10-Q

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

FORM 10-Q

(Mark One)

☑ QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(D) OF THE SECURITIES EXCHANGE ACT OF 1934

For the Quarterly Period Ended October 31, 2020

or

☐ TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(D) OF THE SECURITIES EXCHANGE ACT

For the Transition Period from                      to                     

Commission File Number 001-31756

(Exact Name of Registrant as Specified in Its Charter)

Delaware	13-1947195
(State or Other Jurisdiction of Incorporation)	(I.R.S. Employer Identification No.)

One Church Street, Suite 201, Rockville, Maryland 20850

(Address of Principal Executive Offices) (Zip Code)

(301) 315-0027

(Registrant’s Telephone Number, Including Area Code)

(Former Name, Former Address and Former Fiscal Year, if Changed since Last Report)

Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15 (d) of the Securities Exchange Act of 1934 (the “Exchange Act”) during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.    Yes   þ    No  ☐

Indicate by check mark whether the Registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter period that the Registrant was required to submit such files).    Yes  þ    No  ☐

Indicate by check mark whether the Registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, smaller reporting company or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer ”, “smaller reporting company” and “emerging growth company” in Rule 12b-2 of the Exchange Act.

Large accelerated filer ☐  Accelerated filer þ  Non-accelerated filer ☐  Smaller reporting company ☐  Emerging growth company ☐

If an emerging growth company, indicate by check mark if the Registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐

Indicate by check mark whether the Registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).    Yes  ☐    No  ☑

Title of Each Class	Trading Symbol(s)	Name of Each Exchange on Which Registered
Common Stock, $.15 par value	AGX	New York Stock Exchange

Indicate the number of shares outstanding of each of the Registrant’s classes of common stock, as of the latest practicable date.

Common stock, $0.15 par value: 15,689,969 shares as of December 7, 2020.

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF EARNINGS

(In thousands, except per share data)

(Unaudited)

	Three Months Ended				Nine Months Ended
	October 31,				October 31,
	2020		2019		2020		2019
REVENUES	$	127,331	$	58,406	$	274,971	$	171,009
Cost of revenues		106,988		52,414		234,989		183,078
GROSS PROFIT (LOSS) (Note 2)		20,343		5,992		39,982		(12,069)
Selling, general and administrative expenses		9,398		12,135		28,827		31,761
Impairment loss		—		—		—		2,072
INCOME (LOSS) FROM OPERATIONS		10,945		(6,143)		11,155		(45,902)
Other income, net		175		3,578		1,714		7,472
INCOME (LOSS) BEFORE INCOME TAXES		11,120		(2,565)		12,869		(38,430)
Income tax (expense) benefit (Note 10)		(1,666)		(1,996)		1,391		4,936
NET INCOME (LOSS)		9,454		(4,561)		14,260		(33,494)
Net income (loss) attributable to non-controlling interests		—		2,294		(40)		2,007
NET INCOME (LOSS) ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.		9,454		(6,855)		14,300		(35,501)
Foreign currency translation adjustments		(321)		235		(650)		(825)
COMPREHENSIVE INCOME (LOSS) ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.	$	9,133	$	(6,620)	$	13,650	$	(36,326)
NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC. (Note 11)
Basic	$	0.60	$	(0.44)	$	0.91	$	(2.27)
Diluted	$	0.60	$	(0.44)	$	0.91	$	(2.27)
WEIGHTED AVERAGE NUMBER OF SHARES OUTSTANDING
Basic		15,680		15,633		15,659		15,617
Diluted		15,833		15,633		15,795		15,617
CASH DIVIDENDS PER SHARE (Note 12)	$	0.25	$	0.25	$	1.75	$	0.75

The accompanying notes are an integral part of these condensed consolidated financial statements.

2

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED BALANCE SHEETS

(Dollars in thousands, except per share data)

	October 31,		January 31,
	2020		2020
	(Unaudited)		(Note 1)
ASSETS
CURRENT ASSETS
Cash and cash equivalents	$	353,213	$	167,363
Short-term investments		90,017		160,499
Accounts receivable, net		30,607		37,192
Contract assets		27,223		33,379
Other current assets (Note 10)		37,760		23,322
TOTAL CURRENT ASSETS		538,820		421,755
Property, plant and equipment, net		20,966		22,539
Goodwill		27,943		27,943
Other purchased intangible assets, net		4,324		5,001
Deferred taxes		—		7,894
Right-of-use and other assets		3,447		2,408
TOTAL ASSETS	$	595,500	$	487,540
LIABILITIES AND EQUITY
CURRENT LIABILITIES
Accounts payable	$	48,836	$	35,442
Accrued expenses (Note 10)		51,650		35,907
Contract liabilities		160,544		72,685
TOTAL CURRENT LIABILITIES		261,030		144,034
Deferred taxes		472		—
Other noncurrent liabilities		3,334		2,476
TOTAL LIABILITIES		264,836		146,510
COMMITMENTS AND CONTINGENCIES (Notes 7 and 8)
STOCKHOLDERS’ EQUITY
Preferred stock, par value $0.10 per share – 500,000 shares authorized; no shares issued and outstanding		—		—
Common stock, par value $0.15 per share – 30,000,000 shares authorized; 15,693,202 and 15,638,202 shares issued at October 31 and January 31, 2020, respectively; 15,689,969 and 15,634,969 shares outstanding at October 31 and January 31, 2020, respectively		2,354		2,346
Additional paid-in capital		152,149		148,713
Retained earnings		176,186		189,306
Accumulated other comprehensive loss		(1,766)		(1,116)
TOTAL STOCKHOLDERS’ EQUITY		328,923		339,249
Non-controlling interests		1,741		1,781
TOTAL EQUITY		330,664		341,030
TOTAL LIABILITIES AND EQUITY	$	595,500	$	487,540

The accompanying notes are an integral part of these condensed consolidated financial statements.

3

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF STOCKHOLDERS’ EQUITY

FOR THE THREE AND NINE MONTHS ENDED OCTOBER 31, 2020 AND 2019

(Dollars in thousands)

(Unaudited)

	Common Stock			Additional				Accumulated
	Outstanding	Par		Paid-in		Retained		Other Comprehensive		Non-controlling		Total
	Shares	Value		Capital		Earnings		Loss		Interests		Equity
Balances, August 1, 2020	15,669,969	$	2,351	$	150,847	$	170,653	$	(1,445)	$	1,741	$	324,147
Net income	—		—		—		9,454		—		—		9,454
Foreign currency translation loss	—		—		—		—		(321)		—		(321)
Stock compensation expense	—		—		786		—		—		—		786
Stock option exercises	20,000		3		516		—		—		—		519
Cash dividends	—		—		—		(3,921)		—		—		(3,921)
Balances, October 31, 2020	15,689,969	$	2,354	$	152,149	$	176,186	$	(1,766)	$	1,741	$	330,664
Balances, August 1, 2019	15,633,302	$	2,346	$	147,445	$	211,167	$	(1,406)	$	(483)	$	359,069
Net (loss) income	—		—		—		(6,855)		—		2,294		(4,561)
Foreign currency translation gain	—		—		—		—		235		—		235
Stock compensation expense	—		—		586		—		—		—		586
Cash dividends	—		—		—		(3,911)		—		—		(3,911)
Balances, October 31, 2019	15,633,302	$	2,346	$	148,031	$	200,401	$	(1,171)	$	1,811	$	351,418
Balances, February 1, 2020	15,634,969	$	2,346	$	148,713	$	189,306	$	(1,116)	$	1,781	$	341,030
Net income (loss)	—		—		—		14,300		—		(40)		14,260
Foreign currency translation loss	—		—		—		—		(650)		—		(650)
Stock compensation expense	—		—		2,199		—		—		—		2,199
Stock option exercises	55,000		8		1,237		—		—		—		1,245
Cash dividends	—		—		—		(27,420)		—		—		(27,420)
Balances, October 31, 2020	15,689,969	$	2,354	$	152,149	$	176,186	$	(1,766)	$	1,741	$	330,664
Balances, February 1, 2019	15,573,869	$	2,337	$	144,961	$	247,616	$	(346)	$	(196)	$	394,372
Net (loss) income	—		—		—		(35,501)		—		2,007		(33,494)
Foreign currency translation loss	—		—		—		—		(825)		—		(825)
Stock compensation expense	—		—		1,512		—		—		—		1,512
Stock option exercises	59,433		9		1,558		—		—		—		1,567
Cash dividends	—		—		—		(11,714)		—		—		(11,714)
Balances, October 31, 2019	15,633,302	$	2,346	$	148,031	$	200,401	$	(1,171)	$	1,811	$	351,418

The accompanying notes are an integral part of these condensed consolidated financial statements.

4

ARGAN, INC. AND SUBSIDIARIES

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS

(In thousands)

(Unaudited)

	Nine Months Ended October 31,
	2020		2019
CASH FLOWS FROM OPERATING ACTIVITIES
Net income (loss)	$	14,260	$	(33,494)
Adjustments to reconcile net income (loss) to net cash provided by operating activities
Deferred income tax expense (benefit)		8,366		(4,521)
Depreciation		2,798		2,610
Stock compensation expense		2,199		1,512
Lease expense		1,318		637
Amortization of purchased intangible assets		677		864
Changes in accrued interest on short-term investments		482		1,106
Impairment loss		—		2,072
Other		111		60
Changes in operating assets and liabilities
Accounts receivable		6,585		1,274
Contract assets		6,156		7,992
Other assets		(15,976)		(1,760)
Accounts payable and accrued expenses		27,725		(12,523)
Contract liabilities		87,859		50,072
Net cash provided by operating activities		142,560		15,901
CASH FLOWS FROM INVESTING ACTIVITIES
Maturities of short-term investments		170,000		164,000
Purchases of short-term investments		(100,000)		(75,000)
Purchases of property, plant and equipment		(1,412)		(6,308)
Net cash provided by investing activities		68,588		82,692
CASH FLOWS FROM FINANCING ACTIVITIES
Payments of cash dividends		(27,420)		(11,714)
Proceeds from the exercise of stock options		1,245		1,567
Net cash used in financing activities		(26,175)		(10,147)
EFFECTS OF EXCHANGE RATE CHANGES ON CASH		877		(282)
NET INCREASE IN CASH AND CASH EQUIVALENTS		185,850		88,164
CASH AND CASH EQUIVALENTS, BEGINNING OF PERIOD		167,363		164,318
CASH AND CASH EQUIVALENTS, END OF PERIOD	$	353,213	$	252,482
SUPPLEMENTAL CASH FLOW INFORMATION (Notes 7 and 10)

The accompanying notes are an integral part of these condensed consolidated financial statements.

5

ARGAN, INC. AND SUBSIDIARIES

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

October 31, 2020

(Tabular dollar amounts in thousands, except per share data)

(Unaudited)

NOTE 1 – DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

Description of the Business

Argan, Inc. (“Argan”) conducts operations through its wholly-owned subsidiaries, Gemma Power Systems, LLC and affiliates (“GPS”); The Roberts Company, Inc. (“TRC”); Atlantic Projects Company Limited and affiliates (“APC”) and Southern Maryland Cable, Inc. (“SMC”). Argan and these consolidated subsidiaries are hereinafter collectively referred to as the “Company.”

Through GPS and APC, the Company provides a full range of engineering, procurement, construction, commissioning, operations management, maintenance, project development, technical and other consulting services to the power generation market, including the renewable energy sector. The wide range of customers includes independent power producers, public utilities, power plant equipment suppliers and global energy plant construction firms with projects located in the continental United States (the “US”), the Republic of Ireland (“Ireland”) and the United Kingdom (the “UK”). Including consolidated variable interest entities (“VIEs”), GPS and APC represent the Company’s power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southeast region of the US and that are based on its expertise in producing, delivering and installing fabricated metal components such as piping systems and pressure vessels. Through SMC, which conducts business as SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the mid-Atlantic region of the US.

Basis of Presentation and Significant Accounting Policies

The condensed consolidated financial statements include the accounts of Argan, its wholly-owned subsidiaries and its financially controlled VIEs. All significant inter-company balances and transactions have been eliminated in consolidation.

In Note 14, the Company has provided certain financial information relating to the operating results and assets of its reportable segments based on the manner in which management disaggregates the Company’s financial reporting for purposes of making internal operating decisions. The Company’s fiscal year ends on January 31 each year.

The condensed consolidated balance sheet as of October 31, 2020, the condensed consolidated statements of earnings and stockholders’ equity for the three and nine months ended October 31, 2020 and 2019, and the condensed consolidated statements of cash flows for the nine months ended October 31, 2020 and 2019 are unaudited. The condensed consolidated balance sheet as of January 31, 2020 has been derived from audited financial statements. These condensed consolidated financial statements have been prepared pursuant to the rules and regulations of the US Securities and Exchange Commission (the “SEC”). Certain information and note disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America (“US GAAP”) have been condensed or omitted pursuant to those rules and regulations, although the Company believes that the disclosures made are adequate to make the information not misleading. The accompanying condensed consolidated financial statements and notes should be read in conjunction with the consolidated financial statements, the notes thereto, and the independent registered public accounting firm’s report thereon, that are included in the Company’s Annual Report on Form 10-K for the fiscal year ended January 31, 2020 (“Fiscal 2020”).

In the opinion of management, the accompanying condensed consolidated financial statements contain all adjustments, which are of a normal and recurring nature, considered necessary to present fairly the financial position of the Company as of October 31, 2020, and its earnings and cash flows for the interim periods presented. The results of operations for any interim period are not necessarily indicative of the results of operations for any other interim period or for a full fiscal year.

6

Accounting Policies

In December 2019, the Financial Accounting Standards Board (the “FASB”) issued Accounting Standards Update (“ASU”) 2019-12, Simplifying the Accounting for Income Taxes, which, among other changes, eliminates the exception to the general methodology for calculating income taxes in an interim period when a year-to-date loss exceeds the expected loss for the entire year. In these instances, the estimated annual effective income tax rate shall be used to calculate the tax without limitation. The new standard also requires the recognition of a franchise (or similar) tax that is partially based on income as an income-based tax and the recording of any incremental tax that is incurred by the Company as a non-income based tax. The requirements of this new guidance, effective for the Company on February 1, 2021, are not expected to alter the Company’s current accounting for income taxes.

In 2016, the FASB issued ASU 2016-13, Measurement of Credit Losses on Financial Instruments. The requirements of this new standard cover, among other provisions, the methods that businesses shall use to estimate amounts of uncollectible notes and accounts receivable. Adoption of this new guidance, which became effective for the Company on February 1, 2020, did not affect the Company's consolidated financial statements.

There are no other recently issued accounting pronouncements that have not yet been adopted that the Company considers material to its condensed consolidated financial statements.

The carrying value amounts presented in the condensed consolidated balance sheets for the Company’s current assets, which primarily include cash and cash equivalents, short-term investments, accounts receivable and contract assets, and its current liabilities are reasonable estimates of their fair values due to the short-term nature of these items.

Variable Interest Entity

In January 2018, the Company was deemed to be the primary beneficiary of a VIE that is performing the project development activities related to the planned construction of a new natural gas-fired power plant. Consideration for the Company’s engineering and financial support includes the right to build the power plant pursuant to a turnkey engineering, procurement and construction (“EPC”) services contract that has been negotiated and announced. The account balances of the VIE are included in the condensed consolidated financial statements, including development costs incurred by the VIE during the three and nine-month periods ended October 31, 2020 and 2019. The total amounts of the project development costs included in the balances for property, plant and equipment as of October 31 and January 31, 2020 were $7.4 million and $6.9 million, respectively. Recovery of the Company's investment in this project will most likely depend on the successful completion of the project development efforts, including the arrangement of financing for the construction and operation of the corresponding power plant.

NOTE 2 – REVENUES FROM CONTRACTS WITH CUSTOMERS

The Company’s recognition of revenues under contracts with customers is based on a single comprehensive five-step model that requires reporting entities to:

1. Identify the contract,

2. Identify the performance obligations of the contract,

3. Determine the transaction price of the contract,

4. Allocate the transaction price to the performance obligations, and

5. Recognize revenue.

Major provisions of the standard cover the determination of which goods and services are distinct and represent separate performance obligations, the evaluation of whether revenues should be recognized at a point in time or over time, and the appropriate treatment for variable consideration.

The Company’s revenues are recognized primarily under various types of long-term construction contracts, including those for which revenues are based on either a fixed-price or a time-and-materials basis, and are primarily recognized over time as performance obligations are satisfied due to the continuous transfer of control to the project owner or other customer. Revenues from fixed-price contracts, including a portion of estimated gross profit, are recognized as services are provided, based on costs incurred and estimated total contract costs using the percentage-of-completion method.

7

If, at any time, the estimate of contract profitability indicates an anticipated loss on a contract, the Company will recognize the total loss in the reporting period that it is identified and an amount is estimable. Revenues from time-and-materials contracts are recognized when the related services are provided to the customer.

Almost all of the Company’s fixed-price contracts are considered to have a single performance obligation. Although multiple promises to transfer individual goods or services may exist, they are not typically distinct within the context of such contracts because contract promises included therein are interrelated or the contracts require the Company to perform critical integration so that the customer receives a completed project. The Company’s accounting for its assurance-type warranties provided under contracts with customers is conducted in accordance with the specific professional guidance established to cover such arrangements.

The transaction price for a contract represents the accounting value of the contract awarded to the Company that is used to determine the amount of revenues recognized as of the balance sheet date. It may reflect amounts of variable consideration, which could be either increases or decreases to the transaction price. These adjustments can be made from time-to-time during the period of contract performance as circumstances evolve related to such items as changes in the scope and price of contracts, claims, incentives and liquidated damages.

Contract assets generally include amounts that represent the rights to receive payment for goods or services that have been transferred to the project owner, with the rights conditional upon something other than the passage of time. Contract liabilities generally include the amounts that reflect obligations to provide goods or services for which payment has been received. The balances of accounts receivable exclude billed amounts which, pursuant to the terms of the applicable contract, are not paid by project owners until a defined phase of a contract or project has been completed and accepted. These retained amounts are reflected in contract assets or contract liabilities depending on the net contract position of the particular contract. Retention amounts and the length of retention periods may vary. Retention amounts related to active contracts are considered current regardless of the term of the applicable contract; such amounts are generally collected by the completion of the applicable contract. The total of amounts retained by project owners under construction contracts at October 31 and January 31, 2020 were $32.5 million and $20.0 million, respectively.

Variable Consideration

Amounts for contract variations for which the Company has project-owner directive for additional work or other scope change, but not for the price associated with the corresponding additional effort, are included in the transaction price when it is considered probable that the applicable costs will be recovered through a modification to the contract price. The effects of any revision to a transaction price can be determined at any time and they could be material. The Company may include in the corresponding transaction price a portion of the amount claimed in a dispute that it expects to receive from a project owner. Once a settlement of the dispute has been reached with the project owner, the transaction price may be revised again to reflect the final resolution. The aggregate amount of such contract variations included in the transaction prices that were used to determine project-to-date revenues at October 31, 2020 and January 31, 2020 were $8.0 million and $21.2 million, respectively. Variations related to the Company’s contracts typically represent modifications to the existing contracts and performance obligations, and do not represent new performance obligations. Actual costs related to any changes in the scope of the corresponding contract are expensed as they are incurred. Changes to total estimated contract costs and losses, if any, are reflected in operating results for the period in which they are determined.

The Company’s long-term contracts typically have schedule dates and other performance objectives that if not achieved could subject the Company to liquidated damages. At the outset of each of the Company’s contracts, the potential amounts of liquidated damages typically are not constrained, or subtracted, from the transaction price as the Company believes that it has included activities in its contract plan, and the associated costs, that will be effective in preventing such damages. Of course, circumstances may change as the Company executes the corresponding contract.

The transaction price is reduced by an applicable amount when the Company no longer considers it probable that a future reversal of revenues will not occur when the matter is resolved. The Company considers potential liquidated damages, the costs of other related items and potential mitigating factors in determining the adequacy of its regularly updated estimates of the amounts of gross profit expected to be earned on active projects.

8

The Company records adjustments to revenues and profits on contracts, including those associated with contract variations and estimated cost changes, using a cumulative catch-up method. Under this method, the impact of an adjustment to the amount of revenues recognized to date is recorded in the period that the adjustment is identified. Estimated variable consideration amounts are determined by the Company based primarily on the single most likely amount in the range of possible consideration amounts. Revenues and profits in future periods of contract performance are recognized using the adjusted amounts of transaction price and estimated contract costs.

Accounting for the Loss Subcontract

In its Form 10-K Annual Report for the year ended January 31, 2019 (“Fiscal 2019”), the Company disclosed that APC was completing the mechanical installation of the boiler for a biomass-fired power plant under construction in Teesside, England (the “TeesREP Project”) that had encountered significant operational and contractual challenges. The consolidated operating results for the year ended January 31, 2019 reflected unfavorable gross profit adjustments related to this project. The disclosure explained that the construction project was behind the schedule originally established for the job and warned that the TeesREP Project may continue to impact the Company’s consolidated operating results negatively until it reaches completion.

Subsequent to the release of the Company’s consolidated financial statements for Fiscal 2019, APC’s estimates of the costs of the unfavorable financial impacts of the difficulties on the TeesREP Project escalated substantially. For the nine-month period ended October 31, 2019, the Company recorded a loss related to this project in the amount of $31.2 million, including $0.3 million recorded in the three months ended October 31, 2019, and reversed profit in the amount of $0.7 million that had been recorded in prior fiscal years.

Construction activities on the TeesREP Project were suspended on March 24, 2020 due to the COVID-19 pandemic. At that time, APC had completed approximately 90% of its subcontracted work. As a condition for resuming its efforts on the TeesREP Project, APC entered into an amendment to the subcontract with its customer, effective June 1, 2020, covering the various terms and conditions for completion of the installation of the boiler (“Amendment No. 2”). The agreement represented a global settlement of past commercial differences with both parties making significant concessions, and converted the billing arrangements for the remaining work to a time-and-materials basis.

Amendment No. 2 was treated as a modification of the original subcontract as the arrangement continued to represent a single performance obligation to its customer, the delivery of a complete functioning and integrated boiler that was only partially satisfied when the modification to the subcontract occurred. During October 2020, APC and its customer agreed to additional contractual changes that effectively recognized APC’s completion of the single performance obligation and that establishes a time-and-materials contractual arrangement covering all works requested by APC’s customer until completion of the power plant construction.

The effects of these changes on the financial results reported for the subcontract were the primary reasons for the reductions to the subcontract loss that were recorded during the three and nine months ended October 31, 2020, in the approximate favorable amounts of $2.8 million and $4.1 million, respectively. Accordingly, the final amount of the TeesREP fixed price subcontract loss was $29.5 million, and the remaining subcontract loss reserve balance was eliminated as of October 31, 2020. At January 31, 2020, the subcontract loss reserve balance was $5.8 million. This balance was included in accrued expenses in the accompanying condensed consolidated balance sheet. Final closeout adjustments may result in future changes in the amount of the subcontract loss recognized as of October 31, 2020; however, APC has included an estimate of these costs in accrued expenses in the accompanying condensed consolidated balance sheet as of October 31, 2020. The total amounts of accounts receivable and contract assets related to the TeesREP Project and included in the condensed consolidated balance sheets were $7.3 million as of October 31, 2020 and $19.2 million as of January 31, 2020.

Remaining Unsatisfied Performance Obligations (“RUPO”)

The amount of RUPO represents the unrecognized revenue value of active contracts with customers as determined under the revenue recognition rules of US GAAP. Increases to RUPO during a reporting period represent the transaction prices associated with new contracts, as well as additions to the transaction prices of existing contracts. The amounts of such changes may vary significantly each reporting period based on the timing of major new contract awards and the occurrence and assessment of contract variations.

9

At October 31, 2020, the Company had RUPO of $604.7 million. The largest portion of RUPO at any date usually relates to EPC service contracts with typical performance durations of 2 to 3 years. However, the length of certain significant construction projects may exceed three years. The Company estimates that approximately 63% of the RUPO amount at October 31, 2020 will be included in the amount of consolidated revenues that will be recognized over the next twelve months. Most of the remaining amount of the RUPO amount at October 31, 2020 is expected to be recognized in revenues over the following eighteen months.

Revenues for future periods will also include amounts related to customer contracts started or awarded subsequent to October 31, 2020. It is important to note that estimates may be changed in the future and that cancellations, deferrals, scope adjustments may occur related to work included in the amount of RUPO at October 31, 2020. Accordingly, RUPO may be adjusted to reflect project delays and cancellations, revisions to project scope and cost and foreign currency exchange fluctuations, or to revise estimates, as effects become known. Such adjustments may materially reduce future revenues below Company estimates.

Disaggregation of Revenues

The following table presents consolidated revenues for the three and nine months ended October 31, 2020 and 2019, disaggregated by the geographic area where the corresponding projects were located:

	Three Months Ended				Nine Months Ended
	October 31,				October 31,
	2020		2019		2020		2019
United States	$	109,241	$	39,629	$	241,616	$	117,045
United Kingdom		9,759		10,349		22,595		35,631
Republic of Ireland		8,331		8,256		10,760		18,007
Other		—		172		—		326
Consolidated Revenues	$	127,331	$	58,406	$	274,971	$	171,009

Each year, the majority of consolidated revenues are recognized pursuant to fixed-price contracts with most of the remaining portions earned pursuant to time-and-material contracts. Consolidated revenues are disaggregated by reportable segment in Note 14 to the condensed consolidated financial statements.

NOTE 3 – CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

At October 31 and January 31, 2020, significant amounts of cash and cash equivalents were invested in mutual funds with net assets invested in high-quality money market instruments. Such investments include US Treasury obligations; obligations of US government agencies, authorities, instrumentalities or sponsored enterprises; and repurchase agreements secured by US government obligations. Due to market conditions, returns on money market instruments are currently minimal. The Company considers all liquid investments with original maturities of three months or less at the time of purchase to be cash equivalents.

Short-term investments as of October 31 and January 31, 2020 consisted solely of certificates of deposit purchased from Bank of America (the “Bank”) with weighted average initial maturities of 292 days and 165 days, respectively (the “CDs”). The Company has the intent and ability to hold the CDs until they mature, and they are carried at cost plus accrued interest which approximates fair value. The total carrying value amounts as of October 31 and January 31, 2020 included accrued interest, which was $0.5 million at January 31, 2020. The amount of accrued interest at October 31, 2020 was insignificant. Interest income is recorded when earned and is included in other income. At October 31 and January 31, 2020, the weighted average annual interest rates of the outstanding CDs were 0.2% and 1.8%, respectively.

In addition, the Company has a substantial portion of its cash on deposit in the US at the Bank in excess of federally insured limits. Management does not believe that the combined amount of the CD investments and the cash deposited with the Bank represents a material risk. The Company also maintain certain Euro-based bank accounts in Ireland and certain pound sterling-based bank accounts in the UK in support of the operations of APC.

10

NOTE 4 – ACCOUNTS AND NOTES RECEIVABLE

The Company generally extends credit to a customer based on an evaluation of the customer’s financial condition without requiring tangible collateral. Exposure to losses on accounts and notes receivable is expected to differ due to the varying financial condition of each customer. The Company monitors its exposure to credit losses and may establish an allowance for a credit loss based on management’s estimate of the loss that is expected to occur over the remaining life of the particular financial asset. At October 31 and January 31, 2020, the amounts of credit losses expected by management were insignificant. The amounts of the provision for credit losses for the three and nine months ended October 31, 2020 and the provision for uncollectible accounts for the three and nine months ended October 31, 2019 were also insignificant.

As of October 31, 2020, there were outstanding invoices billed to one former customer and unbilled costs incurred on the related project, with balances included in accounts receivable and contract assets, in the aggregate amount of $24.5 million, for which the recovery time will most likely depend on the resolution of the outstanding legal dispute between the parties (see Note 8).

As of October 31, 2020, there were past due notes receivable from project developers in the aggregate amount of $1.7 million, for which full receipt will most likely depend on the successful financing of the related projects.

NOTE 5 – PURCHASED INTANGIBLE ASSETS

At both October 31, 2020 and January 31, 2020, the goodwill balances related to the acquisitions of GPS and TRC were $18.5 million and $9.5 million, respectively. Primarily due to the significant reduction of the fair value of the business of APC deemed to have occurred as a result of the substantial contract loss discussed in Note 2 above, the Company recorded an impairment loss in the first quarter ended April 30, 2019 in the amount of $2.1 million, which was the remaining balance of goodwill associated with APC. No other changes were made to the balances of goodwill during the nine-month periods ended October 31, 2020 or 2019. Management does not believe that any events or circumstances that have occurred or arisen since January 31, 2020 require an updated assessment of the goodwill balances of either GPS or TRC.

The Company’s purchased intangible assets, other than goodwill, consisted of the following elements as of October 31 and January 31, 2020:

		October 31, 2020						January 31,
	Estimated	Gross		Accumulated		Net		2020, (net
	Useful Life	Amounts		Amortization		Amount		amounts)
Trade names	15 years	$	8,142	$	4,849	$	3,293	$	3,699
Process certifications	7 years		1,897		1,332		565		768
Customer relationships	4-10 years		1,346		880		466		534
Totals		$	11,385	$	7,061	$	4,324	$	5,001

NOTE 6 – FINANCING ARRANGEMENTS

The Company maintains financing arrangements with the Bank that are described in an Amended and Restated Replacement Credit Agreement (the “Credit Agreement”), dated May 15, 2017. The Credit Agreement provides a revolving loan with a maximum borrowing amount of $50.0 million that is available until May 31, 2021 with interest at the 30-day London Interbank Offered Rate (“LIBOR”) plus 2.0%. The Company may also use the borrowing ability to cover other credit instruments issued by the Bank for the Company’s use in the ordinary course of business. As of October 31 and January 31, 2020, the Company had letters of credit outstanding under the Credit Agreement, but no borrowings, in the approximate amounts of $1.7 million and $9.9 million, respectively. The Company expects that it will negotiate either an extension or a replacement agreement prior to the current expiration date of the Credit Agreement.

The Company has pledged the majority of its assets to secure its financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Bank requires that the Company comply with certain financial covenants at its fiscal year-end and at each of its fiscal quarter-ends. The Credit Agreement also includes other terms, covenants and events of default that are customary for a credit facility of its size and nature. As of October 31 and January 31, 2020, the Company was in compliance with the financial covenants.

11

In support of the current project development activities of the VIE described in Note 1, the Bank issued a letter of credit, outside the scope of the Credit Agreement, in the amount of $3.4 million for which the Company has provided cash collateral.

NOTE 7 – COMMITMENTS

Leases

The Company determines if a contract is or contains a lease at inception or upon modification of the contract. A contract is or contains a lease if it conveys the right to control the use of an identified asset for a period in exchange for consideration. Control over the use of the identified asset means the lessee has both (a) the right to obtain substantially all of the economic benefits from the use of the asset and (b) the right to direct the use of the asset. The Company does not apply this accounting to those leases with terms of twelve (12) months or less and that do not include options to purchase the underlying assets that the Company is reasonably certain to exercise.

The Company’s operating leases primarily cover office space that expire on various dates through May 2024 and certain equipment used by the Company in the performance of its construction services contracts. Other construction equipment is rented, with periods of expected usage less than one year, or owned. Certain leases contain renewal options, which are included in expected lease terms if they are reasonably certain of being exercised by the Company. Other equipment leases are embedded in broader arrangements with subcontractors or construction equipment suppliers. The Company has no finance leases.

None of the operating leases include significant amounts for incentives, rent holidays or price escalations. Under certain lease agreements, the Company is obligated to pay property taxes, insurance, and maintenance costs.

Operating lease right-of-use assets and associated lease liabilities are recognized in the balance sheet at the lease commencement date based on the present value of future minimum lease payments to be made over the expected lease term. As the implicit rate is not determinable in most of the Company’s leases, management uses the Company’s incremental borrowing rate (LIBOR plus 2.0%) at the commencement date in determining the present value of future payments. The expected lease term includes an option to extend or to terminate the lease when it is reasonably certain that the Company will exercise such option.

Lease expense for minimum lease payments is recognized on a straight-line basis over the expected lease term. Operating lease expense amounts for the three months ended October 31, 2020 and 2019 were $0.5 million and $0.1 million, respectively. Operating lease expense amounts for the nine months ended October 31, 2020 and 2019 were $1.3 million and $0.6 million, respectively. Operating lease payments for the three months ended October 31, 2020 and 2019 were $0.3 million and $0.2 million, respectively. Operating lease payments for the nine months ended October 31, 2020 and 2019 were $1.2 million and $0.6 million, respectively. For operating leases as of October 31, 2020, the weighted average lease term is 32 months and the weighted average discount rate is 3.3%.

The Company also uses equipment and occupies facilities under short-term rental agreements. Rent expense amounts incurred under operating leases and short-term rental agreements (including portions of the lease expense amounts disclosed above) and included in costs of revenues for the three and nine months ended October 31, 2020 were $2.3 million and $4.2 million, respectively. Rent expense incurred under these types of arrangements and included in costs of revenues for the three and nine months ended October 31, 2019 was $0.9 million and $3.2 million, respectively. Rent expense included in selling, general and administrative expenses for the three and nine months ended October 31, 2020 was $0.2 million and $0.7 million, respectively. Rent expense included in selling, general and administrative expenses for the three and nine months ended October 31, 2019 was $0.1 million and $0.5 million, respectively.

12

The following is a schedule of future minimum lease payments for the operating leases that were recognized in the condensed consolidated balance sheet as of October 31, 2020, including operating leases added during the three and nine months ended October 31, 2020 in the amounts of approximately $0.5 million and $2.3 million, respectively, covering primarily certain construction-site assets required by GPS:

Years Ending January 31,
Remainder of 2021	$	505
2022		1,648
2023		856
2024		242
2025		85
Thereafter		20
Total lease payments		3,356
Less interest portion		90
Present value of lease payments		3,266
Less current portion (included in accrued expenses)		2,760
Non-current portion	$	506

The future minimum lease payments presented above include amounts due under a long-term lease covering the primary offices and plant for TRC with the founder and current chief executive officer of TRC at an annual rate of $0.3 million through April 30, 2021.

Performance Bonds and Guarantees

In the normal course of business and for certain major projects, the Company may be required to obtain surety or performance bonding, to cause the issuance of letters of credit, or to provide parent company guarantees (or some combination thereof) in order to provide performance assurances to clients on behalf of its contractor subsidiaries. As these subsidiaries are wholly-owned, any actual liability is ordinarily reflected in the financial statement account balances determined pursuant to the Company’s accounting for contracts with customers. When sufficient information about claims on guaranteed or bonded projects would be available and monetary damages or other costs or losses would be determined to be probable, the Company would record such losses. Any amounts that may be required to be paid in excess of the estimated costs to complete contracts in progress as of October 31, 2020 are not estimable.

On behalf of APC, Argan has provided a parent company performance guarantee to its customer, the EPC services contractor on the TeesREP Project. Earlier this year, and in connection with the negotiation of Amendment No. 2, the Company replaced an outstanding letter of credit in the amount of $7.6 million with a surety bond.

As of October 31, 2020, the Company has also provided a financial guarantee, subject to certain terms and conditions, on behalf of GPS to an original equipment manufacturer in the amount of $3.6 million in support of business development efforts. The fair value of this guarantee at October 31, 2020 is considered to be immaterial.

Warranties

The Company generally provides assurance-type warranties for work performed under its construction contracts. The warranties cover defects in equipment, materials, design or workmanship, and most warranty periods typically run from nine to twenty-four months after the completion of construction on a particular project. Because of the nature of the Company’s projects, including project owner inspections of the work both during construction and prior to substantial completion, the Company has not experienced material unexpected warranty costs in the past. Warranty costs are estimated based on experience with the type of work and any known risks relative to each completed project. The accruals of liabilities, which are established to cover estimated future warranty costs, are recorded as the contracted work is performed, and they are included in the amounts of accrued expenses in the condensed consolidated balances sheets. The liability amounts may be periodically adjusted to reflect changes in the estimated size and number of expected warranty claims.

13

NOTE 8 – LEGAL CONTINGENCIES

In the normal course of business, the Company may have pending claims and legal proceedings. In the opinion of management, based on information available at this time, there are no current claims and proceedings that could have a material adverse effect on the condensed consolidated financial statements except for the matter described below.

In January 2019, GPS filed a lawsuit against Exelon West Medway II, LLC and Exelon Generation Company, LLC (together referred to as “Exelon”) for Exelon’s breach of contract and failure to remedy various conditions which negatively impacted the schedule and the costs associated with the construction by GPS of a gas-fired power plant for Exelon in Massachusetts. As a result, the Company believes that Exelon has received the benefits of the construction efforts of GPS and the corresponding progress made on the project without making payments to GPS for the value received (see Note 4). In March 2019, Exelon provided GPS with a notice intending to terminate the EPC contract under which GPS had been providing services to Exelon. At that time, the construction project was nearly complete and both of the power generation units included in the plant had successfully reached first fire. The completion of various prescribed performance tests and the clearance of punch-list items were the primary tasks necessary to be accomplished by GPS in order to achieve substantial completion of the power plant. Nevertheless, and among other actions, Exelon provided contractual notice requiring GPS to vacate the construction site. Exelon has asserted that GPS failed to fulfill certain obligations under the contract and was in default, withholding payments from GPS on invoices rendered to Exelon in accordance with the terms of the contract between the parties.

With vigor, GPS intends to continue to assert its rights under the EPC contract with Exelon, to pursue the collection of amounts owed under the EPC contract and to defend itself against the allegations that GPS did not perform in accordance with the contract. During the nine months ended October 31, 2020, most of the litigation activities of the legal teams has focused on the completion of discovery. The difficulties experienced by the legal teams in completing certain discovery activities, due in part to COVID-19 restrictions, resulted in the court granting extensions of the discovery period which is now closed for both parties. The next phase of the case is pre-trial. The Company expects that a mediation will be scheduled for Spring 2021. If the mediation is not successful in resolving the disputes, then the Company expects that trial will occur during the mid-to-late Summer 2021.

NOTE 9 – STOCK-BASED COMPENSATION

The Company’s board of directors may make awards under the 2011 Stock Plan (the “2011 Plan”) or the 2020 Stock Plan (the “2020 Plan”) to officers, directors and key employees (together, the “Stock Plans”). On June 23, 2020, the Company’s stockholders approved the adoption of the 2020 Plan, and the allocation of 500,000 shares of the Company’s common stock for issuance thereunder, which had been established by the Company’s board of directors earlier in the current year. The 2020 Plan will serve to replace the 2011 Plan; the Company’s authority to make awards pursuant to the 2011 Plan will expire on July 19, 2021.

The features of the 2020 Plan are similar to those included in the 2011 Plan. Awards may include nonqualified stock options, incentive stock options,  and restricted or unrestricted stock. The specific provisions for each award made pursuant to the terms of the Stock Plans are documented in a written agreement between the Company and the awardee. All stock options awarded under the Stock Plans shall have an exercise price per share at least equal to the common stock’s market value on the date of grant. Stock options shall have terms no longer than ten years. Typically, stock options are awarded with one-third of each stock option vesting on each of the first three anniversaries of the corresponding award date. As of October 31, 2020, there were approximately 2,170,400 shares of the Company’s common stock reserved for issuance under the Stock Plans; this number includes 688,999 shares of common stock available for future awards.

14

Summaries of stock option activity under the Company’s approved stock option plans for the nine months ended October 31, 2020 and 2019, along with corresponding weighted average per share amounts, are presented below (shares in thousands):

		Exercise		Remaining
	Shares	Price		Term (years)	Fair Value
Outstanding, February 1, 2020	1,271	$	44.83	7.18	$	11.06
Granted	172	$	33.81
Exercised	(55)	$	22.69
Forfeited	(24)	$	55.61
Outstanding, October 31, 2020	1,364	$	44.14	6.96	$	10.52
Exercisable, October 31, 2020	865	$	46.40	5.97	$	11.76
		Exercise		Remaining
	Shares	Price		Term (years)	Fair Value
Outstanding, February 1, 2019	1,140	$	44.01	7.54	$	11.22
Granted	168	$	46.67
Exercised	(59)	$	26.36
Forfeited	(38)	$	46.34
Outstanding, October 31, 2019	1,211	$	45.18	7.28	$	11.27
Exercisable, October 31, 2019	753	$	45.81	6.25	$	10.22

The changes in the number of non-vested options to purchase shares of common stock for the nine months ended October 31, 2020 and 2019, and the weighted average fair value per share for each number, are presented below (shares in thousands):

	Shares	Fair Value
Non-vested, February 1, 2020	448	$	9.74
Granted	172	$	5.68
Vested	(112)	$	9.81
Forfeitures	(9)	$	8.08
Non-vested, October 31, 2020	499	$	8.35
	Shares	Fair Value
Non-vested, February 1, 2019	375	$	10.05
Granted	168	$	10.32
Vested	(57)	$	9.28
Forfeitures	(28)	$	10.47
Non-vested, October 31, 2019	458	$	10.22

Pursuant to the terms of the 2011 Plan and as described in the corresponding agreements with the executives, the Company awarded performance-based restricted stock units to two senior executives in April 2020, 2019 and 2018 covering  45,000, 36,000 and 36,000 maximum total numbers of shares of common stock, respectively, plus a number of shares to be determined based on the amount of cash dividends deemed paid on shares earned pursuant to the awards. The release of the stock restrictions depends on the total return performance of the Company’s common stock measured against the performance of a peer-group of common stocks over three-year periods. The fair value amounts for restricted stock units were determined by using the per share market price of the Company’s common stock on the dates of award and the target number of shares for the awards (50% of the maximum number), by assigning equal probabilities to the thirteen possible payout outcomes at the ends of the three-year vesting periods, and by computing the weighted average of the outcome amounts. For each case, the estimated fair value amount was calculated to be 88.5% of the aggregate market value of the target number of shares on the award date.

The fair values of stock options and restricted stock units are recorded as stock compensation expense over the vesting periods of the corresponding awards. Expense amounts related to stock awards were $0.8 million and $0.6 million for the three months ended October 31, 2020 and 2019, respectively. Expense amounts related to stock awards were $2.2 million

15

and $1.5 million for the nine months ended October 31, 2020 and 2019, respectively. At October 31, 2020, there was $3.8 million in unrecognized compensation cost related to outstanding stock awards that the Company expects to expense over the next three years.

The total intrinsic value amounts of the stock options exercised during the nine months ended October 31, 2020 and 2019 were $1.2 million and $1.4 million, respectively. At October 31, 2020, the aggregate market value amounts of the shares of common stock subject to outstanding and exercisable stock options that were “in-the-money” exceeded the aggregate exercise prices of such options by $4.7 million and $3.3 million, respectively.

The Company estimates the weighted average fair value of stock options on the date of award using a Black-Scholes option pricing model, which was developed for use in estimating the fair value of traded options that have no vesting restrictions and are fully transferable. The Company believes that its past stock option exercise activity is sufficient to provide it with a reasonable basis upon which to estimate the expected life of newly awarded stock options. Risk-free interest rates are determined by blending the rates for three to five year US Treasury notes. The dividend yield is based on the Company’s current annual regular dividend amount. The calculations of the expected volatility factors are based on the monthly closing prices of the Company’s common stock for the five-year periods preceding the dates of the corresponding awards.

The fair value amounts of stock options granted during the nine months ended October 31, 2020 and 2019 were estimated on the corresponding dates of the awards using the Black-Scholes option-pricing model reflecting the following weighted average assumptions:

	Nine Months Ended October 31,
	2020		2019
Dividend yield	3.0	%	2.2	%
Expected volatility	30.0	%	33.1	%
Risk-free interest rate	0.5	%	2.0	%
Expected life (in years)	3.4		3.3

NOTE 10 – INCOME TAXES

Income Tax Expense Reconciliation

The Company’s income tax amounts for the nine months ended October 31, 2020 and 2019 differed from corresponding amounts computed by applying the federal corporate income tax rate of 21% to the income (loss) before income taxes for the periods as presented in the table below.

	Nine Months Ended October 31,
	2020		2019
Computed expected income tax (expense) benefit	$	(2,702)	$	8,070
Difference resulting from:
Net operating loss carryback		4,390		—
Foreign tax rate differential		(77)		(766)
Stock options		66		(170)
State income taxes, net of federal tax effect		(40)		185
Net operating losses deemed unrealizable		—		(6,280)
Bad debt loss		—		5,026
Adjustments and other differences		(246)		(1,129)
Income tax benefit	$	1,391	$	4,936

Foreign income tax expense amounts for the nine months ended October 31, 2020 and 2019 were not material. A valuation allowance in the amount of $6.3 million was established against the deferred tax asset amount created by the net operating loss of APC’s subsidiary in the UK for the nine months ended October 31, 2019. As  the subsidiary is expected to report income for the current year, approximately $0.1 of tax benefit was recorded during the nine-month period ended October 31, 2020.

16

Net Operating Loss Carryback

In an effort to combat the adverse economic impacts of the COVID-19 crisis, the US Congress passed the Coronavirus, Aid, Relief, and Economic Security Act ( the “CARES Act”) that was signed into law on March 27, 2020. This wide-ranging legislation was an emergency economic stimulus package that includes spending and tax breaks aimed at strengthening the US economy and funding a nationwide effort to curtail the effects of the outbreak of COVID-19. The CARES Act has provided many opportunities for taxpayers to evaluate their 2018 and 2019 income tax returns to identify potential tax refunds. One such area is the utilization of net operating losses (“NOLs”). The tax changes of the CARES Act remove the limitations on the future utilization of certain NOLs and re-establish a carryback period for certain losses to five years. The NOLs eligible for carryback under the CARES Act include the Company’s domestic NOL for the year ended January 31, 2020, which was approximately $39.5 million. Substantially all of this loss now may be carried back for application against the Company’s taxable income for the year ended January 31, 2015.

As the carryback of the NOL was not available until the current fiscal year, the tax benefit associated with the NOL for Fiscal 2020 was recorded in deferred tax assets as of January 31, 2020 in the amount of $8.3 million. With the enactment of the CARES Act, the asset was moved to income taxes receivable (included in other current assets in the condensed consolidated financial statements as of October 31, 2020) with a value of approximately $12.7 million. The carryback provides a favorable rate benefit for the Company as the loss, which  was incurred in a year where the statutory federal tax rate was 21%, will be carried back to a tax year where the tax rate was higher. The substantial portion of the net amount of this tax benefit, which is approximately $4.4 million, was recorded in the three-month period ended April 30, 2020 and is, therefore, reflected as income tax benefit in the results for the nine-month period ended October 31, 2020.

Research and Development Tax Credits

During Fiscal 2019, the Company completed a detailed review of the activities of its engineering staff on major EPC services projects in order to identify and quantify the amounts of research and development credits that may be available to reduce prior year income taxes. This study focused on project costs incurred during the three-year period ended January 31, 2018. Based on the results of the study, management identified and estimated significant amounts of income tax benefits that were not previously recognized in the Company’s operating results for any prior year reporting period. The amount of research and development tax credit benefit recognized during the fourth quarter of Fiscal 2019 was $16.2 million. As described below, the IRS is examining the research and development credits that were included in the amendments of the Company’s consolidated federal income tax returns for the years ended January 31, 2016 and 2017 that were filed in January 2019.

The amount of identified but unrecognized income tax benefits related to research and development credits as of October 31, 2020 was $5.0 million, for which the Company has established a liability for uncertain income tax return positions, most of which is included in accrued expenses. The amount of the liability was also $5.0 million as of January 31, 2020. The final outcome of these uncertain tax positions is not yet determinable. However, the Company does not expect that the amount of unrecognized tax benefits will significantly change due to any settlement and/or expiration of statutes of limitation over the next 12 months. As of October 31, 2020, the Company does not believe that it has any other material uncertain income tax positions reflected in its accounts.

As of October 31 and January 31, 2020, the balances of other current assets in the condensed consolidated balance sheets included income tax refunds and prepaid income taxes in the net amounts of approximately $27.3 million and $14.5 million, respectively. The substantial portions of the income tax refunds are expected to be collected after the completion of the federal tax return examinations described below and the filing of the refund request related to the NOL carryback described above.

Income Tax Returns

The Company is subject to federal and state income taxes in the US, and income taxes in Ireland and the UK. Tax treatments within each jurisdiction are subject to the interpretation of the related tax laws and regulations which require significant judgment to apply. The Company is no longer subject to income tax examinations by authorities for its fiscal years ended on or before January 31, 2016 except for several notable exceptions including Ireland, the UK and several states where the open periods are one year longer.

17

The IRS conducted an examination of the Company’s original federal consolidated income tax return for the year ended January 31, 2016. The IRS represented to the Company that no unfavorable adjustment items were noted during this examination. However, the Company has consented to an extension of the audit timeline which is enabling the IRS to also examine the amendment to the income tax return, which includes the research and development credit for the year. In addition, the IRS opened an examination of the Company’s amended consolidated income tax return for the year ended January 31, 2017. In substance, these efforts have evolved into a simultaneously conducted examinations of the research and development credits claimed in both years.

In October 2020, the Company received an initial draft communication from the IRS that documents its understanding of the facts, attempts to summarize the Company’s arguments in support of the claims and states its position which disagrees with the Company’s treatment of certain costs. After a careful review of the draft communication, the Company has concluded that its arguments are sound, that the draft information does not represent new facts relating to the issues and that it will not make any adjustments to its accounting for the research and development claims (that is discussed above) as of October 31, 2020. The Company intends to pursue its income tax position with the IRS, and it expects that the ultimate settlement of the disagreement will be resolved on a basis favorable to the Company.

Subsequent to October 31, 2020, the Company was notified by the IRS that it intended to examine the consolidated income tax return for the year ended January 31, 2018, with a most likely focus on the research and development credit claimed therein. The Company believes that any resulting disagreements regarding its income taxes for the year ended January 31, 2018 will be resolved on a basis favorable to the Company.

Supplemental Cash Flow Information

The amounts of cash paid for income taxes during the nine months ended October 31, 2020 and 2019 were $3.8 million and $3.1 million, respectively. During the nine months ended October 31, 2020 and 2019, the Company received cash refunds of previously paid income taxes from various taxing authorities in the total amounts of $0.9 million and $7.9 million, respectively.

NOTE 11 – NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.

Basic and diluted net income (loss) per share amounts are computed as follows (shares in thousands except in notes (1) below the charts):

	Three Months Ended October 31,
	2020		2019
Net income (loss) attributable to the stockholders of Argan, Inc.	$	9,454	$	(6,855)
Weighted average number of shares outstanding – basic		15,680		15,633
Effect of stock awards (1)		153		—
Weighted average number of shares outstanding – diluted		15,833		15,633
Net income (loss) per share attributable to the stockholders of Argan, Inc.
Basic	$	0.60	$	(0.44)
Diluted	$	0.60	$	(0.44)

(1) For the three months ended October 31, 2020, the weighted average number of shares determined on a dilutive basis excludes the effects of antidilutive stock options covering an aggregate of 506,501 shares of common stock. For the three months ended October 31, 2019, all common stock equivalents, which covered 1,243,000 shares of common stock, were considered to be antidilutive as the Company incurred a net loss for the period.

18

	Nine Months Ended October 31,
	2020		2019
Net income (loss) attributable to the stockholders of Argan, Inc.	$	14,300	$	(35,501)
Weighted average number of shares outstanding – basic		15,659		15,617
Effect of stock awards (1)		136		—
Weighted average number of shares outstanding – diluted		15,795		15,617
Net income (loss) per share attributable to the stockholders of Argan, Inc.
Basic	$	0.91	$	(2.27)
Diluted	$	0.91	$	(2.27)

(1)   For the nine months ended October 31, 2020, the weighted average number of shares determined on a dilutive basis excludes the effects of antidilutive stock options covering an aggregate of 688,000 shares of common stock. For the nine months ended October 31, 2019, all common stock equivalents, which covered 1,243,000 shares of common stock, were considered to be antidilutive as the Company incurred a net loss for the period.

NOTE 12 – CASH DIVIDENDS

On September 10, 2020, the Company’s board of directors declared a regular quarterly cash dividend in the amount of $0.25 per share of common stock, which was paid on October 30, 2020 to stockholders of record at the close of business on October 22, 2020. On June 23, 2020, the board of directors declared a regular quarterly cash dividend and a special cash dividend in the amounts of $0.25 and $1.00 per share of common stock, respectively, which were paid to stockholders on July 31, 2020. On April 9, 2020, the board of directors declared a regular quarterly cash dividend of $0.25 per share of common stock, which was paid to stockholders on April 30, 2020. Last year, the board of directors declared regular quarterly cash dividends, each in the amount of $0.25 per share of common stock, which were paid to stockholders on October 31, 2020, July 31, 2019 and April 30, 2019, respectively.

NOTE 13 – CUSTOMER CONCENTRATIONS

The majority of the Company’s consolidated revenues relate to performance by the power industry services segment which provided 86% and 61% of consolidated revenues for the three months ended October 31, 2020 and 2019, respectively, and 83% and 49% of consolidated revenues for the nine months ended October 31, 2020 and 2019, respectively. The industrial services segment represented 12% and 34% of consolidated revenues for the three months ended October 31, 2020 and 2019, respectively, and 15% and 47% of consolidated revenues for the nine months ended October 31, 2020 and 2019, respectively.

The Company’s most significant customer relationships for the three months ended October 31, 2020 included one power industry service customer, which accounted for 70% of consolidated revenues. The Company’s most significant customer relationships for the three months ended October 31, 2019 included two power industry service customers, which accounted for 27% and 17% of consolidated revenues, respectively, and one industrial services customer, which accounted for 10% of consolidated revenues. The Company’s most significant customer relationships for the nine months ended October 31, 2020 included one power industry service customer, which accounted for 69% of consolidated revenues. The Company’s most significant customer relationships for the nine months ended October 31, 2019 also included two power industry service customers, which accounted for 13% and 10% of consolidated revenues, respectively

The accounts receivable balances from four major customers represented 24%, 14%, 11% and 10% of the corresponding consolidated balance as of October 31, 2020. Accounts receivable balances from three major customers represented 24%, 21% and 12% of the corresponding consolidated balance as of January 31, 2020. The contract asset balances from two major customers represented 63% and 12% of the corresponding consolidated balance as of October 31, 2020. Contract asset balances from two major customers represented 51% and 31% of the corresponding consolidated balance as of January 31, 2020.

19

NOTE 14 – SEGMENT REPORTING

Segments represent components of an enterprise for which discrete financial information is available that is evaluated regularly by the Company’s chief executive officer, who is the chief operating decision maker, in determining how to allocate resources and in assessing performance. The Company’s reportable segments recognize revenues and incur expenses, are organized in separate business units with different management teams, customers, talents and services, and may include more than one operating segment. Intersegment revenues and the related cost of revenues are netted against the corresponding amounts of the segment receiving the intersegment services. For the three and nine months ended October 31, 2020, intersegment revenues totaled approximately $0.5 million and $1.4 million, respectively. For the three and nine months ended October 31, 2019, intersegment revenues totaled approximately $1.1 million and $2.5 million.

Summarized below are certain operating results and financial position data of the Company’s reportable business segments for the three and nine months ended October 31, 2020 and 2019. The “Other” column in each summary includes the Company’s corporate expenses.

Three Months Ended	Power		Industrial		Telecom
October 31, 2020	Services		Services		Services		Other		Totals
Revenues	$	109,712	$	15,730	$	1,889	$	—	$	127,331
Cost of revenues		91,263		14,218		1,507		—		106,988
Gross profit		18,449		1,512		382		—		20,343
Selling, general and administrative expenses		5,096		1,828		489		1,985		9,398
Income (loss) from operations		13,353		(316)		(107)		(1,985)		10,945
Other income, net		172		—		—		3		175
Income (loss) before income taxes	$	13,525	$	(316)	$	(107)	$	(1,982)		11,120
Income tax expense										(1,666)
Net income									$	9,454
Amortization of intangibles	$	62	$	164	$	—	$	—	$	226
Depreciation		178		654		106		2		940
Property, plant and equipment additions		164		34		81		—		279
Current assets	$	392,954		25,404		1,704		118,758	$	538,820
Current liabilities		245,808		13,762		709		751		261,030
Goodwill		18,476		9,467		—		—		27,943
Total assets		425,909		47,356		3,190		119,045		595,500

20

Three Months Ended	Power		Industrial		Telecom
October 31, 2019	Services		Services		Services		Other		Totals
Revenues	$	35,848	$	20,143	$	2,415	$	—	$	58,406
Cost of revenues		31,327		19,159		1,928		—		52,414
Gross profit		4,521		984		487		—		5,992
Selling, general and administrative expenses		7,672		2,018		485		1,960		12,135
(Loss) income from operations		(3,151)		(1,034)		2		(1,960)		(6,143)
Other income, net		3,447		—		—		131		3,578
Income (loss) before income taxes	$	296	$	(1,034)	$	2	$	(1,829)		(2,565)
Income tax expense										(1,996)
Net loss									$	(4,561)
Amortization of intangibles	$	61	$	166	$	45	$	—	$	272
Depreciation		176		625		97		1		899
Property, plant and equipment additions		2,659		436		170		—		3,265
Current assets	$	292,618	$	28,373	$	2,861	$	82,048	$	405,900
Current liabilities		108,474		8,744		796		943		118,957
Goodwill		18,476		12,290		—		—		30,766
Total assets		324,535		55,814		4,370		87,998		472,717

Nine Months Ended	Power		Industrial		Telecom
October 31, 2020	Services		Services		Services		Other		Totals
Revenues	$	227,363	$	42,163	$	5,445	$	—	$	274,971
Cost of revenues		192,583		38,096		4,310		—		234,989
Gross profit		34,780		4,067		1,135		—		39,982
Selling, general and administrative expenses		15,892		5,664		1,447		5,824		28,827
Income (loss) from operations		18,888		(1,597)		(312)		(5,824)		11,155
Other income, net		1,634		—		—		80		1,714
Income (loss) before income taxes	$	20,522	$	(1,597)	$	(312)	$	(5,744)		12,869
Income tax benefit										1,391
Net income									$	14,260
Amortization of intangibles	$	182		495		—		—	$	677
Depreciation		522	$	1,967	$	305	$	4		2,798
Property, plant and equipment additions		857		338		217		—		1,412

21

Nine Months Ended	Power		Industrial		Telecom
October 31, 2019	Services		Services		Services		Other		Totals
Revenues	$	83,941	$	80,442	$	6,626	$	—	$	171,009
Cost of revenues		104,759		72,958		5,361		—		183,078
Gross (loss) profit		(20,818)		7,484		1,265		—		(12,069)
Selling, general and administrative expenses		18,977		5,959		1,535		5,290		31,761
Impairment loss		2,072		—		—		—		2,072
(Loss) income from operations		(41,867)		1,525		(270)		(5,290)		(45,902)
Other income, net		7,037		—		—		435		7,472
(Loss) income before income taxes	$	(34,830)	$	1,525	$	(270)	$	(4,855)		(38,430)
Income tax benefit										4,936
Net loss									$	(33,494)
Amortization of intangibles	$	231	$	497	$	136	$	—	$	864
Depreciation		517		1,791		298		4		2,610
Property, plant and equipment additions		4,533		1,487		277		11		6,308

ITEM 2. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS

The following discussion summarizes the financial position of Argan, Inc. and its subsidiaries as of October 31, 2020, and the results of their operations for the three and nine months ended October 31, 2020 and 2019, and should be read in conjunction with (i) the unaudited condensed consolidated financial statements and notes thereto included elsewhere in this Quarterly Report on Form 10-Q and (ii) the consolidated financial statements and accompanying notes included in our Annual Report on Form 10-K for the fiscal year ended January 31, 2020 that we filed with the SEC on April 14, 2020 (the “Annual Report”).

Cautionary Statement Regarding Forward Looking Statements

The Private Securities Litigation Reform Act of 1995 provides a “safe harbor” for certain forward-looking statements. We have made statements in this Item 2 and elsewhere in this Quarterly Report on Form 10-Q that may constitute “forward-looking statements.” The words “believe,” “expect,” “anticipate,” “plan,” “intend,” “foresee,” “should,” “would,” “could,” or other similar expressions are intended to identify forward-looking statements. Our forward-looking statements, including those relating to the potential effects of the COVID-19 pandemic on our business, financial position and results of operations, are based on our current expectations and beliefs concerning future developments and their potential effects on us.

There can be no assurance that future developments affecting us will be those that we anticipate. All comments concerning our expectations for future revenues and operating results are based on our forecasts for existing operations and do not include the potential impact of any future acquisitions.

Our forward-looking statements, by their nature, involve significant risks and uncertainties (some of which are beyond our control) and assumptions. They are subject to change based upon various factors including, but not limited to, the risks and uncertainties described in this Quarterly Report on Form 10-Q and our Annual Report. Should one or more of these risks or uncertainties materialize, or should any of our assumptions prove to be incorrect, actual results may vary in material respects from those projected in the forward-looking statements. We undertake no obligation to publicly update or revise any forward-looking statements, whether as a result of new information, future events or otherwise.

Business Description

Argan is a holding company that conducts operations through its wholly-owned subsidiaries, GPS, APC, SMC and TRC. Through GPS and APC, we provide a full range of engineering, procurement, construction, commissioning, operations management, maintenance, development, technical and consulting services to the power generation markets, including the renewable energy sector, for a wide range of customers, including independent power project owners, public utilities,

22

equipment suppliers and global energy plant construction firms. GPS and APC represent our power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southeast region of the US and that are based on its expertise in producing, delivering and installing fabricated metal components such as piping systems and pressure vessels. Through SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the mid-Atlantic region of the US.

We may make additional acquisitions of and/or investments in companies with potential for profitable growth that reflect more than one industrial focus. We expect that they will be held in separate subsidiaries that will be operated in a manner that best provides value for our stockholders.

Summary of Operating Results

Due substantially to the recovering revenues of GPS, consolidated revenues for the three months ended October 31, 2020 were $127.3 million, which represented an increase of $68.9 million, or 118.0%, from consolidated revenues of $58.4 million reported for the three months ended October 31, 2019. The revenues of the power industry services segment, including GPS, represented 86.2% and 61.4% of consolidated revenues for the three months ended October 31, 2020 and 2019, respectively. On the other hand, the revenues of TRC and SMC for the three months ended October 31, 2020 declined by 21.9% and 21.8%, respectively, from the comparable amounts reported for the three months ended October 31, 2019.  Together, they represented 13.8% of consolidated revenues for the quarter ended October 31, 2020.

We believe that all of our businesses were adversely impacted during the three months ended October 31, 2020, to some degree, by continuing difficulties presented by the COVID-19 outbreaks. For example, the results for APC were hurt by the slow resumption of postponed Irish works projects. The challenges of managing the continuing activities of the Guernsey Power Station project during this period of various health and safety restrictions resulted in project progress by GPS falling short of prior expectations. In addition, our consolidated revenues suffered from the effects of project delays by customers of both TRC and SMC which were attributable to the restrictive work environments caused by the pandemic.  

Consolidated gross profit for the three months ended October 31, 2020 was $20.3 million, or 16.0% of the corresponding consolidated revenues, which reflected the favorable impacts of the higher consolidated revenues and the adjustments recorded in connection with the negotiation of the latest change to the TeesREP Project subcontract. Our gross profit reported for the three months ended October 31, 2019 was $6.0 million, or 10.3% of corresponding consolidated revenues. Selling, general and administrative expenses for the three months ended October 31, 2020 and 2019 were $9.4 million and $12.1 million, respectively. Due in part to the extremely low rates of return on amounts invested in cash equivalents and short-term investments during the current year, other income declined to $0.2 million for the three months ended October 31, 2020 from $3.6 million for the comparable quarter of the prior year despite the increase in the amount of invested funds between years. In addition, other income for the three months ended October 31, 2019 included a pre-tax gain of $2.2 million which was recorded by the consolidated variable interest entity in connection with the grant of a utility easement at the planned site of a new gas-fired power plant. This gain was also reflected in the amount of net income attributable to non-controlling interests for the three months ended October 31, 2019.

Due primarily to the consolidated pre-tax book income reported for the three months ended October 31, 2020 in the amount of $11.1 million, we reported income tax expense in the amount of $1.7 million for the quarter. We recorded income tax expense for the three months ended October 31, 2019 in the amount of approximately $2.0 million which primarily reflected unfavorable adjustments to the expected annual effective income tax rate for the year.

With results reflecting primarily the factors identified above, the consolidated net income attributable to our stockholders was $9.5 million, or $0.60 per diluted share, for the three months ended October 31, 2020. For the three months ended October 31, 2019, we reported a consolidated net loss attributable to our stockholders of $6.9 million, or $0.44 per diluted share.

The improved consolidated revenues for the quarter ended October 31, 2020 were a primary driver for the increased consolidated revenues for the nine-month period ended October 31, 2020, which were $275.0 million. This amount represented a 60.8% improvement from the amount of revenues for the nine months ended October 31, 2019. The revenues of the power industry services segment, including GPS, represented 82.7% and 49.1% of consolidated revenues for the

23

nine months ended October 31, 2020 and 2019, respectively. Last year, a substantial portion of consolidated revenues were contributed by the industrial services business of TRC which reported revenues of $80.4 million for the nine months ended October 31, 2019, or 47.0% of consolidated revenues for the prior year period. The revenues of TRC declined and represented only 15.3% of consolidated revenues for the current year period.

Consolidated gross profit for the nine months ended October 31, 2020 was $40.0 million, or 14.5% of the corresponding consolidated revenues, which reflected primarily the favorable impact of higher consolidated revenues. The significant subcontract loss incurred by APC caused us to report a consolidated gross loss of $12.1 million for the nine months ended October 31, 2019.

Selling, general and administrative expenses were $28.8 million and $31.8 million for the nine months ended October 31, 2020 and 2019, respectively. Other income, representing primarily income earned on temporary cash investments, declined to $1.7 million for the nine months ended October 31, 2020 from $7.5 million for the nine months ended October 31, 2019. The income for the nine months ended October 31, 2019 also included the pre-tax gain of $2.2 million identified above.

The loss on the TeesREP Project also prompted us to record an impairment loss related to the goodwill of APC in the amount of $2.1 million during the first quarter last year, which amount is included in the reported results for the nine months ended October 31, 2019.

For the nine months ended October 31, 2020, we reported an income tax benefit in the amount of $1.4 million which reflected primarily the net operating loss carryback benefit of $4.4 million, substantially all of which was recorded in the first quarter of the current year. We reported an income tax benefit for the nine months ended October 31, 2019 in the amount of approximately $4.9 million which primarily reflected the favorable estimated income tax impact of the bad debt loss on loans made to APC by Argan which were determined to be uncollectible last year. On the other hand, we did not record any income tax benefit related to the operating loss of APC’s subsidiary in the UK for the nine months ended October 31, 2019.

For the nine months ended October 31, 2020, our improved overall operating performance resulted in net income attributable to our stockholders in the amount of $14.3 million, or $0.91 per diluted share. Last year, due substantially to the subcontract loss recorded for the TeesREP Project, we reported a net loss attributable to our stockholders in the amount of $35.5 million, or $2.27 per dilutive share.

The TeesREP Subcontract

In our Form 10-K Annual Report for Fiscal 2019, we disclosed that APC was completing the mechanical installation of the boiler for a biomass-fired power plant under construction in the UK, the TeesREP Project, and that the project had encountered significant operational and contractual challenges. The consolidated operating results for the year ended January 31, 2019 reflected unfavorable gross profit adjustments related to this project. The disclosure explained that the construction project was behind the schedule originally established for the job and warned that the TeesREP Project may continue to impact our consolidated operating results negatively until it reaches completion.

By April 30, 2019, APC’s estimates of the unfavorable financial impacts on forecasted costs of the numerous and unique difficulties on this particular project, including weather delays, inefficiencies due to unanticipated scope and design changes from preliminary plans, project task re-sequencing and various work interruptions, had escalated substantially from the estimates prepared for the prior year-end. As a result, during the nine months ended October 31, 2019, we recorded a loss related to this project in the amount of $31.2 million, including $0.3 million recorded in last year’s third quarter, and reversed profit in the amount of $0.7 million that had been recorded in prior years.

During the fourth quarter of Fiscal 2020, APC and its customer, the engineering, procurement and construction services contractor on the TeesREP Project, agreed to amend operational and commercial terms for the completion of the project. At the time, this framework addressed the project schedule, payment terms, the scope of the remaining effort, performance guarantees and other terms and conditions for APC to reach substantial completion of its portion of the total project. Although this negotiation returned a meaningful amount of stability to the continuation of the project efforts, the amendment did not resolve significant past commercial differences.

24

Construction on the TeesREP Project was suspended on March 24, 2020 due to the COVID-19 pandemic. At the time of the work suspension, APC had completed approximately 90% of its subcontracted work. As a condition for resuming its efforts on the TeesREP Project, APC entered into Amendment No. 2 to the subcontract, effective June 1, 2020, covering new terms and conditions for completion of the installation of the boiler. This agreement represented a global settlement of past commercial differences with both parties making significant concessions, and converted the billing arrangement for the remaining work to a time-and-materials based scheme.

Despite the change to the billing arrangements, we treated Amendment No. 2 as a continuation of the original subcontract because the arrangement continued to represent a single performance obligation to our customer, the delivery of a complete functioning and integrated boiler, that was only partially satisfied when the modification to the subcontract occurred. The catch-up impact of the accounting for the modification of the subcontract plus the margin earned in the second quarter, partially offset by project-related charges recorded by APC, resulted in a net improvement to consolidated gross profit for the second quarter in the amount of $2.3 million.

Earlier this year, we also made changes in the operational and financial leadership at APC. The new management team is focused on completing the TeesREP Project, reducing costs, limiting future commercial and project risks and achieving sustained profitability for the combined operations of APC. We believed that the APC leadership changes, our active management of this subcontract and the restructuring of the subcontract terms and conditions, as reflected in Amendment No.2, reduced the potential for future material loss on the TeesREP Project.

In fact, during October 2020, APC and its customer agreed to additional contractual changes that effectively recognizes APC’s completion of the single performance obligation, that eliminates any uncertainty regarding APC earning certain cost and schedule incentives included in Amendment No. 2 and that establishes a time-and-materials contractual arrangement covering the additional works that are being requested by APC’s customer until completion of the power plant construction. APC thereby reduced the financial risks associated with the subcontract even further. The catch-up impact of the accounting for the new change to the subcontract plus the margin earned on the performance of construction activities during the three-month period ended October 31, 2020 resulted in a net improvement to consolidated gross profit for the third quarter in the amount of $2.8 million.

The expected final amount of the TeesREP fixed price subcontract loss is $29.5 million. Final closeout adjustments may result in future changes to the amount of the subcontract loss recognized as of October 31, 2020; however, APC has included an estimate of these costs in accrued expenses in the accompanying condensed consolidated balance sheet as of October 31, 2020. The total amounts of accounts receivable and contract assets related to the TeesREP Project and included in the condensed consolidated balance sheets were $7.3 million as of October 31, 2020 and $19.2 million as of January 31, 2020.

Research and Development Tax Credits

During Fiscal 2019 and based on the results of a study of the activities of the engineering staff of GPS on major EPC services projects during the three-year period ended January 31, 2018, management identified and estimated significant amounts of income tax benefits that were not previously recognized in our operating results for any prior year reporting period. The amount of the research and development tax credit benefits recognized during the fourth quarter of Fiscal 2019 was $16.2 million. The amount of identified but unrecognized income tax benefits related to research and development credits as of October 31, 2020 was $5.0 million, for which we established a liability for uncertain income tax return positions, most of which is included in accrued expenses. The research and development credits were included in amendments to our consolidated federal income tax returns for the years ended January 31, 2016 and 2017, that were filed in January 2019, and our consolidated federal income tax return for the year ended January 31, 2018, that was filed in November 2018. Separate income tax return examinations by the IRS have evolved into simultaneously conducted examinations of the research and development credits claimed by us for the years ended January 31, 2016 and 2017.

In October 2020, we received an initial draft communication from the IRS that documents its understanding of the facts, attempts to summarize our arguments in support of the claims and states its position which disagrees with our treatment of certain costs. After a careful review of the draft communication, we have concluded that our arguments are sound, that the draft information does not represent new facts relating to the issues and that we will not make any adjustments to our

25

accounting for the research and development claims as of October 31, 2020. We intend to pursue our income tax position with the IRS, and we expect that the ultimate settlement of the disagreement will be resolved on a basis favorable to us.

Subsequent to October 31, 2020, we were notified by the IRS that it intended to examine the consolidated income tax return for the year ended January 31, 2018, with a most likely focus on the research and development credit claimed therein. We believe that any resulting disagreements regarding its income taxes for the year ended January 31, 2018 will be resolved on a basis favorable to us.

Major Customer Contracts

During August 2019, GPS received a full notice to proceed with activities under an EPC services contract to build an 1,875 MW combined cycle natural gas-fired power plant in Guernsey County, Ohio. The Guernsey Power Station was jointly developed by Caithness Energy, L.L.C. and Apex Power Group, LLC. The ramp-up of activity on this project has favorably impacted our quarterly consolidated operating results since then with its increasing revenues. Substantial completion of this project is currently scheduled to occur by the end of calendar year 2022.

In January 2020, GPS entered into an EPC services contract with Harrison Power, LLC (“Harrison Power”) to construct a 1,085 MW natural gas-fired power plant in the Village of Cadiz, Harrison County, Ohio. The project is being developed by EmberClear, the parent company of Harrison Power. On March 12, 2020, we announced that GPS had entered into an EPC services contract with NTE Connecticut, LLC to construct the Killingly Energy Center, a 650 MW natural gas-fired power plant, in Killingly, Connecticut. The facility is being developed by NTE Energy, LLC (“NTE”). We anticipate adding the value of each of these new contracts to project backlog at times closer to their financial close and expected start dates. We are cautiously optimistic that the start of construction activities for these projects will occur over the next twelve months from now. However, we cannot predict with certainty when the projects will commence. The start dates for construction are generally controlled by the project owners.

In May 2019, GPS entered into an EPC services contract to construct a 625 MW power plant in Harrison County, West Virginia. Caithness is partnered with ESC Harrison County Power, LLC to develop this project. As a limited notice to proceed with certain preliminary activities was received from the owner of this project at the time, the value of the contract was added to our project backlog. However, construction activities for the facility are not likely to begin before January 31, 2021 and until financial close is achieved.

We announced in March 2018 that GPS entered into an EPC services contract with an affiliate of NTE to construct an approximately 500 MW natural gas-fired power plant in Rockingham County, North Carolina. At the time, we expected this project to commence within a reasonable amount of time. However, due to unforeseen project owner delays, including a grid connection dispute between the project owner and a public utility, contract activities have not yet started for this new project. If the current dispute with the public utility terminates on terms that do not move the project forward, we will remove the value of the Reidsville Energy Center from project backlog.

As announced in Fiscal 2019, GPS entered into an EPC services contract to construct the Chickahominy Power Station, a 1,740 MW natural gas-fired power plant, in Charles City County, Virginia. Even though we have been providing financial and technical support to the project development effort through a consolidated VIE and significant project development milestones have been achieved, we have not included the value of this contract in our project backlog. Due to several factors that have interrupted the pace of the development of this project, including additional costs and time being required to secure the natural gas supply for the plant and to obtain the necessary equity financing, we currently cannot predict when construction will commence, if at all. We are monitoring the status of this project and evaluating our alternatives closely as the investment of the VIE in the development of this project was approximately $7.4 million as of October 31, 2020.

On March 10, 2020, we announced that in late February 2020 GPS entered into an EPC services contract with ESC Brooke County Power I, LLC to construct the Brooke County Power plant, a 920 MW natural gas-fired power generation facility, in Brooke County, West Virginia. The facility was being developed by Energy Solutions Consortium, LLC, which announced cancellation of the project in October 2020, citing changing conditions in the energy and financial markets. The value of this project had not been added to our project backlog.

26

The aggregate rated electrical output amount for the natural gas-fired power plants for which we have signed EPC services contracts, including the Guernsey Power Station, is approximately 6.4 gigawatts with an aggregate initial contract value of approximately $3.0 billion. Our project backlog amount was approximately $1.2 billion and $1.3 billion at October 31, 2020 and January 31, 2020, respectively. We include the value of an EPC services contract in project backlog when we believe that it is probable that the project will commence within a reasonable timeframe, among other factors. Our reported amount of project backlog at a point in time represents the total value of projects awarded to us that we consider to be firm as of that date less the amounts of revenues recognized to date on the corresponding projects (project backlog is larger than the value of remaining unsatisfied performance obligations, or RUPO, on active contracts; see Note 2 to the accompanying condensed consolidated financial statements). Cancellations or reductions may occur that may reduce project backlog and our expected future revenues.

We believe that it is important to note that the plans for two of our contracted natural gas-fired power plant projects will adopt integrated green hydrogen solution packages developed by a major gas turbine manufacturer. While the plants will initially run on natural gas alone, it is planned that the plants will eventually burn a mixture of natural gas and green hydrogen, thereby establishing power-generation flexibility for these plants.

We have maintained that the delays in new business awards to GPS and the project construction starts of certain previously awarded projects relate to a variety of factors, especially in the northeast and mid-Atlantic regions of the US. Currently, we believe that the ability of the owners of fully developed gas-fired power plant projects to close on equity and permanent debt financing has been challenged by uncertainty in the capital markets caused by multiple factors including delayed capacity auctions and mounting public and political opposition to fossil-fuel energy projects.  

The viability of future revenue forecasts by power plant owners and operators, particularly independent power producers, depends, to a significant degree, on the amount of future capacity supply secured for a particular power source located within the electricity region coordinated by PJM. For new power projects, lack of visibility regarding future capacity revenue streams complicates the search for equity and debt financing considerably. Most of our recently completed and awarded EPC service contracts relate to the construction of natural gas-fired power plants located within the geographic footprint of the electric power system operated by PJM, the regional transmission organization that coordinates the movement of wholesale electricity in all or parts of 13 states and the District of Columbia.

PJM’s 2022/2023 capacity auction, or base residual auction, was originally scheduled to be held in May 2019, but was postponed pending the approval by the Federal Energy Regulatory Commission (“FERC”) of new capacity market rules governing offered prices. PJM cleared the final requirement to reestablish the auction schedule with the release of FERC’s recent order in November 2020. In that order, FERC approved PJM’s treatment of the energy market and ancillary services market revenue offset, which is used, among other things, to establish the minimum offer price for resources in the capacity auction with state subsidies.

As a result, PJM has announced a schedule for its next five annual capacity auctions. The resumption of auctions for the PJM market and the resulting determination of capacity providers and prices should help to restore some certainty for power project developers in this region.

PJM has scheduled the next capacity auction, for the 2022/2023 delivery year, to occur in May 2021 with results posted in early June 2021. PJM intends to hold subsequent auctions on an accelerated basis, approximately every six months, through 2024, so that the regular annual auction routine can then resume in May 2024.

Nonetheless, our commencement of new EPC power plant projects may continue to be delayed until the visibility regarding future capacity revenue streams is restored by the future announcements of capacity prices in the PJM region.

Besides the downturn in the demand for electric power during the COVID-19 outbreak in the US that is discussed below, other factors to consider include an increase in the amount of power generating capacity provided by renewable energy assets, improvements and decreasing prices in renewable energy storage solutions, increased environmental activism and the results of the recent presidential election in the US.

Protests against fossil-fuel related energy projects continue to garner media attention and stir public skepticism about new projects resulting in delays due to onsite protest demonstrations, indecision by local officials and lawsuits. As discussed above, the Brooke County Power project was canceled by its developer. Although changing market conditions were cited

27

as important factors in the cancellation decision and despite strong local support for the project, the opposition by the governor of West Virginia was likely a factor in the declining enthusiasm for the project. Further, in July 2020, Dominion Energy and Duke Energy announced the abandonment of plans to complete the major Atlantic Coast Pipeline, ending a seven-year effort to build a 600-mile natural gas pipeline between West Virginia and eastern North Carolina, citing that the economic viability of the project was threatened by continuing delays and increasing cost uncertainty after a federal judge issued a ruling preventing the use of an accelerated construction permitting process. Although this recent pipeline cancellation decision is not expected to have any direct unfavorable effect on any of the pending projects awarded to GPS, other pipeline approval delays may jeopardize projects that are needed to bring supplies of natural gas to planned gas-fired power plant sites, thereby increasing the risk of future power plant project delays or cancellations.

In the New England and mid-Atlantic regions of the US, power plant operators are challenged by the requirements of the Regional Greenhouse Gas Initiative, or “RGGI,” which is a cooperative effort by states in these regions to cap and reduce power sector carbon dioxide emissions. In addition, various cities, counties and states have adopted clean energy and carbon-free goals or objectives with achievement expected by a certain future date, typically 10 to 30 years out. These aspirational goals may increase the risk of a new power plant becoming a stranded asset long before the end of its otherwise useful economic life, which is a risk that potential equity capital providers may be unwilling to take. The difficulty in obtaining project equity financing and the other factors identified above, may be adversely impacting the planning and initial phases for the construction of new natural gas-fired power plants which continue to be deferred by project owners.

Perhaps the most significant developing headwind for future gas-fired power plant developments relates to the policies of Joseph R. Biden, Jr., the president-elect of the US. His plan to tackle climate change was described as the most ambitious of any mainstream presidential candidate yet. However, it is more moderate than the much publicized Green New Deal. He has pledged that the US will re-join the Paris climate agreement. Mr. Biden is proposing to make the electricity production in the US carbon free by 2035 and to put the country on the path to achieve net zero carbon emissions by 2050. One element of his plan is to ban fracking on federal land. However, as about 90% of fracking occurs on state or private lands, the vast majority of fracking will be unaffected. There may be practical, political and legal hurdles in Mr. Biden’s path, but his election, in part, does represent an indication that public sentiment against fossil-fuel sourced energy is growing.

Market Outlook

Although the total amount of electricity generated by utility-scale power facilities in calendar year 2019 declined by 1.3% from the total amount in 2018, the 2019 amount was the second highest total annual amount of electricity generated by utility-scale power plants since 2010. In the reference case included in its Annual Energy Outlook 2020 released in January 2020, the US Energy Information Administration (the “EIA”) again forecasted slow but steady growth in net electricity generation through 2050 with average annual increases of slightly less than 1.0% per year.

Despite the overall decline in the amount of electricity generated in the US in 2019 and the increases in the amounts of electricity provided by utility-scale wind and solar power sources, the amount of electricity generated by natural gas-fired power plants rose by 7.7% during 2019, and it represented 38.4% of the total electric power generated in the US in 2019. The combined amount of power generated by the wind and the sun increased by approximately 7.8% in 2019 from the comparable amount for 2018, and represented 10.8% of total utility-scale power generation in 2019. The amount of electricity generated from coal decreased by 15.7% in 2019 from its generation amount for 2018, and coal’s share of the total, utility-scale electricity generation mix declined from 27.4% for 2018 to 23.5% for 2019. In summary, the share of the electrical power generation-mix in the US fueled by natural gas, the sun and wind continued to rise during 2019, while the share fueled by coal continued its fall.

However, reduced economic activity in the US related to the COVID-19 pandemic has caused significant changes in energy supply and demand patterns. In its Short-Term Energy Outlook released in November 2020, EIA forecasts that the consumption of electricity in the US will decline by 3.6% in 2020 before resuming growth at an annual rate slightly less than 1.0% in 2021. Most of the expected decline is predicted for coal-fired and nuclear generation. The updated forecast for natural gas generation is that it will represent 39% of utility-scale electricity generation in 2020, before its share declines to 33.0% in 2021 as the price of natural gas is forecasted to rise.

28

In the pre-COVID-19 reference case of the 2020 outlook identified above, the EIA predicted that coal-fired and nuclear power generating capacity would decline by approximately 47% and 20% by 2050, respectively, representing only 13% and 12% shares of the electricity generation mix by 2050, respectively. It is important to note that most of the reduction in the coal-fired and nuclear capacity was already predicted to occur in the period 2020-2025. As a result, natural gas-fired power generating capacity was forecasted to increase by 26% over the next five years and by 67% by 2050 before any adjustments for adverse and long-lasting effects of the COVID-19 pandemic on the demand for electricity. Of course, the ultimate adverse impacts of the COVID-19 outbreak on electricity generation in the US over the long-term are not known at this time.

EIA reports that for the nine months ended September 30, 2020 as compared to the corresponding period last year, net generation of electricity by utility-scale gas-fired power plants has increased by 3.8%, with its share representing 41% of total generation, while the utility-scale generation from all other sources has declined by 7.8% in the period. For the nine-month period ended September 30, 2019, the share of gas-fired power plant electricity generation was 38.2% of the total for the period.

Reflecting additions to solar and wind generating capacity in 2020, the amount of electricity generated by utility-scale wind farms and solar fields has increased during the nine months ended September 30, 2020 by 12.2% and 23.5%, respectively, compared with the corresponding electricity generation amounts for the nine-month period ended September 30, 2019.  However, it is interesting to note EIA’s forecast that US energy-related carbon dioxide emissions will decrease by 10% in 2020 (after declining by 2.6% in 2019) even though it appears that the net electricity generation by utility-scale gas-fired power plants will increase again in 2020. This underscores the primary reason why carbon emissions in the US have declined meaningfully over the past ten years – coal-fired power plants have been replaced by clean-burning gas-fired power plants and renewable sources of energy more recently. In the PJM region, the largest shares of electricity are generated by natural gas-fired and nuclear power plants. Wind farms and solar fields together typically provide less than 5% of total electricity generation in the PJM region.  

In our view, the competitive landscape in the EPC services market for natural gas-fired power plant construction has changed significantly. Significant competitors have exited the market for a variety of reasons. Others have announced intentions to avoid entering into fixed-price contracts. While the competitive market remains dynamic, we expect that there will be fewer competitors for new gas-fired power plant EPC project opportunities in the foreseeable future.

As a result, we continue to believe that the future long-term prospects for natural gas-fired power plant construction remain generally favorable as natural gas continues to be the primary source for power generation in our country. New gas-fired power plants incorporate major advances in gas-fired turbine technologies that have provided increased power plant efficiencies and the mixture of green hydrogen with natural gas as a cleaner source of fuel, while providing the quick starting capabilities and the reliability that are necessary to balance the inherent intermittencies of wind and solar powered energy plants. It has been reported that renewables currently provide approximately 36% of electricity generation in California. Yet, the recent experience is that the increasing dependence on intermittent renewable energy sources, especially solar, is making it harder to ensure reliable power in California as millions of its residents lost power during a late summer heat wave. The lesson may be that fossil-fuel electricity generation sources remain critical elements of the power generation mix in order to assure grid reliability by avoiding power outages.

Additionally, solar and wind energy plant developers continue to confront the problems caused by grid congestion, often unsuccessfully. Scores of such projects are canceled because of the following dilemma. Renewable plants need to be sited where the resources are optimal, often in remote locations where the transmission systems are not robust. The costs associated with the necessary grid upgrades may be prohibitive. Proponents of wind farms located off the Atlantic coast of the US suffered a recent setback when the owner of Vineyard Wind announced a delay in the project in order to accommodate the use of larger, cutting edge, turbines while reducing the number of towers. However, a contrary view is that US offshore wind projects progress inconsistently, facing challenges in the areas of environmental and fishery impacts, grid connection and capability and federal permitting processes. Further, projects are confronted by shipping regulations in the US that may limit the ability of developers to replicate successful European construction and installation models.  

Major advances in the safe combination of horizontal drilling techniques and hydraulic fracturing led to the boom in natural gas supplies which have been available generally at consistently low prices. The abundant availability of cheap, less carbon-intense and higher efficiency natural gas should continue to be a significant factor in the economic assessment of

29

future power generation capacity additions although the pace of new opportunities emerging may be restrained and the starts of awarded EPC projects may be delayed. We are committed to the rational pursuit of new construction projects and the future growth of our revenues. This may result in our decision to make investments in the development and/or ownership of new projects. Because we believe in the strength of our balance sheet, we are willing to consider certain opportunities that include reasonable and manageable risks in order to assure the award of the related EPC services contracts to us.

Despite our commitment to the construction of state-of-the-art natural gas-fired power plants as important elements of our country’s electricity-generation mix in the future, we are directing business development efforts to winning projects for the erection of utility-scale wind farms, solar fields and other renewable energy projects. We have successfully completed these types of projects in the past and we are renewing efforts to obtain new work in the renewable space that will complement our natural gas-fired EPC services projects going forward.

We believe that the Company has a reputation as an accomplished and cost-effective provider of EPC and other large project construction contracting services. We are convinced that the latest series of new EPC projects awarded to us confirms the soundness of our belief. With the proven ability to deliver completed power facilities, particularly combined cycle, natural gas-fired power plants, we are focused on expanding our position in the power markets where we expect investments to be made based on forecasts of electricity demand covering decades into the future. We believe that our expectations are valid and that our plans for the future continue to be based on reasonable assumptions. 

In July 2020, confidence in our financial strength and the prospects for our business going forward prompted our board of directors to declare and to pay a special cash dividend in the amount of $1.00 per share (see Note 12 to the accompanying condensed consolidated financial statements) and to authorize the use of $25.0 million to repurchase shares of our common stock (see Item 2 in Part II of this Quarterly Report on Form 10-Q). In October 2020, we reverted to our recently normal practice of paying a quarterly cash dividend of $0.25 per share.

Comparison of the Results of Operations for the Three Months Ended October 31, 2020 and 2019

We reported net income attributable to our stockholders of $9.5 million, or $0.60 per diluted share, for the three months ended October 31, 2020. For the three months ended October 31, 2019, we reported a comparable net loss amount of $6.9 million, or $0.44 per diluted share.

30

The following schedule compares our operating results for the three months ended October 31, 2020 and 2019 (dollars in thousands):

	Three Months Ended October 31,
	2020		2019		$ Change		% Change
REVENUES
Power industry services	$	109,712	$	35,848	$	73,864	206.0	%
Industrial fabrication and field services		15,730		20,143		(4,413)	(21.9)
Telecommunications infrastructure services		1,889		2,415		(526)	(21.8)
Revenues		127,331		58,406		68,925	118.0
COST OF REVENUES
Power industry services		91,263		31,327		59,936	191.3
Industrial fabrication and field services		14,218		19,159		(4,941)	(25.8)
Telecommunications infrastructure services		1,507		1,928		(421)	(21.8)
Cost of revenues		106,988		52,414		54,574	104.1
GROSS PROFIT		20,343		5,992		14,351	239.5
Selling, general and administrative expenses		9,398		12,135		(2,737)	(22.6)
INCOME (LOSS) FROM OPERATIONS		10,945		(6,143)		17,088	NM
Other income, net		175		3,578		(3,403)	(95.1)
INCOME (LOSS) BEFORE INCOME TAXES		11,120		(2,565)		13,685	NM
Income tax expense		(1,666)		(1,996)		330	16.5
NET INCOME (LOSS)		9,454		(4,561)		14,015	NM
Net income attributable to non-controlling interests		—		2,294		(2,294)	(100.0)
NET INCOME (LOSS) ATTRIBUTABLE TO
THE STOCKHOLDERS OF ARGAN, INC.	$	9,454	$	(6,855)	$	16,309	NM	%

NM – Not meaningful.

Revenues

Power Industry Services

The revenues of the power industry services business increased by 206.0%, or $73.9 million, to $109.7 million for the three months ended October 31, 2020 compared with revenues of $35.8 million for the three months ended October 31, 2019. The revenues of this business represented approximately 86.2% of consolidated revenues for the quarter ended October 31, 2020 and 61.4% of consolidated revenues for the prior year quarter. The primary driver for the improved performance by this reportable segment for the current year quarter was the increasing revenues associated with the construction of the Guernsey Power Station. This project, which did not commence until the third quarter last year, represented the significant portion of this segment’s revenues for the three months ended October 31, 2020.

GPS reached substantial completion on four gas-fired power plant projects late in Fiscal 2019 and concluded activities on a fifth gas-fired power plant early in Fiscal 2020. As a result, the revenues of GPS were significantly reduced for most of Fiscal 2020, including the quarter ended October 31, 2019 while the project activities of the Guernsey Power Station began. Over one-half of the revenues for this segment for the three-month period ended October 31, 2019 was provided by the operations of APC, including primarily the construction activities of the TeesREP Project.

Industrial Fabrication and Field Services

The revenues of industrial fabrication and field services (representing the business of TRC) provided 12.4% of consolidated revenues for the three months ended October 31, 2020, which reflected a reduction in revenues of $4.4 million, or 21.9%, to $15.7 million compared to revenues of $20.1 million for the three months ended October 31, 2019. New project awards have increased TRC’s project backlog to approximately $39.3 million as of October 31, 2020 from $14.0 million at the beginning of Fiscal 2021. However, a corresponding ramp-up of quarterly revenues has not yet occurred as the start-ups of field service projects in particular have been delayed by customers attributable, in part, to the impacts of COVID-19 on the operations of the customers.

31

Telecommunications Infrastructure Services

The revenues of this business segment (representing the business of SMC) were $1.9 million for the three months ended October 31, 2020 compared with revenues of $2.4 million for the three months ended October 31, 2019, with the decline, to some extent, due to the adverse impacts of COVID-19 on the operations of customers causing project delays. The project backlog of SMC has grown by approximately 119% since January 31, 2020.

Cost of Revenues

With the 118.0% increase in consolidated revenues for the three months ended October 31, 2020 compared with last year’s third quarter, the consolidated cost of revenues also increased between the quarters. These costs were $107.0 million and $52.4 million for the three months ended October 31, 2020 and 2019, respectively, an increase of approximately 104.1%.

For the three months ended October 31, 2020, we reported a consolidated gross profit of approximately $20.3 million which represented a gross profit percentage of approximately 16.0% of corresponding consolidated revenues. The gross profit for the three months ended October 31, 2020 reflected the consistent profit contribution of the construction activities related to the Guernsey Power Station; it was also favorably impacted by the profit contributions of APC, reflecting the most recent change to the contractual arrangements covering the construction activities of the TeesREP Project subcontract. The gross profit percentages of corresponding revenues for the power industry services, industrial services and the telecommunications infrastructure segments were 16.8%, 9.6% and 20.2%, respectively, for the quarter ended October 31, 2020.

Our gross profit reported for the three months ended October 31, 2019 was $6.0 million, or approximately 10.3% of corresponding consolidated revenues. Last year, both the gross profit amount and percentage for the third quarter were adversely affected by unfavorable contract adjustments at TRC and the lack of gross profit contribution from the TeesREP Project. The gross profit percentages of corresponding revenues for the power industry services, industrial services and the telecommunications infrastructure segments were 12.6%, 4.9% and 20.2%, respectively, for the quarter ended October 31, 2019.

Selling, General and Administrative Expenses

These costs were $9.4 million and $12.1 million for the three months ended October 31, 2020 and 2019, respectively, representing 7.4% and 20.8% of consolidated revenues for the corresponding periods, respectively. As disclosed earlier this year, we expect these costs, expressed as a percentage of corresponding revenues, to trend downward through the remaining quarters of the year ending January 31, 2021 (“Fiscal 2021”) and next year, primarily driven by the expected increase in consolidated revenues over the same periods. The reduction in actual costs between the quarters was due primarily to the increased utilization of staff by GPS on the Guernsey Power Station EPC project and reductions in the costs of travel.

Other Income

For the three months ended October 31, 2020 and 2019, the net amounts of other income were $0.2 million and $3.6 million, respectively, which represented a reduction of 95.1% between the comparable quarterly periods. The amounts reported for this line item reflect primarily investment income earned on funds maintained in money market accounts and interest income earned on CDs. Although the aggregate amount of invested funds has increased  meaningfully between the quarters and since January 31, 2020, the significant drop in interest rates that has occurred during the current year has had a meaningfully adverse effect on the returns earned on our invested funds. In addition, other income for the three months ended October 31, 2019 included a pre-tax gain of $2.2 million recorded by the consolidated variable interest entity in connection with the grant of a utility easement at the planned site of a new gas-fired power plant. This gain is also reflected in the amount of net income attributable to non-controlling interests for the three months ended October 31, 2019.

Income Taxes

We reported income tax expense for the three months ended October 31, 2020 in the amount of approximately $1.7 million. We estimate that our annual effective income tax rate for Fiscal 2021 before discrete items will approximate 23.9%. This tax rate differs from the statutory federal tax rate of 21% due primarily to the unfavorable effects of permanent differences, including certain nondeductible executive compensation. Despite incurring a loss before income taxes of $2.6 million for

32

the three months ended October 31, 2019, we reported income tax expense for the three months ended October 31, 2019 in the amount of approximately $2.0 million which primarily reflected unfavorable changes in the estimated annual effective income tax rate determined as of October 31, 2019.

Comparison of the Results of Operations for the Nine Months Ended October 31, 2020 and 2019

We reported net income attributable to our stockholders of $14.3 million, or $0.91 per diluted share, for the nine months ended October 31, 2020. For the nine months ended October 31, 2019, we reported a net loss attributable to our stockholders of $35.5 million, or $2.27 per diluted share.

The following schedule compares our operating results for the nine months ended October 31, 2020 and 2019 (dollars in thousands):

	Nine Months Ended October 31,
	2020		2019		$ Change		% Change
REVENUES
Power industry services	$	227,363	$	83,941	$	143,422	170.9	%
Industrial fabrication and field services		42,163		80,442		(38,279)	(47.6)
Telecommunications infrastructure services		5,445		6,626		(1,181)	(17.8)
Revenues		274,971		171,009		103,962	60.8
COST OF REVENUES
Power industry services		192,583		104,759		87,824	83.8
Industrial fabrication and field services		38,096		72,958		(34,862)	(47.8)
Telecommunications infrastructure services		4,310		5,361		(1,051)	(19.6)
Cost of revenues		234,989		183,078		51,911	28.4
GROSS PROFIT (LOSS)		39,982		(12,069)		52,051	NM
Selling, general and administrative expenses		28,827		31,761		(2,934)	(9.2)
Impairment loss		—		2,072		(2,072)	(100.0)
INCOME (LOSS) FROM OPERATIONS		11,155		(45,902)		57,057	NM
Other income, net		1,714		7,472		(5,758)	(77.1)
INCOME (LOSS) BEFORE INCOME TAXES		12,869		(38,430)		51,299	NM
Income tax benefit		1,391		4,936		(3,545)	(71.8)
NET INCOME (LOSS)		14,260		(33,494)		47,754	NM
Net (loss) income attributable to non-controlling interests		(40)		2,007		(2,047)	NM
NET INCOME (LOSS) ATTRIBUTABLE TO
THE STOCKHOLDERS OF ARGAN, INC.	$	14,300	$	(35,501)	$	49,801	NM

NM – Not meaningful.

Revenues

Power Industry Services

The revenues of the power industry services business increased by 170.9%, or $143.4 million, to $227.4 million for the nine months ended October 31, 2020 compared with revenues of $83.9 million for the nine months ended October 31, 2019, primarily due to the increasing revenues associated with the construction of the Guernsey Power Station by GPS. The revenues of this segment represented approximately 82.7% of consolidated revenues for the nine-month period ended October 31, 2020 and approximately 49.1% of consolidated revenues for the comparable prior year period.

As discussed above, GPS reached substantial completion on four gas-fired power plant projects late in Fiscal 2019 and concluded activities on a fifth gas-fired power plant in the first quarter of Fiscal 2020. As a result, the revenues of GPS were reduced substantially for the nine months ended October 31, 2019 despite the contribution of revenues provided by the start-up activities of the Guernsey Power Station project during the third quarter last year.

Conversely, the revenues of APC declined for the nine months ended October 31, 2020 from the amount of revenues recognized during the nine months ended October 31, 2019, which represented the majority of revenues for this segment

33

last year. The current year-to-date revenues of APC were adversely affected, to a certain degree, by the suspension of work on the TeesREP Project and the postponement of Irish works in response to the COVID-19 pandemic during the current year. More significantly, both the construction of the gas-fired power plant in Spalding, England, and the refurbishment of the turbines for the Moneypoint Power Station in Ireland were completed last year.

Industrial Fabrication and Field Services

The revenues of industrial fabrication and field services (representing the business of TRC) provided 15.3% of consolidated revenues for the nine months ended October 31, 2020, which reflected a reduction in revenues of $38.3 million, or 47.6%, to $42.2 million compared to revenues of $80.4 million for the nine months ended October 31, 2019. With the completion of several large projects last year, the resulting low level of activity on projects this year has unfavorably affected TRC’s revenues for the current year. The improvement in the quarterly revenues of TRC noted for the second quarter, attributed to customers beginning to resume normal plant operations and to commence projects suspended earlier in the year due to the COVID-19 pandemic, did not accelerate during the third quarter. New project awards have increased TRC’s current project backlog to approximately $39.3 million as of October 31, 2020 from $14.0 million at January 31, 2020. However, a corresponding ramp-up of quarterly revenues has not yet occurred as the start-ups of field service projects in particular have been delayed by customers.

Telecommunications Infrastructure Services

The revenues of this business segment (representing the business of SMC) were $5.4 million for the nine months ended October 31, 2020 compared with revenues of $6.6 million for the nine months ended October 31, 2019.

Cost of Revenues

With the increase in consolidated revenues for the nine months ended October 31, 2020 compared with last year’s corresponding period, the consolidated cost of revenues also increased between the periods by 28.4%. These costs were $235.0 million, represented substantially by projects costs incurred on the Guernsey Power Station, and $183.1 million, represented substantially by project costs incurred by TRC and APC, for the nine months ended October 31, 2020 and 2019, respectively. Last year, our cost of revenues included a charge in the amount of $8.6 million representing the amount of the TeesREP subcontract loss reserve on the books of APC as of October 31, 2019.

For the nine months ended October 31, 2020, we reported a consolidated gross profit of approximately $40.0 million, which represented a gross profit percentage of approximately 14.5% of corresponding consolidated revenues. The gross profit percentages of corresponding revenues for the power industry services, industrial services and the telecommunications infrastructure segments were 15.3%, 9.6% and 20.8%, respectively, for the nine months ended October 31, 2020.

The loss incurred by APC on the TeesREP Project in the amount of $31.2 million for the nine months ended October 31, 2019 had a significant unfavorable effect on the Company’s gross profit, which was the primary factor in our reporting a consolidated gross loss for the nine-month period in the amount of $12.1 million. The gross (loss) profit percentages of corresponding revenues for the power industry services, industrial services and the telecommunications infrastructure segments were (24.8)%, 9.3% and 19.1%, respectively, for the nine months ended October 31, 2019.

Selling, General and Administrative Expenses

These costs were $28.8 million and $31.8 million for the nine months ended October 31, 2020 and 2019, respectively, representing 10.5% and 18.6% of consolidated revenues for the corresponding periods, respectively. The 9.2% decrease in expenses between the periods was primarily due to the costs incurred last year by GPS in order to maintain the core members of the operations staff, before the start-up of new EPC projects, whose time is typically charged to active projects to a greater degree.

Impairment Loss

APC recorded a substantial loss on the TeesREP Project during the first quarter last year. We considered the recognition of a contract loss of this magnitude to be an event triggering a re-assessment of the goodwill of APC which resulted in our

34

conclusion that the remaining balance was impaired. Accordingly, an impairment loss was recorded in the amount of $2.1 million which was reflected in our consolidated operating results for the nine months ended October 31, 2019.

Other Income

For the nine months ended October 31, 2020 and 2019, the net amounts of other income were $1.7 million and $7.5 million, respectively, which represented a reduction of 77.1% between the comparable periods. Although the aggregate amount of invested funds has increased between the comparable periods and since January 31, 2020, the significant drop in interest rates that has occurred during the current year has had a meaningfully adverse effect on the returns earned on our temporarily invested funds. Other income for the nine months ended October 31, 2019 included the pre-tax gain of $2.2 million recorded by the consolidated variable interest entity during the period. This gain was also reflected in the amount of income attributable to non-controlling interests for the nine months ended October 31, 2019.

Income Taxes

We reported an income tax benefit for the nine months ended October 31, 2020 in the net amount of approximately $1.4 million, which reflected primarily the net operating loss carryback benefit in the approximate amount of $4.4 million that is discussed in the following paragraph.

In a response to the COVID-19 health crisis, the US Congress passed the CARES Act that was signed into law on March 27, 2020. This wide-ranging legislation was enacted as an emergency economic stimulus package including spending and tax breaks aimed at strengthening the US economy and funding a nationwide effort to curtail the effects of the outbreak of COVID-19. The CARES Act has provided many opportunities for taxpayers to evaluate their 2018 and 2019 income tax returns to identify potential tax refunds. One such area is the utilization of NOLs. The tax changes of the CARES Act removed the limitations on the future utilization of certain NOLs and re-established a carryback period for certain losses to five years. The losses eligible for carryback under the CARES Act include our consolidated NOL for Fiscal 2020, which was approximately $39.5 million. With the filing of our consolidated federal income tax return for Fiscal 2020, we have elected to apply the NOL against our taxable income for the year ended January 31, 2015. This provides a favorable rate benefit for us as the loss, which was incurred in a year where the statutory federal tax rate was 21%, will be carried back to a tax year where the tax rate was higher.

We estimate that our annual effective income tax rate for Fiscal 2021 before discrete items will approximate 23.9%. This tax rate differs from the statutory federal tax rate of 21% due primarily to the unfavorable effects of certain permanent differences as referenced above.

We reported an income tax benefit for the nine months ended October 31, 2019 in the amount of approximately $4.9 million which primarily reflected the favorable tax impact of bad debt loss realized on loans made to APC by Argan that was recorded in the second quarter last year. We did not record any income tax benefit related to the net loss reported by the subsidiary operations of APC located in the United Kingdom last year due to our expectation at that time that only a minimal portion of the benefit, if any, would be utilized in future years. However, as  this subsidiary is expected to report income for Fiscal 2021, approximately $0.1 of tax benefit was recorded during the nine-month period ended October 31, 2020. The consolidated income tax benefit for the nine months ended October 31, 2019 does reflect the unfavorable expected effects of state income taxes and permanent differences associated with nondeductible travel and entertainment expenses, certain nondeductible executive compensation expense and the goodwill impairment loss.

Liquidity and Capital Resources as of October 31, 2020

At October 31 and January 31, 2020, our balances of cash and cash equivalents were $353.2 million and $167.4 million, respectively. During this same period, our working capital increased by $0.1 million to $277.8 million as of October 31, 2020 from $277.7 million as of January 31, 2020.

The net amount of cash provided by operating activities for the nine months ended October 31, 2020 was $142.6 million. Our net income for the nine months ended October 31, 2020, adjusted favorably by the net amount of non-cash income and expense items, represented a source of cash in the total amount of $27.5 million. However, the sources of cash from operations for the current year period included primarily a temporary increase in the balance of contract liabilities  associated with the early phases of the Guernsey Power Station construction and new project awards at TRC in the amount

35

of $87.9 million. Reductions in the balances of accounts receivable and contract assets, primarily at the TRC and APC operations, provided cash in the amounts of $6.6 million and $6.2 million, respectively. In addition, the combined level of accounts payable and accrued expenses increased by $28.9 million during the nine months ended October 31, 2020, a source of cash for the period.

As discussed above, our income tax accounting for the nine months ended October 31, 2020 reflects an entry to record the carryback of our net operating loss incurred for the year ended January 31, 2020 to our tax year ended January 31, 2015. The loss carryback should result in a refund of federal income taxes in the amount of $12.7 million. This tax refund receivable has been included in the balance of other current assets as of October 31, 2020, which was the primary cause of the increase in this balance of $14.5 million during the period, a use of cash.

Primary sources of cash for the nine months ended October 31, 2020 were the net maturities of short-term investments, certificates of deposit issued by the Bank, in the amount of $70.0 million. Non-operating activities used cash during the nine months ended October 31, 2020, including the payment of regular and special cash dividends in the total amount of $27.4 million. During the nine-month period ended October 31, 2020, capital expenditures were reduced by approximately 77.6% to $1.4 million from a capital expenditures amount of $6.3 million for the nine months ended October 31, 2019. Partially offsetting these uses of cash, we received cash proceeds related to the exercise of stock options during the nine months ended October 31, 2020 in the amount of $1.2 million. As of October 31, 2020, there were no restrictions with respect to inter-company payments between GPS, TRC, APC, SMC and the holding company. However, during the prior year, certain loans made by Argan to APC were determined to be uncollectible.

Last year, the net amount of cash provided by operating activities for the nine months ended October 31, 2019 was $15.9 million. Our net loss for the period, offset partially by the favorable adjustments related to non-cash income and expense items, used cash in the total amount of $29.3 million. The Company also used cash during the nine months ended October 31, 2019 in the amount of $12.5 million to reduce the level of accounts payable and accrued expenses. However, these uses of cash were more than offset by the receipt of payments on the initial billings for EPC project work, which caused the balance of contract liabilities to increase temporarily by $50.1 million during the nine months ended October 31, 2019, a substantial source of cash.

Cash required to fund operations during the nine months ended October 31, 2019 was provided primarily by the net maturities of short-term investments, certificates of deposit issued by our Bank, in the amount of $89.0 million. Cash proceeds in the amount of $1.6 million were received from the exercise of stock options during the nine-month period ended October 31, 2019. Non-operating activities used cash during the nine months ended October 31, 2019, including the payment of three quarterly cash dividends in the total amount of $11.7 million and capital expenditures in the amount of $6.3 million.

At October 31, 2020, most of our balance of cash and cash equivalents was invested in money market funds with most of their total assets invested in cash, US Treasury obligations and repurchase agreements secured by US Treasury obligations. The major portion our domestic operating bank account balances are maintained with the Bank. We do maintain certain Euro-based bank accounts in Ireland and certain pound sterling-based bank accounts in the UK in support of the operations of APC.

Our Credit Agreement, which expires on May 31, 2021, includes the following features, among others: a lending commitment of $50.0 million including a revolving loan with interest at the 30-day LIBOR plus 2.0%, and an accordion feature which allows for an additional commitment amount of $10.0 million, subject to certain conditions. We may use the borrowing ability to cover other credit instruments issued by the Bank for our use in the ordinary course of business as defined by the Bank. At October 31, 2020, we had $1.7 million of outstanding letters of credit issued under the Credit Agreement. However, we had no outstanding borrowings. Additionally, in connection with the current project development activities by a VIE, the Bank issued a letter of credit, outside the scope of the Credit Agreement, in the approximate amount of $3.4 million for which the Company has provided cash collateral.

We have pledged the majority of our assets to secure the financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Credit Agreement requires that we comply with certain financial covenants at our fiscal year-end and at each fiscal quarter-end, and includes other terms, covenants and events of default that are customary for a credit facility of its size and nature. At

36

October 31 and January 31, 2020, we were compliant with the financial covenants of the Credit Agreement. We expect that we will negotiate either an extension or a replacement agreement prior to the current expiration date of the Credit Agreement.

In the normal course of business and for certain major projects, we may be required to obtain surety or performance bonding, to provide parent company guarantees, or to cause the issuance of letters of credit (or some combination thereof) in order to provide performance assurances to clients on behalf of one of our contractor subsidiaries.

If our services under a guaranteed project would not be completed or would be determined to have resulted in a material defect or other material deficiency, then we could be responsible for monetary damages or other legal remedies. As is typically required by any surety bond, the Company would be obligated to reimburse the issuer of any surety bond issued on behalf of a subsidiary for any cash payments made thereunder. The commitments under performance bonds generally end concurrently with the expiration of the related contractual obligation. Not all of our projects require bonding.

On behalf of APC, Argan has provided a parent company performance guarantee to its customer, the EPC services contractor on the TeesREP Project. Earlier this year, and in connection with the negotiation of Amendment No. 2, the Company replaced an outstanding letter of credit in the amount of $7.6 million with a surety bond.

As of October 31, 2020, the revenue value of the Company’s unsatisfied bonded performance obligations was less than the value of RUPO disclosed in Note 2 to the accompanying condensed consolidated financial statements. In addition, as of October 31, 2020, there were bonds outstanding in the aggregate amount of approximately $35.0 million covering other risks including warranty obligations related to projects completed by GPS; these bonds expire at various dates over the next sixteen months.

When sufficient information about claims related to our performance on projects would be available and monetary damages or other costs or losses would be determined to be probable, we would record such guaranteed losses. As our subsidiaries are wholly-owned, any actual liability related to contract performance is ordinarily reflected in the financial statement account balances determined pursuant to the Company’s accounting for contracts with customers. Any amounts that we may be required to pay in excess of the estimated costs to complete contracts in progress as of October 31, 2020 are not estimable.

We have also provided a financial guarantee on behalf of GPS to an original equipment manufacturer in the amount of $3.6 million to support project developmental efforts.

We believe that cash on hand, cash that will be provided from the maturities of short-term investments and cash generated from our future operations, with or without funds available under our line of credit, will be adequate to meet our general business needs in the foreseeable future. For the nine months ended October 31, 2020, to assure an optimum level of liquidity during this period of uncertainty and to mitigate the market risks represented by the COVID-19 pandemic, management decided to temporarily maintain larger balances of cash and cash equivalents relative to short-term investments with minimal opportunity cost.

In general, we maintain significant liquid capital in our balance sheet to help ensure our ability to maintain bonding capacity and to provide parent company performance guarantees for EPC and other construction projects. Any future acquisitions, or other significant unplanned cost or cash requirement, may require us to raise additional funds through the issuance of debt and/or equity securities. There can be no assurance that such financing will be available on terms acceptable to us, or at all.

Earnings before Interest, Taxes, Depreciation and Amortization (“EBITDA”)

We believe that EBITDA is a meaningful presentation that enables us to assess and compare our operating cash flow performance on a consistent basis by removing from our operating results the impacts of our capital structure, the effects of the accounting methods used to compute depreciation and amortization and the effects of operating in different income tax jurisdictions. Further, we believe that EBITDA is widely used by investors and analysts as a measure of performance.

However, as EBITDA is not a measure of performance calculated in accordance with US GAAP, we do not believe that this measure should be considered in isolation from, or as a substitute for, the results of our operations presented in accordance with US GAAP that are included in our condensed consolidated financial statements. In addition, our EBITDA

37

does not necessarily represent funds available for discretionary use and is not necessarily a measure of our ability to fund our cash needs.

The following table presents the determinations of EBITDA for the three and nine months ended October 31, 2020 and 2019, respectively (amounts in thousands):

As we believe that our net cash flow provided by or used in operations is the most directly comparable performance measure determined in accordance with US GAAP, the following table reconciles the amounts of EBITDA for the applicable nine-month periods, as presented above, to the corresponding amounts of net cash flows provided by or used in operating activities that are presented in our condensed consolidated statements of cash flows for the nine months ended October 31, 2020 and 2019 (amounts in thousands).

	Three Months Ended
	October 31,
	2020		2019
Net income (loss), as reported	$	9,454	$	(4,561)
Income tax expense		1,666		1,996
Depreciation		940		899
Amortization of purchased intangible assets		226		272
EBITDA		12,286		(1,394)
EBITDA of non-controlling interests		—		2,294
EBITDA attributable to the stockholders of Argan, Inc.	$	12,286	$	(3,688)

	Nine Months Ended
	October 31,
	2020		2019
Net income (loss), as reported	$	14,260	$	(33,494)
Income tax benefit		(1,391)		(4,936)
Depreciation		2,798		2,610
Amortization of purchased intangible assets		677		864
EBITDA		16,344		(34,956)
EBITDA of non-controlling interests		(40)		2,007
EBITDA attributable to the stockholders of Argan, Inc.	$	16,384	$	(36,963)

	Nine Months Ended
	October 31,
	2020		2019
EBITDA	$	16,344	$	(34,956)
Current income tax benefit		9,757		415
Stock option compensation expense		2,199		1,512
Impairment loss		—		2,072
Other non-cash items		1,911		1,631
Decrease in accounts receivable		6,585		1,274
Increase in other assets		(15,976)		(1,588)
Increase (decrease) in accounts payable and accrued expenses		27,725		(12,523)
Change in contracts in progress, net		94,015		58,064
Net cash provided by operating activities	$	142,560	$	15,901

Critical Accounting Policies

Critical accounting policies are those related to the areas where we have made what we consider to be particularly subjective or complex judgments in arriving at estimates and where these estimates can significantly impact our financial results under different assumptions and conditions. These estimates, judgments, and assumptions affect the reported amounts of assets, liabilities and equity, the disclosure of contingent assets and liabilities at the date of financial statements and the reported amounts of revenues and expenses during the reporting periods. We base our estimates on historical experience and various other assumptions that we believe are reasonable under the circumstances, the results of which

38

form the basis for making judgments about the carrying value of assets, liabilities and equity that are not readily apparent from other sources. Actual results and outcomes could differ from these estimates and assumptions.

We consider the accounting policies related to revenue recognition on long-term construction contracts; income tax reporting; the accounting for business combinations; the subsequent valuation of goodwill, other indefinite-lived assets and long-lived assets; the valuation of employee common stock-based awards; and the financial reporting associated with any significant claims or legal matters to be most critical to the understanding of our financial position and results of operations, as well as the accounting and reporting for special purpose entities including joint ventures and variable interest entities. An expanded discussion of our critical accounting policies is included in Item 7 of Part II of our Annual Report. During the nine-month period ended October 31, 2020, there have been no material changes in the way we apply the critical accounting policies described therein.

Recently Issued Accounting Pronouncements

In December 2019, the FASB issued ASU 2019-12, Simplifying the Accounting for Income Taxes, which, among other changes, eliminates the exception to the general methodology for calculating income taxes in an interim period when a year-to-date loss exceeds the expected loss for the entire year. In these instances, the estimated annual effective income tax rate shall be used to calculate the tax without limitation. The new standard also requires the recognition of a franchise (or similar) tax that is partially based on income as an income-based tax and the recording of any incremental tax that is incurred by us as a non-income based tax. The requirements of this new guidance, effective for us on February 1, 2021, are not expected to alter our accounting for income taxes.

In 2016, the FASB also issued ASU 2016-13, Measurement of Credit Losses on Financial Instruments. The requirements of this new standard cover, among other provisions, the methods that businesses shall use to estimate amounts of credit losses. As subsequently amended, the adoption of this new guidance, which became effective for us on February 1, 2020, did not affect our consolidated financial statements.

There are no other recently issued accounting pronouncements that have not yet been adopted that we consider material to our consolidated financial statements. As required for us, we adopted ASU 2016-02, Leases, as of February 1, 2019.

ITEM 3. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

In the normal course of business, our results of operations may be subject to risks related to fluctuations in interest rates. As of October 31, 2020, we had no outstanding borrowings under our financing arrangements with the Bank (see Note 6 to the accompanying condensed consolidated financial statements), which provide a revolving loan with a maximum borrowing amount of $50.0 million that is available until May 31, 2021 with interest at 30-day LIBOR plus 2.0%. During the nine months ended October 31, 2020 and 2019, we did not enter into derivative financial instruments for trading, speculation or other purposes that would expose us to market risk.

Financial markets around the globe are preparing for the discontinuation of LIBOR at the end of 2021 as the widely used indicator of basis for short-term lending rates. The transition from LIBOR is market-driven, not a change required by regulation. The US and other countries are currently working to replace LIBOR with alternative reference rates. We do not expect that the replacement of LIBOR as the basis for the determination of our short-term borrowing rate will have significant effects on the financial arrangements with the Bank or our financial reporting.

We maintain a substantial amount of our temporarily investable funds in a money market account (see Note 3 of the accompanying condensed consolidated financial statements). The balance of these funds, which was included in cash and cash equivalents in our condensed consolidated balance sheet as of October 31, 2020, was $266.9 million with earnings based on a blended annual yield of 0.05%. The significant drop in interest rates during the nine months ended October 31, 2020 has caused a significant reduction in the investment returns earned on these funds by us. At January 31, 2020, our money market funds were providing earnings based on an annual yield of 1.49%.

As of October 31, 2020, the weighted average annual interest rate on our short-term investments of $90.0 million was 0.17%. To illustrate the potential impact of changes in interest rates on our results of operations, we present the following hypothetical analysis, which assumes that our condensed consolidated balance sheet as of October 31, 2020 remains constant, and no further actions are taken to alter our existing interest rate sensitivity, including reinvestments.

39

As the weighted average annual interest rate on our short-term investments held at October 31, 2020 was 0.17%, the largest decrease in the interest rates presented below is 17 basis points (dollars in thousands).

	Increase (Decrease) in		Increase (Decrease) in		Net Increase (Decrease) in
Basis Point Change	Interest Income		Interest Expense		Income (pre-tax)
Up 300 basis points	$	1,892	$	—	$	1,892
Up 200 basis points		1,261		—		1,261
Up 100 basis points		631		—		631
Down 17 basis points		(101)		—		(101)

With the consolidation of APC, we are subject to the effects of translating the financial statements of APC from its functional currency (Euros) into our reporting currency (US dollars). Such effects are recognized in accumulated other comprehensive loss, which is net of tax when applicable. APC remeasures transactions and subsidiary financial statements denominated in local currencies to Euros. Gains and losses on the remeasurements are recorded in the other income line of our condensed consolidated statements of earnings.

In addition, we are subject to fluctuations in prices for commodities including copper, concrete, steel products and fuel. Although we attempt to secure firm quotes from our suppliers, we generally do not hedge against increases in prices for these commodities. Commodity price risks may have an impact on our results of operations due to the fixed-price nature of many of our contracts. We attempt to include the anticipated amounts of price increases or decreases in the costs of our bids.

ITEM 4. CONTROLS AND PROCEDURES

Evaluation of disclosure controls and procedures. Our management, with the participation of our chief executive officer and chief financial officer, evaluated the effectiveness of our disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934 (the “Exchange Act”)) as of October 31, 2020. Management recognizes that any controls and procedures, no matter how well designed and operated, can provide only reasonable assurance of achieving their objectives, and management necessarily applies its judgment in evaluating the cost-benefit relationship of possible controls and procedures. Based on the evaluation of our disclosure controls and procedures as of October 31, 2020, our chief executive officer and chief financial officer concluded that, as of such date, our disclosure controls and procedures were effective to provide reasonable assurance that information required to be disclosed in our Exchange Act reports is recorded, processed, summarized, and reported within the time periods specified by the SEC, and the material information related to the Company and its consolidated subsidiaries is made known to management, including the chief executive officer and chief financial officer, to allow timely decisions regarding required disclosure in the reports.

Changes in internal controls over financial reporting. There have been no significant changes in our internal control over financial reporting (as defined in Rules 13a-15 and 15d-15 under the Exchange Act) during the fiscal quarter ended October 31, 2020 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

PART II

ITEM 1. LEGAL PROCEEDINGS

Included in Note 8 to the condensed consolidated financial statements that are included in Item 1 of Part I of this Quarterly Report on Form 10-Q is the discussion of the status of a specific legal proceeding as of October 31, 2020. In the normal course of business, we may have other pending claims and legal proceedings. It is our opinion, based on information available at this time, that any other current claim or proceeding will not have a material effect on our condensed consolidated financial statements.

ITEM 1A. RISK FACTORS

In the section of Item 2 in Part 1 of this Quarterly Report on Form 10-Q, Management’s Discussion and Analysis of Financial Condition and Results of Operations, identified as Major Customer Contracts, we discuss that certain published policies of president-elect Biden relating to attempts to confront the unfavorable effects of climate change may result in

40

decisions that adversely affect the growth propects for our business. In addition, the tax plan he has released proposes many changes to payroll taxes and individual and business income taxes, including an increase in the corporate income tax rate from 21% to 28%. If enacted, such an increase would have unfavorable effects of our future net income amounts and cash flows from operations.  

There have been no other material changes to the risk factors disclosed in our Annual Report.

ITEM 2. UNREGISTERED SALES OF EQUITY SECURITIES AND USE OF PROCEEDS

On June 24, 2020, we made a filing on Current Report Form 8-K announcing that our board of directors authorized the repurchase of up to $25.0 million of our issued and outstanding common stock through June 2022 (the “Repurchase Plan”). The repurchases may occur in the open market or through investment banking institutions, privately-negotiated transactions, or direct purchases, and the timing and amount of stock repurchased will depend on market and business conditions, applicable legal and credit requirements and other corporate considerations. To date, there have not been any purchases made under the Repurchase Plan.

In accordance with the SEC’s Rule 10b5-1, we have allowed, and may in the future allow, the repurchase of our common stock during trading blackout periods by an investment banking firm or other institution agent acting on our behalf pursuant to predetermined parameters.

ITEM 3. DEFAULTS UPON SENIOR SECURITIES

None

ITEM 4. MINE SAFETY DISCLOSURES (not applicable)

ITEM 5. OTHER INFORMATION

None

ITEM 6. EXHIBITS

Exhibit No.	Title
Exhibit 10.1	Amendment No. 2020-1 to the Gemma Power Systems, LLC Deferred Compensation Plan.
Exhibit 31.1	Certification of Chief Executive Officer, pursuant to Rule 13a-14(c) under the Securities Exchange Act of 1934.
Exhibit 31.2	Certification of Chief Financial Officer, pursuant to Rule 13a-14(c) under the Securities Exchange Act of 1934.
Exhibit 32.1	Certification of Chief Executive Officer, pursuant to 18 U.S.C. Section 1350. *
Exhibit 32.2	Certification of Chief Financial Officer, pursuant to 18 U.S.C. Section 1350. *
Exhibit 101: Exhibit 101.INS	XBRL Instance Document – the instance document does not appear in the Interactive Data File because its XBRL tags are embedded within the Inline XBRL document.
Exhibit 101.SCH	Inline XBRL Taxonomy Extension Schema.
Exhibit 101.CAL	Inline XBRL Taxonomy Extension Calculation Linkbase.
Exhibit 101.LAB	Inline XBRL Taxonomy Label Linkbase.
Exhibit 101.PRE	Inline XBRL Taxonomy Presentation Linkbase.
Exhibit 101.DEF	Inline XBRLTaxonomy Extension Definition Document.
Exhibit 104	Cover Page Interactive Data File – the cover page interactive data file does not appear in the Interactive Data File because its XBRL tags are embedded within the Inline XBRL document.

* The certification is being furnished and shall not be considered filed as part of this report.

41

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the Registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

	ARGAN, INC.
December 9, 2020	By:	/s/ Rainer H. Bosselmann
		Rainer H. Bosselmann
		Chairman of the Board and Chief Executive Officer
December 9, 2020	By:	/s/ David H. Watson
		David H. Watson
		Senior Vice President, Chief Financial Officer,
		Treasurer and Secretary

42

EX-10.1

Exhibit 10.1

AMENDMENT NO. 2020-1

TO THE

GEMMA POWER SYSTEMS, LLC

DEFERRED COMPENSATION PLAN

The Gemma Power Systems, LLC Deferred Compensation Plan (the "Plan"), is hereby amended effective January 1, 2020 pursuant to Section 8.1 of the Plan, as follows:

I.

Section 2.6 of the Plan is deleted in its entirety and replaced with the following new Section 2.6:

2.6"Committee" shall mean an administrative committee appointed by the Board of Managers of the Employer.

II.

Section 2.11 of the Plan is deleted in its entirety and replaced with the following Section 2.11:

2.11"Eligible Employee" shall mean the employees of the Employer selected by the Board of Managers of the Employer from time to time to be eligible to participate in the Plan, provided that the individual must be a highly compensated or management employee of the Employer within the meaning of Sections 201(2), 301(a)(3) and 401(a)(1) of ERISA.

III.

If there shall be any inconsistency between the provisions of this Amendment No. 2020-1 and the provisions of this Plan, this Amendment No. 2020-1 shall control.

IN WITNESS WHEREOF, the Company has caused this Amendment No. 2020-1 to be executed by its duly authorized officer on this ____ day of ______________________, 2020, effective as hereinabove set forth.

GEMMA POWER SYSTEMS, LLC

By:______________________________

Title:______________________________

EX-31.1

Exhibit 31.1

SARBANES-OXLEY ACT SECTION 302(a) CERTIFICATION

I, Rainer H. Bosselmann, certify that:

1.    I have reviewed this Quarterly Report on Form 10-Q of Argan, Inc. (the “Registrant”) for the period ended October 31, 2020;

2.    Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

3.    Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the Registrant as of, and for, the periods presented in this report;

4.    The Registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the Registrant and have:

a)    Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the Registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;

b)    Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;

c)    Evaluated the effectiveness of the Registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures as of the end of the period covered by this report based on such evaluation; and

d)    Disclosed in this report any change in the Registrant’s internal control over financial reporting that occurred during the Registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the Registrant’s internal control over financial reporting; and

5.    The Registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the Registrant’s auditors and the audit committee of the Registrant’s board of directors (or persons performing the equivalent functions):

a)    All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the Registrant’s ability to record, process, summarize and report financial information; and

b)    Any fraud, whether or not material, that involves management or other employees who have a significant role in the Registrant’s internal control over financial reporting.

Date: December 9, 2020	By:	/s/ Rainer H. Bosselmann
		Rainer H. Bosselmann
		Chairman of the Board and Chief Executive Officer
		(Principal Executive Officer)

EX-31.2

Exhibit 31.2

SARBANES-OXLEY ACT SECTION 302(a) CERTIFICATION

I, David H. Watson, certify that:

1.    I have reviewed this Quarterly Report on Form 10-Q of Argan, Inc. (the “Registrant”) for the period ended October 31, 2020;

2.    Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

3.    Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the Registrant as of, and for, the periods presented in this report;

4.    The Registrant’s other certifying officer and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the Registrant and have:

a)    Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the Registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;

b)    Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;

c)    Evaluated the effectiveness of the Registrant’s disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures as of the end of the period covered by this report based on such evaluation; and

d)    Disclosed in this report any change in the Registrant’s internal control over financial reporting that occurred during the Registrant’s most recent fiscal quarter that has materially affected, or is reasonably likely to materially affect, the Registrant’s internal control over financial reporting; and

5.    The Registrant’s other certifying officer and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the Registrant’s auditors and the audit committee of the Registrant’s board of directors (or persons performing the equivalent functions):

a)    All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the Registrant’s ability to record, process, summarize and report financial information; and

b)    Any fraud, whether or not material, that involves management or other employees who have a significant role in the Registrant’s internal control over financial reporting.

Date: December 9, 2020	By:	/s/ David H. Watson
		David H. Watson
		Senior Vice President, Chief Financial Officer, Treasurer and Secretary
		(Principal Financial Officer)

EX-32.1

Exhibit 32.1

CERTIFICATION PURSUANT TO

18 U.S.C. SECTION 1350,

AS ADOPTED PURSUANT TO

SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002

In connection with the Quarterly Report of Argan, Inc., a Delaware corporation (the “Company”), on Form 10-Q for the period ended October 31, 2020, as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, Rainer H. Bosselmann, Chairman and Chief Executive Officer of the Company, hereby certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that to the best of my knowledge:

1.     The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and

2.     Information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

Date: December 9, 2020	By:	/s/ Rainer H. Bosselmann
		Rainer H. Bosselmann
		Chairman of the Board and Chief Executive Officer
		(Principal Executive Officer)

EX-32.2

Exhibit 32.2

CERTIFICATION PURSUANT TO

18 U.S.C. SECTION 1350,

AS ADOPTED PURSUANT TO

SECTION 906 OF THE SARBANES-OXLEY ACT OF 2002

In connection with the Quarterly Report of Argan, Inc., a Delaware corporation (the “Company”), on Form 10-Q for the period ended October 31, 2020, as filed with the Securities and Exchange Commission on the date hereof (the “Report”), I, David H. Watson, Senior Vice President and Chief Financial Officer of the Company, hereby certify, pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that to the best of my knowledge:

1.     The Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934; and

2.     Information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

Date: December 9, 2020	By:	/s/ David H. Watson
		David H. Watson
		Senior Vice President, Chief Financial Officer, Treasurer and Secretary
		(Principal Financial Officer)

XML

Document and Entity Information - shares	9 Months Ended
	Oct. 31, 2020	Dec. 07, 2020
Document And Entity Information
Document Type	10-Q
Document Quarterly Report	true
Document Period End Date	Oct. 31, 2020
Document Transition Report	false
Entity File Number	001-31756
Entity Registrant Name	ARGAN INC
Entity Central Index Key	0000100591
Entity Incorporation, State or Country Code	DE
Entity Tax Identification Number	13-1947195
Entity Address, Address Line One	One Church Street, Suite 201
Entity Address, City or Town	Rockville
Entity Address, State or Province	MD
Entity Address, Postal Zip Code	20850
City Area Code	301
Local Phone Number	315-0027
Amendment Flag	false
Current Fiscal Year End Date	--01-31
Entity Current Reporting Status	Yes
Entity Interactive Data Current	Yes
Entity Filer Category	Accelerated Filer
Entity Small Business	false
Entity Emerging Growth Company	false
Entity Shell Company	false
Title of 12(b) Security	Common Stock, $.15 par value
Trading Symbol	AGX
Security Exchange Name	NYSE
Entity Common Stock, Shares Outstanding		15,689,969
Document Fiscal Year Focus	2021
Document Fiscal Period Focus	Q3

XML

CONDENSED CONSOLIDATED STATEMENTS OF EARNINGS - USD ($) shares in Thousands, $ in Thousands	3 Months Ended		9 Months Ended
	Oct. 31, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019
CONDENSED CONSOLIDATED STATEMENTS OF EARNINGS
REVENUES	$ 127,331	$ 58,406	$ 274,971	$ 171,009
Cost of revenues	106,988	52,414	234,989	183,078
GROSS PROFIT (LOSS) (Note 2)	20,343	5,992	39,982	(12,069)
Selling, general and administrative expenses	9,398	12,135	28,827	31,761
Impairment loss				2,072
INCOME (LOSS) FROM OPERATIONS	10,945	(6,143)	11,155	(45,902)
Other income, net	175	3,578	1,714	7,472
INCOME (LOSS) BEFORE INCOME TAXES	11,120	(2,565)	12,869	(38,430)
Income tax (expense) benefit (Note 10)	(1,666)	(1,996)	1,391	4,936
NET INCOME (LOSS)	9,454	(4,561)	14,260	(33,494)
Net income (loss) attributable to non-controlling interests		2,294	(40)	2,007
NET INCOME (LOSS) ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.	9,454	(6,855)	14,300	(35,501)
Foreign currency translation adjustments	(321)	235	(650)	(825)
COMPREHENSIVE INCOME (LOSS) ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.	$ 9,133	$ (6,620)	$ 13,650	$ (36,326)
NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC. (Note 11)
Basic (in Dollars per share)	$ 0.60	$ (0.44)	$ 0.91	$ (2.27)
Diluted (in Dollars per share)	$ 0.60	$ (0.44)	$ 0.91	$ (2.27)
WEIGHTED AVERAGE NUMBER OF SHARES OUTSTANDING
Basic (in shares)	15,680	15,633	15,659	15,617
Diluted (in shares)	15,833	15,633	15,795	15,617
CASH DIVIDENDS PER SHARE (Note 12)	$ 0.25	$ 0.25	$ 1.75	$ 0.75

XML

CONDENSED CONSOLIDATED BALANCE SHEETS - USD ($) $ in Thousands	Oct. 31, 2020	Jan. 31, 2020
CURRENT ASSETS
Cash and cash equivalents	$ 353,213	$ 167,363
Short-term investments	90,017	160,499
Accounts receivable, net	30,607	37,192
Contract assets	27,223	33,379
Other current assets (Note 10)	37,760	23,322
TOTAL CURRENT ASSETS	538,820	421,755
Property, plant and equipment, net	20,966	22,539
Goodwill	27,943	27,943
Other purchased intangible assets, net	4,324	5,001
Deferred taxes		7,894
Right-of-use and other assets	3,447	2,408
TOTAL ASSETS	595,500	487,540
LIABILITIES AND EQUITY CURRENT LIABILITIES
Accounts payable	48,836	35,442
Accrued expenses (Note 10)	51,650	35,907
Contract liabilities	160,544	72,685
TOTAL CURRENT LIABILITIES	261,030	144,034
Deferred taxes	472
Other noncurrent liabilities	3,334	2,476
TOTAL LIABILITIES	264,836	146,510
COMMITMENTS AND CONTINGENCIES (Notes 7 and 8)
STOCKHOLDERS' EQUITY
Preferred stock, par value $0.10 per share - 500,000 shares authorized; no shares issued and outstanding
Common stock, par value $0.15 per share - 30,000,000 shares authorized; 15,693,202 and 15,638,202 shares issued at October 31 and January 31, 2020, respectively; 15,689,969 and 15,634,969 shares outstanding at October 31 and January 31, 2020, respectively	2,354	2,346
Additional paid-in capital	152,149	148,713
Retained earnings	176,186	189,306
Accumulated other comprehensive loss	(1,766)	(1,116)
TOTAL STOCKHOLDERS' EQUITY	328,923	339,249
Non-controlling interests	1,741	1,781
TOTAL EQUITY	330,664	341,030
TOTAL LIABILITIES AND EQUITY	$ 595,500	$ 487,540

XML

CONDENSED CONSOLIDATED BALANCE SHEETS (Parenthetical) - $ / shares	Oct. 31, 2020	Jan. 31, 2020
CONDENSED CONSOLIDATED BALANCE SHEETS
Preferred stock, par value	$ 0.10	$ 0.10
Preferred stock, shares authorized	500,000	500,000
Preferred stock, shares issued	0	0
Preferred stock, shares outstanding	0	0
Common stock, par value	$ 0.15	$ 0.15
Common stock, shares authorized	30,000,000	30,000,000
Common stock, shares issued	15,693,202	15,638,202
Common stock, shares outstanding	15,689,969	15,634,969

XML

CONDENSED CONSOLIDATED STATEMENTS OF STOCKHOLDERS' EQUITY - USD ($) $ in Thousands	Common Stock	Additional Paid-in Capital	Retained Earnings	Accumulated Other Comprehensive Loss	Non-controlling Interests	Total
Balances at Jan. 31, 2019	$ 2,337	$ 144,961	$ 247,616	$ (346)	$ (196)	$ 394,372
Balances (in shares) at Jan. 31, 2019	15,573,869
Net income (loss)			(35,501)		2,007	(33,494)
Foreign currency translation loss				(825)		(825)
Stock compensation expense		1,512				1,512
Stock option exercises	$ 9	1,558				$ 1,567
Stock option exercises (in shares)	59,433					59,000
Cash dividends			(11,714)			$ (11,714)
Balances at Oct. 31, 2019	$ 2,346	148,031	200,401	(1,171)	1,811	351,418
Balances (in shares) at Oct. 31, 2019	15,633,302
Balances at Jul. 31, 2019	$ 2,346	147,445	211,167	(1,406)	(483)	359,069
Balances (in shares) at Jul. 31, 2019	15,633,302
Net income (loss)			(6,855)		2,294	(4,561)
Foreign currency translation loss				235		235
Stock compensation expense		586				586
Cash dividends			(3,911)			(3,911)
Balances at Oct. 31, 2019	$ 2,346	148,031	200,401	(1,171)	1,811	351,418
Balances (in shares) at Oct. 31, 2019	15,633,302
Balances at Jan. 31, 2020	$ 2,346	148,713	189,306	(1,116)	1,781	341,030
Balances (in shares) at Jan. 31, 2020	15,634,969
Net income (loss)			14,300		(40)	14,260
Foreign currency translation loss				(650)		(650)
Stock compensation expense		2,199				2,199
Stock option exercises	$ 8	1,237				$ 1,245
Stock option exercises (in shares)	55,000					55,000
Cash dividends			(27,420)			$ (27,420)
Balances at Oct. 31, 2020	$ 2,354	152,149	176,186	(1,766)	1,741	330,664
Balances (in shares) at Oct. 31, 2020	15,689,969
Balances at Jul. 31, 2020	$ 2,351	150,847	170,653	(1,445)	1,741	324,147
Balances (in shares) at Jul. 31, 2020	15,669,969
Net income (loss)			9,454			9,454
Foreign currency translation loss				(321)		(321)
Stock compensation expense		786				786
Stock option exercises	$ 3	516				519
Stock option exercises (in shares)	20,000
Cash dividends			(3,921)			(3,921)
Balances at Oct. 31, 2020	$ 2,354	$ 152,149	$ 176,186	$ (1,766)	$ 1,741	$ 330,664
Balances (in shares) at Oct. 31, 2020	15,689,969

XML

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS - USD ($) $ in Thousands	3 Months Ended		9 Months Ended
	Oct. 31, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019
CASH FLOWS FROM OPERATING ACTIVITIES
Net income (loss)	$ 9,454	$ (4,561)	$ 14,260	$ (33,494)
Adjustments to reconcile net income (loss) to net cash provided by operating activities
Deferred income tax expense (benefit)			8,366	(4,521)
Depreciation	940	899	2,798	2,610
Stock compensation expense	800	600	2,199	1,512
Lease expense	500	100	1,318	637
Amortization of purchased intangible assets	226	272	677	864
Changes in accrued interest on short-term investments			482	1,106
Impairment loss				2,072
Other			111	60
Changes in operating assets and liabilities
Accounts receivable			6,585	1,274
Contract assets			6,156	7,992
Other assets			(15,976)	(1,760)
Accounts payable and accrued expenses			27,725	(12,523)
Contract liabilities			87,859	50,072
Net cash provided by operating activities			142,560	15,901
CASH FLOWS FROM INVESTING ACTIVITIES
Maturities of short-term investments			170,000	164,000
Purchases of short-term investments			(100,000)	(75,000)
Purchases of property, plant and equipment			(1,412)	(6,308)
Net cash provided by investing activities			68,588	82,692
CASH FLOWS FROM FINANCING ACTIVITIES
Payments of cash dividends			(27,420)	(11,714)
Proceeds from the exercise of stock options			1,245	1,567
Net cash used in financing activities			(26,175)	(10,147)
EFFECTS OF EXCHANGE RATE CHANGES ON CASH			877	(282)
NET INCREASE IN CASH AND CASH EQUIVALENTS			185,850	88,164
CASH AND CASH EQUIVALENTS, BEGINNING OF PERIOD			167,363	164,318
CASH AND CASH EQUIVALENTS, END OF PERIOD	$ 353,213	$ 252,482	$ 353,213	$ 252,482

XML

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

9 Months Ended

Oct. 31, 2020

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

NOTE 1 – DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

Description of the Business

Argan, Inc. (“Argan”) conducts operations through its wholly-owned subsidiaries, Gemma Power Systems, LLC and affiliates (“GPS”); The Roberts Company, Inc. (“TRC”); Atlantic Projects Company Limited and affiliates (“APC”) and Southern Maryland Cable, Inc. (“SMC”). Argan and these consolidated subsidiaries are hereinafter collectively referred to as the “Company.”

Through GPS and APC, the Company provides a full range of engineering, procurement, construction, commissioning, operations management, maintenance, project development, technical and other consulting services to the power generation market, including the renewable energy sector. The wide range of customers includes independent power producers, public utilities, power plant equipment suppliers and global energy plant construction firms with projects located in the continental United States (the “US”), the Republic of Ireland (“Ireland”) and the United Kingdom (the “UK”). Including consolidated variable interest entities (“VIEs”), GPS and APC represent the Company’s power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southeast region of the US and that are based on its expertise in producing, delivering and installing fabricated metal components such as piping systems and pressure vessels. Through SMC, which conducts business as SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the mid-Atlantic region of the US.

Basis of Presentation and Significant Accounting Policies

The condensed consolidated financial statements include the accounts of Argan, its wholly-owned subsidiaries and its financially controlled VIEs. All significant inter-company balances and transactions have been eliminated in consolidation.

In Note 14, the Company has provided certain financial information relating to the operating results and assets of its reportable segments based on the manner in which management disaggregates the Company’s financial reporting for purposes of making internal operating decisions. The Company’s fiscal year ends on January 31 each year.

The condensed consolidated balance sheet as of October 31, 2020, the condensed consolidated statements of earnings and stockholders’ equity for the three and nine months ended October 31, 2020 and 2019, and the condensed consolidated statements of cash flows for the nine months ended October 31, 2020 and 2019 are unaudited. The condensed consolidated balance sheet as of January 31, 2020 has been derived from audited financial statements. These condensed consolidated financial statements have been prepared pursuant to the rules and regulations of the US Securities and Exchange Commission (the “SEC”). Certain information and note disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America (“US GAAP”) have been condensed or omitted pursuant to those rules and regulations, although the Company believes that the disclosures made are adequate to make the information not misleading. The accompanying condensed consolidated financial statements and notes should be read in conjunction with the consolidated financial statements, the notes thereto, and the independent registered public accounting firm’s report thereon, that are included in the Company’s Annual Report on Form 10-K for the fiscal year ended January 31, 2020 (“Fiscal 2020”).

In the opinion of management, the accompanying condensed consolidated financial statements contain all adjustments, which are of a normal and recurring nature, considered necessary to present fairly the financial position of the Company as of October 31, 2020, and its earnings and cash flows for the interim periods presented. The results of operations for any interim period are not necessarily indicative of the results of operations for any other interim period or for a full fiscal year.

Accounting Policies

In December 2019, the Financial Accounting Standards Board (the “FASB”) issued Accounting Standards Update (“ASU”) 2019-12, Simplifying the Accounting for Income Taxes, which, among other changes, eliminates the exception to the general methodology for calculating income taxes in an interim period when a year-to-date loss exceeds the expected loss for the entire year. In these instances, the estimated annual effective income tax rate shall be used to calculate the tax without limitation. The new standard also requires the recognition of a franchise (or similar) tax that is partially based on income as an income-based tax and the recording of any incremental tax that is incurred by the Company as a non-income based tax. The requirements of this new guidance, effective for the Company on February 1, 2021, are not expected to alter the Company’s current accounting for income taxes.

In 2016, the FASB issued ASU 2016-13, Measurement of Credit Losses on Financial Instruments. The requirements of this new standard cover, among other provisions, the methods that businesses shall use to estimate amounts of uncollectible notes and accounts receivable. Adoption of this new guidance, which became effective for the Company on February 1, 2020, did not affect the Company's consolidated financial statements.

There are no other recently issued accounting pronouncements that have not yet been adopted that the Company considers material to its condensed consolidated financial statements.

The carrying value amounts presented in the condensed consolidated balance sheets for the Company’s current assets, which primarily include cash and cash equivalents, short-term investments, accounts receivable and contract assets, and its current liabilities are reasonable estimates of their fair values due to the short-term nature of these items.

Variable Interest Entity

In January 2018, the Company was deemed to be the primary beneficiary of a VIE that is performing the project development activities related to the planned construction of a new natural gas-fired power plant. Consideration for the Company’s engineering and financial support includes the right to build the power plant pursuant to a turnkey engineering, procurement and construction (“EPC”) services contract that has been negotiated and announced. The account balances of the VIE are included in the condensed consolidated financial statements, including development costs incurred by the VIE during the three and nine-month periods ended October 31, 2020 and 2019. The total amounts of the project development costs included in the balances for property, plant and equipment as of October 31 and January 31, 2020 were $7.4 million and $6.9 million, respectively. Recovery of the Company's investment in this project will most likely depend on the successful completion of the project development efforts, including the arrangement of financing for the construction and operation of the corresponding power plant.

XML

REVENUES FROM CONTRACT WITH CUSTOMERS

9 Months Ended

Oct. 31, 2020

REVENUES FROM CONTRACT WITH CUSTOMERS

REVENUES FROM CONTRACT WITH CUSTOMERS

NOTE 2 – REVENUES FROM CONTRACTS WITH CUSTOMERS

The Company’s recognition of revenues under contracts with customers is based on a single comprehensive five-step model that requires reporting entities to:

1. Identify the contract,

2. Identify the performance obligations of the contract,

3. Determine the transaction price of the contract,

4. Allocate the transaction price to the performance obligations, and

5. Recognize revenue.

Major provisions of the standard cover the determination of which goods and services are distinct and represent separate performance obligations, the evaluation of whether revenues should be recognized at a point in time or over time, and the appropriate treatment for variable consideration.

The Company’s revenues are recognized primarily under various types of long-term construction contracts, including those for which revenues are based on either a fixed-price or a time-and-materials basis, and are primarily recognized over time as performance obligations are satisfied due to the continuous transfer of control to the project owner or other customer. Revenues from fixed-price contracts, including a portion of estimated gross profit, are recognized as services are provided, based on costs incurred and estimated total contract costs using the percentage-of-completion method.

If, at any time, the estimate of contract profitability indicates an anticipated loss on a contract, the Company will recognize the total loss in the reporting period that it is identified and an amount is estimable. Revenues from time-and-materials contracts are recognized when the related services are provided to the customer.

Almost all of the Company’s fixed-price contracts are considered to have a single performance obligation. Although multiple promises to transfer individual goods or services may exist, they are not typically distinct within the context of such contracts because contract promises included therein are interrelated or the contracts require the Company to perform critical integration so that the customer receives a completed project. The Company’s accounting for its assurance-type warranties provided under contracts with customers is conducted in accordance with the specific professional guidance established to cover such arrangements.

The transaction price for a contract represents the accounting value of the contract awarded to the Company that is used to determine the amount of revenues recognized as of the balance sheet date. It may reflect amounts of variable consideration, which could be either increases or decreases to the transaction price. These adjustments can be made from time-to-time during the period of contract performance as circumstances evolve related to such items as changes in the scope and price of contracts, claims, incentives and liquidated damages.

Contract assets generally include amounts that represent the rights to receive payment for goods or services that have been transferred to the project owner, with the rights conditional upon something other than the passage of time. Contract liabilities generally include the amounts that reflect obligations to provide goods or services for which payment has been received. The balances of accounts receivable exclude billed amounts which, pursuant to the terms of the applicable contract, are not paid by project owners until a defined phase of a contract or project has been completed and accepted. These retained amounts are reflected in contract assets or contract liabilities depending on the net contract position of the particular contract. Retention amounts and the length of retention periods may vary. Retention amounts related to active contracts are considered current regardless of the term of the applicable contract; such amounts are generally collected by the completion of the applicable contract. The total of amounts retained by project owners under construction contracts at October 31 and January 31, 2020 were $32.5 million and $20.0 million, respectively.

Variable Consideration

Amounts for contract variations for which the Company has project-owner directive for additional work or other scope change, but not for the price associated with the corresponding additional effort, are included in the transaction price when it is considered probable that the applicable costs will be recovered through a modification to the contract price. The effects of any revision to a transaction price can be determined at any time and they could be material. The Company may include in the corresponding transaction price a portion of the amount claimed in a dispute that it expects to receive from a project owner. Once a settlement of the dispute has been reached with the project owner, the transaction price may be revised again to reflect the final resolution. The aggregate amount of such contract variations included in the transaction prices that were used to determine project-to-date revenues at October 31, 2020 and January 31, 2020 were $8.0 million and $21.2 million, respectively. Variations related to the Company’s contracts typically represent modifications to the existing contracts and performance obligations, and do not represent new performance obligations. Actual costs related to any changes in the scope of the corresponding contract are expensed as they are incurred. Changes to total estimated contract costs and losses, if any, are reflected in operating results for the period in which they are determined.

The Company’s long-term contracts typically have schedule dates and other performance objectives that if not achieved could subject the Company to liquidated damages. At the outset of each of the Company’s contracts, the potential amounts of liquidated damages typically are not constrained, or subtracted, from the transaction price as the Company believes that it has included activities in its contract plan, and the associated costs, that will be effective in preventing such damages. Of course, circumstances may change as the Company executes the corresponding contract.

The transaction price is reduced by an applicable amount when the Company no longer considers it probable that a future reversal of revenues will not occur when the matter is resolved. The Company considers potential liquidated damages, the costs of other related items and potential mitigating factors in determining the adequacy of its regularly updated estimates of the amounts of gross profit expected to be earned on active projects.

The Company records adjustments to revenues and profits on contracts, including those associated with contract variations and estimated cost changes, using a cumulative catch-up method. Under this method, the impact of an adjustment to the amount of revenues recognized to date is recorded in the period that the adjustment is identified. Estimated variable consideration amounts are determined by the Company based primarily on the single most likely amount in the range of possible consideration amounts. Revenues and profits in future periods of contract performance are recognized using the adjusted amounts of transaction price and estimated contract costs.

Accounting for the Loss Subcontract

In its Form 10-K Annual Report for the year ended January 31, 2019 (“Fiscal 2019”), the Company disclosed that APC was completing the mechanical installation of the boiler for a biomass-fired power plant under construction in Teesside, England (the “TeesREP Project”) that had encountered significant operational and contractual challenges. The consolidated operating results for the year ended January 31, 2019 reflected unfavorable gross profit adjustments related to this project. The disclosure explained that the construction project was behind the schedule originally established for the job and warned that the TeesREP Project may continue to impact the Company’s consolidated operating results negatively until it reaches completion.

Subsequent to the release of the Company’s consolidated financial statements for Fiscal 2019, APC’s estimates of the costs of the unfavorable financial impacts of the difficulties on the TeesREP Project escalated substantially. For the nine-month period ended October 31, 2019, the Company recorded a loss related to this project in the amount of $31.2 million, including $0.3 million recorded in the three months ended October 31, 2019, and reversed profit in the amount of $0.7 million that had been recorded in prior fiscal years.

Construction activities on the TeesREP Project were suspended on March 24, 2020 due to the COVID-19 pandemic. At that time, APC had completed approximately 90% of its subcontracted work. As a condition for resuming its efforts on the TeesREP Project, APC entered into an amendment to the subcontract with its customer, effective June 1, 2020, covering the various terms and conditions for completion of the installation of the boiler (“Amendment No. 2”). The agreement represented a global settlement of past commercial differences with both parties making significant concessions, and converted the billing arrangements for the remaining work to a time-and-materials basis.

Amendment No. 2 was treated as a modification of the original subcontract as the arrangement continued to represent a single performance obligation to its customer, the delivery of a complete functioning and integrated boiler that was only partially satisfied when the modification to the subcontract occurred. During October 2020, APC and its customer agreed to additional contractual changes that effectively recognized APC’s completion of the single performance obligation and that establishes a time-and-materials contractual arrangement covering all works requested by APC’s customer until completion of the power plant construction.

The effects of these changes on the financial results reported for the subcontract were the primary reasons for the reductions to the subcontract loss that were recorded during the three and nine months ended October 31, 2020, in the approximate favorable amounts of $2.8 million and $4.1 million, respectively. Accordingly, the final amount of the TeesREP fixed price subcontract loss was $29.5 million, and the remaining subcontract loss reserve balance was eliminated as of October 31, 2020. At January 31, 2020, the subcontract loss reserve balance was $5.8 million. This balance was included in accrued expenses in the accompanying condensed consolidated balance sheet. Final closeout adjustments may result in future changes in the amount of the subcontract loss recognized as of October 31, 2020; however, APC has included an estimate of these costs in accrued expenses in the accompanying condensed consolidated balance sheet as of October 31, 2020. The total amounts of accounts receivable and contract assets related to the TeesREP Project and included in the condensed consolidated balance sheets were $7.3 million as of October 31, 2020 and $19.2 million as of January 31, 2020.

Remaining Unsatisfied Performance Obligations (“RUPO”)

The amount of RUPO represents the unrecognized revenue value of active contracts with customers as determined under the revenue recognition rules of US GAAP. Increases to RUPO during a reporting period represent the transaction prices associated with new contracts, as well as additions to the transaction prices of existing contracts. The amounts of such changes may vary significantly each reporting period based on the timing of major new contract awards and the occurrence and assessment of contract variations.

At October 31, 2020, the Company had RUPO of $604.7 million. The largest portion of RUPO at any date usually relates to EPC service contracts with typical performance durations of 2 to 3 years. However, the length of certain significant construction projects may exceed three years. The Company estimates that approximately 63% of the RUPO amount at October 31, 2020 will be included in the amount of consolidated revenues that will be recognized over the next twelve months. Most of the remaining amount of the RUPO amount at October 31, 2020 is expected to be recognized in revenues over the following eighteen months.

Revenues for future periods will also include amounts related to customer contracts started or awarded subsequent to October 31, 2020. It is important to note that estimates may be changed in the future and that cancellations, deferrals, scope adjustments may occur related to work included in the amount of RUPO at October 31, 2020. Accordingly, RUPO may be adjusted to reflect project delays and cancellations, revisions to project scope and cost and foreign currency exchange fluctuations, or to revise estimates, as effects become known. Such adjustments may materially reduce future revenues below Company estimates.

Disaggregation of Revenues

The following table presents consolidated revenues for the three and nine months ended October 31, 2020 and 2019, disaggregated by the geographic area where the corresponding projects were located:

	Three Months Ended				Nine Months Ended
	October 31,				October 31,
	2020		2019		2020		2019
United States	$	109,241	$	39,629	$	241,616	$	117,045
United Kingdom		9,759		10,349		22,595		35,631
Republic of Ireland		8,331		8,256		10,760		18,007
Other		—		172		—		326
Consolidated Revenues	$	127,331	$	58,406	$	274,971	$	171,009

Each year, the majority of consolidated revenues are recognized pursuant to fixed-price contracts with most of the remaining portions earned pursuant to time-and-material contracts. Consolidated revenues are disaggregated by reportable segment in Note 14 to the condensed consolidated financial statements.

XML

CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

9 Months Ended

Oct. 31, 2020

CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

NOTE 3 – CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS

At October 31 and January 31, 2020, significant amounts of cash and cash equivalents were invested in mutual funds with net assets invested in high-quality money market instruments. Such investments include US Treasury obligations; obligations of US government agencies, authorities, instrumentalities or sponsored enterprises; and repurchase agreements secured by US government obligations. Due to market conditions, returns on money market instruments are currently minimal. The Company considers all liquid investments with original maturities of three months or less at the time of purchase to be cash equivalents.

Short-term investments as of October 31 and January 31, 2020 consisted solely of certificates of deposit purchased from Bank of America (the “Bank”) with weighted average initial maturities of 292 days and 165 days, respectively (the “CDs”). The Company has the intent and ability to hold the CDs until they mature, and they are carried at cost plus accrued interest which approximates fair value. The total carrying value amounts as of October 31 and January 31, 2020 included accrued interest, which was $0.5 million at January 31, 2020. The amount of accrued interest at October 31, 2020 was insignificant. Interest income is recorded when earned and is included in other income. At October 31 and January 31, 2020, the weighted average annual interest rates of the outstanding CDs were 0.2% and 1.8%, respectively.

In addition, the Company has a substantial portion of its cash on deposit in the US at the Bank in excess of federally insured limits. Management does not believe that the combined amount of the CD investments and the cash deposited with the Bank represents a material risk. The Company also maintain certain Euro-based bank accounts in Ireland and certain pound sterling-based bank accounts in the UK in support of the operations of APC.

XML

ACCOUNTS AND NOTES RECEIVABLE

9 Months Ended

Oct. 31, 2020

ACCOUNTS AND NOTES RECEIVABLE

ACCOUNTS AND NOTES RECEIVABLE

NOTE 4 – ACCOUNTS AND NOTES RECEIVABLE

The Company generally extends credit to a customer based on an evaluation of the customer’s financial condition without requiring tangible collateral. Exposure to losses on accounts and notes receivable is expected to differ due to the varying financial condition of each customer. The Company monitors its exposure to credit losses and may establish an allowance for a credit loss based on management’s estimate of the loss that is expected to occur over the remaining life of the particular financial asset. At October 31 and January 31, 2020, the amounts of credit losses expected by management were insignificant. The amounts of the provision for credit losses for the three and nine months ended October 31, 2020 and the provision for uncollectible accounts for the three and nine months ended October 31, 2019 were also insignificant.

As of October 31, 2020, there were outstanding invoices billed to one former customer and unbilled costs incurred on the related project, with balances included in accounts receivable and contract assets, in the aggregate amount of $24.5 million, for which the recovery time will most likely depend on the resolution of the outstanding legal dispute between the parties (see Note 8).

As of October 31, 2020, there were past due notes receivable from project developers in the aggregate amount of $1.7 million, for which full receipt will most likely depend on the successful financing of the related projects.

XML

PURCHASED INTANGIBLE ASSETS

9 Months Ended

Oct. 31, 2020

PURCHASED INTANGIBLE ASSETS

PURCHASED INTANGIBLE ASSETS

NOTE 5 – PURCHASED INTANGIBLE ASSETS

At both October 31, 2020 and January 31, 2020, the goodwill balances related to the acquisitions of GPS and TRC were $18.5 million and $9.5 million, respectively. Primarily due to the significant reduction of the fair value of the business of APC deemed to have occurred as a result of the substantial contract loss discussed in Note 2 above, the Company recorded an impairment loss in the first quarter ended April 30, 2019 in the amount of $2.1 million, which was the remaining balance of goodwill associated with APC. No other changes were made to the balances of goodwill during the nine-month periods ended October 31, 2020 or 2019. Management does not believe that any events or circumstances that have occurred or arisen since January 31, 2020 require an updated assessment of the goodwill balances of either GPS or TRC.

The Company’s purchased intangible assets, other than goodwill, consisted of the following elements as of October 31 and January 31, 2020:

		October 31, 2020						January 31,
	Estimated	Gross		Accumulated		Net		2020, (net
	Useful Life	Amounts		Amortization		Amount		amounts)
Trade names	15 years	$	8,142	$	4,849	$	3,293	$	3,699
Process certifications	7 years		1,897		1,332		565		768
Customer relationships	4-10 years		1,346		880		466		534
Totals		$	11,385	$	7,061	$	4,324	$	5,001

XML

FINANCING ARRANGEMENTS

9 Months Ended

Oct. 31, 2020

FINANCING ARRANGEMENTS

FINANCING ARRANGEMENTS

NOTE 6 – FINANCING ARRANGEMENTS

The Company maintains financing arrangements with the Bank that are described in an Amended and Restated Replacement Credit Agreement (the “Credit Agreement”), dated May 15, 2017. The Credit Agreement provides a revolving loan with a maximum borrowing amount of $50.0 million that is available until May 31, 2021 with interest at the 30-day London Interbank Offered Rate (“LIBOR”) plus 2.0%. The Company may also use the borrowing ability to cover other credit instruments issued by the Bank for the Company’s use in the ordinary course of business. As of October 31 and January 31, 2020, the Company had letters of credit outstanding under the Credit Agreement, but no borrowings, in the approximate amounts of $1.7 million and $9.9 million, respectively. The Company expects that it will negotiate either an extension or a replacement agreement prior to the current expiration date of the Credit Agreement.

The Company has pledged the majority of its assets to secure its financing arrangements. The Bank’s consent is not required for acquisitions, divestitures, cash dividends or significant investments as long as certain conditions are met. The Bank requires that the Company comply with certain financial covenants at its fiscal year-end and at each of its fiscal quarter-ends. The Credit Agreement also includes other terms, covenants and events of default that are customary for a credit facility of its size and nature. As of October 31 and January 31, 2020, the Company was in compliance with the financial covenants.

In support of the current project development activities of the VIE described in Note 1, the Bank issued a letter of credit, outside the scope of the Credit Agreement, in the amount of $3.4 million for which the Company has provided cash collateral.

XML

COMMITMENTS

9 Months Ended

Oct. 31, 2020

COMMITMENTS

COMMITMENTS

NOTE 7 – COMMITMENTS

Leases

The Company determines if a contract is or contains a lease at inception or upon modification of the contract. A contract is or contains a lease if it conveys the right to control the use of an identified asset for a period in exchange for consideration. Control over the use of the identified asset means the lessee has both (a) the right to obtain substantially all of the economic benefits from the use of the asset and (b) the right to direct the use of the asset. The Company does not apply this accounting to those leases with terms of twelve (12) months or less and that do not include options to purchase the underlying assets that the Company is reasonably certain to exercise.

The Company’s operating leases primarily cover office space that expire on various dates through May 2024 and certain equipment used by the Company in the performance of its construction services contracts. Other construction equipment is rented, with periods of expected usage less than one year, or owned. Certain leases contain renewal options, which are included in expected lease terms if they are reasonably certain of being exercised by the Company. Other equipment leases are embedded in broader arrangements with subcontractors or construction equipment suppliers. The Company has no finance leases.

None of the operating leases include significant amounts for incentives, rent holidays or price escalations. Under certain lease agreements, the Company is obligated to pay property taxes, insurance, and maintenance costs.

Operating lease right-of-use assets and associated lease liabilities are recognized in the balance sheet at the lease commencement date based on the present value of future minimum lease payments to be made over the expected lease term. As the implicit rate is not determinable in most of the Company’s leases, management uses the Company’s incremental borrowing rate (LIBOR plus 2.0%) at the commencement date in determining the present value of future payments. The expected lease term includes an option to extend or to terminate the lease when it is reasonably certain that the Company will exercise such option.

Lease expense for minimum lease payments is recognized on a straight-line basis over the expected lease term. Operating lease expense amounts for the three months ended October 31, 2020 and 2019 were $0.5 million and $0.1 million, respectively. Operating lease expense amounts for the nine months ended October 31, 2020 and 2019 were $1.3 million and $0.6 million, respectively. Operating lease payments for the three months ended October 31, 2020 and 2019 were $0.3 million and $0.2 million, respectively. Operating lease payments for the nine months ended October 31, 2020 and 2019 were $1.2 million and $0.6 million, respectively. For operating leases as of October 31, 2020, the weighted average lease term is 32 months and the weighted average discount rate is 3.3%.

The Company also uses equipment and occupies facilities under short-term rental agreements. Rent expense amounts incurred under operating leases and short-term rental agreements (including portions of the lease expense amounts disclosed above) and included in costs of revenues for the three and nine months ended October 31, 2020 were $2.3 million and $4.2 million, respectively. Rent expense incurred under these types of arrangements and included in costs of revenues for the three and nine months ended October 31, 2019 was $0.9 million and $3.2 million, respectively. Rent expense included in selling, general and administrative expenses for the three and nine months ended October 31, 2020 was $0.2 million and $0.7 million, respectively. Rent expense included in selling, general and administrative expenses for the three and nine months ended October 31, 2019 was $0.1 million and $0.5 million, respectively.

The following is a schedule of future minimum lease payments for the operating leases that were recognized in the condensed consolidated balance sheet as of October 31, 2020, including operating leases added during the three and nine months ended October 31, 2020 in the amounts of approximately $0.5 million and $2.3 million, respectively, covering primarily certain construction-site assets required by GPS:

Years Ending January 31,
Remainder of 2021	$	505
2022		1,648
2023		856
2024		242
2025		85
Thereafter		20
Total lease payments		3,356
Less interest portion		90
Present value of lease payments		3,266
Less current portion (included in accrued expenses)		2,760
Non-current portion	$	506

The future minimum lease payments presented above include amounts due under a long-term lease covering the primary offices and plant for TRC with the founder and current chief executive officer of TRC at an annual rate of $0.3 million through April 30, 2021.

Performance Bonds and Guarantees

In the normal course of business and for certain major projects, the Company may be required to obtain surety or performance bonding, to cause the issuance of letters of credit, or to provide parent company guarantees (or some combination thereof) in order to provide performance assurances to clients on behalf of its contractor subsidiaries. As these subsidiaries are wholly-owned, any actual liability is ordinarily reflected in the financial statement account balances determined pursuant to the Company’s accounting for contracts with customers. When sufficient information about claims on guaranteed or bonded projects would be available and monetary damages or other costs or losses would be determined to be probable, the Company would record such losses. Any amounts that may be required to be paid in excess of the estimated costs to complete contracts in progress as of October 31, 2020 are not estimable.

On behalf of APC, Argan has provided a parent company performance guarantee to its customer, the EPC services contractor on the TeesREP Project. Earlier this year, and in connection with the negotiation of Amendment No. 2, the Company replaced an outstanding letter of credit in the amount of $7.6 million with a surety bond.

As of October 31, 2020, the Company has also provided a financial guarantee, subject to certain terms and conditions, on behalf of GPS to an original equipment manufacturer in the amount of $3.6 million in support of business development efforts. The fair value of this guarantee at October 31, 2020 is considered to be immaterial.

Warranties

The Company generally provides assurance-type warranties for work performed under its construction contracts. The warranties cover defects in equipment, materials, design or workmanship, and most warranty periods typically run from nine to twenty-four months after the completion of construction on a particular project. Because of the nature of the Company’s projects, including project owner inspections of the work both during construction and prior to substantial completion, the Company has not experienced material unexpected warranty costs in the past. Warranty costs are estimated based on experience with the type of work and any known risks relative to each completed project. The accruals of liabilities, which are established to cover estimated future warranty costs, are recorded as the contracted work is performed, and they are included in the amounts of accrued expenses in the condensed consolidated balances sheets. The liability amounts may be periodically adjusted to reflect changes in the estimated size and number of expected warranty claims.

XML

LEGAL CONTINGENCIES

9 Months Ended

Oct. 31, 2020

LEGAL CONTINGENCIES

LEGAL CONTINGENCIES

NOTE 8 – LEGAL CONTINGENCIES

In the normal course of business, the Company may have pending claims and legal proceedings. In the opinion of management, based on information available at this time, there are no current claims and proceedings that could have a material adverse effect on the condensed consolidated financial statements except for the matter described below.

In January 2019, GPS filed a lawsuit against Exelon West Medway II, LLC and Exelon Generation Company, LLC (together referred to as “Exelon”) for Exelon’s breach of contract and failure to remedy various conditions which negatively impacted the schedule and the costs associated with the construction by GPS of a gas-fired power plant for Exelon in Massachusetts. As a result, the Company believes that Exelon has received the benefits of the construction efforts of GPS and the corresponding progress made on the project without making payments to GPS for the value received (see Note 4). In March 2019, Exelon provided GPS with a notice intending to terminate the EPC contract under which GPS had been providing services to Exelon. At that time, the construction project was nearly complete and both of the power generation units included in the plant had successfully reached first fire. The completion of various prescribed performance tests and the clearance of punch-list items were the primary tasks necessary to be accomplished by GPS in order to achieve substantial completion of the power plant. Nevertheless, and among other actions, Exelon provided contractual notice requiring GPS to vacate the construction site. Exelon has asserted that GPS failed to fulfill certain obligations under the contract and was in default, withholding payments from GPS on invoices rendered to Exelon in accordance with the terms of the contract between the parties.

With vigor, GPS intends to continue to assert its rights under the EPC contract with Exelon, to pursue the collection of amounts owed under the EPC contract and to defend itself against the allegations that GPS did not perform in accordance with the contract. During the nine months ended October 31, 2020, most of the litigation activities of the legal teams has focused on the completion of discovery. The difficulties experienced by the legal teams in completing certain discovery activities, due in part to COVID-19 restrictions, resulted in the court granting extensions of the discovery period which is now closed for both parties. The next phase of the case is pre-trial. The Company expects that a mediation will be scheduled for Spring 2021. If the mediation is not successful in resolving the disputes, then the Company expects that trial will occur during the mid-to-late Summer 2021.

XML

STOCK-BASED COMPENSATION

9 Months Ended

Oct. 31, 2020

STOCK-BASED COMPENSATION

STOCK-BASED COMPENSATION

NOTE 9 – STOCK-BASED COMPENSATION

The Company’s board of directors may make awards under the 2011 Stock Plan (the “2011 Plan”) or the 2020 Stock Plan (the “2020 Plan”) to officers, directors and key employees (together, the “Stock Plans”). On June 23, 2020, the Company’s stockholders approved the adoption of the 2020 Plan, and the allocation of 500,000 shares of the Company’s common stock for issuance thereunder, which had been established by the Company’s board of directors earlier in the current year. The 2020 Plan will serve to replace the 2011 Plan; the Company’s authority to make awards pursuant to the 2011 Plan will expire on July 19, 2021.

The features of the 2020 Plan are similar to those included in the 2011 Plan. Awards may include nonqualified stock options, incentive stock options,  and restricted or unrestricted stock. The specific provisions for each award made pursuant to the terms of the Stock Plans are documented in a written agreement between the Company and the awardee. All stock options awarded under the Stock Plans shall have an exercise price per share at least equal to the common stock’s market value on the date of grant. Stock options shall have terms no longer than ten years. Typically, stock options are awarded with one-third of each stock option vesting on each of the first three anniversaries of the corresponding award date. As of October 31, 2020, there were approximately 2,170,400 shares of the Company’s common stock reserved for issuance under the Stock Plans; this number includes 688,999 shares of common stock available for future awards.

Summaries of stock option activity under the Company’s approved stock option plans for the nine months ended October 31, 2020 and 2019, along with corresponding weighted average per share amounts, are presented below (shares in thousands):

		Exercise		Remaining
	Shares	Price		Term (years)	Fair Value
Outstanding, February 1, 2020	1,271	$	44.83	7.18	$	11.06
Granted	172	$	33.81
Exercised	(55)	$	22.69
Forfeited	(24)	$	55.61
Outstanding, October 31, 2020	1,364	$	44.14	6.96	$	10.52
Exercisable, October 31, 2020	865	$	46.40	5.97	$	11.76
		Exercise		Remaining
	Shares	Price		Term (years)	Fair Value
Outstanding, February 1, 2019	1,140	$	44.01	7.54	$	11.22
Granted	168	$	46.67
Exercised	(59)	$	26.36
Forfeited	(38)	$	46.34
Outstanding, October 31, 2019	1,211	$	45.18	7.28	$	11.27
Exercisable, October 31, 2019	753	$	45.81	6.25	$	10.22

The changes in the number of non-vested options to purchase shares of common stock for the nine months ended October 31, 2020 and 2019, and the weighted average fair value per share for each number, are presented below (shares in thousands):

	Shares	Fair Value
Non-vested, February 1, 2020	448	$	9.74
Granted	172	$	5.68
Vested	(112)	$	9.81
Forfeitures	(9)	$	8.08
Non-vested, October 31, 2020	499	$	8.35
	Shares	Fair Value
Non-vested, February 1, 2019	375	$	10.05
Granted	168	$	10.32
Vested	(57)	$	9.28
Forfeitures	(28)	$	10.47
Non-vested, October 31, 2019	458	$	10.22

Pursuant to the terms of the 2011 Plan and as described in the corresponding agreements with the executives, the Company awarded performance-based restricted stock units to two senior executives in April 2020, 2019 and 2018 covering  45,000, 36,000 and 36,000 maximum total numbers of shares of common stock, respectively, plus a number of shares to be determined based on the amount of cash dividends deemed paid on shares earned pursuant to the awards. The release of the stock restrictions depends on the total return performance of the Company’s common stock measured against the performance of a peer-group of common stocks over three-year periods. The fair value amounts for restricted stock units were determined by using the per share market price of the Company’s common stock on the dates of award and the target number of shares for the awards (50% of the maximum number), by assigning equal probabilities to the thirteen possible payout outcomes at the ends of the three-year vesting periods, and by computing the weighted average of the outcome amounts. For each case, the estimated fair value amount was calculated to be 88.5% of the aggregate market value of the target number of shares on the award date.

The fair values of stock options and restricted stock units are recorded as stock compensation expense over the vesting periods of the corresponding awards. Expense amounts related to stock awards were $0.8 million and $0.6 million for the three months ended October 31, 2020 and 2019, respectively. Expense amounts related to stock awards were $2.2 million

and $1.5 million for the nine months ended October 31, 2020 and 2019, respectively. At October 31, 2020, there was $3.8 million in unrecognized compensation cost related to outstanding stock awards that the Company expects to expense over the next three years.

The total intrinsic value amounts of the stock options exercised during the nine months ended October 31, 2020 and 2019 were $1.2 million and $1.4 million, respectively. At October 31, 2020, the aggregate market value amounts of the shares of common stock subject to outstanding and exercisable stock options that were “in-the-money” exceeded the aggregate exercise prices of such options by $4.7 million and $3.3 million, respectively.

The Company estimates the weighted average fair value of stock options on the date of award using a Black-Scholes option pricing model, which was developed for use in estimating the fair value of traded options that have no vesting restrictions and are fully transferable. The Company believes that its past stock option exercise activity is sufficient to provide it with a reasonable basis upon which to estimate the expected life of newly awarded stock options. Risk-free interest rates are determined by blending the rates for three to five year US Treasury notes. The dividend yield is based on the Company’s current annual regular dividend amount. The calculations of the expected volatility factors are based on the monthly closing prices of the Company’s common stock for the five-year periods preceding the dates of the corresponding awards.

The fair value amounts of stock options granted during the nine months ended October 31, 2020 and 2019 were estimated on the corresponding dates of the awards using the Black-Scholes option-pricing model reflecting the following weighted average assumptions:

	Nine Months Ended October 31,
	2020		2019
Dividend yield	3.0	%	2.2	%
Expected volatility	30.0	%	33.1	%
Risk-free interest rate	0.5	%	2.0	%
Expected life (in years)	3.4		3.3

XML

INCOME TAXES

9 Months Ended

Oct. 31, 2020

INCOME TAXES

INCOME TAXES

NOTE 10 – INCOME TAXES

Income Tax Expense Reconciliation

The Company’s income tax amounts for the nine months ended October 31, 2020 and 2019 differed from corresponding amounts computed by applying the federal corporate income tax rate of 21% to the income (loss) before income taxes for the periods as presented in the table below.

	Nine Months Ended October 31,
	2020		2019
Computed expected income tax (expense) benefit	$	(2,702)	$	8,070
Difference resulting from:
Net operating loss carryback		4,390		—
Foreign tax rate differential		(77)		(766)
Stock options		66		(170)
State income taxes, net of federal tax effect		(40)		185
Net operating losses deemed unrealizable		—		(6,280)
Bad debt loss		—		5,026
Adjustments and other differences		(246)		(1,129)
Income tax benefit	$	1,391	$	4,936

Foreign income tax expense amounts for the nine months ended October 31, 2020 and 2019 were not material. A valuation allowance in the amount of $6.3 million was established against the deferred tax asset amount created by the net operating loss of APC’s subsidiary in the UK for the nine months ended October 31, 2019. As  the subsidiary is expected to report income for the current year, approximately $0.1 of tax benefit was recorded during the nine-month period ended October 31, 2020.

Net Operating Loss Carryback

In an effort to combat the adverse economic impacts of the COVID-19 crisis, the US Congress passed the Coronavirus, Aid, Relief, and Economic Security Act ( the “CARES Act”) that was signed into law on March 27, 2020. This wide-ranging legislation was an emergency economic stimulus package that includes spending and tax breaks aimed at strengthening the US economy and funding a nationwide effort to curtail the effects of the outbreak of COVID-19. The CARES Act has provided many opportunities for taxpayers to evaluate their 2018 and 2019 income tax returns to identify potential tax refunds. One such area is the utilization of net operating losses (“NOLs”). The tax changes of the CARES Act remove the limitations on the future utilization of certain NOLs and re-establish a carryback period for certain losses to five years. The NOLs eligible for carryback under the CARES Act include the Company’s domestic NOL for the year ended January 31, 2020, which was approximately $39.5 million. Substantially all of this loss now may be carried back for application against the Company’s taxable income for the year ended January 31, 2015.

As the carryback of the NOL was not available until the current fiscal year, the tax benefit associated with the NOL for Fiscal 2020 was recorded in deferred tax assets as of January 31, 2020 in the amount of $8.3 million. With the enactment of the CARES Act, the asset was moved to income taxes receivable (included in other current assets in the condensed consolidated financial statements as of October 31, 2020) with a value of approximately $12.7 million. The carryback provides a favorable rate benefit for the Company as the loss, which  was incurred in a year where the statutory federal tax rate was 21%, will be carried back to a tax year where the tax rate was higher. The substantial portion of the net amount of this tax benefit, which is approximately $4.4 million, was recorded in the three-month period ended April 30, 2020 and is, therefore, reflected as income tax benefit in the results for the nine-month period ended October 31, 2020.

Research and Development Tax Credits

During Fiscal 2019, the Company completed a detailed review of the activities of its engineering staff on major EPC services projects in order to identify and quantify the amounts of research and development credits that may be available to reduce prior year income taxes. This study focused on project costs incurred during the three-year period ended January 31, 2018. Based on the results of the study, management identified and estimated significant amounts of income tax benefits that were not previously recognized in the Company’s operating results for any prior year reporting period. The amount of research and development tax credit benefit recognized during the fourth quarter of Fiscal 2019 was $16.2 million. As described below, the IRS is examining the research and development credits that were included in the amendments of the Company’s consolidated federal income tax returns for the years ended January 31, 2016 and 2017 that were filed in January 2019.

The amount of identified but unrecognized income tax benefits related to research and development credits as of October 31, 2020 was $5.0 million, for which the Company has established a liability for uncertain income tax return positions, most of which is included in accrued expenses. The amount of the liability was also $5.0 million as of January 31, 2020. The final outcome of these uncertain tax positions is not yet determinable. However, the Company does not expect that the amount of unrecognized tax benefits will significantly change due to any settlement and/or expiration of statutes of limitation over the next 12 months. As of October 31, 2020, the Company does not believe that it has any other material uncertain income tax positions reflected in its accounts.

As of October 31 and January 31, 2020, the balances of other current assets in the condensed consolidated balance sheets included income tax refunds and prepaid income taxes in the net amounts of approximately $27.3 million and $14.5 million, respectively. The substantial portions of the income tax refunds are expected to be collected after the completion of the federal tax return examinations described below and the filing of the refund request related to the NOL carryback described above.

Income Tax Returns

The Company is subject to federal and state income taxes in the US, and income taxes in Ireland and the UK. Tax treatments within each jurisdiction are subject to the interpretation of the related tax laws and regulations which require significant judgment to apply. The Company is no longer subject to income tax examinations by authorities for its fiscal years ended on or before January 31, 2016 except for several notable exceptions including Ireland, the UK and several states where the open periods are one year longer.

The IRS conducted an examination of the Company’s original federal consolidated income tax return for the year ended January 31, 2016. The IRS represented to the Company that no unfavorable adjustment items were noted during this examination. However, the Company has consented to an extension of the audit timeline which is enabling the IRS to also examine the amendment to the income tax return, which includes the research and development credit for the year. In addition, the IRS opened an examination of the Company’s amended consolidated income tax return for the year ended January 31, 2017. In substance, these efforts have evolved into a simultaneously conducted examinations of the research and development credits claimed in both years.

In October 2020, the Company received an initial draft communication from the IRS that documents its understanding of the facts, attempts to summarize the Company’s arguments in support of the claims and states its position which disagrees with the Company’s treatment of certain costs. After a careful review of the draft communication, the Company has concluded that its arguments are sound, that the draft information does not represent new facts relating to the issues and that it will not make any adjustments to its accounting for the research and development claims (that is discussed above) as of October 31, 2020. The Company intends to pursue its income tax position with the IRS, and it expects that the ultimate settlement of the disagreement will be resolved on a basis favorable to the Company.

Subsequent to October 31, 2020, the Company was notified by the IRS that it intended to examine the consolidated income tax return for the year ended January 31, 2018, with a most likely focus on the research and development credit claimed therein. The Company believes that any resulting disagreements regarding its income taxes for the year ended January 31, 2018 will be resolved on a basis favorable to the Company.

Supplemental Cash Flow Information

The amounts of cash paid for income taxes during the nine months ended October 31, 2020 and 2019 were $3.8 million and $3.1 million, respectively. During the nine months ended October 31, 2020 and 2019, the Company received cash refunds of previously paid income taxes from various taxing authorities in the total amounts of $0.9 million and $7.9 million, respectively.

XML

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.

9 Months Ended

Oct. 31, 2020

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.

NOTE 11 – NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.

Basic and diluted net income (loss) per share amounts are computed as follows (shares in thousands except in notes (1) below the charts):

	Three Months Ended October 31,
	2020		2019
Net income (loss) attributable to the stockholders of Argan, Inc.	$	9,454	$	(6,855)
Weighted average number of shares outstanding – basic		15,680		15,633
Effect of stock awards (1)		153		—
Weighted average number of shares outstanding – diluted		15,833		15,633
Net income (loss) per share attributable to the stockholders of Argan, Inc.
Basic	$	0.60	$	(0.44)
Diluted	$	0.60	$	(0.44)

(1) For the three months ended October 31, 2020, the weighted average number of shares determined on a dilutive basis excludes the effects of antidilutive stock options covering an aggregate of 506,501 shares of common stock. For the three months ended October 31, 2019, all common stock equivalents, which covered 1,243,000 shares of common stock, were considered to be antidilutive as the Company incurred a net loss for the period.

	Nine Months Ended October 31,
	2020		2019
Net income (loss) attributable to the stockholders of Argan, Inc.	$	14,300	$	(35,501)
Weighted average number of shares outstanding – basic		15,659		15,617
Effect of stock awards (1)		136		—
Weighted average number of shares outstanding – diluted		15,795		15,617
Net income (loss) per share attributable to the stockholders of Argan, Inc.
Basic	$	0.91	$	(2.27)
Diluted	$	0.91	$	(2.27)

(1)   For the nine months ended October 31, 2020, the weighted average number of shares determined on a dilutive basis excludes the effects of antidilutive stock options covering an aggregate of 688,000 shares of common stock. For the nine months ended October 31, 2019, all common stock equivalents, which covered 1,243,000 shares of common stock, were considered to be antidilutive as the Company incurred a net loss for the period.

XML

CASH DIVIDENDS

9 Months Ended

Oct. 31, 2019

CASH DIVIDENDS

CASH DIVIDENDS

NOTE 12 – CASH DIVIDENDS

On September 10, 2020, the Company’s board of directors declared a regular quarterly cash dividend in the amount of $0.25 per share of common stock, which was paid on October 30, 2020 to stockholders of record at the close of business on October 22, 2020. On June 23, 2020, the board of directors declared a regular quarterly cash dividend and a special cash dividend in the amounts of $0.25 and $1.00 per share of common stock, respectively, which were paid to stockholders on July 31, 2020. On April 9, 2020, the board of directors declared a regular quarterly cash dividend of $0.25 per share of common stock, which was paid to stockholders on April 30, 2020. Last year, the board of directors declared regular quarterly cash dividends, each in the amount of $0.25 per share of common stock, which were paid to stockholders on October 31, 2020, July 31, 2019 and April 30, 2019, respectively.

XML

CUSTOMER CONCENTRATIONS

9 Months Ended

Oct. 31, 2020

CUSTOMER CONCENTRATIONS

CUSTOMER CONCENTRATIONS

NOTE 13 – CUSTOMER CONCENTRATIONS

The majority of the Company’s consolidated revenues relate to performance by the power industry services segment which provided 86% and 61% of consolidated revenues for the three months ended October 31, 2020 and 2019, respectively, and 83% and 49% of consolidated revenues for the nine months ended October 31, 2020 and 2019, respectively. The industrial services segment represented 12% and 34% of consolidated revenues for the three months ended October 31, 2020 and 2019, respectively, and 15% and 47% of consolidated revenues for the nine months ended October 31, 2020 and 2019, respectively.

The Company’s most significant customer relationships for the three months ended October 31, 2020 included one power industry service customer, which accounted for 70% of consolidated revenues. The Company’s most significant customer relationships for the three months ended October 31, 2019 included two power industry service customers, which accounted for 27% and 17% of consolidated revenues, respectively, and one industrial services customer, which accounted for 10% of consolidated revenues. The Company’s most significant customer relationships for the nine months ended October 31, 2020 included one power industry service customer, which accounted for 69% of consolidated revenues. The Company’s most significant customer relationships for the nine months ended October 31, 2019 also included two power industry service customers, which accounted for 13% and 10% of consolidated revenues, respectively

The accounts receivable balances from four major customers represented 24%, 14%, 11% and 10% of the corresponding consolidated balance as of October 31, 2020. Accounts receivable balances from three major customers represented 24%, 21% and 12% of the corresponding consolidated balance as of January 31, 2020. The contract asset balances from two major customers represented 63% and 12% of the corresponding consolidated balance as of October 31, 2020. Contract asset balances from two major customers represented 51% and 31% of the corresponding consolidated balance as of January 31, 2020.

XML

SEGMENT REPORTING

9 Months Ended

Oct. 31, 2020

SEGMENT REPORTING

SEGMENT REPORTING

NOTE 14 – SEGMENT REPORTING

Segments represent components of an enterprise for which discrete financial information is available that is evaluated regularly by the Company’s chief executive officer, who is the chief operating decision maker, in determining how to allocate resources and in assessing performance. The Company’s reportable segments recognize revenues and incur expenses, are organized in separate business units with different management teams, customers, talents and services, and may include more than one operating segment. Intersegment revenues and the related cost of revenues are netted against the corresponding amounts of the segment receiving the intersegment services. For the three and nine months ended October 31, 2020, intersegment revenues totaled approximately $0.5 million and $1.4 million, respectively. For the three and nine months ended October 31, 2019, intersegment revenues totaled approximately $1.1 million and $2.5 million.

Summarized below are certain operating results and financial position data of the Company’s reportable business segments for the three and nine months ended October 31, 2020 and 2019. The “Other” column in each summary includes the Company’s corporate expenses.

Three Months Ended	Power		Industrial		Telecom
October 31, 2020	Services		Services		Services		Other		Totals
Revenues	$	109,712	$	15,730	$	1,889	$	—	$	127,331
Cost of revenues		91,263		14,218		1,507		—		106,988
Gross profit		18,449		1,512		382		—		20,343
Selling, general and administrative expenses		5,096		1,828		489		1,985		9,398
Income (loss) from operations		13,353		(316)		(107)		(1,985)		10,945
Other income, net		172		—		—		3		175
Income (loss) before income taxes	$	13,525	$	(316)	$	(107)	$	(1,982)		11,120
Income tax expense										(1,666)
Net income									$	9,454
Amortization of intangibles	$	62	$	164	$	—	$	—	$	226
Depreciation		178		654		106		2		940
Property, plant and equipment additions		164		34		81		—		279
Current assets	$	392,954		25,404		1,704		118,758	$	538,820
Current liabilities		245,808		13,762		709		751		261,030
Goodwill		18,476		9,467		—		—		27,943
Total assets		425,909		47,356		3,190		119,045		595,500

Three Months Ended	Power		Industrial		Telecom
October 31, 2019	Services		Services		Services		Other		Totals
Revenues	$	35,848	$	20,143	$	2,415	$	—	$	58,406
Cost of revenues		31,327		19,159		1,928		—		52,414
Gross profit		4,521		984		487		—		5,992
Selling, general and administrative expenses		7,672		2,018		485		1,960		12,135
(Loss) income from operations		(3,151)		(1,034)		2		(1,960)		(6,143)
Other income, net		3,447		—		—		131		3,578
Income (loss) before income taxes	$	296	$	(1,034)	$	2	$	(1,829)		(2,565)
Income tax expense										(1,996)
Net loss									$	(4,561)
Amortization of intangibles	$	61	$	166	$	45	$	—	$	272
Depreciation		176		625		97		1		899
Property, plant and equipment additions		2,659		436		170		—		3,265
Current assets	$	292,618	$	28,373	$	2,861	$	82,048	$	405,900
Current liabilities		108,474		8,744		796		943		118,957
Goodwill		18,476		12,290		—		—		30,766
Total assets		324,535		55,814		4,370		87,998		472,717

Nine Months Ended	Power		Industrial		Telecom
October 31, 2020	Services		Services		Services		Other		Totals
Revenues	$	227,363	$	42,163	$	5,445	$	—	$	274,971
Cost of revenues		192,583		38,096		4,310		—		234,989
Gross profit		34,780		4,067		1,135		—		39,982
Selling, general and administrative expenses		15,892		5,664		1,447		5,824		28,827
Income (loss) from operations		18,888		(1,597)		(312)		(5,824)		11,155
Other income, net		1,634		—		—		80		1,714
Income (loss) before income taxes	$	20,522	$	(1,597)	$	(312)	$	(5,744)		12,869
Income tax benefit										1,391
Net income									$	14,260
Amortization of intangibles	$	182		495		—		—	$	677
Depreciation		522	$	1,967	$	305	$	4		2,798
Property, plant and equipment additions		857		338		217		—		1,412

Nine Months Ended	Power		Industrial		Telecom
October 31, 2019	Services		Services		Services		Other		Totals
Revenues	$	83,941	$	80,442	$	6,626	$	—	$	171,009
Cost of revenues		104,759		72,958		5,361		—		183,078
Gross (loss) profit		(20,818)		7,484		1,265		—		(12,069)
Selling, general and administrative expenses		18,977		5,959		1,535		5,290		31,761
Impairment loss		2,072		—		—		—		2,072
(Loss) income from operations		(41,867)		1,525		(270)		(5,290)		(45,902)
Other income, net		7,037		—		—		435		7,472
(Loss) income before income taxes	$	(34,830)	$	1,525	$	(270)	$	(4,855)		(38,430)
Income tax benefit										4,936
Net loss									$	(33,494)
Amortization of intangibles	$	231	$	497	$	136	$	—	$	864
Depreciation		517		1,791		298		4		2,610
Property, plant and equipment additions		4,533		1,487		277		11		6,308

XML

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION (Policies)

9 Months Ended

Oct. 31, 2020

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION

Description of the Business

Description of the Business

Argan, Inc. (“Argan”) conducts operations through its wholly-owned subsidiaries, Gemma Power Systems, LLC and affiliates (“GPS”); The Roberts Company, Inc. (“TRC”); Atlantic Projects Company Limited and affiliates (“APC”) and Southern Maryland Cable, Inc. (“SMC”). Argan and these consolidated subsidiaries are hereinafter collectively referred to as the “Company.”

Through GPS and APC, the Company provides a full range of engineering, procurement, construction, commissioning, operations management, maintenance, project development, technical and other consulting services to the power generation market, including the renewable energy sector. The wide range of customers includes independent power producers, public utilities, power plant equipment suppliers and global energy plant construction firms with projects located in the continental United States (the “US”), the Republic of Ireland (“Ireland”) and the United Kingdom (the “UK”). Including consolidated variable interest entities (“VIEs”), GPS and APC represent the Company’s power industry services reportable segment. Through TRC, the industrial fabrication and field services reportable segment provides on-site services that support maintenance turnarounds, shutdowns and emergency mobilizations for industrial plants primarily located in the southeast region of the US and that are based on its expertise in producing, delivering and installing fabricated metal components such as piping systems and pressure vessels. Through SMC, which conducts business as SMC Infrastructure Solutions, the telecommunications infrastructure services segment provides project management, construction, installation and maintenance services to commercial, local government and federal government customers primarily in the mid-Atlantic region of the US.

Basis of Presentation and Significant Accounting Policies

Basis of Presentation and Significant Accounting Policies

The condensed consolidated financial statements include the accounts of Argan, its wholly-owned subsidiaries and its financially controlled VIEs. All significant inter-company balances and transactions have been eliminated in consolidation.

In Note 14, the Company has provided certain financial information relating to the operating results and assets of its reportable segments based on the manner in which management disaggregates the Company’s financial reporting for purposes of making internal operating decisions. The Company’s fiscal year ends on January 31 each year.

The condensed consolidated balance sheet as of October 31, 2020, the condensed consolidated statements of earnings and stockholders’ equity for the three and nine months ended October 31, 2020 and 2019, and the condensed consolidated statements of cash flows for the nine months ended October 31, 2020 and 2019 are unaudited. The condensed consolidated balance sheet as of January 31, 2020 has been derived from audited financial statements. These condensed consolidated financial statements have been prepared pursuant to the rules and regulations of the US Securities and Exchange Commission (the “SEC”). Certain information and note disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America (“US GAAP”) have been condensed or omitted pursuant to those rules and regulations, although the Company believes that the disclosures made are adequate to make the information not misleading. The accompanying condensed consolidated financial statements and notes should be read in conjunction with the consolidated financial statements, the notes thereto, and the independent registered public accounting firm’s report thereon, that are included in the Company’s Annual Report on Form 10-K for the fiscal year ended January 31, 2020 (“Fiscal 2020”).

In the opinion of management, the accompanying condensed consolidated financial statements contain all adjustments, which are of a normal and recurring nature, considered necessary to present fairly the financial position of the Company as of October 31, 2020, and its earnings and cash flows for the interim periods presented. The results of operations for any interim period are not necessarily indicative of the results of operations for any other interim period or for a full fiscal year.

Accounting Policies

In December 2019, the Financial Accounting Standards Board (the “FASB”) issued Accounting Standards Update (“ASU”) 2019-12, Simplifying the Accounting for Income Taxes, which, among other changes, eliminates the exception to the general methodology for calculating income taxes in an interim period when a year-to-date loss exceeds the expected loss for the entire year. In these instances, the estimated annual effective income tax rate shall be used to calculate the tax without limitation. The new standard also requires the recognition of a franchise (or similar) tax that is partially based on income as an income-based tax and the recording of any incremental tax that is incurred by the Company as a non-income based tax. The requirements of this new guidance, effective for the Company on February 1, 2021, are not expected to alter the Company’s current accounting for income taxes.

In 2016, the FASB issued ASU 2016-13, Measurement of Credit Losses on Financial Instruments. The requirements of this new standard cover, among other provisions, the methods that businesses shall use to estimate amounts of uncollectible notes and accounts receivable. Adoption of this new guidance, which became effective for the Company on February 1, 2020, did not affect the Company's consolidated financial statements.

There are no other recently issued accounting pronouncements that have not yet been adopted that the Company considers material to its condensed consolidated financial statements.

The carrying value amounts presented in the condensed consolidated balance sheets for the Company’s current assets, which primarily include cash and cash equivalents, short-term investments, accounts receivable and contract assets, and its current liabilities are reasonable estimates of their fair values due to the short-term nature of these items.

Variable Interest Entity

Variable Interest Entity

In January 2018, the Company was deemed to be the primary beneficiary of a VIE that is performing the project development activities related to the planned construction of a new natural gas-fired power plant. Consideration for the Company’s engineering and financial support includes the right to build the power plant pursuant to a turnkey engineering, procurement and construction (“EPC”) services contract that has been negotiated and announced. The account balances of the VIE are included in the condensed consolidated financial statements, including development costs incurred by the VIE during the three and nine-month periods ended October 31, 2020 and 2019. The total amounts of the project development costs included in the balances for property, plant and equipment as of October 31 and January 31, 2020 were $7.4 million and $6.9 million, respectively. Recovery of the Company's investment in this project will most likely depend on the successful completion of the project development efforts, including the arrangement of financing for the construction and operation of the corresponding power plant.

XML

REVENUES FROM CONTRACT WITH CUSTOMERS (Tables)

9 Months Ended

Oct. 31, 2020

REVENUES FROM CONTRACT WITH CUSTOMERS

Schedule of consolidated revenues disaggregated by geographical area

	Three Months Ended				Nine Months Ended
	October 31,				October 31,
	2020		2019		2020		2019
United States	$	109,241	$	39,629	$	241,616	$	117,045
United Kingdom		9,759		10,349		22,595		35,631
Republic of Ireland		8,331		8,256		10,760		18,007
Other		—		172		—		326
Consolidated Revenues	$	127,331	$	58,406	$	274,971	$	171,009

XML

PURCHASED INTANGIBLE ASSETS (Tables)

9 Months Ended

Oct. 31, 2020

PURCHASED INTANGIBLE ASSETS

Schedule of company's purchased intangible assets, other than goodwill

		October 31, 2020						January 31,
	Estimated	Gross		Accumulated		Net		2020, (net
	Useful Life	Amounts		Amortization		Amount		amounts)
Trade names	15 years	$	8,142	$	4,849	$	3,293	$	3,699
Process certifications	7 years		1,897		1,332		565		768
Customer relationships	4-10 years		1,346		880		466		534
Totals		$	11,385	$	7,061	$	4,324	$	5,001

XML

COMMITMENTS (Tables)

9 Months Ended

Oct. 31, 2020

COMMITMENTS

Schedule of future minimum lease payments for the operating leases

Years Ending January 31,
Remainder of 2021	$	505
2022		1,648
2023		856
2024		242
2025		85
Thereafter		20
Total lease payments		3,356
Less interest portion		90
Present value of lease payments		3,266
Less current portion (included in accrued expenses)		2,760
Non-current portion	$	506

XML

STOCK-BASED COMPENSATION (Tables)

9 Months Ended

Oct. 31, 2020

STOCK-BASED COMPENSATION

Schedule of stock option activity under the Company's stock plans

Summaries of stock option activity under the Company’s approved stock option plans for the nine months ended October 31, 2020 and 2019, along with corresponding weighted average per share amounts, are presented below (shares in thousands):

		Exercise		Remaining
	Shares	Price		Term (years)	Fair Value
Outstanding, February 1, 2020	1,271	$	44.83	7.18	$	11.06
Granted	172	$	33.81
Exercised	(55)	$	22.69
Forfeited	(24)	$	55.61
Outstanding, October 31, 2020	1,364	$	44.14	6.96	$	10.52
Exercisable, October 31, 2020	865	$	46.40	5.97	$	11.76
		Exercise		Remaining
	Shares	Price		Term (years)	Fair Value
Outstanding, February 1, 2019	1,140	$	44.01	7.54	$	11.22
Granted	168	$	46.67
Exercised	(59)	$	26.36
Forfeited	(38)	$	46.34
Outstanding, October 31, 2019	1,211	$	45.18	7.28	$	11.27
Exercisable, October 31, 2019	753	$	45.81	6.25	$	10.22

Schedule of changes in the number of non-vested options to purchase shares of common stock

The changes in the number of non-vested options to purchase shares of common stock for the nine months ended October 31, 2020 and 2019, and the weighted average fair value per share for each number, are presented below (shares in thousands):

	Shares	Fair Value
Non-vested, February 1, 2020	448	$	9.74
Granted	172	$	5.68
Vested	(112)	$	9.81
Forfeitures	(9)	$	8.08
Non-vested, October 31, 2020	499	$	8.35
	Shares	Fair Value
Non-vested, February 1, 2019	375	$	10.05
Granted	168	$	10.32
Vested	(57)	$	9.28
Forfeitures	(28)	$	10.47
Non-vested, October 31, 2019	458	$	10.22

Summary of assumptions used to estimate fair value of stock options granted

	Nine Months Ended October 31,
	2020		2019
Dividend yield	3.0	%	2.2	%
Expected volatility	30.0	%	33.1	%
Risk-free interest rate	0.5	%	2.0	%
Expected life (in years)	3.4		3.3

XML

INCOME TAXES (Tables)

9 Months Ended

Oct. 31, 2020

INCOME TAXES

Schedule of actual income tax expense amounts

	Nine Months Ended October 31,
	2020		2019
Computed expected income tax (expense) benefit	$	(2,702)	$	8,070
Difference resulting from:
Net operating loss carryback		4,390		—
Foreign tax rate differential		(77)		(766)
Stock options		66		(170)
State income taxes, net of federal tax effect		(40)		185
Net operating losses deemed unrealizable		—		(6,280)
Bad debt loss		—		5,026
Adjustments and other differences		(246)		(1,129)
Income tax benefit	$	1,391	$	4,936

XML

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC. (Tables)

9 Months Ended

Oct. 31, 2020

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.

Schedule of computations of basic and diluted net income (loss) per share

Basic and diluted net income (loss) per share amounts are computed as follows (shares in thousands except in notes (1) below the charts):

	Three Months Ended October 31,
	2020		2019
Net income (loss) attributable to the stockholders of Argan, Inc.	$	9,454	$	(6,855)
Weighted average number of shares outstanding – basic		15,680		15,633
Effect of stock awards (1)		153		—
Weighted average number of shares outstanding – diluted		15,833		15,633
Net income (loss) per share attributable to the stockholders of Argan, Inc.
Basic	$	0.60	$	(0.44)
Diluted	$	0.60	$	(0.44)

(1) For the three months ended October 31, 2020, the weighted average number of shares determined on a dilutive basis excludes the effects of antidilutive stock options covering an aggregate of 506,501 shares of common stock. For the three months ended October 31, 2019, all common stock equivalents, which covered 1,243,000 shares of common stock, were considered to be antidilutive as the Company incurred a net loss for the period.

	Nine Months Ended October 31,
	2020		2019
Net income (loss) attributable to the stockholders of Argan, Inc.	$	14,300	$	(35,501)
Weighted average number of shares outstanding – basic		15,659		15,617
Effect of stock awards (1)		136		—
Weighted average number of shares outstanding – diluted		15,795		15,617
Net income (loss) per share attributable to the stockholders of Argan, Inc.
Basic	$	0.91	$	(2.27)
Diluted	$	0.91	$	(2.27)

(1)   For the nine months ended October 31, 2020, the weighted average number of shares determined on a dilutive basis excludes the effects of antidilutive stock options covering an aggregate of 688,000 shares of common stock. For the nine months ended October 31, 2019, all common stock equivalents, which covered 1,243,000 shares of common stock, were considered to be antidilutive as the Company incurred a net loss for the period.

XML

DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION (Details) - USD ($) $ in Millions	9 Months Ended	12 Months Ended
	Oct. 31, 2020	Jan. 31, 2020
DESCRIPTION OF THE BUSINESS AND BASIS OF PRESENTATION
Cost of property, plant and equipment	$ 7.4	$ 6.9

XML

REVENUES FROM CONTRACT WITH CUSTOMERS (Details) - USD ($) $ in Millions	Oct. 31, 2020	Jan. 31, 2020
REVENUES FROM CONTRACT WITH CUSTOMERS
Retained amounts by project owners	$ 32.5	$ 20.0
Amounts of unpriced change orders included in transaction prices	8.0	21.2

XML

REVENUES FROM CONTRACT WITH CUSTOMERS - Accounting for the Loss Subcontract (Details) - USD ($) $ in Millions	3 Months Ended		9 Months Ended		12 Months Ended
	Oct. 31, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019	Jan. 31, 2020	Mar. 24, 2020
Revenue, Initial Application Period Cumulative Effect Transition [Line Items]
Provision for contract loss					$ 5.8
TeesREPProject
Revenue, Initial Application Period Cumulative Effect Transition [Line Items]
Loss recorded		$ 0.3		$ 31.2
Reversal of profit				$ 0.7
Percentage of completion of subcontracted work						90.00%
Reduction to the subcontract loss	$ (2.8)		$ (4.1)
Subcontract loss			(29.5)
The total amounts of accounts receivable and contract assets with the customer			$ 7.3		$ 19.2

XML

REVENUES FROM CONTRACT WITH CUSTOMERS - Remaining Unsatisfied Performance Obligations (Details) - Revenue, Remaining Performance Obligation, Expected Timing of Satisfaction, Start Date [Axis]: 2020-11-01 $ in Millions	Oct. 31, 2020 USD ($)
Revenue, Remaining Performance Obligation, Expected Timing of Satisfaction [Line Items]
Contract backlog amount	$ 604.7
Contract backlog (as percent)	63.00%
Revenue, Remaining Performance Obligation, Expected Timing of Satisfaction, Period	12 months

XML

REVENUES FROM CONTRACT WITH CUSTOMERS - Disaggregation of Revenues (Details) - USD ($) $ in Thousands	3 Months Ended		9 Months Ended
	Oct. 31, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019
Disaggregation of Revenues
Totals	$ 127,331	$ 58,406	$ 274,971	$ 171,009
United States
Disaggregation of Revenues
Totals	109,241	39,629	241,616	117,045
United Kingdom
Disaggregation of Revenues
Totals	9,759	10,349	22,595	35,631
Republic of Ireland
Disaggregation of Revenues
Totals	$ 8,331	8,256	$ 10,760	18,007
Other
Disaggregation of Revenues
Totals		$ 172		$ 326

XML

CASH, CASH EQUIVALENTS AND SHORT-TERM INVESTMENTS (Details) - Held-to-maturity Securities - USD ($) $ in Millions	9 Months Ended	12 Months Ended
	Oct. 31, 2020	Jan. 31, 2020
Cash and Cash Equivalents
Maturity period	292 days	165 days
Accrued interest on held-to-maturity securities		$ 0.5
Weighted average annual interest rates of CDs (as a percent)	0.20%	1.80%

XML

ACCOUNTS AND NOTES RECEIVABLE (Details) $ in Millions	Oct. 31, 2020 USD ($)
ACCOUNTS AND NOTES RECEIVABLE
Outstanding balances of accounts receivable and contract assets	$ 24.5
Past due notes receivable	$ 1.7

XML

PURCHASED INTANGIBLE ASSETS - Goodwill and Finite Lived Intangible Assets (Details) - USD ($) $ in Thousands	3 Months Ended	9 Months Ended
	Apr. 30, 2019	Oct. 31, 2020	Oct. 31, 2019	Jan. 31, 2020
Indefinite-Lived Intangible Assets
Goodwill		$ 27,943	$ 30,766	$ 27,943
Goodwill changes		0	0
Impairment loss			$ 2,072
Intangible Assets - Gross Carrying Amount		11,385
Accumulated Amortization		7,061
Finite Lived Intangible Assets - Net Amount		4,324		5,001
APC
Indefinite-Lived Intangible Assets
Impairment loss	$ 2,100
GPS
Indefinite-Lived Intangible Assets
Goodwill		18,500		18,500
TRC
Indefinite-Lived Intangible Assets
Goodwill		$ 9,500		9,500
Trade names
Indefinite-Lived Intangible Assets
Finite-Lived Intangible Assets - Estimated Useful Life		15 years
Intangible Assets - Gross Carrying Amount		$ 8,142
Accumulated Amortization		4,849
Finite Lived Intangible Assets - Net Amount		$ 3,293		3,699
Process certifications
Indefinite-Lived Intangible Assets
Finite-Lived Intangible Assets - Estimated Useful Life		7 years
Intangible Assets - Gross Carrying Amount		$ 1,897
Accumulated Amortization		1,332
Finite Lived Intangible Assets - Net Amount		565		768
Customer relationships
Indefinite-Lived Intangible Assets
Intangible Assets - Gross Carrying Amount		1,346
Accumulated Amortization		880
Finite Lived Intangible Assets - Net Amount		$ 466		$ 534
Customer relationships | Maximum
Indefinite-Lived Intangible Assets
Finite-Lived Intangible Assets - Estimated Useful Life		10 years
Customer relationships | Minimum
Indefinite-Lived Intangible Assets
Finite-Lived Intangible Assets - Estimated Useful Life		4 years

XML

FINANCING ARRANGEMENTS (Details) - USD ($) $ in Millions		9 Months Ended
	May 15, 2017	Oct. 31, 2020	Jan. 31, 2020
Financing Arrangements
Amount of an outstanding letter of credit issued by Bank in support of project development activities and deposited with the Bank as collateral		$ 3.4
London Interbank Offered Rate (LIBOR)
Financing Arrangements
Interest rate margin on referred rate		2.00%
Revolving Credit Facility | London Interbank Offered Rate (LIBOR)
Financing Arrangements
Variable rate	30-day LIBOR
Interest rate margin on referred rate	2.00%
Revolving Credit Facility | Expires on May 31, 2021
Financing Arrangements
Borrowing available under financing arrangements	$ 50.0
Letter of Credit
Financing Arrangements
Borrowings outstanding under Bank financing arrangements		$ 0.0	$ 0.0
Letters of credit outstanding amount		$ 1.7	$ 9.9

XML

COMMITMENTS - Future minimum lease payments (Details) $ in Thousands	Oct. 31, 2020 USD ($)
Operating Leases
Remainder of 2021	$ 505
2022	1,648
2023	856
2024	242
2025	85
Thereafter	20
Total lease payments	3,356
Less interest portion	90
Present value of lease payments	3,266
Less current portion (included in accrued expenses)	$ 2,760
Less current portion (included in accrued expenses)	us-gaap:AccruedLiabilitiesCurrent
Non-current portion	$ 506

XML

COMMITMENTS - Warranties (Details)	9 Months Ended
	Oct. 31, 2020
Minimum
Warranty period	9 months
Maximum
Warranty period	24 months

XML

COMMITMENTS - Leases (Details) - USD ($) $ in Thousands	3 Months Ended		9 Months Ended
	Oct. 31, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019
Operating leases, options to extend			true
Operating leases, options to terminate			true
Operating lease expense	$ 500	$ 100	$ 1,318	$ 637
Operating lease payments	$ 300	200	$ 1,200	600
Weighted average lease term	32 months		32 months
Weighted average discount rate	3.30%		3.30%
Surety Bond
Outstanding letter of credit replaced with Surety bond	$ 7,600		$ 7,600
London Interbank Offered Rate (LIBOR)
Interest rate margin on referred rate			2.00%
TRC
April 30, 2021	300		$ 300
GPS
Future minimum lease payment	500		2,300
GPS | Financial guarantee
Guarantor obligation maximum exposure	3,600		3,600
Costs of Revenues
Rent expense	2,300	900	4,200	3,200
Selling, General and Administrative Expenses
Rent expense	$ 200	$ 100	$ 700	$ 500

XML

STOCK-BASED COMPENSATION - Summary of Activity under Company's Stock Option Plans (Details) - $ / shares shares in Thousands	9 Months Ended		12 Months Ended
	Oct. 31, 2020	Oct. 31, 2019	Jan. 31, 2020	Jan. 31, 2019
STOCK-BASED COMPENSATION
Shares, Outstanding, Beginning balance	1,271	1,140	1,140
Shares, Granted	172	168
Shares, Exercised	(55)	(59)
Shares, Forfeited	(24)	(38)
Shares, Outstanding, Ending balance	1,364	1,211	1,271	1,140
Shares, Exercisable	865	753
Weighted Average Exercise Price, Outstanding, Beginning balance	$ 44.83	$ 44.01	$ 44.01
Weighted Average Exercise Price, Granted	33.81	46.67
Weighted Average Exercise Price, Exercised	22.69	26.36
Weighted Average Exercise Price, Forfeited	55.61	46.34
Weighted Average Exercise Price, Outstanding, Ending balance	44.14	45.18	$ 44.83	$ 44.01
Weighted Average Exercise Price, Exercisable	$ 46.40	$ 45.81
Weighted Average Remaining Term (Years), Outstanding	6 years 11 months 15 days	7 years 3 months 10 days	7 years 2 months 4 days	7 years 6 months 14 days
Weighted Average Remaining Term (Years), Exercisable	5 years 11 months 19 days	6 years 3 months
Weighted Average Fair Value, Outstanding	$ 10.52	$ 11.27	$ 11.06	$ 11.22
Weighted Average Fair Value, Exercisable	$ 11.76	$ 10.22

XML

STOCK-BASED COMPENSATION - Summary of Change in Number of Non-Vested Options to Purchase Shares of Common Stock (Details) - $ / shares shares in Thousands	9 Months Ended
	Oct. 31, 2020	Oct. 31, 2019
STOCK-BASED COMPENSATION
Shares, Non-vested, Beginning balance	448	375
Shares, Granted	172	168
Shares, Vested	(112)	(57)
Shares, Forfeitures	(9)	(28)
Shares, Non-vested, Ending balance	499	458
Weighted Average Fair Value, Non-vested, Beginning balance	$ 9.74	$ 10.05
Weighted Average Fair Value, Granted	5.68	10.32
Weighted Average Fair Value, Vested	9.81	9.28
Weighted Average Fair Value, Forfeitures	8.08	10.47
Weighted Average Fair Value, Non-vested, Ending balance	$ 8.35	$ 10.22

XML

STOCK-BASED COMPENSATION - Summary of Assumptions Used to Estimate Fair Value of Stock Options Granted (Details) - Stock Options Plans	9 Months Ended
	Oct. 31, 2020	Oct. 31, 2019
Share-based Compensation Arrangement by Share-based Payment Award
Dividend yield	3.00%	2.20%
Expected volatility	30.00%	33.10%
Risk-free interest rate	0.50%	2.00%
Expected life (in years)	3 years 4 months 24 days	3 years 3 months 18 days

XML

STOCK-BASED COMPENSATION - Additional Information (Details) $ in Thousands	3 Months Ended					9 Months Ended
	Oct. 31, 2020 USD ($) shares	Apr. 30, 2020 shares	Oct. 31, 2019 USD ($)	Apr. 30, 2019 shares	Apr. 30, 2018 shares	Oct. 31, 2020 USD ($) person shares	Oct. 31, 2019 USD ($)	Jun. 23, 2020 shares
Share-based Compensation Arrangement by Share-based Payment Award
Percentage Reduction In The Aggregate Fair Value Of Stock Option						88.50%
Percentage reduction in the aggregate fair value of stock option						88.50%
Stock compensation expense	$ 800		$ 600			$ 2,199	$ 1,512
Unrecognized compensation cost	3,800					$ 3,800
Compensation expense recognize, period						3 years
Intrinsic value of outstanding stock options	4,700					$ 4,700
Intrinsic value of exercisable stock options	$ 3,300					$ 3,300
Period used for calculations						5 years
Minimum
Share-based Compensation Arrangement by Share-based Payment Award
Period used for calculations						3 years
Maximum
Share-based Compensation Arrangement by Share-based Payment Award
Period used for calculations						5 years
2020 Plan
Share-based Compensation Arrangement by Share-based Payment Award
Number of shares of common stock reserved for issuance | shares								500,000
Stock Options Plans
Share-based Compensation Arrangement by Share-based Payment Award
Initial vesting percentage						33.33%
Period to become exercisable						3 years
Number of shares of common stock available for award | shares	688,999					688,999
Number of shares of common stock reserved for issuance | shares	2,170,400					2,170,400
Intrinsic value of the stock options exercised						$ 1,200	$ 1,400
ISOs/NSOs | 2011 Plan
Share-based Compensation Arrangement by Share-based Payment Award
Incentive stock option award maximum expiration period						10 years
Senior executives | Performance-based restricted stock units | 2011 Plan
Share-based Compensation Arrangement by Share-based Payment Award
Period to become exercisable						3 years
Number of executives | person						2
Percentage of the maximum shares for the target number of shares awarded						50.00%
Senior executives | Performance-based restricted stock units | 2011 Plan | Maximum
Share-based Compensation Arrangement by Share-based Payment Award
Number of shares awarded | shares		45,000		36,000	36,000

XML

INCOME TAXES - Income Tax Expense Reconciliation (Details) - USD ($) $ in Thousands	3 Months Ended			9 Months Ended		12 Months Ended
	Oct. 31, 2020	Apr. 30, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019	Jan. 31, 2020
Federal corporate income tax rate (as percent)				21.00%		21.00%
Computed expected income tax (expense) benefit				$ (2,702)	$ 8,070
Net operating loss carryback		$ 4,400		4,390
Foreign tax rate differential				(77)	(766)
Stock options				66	(170)
State income taxes, net of federal tax effect				(40)	185
Net operating losses deemed unrealizable					(6,280)
Bad debt loss					5,026
Adjustments and other permanent differences				(246)	(1,129)
Income tax benefit	$ (1,666)		$ (1,996)	1,391	4,936
Tax benefit from subsidiaries				$ 100
United Kingdom
Deferred tax valuation allowance			$ 6,300		$ 6,300

XML

INCOME TAXES - Net Operating Loss Carryback (Details) - USD ($) $ in Thousands	3 Months Ended	9 Months Ended	12 Months Ended
	Apr. 30, 2020	Oct. 31, 2020	Jan. 31, 2020
Operating Loss Carryforwards [Line Items]
Increase in loss carryback period for certain losses		5 years
Domestic net operating loss carryback			$ 39,500
Deferred tax asset operating loss carryforward			$ 8,300
Effective Income Tax Rate Reconciliation, at Federal Statutory Income Tax Rate, Percent		21.00%	21.00%
Amount of rate difference tax benefit	$ 4,400	$ 4,390
Other current assets
Operating Loss Carryforwards [Line Items]
Income tax receivable		$ 12,700

XML

INCOME TAXES - Research and Development Tax Credits (Details) - USD ($) $ in Millions	12 Months Ended
	Jan. 31, 2018	Oct. 31, 2020	Jan. 31, 2020	Jan. 31, 2019
INCOME TAXES
Prior period for identify and quantify the amounts of research and development credits	3 years
Research and development tax credit benefit				$ 16.2
Unrecognized income tax benefits related to research and development credits		$ 5.0
Amount of unrecognized income tax benefits liability			$ 5.0
Income tax refunds and prepaid income taxes		$ 27.3	$ 14.5

XML

INCOME TAXES - Supplemental Cash Flow Information (Details) - USD ($) $ in Millions	9 Months Ended
	Oct. 31, 2020	Oct. 31, 2019
INCOME TAXES
Income Taxes Paid	$ 3.8	$ 3.1
Proceeds from Income Tax Refunds	$ 0.9	$ 7.9

XML

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC. (Details) - USD ($) $ / shares in Units, shares in Thousands, $ in Thousands	3 Months Ended		9 Months Ended
	Oct. 31, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019
NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.
Net income (loss) attributable to the stockholders of Argan, Inc.	$ 9,454	$ (6,855)	$ 14,300	$ (35,501)
Weighted average number of shares outstanding - basic	15,680	15,633	15,659	15,617
Effects of stock awards	153		136
Weighted average number of shares outstanding - diluted	15,833	15,633	15,795	15,617
Basic (in Dollars per share)	$ 0.60	$ (0.44)	$ 0.91	$ (2.27)
Diluted (in Dollars per share)	$ 0.60	$ (0.44)	$ 0.91	$ (2.27)

XML

NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC. - Additional information (Details) - shares	3 Months Ended		9 Months Ended
	Oct. 31, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019
NET INCOME (LOSS) PER SHARE ATTRIBUTABLE TO THE STOCKHOLDERS OF ARGAN, INC.
Antidilutive common stock	506,501	1,243,000	688,000	1,243,000

XML

CASH DIVIDENDS (Details) - $ / shares										3 Months Ended		9 Months Ended		12 Months Ended
	Oct. 31, 2020	Oct. 30, 2020	Sep. 10, 2020	Jul. 31, 2020	Jun. 23, 2020	Apr. 30, 2020	Apr. 09, 2020	Jul. 31, 2019	Apr. 30, 2019	Oct. 31, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019	Jan. 31, 2020
CASH DIVIDENDS
Regular cash dividend declared per common stock			$ 0.25		$ 0.25		$ 0.25			$ 0.25	$ 0.25	$ 1.75	$ 0.75
Regular cash dividend paid per common stock	$ 0.25	$ 0.25		$ 0.25		$ 0.25		$ 0.25	$ 0.25
Regular quarterly cash dividend declared per common stock														$ 0.25
Special Cash dividend declared per common stock					$ 1.00
Special cash dividend paid per common stock				$ 1.00

XML

CUSTOMER CONCENTRATIONS (Details) - customer	3 Months Ended		9 Months Ended		12 Months Ended
	Oct. 31, 2020	Oct. 31, 2019	Oct. 31, 2020	Oct. 31, 2019	Jan. 31, 2020
Accounts Receivable
Customer Concentrations
Number of customers			4		3
Contract Asset
Customer Concentrations
Number of customers			2		2
Major Customer One | Accounts Receivable
Customer Concentrations
Percentage of consolidated accounts receivable accounted by major customer			24.00%		24.00%
Major Customer One | Contract Asset
Customer Concentrations
Percentage of major customers or segments			63.00%		51.00%
Major Customer Two | Accounts Receivable
Customer Concentrations
Percentage of consolidated accounts receivable accounted by major customer			14.00%		21.00%
Major Customer Two | Contract Asset
Customer Concentrations
Percentage of major customers or segments			12.00%		31.00%
Major Customer Three | Accounts Receivable
Customer Concentrations
Percentage of consolidated accounts receivable accounted by major customer			11.00%		12.00%
Major Customer Four | Accounts Receivable
Customer Concentrations
Percentage of consolidated accounts receivable accounted by major customer			10.00%
Power Services | Revenue
Customer Concentrations
Percentage of major customers or segments	86.00%	61.00%	83.00%	49.00%
Number of customers	1	2	1	2
Power Services | Major Customer One | Revenue
Customer Concentrations
Percentage of major customers or segments	70.00%	27.00%	69.00%	13.00%
Power Services | Major Customer Two | Revenue
Customer Concentrations
Percentage of major customers or segments		17.00%		10.00%
Industry services | Revenue
Customer Concentrations
Percentage of major customers or segments	12.00%	34.00%	15.00%	47.00%
Number of customers		1
Industry services | Major Customer One | Revenue
Customer Concentrations
Percentage of major customers or segments		10.00%

XML

SEGMENT REPORTING (Details) $ in Thousands	3 Months Ended		9 Months Ended
	Oct. 31, 2020 USD ($)	Oct. 31, 2019 USD ($)	Oct. 31, 2020 USD ($) segment	Oct. 31, 2019 USD ($)	Jan. 31, 2020 USD ($)
Segment Reporting Information
Operating segment | segment			1
Revenues	$ 127,331	$ 58,406	$ 274,971	$ 171,009
Cost of revenues	106,988	52,414	234,989	183,078
Gross (loss) profit	20,343	5,992	39,982	(12,069)
Selling, general and administrative expenses	9,398	12,135	28,827	31,761
Impairment loss				2,072
(Loss) income from operations	10,945	(6,143)	11,155	(45,902)
Other income, net	175	3,578	1,714	7,472
(Loss) income before income taxes	11,120	(2,565)	12,869	(38,430)
Income tax (expense) benefit (Note 10)	(1,666)	(1,996)	1,391	4,936
Net income (loss)	9,454	(4,561)	14,260	(33,494)
Amortization of intangibles	226	272	677	864
Depreciation	940	899	2,798	2,610
Property, plant and equipment additions	279	3,265	1,412	6,308
Current assets	538,820	405,900	538,820	405,900	$ 421,755
Current liabilities	261,030	118,957	261,030	118,957	144,034
Goodwill	27,943	30,766	27,943	30,766	27,943
Total assets	595,500	472,717	595,500	472,717	$ 487,540
Other
Segment Reporting Information
Selling, general and administrative expenses	1,985	1,960	5,824	5,290
(Loss) income from operations	(1,985)	(1,960)	(5,824)	(5,290)
Other income, net	3	131	80	435
(Loss) income before income taxes	(1,982)	(1,829)	(5,744)	(4,855)
Depreciation	2	1	4	4
Property, plant and equipment additions				11
Current assets	118,758	82,048	118,758	82,048
Current liabilities	751	943	751	943
Total assets	119,045	87,998	119,045	87,998
Intercompany Eliminations
Segment Reporting Information
Revenues	500	1,100	1,400	2,500
Power Services
Segment Reporting Information
Revenues	109,712	35,848	227,363	83,941
Cost of revenues	91,263	31,327	192,583	104,759
Gross (loss) profit	18,449	4,521	34,780	(20,818)
Selling, general and administrative expenses	5,096	7,672	15,892	18,977
Impairment loss				2,072
(Loss) income from operations	13,353	(3,151)	18,888	(41,867)
Other income, net	172	3,447	1,634	7,037
(Loss) income before income taxes	13,525	296	20,522	(34,830)
Amortization of intangibles	62	61	182	231
Depreciation	178	176	522	517
Property, plant and equipment additions	164	2,659	857	4,533
Current assets	392,954	292,618	392,954	292,618
Current liabilities	245,808	108,474	245,808	108,474
Goodwill	18,476	18,476	18,476	18,476
Total assets	425,909	324,535	425,909	324,535
Industrial Services
Segment Reporting Information
Revenues	15,730	20,143	42,163	80,442
Cost of revenues	14,218	19,159	38,096	72,958
Gross (loss) profit	1,512	984	4,067	7,484
Selling, general and administrative expenses	1,828	2,018	5,664	5,959
(Loss) income from operations	(316)	(1,034)	(1,597)	1,525
(Loss) income before income taxes	(316)	(1,034)	(1,597)	1,525
Amortization of intangibles	164	166	495	497
Depreciation	654	625	1,967	1,791
Property, plant and equipment additions	34	436	338	1,487
Current assets	25,404	28,373	25,404	28,373
Current liabilities	13,762	8,744	13,762	8,744
Goodwill	9,467	12,290	9,467	12,290
Total assets	47,356	55,814	47,356	55,814
Telecom Services
Segment Reporting Information
Revenues	1,889	2,415	5,445	6,626
Cost of revenues	1,507	1,928	4,310	5,361
Gross (loss) profit	382	487	1,135	1,265
Selling, general and administrative expenses	489	485	1,447	1,535
(Loss) income from operations	(107)	2	(312)	(270)
(Loss) income before income taxes	(107)	2	(312)	(270)
Amortization of intangibles		45		136
Depreciation	106	97	305	298
Property, plant and equipment additions	81	170	217	277
Current assets	1,704	2,861	1,704	2,861
Current liabilities	709	796	709	796
Total assets	$ 3,190	$ 4,370	$ 3,190	$ 4,370