayment terms of note*
  24 months   24 months
Probability rate of casino opening (weighting of four scenarios)
  70%   70%
 
Payable in varying monthly installments based on contract terms subsequent to the casino opening.
      See discussion included below under “Description of each Indian casino project and evaluation of critical milestones — Shingle Springs.”

38


Table of Contents

Jamul Tribe:
         
    As of April 2, 2006   As of January 1, 2006
         
Face value of note (principal and interest)
  $22,707   $21,247
    $(17,766 principal and   $(16,858 principal and
    $4,941 interest)   $4,389 interest)
Estimated months until casino opens (weighted average of three scenarios)
  34 months   34 months
Projected interest rate until casino opens
  17.0%   9.2%
Projected interest rate during the loan repayment term
  17.0%   9.2%
Discount rate
  17.5%   15%
Repayment terms of note
  24 months *   84 months
Probability rate of casino opening (weighting of four scenarios)
  85%   80%
 
Payable in varying monthly installments based on contract terms subsequent to the casino opening.
      See discussion below included under the caption “Description of each Indian casino project and evaluation of critical milestones — Jamul Tribe”.
      The following table represents a sensitivity analysis prepared by the Company of the notes receivable from the Jamul Tribe, Pokagon Band and Shingle Springs Tribe, based upon a change in the probability rate of the casino opening by five percentage points and the estimated casino opening date by one year (probability will not be adjusted in excess of 100%):
                                                         
        Sensitivity Analysis
    April 2, 2006    
    Fair Value   5% Less   One Year       5% Increased   One Year    
    Notes Receivable   Probable   Delay   Both   Probability   Sooner   Both
                             
Pokagon
  $ 49,858,353     $ 46,658,897     $ 46,459,463     $ 44,108,447     $ 50,392,213     $ 51,993,728     $ 53,311,140  
Shingle Springs
  $ 28,611,323     $ 26,133,497     $ 26,833,973     $ 24,912,047     $ 30,266,464     $ 29,628,165     $ 31,749,677  
Jamul
  $ 20,001,653     $ 18,020,175     $ 19,054,439     $ 17,944,266     $ 20,250,009     $ 19,216,091     $ 20,335,772  
                                           
    $ 98,471,329     $ 90,812,569     $ 92,347,875     $ 86,964,760     $ 100,908,686     $ 100,837,984     $ 105,396,589  
                                           
                                                         
        Sensitivity Analysis
    January 1, 2006    
    Fair Value   5% Less   One Year       5% Increased   One Year    
    Notes Receivable   Probable   Delay   Both   Probability   Sooner   Both
                             
Pokagon
  $ 44,028,057     $ 41,751,387     $ 41,590,634     $ 39,449,376     $ 46,304,727     $ 46,619,622     $ 49,040,268  
Shingle Springs
  $ 26,549,694     $ 24,632,645     $ 25,186,755     $ 23,367,059     $ 28,466,744     $ 27,985,550     $ 30,005,160  
Jamul
  $ 12,957,357     $ 12,175,960     $ 12,322,455     $ 11,580,739     $ 13,738,755     $ 13,626,227     $ 14,449,428  
                                           
    $ 83,535,108     $ 78,559,992     $ 79,099,844     $ 74,397,174     $ 88,510,226     $ 88,231,399     $ 93,494,856  
                                           
      The assumption changes used in the sensitivity analysis above are hypothetical. The effect of the variation in the probability assumption and estimated opening date on the estimated fair value of the notes receivable from Indian tribes was calculated without changing any other assumptions; in reality, changes in these factors may result in changes in another. For example, the change in probability could be associated with a change in discount rate, which might magnify or counteract the sensitivities.

39


Table of Contents

      The following represents the nature of the advances to the tribes. The table represents the total amount of advances, which represent the principal amount of the notes receivable, as of April 2, 2006 and January 1, 2006. The notes receivable are carried on the consolidated balance sheets at April 2, 2006 and January 1, 2006 at their estimated fair values of $105.4 million and $87.1 million, respectively.
                                         
    Balance at April 2, 2006
     
        Shingle    
Advances Principal Balance   Pokagon   Springs   Jamul   Other   Total
                     
Note receivable, pre-construction(a)
  $ 23,160     $ 39,609     $ 16,816     $     $ 79,585  
Note receivable, non — gaming land(b)
    13,176                         13,176  
Note receivable, land(b)
    10,930             950             11,880  
Note receivable, other(c)
                            7,891       7,891  
                               
    $ 47,266     $ 39,609     $ 17,766     $ 7,891     $ 112,532  
                               
                                         
    Balance at January 1, 2006
     
        Shingle    
Advances Principal Balance   Pokagon   Springs   Jamul   Other   Total
                     
Note receivable, pre-construction(a)
  $ 22,344     $ 37,905     $ 15,908     $     $ 76,157  
Note receivable, non — gaming land(b)
    13,176                         13,176  
Note receivable, land(b)
    10,925             950             11,875  
Note receivable, other(c)
                            4,474       4,474  
                               
    $ 46,445     $ 37,905     $ 16,858     $ 4,474     $ 105,682  
                               
 
(a)  Lakes funds certain costs incurred to develop the casino project. These costs relate to construction costs, legal fees in connection with various regulatory approvals and litigation, environmental costs and design consulting, and Lakes, in order to obtain the development agreement and management contract, agrees to advance a monthly amount used by the tribe for a variety of tribal expenses.
(b) Lakes purchased land to be used and transferred to the tribe in connection with the casino project. At Pokagon, a portion of the land will be used by the tribe separate from the casino project land.
 
(c) Represents amounts advanced under the agreements with the Iowa Tribe and Pawnee Nation. April 2, 2006 amount includes $2.5 million related to a settlement reached with the Kickapoo Tribe in March 2006.
      The notes receivable pre-construction advances consist of the following principal amounts advanced to the tribes at April 2, 2006 and January 1, 2006 (in thousands):
                 
    April 2,   January 1,
Pokagon   2006   2006
         
Monthly stipend
  $ 10,000     $ 9,625  
Construction
    2,639       2,635  
Legal
    1,894       1,634  
Environmental
    652       650  
Design
    7,975       7,800  
             
    $ 23,160     $ 22,344  
             

40


Table of Contents

                 
    April 2,   January 1,
Shingle Springs   2006   2006
         
Monthly stipend
  $ 6,890     $ 6,390  
Construction
    1,623       1,623  
Legal
    12,731       12,195  
Environmental
    1,602       1,588  
Design
    9,420       9,306  
Gaming license
    3,476       3,426  
Lobbyist
    3,867       3,377  
             
    $ 39,609     $ 37,905  
             
                 
    April 2,   January 1,
Jamul   2006   2006
         
Monthly stipend
  $ 3,988     $ 3,841  
Construction
    346       326  
Legal
    3,422       3,340  
Environmental
    1,678       1,668  
Design
    4,650       4,168  
Gaming license
    538       511  
Lobbyist
    2,194       2,054  
             
    $ 16,816     $ 15,908  
             
Lakes’ evaluation of impairment related to Lakes’ long-term assets related to Indian casino projects, excluding the notes receivable, which are valued at fair value:
      Management periodically evaluates the intangible assets, land held for development and other costs associated with each of the projects for impairment. The assets are periodically evaluated for impairment based on the estimated cash flows from the management contract on an undiscounted basis. In the event the carrying value of the intangible assets, in combination with the carrying value of land held for development and other assets associated with the Indian casino projects were to exceed the undiscounted cash flow, an impairment would be recorded. Such impairment would be measured based on the difference between the fair value and carrying value of the assets.
      The financial models prepared by management for each project are based upon the scope of each of the projects, which are supported by a feasibility study as well as a market analysis where the casino will be built. Lakes (as its predecessor Grand Casinos Inc.) began developing Indian casino projects in 1990 and demonstrated success from the day the first Indian casino opened in 1991 through the expiration of its Coushatta management contract in 2002. This success legitimizes many of the key assumptions supporting the financial models. Projections for each applicable casino development were developed based on analysis of published information pertaining to the particular markets in which the Company’s Indian casinos will be located. In addition, Lakes has many years of casino operations experience within the Company, which provides a basis for its revenue expectations. The projections were prepared by Lakes not for purposes of the valuation at hand but rather for purposes of Lakes’ and the tribes’ business planning.

41


Table of Contents

      The primary assumptions included within management’s financial model for each Indian casino project is as follows:
Pokagon Band
                 
    April 2, 2006   January 1, 2006
         
No. of Class III slot machines
    3,000       3,000  
No. of Table games
    90       90  
No. of Poker tables
    20       20  
Win/ Class III slot machine/day — 1st year
    $281       $275  
Win/ Table game/day — 1st year
    $1,474       $1,444  
Win/ Poker game/day — 1st year
    $1,021       $1,000  
Expected increase (decrease) in management fee cash flows
    Year 2 — 4.5%       Year 2 — 2.1%  
      Year 3 — 4.1%       Year 3 — 1.9%  
      Year 4 — 3.3%       Year 4 — 3.6%  
      Year 5 — 3.0%       Year 5 — 2.8%  
      With regard to the Pokagon Casino project in southwest Michigan, the competitive market consists primarily of five Northern Indiana riverboats. The state of Indiana publicly reports certain results from these riverboat casinos which supports the underlying assumptions in our projections. Specifically, the Northern Indiana trailing twelve months market average for slot machine revenue has consistently been above $300 win per unit per day or greater than $105,000 per machine per year which exceeds the $275 win per unit per day that we used in our Pokagon Casino projections. Of the five casinos in the market, two locations produced a win per unit less than our projections with three casinos producing win per unit revenue amounts greater than our forecast. The closest casino to our location consistently produces approximately $330 win per unit per day.
Jamul Tribe
                 
    April 2,   January 1,
    2006   2006
         
No. of Class III slot machines
    349       349  
No. of Class II slot machines
    1,651       1,651  
No. of Table games
    65       65  
No. of Poker tables
    10       10  
Win/ Class III slot machine/day — 1st year
  $ 307     $ 307  
Win/ Class II slot machine/day — 1st year
  $ 220     $ 220  
Win/ Table game/day — 1st year
  $ 1,100     $ 1,100  
Win/ Poker table/day — 1st year
  $ 650     $ 650  
      The San Diego market contains other Indian-owned casinos in the surrounding area, each of which is self-managed. Because of the proprietary nature of those operations no public information is readily attainable. However, based on the apparent successful nature of their operations (large casinos which continually expand, new hotel developments, new golf courses, etc.) coupled with our knowledge of their operations, we feel that our forecast of operations is within the revenue metrics of the market.

42


Table of Contents

Shingle Springs Tribe
                 
    April 2, 2006   January 1, 2006
         
No. of Class III slot machines
    349       349  
No. of Class II slot machines
    1,651       1,651  
No. of Table games
    100       100  
No. of Poker tables
    20       20  
Win/ Class III slot machine/day — 1st year
    $350       $350  
Win/ Class II slot machine/day — 1st year
    $250       $250  
Win/ Table game/day — 1st year
    $1,275       $1,275  
Win/ Poker table/day — 1st year
    $624       $624  
Expected increase (decrease) in management fee cash flows
    Year 2 — 5.5%       Year 2 — 5.5%  
      Year 3 — 4.3%       Year 3 — 4.3%  
      Year 4 — 3%       Year 4 — 3%  
      Year 5 — 5.1%       Year 5 — 5.1%  
      Year 6 — (17)%       Year 6 — (17)%  
      (management fees       (management fees  
      were reduced in       were reduced in  
      years six and seven)       years six and seven)  
      Year 7 — 1.5%       Year 7 — 1.5%  
      In the Shingle Springs Sacramento market, there is one other Indian casino that is managed by another public company. Management considered the available information related to this other Indian casino when projecting management fees from the Shingle Springs Casino. Based on the apparent successful nature of their operations coupled with our knowledge of their operations, we feel that our forecast of operations is within the revenue metrics of the market.
      As of April 2, 2006 and January 1, 2006 no impairment was recognized on the Pokagon, Shingle Springs or Jamul projects.
Description of each Indian casino project and evaluation of critical milestones:
Pokagon Band
Business arrangement:
      Lakes, in July 1999, entered into a development agreement and management contract with the Pokagon Band, a federally recognized tribe with a compact with the State of Michigan, to develop and manage a casino on approximately 675 acres in southwest Michigan. The first phase of the casino is planned to include approximately 3,000 slot machines, 90 table games, a 20 table poker room, various restaurant and bar venues, a hotel, enclosed parking, a childcare facility and arcade, and various other resort amenities.
      The development agreement provides for Lakes to advance up to approximately $73.0 million for purchase of land and for the initial development phase of the project. The development agreement for the Pokagon project also provides that to the extent the Pokagon Band is unable to raise additional funding from third parties at an interest rate not to exceed 13%, Lakes will be required to provide additional financing of up to approximately $54.0 million. Based on extensive discussions with prospective lenders, it appears that third party financing will be available for this project; however, there can be no assurance that third party financing will be available at the time construction for the project begins. Lakes is not required to fund these amounts; however, if Lakes discontinued the funding prior to fulfilling the obligation, Lakes would forfeit the rights under the management contract.
      Lakes will receive approximately 24% of net income up to a certain level and 19% of the net income over that level, as a management fee. The term of the management contract is currently planned for five years beginning when the casino opens to the public and may extend for a total of seven years under certain

43


Table of Contents

circumstances. Payment of Lakes’ management fee will be subordinated to senior indebtedness of the Pokagon casino. The Pokagon Band may terminate the management contract after five years from the opening of the casino if any of certain required elements of the project have not been developed or certain financial commitments to the Pokagon Band have not been met. The Pokagon Band may also buy out the management contract provisions after two years from the opening date. The buyout amount is calculated based upon the previous 12 months of management fees earned multiplied by the remaining number of years under the management contract, discounted back to the present value at the time the buyout occurs. The management fee and length of contract are subject to regulatory approval. The casino could open as early as third quarter of fiscal 2007.
      The Company will be obligated to pay an amount to an unrelated third party once the Pokagon Casino is open and Lakes is the manager of the casino. The amount is payable quarterly for five years and is only payable if Lakes is the manager of the casino. The payment is part of a settlement and release agreement associated with Lakes obtaining the management contract with the Pokagon Band. The maximum liability over the five-year period is approximately $11 million. The Company will also be obligated to pay approximately $3.3 million to a third party on behalf of the Pokagon Band; in accordance with the management contract which is payable once the casino opens over 24 months. In accordance with the management contract, Lakes contributed $1 million to the Pokagon Band scholarship fund in April 2006 because the land was taken into trust and the management contract was approved by the NIGC.
Lakes’ evaluation of critical milestones:
      The following table outlines the status of each of the following primary milestones necessary to complete the Pokagon project as of the end of the first quarter of fiscal 2006, fiscal year 2005 and fiscal year 2004. Both the positive and negative evidence was reviewed during Lakes’ evaluation of the critical milestones.
                     
                     
 Critical Milestone     April 2, 2006     January 1, 2006     January 2, 2005  
                     
Federal recognition of the tribe     Yes     Yes     Yes  
                     
Possession of usable land corresponding with needs based on the Company’s project plan     Yes     Yes     Yes  
                     

44


Table of Contents

                     
                     
 Critical Milestone     April 2, 2006     January 1, 2006     January 2, 2005  
                     
Usable land placed in trust by Federal government     Yes     Yes — The additional information was submitted by the BIA in August 2004 and the lawsuit was still pending resolution as of January 1, 2006. In March 2005 the federal judge dismissed the last remaining issue filed by Taxpayers of Michigan Against Casinos (TOMAC) and ruled in favor of the Pokagon Band allowing the land to be placed into trust by the BIA. During the required 60 day waiting period, TOMAC filed for an appeal. The appeal hearing date was held on December 8, 2005. On January 6, 2006 the United States Court of Appeals for the District of Columbia Circuit ruled in favor of the Pokagon Band by affirming the Federal District Court’s grant of summary judgment in the lawsuit by TOMAC versus the U.S. Department of the Interior. On January 27, 2006, the Federal Government took official action to acquire the Pokagon Band’s 675-acre parcel of land in New Buffalo Township, Michigan, into trust for the Pokagon Band. This official action by the Department of the Interior paves the way for the Pokagon Band to move forward with their Four Winds Casino Resort project.     No — The additional information was submitted by the BIA in August 2004 and the lawsuit was still pending resolution as of January 2, 2005.  
                     
Usable county agreement, if applicable     Yes     Yes     Yes  
                     

45


Table of Contents

                     
                     
 Critical Milestone     April 2, 2006     January 1, 2006     January 2, 2005  
                     
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan     Yes     Yes     Yes  
                     
NIGC approval of management contract in current and desired form     Yes     No, submitted to the NIGC for review in 2000 and approval is expected in April 2006 as the land was taken into trust by the BIA on January 27, 2006.     No, submitted to the NIGC for review in 2000 and approval is expected at approximately the same time the land is being placed into trust by the BIA.  
                     
Resolution of all litigation and legal obstacles     No, The Michigan Supreme Court has now agreed to hear the appeal by TOMAC that the Compact entered into with the State of Michigan is invalid. The Michigan Court of Appeals (lower court) refused to hear TOMAC’s argument. TOMAC is arguing that the Compact is invalid as the 8% payment to the Michigan Strategic Fund is unconstitutional and invalid (in that it illegally bypasses the appropriation requirement). The financing lenders have indicated this will not hold-up the process of obtaining financing to begin construction.     No. However on January 6, 2006 the United States Court of Appeals for the District of Columbia Circuit ruled in favor of the Pokagon Band by affirming the Federal District Court’s grant of summary judgment in the lawsuit by TOMAC versus the U.S. Department of the Interior.     No, pending litigation regarding land in trust.  
                     
Financing for construction     No, however the Tribe engaged an investment banker to assist with obtaining financing, which we expect to occur as early as mid 2006.     No, however the Tribe engaged an investment banker to assist with obtaining financing, which we expect to occur as early as mid 2006.     No, however the Tribe engaged an investment banker to assist with obtaining financing.  
                     
Any other significant project milestones or contingencies, the outcome of which could have a material affect on the probability of project completion as planned     No others known at this time by Lakes.     No others known at this time by Lakes.     No others known at this time by Lakes.  
                     

46


Table of Contents

Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      Approximately $10.9 million of the loans due from the Pokagon Band were used by the Pokagon Band to purchase real property comprising the project site. The Company’s first deed of trust against the gaming land portion of this property (except for a small parcel worth approximately $0.3 million) was relinquished when the BIA placed the land into trust in January 2006. The Company still holds a deed of trust against the non-gaming land which has a cost basis of approximately $13.2 million.
      The estimated probability rate was increased from 90% to 97.5% in the first quarter of fiscal 2006 as the management contract was approval by the NIGC in March 2006 and the appeal deadline passed for TOMAC to appeal the January 6, 2006 favorable federal judge ruling that allowed the land to be taken into trust by the Federal Government. We expect to close on the third party financing to begin construction of the casino in the second quarter of fiscal 2006. Based upon a review of each of the milestones as discussed in the table above there is one new litigation matter: the Michigan Supreme Court has now agreed to hear the appeal by TOMAC that the Compact entered into with the State of Michigan is invalid. The Michigan Court of Appeals (lower court) refused to hear TOMAC’s argument. TOMAC is arguing that the Compact is invalid as the 8% payment to the Michigan Strategic Fund is unconstitutional and invalid (in that it illegally bypasses the appropriation requirement). The financing lenders have indicated this will not hold-up the process of obtaining financing to begin construction.
      The estimated probability rate was increased from 75% to 90% in fiscal 2005, due to an evaluation of all critical milestones and due to the favorable federal judge ruling issued in March 2005 that allowed the land to be taken into trust by the Federal Government. TOMAC filed for an appeal. The appeal hearing date was held on December 8, 2005. On January 6, 2006 the United States Court of Appeals for the District of Columbia Circuit ruled in favor of the Pokagon Band by affirming the Federal District Court’s grant of summary judgment in the lawsuit by TOMAC versus the U.S. Department of the Interior. On January 27, 2006, the Federal Government took official action to acquire the Pokagon Band’s 675-acre parcel of land in New Buffalo Township, Michigan, into trust for the Pokagon Band.
      Due to the status of the critical milestones as described above the weighted average estimated casino opening date was moved ahead from October 2008 to April 2008 during the first quarter ended April 2, 2006.
Shingle Springs
Business arrangement:
      Plans for the Shingle Springs Casino project include an approximately 1,100,000 square-foot facility (including approximately 85,000 square feet of casino space) to be located adjacent to the planned Shingle Springs Rancheria exit, approximately 35 miles east of downtown Sacramento, on U.S. Highway 50. The Shingle Springs Casino is currently planned to feature approximately 2,000 gaming devices and approximately 100 table games, 20 poker table games as well as restaurants, enclosed parking and other facilities.
      Lakes acquired its initial interest in the development and management contracts for the Shingle Springs Casino from Kean Argovitz Resorts- Shingle Springs, LLC (“KAR — Shingle Springs”) in 1999 and formed a joint venture, in which the contracts were held, between Lakes and KAR — Shingle Springs. On January 30, 2003, Lakes purchased the remaining KAR — Shingle Springs’ partnership interest in the joint venture. In connection with the purchase transaction, Lakes entered into separate agreements with the two individual owners of KAR — Shingle Springs (Kevin M. Kean and Jerry A. Argovitz). Under the agreement with Mr. Kean, Mr. Kean may elect to serve as a consultant to Lakes during the term of the casino management contract if he is found suitable by relevant gaming regulatory authorities. In such event, Mr. Kean will be entitled to receive annual consulting fees equal to 15% of the management fees received by Lakes from the Shingle Springs Casino operations, less certain costs of these operations. If Mr. Kean is not found suitable by relevant gaming regulatory authorities or otherwise elects not to serve as a consultant, he will be entitled to receive annual payments of $1 million from the Shingle Springs Casino project during the term of the respective casino management contract (but not during any renewal term of such management contract).

47


Table of Contents

      Under the agreement with Mr. Argovitz, if he is found suitable by relevant gaming regulatory authorities he may elect to re-purchase his respective original equity interest in the Lakes’ subsidiary and then be entitled to obtain a 15% equity interest in the Lakes’ entity that holds the rights to the management contract with the Shingle Springs Casino. If he is not found suitable or does not elect to purchase equity interests in the Lakes’ subsidiary, Mr. Argovitz would receive annual payments of $1 million from the Shingle Springs Casino project from the date of election through the term of the respective casino management contract (but not during any renewal term of such management contract).
      The development agreement provides for Lakes to make certain pre-construction advances to the Shingle Springs Tribe in the form of a transition loan and land loan up to a maximum amount of $50.0 million. Lakes is not required to fund these amounts. If, however, Lakes discontinued the funding prior to fulfilling the obligation, Lakes would forfeit the rights under the management contract.
      The agreement provides for Lakes to arrange for financing or, in its discretion, loan funds to the Shingle Springs Tribe in the form of a facility loan, for the costs of construction and initial costs of operation up to a maximum currently of $300 million. In addition, Lakes will assist in the design, development and construction of the facility as well as manage the pre-opening, opening and continued operations of the casino and related amenities for a period of seven years. As compensation for its management services, Lakes will receive a management fee between 21% and 30% of net income of the operations annually for the first five years, with a declining percentage in years six and seven, as that term is defined by the management contract. Payment of Lakes’ management fee will be subordinated to senior indebtedness of the Shingle Springs Casino and minimum priority payment to the Shingle Springs Tribe. The Shingle Springs Tribe may terminate the agreement after five years from the opening of the casino if any of certain required elements of the project have not been developed. The management contract includes provisions that allow the Shingle Springs Tribe to buy out the management contract after four years from the opening date. The buyout amount is calculated based upon the previous twelve months of management fees earned multiplied by the remaining number of years under the contract, discounted back to the present value at the time the buyout occurs.
Lakes’ Evaluation of the Critical Milestones:
      The following table outlines the status of each of the following primary milestones necessary to complete the Shingle Springs project as of the end of the first quarter of fiscal 2006, fiscal year 2005 and fiscal year 2004. Both the positive and negative evidence was reviewed during Lakes’ evaluation of the critical milestones.
                     
                     
 Critical Milestone     April 2, 2006     January 1, 2006     January 2, 2005  
                     
Federal recognition of the tribe     Yes     Yes     Yes  
                     
Possession of usable land corresponding with needs based on the Company’s project plan     Yes     Yes     Yes  
                     
Usable land placed in trust by Federal government     Not necessary, as land is reservation land.     Not necessary, as land is reservation land.     Not necessary, as land is reservation land.  
                     

48


Table of Contents

                     
                     
 Critical Milestone     April 2, 2006     January 1, 2006     January 2, 2005  
                     
Usable county agreement, if applicable     N/A     N/A     N/A  
                     
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan     Yes     Yes     Yes  
                     
NIGC approval of management contract in current and desired form     Yes — approval received in 2004.     Yes — approval received in 2004.     Yes — approval received in 2004.  
                     
Resolution of all litigation and legal obstacles     No, Federal and state litigation regarding approval of highway interchange, environmental issues and other issues.     No, Federal and state litigation regarding approval of highway interchange, environmental issues and other issues.     No, Federal and state litigation regarding approval of highway interchange, environmental issues and other issues.  
      — See below.     — See below.     — See below.  
                     
Financing for construction     No, however the Shingle Springs Tribe has engaged investment banks to assist with obtaining financing.     No, however the Shingle Springs Tribe has engaged investment banks to assist with obtaining financing.     No, however the Shingle Springs Tribe has engaged investment banks to assist with obtaining financing.  
                     
Any other significant project milestones or contingencies, the outcome of which could have a material affect on the probability of project completion as planned     No others known at this time by Lakes.     No others known at this time by Lakes.     No others known at this time by Lakes.  
                     
Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      As a result of delays related to litigation surrounding access to the reservation via an interchange, the weighted average estimated casino opening date was extended from February 2009 to May 2009 during the first quarter ended April 2, 2006.
      In January 2005, Lakes received a favorable ruling from the federal court on all federal issues with respect to the casino development planned by the Shingle Springs Tribe. The federal favorable ruling related to the project is being appealed by El Dorado County. The Shingle Springs Tribe is a federally recognized tribe, has a compact with the State of California and owns approximately 160 acres of reservation land on which the casino can be built. During July 2004, Lakes received notification from the NIGC that the development and management contract between the Shingle Springs Tribe and Lakes, allowing Lakes to manage a Class II and Class III casino, was approved by the NIGC.
      The most significant milestone yet to be achieved for this project is commercial access to the reservation on which the casino will be built. The Shingle Springs Tribe received state regulatory approval of a necessary interchange to access the tribal land during 2002. Neighboring El Dorado County and another local group commenced litigation in federal and state courts against the California regulatory agencies attempting to block the approval of the interchange. During January of 2004, the California Superior Court ruled in favor of the California Department of Transportation (“CalTrans”) on all of El Dorado County’s claims challenging

49


Table of Contents

CalTrans’ environmental review of the proposed casino project except that the court asked for clarification on one issue. The one remaining issue in the state case questions the state standards for ozone requirements of all of CalTrans projects throughout California. El Dorado County, Voices for Rural Living, CalTrans and the Shingle Springs Tribe filed an appeal and oral arguments on these appeals was heard in August 2005. In November 2005, the California Court of Appeal (“Court”) issued its decision on these appeals. The Court ruled in favor of CalTrans’ appeal, rejecting the El Dorado County’s argument that the transportation conformity analysis did not conform to state standards. The Court also rejected all but two of the legal claims asserted in the appeal by El Dorado County and Voices for Rural Living against the environmental impact report (“EIR”) prepared by CalTrans for the interchange that will connect Highway 50 to the Shingle Springs Rancheria. For the remaining two issues, the Court held that CalTrans must supplement its environmental analysis by adding some discussion to the air quality chapter to further explain the project’s contribution to overall vehicular emissions in the region, and that CalTrans also must evaluate whether a smaller casino and hotel would reduce environmental impacts. On December 19, 2005, CalTrans filed a Petition for Review with the Supreme Court of the State of California, and on February 8, 2006 the Supreme Court denied the Petition for Review and ordered the Court of Appeals decision to be depublished. CalTrans is preparing the necessary additional information as requested by the Court for the two issues described above. The Court acknowledged CalTrans lacks jurisdiction to require the Shingle Springs Tribe to develop a smaller casino, but nevertheless required some discussion of this alternative in the interchange EIR. Construction of the interchange and casino could begin as early as the beginning of fiscal 2007 with an estimated opening date approximately 14 months after the start of the construction.
      Under the form of tribal-state compact first signed by the State of California with both the Jamul and Shingle Springs tribes in 1999, each tribe is allowed to operate up to 350 Class III slot machines without licenses from the state. This form of compact allows tribes to operate up to an additional 1,650 Class II slot machines by obtaining licenses for the devices from the state. Under these tribal-state compacts, there is a state-wide limitation on the aggregate number of Class III slot machine licenses that are available. Tribes who have entered into new tribal-state compacts or amendments to the 1999 form of tribal-state compact in general are allowed to operate an unlimited number of Class II slot machines without the need for obtaining additional licenses, subject to the payment of additional fees to the state, including, in recent cases, fees based on a percentage of slot “net win.” Currently, neither the Jamul Tribe nor the Shingle Springs Tribe have amended their tribal-state compacts. If the compacts are not renegotiated and amended, the tribes could operate under their existing compacts which allows for up to 350 Class III gaming devices and an unlimited number of Class II gaming devices. Management believes that this number of gaming devices is adequate to equip the planned developments. Therefore, Lakes believes the availability of additional slot licenses is not an issue that could prevent the projects from progressing. The Shingle Springs project is currently planned to open with 349 Class III slot machines and approximate 1,650 Class II devices.
Jamul Tribe
Business arrangement:
      The Jamul Tribe has an approximate six-acre reservation on which the casino project is currently planned to be built. The reservation is located near San Diego, California. Plans for the casino include approximately 2,000 gaming devices and approximately 75 table games, along with various restaurants and related amenities.
      Effective March 30, 2006, Lakes entered into a development financing and services agreement with the Jamul Tribe. As part of the agreement, Lakes will use its best efforts to obtain financing from which advances of up to $350 million will be made to the Jamul Tribe to pay for the design and construction of the project. However, there can be no assurance that third party financing will be available, and if Lakes is unable to obtain the appropriate amount of financing for this project, the project may not be completed as planned. This agreement will help assist the Jamul Tribe in developing a first class casino with related amenities/services on its existing six acre reservation which the Jamul Tribe will manage.
      Under the new agreement, Lakes will receive a flat fee of $15 million for its development design services, and a flat fee of $15 million for its construction oversight services. Each of these fees will be payable to Lakes

50


Table of Contents

evenly over the first five years after the opening date of the Jamul Casino. In connection with Lakes financing of the Jamul Casino, the Jamul Tribe will pay interest over a ten year period on sums advanced by Lakes equal to the rate charged to Lakes for obtaining the funds necessary plus 5%. Amounts previously advanced by Lakes to the Jamul Tribe in connection with the Tribe’s proposed casino resort are to be included in the financing for the Jamul Casino.
      Prior to entering into the 2006 development financing and services agreement Lakes and the Jamul Tribe entered into a development agreement and management contract in 1999, which has been submitted to the NIGC for approval.
Lakes’ Evaluation of the Critical Milestones:
      The following table outlines the status of each of the following primary milestones necessary to complete the Jamul project as of the end of the first quarter of fiscal 2006, fiscal year 2005 and fiscal year 2004. Both the positive and negative evidence was reviewed during Lakes’ evaluation of the critical milestones.
                     
                     
 Critical Milestone     April 2, 2006     January 1, 2006     January 2, 2005  
                     
Federal recognition of the tribe     Yes     Yes     Yes  
                     
Possession of usable land corresponding with needs based on the Company’s project plan     Yes     Yes     Yes  
                     
Usable land placed in trust by Federal government     Not necessary, as land is reservation land.     Yes, six acres is reservation land held by the Jamul Tribe on which the casino will be built. There is an additional 82 acres contiguous to the reservation land pending BIA approval to be placed into trust that could be used for additional development of the project. The Jamul Tribe and Lakes prepared an EIS and trust application, which has been submitted to, reviewed and recommended for approval by the regional office of the BIA. The Washington, D.C. office of the BIA is currently reviewing the submission.     Yes, six acres is reservation land held by the Jamul Tribe on which the casino will be built. There is an additional 82 acres contiguous to the reservation land pending BIA approval to be placed into trust that could be used for additional development of the project. The Jamul Tribe and Lakes prepared an EIS and trust application, which has been submitted to, reviewed and recommended for approval by the regional office of the BIA. The Washington, D.C. office of the BIA is currently reviewing the submission.  
                     

51


Table of Contents

                     
                     
 Critical Milestone     April 2, 2006     January 1, 2006     January 2, 2005  
                     
Usable county agreement, if applicable     N/A     N/A     N/A  
                     
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan     Yes     Yes     Yes  
                     
NIGC approval of management contract in current and desired form     N/A as the Jamul Tribe and Lakes entered into a development financing and services agreement in March 2006, which does not need to be approved by the NIGC.     No, submitted for approval by the NIGC in 2000. We are in communication with the NIGC and have responded to initial comments. Approval is not expected until the process to place land in trust by the BIA is complete.     No, submitted for approval by the NIGC in 2000. We are in communication with the NIGC and have responded to initial comments. Approval is not expected until the process to place land in trust by the BIA is complete.  
                     
Resolution of all litigation and legal obstacles     N/A, there has been some local opposition regarding the project, although no formal legal action has been taken.     N/A, there has been some local opposition regarding the project, although no formal legal action has been taken.     N/A, there has been some local opposition regarding the project, although no formal legal action has been taken.  
                     
Financing for construction     No, however, preliminary discussions with investment bankers regarding assisting in obtaining financing have taken place.     No, however, preliminary discussions with investment bankers regarding assisting in obtaining financing have taken place.     No, however, preliminary discussions with investment bankers regarding assisting in obtaining financing have taken place.  
                     
Any other significant project milestones or contingencies, the outcome of which could have a material affect on the probability of project completion as planned     No others known at this time by Lakes.     No others known at this time by Lakes.     No others known at this time by Lakes.  
                     
Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      As a result of delays related to getting land contiguous to the reservation placed into trust (which is now eliminated as a result of the new agreement entered into with the Jamul Tribe on March 30, 2006), the weighted average estimated casino opening date was extended from November 2008 to February 2009 during the first quarter ended April 2, 2006. The probability rate was increased from 80% at January 1, 2006 to 85% at April 2, 2006 as a result of the Jamul Tribe and Lakes entering into a development financing and services agreement in March 2006 which eliminates the need for land contiguous to the reservation land being taken into trust and the NIGC does not need to approve the development financing and services agreement. The casino will be built on the Jamul Tribe’s existing six acres of reservation land. Reservation land qualifies for gaming without going through a land in trust process.

52


Table of Contents

      The process of getting the land contiguous to the reservation placed into trust has been slow. Therefore, during August of 2005, the Jamul Tribe and Lakes formally announced plans to build the casino on the approximately six acres of reservation land held by the Jamul Tribe. The approximate size of the casino and related guest amenities will not change in total, as the casino was always planned to be built on the reservation land. The approximate six-acre project would be built on various levels to accommodate essentially all of the same amenities that were planned for the project on the larger parcel of land. Therefore, the design of the project would change significantly from a complex of lower-level buildings spread out over a larger area to a multi-level resort built on a smaller parcel of land. Neither the total square footage nor the nature or cost of the project are expected to change significantly as it will be primarily the same project being built on a smaller footprint.
      Lakes has consulted with third-party advisors as to the architectural feasibility of the alternative plan and has been assured that the project can be successfully built on the reservation land. The Company has completed economic models for each alternative and concluded that either would result in a successful operation assuming that adequate financing can be obtained.
      Therefore, the Company believes this project will be successfully completed. Construction of the casino could begin in late fiscal 2006 with an estimated opening date of the casino 18 months thereafter.
      The Jamul Tribe is a federally recognized tribe with a compact with the State of California and has an approximate six acre reservation on which the casino is planned to be built. The primary effort in this project has been to place approximately 82 acres of land contiguous to the reservation into trust for gaming. Lakes acquired 101 acres of land contiguous to the six acres of reservation land of which 19 acres relate to land with certain easements, which will not be accepted into trust. The trust application, including an Environmental Impact Statement (“EIS”), has been prepared, submitted to, reviewed and recommended for approval by the regional office of the BIA. The Washington, D.C. office of the BIA is currently reviewing the submission to determine if the land should be taken into trust. There has been some local opposition regarding the project. An EIS is more rigorous to complete than a more typical EA (Environmental Assessment). The EIS was more intense and took longer to prepare but is considered a better method to address all potential environmental concerns surrounding this project and to mitigate potential future opposition that may delay the project. The Jamul Tribe is in process of preparing a Tribal Environmental Impact Report under guidelines of the State compact.
      Under the form of tribal-state compact first signed by the State of California with both the Jamul and Shingle Springs tribes in 1999, each tribe is allowed to operate up to 350 Class III slot machines without licenses from the state. This form of compact allows tribes to operate up to an additional 1,650 Class II slot machines by obtaining licenses for the devices from the state. Under these tribal-state compacts, there is a state-wide limitation on the aggregate number of Class III slot machine licenses that are available to tribes. Certain tribes have entered into new tribal-state compacts or amendments to the 1999 form of tribal-state compact that allow them to operate an unlimited number of Class II slot machines without the need for obtaining additional licenses, subject to the payment of additional fees to the state, including in recent cases, fees based on a percentage of slot “net win.” Currently, neither the Jamul tribe nor the Shingle Springs tribe have amended their tribal-state compacts. If the compacts are not renegotiated and amended the tribes could operate under their existing compacts which allow for up to 350 Class III gaming devices and an unlimited number of Class II gaming devices. This number of gaming devices is adequate to equip the planned developments. Therefore, Lakes believes the availability of additional slot licenses is not an issue that could prevent the projects from progressing. The Jamul project is currently planned to open with 349 Class III slot machines and approximate 1,650 Class II devices.
Pawnee Nation of Oklahoma
Business arrangement:
      In January 2005, Lakes entered into three gaming development and consulting agreements (collectively “Pawnee Development and Consulting Agreements”) and three separate management contracts (collectively “Pawnee Management Contracts”) with three wholly-owned subsidiaries of the Pawnee Tribal Development

53


Table of Contents

Corporation (“Pawnee TDC)” referred to collectively as the “Pawnee Nation” in connection with assisting the Pawnee Nation in developing, equipping and managing three separate casino destinations.
      The largest of the casino resort developments, referred to as the “Chilocco Casino”, will be located on approximately 800 acres of Indian gaming land owned by the Pawnee Nation in northern Oklahoma near the Kansas border. This project is planned to include a large first class casino, hotel and meeting space, multiple restaurants and bar venues, an entertainment and event center, a golf course and various other casino resort amenities. The first phase of the project is planned to include approximately 1,200 gaming devices, 24 table games, a poker room, various restaurants and bars, a 150-room hotel and parking.
      The Pawnee Nation currently operates a “Travel Plaza” at the intersection of U.S. Highway 412 and State Highway 18, approximately 25 miles from Stillwater, Oklahoma. The Pawnee Nation intends to expand the Travel Plaza to include gaming and has engaged Lakes to assist with this project. When expanded, the planned project will open with approximately 200 gaming devices and a full service restaurant.
      As compensation for the performance of its obligations under the management contract for each of these two locations, Lakes shall be entitled to receive a fee of 30% of net income of the respective casino (as defined in the contracts) for a period of five to seven years, depending on the scope of the facilities, less any amounts earned by any Company affiliate for consulting on the two projects. The management contracts are subject to approval of the NIGC and certain other conditions.
      The Pawnee Nation also operates its “Trading Post” Casino, which currently includes approximately 65 gaming devices along with a retail convenience store and gas station in the town of Pawnee, Oklahoma. Lakes will assist in the management of this project and in its expansion if the Pawnee Nation decides to expand the casino. As compensation for its management services on this project, Lakes will receive a management fee of approximately 30% of net income, as defined in the agreement, based on the incremental net income produced at this location during the length of the management contract, expected to be from five to seven years, depending on the scope of the facilities, less any amounts earned by any Company affiliate for consulting on the two projects subject to regulatory approval and certain other conditions.
      Prior to the approval of the Pawnee Management Contracts by the NIGC, Lakes will provide services under the Pawnee Development and Consulting Agreements to each of the three Pawnee casino projects. Under these agreements Lakes will provide advances to the Pawnee Nation, if needed, from time to time to each particular project for preliminary development costs as agreed to by Lakes and the Pawnee Nation. Any advances made will accrue interest at prime plus two percent and be repayable in 24 equal monthly installments beginning on the 25th day following the opening date for the project if the loan has not previously been repaid through the project permanent financing. The Pawnee Development and Consulting Agreements are for 12 years from the effective date of the agreements or until the project development fees and the project preliminary development loans have been fully paid, whichever date is later, subject to early termination. In addition to interest earned on the project preliminary development loan, Lakes will receive a development fixed fee equal to three percent of project costs at each location and a monthly consulting flat fee for each of the three projects of $5,000 for the Trading Post location, $25,000 for the Travel Plaza location and $250,000 for the new casino, per month for 120 months. The above development fixed fees shall be paid on the opening date of each of the projects. No monthly consulting fixed fee is earned or paid prior to the opening date of the project. After the opening date of the project the monthly consulting fixed fee shall be due and paid commencing on the 25th day of the following calendar month and each successive month.
      The Pawnee Development and Consulting Agreements and Pawnee Management Contracts are subject to NIGC review and include provisions for an early buyout of the Pawnee Development and Consulting Agreements and the Pawnee Management Contracts by the Pawnee Nation.
      Arrangement with Consultant. The Company has executed an agreement stipulating that Kevin Kean will be compensated for his consulting services (relating to the Pawnee Nation) rendered to the Company. Under this arrangement, subject to Mr. Kean obtaining certain regulatory approvals, Mr. Kean will receive 20 percent of the Company’s fee compensation earned under the Pawnee Development and Consulting Agreements and Pawnee Management Contracts with the Pawnee Nation (i.e., six percent of the incremental

54


Table of Contents

total net income or 20 percent of the Company’s 30 percent share). This agreement provides that payments will be due to Mr. Kean when the Company is paid by the Pawnee Nation.
Lakes’ Evaluation of the three Pawnee Nation Projects:
      The following table outlines the status of each of the following primary milestones necessary to complete the Pawnee Nation projects as of April 2, 2006:
                     
                     
 Critical Milestone     Chilocco Casino Project     Travel Plaza     Trading Post  
                     
Federal recognition of the tribe     Yes     Yes     Yes  
                     
Possession of usable land corresponding with needs based on the Company’s project plan     Yes, the Pawnee Nation currently holds land in trust where the Chilocco casino will be built.     Yes, the Pawnee Nation is currently leasing land from tribal members, which is held in trust for the individual tribal members by the United States Government. The BIA approved the lease documents on January 13, 2006.     Yes, the Trading Post is currently open.  
                     
Usable land placed in trust by Federal government     Yes, the Pawnee Nation currently holds land in trust where the Chilocco Casino will be built.     Yes, the Pawnee Nation is currently leasing land from tribal members, which is held in trust for the individual tribal members by the United States Government. The BIA approved the lease documents on January 13, 2006.     Yes, the Trading Post is currently open.  
                     
Usable county agreement, if applicable     N/A     N/A     N/A  
                     
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan     Yes     Yes     Yes  
                     

55


Table of Contents

                     
                     
 Critical Milestone     Chilocco Casino Project     Travel Plaza     Trading Post  
                     
NIGC approval of management contract in current and desired form     No, submitted to the NIGC for review on March 22, 2005. The NIGC approved publication of the Final EA in December 2005 and no comments were received during the required 30-day comment period from the public. The NIGC is now able to issue a FONSI and approve the management contract, which is expected to occur in the third quarter of fiscal 2006.     No, submitted to the NIGC for review on March 22, 2005. The NIGC approved publication of the Final EA in December 2005 and no comments were received during the required 30-day comment period from the public. The NIGC issued a FONSI in March 2006. The management contract is expected to be approved in the second quarter of fiscal 2006.     No, submitted to the NIGC for review on March 22, 2005. The NIGC has provided comments which the Tribe and Lakes have provided a response. The management contract is expected to be approved as early as the second quarter of fiscal 2006.  
                     
Resolution of all litigation and legal obstacles     None at this time.     None at this time.     None at this time.  
                     
Financing for construction     No, preliminary discussions with lending institutions has occurred and the Pawnee Nation will issue a request for proposal. A lender will be selected under this process in the second quarter of fiscal 2006.     No, The Pawnee Nation has received and approved, subject to minor negotiations, a commitment for financing from a lender for the desired amount. The intent is to close the loan in the second quarter of fiscal 2006.     None needed.  
                     
Any other significant project milestones or contingencies, the outcome of which could have a material affect on the probability of project completion as planned     No others known at this time by Lakes.     No others known at this time by Lakes.     No others known at this time by Lakes.  
                     
Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      Long-term assets have been recorded as it is considered probable that the three Pawnee Nation Projects will result in economic benefit to Lakes sufficient to recover Lakes investment. Based upon the above status of all primary milestones and the projected fees to be earned under the consulting agreements and management contracts, no impairment has been recorded. The Pawnee Trading Post is currently open and operating and the refurbishments were completed in the fourth quarter of fiscal 2005. The Pawnee Travel Plaza is currently open and expansion could be completed to include gaming as early as the fourth quarter of fiscal 2006. The Chilocco Casino project could open as early as mid 2007.

56


Table of Contents

Iowa Tribe of Oklahoma
Business arrangement:
      On March 15, 2005, the Company, through its wholly-owned subsidiaries, entered into consulting agreements and management contracts with the Iowa Tribe of Oklahoma, a federally recognized Indian Tribe, and The Iowa Tribe of Oklahoma, a federally-chartered corporation (collectively, the “Iowa Tribe”). The agreements are effective as of January 27, 2005. The Company will provide consulting services to assist the Iowa Tribe with two separate casino destinations in Oklahoma including (i) assisting in developing a new first class casino and ancillary amenities and facilities to be located on Indian land approximately 25 miles northeast of Oklahoma City along Route 66 (the “Development Project”); and (ii) assisting with operational efforts at the Iowa Tribe’s existing Cimarron Casino, located in Perkins Oklahoma (the “Cimarron Casino”). The Company will also provide management services for the Tribe’s casino operations at each location subject to regulatory approval.
      Each of the projects has a gaming consulting agreement (“Iowa Consulting Agreement”) and a management contract (“Iowa Management Contract”), independent of the other project. Key terms relating to the agreements for the projects are as follows:
      The Development Project. The proposed development would have an initial phase of approximately 1,500 slot machines, four restaurants, a KidsQuest, 250 hotel rooms and parking. Future development would include additional gaming, hotel rooms, meeting space, special events center, golf course and other market driven amenities. For its gaming development consulting services under the Iowa Consulting Agreement related to the Development Project, the Company will receive a development fee of two percent of the project costs of the Development Project, paid upon the opening of the Development Project, and a flat monthly fee of $500,000 for a period of 120 months commencing upon the opening of the project.
      The Company has agreed to make advances to the Iowa Tribe, subject to a project budget to be agreed upon by the Company and the Iowa Tribe and certain other conditions. The development loan will be for preliminary development costs under the Development Project budget. The Company has also agreed to use reasonable efforts to assist the Iowa Tribe in obtaining permanent financing for any projects developed under the Iowa Consulting Agreement.
      The Iowa Management Contract for the Development Project is subject to the approval of the NIGC and certain other conditions. For its performance under the Iowa Management Contract, the Company will be entitled to receive management fees of approximately 30% of net income, as defined in the agreement, for each month during the term of the Iowa Management Contract less any amounts earned by any Company affiliate for consulting on the Development Project. The Iowa Management Contract term is seven years from the first day that the Company is able to commence management of the Development Project gaming operations under all legal and regulatory requirements (the “Commencement Date”), provided that the Iowa Tribe has the right to buy out the remaining term of the Iowa Management Contract after the Development Project has been in continuous operation for 60 months, for an amount based on the then present value of estimated future management fees. If the Iowa Tribe elects to buy-out the contract, all outstanding amounts owed to Lakes become payable if not already paid. Subject to certain conditions, the Company agrees to make advances for the Development Project’s working capital requirements, if needed, during the first six months after the Commencement Date. The advances are to be repaid through an operating note payable from revenues generated by future operations of the Development Project bearing interest at two percent over the prime rate. The Company also agrees to fund any shortfall in certain minimum monthly Development Project payments to the Iowa Tribe by means of non-interest bearing advances under the same operating note.
      Cimarron Casino. The Iowa Tribe historically operated a 240 gaming machine and 200-seat bingo parlor located on the northern edge of Perkins, Oklahoma, approximately eight miles south of Stillwater, Oklahoma. The existing facility is being renovated to provide for space for 325 gaming machines, six table games, and a new snack bar. The Company has entered into a separate gaming consulting agreement (“Cimarron Consulting Agreement”) and management contract (“Cimarron Management Contract”) with the Iowa Tribe with respect to the Cimarron Casino. The NIGC approved the Cimarron Management

57


Table of Contents

Contract in April 2006. The fee under the Cimarron Consulting Agreement consisted entirely of a limited flat monthly fee of $50,000. The annual fee under the Cimarron Management Contract will be 30% of net income in excess of $4 million (reduced by any amounts earned by any Company affiliate for consulting services under the Cimarron Consulting Agreement).
      Arrangement with Consultant. The Company has executed an agreement stipulating that Kevin Kean will be compensated for his consulting services (relating to the Iowa Tribe) rendered to the Company. Under this arrangement, subject to Mr. Kean obtaining certain regulatory approvals, Mr. Kean will receive 20 percent of the Company’s fee compensation that is received under the Iowa Consulting Agreement, Cimarron Consulting Agreement, Iowa Management Contract and Cimarron Management Contract with the Iowa Tribe (i.e., six percent of the incremental total net income or 20 percent of the Company’s 30 percent share). This agreement provides that payments will be due to Mr. Kean when the Company is paid by the Iowa Tribe.
Lakes’ Evaluation of the two Iowa Tribe Projects:
      The following table outlines the status of each of the following primary milestones necessary to complete the Iowa Tribe projects as of April 2, 2006:
               
               
      Development Project     Cimarron Casino  
               
Federal recognition of the tribe     Yes     Yes  
               
Possession of usable land corresponding with needs based on the Company’s project plan     Yes, the Iowa Tribe is currently leasing and acquiring land from tribal members, which is held in trust for the individual tribal members by the United States Government. These transactions will need to be approved by the BIA.     Yes, currently an open casino.  
               
Usable land placed in trust by Federal government     Yes, the Iowa Tribe is currently leasing and acquiring land from tribal members, which is held in trust for the individual tribal members by the United States Government. These transactions will need to be approved by the BIA.     Yes, currently an open casino.  
               
Usable county agreement, if applicable     N/A     N/A  
               
Usable state compact that allows for gaming consistent with that outlined in the Company’s project plan     Yes     Yes  
               
NIGC approval of management contract in current and desired form     No, submitted to the NIGC for review on April 22, 2005. An EA will be prepared in order for the management contract to be approved, which is expected to be completed in late 2006.     No, however the NIGC approved the management contract in April 2006.  
               
Resolution of all litigation and legal obstacles     None at this time, the acquisition of other tribal land needs to be approved by the BIA.     None at this time. The first part of the refurbished casino opened in May 2006.  
               

58


Table of Contents

               
               
      Development Project     Cimarron Casino  
               
Financing for construction     No, preliminary discussions with lending institutions has occurred.     Permanent financing was obtained from a lending institution in December 2005 and Lakes was repaid all amounts outstanding under the business improvement loan.  
               
Any other significant project milestones or contingencies, the outcome of which could have a material affect on the probability of project completion as planned     No others known at this time by Lakes.     No others known at this time by Lakes.  
               
Lakes’ evaluation and conclusion regarding the above critical milestones and progress:
      Long-term assets have been recorded as it is considered probable that the two Iowa Tribe Projects will result in economic benefit to Lakes sufficient to recover Lakes’ investment. Based upon the above status of all primary milestones and the projected fees to be earned under the consulting agreements and management contracts, no impairment has been recorded. The Cimarron Casino is currently open and refurbishment of the casino could be completed as early as mid 2006. The Development Project could open as early as the first quarter of fiscal 2008.
Kickapoo Tribe
      Lakes entered into consulting agreements and management contracts with the Kickapoo Tribe effective January 2005 to improve the performance of the gaming operations conducted at the Kickapoo Tribe’s existing Lucky Eagle Casino in Eagle Pass, Texas, located approximately 140 miles southwest of San Antonio. During the third quarter of fiscal 2005 the Company’s relationship with the Kickapoo Tribe deteriorated and in November 2005, Lakes and the Kickapoo Tribe terminated their business relationship. Lakes recognized an impairment charge of $0.1 million related to the intangible asset related to the acquisition of the management contract during the third quarter of fiscal 2005. In addition during fiscal 2005, the Company recorded an unrealized loss on notes receivable of $6.2 million related to the Kickapoo project. Included in the $6.2 million are unrealized losses of approximately $3.9 million related to project costs incurred that Lakes may be required to pay as a result of the terminated relationship, and approximately $2.3 million related to advances made by Lakes on the note receivable from the Kickapoo Tribe. As of January 1, 2006, Lakes owns approximately 18 acres of land near the Kickapoo site with a cost basis of approximately $0.7 million.
      Lakes entered into a Letter of Settlement (“Settlement Agreement”) with the Kickapoo Tribe pursuant to which Lakes and the Kickapoo Tribe resolved all outstanding issues relating to the parties’ business relationship that was terminated in November 2005. Pursuant to the Settlement Agreement, during April 2006, Lakes received a cash payment of approximately $2.6 million as reimbursement for payments made directly by Lakes to vendors on behalf of the Kickapoo Tribe and the Kickapoo Tribe agreed to pay $0.6 million into an escrow to be released to Lakes at such time as Lakes transfers title to certain land owned by Lakes to the Kickapoo Tribe. The Company and the Kickapoo Tribe have agreed that title will transfer only after the Kickapoo Tribe assumes, settles or pays certain accounts payable to vendors related to the Kickapoo Tribe’s casino that remain on Lakes’ books, and once Lakes receives full releases for any liability thereto. As a result of the $2.6 million payment, Lakes revalued the note receivable from the Kickapoo Tribe at $2.6 million as of April 2, 2006, and a gain of that amount was recognized in the first quarter of 2006. The land transfer and related release of liabilities will be recognized in the period they occur. When the releases are received from the vendors the Company will recognize a gain. The Company does not have an estimate of when or if this will occur.

59


Table of Contents

      Litigation costs: The Company does not accrue for estimated future litigation defense costs, if any, to be incurred by the Company in connection with outstanding litigation and other disputed matters but instead, records such costs as the related legal and other services are rendered.
      Income taxes: In accordance with Statement of Financial Accounting Standards No. 109, Accounting for Income Taxes (SFAS 109), Lakes evaluated the ability to utilize deferred tax assets arising from net operating loss carry forwards, net deferred tax assets relating to Lakes’ accounting for advances made to Indian tribes and other ordinary items and determined that a valuation allowance was appropriate at April 2, 2006 and January 1, 2006. Lakes evaluated all evidence and determined the negative evidence relating to net losses generated over the past four years outweighed the current positive evidence that the Company believes exists surrounding its ability to generate significant income from its long-term assets related to Indian casino projects. The Company recorded a 100% valuation allowance against these items at April 2, 2006 and January 1, 2006 based upon the above factors. The Company has established deferred tax assets related to unrealized investment losses and related carryovers as of April 2, 2006 and January 1, 2006. The Company believes it will have sufficient capital gains in the foreseeable future to utilize these benefits due to significant appreciation in its investment in WPTE. The Company owns approximately 12.5 million shares of WPTE common stock valued at approximately $79.7 million as of May 2, 2006 based upon the closing stock price as reported by the Nasdaq National Market on May 2, 2006 of $6.39. Lakes’ basis in the WPTE common stock is minimal.
      Other Recent Accounting Pronouncements: In 2005, the Financial Accounting Standards Board (FASB) issued Statement of Financial Accounting Standards (SFAS) No 155, Accounting for Certain Hybrid Instruments amending the guidance in SFAS. 133, Accounting for Derivative Instruments and Hedging Activities, and No. 140, Accounting for Transfers and Servicing of Financial Assets and Extinguishments of Liabilities. SFAS 155 allows financial instruments that have embedded derivatives to be accounted for as a whole (eliminating the need to bifurcate the derivative from its host) if the holder elects to account for the whole instrument on a fair value basis. SFAS 155 will be effective for financial instruments acquired or issued during our fiscal year that begins after September 15, 2006. We presently do not expect SFAS 156 to be applicable to any instruments likely to be acquired or issued by us.
      In 2005, the FASB also issued SFAS 156, Accounting for Servicing of Financial Assets — An Amendment of FASB Statement No. 140. SFAS 156 further amends the guidance in SFAS 140, Accounting for Transfers and Servicing of Financial Assets and Extinguishments of Liabilities and, among other things, requires recognition of a servicing asset or servicing liability each time it undertakes an obligation to service a financial asset by entering into a servicing contract in certain situations. Statement 156 will be effective as of the beginning of an entity’s first fiscal year that begins after September 15, 2006. We presently do not expect SFAS 156 to be applicable to any of our activities.
Seasonality
      The Company believes that the operations of all casinos to be managed by the Company will be affected by seasonal factors, including holidays, weather and travel conditions. WPTE’s license revenues are affected by the timetable for delivery of episodes to TRV.
Regulation and taxes
      The Company and the casinos to be managed by the Company are subject to extensive regulation by state gaming authorities. The Company will also be subject to regulation, which may or may not be similar to current state regulations, by the appropriate authorities in any jurisdiction where it may conduct gaming activities in the future. Changes in applicable laws or regulations could have an adverse effect on the Company.
      The gaming industry represents a significant source of tax revenues to regulators. From time to time, various federal legislators and officials have proposed changes in tax law, or in the administration of such law, affecting the gaming industry. It is not possible to determine the likelihood of possible changes in tax law or in the administration of such law. Such changes, if adopted, could have a material adverse effect on the Company’s future financial position, results of operations and cash flows.

60


Table of Contents

Off-balance sheet arrangements
      The Company has no off-balance sheet arrangements that have or are reasonably likely to have a current or future effect on its financial condition, changes in financial condition, revenues or expenses, results of operations, liquidity, capital expenditures or capital resources that is material to investors, except for the financing commitments previously discussed.
Private Securities Litigation Reform Act
      The Private Securities Litigation Reform Act of 1995 provides a “safe harbor” for forward-looking statements. Certain information included in this Quarterly Report on Form 10-Q and other materials filed or to be filed by the Company with the SEC as well as information included in oral statements or other written statements made or to be made by the Company contain statements that are forward-looking, such as plans for future expansion and other business development activities as well as other statements regarding capital spending, financing sources and the effects of regulation (including gaming and tax regulation) and competition.
      Such forward looking information involves important risks and uncertainties that could significantly affect the anticipated results in the future and, accordingly, actual results may differ materially from those expressed in any forward-looking statements made by or on behalf of the Company.
      These risks and uncertainties include, but are not limited to, need for current financing to meet Lakes’ operational and development needs; those relating to the inability to complete or possible delays in completion of Lakes’ casino projects, including various regulatory approvals and numerous other conditions which must be satisfied before completion of these projects; possible termination or adverse modification of management contracts; Lakes operates in a highly competitive industry; possible changes in regulations; reliance on continued positive relationships with Indian tribes and repayment of amounts owed to Lakes by Indian tribes; possible need for future financing to meet Lakes’ expansion goals; risks of entry into new businesses; reliance on Lakes’ management; and the fact that WPTE shares held by Lakes are currently not liquid assets, and there is no assurance that Lakes will be able to realize value from these holdings equal to the current or future market value of WPTE common stock. There are also risks and uncertainties relating to WPTE that may have a material effect on the Company’s consolidated results of operations or the market value of the WPTE shares held by the Company, including WPTE’s significant dependence on the Travel Channel as a source of revenue; the potential that WPTE’s television programming will fail to maintain a sufficient audience; difficulty of predicting the growth of WPTE’s online casino business, which is a relatively new industry with an increasing number of market entrants; the risk that WPTE may not be able to protect its entertainment concepts, current and future brands and other intellectual property rights; the risk that competitors with greater financial resources or marketplace presence might develop television programming that would directly compete with WPTE’s television programming; the risk that WPTE may not be able to protect its entertainment concepts, current and future brands and other intellectual property rights; risks associated with future expansion into new or complementary businesses; the termination or impairment of WPTE’s relationships with key licensing and strategic partners; and WPTE’s dependence on its senior management team. For more information, review the Company’s filings with the SEC. For further information regarding the risks and uncertainties, see the “Risk Factors” section in Item 1A of the Company’s Annual Report on Form 10-K for the fiscal year ended January 1, 2006.
ITEM 3. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK
      The Company’s financial instruments include cash and cash equivalents and marketable securities. The Company’s main investment objectives are the preservation of investment capital and the maximization of after-tax returns on its investment portfolio. Consequently, the Company invests with only high-credit-quality issuers and limits the amount of credit exposure to any one issuer. The Company does not use derivative instruments for speculative or investment purposes.
      The Company’s cash and cash equivalents are not subject to significant interest rate risk due to the short maturities of these instruments. As of April 2, 2006, the carrying value of the Company’s cash and cash equivalents approximates fair value. The Company also holds short-term investments consisting of marketable debt securities (principally consisting of commercial paper, corporate bonds, and government securities)

61


Table of Contents

having a weighted average duration of one year or less. Consequently, such securities are not subject to significant interest rate risk.
      The Company’s primary exposure to market risk associated with changes in interest rates involves the Company’s long-term assets related to Indian casino projects in the form of notes receivable due from its tribal partners for the development and construction of Indian-owned casinos. The loans earn interest based upon a defined reference rate. The floating interest rate will generate more or less interest income if interest rates rise or fall.
      Lakes’ notes receivable from Indian tribes related to properties under development bear interest generally at prime plus one percent or two percent, however, the interest is only payable if the casino is successfully opened and distributable profits are available from casino operations. Lakes records its notes receivable at fair value and subsequent changes in fair value are recorded as income or expense in the Company’s consolidated statement of operations. As of April 2, 2006, Lakes had $102.9 million of notes receivable, at fair value with a floating interest rate (principal amount of $110.0 million, excluding advances to the Kickapoo Tribe). Based on the applicable current reference rates and assuming all other factors remain constant, interest income for a twelve month period would be approximately $10.2 million. A reference rate increase of 100 basis points would result in an increase in interest income of $1.1 million. A 100 basis point decrease in the reference rate would result in a decrease of $1.1 million in interest income over the same twelve-month period.
ITEM 4. CONTROLS AND PROCEDURES
      Under the supervision and with the participation of our management, including our chief executive officer and chief financial officer, we conducted an evaluation of our disclosure controls and procedures, as such term is defined under Rules 13a-15(e) or Rule 15d — 15(e) promulgated under the Securities Exchange Act of 1934, as of the end of the period covered by this quarterly report. Based on their evaluation, our chief executive officer and chief financial officer concluded that Lakes Entertainment, Inc.’s disclosure controls and procedures are effective.
      There have been no significant changes (including corrective actions with regard to significant deficiencies or material weaknesses) in our internal control over financial reporting during the three months ended April 2, 2006 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

62


Table of Contents

LAKES ENTERTAINMENT, INC. AND SUBSIDIARIES
Part II
Other Information
ITEM 1. LEGAL PROCEEDINGS
Slot machine litigation
      In 1994, William H. Poulos filed a class-action lawsuit in the United States District Court for the Middle District of Florida against various parties, including Lakes’ predecessor, Grand Casinos, and numerous other parties alleged to be casino operators or slot machine manufacturers. This lawsuit was followed by several additional lawsuits of the same nature against the same, as well as additional defendants, all of which were subsequently consolidated into a single class-action pending in the United States District Court for the District of Nevada. Following a court order dismissing all pending pleadings and allowing the plaintiffs to re-file a single complaint, a complaint has been filed containing substantially identical claims, alleging that the defendants fraudulently marketed and operated casino video poker machines and electronic slot machines, and asserting common law fraud and deceit, unjust enrichment and negligent misrepresentation and claims under the federal Racketeering-Influenced and Corrupt Organizations Act. Various motions were filed by the defendants seeking to have this new complaint dismissed or otherwise limited. In December 1997, the Court, in general, ruled on all motions in favor of the plaintiffs. The plaintiffs then filed a motion seeking class certification and the defendants opposed it. In June 2002, the District Court entered an order denying class certification. On August 10, 2004, the Ninth Circuit Court of Appeals affirmed the District Court’s denial of class certification. On September 14, 2005, the United States District Court for the District of Nevada granted the defendants’ motions for summary judgment, and judgment was entered against the plaintiffs on that same day. The plaintiffs have appealed the judgment dismissing their claims to the United States Ninth Circuit Court of Appeals. The briefing of the appeal is scheduled to be completed by early June 2006.
      The Company has not recorded any liability for this matter, as currently an estimate of any possible loss cannot be made. Management currently believes the final outcome of this matter is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
El Dorado County, California litigation
      On January 3, 2003, El Dorado County filed an action in the Superior Court of the State of California, seeking to prevent the construction of a highway interchange that was approved by a California state agency. The action, which was consolidated with a similar action brought by Voices for Rural Living and others, does not seek relief directly against Lakes. However, the interchange is necessary to permit the construction of a casino to be developed and managed by Lakes through a joint venture. The casino will be owned by the Shingle Springs Tribe. The matter was tried to the court on August 22, 2003. On January 2, 2004, Judge Lloyd G. Connelly, Judge of the Superior Court of the State of California, issued his ruling on the matter denying the petition in all respects except one. As to the one exception, the court sought clarification as to whether the transportation conformity determination used to determine the significance of the air quality impact of the interchange operations considered the impact on attainment of the state ambient air quality standard for ozone. The California Department of Transportation (CalTrans) prepared and filed the clarification addendum sought by the court. Prior to the court’s determination of the adequacy of the clarification, El Dorado County and Voices for Rural Living appealed Judge Connelly’s ruling to the California Court of Appeals on all of the remaining issues.
      A ruling with respect to the addendum was issued June 21, 2004 by the Superior Court of the State of California, County of Sacramento. The ruling indicated that the addendum provided to the court by CalTrans did not provide a quantitative showing to satisfy the court’s earlier request for a clarification on meeting the state ambient ozone standard. The court recognized that the information provided by CalTrans does qualitatively show that the project may comply with the state standard, but concluded that a quantitative analysis is necessary even though the court recognized that the methodology for that analysis “is not readily apparent”. In addition, the ruling specifically stated, “Moreover, such methodology appears necessary for the

63


Table of Contents

CEQA analysis of transportation projects throughout the state, including transportation projects for which respondents (i.e., CalTrans) have approval authority.” CalTrans, the Shingle Springs Tribe and Lakes responded to the court with a revised submission in August 2004. Representatives of the California Air Resources Board and the Sacramento Area Council of Governments filed declarations supporting the revised submission to the court. Opposition to that revised submission was filed, a hearing on the revised submission took place on August 20, 2004 and the court again found the revised submission of CalTrans, the Shingle Springs Tribe and Lakes to be inadequate. That ruling was separately appealed to the California Court of Appeals (the “Court”) and an oral argument for these appeals and the appeals of El Dorado County and Voices of Rural Living was held before the Court on August 29, 2005.
      The Court issued its decision on the appeals on November 8, 2005. The Court ruled in favor of CalTrans’ appeal, rejecting the El Dorado County’s argument that the transportation conformity analysis did not conform to state standards. The Court also rejected all but two of the legal claims asserted in the appeal by El Dorado County and Voices for Rural Living against the environmental impact report (“EIR”) prepared by CalTrans for the interchange that will connect Highway 50 to the Shingle Springs Rancheria. For the remaining two issues, the Court held that CalTrans must supplement its environmental analysis by adding some discussion to the air quality chapter to further explain the project’s contribution to overall vehicular emissions in the region, and that CalTrans also must evaluate whether a smaller casino and hotel would reduce environmental impacts. The Court acknowledged CalTrans lacks jurisdiction to require the Shingle Springs Tribe to develop a smaller casino, but nevertheless required some discussion of this alternative in the interchange EIR. On December 19, 2005, CalTrans filed a Petition for Review with the Supreme Court of the State of California, and on February 8, 2006 the Supreme Court denied the Petition for Review and ordered the Court of Appeals decision to be depublished. CalTrans is now preparing to comply with the Court of Appeals order.
      The Company has not recorded any liability for this matter as management currently believes that the Court’s rulings will ultimately allow the project to commence. However, there can be no assurance that the final outcome of this matter is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
WPTE litigation with TRV
      In late 2005 and early 2006, WPTE was involved in a dispute with the Travel Channel in connection with licensing the Professional Poker Tourtm, or the PPTtm for telecast. Under the WPT agreements between WPTE and the Travel Channel, the Travel Channel is afforded the right to negotiate with WPTE with respect to certain types of programming developed by WPTE during a sixty (60) day period. Pursuant to the WPT agreements, WPTE had submitted the PPT to the Travel Channel and began negotiations but failed to reach an agreement with the Travel Channel within the allotted negotiation window. Consequently, WPTE began discussions with other networks. While WPTE later revived its attempts to reach a deal with the Travel Channel after its exclusive bargaining window had ended, WPTE ultimately received an offer from another network. WPTE submitted this offer to the Travel Channel pursuant to its contractual last right to match the deal as specified under the WPT agreements. Thereafter, the Travel Channel sent letters to WPTE and the other broadcaster asserting, among other things, that WPTE was not entitled to complete a deal for the PPT with a third party.
      In response to the Travel Channel’s communications, WPTE filed suit in California Superior Court in September 2005, alleging that the Travel Channel had interfered with WPTE’s prospective contractual relationship with a third party as well as attempted to contravene WPTE’s express contractual right to produce non-World Poker Tour branded programs covering poker tournaments. After a series of motions and cross-motions between the parties, on January 25, 2006, WPTE settled the dispute and entered into a settlement agreement with the Travel Channel, as well as agreements with the Travel Channel with respect to certain amendments to the WPT agreements and the licensing of the PPT for telecast on the Travel Channel.

64


Table of Contents

Other litigation
      Lakes and its subsidiaries are involved in various other inquiries, administrative proceedings, and litigation relating to contracts and other matters arising in the normal course of business. While any proceeding or litigation has an element of uncertainty, management currently believes that the final outcome of these matters, including the matters discussed above, is not likely to have a material adverse effect upon the Company’s consolidated financial statements.
ITEM 1A. RISK FACTORS
      There have been no material changes to Lakes’ risk factors identified in the “Risk Factors” section in Item 1A of our Annual Report on Form 10-K for the fiscal year ended January 1, 2006 except that Lakes is no longer subject to the risk that its common stock may not be re-listed on the Nasdaq National Market. As previously announced, Lakes’ common stock resumed trading on the Nasdaq National Market on March 23, 2006 under the symbol “LACO.”
ITEM 6. EXHIBITS
      (a) Exhibits
         
  31 .1   Certification of CEO pursuant to Securities Exchange Act Rules 13a-15(e) and 15d-15(e) as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002
 
  31 .2   Certification of CFO pursuant to Securities Exchange Act Rules 13a-15(e) and 15d-15(e) as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002
 
  32 .1   Certification of Chief Executive Officer and Chief Financial Officer pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002

65


Table of Contents

SIGNATURES
      Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report on Form 10-Q to be signed on its behalf by the undersigned, thereunto duly authorized.
  LAKES ENTERTAINMENT, INC.
  Registrant
 
  /s/ LYLE BERMAN
 
 
  Lyle Berman
  Chairman of the Board and
  Chief Executive Officer
 
  /s/ TIMOTHY J. COPE
 
 
  Timothy J. Cope
  President and
  Chief Financial Officer
Dated: May 12, 2006

66 EX-31.1 2 c05297exv31w1.htm CERTIFICATION OF CEO PURSUANT TO SECTION 302 exv31w1

 

Exhibit 31.1
CERTIFICATIONS
I, Lyle Berman, certify that:
      1. I have reviewed this report on Form 10-Q of Lakes Entertainment, Inc.;
      2. Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this quarterly report;
      3. Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;
      4. The registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the registrant, and have:
        a. designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
 
        b. designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;
 
        c. evaluated the effectiveness of the registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and
 
        d. disclosed in this report any change in the registrant’s internal control over financial reporting that occurred during the registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the registrant’s internal control over financial reporting; and
      5. The registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant’s auditors and the audit committee of the registrant’s board of directors (or persons performing the equivalent functions):
        a. all significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant’s ability to record, process, summarize and report financial information; and
 
        b. any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant’s internal control over financial reporting.
  /s/ Lyle Berman
 
 
  Lyle Berman
  Chief Executive Officer
Date: May 12, 2006
EX-31.2 3 c05297exv31w2.htm CERTIFICATION OF CFO PURSUANT TO SECTION 302 exv31w2
 

Exhibit 31.2
CERTIFICATIONS
I, Timothy J. Cope, certify that:
      1. I have reviewed this report on Form 10-Q of Lakes Entertainment, Inc.;
      2. Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this quarterly report;
      3. Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;
      4. The registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the registrant, and have:
        a. designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;
 
        b. designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;
 
        c. evaluated the effectiveness of the registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and
 
        d. disclosed in this report any change in the registrant’s internal control over financial reporting that occurred during the registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the registrant’s internal control over financial reporting; and
      5. The registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant’s auditors and the audit committee of the registrant’s board of directors (or persons performing the equivalent functions):
        a. all significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant’s ability to record, process, summarize and report financial information; and
 
        b. any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant’s internal control over financial reporting.
  /s/ Timothy J. Cope
 
 
  Timothy J. Cope
  Chief Financial Officer
Date: May 12, 2006
EX-32.1 4 c05297exv32w1.htm CERTIFICATION OF CEO AND CFO PURSUANT TO SECTION 906 exv32w1
 

Exhibit 32.1
CERTIFICATION PURSUANT TO
18 U.S.C. §1350,
AS ADOPTED PURSUANT TO
SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002
      In connection with the Quarterly Report of Lakes Entertainment, Inc. (the “Company”) on Form 10-Q for the period ended April 2, 2006 as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, Lyle Berman, Chief Executive Officer of the Company, and Timothy J. Cope, Chief Financial Officer of the Company, certify, pursuant to 18 U.S.C. §1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that:
        1. The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and
 
        2. The information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.
  /s/ Lyle Berman
 
 
  Lyle Berman
  Chief Executive Officer
 
  /s/ Timothy J. Cope
 
 
  Timothy J. Cope
  Chief Financial Officer
May 12, 2006
-----END PRIVACY-ENHANCED MESSAGE-----