EX-10.22 7 logc-ex1022_360.htm EX-10.22 logc-ex1022_360.htm

 

Exhibit 10.22

 

65 HAYDEN AVENUE
LEXINGTON, MASSACHUSETTS 02421

LEASE SUMMARY SHEET

 

Execution Date:

November 4, 2019

Tenant:

LOGICBIO THERAPEUTICS, INC., a Delaware corporation

Tenant’s Mailing Address Prior to Occupancy:

99 Erie Street, Cambridge, MA 02139

Landlord:

HCP/KING HAYDEN CAMPUS LLC,
a Delaware limited liability company

Building:

65 Hayden Avenue, Lexington, Massachusetts 02421.  The Building consists of approximately 213,005 rentable square feet, including a four-story garage with 298 spaces (the “65 Hayden Garage”).  The Building consists of two wings—the North Building and the South Building.  The land (the “Land”) on which the Building and the Garage are located is described as “Parcel Three” and “Parcel Four” on Exhibit 2 attached hereto and made a part hereof.

Campus:

All of the land described on Exhibit 2 (including the Land described above) together with the Building described above, the buildings now known as and numbered 45 Hayden Avenue, 55 Hayden Avenue, and 75 Hayden Avenue (“Building 75”), and any other building and/or improvements constructed on the Land. The Campus includes a parking garage at Building 75 (collectively, along with the 65 Hayden Garage, the “Garage”).

1


 

Premises:

Areas on the first (1st) and second (2nd) floors of the South portion of the Building, containing approximately 23,901 rentable square feet in the aggregate.  The Premises consist of:

Prime Premises, which are located on the second (2nd) floor;  

PH System Premises, which are located on the first (1st) floor. The PH System Premises are located in a room (the “PH System Room”) which contains the PH systems of other tenants;

The term “Premises” shall mean the Prime Premises and PH System Premises, as applicable.  The Premises are shown the Lease Plans attached hereto as Exhibit 1A and Exhibit 1B and made a part hereof (the “Lease Plans”).

Landlord and Tenant stipulate and agree that the Rentable Square Footage of the Building and the Rentable Square Footage of the Premises are correct and shall not be remeasured.

Property:

The Building, the Garage, the Land, and other improvements located on, and to be constructed on, the Land.

Parking Areas:

The parking structures (surface lots and parking decks, including the Garage adjacent to the Building) located on the Campus that Landlord provides for parking by all tenants of space on the Property.

Term Commencement Dates:


The earlier of (i) the date that Tenant first commences to use the Premises, or any portion thereof, for the Permitted Use and (ii) the Substantial Completion, as hereinafter defined, of the Landlord’s Work, as hereinafter defined, subject to the completion of the Vivarium Work, as hereinafter defined, subsequent to the Term Commencement Date, as more particularly set forth in Section 3.1 below.

Rent Commencement Date:


The date that occurs three (3) months after the Term Commencement Date.

Expiration Date:

Five (5) years after the Rent Commencement Date, except that if the Rent Commencement Date does not occur on the first day of a calendar month, then the Expiration Date shall be the last day of the calendar month in which the fifth (5th) anniversary of the Rent Commencement Date occurs.

Extension Term(s):

Subject to Section 1.2 below, one (1) extension term of five (5) years.

Permitted Uses:

Subject to Legal Requirements, general office, research, development and laboratory use, and other ancillary uses (including, but not limited to, vivarium uses) related to the foregoing.

Base Rent:

RENT YEAR

ANNUAL BASE RENT

MONTHLY PAYMENT

 

1

$1,493,812.50

$124,484.38

 

2

$1,538,626.88

$128,218.91

 

3

$1,584,785.68

$132,065.47

 

4

$1,632,329.25

$136,027.44

 

5

$1,681,299.13

$140,108.26

 

2


 

Rent Year:

Rent Year 1 shall be the twelve-(12)-month period commencing as of the Rent Commencement Date, except that if the Rent Commencement Date occurs on other than the first day of a calendar month, then Rent Year 1 shall commence as of the Rent Commencement Date and shall end on the last day of the calendar year in which the first anniversary of the Rent Commencement Date occurs.  Each Rent Year after Rent Year 1 shall be the twelve-(12)-month period immediately following the preceding Rent Year.

Operating Costs and Taxes:


See Sections 5.2 and 5.3.

Tenant’s Share:

A fraction, the numerator of which is the number of rentable square feet in the Premises and the denominator of which is the number of rentable square feet in the Building.  As of the Execution Date, Tenant’s Share with respect to the Premises is 11.22%

Security Deposit/ Letter of Credit:


$622,421.88

Guarantor:

N/A

 

EXHIBIT 1A

LEASE PLAN - PRIME PREMISES

EXHIBIT 1B

EXHIBIT 1C

LEASE PLAN - PH SYSTEM PREMISES

TENANT’S ROOFTOP PREMISES

EXHIBIT 2

LEGAL DESCRIPTION - LAND

EXHIBIT 3

Intentionally Deleted

EXHIBIT 4

WORK LETTER

EXHIBIT 4-1

BASE BUILDING WORK

EXHIBIT 4-2

INITIAL PLAN

EXHIBIT 4-3

EQUIPMENT LIST

EXHIBIT 5

BASE BUILDING CAPACITIES

EXHIBIT 6

FORM OF LETTER OF CREDIT

EXHIBIT 7

LANDLORD’S SERVICES

EXHIBIT 8

TENANT’S HAZARDOUS MATERIALS

EXHIBIT 9

RULES AND REGULATIONS

EXHIBIT 9-1

BUILDING RULES AND REGULATIONS

EXHIBIT 9-2

CONSTRUCTION RULES AND REGULATIONS

EXHIBIT 10

TENANT’S WORK INSURANCE SCHEDULE

EXHIBIT 11

TENANT CONTROL AREAS

 

 

3


 

TABLE OF CONTENTS

 

1.

LEASE GRANT; TERM; APPURTENANT RIGHTS; EXCLUSIONS

1

 

1.1

 

Lease Grant

1

 

1.2

 

Extension Terms

1

 

1.3

 

Appurtenant Rights

2

 

1.4

 

Tenant’s Access

5

 

1.5

 

No recording // Notice of Lease

5

 

1.6

 

Exclusions

5

 

1.7

 

Acid Neutralization Tank

5

2.

RIGHTS RESERVED TO LANDLORD

7

 

2.1

 

Additions and Alterations

7

 

2.2

 

Additions to the Property

7

 

2.3

 

Name and Address of Building

8

 

2.4

 

Landlord’s Access

8

 

2.5

 

Pipes, Ducts and Conduits

9

 

2.6

 

Minimize Interference

9

3.

CONDITION OF PREMISES; CONSTRUCTION

10

 

3.1

 

Condition of Premises

10

 

3.2

 

Landlord’s Work

10

 

3.3

 

Tenant’s Remedies in the Event of Delays in Term Commencement Date.

11

4.

USE OF PREMISES

12

 

4.1

 

Permitted Uses

12

 

4.2

 

Prohibited Uses

12

 

4.3

 

Transportation of Animals

13

 

4.4

 

MWRA Permit

13

 

4.5

 

Parking and Traffic Demand Management Plan

14

 

4.6

 

Vivarium

14

5.

RENT; ADDITIONAL RENT

14

 

5.1

 

Base Rent

14

 

5.2

 

Operating Costs

14

 

5.3

 

Taxes

18

 

5.4

 

Late Payments

20

 

5.5

 

No Offset; Independent Covenants; Waiver

20

 

5.6

 

Survival

21

6.

Intentionally Omitted

21

7.

LETTER OF CREDIT

21

 

7.1

 

Amount

21

 

7.2

 

Application of Proceeds of Letter of Credit

22

 

7.3

 

Transfer of Letter of Credit

22

 

7.4

 

Cash Proceeds of Letter of Credit

22

 

7.5

 

Return of Security Deposit or Letter of Credit

23

8.

Intentionally Deleted

23

9.

UTILITIES, LANDLORD’S SERVICES

23

 

9.1

 

Electricity

23

 

9.2

 

Water

23

i


 

 

9.3

 

Gas

23

 

9.4

 

Other Utilities

24

 

9.5

 

Interruption or Curtailment of Utilities

24

 

9.6

 

Landlord’s Services

24

10.

MAINTENANCE AND REPAIRS

25

 

10.1

 

Maintenance and Repairs by Tenant

25

 

10.2

 

Maintenance and Repairs by Landlord

25

 

10.3

 

Accidents to Sanitary and Other Systems

25

 

10.4

 

Floor Load--Heavy Equipment

25

 

10.5

 

Premises Cleaning

26

 

10.6

 

Pest Control

26

 

10.7

 

Service Interruptions

26

11.

ALTERATIONS AND IMPROVEMENTS BY TENANT

27

 

11.1

 

Landlord’s Consent Required

27

 

11.2

 

After-Hours

28

 

11.3

 

Harmonious Relations

28

 

11.4

 

Liens

28

 

11.5

 

General Requirements

29

12.

SIGNAGE

29

 

12.1

 

Restrictions

29

 

12.2

 

Exterior Signage

29

 

(a)

 

Monument Signage

29

 

12.3

 

Building Directory

29

13.

ASSIGNMENT, MORTGAGING AND SUBLETTING

29

 

13.1

 

Landlord’s Consent Required

29

 

13.2

 

Landlord’s Recapture Right

30

 

13.3

 

Standard of Consent to Transfer

30

 

13.4

 

Listing Confers no Rights

30

 

13.5

 

Profits in Connection with Transfers

31

 

13.6

 

Prohibited Transfers

31

 

13.7

 

Exceptions to Requirement for Consent

31

14.

INSURANCE; INDEMNIFICATION; EXCULPATION

32

 

14.1

 

Tenant’s Insurance

32

 

14.2

 

Indemnification

33

 

14.3

 

Property of Tenant

34

 

14.4

 

Limitation of Landlord’s Liability for Damage or Injury

34

 

14.5

 

Waiver of Subrogation; Mutual Release

34

 

14.6

 

Tenant’s Acts--Effect on Insurance

35

 

14.7

 

Landlord’s Insurance

35

15.

CASUALTY; TAKING

35

 

15.1

 

Damage

35

 

15.2

 

Termination Rights

36

 

15.3

 

Rent Abatement

37

 

15.4

 

Taking for Temporary Use

37

 

15.5

 

Disposition of Awards

37

16.

ESTOPPEL CERTIFICATE

37

ii


 

17.

HAZARDOUS MATERIALS

38

 

17.1

 

Prohibition

38

 

17.2

 

Environmental Laws

39

 

17.3

 

Hazardous Material Defined

39

 

17.4

 

Chemical Safety Program

39

 

17.5

 

Testing

39

 

17.6

 

Indemnity; Remediation

40

 

17.7

 

Disclosures

42

 

17.8

 

Removal

42

18.

RULES AND REGULATIONS.

42

 

18.1

 

Rules and Regulations

42

 

18.2

 

Energy Conservation

42

 

18.3

 

Recycling

42

19.

LAWS AND PERMITS.

43

 

19.1

 

Legal Requirements

43

20.

DEFAULT

44

 

20.1

 

Events of Default

44

 

20.2

 

Remedies

45

 

20.3

 

Damages - Termination

45

 

20.4

 

Landlord’s Self-Help; Fees and Expenses

47

 

20.5

 

Waiver of Redemption, Statutory Notice and Grace Periods

47

 

20.6

 

Remedies Not Exclusive

47

 

20.7

 

No Waiver

47

 

20.8

 

[Intentionally Deleted]

48

 

20.9

 

Landlord Default

48

21.

SURRENDER; ABANDONED PROPERTY; HOLD-OVER

48

 

21.1

 

Surrender

48

 

21.2

 

Abandoned Property

50

 

21.3

 

Holdover

50

 

21.4

 

Warranties

50

22.

MORTGAGEE RIGHTS

50

 

22.1

 

Subordination

50

 

22.2

 

Notices

51

 

22.3

 

Mortgagee Consent

51

 

22.4

 

Mortgagee Liability

51

23.

QUIET ENJOYMENT.

51

24.

NOTICES.

52

25.

MISCELLANEOUS

53

 

25.1

 

Separability

53

 

25.2

 

Captions

53

 

25.3

 

Broker

53

 

25.4

 

Entire Agreement

53

 

25.5

 

Governing Law

53

 

25.6

 

Representation of Authority

53

 

25.7

 

Expenses Incurred by Landlord Upon Tenant Requests

53

 

25.8

 

Survival

54

iii


 

 

25.9

 

Limitation of Liability

54

 

25.10

 

Binding Effect

54

 

25.11

 

Landlord Obligations upon Transfer

54

 

25.12

 

No Grant of Interest

54

 

25.13

 

Financial Information

54

 

25.14

 

OFAC Certificate and Indemnity

54

 

25.15

 

Confidentiality

55

 

25.16

 

Force Majeure

55

 

 

 

 

iv


 

THIS INDENTURE OF LEASE (this “Lease”) is hereby made and entered into on the Execution Date by and between Landlord and Tenant.

Each reference in this Lease to any of the terms and titles contained in any Exhibit attached to this Lease shall be deemed and construed to incorporate the data stated under that term or title in such Exhibit. All capitalized terms not otherwise defined herein shall have the meanings ascribed to them as set forth in the Lease Summary Sheet which is attached hereto and incorporated herein by reference.

1.

LEASE GRANT; TERM; APPURTENANT RIGHTS; EXCLUSIONS

1.1Lease Grant.  Landlord hereby leases to Tenant, and Tenant hereby leases from Landlord, the Premises upon and subject to terms and conditions of this Lease, for a term of years commencing on the Term Commencement Date and, unless earlier terminated or extended pursuant to the terms hereof, ending on the Expiration Date (the “Initial Term”; the Initial Term and any duly exercised Extension Terms are hereinafter collectively referred to as the “Term”).

1.2Extension Terms.  

(a)Provided that the following conditions, which may be waived by Landlord in its sole discretion, are satisfied (i) Tenant, an Affiliated Entity (hereinafter defined) and/or a Successor (hereinafter defined) is/are then occupying seventy-five percent (75%) of the Premises; and (ii) no Event of Default nor an event which, with the passage of time and/or the giving of notice would constitute an Event of Default has occurred (1) as of the date of the Extension Notice (hereinafter defined), and (2) at the commencement of the applicable Extension Term (hereinafter defined), Tenant shall have the option to extend the Term for one (1) additional term(s) of five (5) years (the “Extension Term”), commencing as of the expiration of the Initial Term.  Tenant must exercise such option to extend, if at all, by giving Landlord written notice (the “Extension Notice”) on or before the date that is nine (9) months prior to the expiration of the then-current Term of this Lease, time being of the essence.  Upon the timely giving of such notice, the Term shall be deemed extended upon all of the terms and conditions of this Lease, except that Base Rent during the Extension Term shall be calculated in accordance with this Section 1.2, Landlord shall have no obligation to construct or renovate the Premises and Tenant shall have no further right to extend the Term.  If Tenant fails to give timely notice, as aforesaid, Tenant shall have no further right to extend the Term.  Notwithstanding the fact that Tenant’s proper and timely exercise of such option to extend the Term shall be self-executing, the parties shall promptly execute a lease amendment reflecting such Extension Term after Tenant exercises such option.  The parties’ mutual execution of such lease amendment shall be deemed presumptive evidence that Tenant has satisfied the conditions under this Section 1.2.

(b)The Base Rent during the Extension Term (the “Extension Term Base Rent”) shall be determined in accordance with the process described hereafter.  Extension Term Base Rent shall be the greater of (i) Base Rent for the last Rent Year of the prior Term, or (ii) the fair market rental value of the Premises then demised to Tenant as of the commencement of the Extension Term as determined in accordance with the process described below, for renewals of first class office/research/laboratory building/campus in the Route 128/Route 2/Alewife corridor real estate market (the “Market Area”) of equivalent quality, size, utility and location, with the

1


 

length of the Extension Term, the credit standing of Tenant and all other relevant factors to be taken into account.  Within thirty (30) days after receipt of the Extension Notice, Landlord shall deliver to Tenant written notice of its determination of the Extension Term Base Rent for the Extension Term.  Tenant shall, within thirty (30) days after receipt of such notice, notify Landlord in writing whether Tenant accepts or rejects Landlord’s determination of the Extension Term Base Rent (“Tenants Response Notice”).  If Tenant fails timely to deliver Tenant’s Response Notice, Landlord’s determination of the Extension Term Base Rent shall be binding on Tenant.

(c)If and only if Tenant’s Response Notice is timely addressed to Landlord and indicates both that Tenant rejects Landlord’s determination of the Extension Term Base Rent and desires to submit the matter to arbitration, then the Extension Term Base Rent shall be determined in accordance with the procedure set forth in this Section 1.2(c).  In such event, within ten (10) days after receipt by Landlord of Tenant’s Response Notice indicating Tenant’s desire to submit the determination of the Extension Term Base Rent to arbitration, Tenant and Landlord shall each notify the other, in writing, of their respective selections of an appraiser (respectively, “Landlord’s Appraiser” and “Tenant’s Appraiser”).  Landlord’s Appraiser and Tenant’s Appraiser shall then jointly select a third appraiser (the “Third Appraiser”) within ten (10) days of their appointment.  All of the appraisers selected shall be individuals with at least five (5) consecutive years’ commercial appraisal experience in the area in which the Premises are located, shall be members of the Appraisal Institute (M.A.I.), and, in the case of the Third Appraiser, shall not have acted in any capacity for either Landlord or Tenant within five (5) years of his or her selection.  The three appraisers shall determine the Extension Term Base Rent in accordance with the requirements and criteria set forth in Section 1.2(b) above, employing the method commonly known as Baseball Arbitration, whereby Landlord’s Appraiser and Tenant’s Appraiser each sets forth its determination of the Extension Term Base Rent as defined above, and the Third Appraiser must select one or the other (it being understood that the Third Appraiser shall be expressly prohibited from selecting a compromise figure). Landlord’s Appraiser and Tenant’s Appraiser shall deliver their determinations of the Extension Term Base Rent to the Third Appraiser within five (5) days of the appointment of the Third Appraiser and the Third Appraiser shall render his or her decision within ten (10) days after receipt of both of the other two determinations of the Extension Term Base Rent.  The Third Appraiser’s decision shall be binding on both Landlord and Tenant.  Each party shall bear the cost of its own appraiser and the cost of the Third Appraiser shall be paid by the party whose determination is not selected. For any part of the Extension Term during which the Base Rent is in dispute or has otherwise not finally been determined, Tenant shall make payment of Base Rent at the rate equal to the final month of the original Term and the parties shall adjust for any overpayments or underpayments upon the final determination of Base Rent.  

1.3Appurtenant Rights.

(a)Common Areas.  Subject to the terms of this Lease and the Rules and Regulations (hereinafter defined), Tenant shall have, as appurtenant to the Premises, rights to use in common with others entitled thereto, without additional charge (unless otherwise expressly provided in this Lease, such as through Operating Costs), the following areas (such areas are hereinafter referred to as the “Common Areas”): (i) the common loading docks, hallways, lobby, and elevator of the Building serving the Premises, (ii) the common lavatories located on the floor(s) on which the Premises are located, (iii) common walkways and driveways necessary for access to the Building, (iv) the Parking Areas, and (v) other areas and facilities located in the Building, on

2


 

the Land, or elsewhere on the Campus designated by Landlord from time to time for the common use of tenants of the Building and other entitled thereto; and no other appurtenant rights or easements.  “Rules and Regulations” shall be defined as the rules and regulations promulgated by Landlord pursuant to, and subject to, the provisions of Section 18.1 of the Lease.  The three (3) loading docks, receiving area, and freight elevators shown on Exhibit 12, attached hereto and incorporated herein, are available for the use of the tenants in the Building and are part of the Common Areas.

(b)Parking.  During the Term, and any extension thereof, and commencing on the Commencement Date, Landlord shall, subject to the terms hereof, make available up to sixty (60) parking spaces for Tenant’s use free of charge (except that the costs of maintenance and repair of the parking areas shall, subject to the provisions of Section 5.2, be included in Operating Costs) in the Parking Areas serving the Building, of which up to five (5) parking spaces may be reserved spaces designated for use by Tenant.  The number of parking spaces in the parking areas reserved for Tenant, as modified pursuant to this Lease or as otherwise permitted by Landlord, are hereinafter referred to as the “Parking Spaces.”  Tenant shall have no right to hypothecate or encumber the Parking Spaces, and shall not sublet, assign, or otherwise transfer the Parking Spaces other than to employees of Tenant occupying the Premises or to a Successor (hereinafter defined), an Affiliated Entity (hereinafter defined), or a transferee pursuant to an approved Transfer under Section 13 of this Lease.  Subject to Landlord’s right to reserve parking for other tenants of the Building, said Parking Spaces will be on an unassigned, non-reserved basis, and shall be subject to such Rules and Regulations, as may be in effect for the use of the parking areas from time to time.  Reserved and handicap parking spaces must be honored.  Notwithstanding anything to the contrary contained herein, Landlord shall have the right during any period of time that Landlord is performing construction or maintenance work on the Campus, upon at least three (3) months’ prior written notice to Tenant, to temporarily relocate all or any portion of the Parking Spaces in to other portions of the Property and/or parking areas owned, controlled or leased by Landlord and located on Hayden Avenue in Lexington.  If Landlord elects to relocate Tenant’s Parking Spaces, Landlord (at its sole cost and expense) shall provide, for the duration of such temporary relocation, shuttle service to and from such temporary parking location.  In addition, Landlord may, at its election, implement valet parking in order to accommodate the parking needs of the Property from time to time.

(c)Rooftop Premises.  During the Term, and any extension thereof, Tenant shall have the non-exclusive license, at no additional cost, to use a portion of the rooftop of the Building designated by Landlord and in the location shown on Exhibit 1C (the “Rooftop Premises”) for the installation of a dedicated exhaust system for the Tenant’s vivarium installed by Landlord as part of the Tenant Improvement Work (any equipment installed within the Rooftop Premises, as the same may be modified, altered or replaced during the Term, is collectively referred to herein as “Tenant’s Rooftop Equipment”). Landlord shall have the right to relocate Tenant’s Rooftop Equipment, at Landlord’s sole cost and expense, if Landlord determines that Tenant’s Rooftop Equipment is interfering with that of any other occupant of the Building or with Landlord’s configuration of the roof or rooftop equipment, provided that such relocation will not materially interfere with Tenant’s use of such Tenant’s Rooftop Equipment. Landlord’s approval of alterations or modifications to such equipment shall not be unreasonably withheld, conditioned or delayed provided Tenant demonstrates to Landlord’s reasonable satisfaction that the proposed alterations or modifications (i) do not interfere with any base building equipment operated by

3


 

Landlord on the roof; (ii) will not affect the structural integrity of the Building or impact the roof or the roof membrane in any manner; (iii) shall be adequately screened so as to minimize the visibility of such equipment; and (iv) shall be adequately sound-proofed to meet all requirements of Legal Requirements and Landlord’s specified maximum decibel levels for equipment operations.  Tenant shall not install or operate Tenant’s Rooftop Equipment until Tenant has obtained and submitted to Landlord copies of all required governmental permits, licenses, and authorizations necessary for the installation and operation thereof.  In addition, Tenant shall comply with all reasonable construction rules and regulations promulgated by Landlord in connection with the installation, maintenance and operation of Tenant’s Rooftop Equipment.  Landlord shall have no obligation to provide any services including, without limitation, electric current or gas service, to the Rooftop Premises or to Tenant’s Rooftop Equipment.  Tenant shall be responsible for the cost of repairing and maintaining Tenant’s Rooftop Equipment and the cost of repairing any damage to the Building, or the cost of any necessary improvements to the Building, caused by or as a result of the installation, replacement and/or removal of Tenant’s Rooftop Equipment. In connection with any repairs and/or maintenance work by Landlord affecting the roof of the Building (“Roof Repairs”), Landlord may request the temporary removal or relocation of Tenant’s Rooftop Equipment. Upon such request, Tenant shall relocate and reinstall Tenant’s Rooftop Equipment in such alternate location indicated by Landlord and where its location will not interfere with Tenant’s use of such equipment, and Landlord shall pay for said relocation and reimburse Tenant for all other reasonable out-of-pocket costs and expenses incurred by Tenant in the course of such relocation and reinstallation. Additionally, Landlord shall be responsible for repairing any damage incurred with respect to Tenant’s Rooftop Equipment to the extent caused by any Roof Repairs and/or incidental to the equipment’s relocation.

(d)Cafeteria.  During the Term and any extension thereof, Tenant, its employees, contractors, and visitors shall have the right to use the Cafeterias at no additional cost (unless otherwise expressly provided in this Lease, such as through Operating Costs), as hereinafter defined, in common with others entitled thereto.  The “Cafeterias,” as the same may be relocated as hereinafter set forth, shall be defined as food services facilities which provide food to tenants and occupants of the Campus.  As of the Execution Date, one Cafeteria is located in Building 55 (the “Building 55 Cafeteria”), and a second Cafeteria is being constructed in Building 75 (the “Building 75 Cafeteria”), which, upon the completion of such Building 75 Cafeteria, will be available for use by Tenant, its employees, contractors, and visitors in the same manner as the Building 55 Cafeteria. Tenant hereby acknowledges that the Cafeterias may be relocated, from time to time, to other buildings located on the Campus.  A third-party provider is currently contemplated to operate the Cafeterias.  Any amounts paid by Landlord on account of the operation of the Cafeterias in excess of the net revenues derived from the operation of the Cafeterias shall be included in Operating Costs, as shall all of Landlord’s costs of cleaning, maintaining, and repairing the Cafeterias.  Card readers shall, at no cost to Tenant, be installed and maintained at appropriate access points to the Cafeterias and identification cards shall be issued to authorized users.

(e)Fitness Center.  During the Term and any extension thereof, Tenant, its employees and visitors shall have the right to use the Fitness Center, as hereinafter defined, in common with others entitled thereto at no additional cost (unless otherwise expressly provided in this Lease, such as through Operating Costs).  The “Fitness Center” shall be a work-out facility for the use of tenants and occupants of the Campus.  As of the Execution Date, the Fitness Center

4


 

is located in the Building.  Tenant acknowledges that the Fitness Center may be relocated, from time to time, to other buildings located on the Campus.  Card readers shall, at no cost to Tenant, be installed and maintained at appropriate access points to the Fitness Center and identification cards shall be issued to authorized users.  Users of the fitness center shall be required to execute such liability waivers as Landlord shall reasonably require.  Any amounts paid by Landlord on account of the operation of the Fitness Center in excess of any net revenues derived from the operation of the Fitness Center shall be included in Operating Costs, as shall all of Landlord’s costs of cleaning, maintaining, and repairing the Fitness Center.  If for any reason Landlord decides to cease operating a Fitness Center, then, within thirty (30) days after delivery of written notice from Landlord to Tenant of Landlord’s decision, then Tenant shall no longer have the right to use the Fitness Center.  

1.4Tenant’s Access.  From and after the Term Commencement Date and until the end of the Term and any extension thereof, Tenant shall have access to the Premises twenty-four (24) hours a day, seven (7) days a week, subject to Landlord’s reasonable Building security requirements, causes beyond Landlord’s reasonable control, Legal Requirements, the Rules and Regulations, the terms of this Lease, Force Majeure (hereinafter defined) and matters of record.

1.5No recording // Notice of Lease.  Neither party shall record this Lease.  Tenant shall not record a memorandum of this Lease and/or a notice of this Lease.  Notwithstanding the foregoing, if the Initial Term plus any Extension Term(s) exceed in the aggregate seven (7) years, Landlord agrees to join in the execution, in recordable form, of a statutory notice of lease and/or written declaration in which shall be stated the Term Commencement Date, the Rent Commencement Date, the number and length of the Extension Term(s) and the Expiration Date, which notice of lease may be recorded by Tenant with the Middlesex South Registry of Deeds and/or filed with the Middlesex South Registry District of the Land Court, as appropriate (alternatively and collectively, the “Registry”) at Tenant’s sole cost and expense.  If a notice of lease was previously recorded with the Registry, upon the expiration or earlier termination of this Lease, Landlord shall deliver to Tenant a notice of termination of Lease and Tenant shall promptly execute, acknowledge, and deliver the same (together with any other instrument(s) that may be necessary in order to record and/or file same with the Registry) to Landlord for Landlord’s execution and recordation with the Registry, which obligation shall survive the expiration or earlier termination of the Lease.

1.6Exclusions.  The following are expressly excluded from the Premises and reserved to Landlord:  all the perimeter walls of the Premises (except the inner surfaces thereof), the Common Areas, and any space in or adjacent to the Premises used for shafts, stacks, pipes, conduits, wires and appurtenant fixtures, fan rooms, ducts, electric or other utilities, sinks or other Building facilities, and the use of all of the foregoing, except as expressly permitted pursuant to Section 1.3(a) above.

1.7Acid Neutralization Tank.  

(a)There currently exists an acid neutralization tank (the “Acid Neutralization Tank”) that is located in the PH System Premises.  Tenant acknowledges and agrees that Tenant is leasing the Acid Neutralization Tank in its “AS IS,” “WHERE IS” condition and with all faults on the Execution Date, without representations or warranties, express or implied, in fact or by law,

5


 

of any kind, or recourse to Landlord.  Tenant shall have the exclusive right, throughout the Term of the Lease, as the same may be extended, to use the Acid Neutralization Tank in accordance with Legal Requirements.  Tenant shall obtain and maintain all governmental permits and approvals necessary for the operation and maintenance of the Acid Neutralization Tank.  Tenant shall be responsible for all costs, charges and expenses incurred from time to time in connection with or arising out of the operation, use, maintenance, repair and replacement of the Acid Neutralization Tank, including all clean-up costs relating to the Acid Neutralization Tank (collectively, “Tank Costs”), except, subject to Section 14.5, to the extent such costs are caused by the negligence or willful misconduct of any of the Landlord Parties (as hereinafter defined).

(b)Tenant shall be responsible for assuring that the maintenance, operation and repair of the Acid Neutralization Tank shall in no way damage any portion of the Building or Property.  To the maximum extent permitted by Law, the Acid Neutralization Tank and all appurtenances thereto shall be at the sole risk of Tenant, and Landlord shall have no liability to Tenant if the Acid Neutralization Tank or any appurtenant installations are damaged for any reason.  Except for Landlord’s negligence or willful misconduct, Tenant agrees to be responsible for any damage caused to the Building or Property in connection with the maintenance, operation or removal of the Acid Neutralization Tank.  Except (subject to Section 14.5) with respect to Claims, to the extent caused by the negligence or willful misconduct of Landlord or any Landlord Parties, Tenant shall indemnify, save, defend (at Landlord’s option and with counsel reasonably acceptable to Landlord) and hold the Landlord Parties, as hereinafter defined, harmless from and against any and all Claims (as hereinafter defined), including (i) diminution in value of the Premises or any portion thereof, (ii) damages for the loss of or restriction on use of rentable or usable space of the Premises, (iii) damages arising from any adverse impact on marketing of space in the Premises or any portion thereof, and (iv) sums paid in settlement of Claims that arise during or after the Term, subject to the applicable statute of limitations, as a result of Tenant’s improper use of the Acid Neutralization Tank in violation of applicable Legal Requirements.  This indemnification by Tenant includes costs actually incurred by Landlord: (1) in connection with any investigation required by any Governmental Authority of site conditions, (2) in connection with any investigation required by Landlord pursuant to which it is determined that Tenant has breach its obligations with respect to the Acid Neutralization Tank, and (3) any clean-up, remediation, and/or removal of any Hazardous Materials and/or restoration of the Property required by any Governmental Authority caused by Tenant’s improper use of the Acid Neutralization Tank.  

(c)At the expiration or earlier termination of the Term, Tenant shall decommission the Acid Neutralization Tank in accordance with applicable Legal Requirements and shall provide any associated documentation of decommissioning to Landlord upon request therefor.  

(d)Landlord shall have no obligation to provide any services, including, without limitation, electric current, to Tenant’s Acid Neutralization Tank.

6


 

2.

RIGHTS RESERVED TO LANDLORD

2.1Additions and Alterations.  Landlord reserves the right, at any time and from time to time, to make such changes, alterations, additions, improvements, repairs or replacements in or to the Property (including the Premises but, with respect to the Premises, only for purposes of repairs, maintenance, replacements and the exercise of any other rights expressly reserved to Landlord herein, provided that Landlord shall give Tenant at least five (5) business days’ prior notice thereof) and the fixtures and equipment therein, as well as in or to the street entrances and/or the Common Areas, as it may deem necessary or desirable, provided, however, that there be no material obstruction of permanent access to, or material interference with the use and enjoyment of, the Premises by Tenant. Subject to the foregoing, Landlord expressly reserves the right to temporarily close all, or any portion, of the Common Areas for the purpose of making repairs or changes thereto.

2.2Additions to the Property.  

(a)Landlord may at any time or from time to time (i) construct additional building(s) and improvements and related site improvements (collectively, “Future Development”) in all or any part of the Property and/or (ii) change the location or arrangement of any improvement outside the Building in or on the Property or all or any part of the Common Areas, or add or deduct any land to or from the Property; provided that there shall be no material increase in Tenant’s obligations or material interference with Tenant’s rights under this Lease in connection with the exercise of the foregoing reserved rights and any such construction or changes shall be subject to Tenant’s rights under Section 23 of this Lease.

(b)In case any excavation shall be made for building or improvements or for any other purpose upon the land adjacent to or near the Premises, Tenant will afford without charge to Landlord, or the person or persons, firms or corporations causing or making such excavation (provided that Landlord shall give Tenant at least five (5) business days’ prior notice thereof), license to enter upon the Premises for the purpose of doing such work as Landlord or such person or persons, firms or corporation shall deem to be necessary to preserve the walls or structures of the Building from injury, and to protect the Building by proper securing of foundations.

(c)Tenant acknowledges and agrees that this Lease is subject and subordinate to (i) The Hayden Science Center Condominium (the “Condominium”), which was established by Master Deed dated December 1, 2017, recorded in Book 70325, Page 108, in the Middlesex South District Registry of Deeds and filed as Document No. 195793 in the Middlesex South Registry District of the Land Court, (ii) the Condominium Floor Plans and Site Plans dated December 1, 2017, and filed with the Middlesex Registry of Deeds, Southern District, as Plan No. 1090, Pages 1 through 13, and (iii) the Declaration of Trust of The Hayden Science Center Condominium Trust dated December 1, 2017, recorded in Book 70325, Page 148, in the Middlesex South District Registry of Deeds and filed as Document No. 195794 in the Middlesex South Registry District of the Land Court (the Master Deed, Declaration of Trust, and the Plans are being referred to herein as the “Condominium Documents”).  Tenant agrees that the Condominium Documents may be amended and that this Lease shall remain subject to and subordinate to the Condominium Documents, as so amended, so long as such amendments do not materially adversely affect Tenant’s rights or obligations under this Lease and subject to Tenant’s right to quiet enjoyment set forth in Section 23 of this Lease.  

7


 

(d)Landlord and Tenant each hereby acknowledges and agrees that, in connection with any Future Development, (i) Landlord shall have the right to enter into, and subject the Property to the terms and conditions of, a commercially reasonable reciprocal easement agreement with any one or more of the neighboring property owners in order to create a commercial campus-like setting (“REA”); (ii) upon Landlord’s request in connection with the recording of the REA, Tenant shall execute a commercially reasonable instrument in recordable form making this Lease subject and subordinate to the REA; (iii) Landlord shall have the right to subdivide the Property so long as Tenant continues to have all of the rights and obligations contained in this Lease (e.g., the appurtenant right to use all Common Areas); and (iv) Tenant shall execute such reasonable documents (which may be in recordable form) evidencing the foregoing promptly upon Landlord’s request.

2.3Name and Address of Building.  Landlord reserves the right at any time and from time to time to change the name or address of the Building and/or the Property, provided Landlord gives Tenant at least three (3) months’ prior written notice thereof.

2.4Landlord’s Access.  

(a)Subject to the terms hereof, Tenant shall (a) upon not less than forty-eight (48) hours’ advance notice, which may be oral (except that no notice shall be required in emergency situations), permit Landlord and any holder of a Mortgage (hereinafter defined) (each such holder, a “Mortgagee”), and the agents, representatives, employees and contractors of each of them, each of whom must be at all times accompanied by a designated representative of Tenant while in the Premises (provided that Tenant shall make a designated representative available at all reasonable times for the purposes of accompanying Landlord and its designees), to have reasonable access to the Premises at all reasonable hours for the purposes of inspection, making repairs, replacements or improvements in or to the Premises or the Building or equipment therein (including, without limitation, sanitary, electrical, heating, air conditioning or other systems), complying with all applicable laws, ordinances, rules, regulations, statutes, by-laws, court decisions and orders and requirements of all public authorities (collectively, “Legal Requirements”), or exercising any right reserved to Landlord under this Lease (including without limitation the right to take upon or through, or to keep and store within the Premises all necessary materials, tools and equipment); (b) permit Landlord and its agents and employees, at reasonable times, upon reasonable advance notice, to show the Premises during normal business hours (i.e. Monday – Friday 7 A.M. - 6 P.M., Saturday 7 A.M. – 12 P.M., excluding holidays) to any prospective Mortgagee or purchaser of the Building and/or the Property or of the interest of Landlord therein, and, during the last twelve (12) months of the Term or at any time after the occurrence of an Event of Default, prospective tenants; and (c) upon reasonable prior written notice from Landlord, permit Landlord and its agents, at Landlord’s sole cost and expense, to perform environmental audits, environmental site investigations and environmental site assessments (“Site Assessments”) in, on, under and at the Premises and the Land, it being understood that Landlord shall repair any damage arising as a result of the Site Assessments, and such Site Assessments may include both above and below the ground testing and such other tests as may be necessary or appropriate to conduct the Site Assessments.  In addition, to the extent that it is necessary to enter the Premises in order to access any area that serves any portion of the Building outside the Premises, then Tenant shall, upon as much advance notice as is practical under the circumstances, and in any event at least twenty-four (24) hours’ prior written notice (except that no notice shall

8


 

be required in emergency situations), permit contractors engaged by other occupants of the Building to pass through the Premises in order to access such areas but only if accompanied by a representative of Landlord.  The parties agree and acknowledge that, despite commercially reasonable and customary precautions (which Landlord agrees it shall exercise), any property or equipment in the Premises of a delicate, fragile or vulnerable nature may nevertheless be damaged in the course of performing Landlord’s obligations.  Landlord and Tenant shall take commercially reasonable protective precautions with unusually fragile, vulnerable or sensitive property and equipment.  Nonetheless, in the event any of Tenant’s equipment is damaged Landlord shall, subject to Section 14.5, repair and/or replace same.

(b)Secure Areas within the Premises.  Notwithstanding the foregoing, Tenant, at its own expense may, as hereinafter set forth, designate one or more areas of the Premises to be “Secure Areas” (i.e., portions of the Premises to which Landlord shall not have a right of entry or access for any reason whatsoever (except as otherwise provided below).  Tenant may, from time to time, exercise its right to create Secure Areas by delivering to Landlord, for Landlord’s written approval, which shall not be unreasonably withheld, conditioned or delayed, a plan showing the location of any such Secure Areas.  If Landlord must gain access to a Secure Areas in a non-emergency situation, Landlord shall contact Tenant, and Landlord and Tenant shall arrange a mutually agreed upon time for Landlord to have such access.  Landlord shall be accompanied by an employee of Tenant or a party designated by Tenant (the “Escort”).  Tenant shall make an Escort available to Landlord during mutually agreed upon times within a reasonable period of time after request.  At all times, Landlord shall comply with all reasonable security measures of the Tenant pertaining to the Secure Areas.  If an emergency representing an imminent risk of injury to persons or material property damage in the Building or the Premises, including, without limitation, a suspected fire or flood, requires Landlord to gain access to the Secure Areas, Landlord may enter the Secure Areas without an Escort.  If practicable under the emergency circumstances, Landlord shall immediately notify (which may be oral notification) and request that Tenant make an Escort available to Landlord if time permits, and if Tenant shall not make an Escort available to accompany Landlord, then Tenant hereby authorizes Landlord to enter the Secure Areas with a master key, and to enter without an Escort.  In any such event, except (subject to Section 14.5 of this Lease) to the extent resulting from Landlord’s negligence or willful misconduct, Landlord shall have no liability whatsoever to Tenant, and Tenant shall pay all reasonable expenses incurred by Landlord in repairing or reconstructing any entrance, corridor, door or other portions of the Premises damaged as a result of a forcible entry by Landlord.  Landlord shall have no obligation to provide either janitorial service or cleaning in the Secure Areas unless Tenant shall make arrangements to have an Escort in the Secure Areas at the time such service or cleaning is provided to the remainder of the Premises.   

2.5Pipes, Ducts and Conduits.  Tenant shall permit Landlord to erect, use, maintain and relocate pipes, ducts and conduits in and through the Premises, provided the same do not materially reduce the floor area or materially adversely affect the appearance thereof.

2.6Minimize Interference.  Except in the event of an emergency, Landlord shall use commercially reasonable efforts to minimize any interference with Tenant’s business operations and use and occupancy of the Premises in connection with the exercise any of the foregoing rights under this Section 2.

9


 

3.

CONDITION OF PREMISES; CONSTRUCTION.

3.1Condition of Premises.  Tenant acknowledges and agrees that Tenant is leasing the Premises in their “AS IS,” “WHERE IS” condition and with all faults on the Execution Date, without representations or warranties, express or implied, in fact or by law, of any kind, and without recourse to Landlord, except that:  (i) Landlord represents to Tenant that, as of the Term Commencement Date, the Building has the systems and capacities set forth on Exhibit 5 and (ii) Landlord shall perform Landlord’s Work in accordance with the provisions of this Section 3 and Exhibit 4; provided, however, that Landlord and Tenant acknowledge and agree that the Vivarium Work (as hereinafter defined) will be performed by Landlord subsequent to the Term Commencement Date, as more particularly set forth in Section 3.2, below.  

3.2Landlord’s Work.

(a)Subject to Force Majeure, as defined in Section 25.16 and any Tenant Delay, as hereinafter defined, Landlord shall perform Landlord’s Work in order to prepare the Premises for Tenant’s use and occupancy in accordance with Exhibit 4 attached hereto.  Landlord shall use diligent efforts to substantially complete Landlord’s Work, excluding the Vivarium Work, by April 1, 2020 (the “Estimated Term Commencement Date”), and to substantially complete the Vivarium Work by May 1, 2020 (the “Estimated Vivarium Delivery Date”).  However, except to the extent that such failure constitutes a delay in the occurrence of the Term Commencement Date (as provided in the definition of the Term Commencement Date), and, except for Tenant’s remedies set forth in Section 3.2 hereof: (i) Tenant’s sole remedies shall be a delay in the Term Commencement Date, (ii) Tenant shall have no claim or rights against Landlord, and Landlord shall have no liability or obligation to Tenant in the event of delay in Landlord’s Work, and (iii) no delay in Landlord’s Work shall have any effect on the parties’ rights or obligations under this Lease.  Further, notwithstanding anything herein to the contrary, Tenant acknowledges that Landlord will be performing the Vivarium Work subsequent to the Term Commencement Date, and that so long as Landlord is using diligent efforts to complete the Vivarium Work in light of the circumstances (i.e., Tenant’s occupancy of the Premises), Tenant shall have no claim or rights against Landlord, and Landlord shall have no liability or obligation to Tenant in the event of delay in the Vivarium Work, and no delay in the Vivarium Work shall have any effect on the parties’ rights or obligations under this Lease.  

(b)Definitions.

(i)Tenant Delay” shall mean any act or omission by Tenant and/or Tenant’s agents, employees or contractors (collectively with Tenant, the “Tenant Parties”) which causes an actual delay in the performance of Landlord’s Work, including, without limitation, any Changes to the Plans or the scope of Landlord’s Work as shown on the Initial Plan (as such terms are hereinafter defined) that are requested by Tenant.  Notwithstanding the foregoing, except where a Tenant Delay arises from Tenant’s failure timely to act within on or before a date or time period expressly set forth in the Lease (in which event no Tenant Delay Notice shall be required): (x) in no event shall any act or omission be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (a) that a Tenant Delay is occurring, and (b) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (y) no period of time prior to the time that Tenant receives a Tenant Delay Notice

10


 

shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice. The term “Tenant Parties” shall not include any of the following, to the extent hired by Landlord: contractors, subcontractors, architects, space planners, interior designers, facility managers, and other consultants.

(ii)Substantially Complete” or “Substantial Completion,” when referring to Landlord’s Work shall mean that:  (1) Landlord’s Work is completed, other than minor work which does not materially affect Tenant’s use of, or access to, the Premises, (2) the Premises and those portions of the Common Areas of the Building which affect Tenant’s occupancy are in conformance with all applicable building codes, permits, laws and regulations, including without limitation, ADA, (3) all structural elements and subsystems of the Building, including but not limited to HVAC, mechanical, electrical, lighting, plumbing, and life safety systems, will be in good working condition and repair, (4) Landlord has delivered to Tenant a certificate of substantial completion from Landlord’s architect stating that Landlord’s Work is substantially complete, and (5) such evidence (the “Town Approval”) as is customarily provided by the Town of Lexington to evidence its acceptance of Landlord’s Work and Tenant’s right to lawfully occupy the Premises (e.g., sign-offs on the Building permit by all applicable Town of Lexington departments or a certificate of occupancy, which may be a temporary certificate of occupancy) has been provided by the Town of Lexington; provided, however, that Substantial Completion shall be deemed to have occurred for purposes of clause (5) if (x) such required sign-offs are completed with respect to Landlord’s Work but cannot be completed for the entire Premises due to Tenant’s failure to complete installation or work to be performed by Tenant (including furniture, wiring and cabling) in a manner that allows such required inspections to be completed and a temporary certificate of occupancy to be issued, or (y) approval of applicable governmental authorities required to permit legal occupancy of the Premises for the Permitted Uses cannot be obtained for the entire Premises due to Tenant’s failure to complete installation of installation or work to be performed by Tenant (including furniture, wiring and cabling) in a manner that allows such approval to be obtained.  No costs incurred by Landlord in satisfying the definition of Substantial Completion shall be included in Operating Costs.  Notwithstanding anything to the contrary herein contained, in the event that Landlord’s Work is delayed by reason of a Tenant Delay, then Landlord shall be deemed to have achieved Substantial Completion of Landlord’s Work on the date that Landlord would have achieved Substantial Completion of Landlord’s Work, but for such Tenant Delay.  

(iii)Punchlist.  Promptly following Substantial Completion of Landlord’s Work, Landlord shall provide Tenant with a punchlist prepared by Landlord’s architect (the “Punchlist”) incorporating those items jointly identified by Landlord and Tenant during their joint inspection of Landlord’s Work, of outstanding items (the “Punchlist Items”).  Promptly after Substantial Completion of Landlord’s Work, Landlord and Tenant shall jointly inspect the Premises.  Subject to Landlord’s Force Majeure and Tenant Delays, Landlord shall complete all Punchlist Items within thirty (30) days of the date of the Punchlist (other than seasonal items, such as landscaping, requiring a longer period), provided that Tenant reasonably cooperates in connection with the completion of such Punchlist Items.  

3.3Tenant’s Remedies in the Event of Delays in Term Commencement Date.  If the Term Commencement Date does not occur on or before the Outside Termination Date, as hereinafter defined, then Tenant shall have the right to terminate the Lease, which shall be exercisable by a written thirty-(30)-day termination notice given on or after the Outside

11


 

Termination Date but before the date that the Term Commencement Date occurs.  If the Term Commencement Date occurs on or before the thirtieth (30th) day after Landlord receives such termination notice, Tenant’s termination notice shall be deemed to be void and of no force or effect.   If the Term Commencement Date does not occur on or before such thirtieth (30th) day, this Lease shall terminate and shall be of no further force or effect, and, except for provisions of the Lease, which are intended to survive termination of the Lease (e.g., indemnification provisions), Landlord shall promptly refund to Tenant any Security Deposit paid by Tenant to Landlord and neither party shall have any further obligation to the other party.  In such event, Tenant shall not be responsible for the payment of or reimbursement to Landlord for any expense associated with the design, construction, the preparations of plans and drawings to engage in the permitting process with local authorities or delivery of the Premises.  For the purposes hereof, the “Outside Termination Date” shall be defined as October 1, 2020, provided however, that the Outside Termination Date shall be extended by the lesser of:  (x) ninety (90) days, or (y) the length of any delays in Landlord’s Work arising from Force Majeure.

4.

USE OF PREMISES

4.1Permitted Uses.  During the Term, Tenant shall use the Premises only for the Permitted Uses and for no other purposes.  Service and utility areas (whether or not a part of the Premises) shall be used only for the particular purpose for which they are designed.  Tenant shall keep the Premises equipped with appropriate safety appliances to the extent required by applicable laws or insurance requirements.

4.2Prohibited Uses.

(a)Notwithstanding any other provision of this Lease, Tenant shall not use the Premises or the Building, or any part thereof, or suffer or permit the use or occupancy of the Premises or the Building or any part thereof by any of the Tenant Parties (i) in a manner which would violate any of the covenants, agreements, terms, provisions and conditions of this Lease or otherwise applicable to or binding upon the Premises; (ii) for any unlawful purposes or in any unlawful manner; (iii) which, in the reasonable judgment of Landlord (taking into account the use of the Building as a combination laboratory, research and development and office building and the Permitted Uses) shall (a) impair the appearance or reputation of the Building; (b) impair, interfere with or otherwise diminish the quality of any of the Building services or the proper and economic heating, cleaning, ventilating, air conditioning or other servicing of the Building or Premises, or the use or occupancy of any of the Common Areas; (c) occasion discomfort, inconvenience or annoyance in any material respect (and Tenant shall not install or use any electrical or other equipment of any kind which, in the reasonable judgment of Landlord, will cause any such impairment, interference, discomfort, inconvenience, annoyance or injury), or cause any injury or damage to any occupants of the Premises or other tenants or occupants of the Building or their property; or (d) cause harmful air emissions, laboratory odors or noises or any unusual or other objectionable odors, noises or emissions to emanate from the Premises; (iv) in a manner which is inconsistent with the operation and/or maintenance of the Building as a first-class combination office, research, development and laboratory facility; (v) for any fermentation processes whatsoever; or (vi) in a manner which shall increase such insurance rates on the Building or on property located therein over that applicable when Tenant first took occupancy of the Premises hereunder.

12


 

(b)With respect to the use and occupancy of the Premises and the Common Areas, Tenant will not:  (i) place or maintain any signage (except as set forth in Section 12.2 below), trash, refuse or other articles in any vestibule or entry of the Premises, on the footwalks or corridors adjacent thereto or elsewhere on the exterior of the Premises, nor obstruct any driveway, corridor, footwalk, parking area, mall or any other Common Areas; (ii) permit undue accumulations of or burn garbage, trash, rubbish or other refuse within or without the Premises; (iii) permit the parking of vehicles so as to interfere with (x) the ability of others, entitled thereto, to park in the common parking areas, or (y) the use of any driveway, corridor, footwalk, parking area, or other Common Areas; (iv) receive or ship articles of any kind outside of those areas reasonably designated by Landlord; (v) conduct or permit to be conducted any auction, going out of business sale, bankruptcy sale (unless directed by court order), or other similar type sale in or connected with the Premises; (vi) use the name of Landlord, or any of Landlord’s affiliates in any publicity, promotion, trailer, press release, advertising, printed, or display materials without Landlord’s prior written consent; or (vii) except in connection with Alterations (hereinafter defined) approved by Landlord, cause or permit any hole to be drilled or made in any part of the Building.

4.3Transportation of Animals.  No animals, animal waste, food or supplies relating to the animals maintained from time to time in the animal storage areas of the Premises shall be transported within the Building except as provided in this Section 4.3.   All deliveries of animals or animal food or supplies to Tenant at the Building shall be made prior to 11:00 a.m.  No transportation of animals, animal waste, food or supplies within the Building shall occur between the hours of 11:00 a.m. and 1:00 p.m.  At all times that animals are transported within the Common Areas, they shall be transported in an appropriate cage or other container.  At no time shall any animals, animal waste, food or supplies relating to the animals be brought into, transported through, or delivered to the lobby of the Building or be transported within the Building in elevators other than the freight elevator.

4.4MWRA Permit.  Tenant shall establish and maintain with respect to its use of wastewater facilities exclusively serving the Leased Premises, an MWRA waste water discharge program administered by a licensed, qualified individual (which individual may be (i) a third party contractor/consultant approved by Landlord, which approval shall not be unreasonably withheld, conditioned or delayed, or (ii) an employee of Tenant or Tenant’s affiliate) in accordance with the requirements of the Massachusetts Water Resources Authority (“MWRA”) and any other applicable governmental authority.  Tenant shall be solely responsible for all costs incurred in connection with such MWRA waste water discharge, and Tenant shall provide Landlord with such documentation as Landlord may reasonably require evidencing Tenant’s compliance with the requirements of (a) the MWRA and any other applicable governmental authority with respect to such chemical safety program and (b) this Section.  Tenant shall obtain and maintain during the Term (i) any permit required by the MWRA (“MWRA Permit”) and (ii) a wastewater treatment operator license from the Commonwealth of Massachusetts with respect to Tenant’s use of any acid neutralization tank exclusively serving the Leased Premises in the Building.  Tenant shall not introduce anything into the acid neutralization tank serving the Premises, if any (x) in violation of the terms of the MWRA Permit, (y) in violation of Legal Requirements or (z) that would interfere with the proper functioning of any such acid neutralization tank.

13


 

4.5Parking and Traffic Demand Management Plan.  The Property is subject to a Parking and Traffic Demand Management Plan with the Town of Lexington (the “Initial PTDM”).  Tenant agrees to comply with the requirements of the Initial PTDM, only insofar as they apply to the Premises and/or Tenant’s use and occupancy thereof.  In the event that the Initial PTDM is ever modified, supplemented, amended or replaced (“PTDM Modifications”), Tenant agrees to comply with the requirements of the PTDM Modifications, only insofar as they apply to the Premises and/or Tenant’s use and occupancy thereof.  As of the date hereof, Landlord represents that, to Landlord’s knowledge, the Premises currently comply with the Initial PTDM.

4.6Vivarium.  Tenant shall be responsible, at its sole expense, for the operations of its vivarium in accordance with all Legal Requirements and with best industry practices.  Without limiting the general application of the foregoing, Tenant shall separately dispose of all waste products from the operation of Tenant’s vivarium, including, without limitation, dead animals, strictly in accordance with Legal Requirements.  Landlord shall have the right, from time to time by written notice to Tenant, to promulgate reasonable rules and regulations with respect to the operation of Tenant’s vivarium so as to minimize any adverse effects that such operation may have on other occupants of the Building, including without limitation, regulations as to noise mitigation.

5.

RENT; ADDITIONAL RENT

5.1Base Rent.  Commencing as of the Rent Commencement Date and continuing thereafter throughout the remainder of the Term, Tenant shall pay Base Rent to Landlord in equal monthly installments, in advance and without demand on the first day of each month for and with respect to such month.  Unless otherwise expressly provided herein, the payment of Base Rent, Additional Rent and other charges reserved and covenanted to be paid under this Lease with respect to the Premises (collectively, “Rent”) shall commence on the Rent Commencement Date and shall be prorated for any partial months.  Rent shall be payable to Landlord or, if Landlord shall so direct in writing, to Landlord’s agent or nominee, in lawful money of the United States which shall be legal tender for payment of all debts and dues, public and private, at the time of payment.  

5.2Operating Costs.

(a)Operating Costs” shall mean all costs incurred and expenditures of whatever nature made by Landlord in the operation, management, repair, replacement, maintenance and insurance (including, without limitation, environmental liability insurance and property insurance on Landlord-supplied leasehold improvements for tenants, but not property insurance on tenants’ equipment) of the Property or allocated to the Property, including without limitation all costs of labor (wages, salaries, fringe benefits, etc.) up to and including the Director of Property Management, any costs for utilities supplied to exterior areas and the Common Areas, and any costs for repair and replacements, cleaning and maintenance of exterior areas and the Common Areas, related equipment, facilities and appurtenances and HVAC equipment, security services, a management fee in the amount of four percent (4%) of gross Building revenues (increased, if applicable, in accordance with Section 5.2(f)), the costs, including, without limitation, a commercially reasonable rental factor, of Landlord’s management office for the Property, which management office may be located outside the Property and which may serve other properties in addition to the Property (in which event such costs shall be equitably allocated

14


 

among the properties served by such office), the cost of operating any amenities in the Property available to all tenants of the Property and any subsidy provided by Landlord for or with respect to any such amenity, and the Annual Charge-Off (as hereinafter defined) with respect to a Permitted Capital Expenditure (as hereinafter defined), and all costs of applying and reporting for the Building or any part thereof to seek or maintain certification under the U.S. EPA’s Energy Star® rating system, the U.S. Green Building Council’s Leadership in Energy and Environmental Design (LEED) rating system or a similar system or standard.  For costs and expenditures made by Landlord in connection with the operation, management, repair, replacement, maintenance and insurance of the Building as a whole, Landlord shall make a reasonable allocation thereof between the retail and non-retail portions of the Building, if applicable.  The allocation of Operating Costs relating to the Common Areas of the Campus shall be made in accordance with the Condominium Documents.  Operating Costs shall not include Excluded Costs (hereinafter defined).

(b)Capital Expenditures. Permitted Capital Expenditures (as hereinafter defined) shall only be included in Operating Costs for each fiscal year during the Term to the extent of the Annual Charge-Off, as hereinafter defined, for such fiscal year with respect to such capital expenditure.  Operating Costs shall not include any Annual Charge-Off with respect to Excluded Costs, as hereinafter defined.  For the purposes hereof:

(i)Annual Charge-Off” means the annual amount of principal and interest payments which would be required to repay a loan in equal monthly installments over the Useful Life, as defined below, of the capital item in question on a direct reduction basis at an annual interest rate equal to the Capital Interest Rate, as defined below, where the initial principal balance is the cost of the capital item in question.

(ii)Useful Life” shall be reasonably determined by Landlord in accordance with generally accepted accounting principles and practices in effect at the time of acquisition of the capital item.

(iii)Capital Interest Rate” shall be defined as an annual rate of either one percentage point over the AA bond rate (Standard & Poor’s corporate composite or, if unavailable, its equivalent) as reported in the financial press at the time the capital expenditure is made or, if the capital item is acquired through third-party financing, then the actual (including fluctuating) rate paid by Landlord in financing the acquisition of such capital item.

(c)Excluded Costs” shall be defined as (i) any fixed or percentage ground rent payable to any ground lessor, or any mortgage charges or other financing charges payable by Landlord (including but not limited to interest, principal, points and fees); (ii) brokerage commissions; (iii) salaries of executives and owners not directly employed in the management/operation of the Property; (iv) the cost of work done by Landlord for a particular tenant or prospective tenant; (v) the cost of items which, by generally accepted accounting principles, would be capitalized on the books of Landlord or are otherwise not properly chargeable against income, except to the extent such capital item is (A) required by any Legal Requirements, or (B) reasonably projected to reduce Operating Costs; (vi) the costs of Landlord’s Work and any contributions made by Landlord to any tenant of the Property in connection with the build-out of its premises; (vii) franchise or income taxes imposed on Landlord; (viii) costs paid directly by individual tenants to suppliers, including tenant electricity, telephone and other utility costs; (ix)

15


 

increases in premiums for insurance when such increase is caused by the use of the Building by Landlord or any other tenant of the Building; (x) depreciation of the Building; (xi) costs relating to maintaining Landlord’s existence as a corporation, partnership or other entity; (xii) advertising and other fees and costs incurred in procuring and negotiating leases with tenants; (xiii) the cost of any items for which Landlord is reimbursed by insurance, condemnation awards, refund, rebate or otherwise, and any expenses for repairs or maintenance to the extent covered by warranties, guaranties and service contracts; and (xiv) costs incurred in connection with any disputes between Landlord and its employees, between Landlord and Building management, or between Landlord and other tenants or occupants or contractors, (xv) Taxes, (xvi) costs associated with the operation of the Landlord entity, as distinguished from costs associated with the operation of the Building and Property, (xvii) costs associated with the sale or financing of the Building or Property, (xviii) the cost of remediating Hazardous Materials from the Building other than Included Hazardous Materials, as hereinafter defined; “Included Hazardous Materials” shall be defined as all Hazardous Materials, other than:  (A) any material or substance located in the Building or the Property on the Execution Date which, as of the Execution Date, is not considered under then existing Legal Requirements, to be Hazardous Material, but which is subsequently determined to be a Hazardous Material by reason of a Legal Requirement which first becomes effective after the Execution Date of this Lease, and (B) any material or substance that is introduced to the Building or the Property after the Execution Date which, when introduced to the Building or the Property, is not then (i.e., at the time of introduction to the Building or the Property) considered, as a matter of any Legal Requirement, to be a Hazardous Material, but which is subsequently determined to be a Hazardous Material by reason of Legal Requirements which first becomes effective after the date of introduction of such material or substance to the Building or Property, (xix) interest and penalties incurred as a result of Landlord’s late payment of Taxes or utility bills, (xx) fines and penalties incurred by Landlord in connection with any building code violation, to the extent the condition which gave rise to such building code violation existed prior to the Term Commencement Date, (xxi) costs incurred by Landlord in connection with a breach by Landlord or by another tenant of such tenant’s lease, (xxii) charitable contributions and donations, (xxiii) costs incurred by Landlord in connection with the enforcement of the obligations or liabilities of other tenants in the Building or Property, (xxiv) income taxes paid by Landlord, and (xxv) all other items for which another party compensates Landlord so that Landlord shall not recover for any item more than once.

(d)Payment of Operating Costs.  Commencing as of the Term Commencement Date and continuing thereafter throughout the remainder of the Term of the Lease, Tenant shall pay to Landlord, as Additional Rent, Tenant’s Share of Operating Costs.  Landlord may make a good faith estimate of Tenant’s Share of Operating Costs for any fiscal year or part thereof during the Term, and Tenant shall pay to Landlord, on the Rent Commencement Date and on the first (1st) day of each calendar month thereafter, an amount equal to Tenant’s Share of Operating Costs for such fiscal year and/or part thereof divided by the number of months therein.  Landlord may estimate and re-estimate Tenant’s Share of Operating Costs and deliver a copy of the estimate or re-estimate to Tenant.  Thereafter, the monthly installments of Tenant’s Share of Operating Costs shall be appropriately adjusted in accordance with the estimations so that, by the end of the fiscal year in question, Tenant shall have paid all of Tenant’s Share of Operating Costs as estimated by Landlord.  Any amounts paid based on such an estimate shall be subject to adjustment as herein provided when actual Operating Costs are available for each fiscal year.  As of the Execution Date, the Property’s fiscal year is January 1 – December 31.

16


 

(e)Annual Reconciliation.  Landlord shall, within one hundred twenty (120) days after the end of each fiscal year, deliver to Tenant a reasonably detailed statement of the actual amount of Operating Costs for such fiscal year (“Year End Statement”).  Failure of Landlord to provide the Year End Statement within the time prescribed shall not relieve Tenant from its obligations hereunder.  If the total of such monthly remittances on account of any fiscal year is greater than Tenant’s Share of Operating Costs actually incurred for such fiscal year, then, provided no Event of Default has occurred nor any event which, with the passage of time and/or the giving of notice would constitute an Event of Default, Tenant may credit the difference against the next installment of Additional Rent on account of Operating Costs due hereunder, except that if such difference is determined after the end of the Term, Landlord shall refund such difference to Tenant within thirty (30) days after such determination to the extent that such difference exceeds any amounts then due from Tenant to Landlord.  If the total of such remittances is less than Tenant’s Share of Operating Costs actually incurred for such fiscal year, Tenant shall pay the difference to Landlord, as Additional Rent hereunder, within thirty (30) days of Tenant’s receipt of an invoice therefor.  Landlord’s estimate of Operating Costs for the next fiscal year shall be based upon the Operating Costs actually incurred for the prior fiscal year as reflected in the Year-End Statement plus a reasonable adjustment based upon estimated increases in Operating Costs.  The provisions of this Section 5.2(d) shall survive the expiration or earlier termination of this Lease.

(f)Part Years.  If the Rent Commencement Date or the Expiration Date occurs in the middle of a calendar year, Tenant shall be liable for only that portion of the Operating Costs with respect to such calendar year within the Term.  

(g)Gross-Up.  If, during any fiscal year, less than 95% of the Building is occupied by tenants or if Landlord was not supplying all tenants with the services being supplied to Tenant hereunder, actual Operating Costs incurred shall be reasonably extrapolated by Landlord on an item-by-item basis to the reasonable Operating Costs that would have been incurred if the Building was 95% occupied and such services were being supplied to all tenants, and such extrapolated Operating Costs shall, for all purposes hereof, be deemed to be the Operating Costs for such fiscal year.  This “gross up” treatment shall be applied only with respect to variable Operating Costs arising from services provided to Common Areas or to space in the Building being occupied by tenants (which services are not provided to vacant space or may be provided only to some tenants) in order to allocate equitably such variable Operating Costs to the tenants receiving the benefits thereof.

(h)Audit Right.  The Year End Statement shall be final and binding upon Tenant unless Tenant, within ninety (90) days after Tenant’s receipt thereof, shall contest any item therein by giving written notice to Landlord, specifying each item contested and the reason therefor. Upon the timely delivery of such written notice by Tenant, and provided there is no Event of Default nor any event which, with the passage of time and/or the giving of notice would constitute an Event of Default, Landlord will provide Tenant with access to Landlord’s books and records relating to Landlord’s calculation of Operating Costs for any periods of time within the previous fiscal year before the audit or inspection. However, no audit or inspection shall extend to periods of time before the Rent Commencement Date.  If Tenant fails to object to the calculation of Tenant’s Share of Operating Costs on the Year-End Statement within ninety (90) days after such statement has been delivered to Tenant and/or fails to complete any such audit or inspection within ninety (90) days after receipt of the Year End Statement, then Tenant shall be deemed to

17


 

have waived its right to object to the calculation of Tenant’s Share of Operating Costs for the year in question and the calculation thereof as set forth on such statement shall be final.  Tenant’s audit or inspection shall be conducted only at Landlord’s offices or the offices of Landlord’s property manager during business hours reasonably designated by Landlord.  Tenant shall pay the cost of such audit or inspection.  Tenant may not conduct an inspection or have an audit performed more than once during any fiscal year.  If such inspection or audit reveals an underpayment by Tenant, then Tenant shall pay to Landlord, as Additional Rent hereunder, any underpayment of any such costs, as the case may be, within thirty (30) days after receipt of an invoice therefor. If such inspection and audit reveal that Landlord has overstated Operating Costs, then Landlord shall credit the discrepancy to Tenant against Tenant’s next payment(s) of the applicable Additional Rent.  In the event such inspection and audit reveal that Landlord has overstated Operating Costs by more than five (5) percent, then, in addition to a credit or refund to Tenant of the amount overcharged, Landlord shall reimburse Tenant for the reasonable out-of-pocket cost of said audit.  In the event the Landlord disagrees in good faith with the results of the audit, Landlord shall notify Tenant within fifteen (15) days of the audit, and Landlord and Tenant shall mutually select a neutral third party to evaluate the charges for Tenant’s Share of Operating Costs, and the results of such third party’s evaluation shall bind Landlord and Tenant and shall be final. Costs charged by any such third party shall be shared equally by Landlord and Tenant.  Tenant shall maintain the results of any such audit or inspection confidential and shall not be permitted to use any third party to perform such audit or inspection, other than an independent firm of certified public accountants (A) reasonably acceptable to Landlord, (B) which is not compensated on a contingency fee basis or in any other manner which is dependent upon the results of such audit or inspection, and (C) which executes Landlord’s standard confidentiality agreement whereby it shall agree to maintain the results of such audit or inspection confidential.  The provisions of this Section 5.2(h) shall survive the expiration or earlier termination of this Lease.

5.3Taxes.

(a)Taxes” shall mean the real estate taxes and other taxes, levies and assessments imposed upon the Unit of the Condominium in which the Building and the Land are located (the “Unit”) and upon any personal property of Landlord used in the operation thereof, or on Landlord’s interest therein or such personal property; charges, fees and assessments for transit, housing, police, fire or other services or purported benefits to the Building and the Land (including without limitation any community preservation assessments); service or user payments in lieu of taxes; and any and all other taxes, levies, betterments, assessments and charges arising from the ownership, leasing, operation, use or occupancy of the Building and the Land or based upon rentals derived therefrom, which are or shall be imposed by federal, state, county, municipal or other governmental authorities.  Taxes shall not include any inheritance, estate, succession, gift, franchise, rental, income or profit tax, capital stock tax, capital levy or excise, or any income taxes arising out of or related to the ownership and operation of the Unit, provided, however, that any of the same and any other tax, excise, fee, levy, charge or assessment, however described, that may in the future be levied or assessed as a substitute for or an addition to, in whole or in part, any tax, levy or assessment which would otherwise constitute Taxes, whether or not now customary or in the contemplation of the parties on the Execution Date of this Lease, shall constitute Taxes, but only to the extent calculated as if the Unit were the only real estate owned by Landlord.  “Taxes” shall also include reasonable expenses (including without limitation legal and consultant fees) of tax abatement or other proceedings contesting assessments or levies.

18


 

Landlord shall allocate Taxes which are incurred with respect to the Common Areas of the Campus on a reasonable basis.  From and after substantial completion of any occupiable improvements constructed as part of a Future Development, if such improvements are not separately assessed, Landlord shall reasonably allocate Taxes between the Building and such improvements and the land area associated with the same.  From and after the creation of the Condominium for the Campus, such allocation shall be effected based upon the Taxes payable by Landlord with respect to the unit in the Condominium in which the Property is located.

(b)Tax Period” shall be any fiscal/tax period in respect of which Taxes are due and payable to the appropriate governmental taxing authority (i.e., as mandated by the governmental taxing authority), any portion of which period occurs during the Term of this Lease.

(c)Payment of Taxes.  Commencing as of the Term Commencement Date and continuing thereafter throughout the remainder of the Term of the Lease, Tenant shall pay to Landlord, as Additional Rent, Tenant’s Share of Taxes.  Landlord may make a good faith estimate of the Taxes to be due by Tenant for any Tax Period or part thereof during the Term, and Tenant shall pay to Landlord, on the Rent Commencement Date and on the first (1st) day of each calendar month thereafter, an amount equal to Tenant’s Share of Taxes for such Tax Period or part thereof divided by the number of months therein. Landlord may estimate and re-estimate Tenant’s Share of Taxes and deliver a copy of the estimate or re-estimate to Tenant.  Thereafter, the monthly installments of Tenant’s Share of Taxes shall be appropriately adjusted in accordance with the estimations so that, by the end of the Tax Period in question, Tenant shall have paid all of Tenant’s Share of Taxes as estimated by Landlord.  Any amounts paid based on such an estimate shall be subject to adjustment as herein provided when actual Taxes are available for each Tax Period.  If the total of such monthly remittances is greater than Tenant’s Share of Taxes actually due for such Tax Period, then, provided no Event of Default has occurred nor any event which, with the passage of time and/or the giving of notice would constitute an Event of Default, Tenant may credit the difference against the next installment of Additional Rent on account of Taxes due hereunder, except that if such difference is determined after the end of the Term, Landlord shall refund such difference to Tenant within thirty (30) days after such determination to the extent that such difference exceeds any amounts then due from Tenant to Landlord.  If the total of such remittances is less than Tenant’s Share of Taxes actually due for such Tax Period, Tenant shall pay the difference to Landlord, as Additional Rent hereunder, within thirty (30) days of Tenant’s receipt of an invoice therefor.  Landlord’s estimate for the next Tax Period shall be based upon actual Taxes for the prior Tax Period plus a reasonable adjustment based upon estimated increases in Taxes.  The provisions of this Section 5.3(c) shall survive the expiration or earlier termination of this Lease.

(d)Effect of Abatements.  Appropriate credit against Taxes shall be given for any refund obtained by reason of a reduction in any Taxes by the assessors or the administrative, judicial or other governmental agency responsible therefor after deduction of Landlord’s expenditures for reasonable legal fees and for other reasonable expenses incurred in obtaining the Tax refund.

(e)Part Years.  If the Rent Commencement Date or the Expiration Date occurs in the middle of a Tax Period, Tenant shall be liable for only that portion of the Taxes, as the case may be, with respect to such Tax Period within the Term.  

19


 

5.4Late Payments.

(a)Any payment of Rent due hereunder not paid when due shall bear interest for each month or fraction thereof from the due date until paid in full at the annual rate of twelve percent (12%), or at any applicable lesser maximum legally permissible rate for debts of this nature (the “Default Rate”).

(b)Additionally, if Tenant fails to make any payment within five (5) days after the due date therefor, Landlord may charge Tenant a fee, which shall constitute liquidated damages, equal to three (3%) of any such late payment.  Notwithstanding anything to the contrary in Section 5.4(a) and (b), the first late payment of Rent due in any twelve (12) month period shall not accrue interest at the Default Rate or liquidated damages so long as such payment is made within ten (10) days of notice from Landlord.

(c)For each Tenant payment check to Landlord that is returned by a bank for any reason, Tenant shall pay a returned check charge equal to the amount as shall be customarily charged by Landlord’s bank at the time.

(d)Money paid by Tenant to Landlord shall be applied to Tenant’s account in the following order: first, to any unpaid Additional Rent, including without limitation late charges, returned check charges, legal fees and/or court costs chargeable to Tenant hereunder; and then to unpaid Base Rent.

(e)The parties agree that the late charge referenced in Section 5.4(b) represents a fair and reasonable estimate of the costs that Landlord will incur by reason of any late payment by Tenant, and the payment of late charges and interest are distinct and separate in that the payment of interest is to compensate Landlord for the use of Landlord’s money by Tenant, while the payment of late charges is to compensate Landlord for Landlord’s processing, administrative and other costs incurred by Landlord as a result of Tenant’s delinquent payments.  Acceptance of a late charge or interest shall not constitute a waiver of Tenant’s default with respect to the overdue amount or prevent Landlord from exercising any of the other rights and remedies available to Landlord under this Lease or at law or in equity now or hereafter in effect.

(f)If Tenant during any six (6) month period shall be more than five (5) days delinquent in the payment of any installment of Rent on three (3) or more occasions, then, notwithstanding anything herein to the contrary, Landlord may, by written notice to Tenant, elect to require Tenant to pay all Base Rent and Additional Rent on account of Operating Costs and Taxes quarterly in advance.  Such right shall be in addition to and not in lieu of any other right or remedy available to Landlord hereunder or at law on account of Tenant’s default hereunder.

5.5No Offset; Independent Covenants; Waiver.  Rent shall be paid without notice or demand, and without setoff, counterclaim, defense, abatement, suspension, deferment, reduction or deduction, except as expressly provided herein.  TENANT WAIVES ALL RIGHTS (I) TO ANY ABATEMENT, SUSPENSION, DEFERMENT, REDUCTION OR DEDUCTION OF OR FROM RENT, AND (II) TO QUIT, TERMINATE OR SURRENDER THIS LEASE OR THE PREMISES OR ANY PART THEREOF, EXCEPT AS EXPRESSLY PROVIDED HEREIN.  TENANT HEREBY ACKNOWLEDGES AND

20


 

AGREES THAT THE OBLIGATIONS OF TENANT HEREUNDER SHALL BE SEPARATE AND INDEPENDENT COVENANTS AND AGREEMENTS, THAT RENT SHALL CONTINUE TO BE PAYABLE IN ALL EVENTS AND THAT THE OBLIGATIONS OF TENANT HEREUNDER SHALL CONTINUE UNAFFECTED, UNLESS THE REQUIREMENT TO PAY OR PERFORM THE SAME SHALL HAVE BEEN TERMINATED PURSUANT TO AN EXPRESS PROVISION OF THIS LEASE.  LANDLORD AND TENANT EACH ACKNOWLEDGES AND AGREES THAT THE INDEPENDENT NATURE OF THE OBLIGATIONS OF TENANT HEREUNDER REPRESENTS FAIR, REASONABLE, AND ACCEPTED COMMERCIAL PRACTICE WITH RESPECT TO THE TYPE OF PROPERTY SUBJECT TO THIS LEASE, AND THAT THIS AGREEMENT IS THE PRODUCT OF FREE AND INFORMED NEGOTIATION DURING WHICH BOTH LANDLORD AND TENANT WERE REPRESENTED BY COUNSEL SKILLED IN NEGOTIATING AND DRAFTING COMMERCIAL LEASES IN MASSACHUSETTS, AND THAT THE ACKNOWLEDGEMENTS AND AGREEMENTS CONTAINED HEREIN ARE MADE WITH FULL KNOWLEDGE OF THE HOLDING IN WESSON V. LEONE ENTERPRISES, INC., 437 MASS. 708 (2002).  SUCH ACKNOWLEDGEMENTS, AGREEMENTS AND WAIVERS BY TENANT ARE A MATERIAL INDUCEMENT TO LANDLORD ENTERING INTO THIS LEASE.  

5.6Survival.  Any obligations under this Section 5 which shall not have been paid at the expiration or earlier termination of the Term shall survive such expiration or earlier termination and shall be paid when and as the amount of same shall be determined and be due, subject to any applicable statute of limitations.

6.

Intentionally Omitted.

7.

LETTER OF CREDIT

7.1Amount.  Contemporaneously with the execution of this Lease, Tenant shall deliver to Landlord either (i) cash in the amount specified in the Lease Summary Sheet (the “Cash Security Deposit”), which shall be held by Landlord in accordance with Section 7.5 below, or (ii) an irrevocable letter of credit (the “Letter of Credit”) that shall (a) be in the initial amount of $622,421.90; (b) be issued on the form attached hereto as Exhibit 6; (c) name Landlord as its beneficiary; (d) be drawn on an FDIC insured financial institution reasonably satisfactory to Landlord that both (x) has an office in the greater Boston metropolitan area that will accept presentation of, and pay against, the Letter of Credit and (y) satisfies both the Minimum Rating Agency Threshold and the Minimum Capital Threshold (as those terms are defined below).  The “Minimum Rating Agency Threshold” shall mean that the issuing bank has outstanding unsecured, uninsured and unguaranteed senior long-term indebtedness that is then rated (without regard to qualification of such rating by symbols such as “+” or “-” or numerical notation) “Baa” or better by Moody’s Investors Service, Inc. and/or “BBB” or better by Standard & Poor’s Rating Services, or a comparable rating by a comparable national rating agency designated by Landlord in its discretion.  The “Minimum Capital Threshold” shall mean that the issuing bank has combined capital, surplus and undivided profits of not less than $10,000,000,000.  The Letter of Credit (and any renewals or replacements thereof) shall be for a term of not less than one (1) year.  If the issuer of the Letter of Credit gives notice of its election not to renew such Letter of Credit

21


 

for any additional period, Tenant shall be required to deliver a substitute Letter of Credit satisfying the conditions hereof at least thirty (30) days prior to the expiration of the term of such Letter of Credit.  If the issuer of the Letter of Credit fails to satisfy either or both of the Minimum Rating Agency Threshold or the Minimum Capital Threshold, Tenant shall be required to deliver a substitute letter of credit from another issuer reasonably satisfactory to the Landlord and that satisfies both the Minimum Rating Agency Threshold and the Minimum Capital Threshold not later than ten (10) business days after Landlord notifies Tenant of such failure.  Tenant agrees that it shall from time to time, as necessary, whether as a result of a draw on the Letter of Credit by Landlord pursuant to the terms hereof or as a result of the expiration of the Letter of Credit then in effect, renew or replace the original and any subsequent Letter of Credit so that a Letter of Credit, in the amount required hereunder, is in effect until a date which is at least ninety (90) days after the Expiration Date.  If Tenant fails to furnish such renewal or replacement at least sixty (60) days prior to the stated expiration date of the Letter of Credit then held by Landlord, Landlord may draw upon such Letter of Credit and hold the proceeds thereof (and such proceeds need not be segregated) as a Security Deposit pursuant to the terms of this Article 7 until such time as a renewal or replacement Letter of Credit is furnished.  Any renewal or replacement of the original or any subsequent Letter of Credit shall meet the requirements for the original Letter of Credit as set forth above, except that such replacement or renewal shall be issued by a national bank reasonably satisfactory to Landlord at the time of the issuance thereof.

7.2Application of Proceeds of Letter of Credit.  Upon an Event of Default, or if any proceeding shall be instituted by or against Tenant pursuant to any of the provisions of any Act of Congress or State law relating to bankruptcy, reorganizations, arrangements, compositions or other relief from creditors (and, in the case of any proceeding instituted against it, if Tenant shall fail to have such proceedings dismissed within thirty (30) days) or if Tenant is adjudged bankrupt or insolvent as a result of any such proceeding, Landlord at its sole option may draw down all or a part of the Letter of Credit.  The balance of any Letter of Credit cash proceeds shall be held in accordance with Section 7.5 below.  Should the entire Letter of Credit, or any portion thereof, be drawn down by Landlord, Tenant shall, upon the written demand of Landlord, deliver a replacement Letter of Credit in the amount drawn, and Tenant’s failure to do so within ten (10) days after receipt of such written demand shall constitute an additional Event of Default hereunder.  The application of all or any part of the cash proceeds of the Letter of Credit to any obligation or default of Tenant under this Lease shall not deprive Landlord of any other rights or remedies Landlord may have nor shall such application by Landlord constitute a waiver by Landlord.

7.3Transfer of Letter of Credit.  In the event that Landlord transfers its interest in the Premises, Tenant shall upon notice from and at no cost to Landlord, deliver to Landlord an amendment to the Letter of Credit or a replacement Letter of Credit naming Landlord’s successor as the beneficiary thereof. If Tenant fails to deliver such amendment or replacement within ten (10) days after written notice from Landlord, Landlord shall have the right to draw down the entire amount of the Letter of Credit and hold the proceeds thereof in accordance with Section 7.5 below.

7.4Cash Proceeds of Letter of Credit.  Landlord shall hold the balance of proceeds remaining after a draw on the Letter of Credit (each hereinafter referred to as the “Security Deposit”) as security for Tenant’s performance of all its Lease obligations.  After an Event of Default, Landlord may apply the Security Deposit, or any part thereof, to Landlord’s damages without prejudice to any other Landlord remedy.  Landlord has no obligation to pay interest on the

22


 

Security Deposit and may co-mingle the Security Deposit with Landlord’s funds.  If Landlord conveys its interest under this Lease, the Security Deposit, or any part not applied previously, may be turned over to the grantee in which case Tenant shall look solely to the grantee for the proper application and return of the Security Deposit.

7.5Return of Security Deposit or Letter of Credit.  Should Tenant comply with all of such terms, covenants and conditions and promptly pay all sums payable by Tenant to Landlord hereunder, the Security Deposit and/or Letter of Credit or the remaining proceeds therefrom, as applicable, shall (less any portion thereof which may have been utilized by Landlord to cure any default or applied to any actual damage suffered by Landlord) be returned to Tenant within ninety (90) days after the end of the Term.

8.

Intentionally Deleted.  

9.

UTILITIES, LANDLORD’S SERVICES

9.1Electricity.  Landlord shall contract with the utility provider for electric service to the Property, including the Premises.  Commencing on the Term Commencement Date, Tenant shall pay all charges for electricity furnished to the Premises and any equipment exclusively serving the Premises, as Additional Rent, based on the submeter(s) currently installed in the Premises.  At Tenant’s request, Landlord shall provide Tenant with reasonable back-up documentation regarding the total charges and the method of allocating the charges to Tenant.  Tenant shall, at Tenant’s sole cost and expense, maintain and keep in good order, condition and repair the metering equipment used to measure electricity furnished to the Premises and any equipment exclusively serving the same.  

9.2Water.  Landlord shall contract with the utility provider for water service to the Property, including the Premises.  Except as otherwise provided below, the cost of providing water service to the Premises and all other portions of the Building (including, without limitation, the premises of other tenants or occupants of the Building) shall be included in Operating Costs.  Notwithstanding the foregoing, if Landlord determines that Tenant is using water in excess of its proportionate share (by floor area) of the total water usage in the Building, Landlord may elect, at Tenant’s expense, to furnish and install in a location in or near the Premises metering equipment to measure water furnished to the Premises and any equipment exclusively serving the same.  In such event, Tenant shall, within thirty (30) days after Landlord’s written demand therefor from time to time, pay to Landlord, as Additional Rent, the full amount of any water service charges attributable to such meter.

9.3Gas.  Landlord shall contract with the utility provider for gas service to the Property, including the Premises.  The cost of gas used to serve base building plumbing, mechanical and electrical systems shall be included in the costs reimbursed by Tenant pursuant to Section 9.6 below.  If Tenant requires gas service for the operation of Tenant’s laboratory equipment in the Premises, Tenant shall pay all charges for gas furnished to the Premises and/or any equipment exclusively serving the Premises as Additional Rent, based, at Landlord’s election, (i) on Landlord’s reasonable estimate of such gas usage or (ii) on metering or submetering equipment installed by Landlord at Tenant’s expense.  

23


 

9.4Other Utilities.  Subject to Landlord’s reasonable rules and regulations governing the same, Tenant shall obtain and pay, as and when due, for all other utilities and services consumed in and/or furnished to the Premises, together with all taxes, penalties, surcharges and maintenance charges pertaining thereto.  

9.5Interruption or Curtailment of Utilities.  When necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements which in the reasonable judgment of Landlord are desirable or necessary to be made, Landlord reserves the right, upon as much prior notice to Tenant as is practicable under the circumstances and no less than twenty-four (24) hours’ notice except in the event of an emergency, to interrupt, curtail, or stop (i) the furnishing of hot and/or cold water, and (ii) the operation of the plumbing and electric systems.  Landlord shall exercise reasonable diligence to eliminate the cause of any such interruption, curtailment, stoppage or suspension, but, except as set forth in Section 10.7, there shall be no diminution or abatement of Rent or other compensation due from Landlord to Tenant hereunder, nor shall this Lease be affected or any of Tenant’s obligations hereunder reduced, and Landlord shall have no responsibility or liability for any such interruption, curtailment, stoppage, or suspension of services or systems.  

9.6Landlord’s Services.  Subject to reimbursement pursuant to Section 5.2 above, Landlord shall provide the services described in Exhibit 7 attached hereto and made a part hereof (“Landlord’s Services”).  Except for the cost of providing and maintaining supplemental HVAC equipment (which shall be Tenant’s responsibility), all costs incurred in connection with the provision of Landlord’s Services shall be included in Operating Costs.  Landlord shall allocate to the Premises a portion of the total amount of such costs incurred with respect to the Building based upon the cubic footage of heated, chilled, and fresh air distributed in the Premises as indicated by the energy management system serving the Building as a percentage of the aggregate cubic footage of heated, chilled, and fresh air distributed in the entire Building for the applicable period.  Tenant shall pay such costs monthly, together with monthly installments of Base Rent, on an estimated basis in amounts from time to time reasonably determined by Landlord.  After the close of each fiscal year, Landlord shall determine the actual amount of such costs for such year and deliver to Tenant a reasonably detailed statement thereof, together with a statement of the amounts paid by Tenant on an estimated basis toward such costs as aforesaid.  If such statement indicates that the estimated amounts paid by Tenant are less than Tenant’s allocable share of the actual amount of such costs for such fiscal year, then Tenant shall pay the amount of such shortfall to Landlord within thirty (30) days after delivery of such statement.  If such statement indicates that Tenant’s estimated payments for such year exceed the actual amount of such costs for such year, then Landlord shall credit the excess against the next due installment(s) of Additional Rent payable under this Section 9.6.

9.7Backup Generator. Reference is made to the fact the Building is served by a 400 kw 480/277 3 phase 4 wire (“Existing Generator Capacity”) emergency generator (the “Existing Generator”).  Tenant shall have the right, subject to obtaining Landlord’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed, to connect its equipment in the Premises to the Existing Generator, provided that the aggregate electrical demand of all equipment connected by Tenant to the Existing Generator at any time shall not exceed 80kW.  Landlord’s sole obligation to Tenant with respect to the Existing Generator shall be to contract with a reputable third party (“Generator Servicer”) to maintain the Existing Generator as per the

24


 

manufacturer’s standard maintenance guidelines.  Landlord shall have no obligation to supervise, oversee or confirm that the Generator Servicer is maintaining the Existing Generator per the manufacturer’s standard guidelines or otherwise, and Landlord shall have no obligation or liability to Tenant in the event that the Existing Generator is not operational.

10.

MAINTENANCE AND REPAIRS

10.1Maintenance and Repairs by Tenant.  Tenant shall keep neat and clean and free of insects, rodents, vermin and other pests and in good repair, order and condition (reasonable wear and tear and damage by Casualty excepted):  the Premises, including without limitation the entire interior of the Premises, all electronic, phone and data cabling and related equipment (other than building service equipment) that is installed by or for the exclusive benefit of the Tenant (whether located in the Premises or other portions of the Building), all fixtures, equipment and specialty lighting therein, any supplemental HVAC and humidification equipment exclusively serving the Premises, electrical equipment wiring, doors, non-structural walls, windows and floor coverings, and all laboratory specific systems and equipment that exclusively serve the Premises, including, without limitation, equipment critical to laboratory operations.  Without limiting the foregoing, Tenant agrees that it shall maintain in the same repair, order, and condition as on the Term Commencement Date (reasonable wear and tear and damage by Casualty excepted) any equipment which is the responsibility for Tenant to maintain as set forth on Exhibit 4-3.  

10.2Maintenance and Repairs by Landlord.  Except as otherwise provided in Section 15, and subject to Tenant’s obligations in Section 10.1 above, Landlord shall maintain and keep in reasonable condition the Building foundation, the roof, Building structure, the common mechanical systems serving the Building, the structural floor slabs and columns in good repair, order and condition.  In addition, Landlord shall operate and maintain the Common Areas in substantially the same manner as comparable combination office and laboratory facilities in the vicinity of the Premises.  All costs incurred by Landlord under this Section 10.2 shall be included in Operating Costs, subject to, and in accordance with Section 5.2.

10.3Accidents to Sanitary and Other Systems.  Tenant shall give to Landlord prompt notice of any fire or accident in the Premises or in the Building and of any damage to, or defective condition in, any part or appurtenance of the Building including, without limitation, sanitary, electrical, ventilation, heating and air conditioning or other systems located in, or passing through, the Premises.  Except as otherwise provided in Section 15, and subject to Tenant’s obligations in Section 10.1 above, such damage or defective condition shall be remedied by Landlord with reasonable diligence, but, subject to Section 14.5 below, if such damage or defective condition was caused by any of the Tenant Parties, the cost to remedy the same shall be paid by Tenant.

10.4Floor Load--Heavy Equipment.  Tenant shall not place a load upon any floor of the Premises exceeding the floor load per square foot of area which such floor was designed to carry, and which is allowed by Legal Requirements.  Landlord reserves the right to prescribe the weight and position of all safes, heavy machinery, heavy equipment, freight, bulky matter or fixtures (collectively, “Heavy Equipment”), which shall be placed so as to distribute the weight.  Heavy Equipment shall be placed and maintained by Tenant at Tenant’s expense in settings sufficient in Landlord’s reasonable judgment to absorb and prevent vibration, noise and annoyance. Tenant shall not move any Heavy Equipment into or out of the Building without giving

25


 

Landlord prior written notice thereof and observing all of Landlord’s Rules and Regulations with respect to the same.  If such Heavy Equipment requires special handling, Tenant agrees to employ only persons holding a Master Rigger’s License to do said work, and that all work in connection therewith shall comply with Legal Requirements.  Any such moving shall be at the sole risk and hazard of Tenant and Tenant will defend, indemnify and save Landlord and Landlord’s agents (including without limitation its property manager), contractors and employees (collectively with Landlord, the “Landlord Parties”) harmless from and against any and all claims, damages, losses, penalties, costs, expenses and fees (including without limitation reasonable legal fees) (collectively, “Claims”) resulting directly or indirectly from such moving, except if caused by Landlord’s negligence.  Proper placement of all Heavy Equipment in the Premises shall be Tenant’s responsibility.

10.5Premises Cleaning.  Tenant shall be responsible, at its sole cost and expense, for janitorial and removing trash from the Premises to the common dumpster designated by Landlord and for providing biohazard disposal services for the Premises, including the laboratory areas thereof.  Such services shall be performed by licensed (where required by law or governmental regulation), insured and qualified contractors approved in advance, in writing, by Landlord (which approval shall not be unreasonably withheld, delayed or conditioned) and on a sufficient basis to ensure that the Premises are at all times kept neat and clean.  Landlord shall provide a dumpster and/or compactor at the Building loading dock for Tenant’s disposal of non-hazardous and non-controlled substances.

10.6Pest Control.  Tenant, at Tenant’s sole cost and expense, shall cause the Premises to be exterminated to Landlord’s reasonable satisfaction and shall cause all portions of the Premises used for the storage, preparation, service or consumption of food or beverages to be cleaned daily in a manner reasonably satisfactory to Landlord, and to be treated against infestation by insects, rodents and other vermin and pests whenever there is evidence of any infestation.  Tenant shall not permit any person to enter the Premises for the purpose of providing such extermination services, unless such persons have been approved by Landlord.  If requested by Landlord, Tenant shall, at Tenant’s sole cost and expense, store any refuse generated in the Premises by the consumption of food or beverages in a cold box or similar facility.

10.7Service Interruptions.

(a)Abatement of Rent.  In the event that: (i) there shall be an interruption, curtailment or suspension of any service or failure to perform any obligation required to be provided or performed by Landlord pursuant to Sections 9 and/or 10 (and no reasonably equivalent alternative service or supply is provided by Landlord) that shall materially interfere with Tenant’s use and enjoyment of the Premises, or any portion thereof (any such event, a “Service Interruption”), and (ii) such Service Interruption shall continue for five (5) consecutive business days following receipt by Landlord of written notice (the “Service Interruption Notice”) from Tenant describing such Service Interruption (“Abatement Service Interruption Cure Period”), and (iii) such Service Interruption shall not have been caused by a negligent act or negligent omission of Tenant or Tenant’s agents, employees, contractors or invitees (an event that satisfies the foregoing conditions (i)-(iii) being referred to hereinafter as a “Material Service Interruption”) then, Tenant, subject to the next following sentence, shall be entitled to an equitable abatement of Base Rent, Operating Costs and Taxes based on the nature and duration of

26


 

the Material Service Interruption and the area of the Premises affected, for any and all days following the Material Service Interruption Cure Period that both (x) the Material Service Interruption is continuing and (y) Tenant does not use such affected areas of the Premises for a bona fide business purpose.  Any efforts by Tenant to respond or react to any Material Service Interruption, including, without limitation, any activities by Tenant to remove its personal property from the affected areas of the Premises, shall not constitute a use that precludes abatement pursuant to this Section 10.7(a).  The Abatement Service Interruption Cure Period shall be extended by reason of any delays in Landlord’s ability to cure the Service Interruption in question caused by Landlord’s Force Majeure, provided however, that in no event shall the extension of the Abatement Service Interruption Cure Period resulting from Force Majeure with respect to any Service Interruption exceed fifteen (15) consecutive business days.

(b)The provisions of this Section 10.7 shall not apply in the event of a Service Interruption caused by Casualty or Taking (see Section 15 below).

(c)The provisions of this Section 10.7 set forth Tenant’s sole rights and remedies, both in law and in equity, in the event of any Service Interruption.

11.

ALTERATIONS AND IMPROVEMENTS BY TENANT

11.1Landlord’s Consent Required.  Tenant shall not make any alterations, decorations, installations, removals, additions or improvements (collectively with Tenant’s Work, “Alterations”) in or to the Premises without Landlord’s prior written approval of the contractor(s), written plans and specifications and a time schedule therefor.  Landlord reserves the right to require that Tenant use Landlord’s preferred vendor(s) for any Alterations that involve roof penetrations, alarm tie-ins, sprinklers, fire alarm and other life safety equipment.  Tenant shall not make any amendments or additions to plans and specifications approved by Landlord without Landlord’s prior written consent.  Landlord’s approval of non-structural Alterations shall not be unreasonably withheld, conditioned or delayed.  Notwithstanding the foregoing, Landlord may withhold its consent in its sole discretion (a) to any Alteration to or affecting the fixed lab benches, fume hoods, roof and/or building systems, (b) with respect to matters of aesthetics relating to Alterations to or affecting the exterior of the Building, and (c) to any Alteration affecting the Building structure.  Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with Legal Requirements, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design.  In seeking Landlord’s approval, Tenant shall provide Landlord, at least fourteen (14) business days in advance of any proposed construction, with plans, specifications, bid proposals, certified stamped engineering drawings and calculations by Tenant’s engineer of record or architect of record (including connections to the Building’s structural system, the Building’s mechanical, electrical and plumbing systems, modifications to the Building’s envelope, non-structural penetrations in slabs or walls, and modifications or tie-ins to life safety systems), work contracts, requests for laydown areas and such other information concerning the nature and cost of the Alterations as Landlord may reasonably request.  Landlord shall have no liability or responsibility for any claim, injury or damage alleged to have been caused by the particular materials (whether building standard or non-building standard), appliances or equipment selected by Tenant in connection with any work performed by or on behalf of Tenant.  Except as

27


 

otherwise expressly set forth herein, all Alterations shall be done at Tenant’s sole cost and expense and at such times and in such manner as Landlord may from time to time reasonably designate.  If Tenant shall make any Alterations, then Landlord shall advise Tenant contemporaneously with Landlord’s approval of such Alterations whether Landlord will require said Alterations to be removed at the expiration or sooner termination of the Term, and whether Tenant will be required to restore the Premises to substantially the same condition as existed immediately prior to the Alterations in question, upon which Tenant will rely in determining whether to make said Alterations.  Tenant shall provide Landlord with reproducible record drawings (in CAD format) of all Alterations within sixty (60) days after completion thereof.

11.2After-Hours.  Landlord and Tenant recognize that to the extent Tenant elects to perform some or all of the Alterations during times other than normal construction hours (i.e., Monday-Friday, 7:00 a.m. to 3:00 p.m., excluding holidays), Landlord may need to make arrangements to have supervisory personnel on site.  Accordingly, Landlord and Tenant agree as follows:  Tenant shall give Landlord at least two (2) business days’ prior written notice of any time outside of normal construction hours when Tenant intends to perform any Alterations (the “After-Hours Work”).  Tenant shall reimburse Landlord, within ten (10) days after demand therefor, for the out-of-pocket cost of Landlord’s supervisory personnel overseeing the After-Hours Work.  In addition, if construction during normal construction hours unreasonably disturbs other tenants of the Building, in Landlord’s sole discretion, Landlord may require Tenant to stop the performance of Alterations during normal construction hours and to perform the same after hours, subject to the foregoing requirement to pay for the cost of Landlord’s supervisory personnel.

11.3Harmonious Relations.  Tenant agrees that it will not, either directly or indirectly, use any contractors and/or materials if their use will create any difficulty, whether in the nature of a labor dispute or otherwise, with other contractors and/or labor engaged by Tenant or Landlord or others in the construction, maintenance and/or operation of the Building, the Property or any part thereof.  In the event of any such difficulty, upon Landlord’s reasonable request, Tenant shall cause all contractors, mechanics or laborers causing such difficulty to leave the Property within twenty-four (24) hours of its receipt of such request.

11.4Liens.  No Alterations shall be undertaken by Tenant until (i) Tenant has made provision for written waiver of liens from all contractors for such Alteration and taken other appropriate protective measures approved and/or required by Landlord; and (ii) Tenant has procured appropriate surety payment and performance bonds which shall name Landlord as an additional obligee and has filed lien bond(s) (in jurisdictions where available) on behalf of such contractors.  Any mechanic’s lien filed against the Premises or the Building for work claimed to have been done for, or materials claimed to have been furnished to, Tenant shall be discharged by Tenant within ten (10) days thereafter, at Tenant’s expense by filing the bond required by law or otherwise.    

28


 

11.5General Requirements.  Unless Landlord and Tenant otherwise agree in writing, Tenant shall (a) procure or cause others to procure on its behalf all necessary permits before undertaking any Alterations in the Premises (and provide copies thereof to Landlord); (b) perform all of such Alterations in a good and workmanlike manner, employing materials of good quality and in compliance with Landlord’s construction rules and regulations, all insurance requirements of this Lease, and Legal Requirements; and (c) defend, indemnify and hold the Landlord Parties harmless from and against any and all Claims occasioned by or growing out of such Alterations.  

12.

SIGNAGE

12.1Restrictions.  Tenant shall have the right to install Building standard signage identifying Tenant’s business at the entrance to the Premises, which signage shall be subject to Landlord’s prior written consent (which consent shall not be unreasonably withheld, conditioned or delayed).  Subject to the foregoing, and subject to Section 12.2 below, Tenant shall not place or suffer to be placed or maintained on the exterior of the Premises, or any part of the interior visible from the exterior thereof, any sign, banner, advertising matter or any other thing of any kind (including, without limitation, any hand-lettered advertising), and shall not place or maintain any decoration, letter or advertising matter on the glass of any window or door of the Premises without first obtaining Landlord’s written approval. No signs may be put on or in any window or elsewhere if visible from the exterior of the Building.

12.2Exterior Signage.

(a)Monument Signage. Subject to the provisions of this Section 12.2, for so long as:  (x) there is no Event of Default of Tenant and (y) the Lease is in full force and effect (the “Monument Signage Condition”), then Tenant shall have the right to require Landlord (i) to list, at Landlord’s initial cost and expense, Tenant’s name (“Tenant’s Monument Signage”) on the existing exterior monument sign (the “Monument Sign”) serving the Property during the initial Term of the Lease, and any extensions thereof, subject to the provisions of this Section 12.2.  The parties hereby agree that the maintenance and removal of such Tenant’s Monument Signage (including, without limitation, the repair and cleaning of the existing monument façade upon removal of Tenant’s Monument Signage) shall be performed at Landlord’s sole cost and expense, except that Tenant shall be responsible for the cost of any change in Tenant’s Monument Signage during the initial Term of the lease.

12.3Building Directory.

Landlord shall list Tenant within the directory in the Building lobby.  The initial listing shall be at Landlord’s cost and expense, and any changes to such directory listing shall be at Tenant’s cost and expense.  

13.

ASSIGNMENT, MORTGAGING AND SUBLETTING

13.1Landlord’s Consent Required.  Tenant shall not mortgage or encumber this Lease or in whole or in part whether at one time or at intervals, operation of law or otherwise.  Except as expressly otherwise set forth herein, Tenant shall not, without Landlord’s prior written consent, assign, sublet, license or transfer this Lease or the Premises in whole or in part whether by changes in the ownership or control of Tenant, or any direct or indirect owner of Tenant, whether at one

29


 

time or at intervals, by sale or transfer of stock, partnership or beneficial interests, operation of law or otherwise, or permit the occupancy of all or any portion of the Premises by any person or entity other than Tenant’s employees (each of the foregoing, a “Transfer”).  Any purported Transfer made without Landlord’s consent, if required hereunder, shall be void and confer no rights upon any third person, provided that if there is a Transfer, Landlord may collect rent from the transferee without waiving the prohibition against Transfers, accepting the transferee, or releasing Tenant from full performance under this Lease.  In the event of any Transfer in violation of this Section 13, Landlord shall have the right to terminate this Lease upon thirty (30) days’ written notice to Tenant given within sixty (60) days after receipt of written notice from Tenant to Landlord of any completed Transfer, or within one (1) year after Landlord first learns of the completed Transfer if no notice is given. No Transfer shall relieve Tenant of its primary obligation as party Tenant hereunder, nor shall it reduce or increase Landlord’s obligations under this Lease.

13.2Landlord’s Recapture Right.  

Subject to Section 13.7 below, Tenant shall, prior to offering or advertising the Premises or any portion thereof for a Transfer, give a written notice (the “Recapture Notice”) to Landlord which: (i) states that Tenant desires to make a Transfer, (ii) identifies the affected portion of the Premises (the “Recapture Premises”),  (iii) identifies the period of time (the “Recapture Period”) during which Tenant proposes to sublet the Recapture Premises, or indicates that Tenant proposes to assign its interest in this Lease, and (iv) offers to Landlord to terminate this Lease with respect to the Recapture Premises (in the case of a proposed assignment of Tenant’s interest in this Lease or a subletting for the remainder of the Term of this Lease) or to suspend the Term for the Recapture Period (i.e. the Term with respect to the Recapture Premises shall be terminated during the Recapture Period and Tenant’s rental obligations shall be proportionately reduced, or, if the Recapture Premises constitutes the entire Premises, fully abated during the Recapture Period).  Landlord shall have fifteen (15) business days within which to respond to the Recapture Notice.

13.3Standard of Consent to Transfer.  If Landlord does not timely give written notice to Tenant accepting a Recapture Offer or declines to accept the same, then Landlord agrees that, subject to the provisions of this Section 13, Landlord shall not unreasonably withhold, condition or delay its consent to a Transfer on the terms contained in the Recapture Notice to an entity which will use the Premises for the Permitted Uses and, in Landlord’s reasonable opinion: (a) has a tangible net worth not less than Tenant’s net worth at the time of the transfer and other financial indicators sufficient to meet the Transferee’s obligations under the Transfer instrument in question; (b) has a business reputation compatible with the operation of a first-class combination laboratory, research, development and office building; and (c) the intended use of such entity does not violate any restrictive use provisions then in effect with respect to space in the Building.

13.4Listing Confers no Rights.  The listing of any name other than that of Tenant, whether on the doors of the Premises or on the Building directory, or otherwise, shall not operate to vest in any such other person, firm or corporation any right or interest in this Lease or in the Premises or be deemed to effect or evidence any consent of Landlord, it being expressly understood that any such listing is a privilege extended by Landlord revocable at will by written notice to Tenant.

30


 

13.5Profits in Connection with Transfers.  Tenant shall, within thirty (30) days of receipt thereof, pay to Landlord fifty percent (50%) of any rent, sum or other consideration to be paid or given in connection with any Transfer (excluding payments or consideration paid or given for the sale merger or consolidation of Tenant’s business in connection with a Permitted Transfer), either initially or over time, after deducting reasonable actual out-of-pocket legal, and brokerage expenses incurred by Tenant and unamortized improvements paid for by Tenant in connection therewith, in excess of Rent hereunder as if such amount were originally called for by the terms of this Lease as Additional Rent.

13.6Prohibited Transfers.  Notwithstanding any contrary provision of this Lease, Tenant shall have no right to make a Transfer unless on both (i) the date on which Tenant notifies Landlord of its intention to enter into a Transfer and (ii) the date on which such Transfer is to take effect, Tenant is not in default of any of its obligations under this Lease beyond the applicable notice and cure period.  Notwithstanding anything to the contrary contained herein, Tenant agrees that in no event shall Tenant make a Transfer to (a) any government agency; (b) any tenant, subtenant or occupant of other space in the Building; or (c) any entity with whom Landlord shall have negotiated for space in the Property in the six (6) months immediately preceding such proposed Transfer.

13.7Exceptions to Requirement for Consent.  Notwithstanding anything to the contrary herein contained, Tenant shall have the right, without obtaining Landlord's consent and without giving Landlord a Recapture Notice, to (a) make a Transfer to an Affiliated Entity (hereinafter defined) so long as the transfer to such Affiliated Entity is for legitimate business purposes (and not for the purpose of avoiding the provisions of this Section 13), and (b) assign all of Tenant’s interest in and to the Lease to a Successor, provided that prior to or simultaneously with any assignment pursuant to this Section 13.7, such Affiliated Entity or Successor, as the case may be, and Tenant execute and deliver to Landlord an assignment and assumption agreement in form and substance reasonably acceptable to Landlord whereby such Affiliated Entity or Successor, as the case may be, shall agree to be independently bound by and upon all the covenants, agreements, terms, provisions and conditions set forth in the Lease on the part of Tenant to be performed, and whereby such Affiliated Entity or Successor, as the case may be, shall expressly agree that the provisions of this Article 13 shall, notwithstanding such Transfer, continue to be binding upon it with respect to all future Transfers.  For the purposes hereof, an “Affiliated Entity” shall be defined as any entity which is controlled by, is under common control with, or which controls Tenant. For the purposes hereof, a “Successor” shall be defined as any entity into or with which Tenant is merged or with which Tenant is consolidated or reorganized or which acquires all or substantially all of Tenant’s stock or assets, provided that the surviving entity shall have a net worth and other financial indicators sufficient to meet Tenant’s obligations hereunder. Tenant shall give Landlord at least ten (10) days’ prior written notice of ay Permitted Transfer, such notice to include evidence, reasonably satisfactory to Landlord, that the conditions to the Permitted Transfer in question have been satisfied. Transfers to Affiliated Entities and to Successor which are permitted pursuant to this Section 13.7, are referred to collectively herein as “Permitted Transfers”, and such Affiliated Entities and Successors are referred to herein as “Permitted Transferees”.

31


 

14.

INSURANCE; INDEMNIFICATION; EXCULPATION

14.1Tenant’s Insurance.

(a)Tenant shall procure, pay for and keep in force throughout the Term (but in all events commencing on the date on which any Tenant Party first enters the Premises for the performance of any Tenant’s Work, and for so long thereafter as Tenant remains in occupancy of the Premises) commercial general liability insurance insuring Tenant on an occurrence basis against all claims and demands for personal injury liability (including, without limitation, bodily injury, sickness, disease, and death) or damage to property which may be claimed to have occurred from and after the time any of the Tenant Parties shall first enter the Premises, of not less than One Million Dollars ($1,000,000) per occurrence and Two Million Dollars ($2,000,000) in the aggregate annually, and from time to time thereafter shall be not less than such higher amounts, if procurable, as may be reasonably required by Landlord. Tenant shall also carry umbrella liability coverage in an amount of no less than Five Million Dollars ($5,000,000). Such policy shall also include contractual liability coverage covering Tenant’s liability assumed under this Lease, including without limitation Tenant’s indemnification obligations.  Such insurance policy(ies) shall name Landlord, Landlord’s managing agent and persons claiming by, through or under them, if any, as additional insureds.

(b)Tenant shall take out and maintain throughout the Term a policy of fire, vandalism, malicious mischief, extended coverage and so-called “all risk” coverage insurance in an amount equal to one hundred percent (100%) of the replacement cost insuring (i) all items or components of Alterations (collectively, the “Tenant-Insured Improvements”), and (ii) all of Tenant’s furniture, equipment, fixtures and property of every kind, nature and description related or arising out of Tenant’s leasehold estate hereunder, which may be in or upon the Premises or the Building, including without limitation all of Tenant’s animals (collectively, “Tenant’s Property”).  The insurance required to be maintained by Tenant pursuant to this Section 14.1(b) (referred to herein as “Tenant Property Insurance”) shall insure the interests of both Landlord and Tenant as their respective interests may appear from time to time.

(c)Tenant shall take out and maintain a policy of business interruption insurance throughout the Term sufficient to cover at least twelve (12) months of Rent due hereunder and Tenant’s business losses during such 12-month period.

(d)During periods when Tenant’s Work and/or any Alterations are being performed, Tenant shall maintain, or cause to be maintained, so-called all risk or special cause of loss property insurance or its equivalent and/or builders risk insurance on 100% replacement cost coverage basis, including hard and soft costs coverages. Such insurance shall protect and insure Landlord, Landlord’s agents, Tenant and Tenant’s contractors, as their interests may appear, against loss or damage by fire, water damage, vandalism and malicious mischief, and such other risks as are customarily covered by so-called all risk or special cause of loss property / builders risk coverage or its equivalent.

(e)Tenant shall procure and maintain at its sole expense such additional insurance as may be necessary to comply with any Legal Requirements.

32


 

(f)Tenant shall cause all contractors and subcontractors to maintain during the performance of any Alterations the insurance described in Exhibit 10 attached hereto.

(g)The insurance required pursuant to Sections 14.1(a), (b), (c), (d) and (e) (collectively, “Tenant’s Insurance Policies”) shall be effected with insurers approved by Landlord, with a rating of not less than “A-XI” in the current Best’s Insurance Reports, and authorized to do business in the Commonwealth of Massachusetts under valid and enforceable policies.  Tenant’s Insurance Policies shall each provide that it shall not be canceled or modified without at least thirty (30) days’ prior written notice to each insured named therein.  Tenant’s Insurance Policies may include deductibles in an amount no greater than the greater of $25,000 or commercially reasonable amounts. On or before the date on which any of the Tenant Parties shall first enter the Premises and thereafter not less than fifteen (15) days prior to the expiration date of each expiring policy, Tenant shall deliver to Landlord binders of Tenant’s Insurance Policies issued by the respective insurers setting forth in full the provisions thereof together with evidence satisfactory to Landlord of the payment of all premiums for such policies.  In the event of any claim, and upon Landlord’s request, Tenant shall deliver to Landlord complete copies of Tenant’s Insurance Policies.  Upon request of Landlord, Tenant shall deliver to any Mortgagee copies of the foregoing documents.

14.2Indemnification.  

(a)Except to the extent caused by the negligence or willful misconduct of any of the Landlord Parties, Tenant shall defend, indemnify and save the Landlord Parties harmless from and against any and all Claims asserted by or on behalf of any person, firm, corporation or public authority arising from:

(i)Tenant’s breach of any covenant or obligation under this Lease;

(ii)From and after the Term commencement Date, any injury to or death of any person, or loss of or damage to property, sustained or occurring in, upon, at or about the Premises;

(iii)Any injury to or death of any person, or loss of or damage to property arising out of the use or occupancy of the Premises by or the negligence or willful misconduct of any of the Tenant Parties; and

(iv)On account of or based upon any work or thing whatsoever done (other than by Landlord or any of the Landlord Parties) at the Premises during the Term and during the period of time, if any, prior to the Term Commencement Date that any of the Tenant Parties may have been given access to the Premises.

(b)Notwithstanding anything in this Lease to the contrary, the individual partners, members or shareholders directly or indirectly comprising Tenant (as opposed to Tenant itself) shall not have any personal liability for the performance of Tenant’s obligations under this Lease.

33


 

(c)Except to the extent caused by the negligence or willful misconduct of any of the Tenant Parties, Landlord shall defend, indemnify and save the Tenant Parties harmless from and against any and all Claims asserted by or on behalf of third party which is unrelated to Tenant or any Tenant Party arising from any injury to or death of any person, or loss of or damage to property at the Property arising out the negligence or willful misconduct of any of the Landlord Parties.

14.3Property of Tenant.  Tenant covenants and agrees that, to the maximum extent permitted by Legal Requirements, all of Tenant’s Property at the Premises shall be at the sole risk and hazard of Tenant, and that if the whole or any part thereof shall be damaged, destroyed, stolen or removed from any cause or reason whatsoever, no part of said damage or loss shall be charged to, or borne by, Landlord, except, subject to Section 14.5 hereof, to the extent such damage or loss is due to the negligence or willful misconduct of any of the Landlord Parties.

14.4Limitation of Landlord’s Liability for Damage or Injury.  Landlord shall not be liable for any injury or damage to persons, animals or property resulting from fire, explosion, falling plaster, steam, gas, air contaminants or emissions, electricity, electrical or electronic emanations or disturbance, water, rain or snow or leaks from any part of the Building or from the pipes, appliances, equipment or plumbing works or from the roof, street or sub-surface or from any other place or caused by dampness, vandalism, malicious mischief or by any other cause of whatever nature, except, subject to Section 14.5, to the extent caused by or due to the negligence or willful misconduct of any of the Landlord Parties.  Notwithstanding the foregoing, in no event shall any of the Landlord Parties be liable for any loss which is covered by insurance policies actually carried or required to be so carried by this Lease; nor shall any of the Landlord Parties be liable for any such damage caused by other tenants or persons in the Building or caused by operations in construction of any private, public, or quasi-public work; nor shall any of the Landlord Parties be liable for any latent defect in the Premises or in the Building.

14.5Waiver of Subrogation; Mutual Release.  Landlord and Tenant each hereby waives on behalf of itself and its property insurers (none of which shall ever be assigned any such claim or be entitled thereto due to subrogation or otherwise) any and all rights of recovery, claim, action, or cause of action against the other and its agents, officers, servants, partners, shareholders, or employees (collectively, the “Related Parties”) for any loss or damage that may occur to or within the Premises or the Building or any improvements thereto, or any personal property of such party therein which is insured against under any Property Insurance (as defined in Section 14.7) policy actually being maintained by the waiving party from time to time, even if not required hereunder, or which would be insured against under the terms of any Property Insurance policy required to be carried or maintained by the waiving party hereunder, whether or not such insurance coverage is actually being maintained, including, in every instance, such loss or damage that may be caused by the negligence of the other party hereto and/or its Related Parties.  Landlord and Tenant each agrees to cause appropriate clauses to be included in its Property Insurance policies necessary to implement the foregoing provisions.

34


 

14.6Tenant’s Acts--Effect on Insurance.  Tenant shall not do or permit any Tenant Party to do any act or thing upon the Premises or elsewhere in the Building which will invalidate or be in conflict with any insurance policies covering the Building and the fixtures and property therein; and shall not do, or permit to be done, any act or thing upon the Premises which shall subject Landlord to any liability or responsibility for injury to any person or persons or to property by reason of any business or operation being carried on upon said Premises or for any other reason.  If by reason of the failure of Tenant to comply with the provisions hereof the insurance rate applicable to any policy of insurance shall at any time thereafter be higher than it otherwise would be, Tenant shall, subject to the applicable notice and cure periods, reimburse Landlord upon demand for that part of any insurance premiums which shall have been charged because of such failure by Tenant, together with interest at the Default Rate until paid in full, within ten (10) days after receipt of an invoice therefor.  In addition, Tenant shall reimburse Landlord for any increase in insurance premium arising as a result of Tenant’s use and/or storage of any Hazardous Materials in the Premises.

14.7Landlord’s Insurance.  Landlord shall carry at all times during the Term of this Lease: (i) commercial general liability insurance with respect to the Building, the Land and the Common Areas thereof in an amount not less than Five Million Dollars ($5,000,000) combined single limit per occurrence, (ii) with respect to the Building, excluding Tenant-Insured Improvements and improvements made by other tenants or occupants, insurance against loss or damage caused by any peril covered under fire, extended coverage and all risk insurance with coverage against vandalism, malicious mischief and such other insurable hazards and contingencies as are from time to time normally insured against by owners of similar first class offices/research/laboratory buildings/campuses in the Market Area or which are required by Landlord’s mortgagee, in an amount equal to one hundred percent (100%) of the full replacement cost thereof above foundation walls (“Landlord Property Insurance”), and (iii) rent interruption insurance covering at least eighteen (18) months.  Any and all such insurance: (x) may be maintained under a blanket policy affecting other properties of Landlord and/or its affiliated business organizations, and (y) may be written with commercially reasonable deductibles as determined by Landlord.  The costs incurred by Landlord related to such insurance shall be included in Operating Costs.  Tenant Property Insurance and Landlord Property Insurance are referred to collectively herein as “Property Insurance”.

15.

CASUALTY; TAKING

15.1Damage.  If the Premises are damaged in whole or part because of fire or other insured casualty (“Casualty”), or if the Premises are subject to a taking in connection with the exercise of any power of eminent domain, condemnation, or purchase under threat or in lieu thereof (any of the foregoing, a “Taking”), then unless this Lease is terminated in accordance with Section 15.2 below, Landlord shall restore the Building and/or the Premises to substantially the same condition as existed immediately following completion of Landlord’s Work, or in the event of a partial Taking which affects the Building and the Premises, restore the remainder of the Building and the Premises not so Taken to substantially the same condition as is reasonably feasible.  If, in Landlord’s reasonable judgment, any element of the Tenant-Insured Improvements can more effectively be restored as an integral part of Landlord’s restoration of the Building or the Premises, such restoration shall also be made by Landlord, but at Tenant’s sole cost and expense.  Subject to rights of Mortgagees, Tenant Delays, Legal Requirements then in existence and to delays for

35


 

adjustment of insurance proceeds or Taking awards, as the case may be, and instances of Force Majeure, Landlord shall substantially complete such restoration within one (1) year after Landlord’s receipt of all required permits therefor with respect to substantial reconstruction of at least 50% of the Building, or, within one hundred eighty (180) days after Landlord’s receipt of all required permits therefor in the case of restoration of less than 50% of the Building.  Upon substantial completion of such restoration by Landlord, Tenant shall use diligent efforts to complete restoration of the Premises to substantially the same condition as existed immediately prior to such Casualty or Taking, as the case may be, as soon as reasonably possible.  Tenant agrees to cooperate with Landlord in such manner as Landlord may reasonably request to assist Landlord in collecting insurance proceeds due in connection with any Casualty which affects the Premises or the Building.  In no event shall Landlord be required to expend more than the Net (hereinafter defined) insurance proceeds Landlord receives for damage to the Premises and/or the Building or the Net Taking award attributable to the Premises and/or the Building.  “Net” means the insurance proceeds or Taking award actually paid to Landlord (and not paid over to a Mortgagee) less all costs and expenses, including adjusters and attorney’s fees, of obtaining the same.  In the Operating Year in which a Casualty occurs, there shall be included in Operating Costs Landlord’s deductible under its property insurance policy.  Except as Landlord may elect pursuant to this Section 15.1, under no circumstances shall Landlord be required to repair any damage to, or make any repairs to or replacements of, any Tenant-Insured Improvements.  

15.2Termination Rights.  

(a)Landlord’s Termination Rights.  Landlord may terminate this Lease upon thirty (30) days’ prior written notice to Tenant if:

(i)any material portion of the Building or any material means of access thereto is taken;

(ii)more than thirty-five percent (35%) of the Building is damaged by Casualty; or

(iii)if the estimated time to complete restoration exceeds one (1) year from the date on which Landlord receives all required permits for such restoration.

(b)Tenant’s Termination Right.  If Landlord is so required but fails to complete restoration of the Premises within the time frames and subject to the conditions set forth in Section 15.1 above, then Tenant may terminate this Lease upon thirty (30) days’ written notice to Landlord; provided, however, that if Landlord completes such restoration within thirty (30) days after receipt of any such termination notice, such termination notice shall be null and void and this Lease shall continue in full force and effect.  The remedies set forth in this Section 15.2(b) and in Section 15.2(c) below are Tenant’s sole and exclusive rights and remedies based upon Landlord’s failure to complete the restoration of the Premises as set forth herein. Notwithstanding anything to the contrary contained herein, Tenant shall not have the right to terminate this Lease pursuant to this Section 15 if the Casualty was caused by the negligence or intentional misconduct of any Tenant Party.

36


 

(c)Either Party May Terminate.  In the case of any Casualty or Taking affecting the Premises and occurring during the last twelve (12) months of the Term, then (i) if such Casualty or Taking results in more than twenty-five percent (25%) of the floor area of the Premises being unsuitable for the Permitted Uses, or (ii) the damage to the Premises costs more than $250,000 to restore, then either Landlord or Tenant shall have the option to terminate this Lease upon thirty (30) days’ written notice to the other.  In addition, if Landlord’s Mortgagee does not release sufficient insurance proceeds to cover the cost of Landlord’s restoration obligations, then Landlord shall (i) notify Tenant thereof, and (ii) have the right to terminate this Lease.  If Landlord does not terminate this Lease pursuant to the previous sentence and such notice by Landlord does not include an agreement by Landlord to pay for the difference between the cost of such restoration and such released insurance proceeds, then Tenant may terminate this Lease by written notice to Landlord on or before the date that is thirty (30) days after such notice.  Notwithstanding anything to the contrary contained in this Section 15, in no event may Tenant elect to terminate this Lease hereunder if the Casualty that would otherwise give rise to such right results from the gross negligence or willful misconduct of Tenant, its agents, contractors, or employees.

(d)Automatic Termination.  In the case of a Taking of the entire Premises, then this Lease shall automatically terminate as of the date of possession by the Taking authority.

15.3Rent Abatement.  In the event of a Casualty affecting the Premises, there shall be an equitable adjustment of Base Rent, Operating Costs and Taxes based upon the degree to which Tenant’s ability to conduct its business in the Premises is impaired by reason of such Casualty from and after the date of a Casualty, and continuing until the following portions of the repair and restoration work to be performed by Landlord, as set forth above, are substantially completed: (i) any repair and restoration work to be performed by Landlord within the Premises, and (ii) repair and restoration work with respect to the Common Areas to the extent that damage to the Common Areas caused by such Casualty materially adversely affects Tenant’s use of, or access to, the Premises.

15.4Taking for Temporary Use. If the Premises are Taken for temporary use, Tenant’s obligations, including without limitation the payment of Rent, shall equitably abate.  For purposes hereof, a “Taking for temporary use” shall mean a Taking of ninety (90) days or less.  

15.5Disposition of Awards.  Except for any separate award for Tenant’s movable trade fixtures, relocation expenses, and unamortized leasehold improvements paid for by Tenant (provided that the same may not reduce Landlord’s award), all Taking awards to Landlord or Tenant shall be Landlord’s property without Tenant’s participation, and Tenant hereby assigns to Landlord Tenant’s interest, if any, in such award.  Tenant may pursue its own claim against the Taking authority.

16.

ESTOPPEL CERTIFICATE.  

Tenant shall at any time and from time to time upon not less than ten (10) days’ prior notice from Landlord, execute, acknowledge and deliver to Landlord a statement in writing certifying that this Lease is unmodified and in full force and effect (or if there have been modifications, that the same is in full force and effect as modified and stating the modifications), and the dates to which Rent has been paid in advance, if any, stating whether or not Landlord is in default in

37


 

performance of any covenant, agreement, term, provision or condition contained in this Lease and, if so, specifying each such default, and such other facts as Landlord may reasonably request, it being intended that any such statement delivered pursuant hereto may be relied upon by Landlord, any prospective purchaser of the Building or of any interest of Landlord therein, any Mortgagee or prospective Mortgagee thereof, any lessor or prospective lessor thereof, any lessee or prospective lessee thereof, or any prospective assignee of any mortgage thereof.  Time is of the essence with respect to any such requested certificate, Tenant hereby acknowledging the importance of such certificates in mortgage financing arrangements, prospective sales and the like.  If Tenant shall fail to execute and deliver to Landlord any such statement within such ten-day period, Tenant hereby appoints Landlord as Tenant’s attorney-in-fact in its name and behalf to execute such statement, such appointment being coupled with an interest.

17.

HAZARDOUS MATERIALS

17.1Prohibition.  Tenant shall not, without the prior written consent of Landlord, bring or permit to be brought or kept in or on the Premises or elsewhere in the Building or the Property (i) any inflammable, combustible or explosive fluid, material, chemical or substance (except for standard office supplies stored in proper containers); and (ii) any Hazardous Material (hereinafter defined), other than the types and quantities of Hazardous Materials which are listed on Exhibit 8 attached hereto (“Tenant’s Hazardous Materials”), provided that the same shall at all times be brought upon, kept or used in so-called ‘control areas’ (the number and size of which shall be reasonably determined by Landlord), as described in, and in accordance with, Exhibit 11 attached hereto and in accordance with all applicable Environmental Laws (hereinafter defined) and prudent environmental practice and (with respect to medical waste and so-called “biohazard” materials) good scientific and medical practice.  Tenant shall be responsible for assuring that all laboratory uses are adequately and properly vented.  On or before each anniversary of the Rent Commencement Date, and on any earlier date during the 12-month period on which Tenant intends to add a new Hazardous Material or materially increase the quantity of any Hazardous Material to the list of Tenant’s Hazardous Materials, Tenant shall submit to Landlord an updated list of Tenant’s Hazardous Materials for Landlord’s review and approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall have the right, from time to time, to inspect the Premises for compliance with the terms of this Section 17.1.  Notwithstanding the foregoing, with respect to any of Tenant’s Hazardous Materials which Tenant does not properly handle, store or dispose of in compliance with all applicable Environmental Laws (hereinafter defined), prudent environmental practice and (with respect to medical waste and so-called “biohazard materials”) good scientific and medical practice, Tenant shall, upon written notice from Landlord, no longer have the right to bring such material into the Building or the Property until Tenant has demonstrated, to Landlord’s reasonable satisfaction, that Tenant has implemented programs to thereafter properly handle, store or dispose of such material.  In order to induce Landlord to waive its otherwise applicable requirement that Tenant maintain insurance in favor of Landlord against liability arising from the presence of radioactive materials in the Premises, and without limiting the foregoing, Tenant hereby represents and warrants to Landlord that at no time during the Term will Tenant bring upon, or permit to be brought upon, the Premises any radioactive materials whatsoever.

38


 

17.2Environmental Laws.  For purposes hereof, “Environmental Laws” shall mean all laws, statutes, ordinances, rules and regulations of any local, state or federal governmental authority having jurisdiction concerning environmental, health and safety matters, including but not limited to any discharge by any of the Tenant Parties into the air, surface water, sewers, soil or groundwater of any Hazardous Material (hereinafter defined) whether within or outside the Premises, including, without limitation (a) the Federal Water Pollution Control Act, 33 U.S.C. Section 1251 et seq., (b) the Federal Resource Conservation and Recovery Act, 42 U.S.C. Section 6901 et seq., (c) the Comprehensive Environmental Response, Compensation and Liability Act, 42 U.S.C. Section 9601 et seq., (d) the Toxic Substances Control Act of 1976, 15 U.S.C. Section 2601 et seq., and (e) Chapter 21E of the General Laws of Massachusetts.  Tenant, at its sole cost and expense, shall comply with (i) Environmental Laws, and (ii) any rules, requirements and safety procedures of the Massachusetts Department of Environmental Protection, the Town of Lexington and any insurer of the Building or the Premises with respect to Tenant’s use, storage and disposal of any Hazardous Materials.

17.3Hazardous Material Defined.  As used herein, the term “Hazardous Material” means asbestos, oil or any hazardous, radioactive or toxic substance, material or waste or petroleum derivative which is or becomes regulated by any Environmental Law, including without limitation live organisms, viruses and fungi, medical waste and any so-called “biohazard” materials.  The term “Hazardous Material” includes, without limitation, oil and/or any material or substance which is (i) designated as a “hazardous substance,” “hazardous material,” “oil,” “hazardous waste” or toxic substance under any Environmental Law.

17.4Chemical Safety Program.  Tenant shall establish and maintain a chemical safety program administered by a licensed, qualified individual in accordance with the requirements of any applicable governmental authority.  Tenant shall be solely responsible for all costs incurred in connection with such chemical safety program, and Tenant shall provide Landlord with such documentation as Landlord may reasonably require evidencing Tenant’s compliance with the requirements of (a) any applicable governmental authority with respect to such chemical safety program and (b) this Section.  Tenant shall obtain and maintain during the Term any permit required by any such applicable governmental authority.

17.5Testing.  If any Mortgagee or governmental authority requires testing to determine whether there has been any release of Hazardous Materials and such testing is required as a result of the acts or omissions of any of the Tenant Parties, then Tenant shall reimburse Landlord upon demand, as Additional Rent, for the reasonable costs thereof, together with interest at the Default Rate until paid in full.  Tenant shall execute affidavits, certifications and the like, as may be reasonably requested by Landlord from time to time concerning Tenant’s best knowledge and belief concerning the presence of Hazardous Materials in or on the Premises, the Building or the Property.  In addition to the foregoing, if Landlord reasonably believes that any Hazardous Materials have been released on the Premises in violation of this Lease or any Legal Requirement, Landlord shall have the right to conduct appropriate tests of the Premises or any portion thereof to demonstrate that Hazardous Materials are present or that contamination has occurred due to the acts or omissions of any of the Tenant Parties.  Tenant shall pay all reasonable costs of such tests if such tests reveal that Hazardous Materials exist at the Premises in violation of this Lease or any Legal Requirement.  Further, Landlord shall have the right to cause a third party consultant retained by Landlord, at Landlord’s expense (provided, however, that such costs shall be included in

39


 

Operating Costs), to review, but not more than once in any calendar year, Tenant’s lab operations, procedures and permits to ascertain whether or not Tenant is complying with law and adhering to best industry practices.  Said consultant shall be accompanied by a designated representative of Tenant while in the Premises (provided that Tenant shall make a designated representative available at such times as Landlord may reasonably require for the purposes of accompanying said consultant), and Landlord agrees to cause said consultant to sign a reasonable non-disclosure agreement prior to entering the Premises; provided, however, that such non-disclosure agreement shall permit Landlord’s consultant to disclose its findings to Landlord and Landlord’s property manager, and, to the extent required by a Mortgage or applicable law, to any Mortgagee or governmental authority, respectively.  Tenant agrees to cooperate in good faith with any such review and to provide to such consultant any information requested by such consultant and reasonably required in order for such consultant to perform such review, but nothing contained herein shall require Tenant to provide proprietary or confidential information to such consultant.

17.6Indemnity; Remediation.  

(a)Tenant hereby covenants and agrees to indemnify, defend and hold the Landlord Parties harmless from and against any and all Claims against any of the Landlord Parties arising out of contamination of any part of the Property or other adjacent property, which contamination arises as a result of: (i) the presence of Hazardous Material in the Premises, the presence of which is caused by any act or omission of any of the Tenant Parties, or (ii) from a breach by Tenant of its obligations under this Section 17.  This indemnification of the Landlord Parties by Tenant includes, without limitation, reasonable costs incurred in connection with any investigation of site conditions or any cleanup, remedial, removal or restoration work or any other response actions required by any federal, state or local governmental agency or political subdivision because of Hazardous Material present in the soil, soil vapor or ground water on or under or any indoor air in the Building based upon the circumstances identified in the first sentence of this Section 17.6.  The indemnification and hold harmless obligations of Tenant under this Section 17.6 shall survive the expiration or any earlier termination of this Lease, but are subject to any applicable statute of limitations.  Without limiting the foregoing, if the presence of any Hazardous Material in the Building or otherwise in the Property is caused or permitted by any of the Tenant Parties and results in any contamination of any part of the Property or any adjacent property, Tenant shall promptly take all actions at Tenant’s sole cost and expense as are necessary to return the Property and/or the Building or any adjacent property to their condition as of the date of this Lease, provided that Tenant shall first obtain Landlord’s written approval of such actions, which approval shall not be unreasonably withheld, conditioned or delayed so long as such actions, in Landlord’s reasonable discretion, would not potentially have any adverse effect on the Property, and, in any event, Landlord shall not withhold its approval of any proposed actions which are required by applicable Environmental Laws.  Notwithstanding anything in this Lease to the contrary, Tenant shall not be liable for any Hazardous Materials existing on the Property (or any migration thereof) prior to the Term Commencement Date.  The provisions of this Section 17.6 shall survive the expiration or earlier termination of the Lease, but are subject to any applicable statute of limitations.

40


 

(b)Without limiting the obligations set forth in Section 17.6(a) above, if any Hazardous Material is in, on, under, at or about the Building or the Property as a result of the acts or omissions of any of the Tenant Parties and results in any contamination of any part of the Property or any adjacent property that is in violation of any applicable Environmental Law or that requires the performance of any response action pursuant to any Environmental Law, Tenant shall promptly take all actions at Tenant’s sole cost and expense as are necessary to reduce such Hazardous Material to amounts below any applicable Reportable Quantity, any applicable Reportable Concentration and any other applicable standard set forth in any Environmental Law such that no further response actions are required; provided that Tenant shall first obtain Landlord’s written approval of such actions, which approval shall not be unreasonably withheld, conditioned or delayed so long as such actions would not be reasonably expected to have an adverse effect on the market value or utility of the Property for the Permitted Uses, and in any event, Landlord shall not withhold its approval of any proposed actions which are required by applicable Environmental Laws (such approved actions, “Tenant’s Remediation”).

(c)In the event that Tenant fails to complete Tenant’s Remediation prior to the end of the Term, then:

(i)until the completion of Tenant’s Remediation (as evidenced by the certification of Tenant’s Licensed Site Professional (as such term is defined by applicable Environmental Laws), who shall be reasonably acceptable to Landlord) (the “Remediation Completion Date”), Tenant shall pay to Landlord, with respect to the portion of the Premises which reasonably cannot be occupied by a new tenant until completion of Tenant’s Remediation, (A) Additional Rent on account of Operating Costs and Taxes and (B) Base Rent in an amount equal to the greater of (1) the fair market rental value of such portion of the Premises (determined in substantial accordance with the process described in Section 1.2 above), and (2) Base Rent attributable to such portion of the Premises in effect immediately prior to the end of the Term; and

(ii)Tenant shall maintain responsibility for Tenant’s Remediation and Tenant shall complete Tenant’s Remediation as soon as reasonably practicable in accordance with Environmental Laws.  If Tenant does not diligently pursue completion of Tenant’s Remediation, Landlord shall have the right to either (A) assume control for overseeing Tenant’s Remediation, in which event Tenant shall pay all reasonable costs and expenses of Tenant’s Remediation (it being understood and agreed that all costs and expenses of Tenant’s Remediation incurred pursuant to contracts entered into by Tenant shall be deemed reasonable) within thirty (30) days of demand therefor (which demand shall be made no more often than monthly), and Landlord shall be substituted as the party identified on any governmental filings as the party responsible for the performance of such Tenant’s Remediation or (B) require Tenant to maintain responsibility for Tenant’s Remediation, in which event Tenant shall complete Tenant’s Remediation as soon as reasonably practicable in accordance with Environmental Laws, it being understood that Tenant’s Remediation shall not contain any requirement that Tenant remediate any contamination to levels or standards more stringent than those associated with the Property’s current office, research and development, laboratory, and vivarium uses.

(d)The provisions of this Section 17.6 shall survive the expiration or earlier termination of this Lease, but are subject to any applicable statute of limitations.

41


 

17.7Disclosures.  Prior to bringing any Hazardous Material into any part of the Property, Tenant shall deliver to Landlord the following information with respect thereto: (a) a description of handling, storage, use and disposal procedures; (b) all plans or disclosures and/or emergency response plans which Tenant has prepared, including without limitation Tenant’s Spill Response Plan, and all plans which Tenant is required to supply to any governmental agency or authority pursuant to any Environmental Laws; (c) copies of all Required Permits relating thereto; and (d) other information reasonably requested by Landlord.

17.8Removal.  Tenant shall be responsible, at its sole cost and expense, for Hazardous Material and other biohazard disposal services for the Premises.  Such services shall be performed by contractors reasonably acceptable to Landlord and on a sufficient basis to ensure that the Premises are at all times kept neat, clean and free of Hazardous Materials and biohazards except in appropriate, specially marked containers reasonably approved by Landlord.

18.

RULES AND REGULATIONS.  

18.1Rules and Regulations.  Tenant will faithfully observe and comply with the Rules and Regulations attached hereto as Exhibit 9 (“Current Rules and Regulations”)  and reasonable rules and regulations as may be promulgated, from time to time, with respect to the Building, the Property and construction within the Property (collectively, the “Rules and Regulations”).  The Current Rules and Regulations consist of the Building Rules and Regulations attached hereto as Exhibit 9-1 and the Construction Rules and Regulations attached hereto as Exhibit 9-2.  In the case of any conflict between the provisions of this Lease and any future rules and regulations, the provisions of this Lease shall control.  Nothing contained in this Lease shall be construed to impose upon Landlord any duty or obligation to enforce the Rules and Regulations or the terms, covenants or conditions in any other lease as against any other tenant and Landlord shall not be liable to Tenant for violation of the same by any other tenant, its servants, employees, agents, contractors, visitors, invitees or licensees.  

18.2Energy Conservation.  Landlord may institute upon written notice to Tenant such policies, programs and measures as may be necessary, required, or expedient for the conservation and/or preservation of energy or energy services (collectively, the “Conservation Program”), provided however, that the Conservation Program does not, by reason of such policies, programs and measures, materially adversely affect Tenant’s ability to maintain its normal business operations in the Premises, or reduce the level of energy or energy services being provided to the Premises below the level of energy or energy services then being provided in comparable combination laboratory, research and development and office buildings in the vicinity of the Premises, or as may be necessary or required to comply with Legal Requirements or standards or the other provisions of this Lease.  Upon receipt of such notice, Tenant shall comply with the Conservation Program.  

18.3Recycling.  Upon written notice, Landlord may establish policies, programs and measures for the recycling of paper, products, plastic, tin and other materials (a “Recycling Program”).  Upon receipt of such notice, Tenant will comply with the Recycling Program at Tenant’s sole cost and expense.

42


 

19.

LAWS AND PERMITS.  

19.1Legal Requirements.  Tenant shall not cause or permit the Premises, or cause the Property or the Building to be used in any way that violates any Legal Requirement, order, permit, approval, variance, covenant or restrictions of record or any provisions of this Lease, interferes with the rights of tenants of the Building, or constitutes a nuisance or waste.  Tenant shall obtain, maintain and pay for all permits and approvals needed for the operation of Tenant’s business and/or Tenant’s Rooftop Equipment, as soon as reasonably possible, and in any event shall not undertake any operations or use of Tenant’s Rooftop Equipment unless all applicable permits and approvals are in place and shall, promptly take all actions necessary to comply with all Legal Requirements, including, without limitation, the Occupational Safety and Health Act, applicable to Tenant’s use of the Premises, the Property or the Building.  Tenant shall maintain in full force and effect all certifications or permissions required by any authority having jurisdiction to authorize, franchise or regulate Tenant’s use of the Premises.  Tenant shall be solely responsible for procuring and complying at all times with any and all necessary permits and approvals directly or indirectly relating or incident to: the conduct of its activities on the Premises; its scientific experimentation, transportation, storage, handling, use and disposal of any chemical or radioactive or bacteriological or pathological substances or organisms or other hazardous wastes or environmentally dangerous substances or materials or medical waste or animals or laboratory specimens.  Within ten (10) days of a request by Landlord, which request shall be made not more than once during each period of twelve (12) consecutive months during the Term hereof, unless otherwise requested by any mortgagee of Landlord or unless Landlord reasonably suspects that Tenant has violated the provisions of this Section 19.1, Tenant shall furnish Landlord with copies of all such permits and approvals that Tenant possesses or has obtained together with a certificate certifying that such permits are all of the permits that Tenant possesses or has obtained with respect to the Premises.  Tenant shall promptly give written notice to Landlord of any warnings or violations relative to the above received from any federal, state or municipal agency or by any court of law and shall promptly cure the conditions causing any such violations.  Tenant shall not be deemed to be in default of its obligations under the preceding sentence to promptly cure any condition causing any such violation in the event that, in lieu of such cure, Tenant shall contest the validity of such violation by appellate or other proceedings permitted under applicable law, provided that: (i) any such contest is made reasonably and in good faith, (ii) Tenant makes provisions, including, without limitation, posting bond(s) or giving other security, reasonably acceptable to Landlord to protect Landlord, the Building and the Property from any liability, costs, damages or expenses arising in connection with such alleged violation and failure to cure, (iii) Tenant shall agree to indemnify, defend (with counsel reasonably acceptable to Landlord) and hold Landlord harmless from and against any and all liability, costs, damages, or expenses arising in connection with such condition and/or violation, (iv) Tenant shall promptly cure any violation in the event that its appeal of such violation is overruled or rejected, and (v) Tenant’s decision to delay such cure shall not, in Landlord’s good faith determination, be likely to result in any actual or threatened bodily injury, property damage, or any civil or criminal liability to Landlord, any tenant or occupant of the Building or the Property, or any other person or entity.  Nothing contained in this Section 19.1 shall be construed to expand the uses permitted hereunder beyond the Permitted Uses.  Landlord shall comply with any Legal Requirements and with any direction of any public office or officer relating to the maintenance or operation of the structural elements of the Building and the Common Areas, and the costs so incurred by Landlord shall be included in Operating Costs in accordance with the provisions of Section 5.2.

43


 

20.

DEFAULT

20.1Events of Default.  The occurrence of any one or more of the following events shall constitute an “Event of Default” hereunder by Tenant:

(a)If Tenant fails to make any payment of Rent or any other payment required hereunder, as and when due, and such failure shall continue for a period of five (5) days after notice thereof from Landlord to Tenant; provided, however, an Event of Default shall occur hereunder without any obligation of Landlord to give any notice if (i) Tenant fails to make any payment within five (5) days after the due date therefor, and (ii) Landlord has given Tenant written notice under this Section 20.1(a) on more than one (1) occasion during the twelve (12) month interval preceding such failure by Tenant;

(b)If Tenant shall abandon the Premises (meaning that Tenant has ceased operating for normal business purposes in the Premises for a period of thirty (30) consecutive calendar days) (whether or not the keys shall have been surrendered or the Rent shall have been paid);

(c)If Tenant shall fail to execute and deliver to Landlord an estoppel certificate pursuant to Section 16 above or a subordination and attornment agreement pursuant to Section 22 below, within the timeframes set forth therein;

(d)If Tenant shall fail to maintain any insurance required hereunder, and, in the event of the lapse of any of Tenant’s insurance policies required hereunder, Tenant fails to provide Landlord with proof of insurance satisfying the requirements of this Lease within five (5) days after delivery of notice thereof by Landlord;

(e)If Tenant shall fail to restore the Security Deposit to its original amount or deliver a replacement Letter of Credit as required under Section 7 above;

(f)If Tenant causes or suffers any release of Hazardous Materials in or near the Property;

(g)If Tenant shall make a Transfer in violation of the provisions of Section 13 above, or if any event shall occur or any contingency shall arise whereby this Lease, or the Term and estate thereby created, would (by operation of law or otherwise) devolve upon or pass to any person, firm or corporation other than Tenant, except as expressly permitted under Section 13 hereof;

(h)If Tenant shall fail to perform its obligations under Section 3 hereof and such failure continues for more than thirty (30) days after delivery of notice thereof from Landlord;

(i)The failure by Tenant to observe or perform any of the covenants or provisions of this Lease to be observed or performed by Tenant, other than as specified above, and such failure continues for more than thirty (30) days after delivery of notice thereof from Landlord; provided, further, that if the nature of Tenant’s default is such that more than thirty (30) days are reasonably required for its cure, then Tenant shall not be deemed to be in default if Tenant shall commence such cure within said thirty (30) day period and thereafter diligently prosecute such cure to completion, which completion shall occur not later than ninety (90) days from the date of such notice from Landlord;

44


 

(j)Tenant shall be involved in financial difficulties as evidenced by an admission in writing by Tenant of Tenant’s inability to pay its debts generally as they become due, or by the making or offering to make a composition of its debts with its creditors;

(k)Tenant shall make an assignment or trust mortgage, or other conveyance or transfer of like nature, of all or a substantial part of its property for the benefit of its creditors,

(l)an attachment on mesne process, on execution or otherwise, or other legal process shall issue against Tenant or its property and a sale of any of its assets shall be held thereunder;

(m)[intentionally deleted];

(n)the leasehold hereby created shall be taken on execution or by other process of law and shall not be revested in Tenant within thirty (30) days thereafter;

(o)a receiver, sequesterer, trustee or similar officer shall be appointed by a court of competent jurisdiction to take charge of all or any part of Tenant’s Property and such appointment shall not be vacated within thirty (30) days; or

(p)any proceeding shall be instituted by or against Tenant pursuant to any of the provisions of any Act of Congress or State law relating to bankruptcy, reorganizations, arrangements, compositions or other relief from creditors, and, in the case of any proceeding instituted against it, if Tenant shall fail to have such proceedings dismissed within thirty (30) days or if Tenant is adjudged bankrupt or insolvent as a result of any such proceeding; or

20.2Remedies.  Upon an Event of Default, Landlord may, by notice to Tenant, elect to terminate this Lease; and thereupon (and without prejudice to any remedies which might otherwise be available for arrears of Rent or preceding breach of covenant or agreement and without prejudice to Tenant’s liability for damages as hereinafter stated), upon the giving of such notice, this Lease shall terminate as of the date specified therein as though that were the Expiration Date.  Upon such termination, Landlord shall have the right to utilize the Security Deposit or draw down the entire Letter of Credit, as applicable, and apply the proceeds thereof to its damages hereunder.  Without being taken or deemed to be guilty of any manner of trespass or conversion, and without being liable to indictment, prosecution or damages therefor, Landlord may, by lawful process, enter into and upon the Premises (or any part thereof in the name of the whole); repossess the same, as of its former estate; and expel Tenant and those claiming under Tenant.  The words “re-entry” and “re-enter” as used in this Lease are not restricted to their technical legal meanings.

20.3Damages - Termination.  

(a)Upon the termination of this Lease under the provisions of this Section 20, Tenant shall pay to Landlord Rent up to the time of such termination, shall continue to be liable for any preceding breach of covenant, and in addition, shall pay to Landlord as damages, at the election of Landlord, either:

45


 

(i)the amount (discounted to present value at the rate of five percent (5%) per annum) by which, at the time of the termination of this Lease (or at any time thereafter if Landlord shall have initially elected damages under Section 20.3(a)(ii) below), (x) the aggregate of Rent projected over the period commencing with such termination and ending on the Expiration Date, exceeds (y) the aggregate projected rental value of the Premises for such period, taking into account a reasonable time period during which the Premises shall be unoccupied, plus all Reletting Costs (hereinafter defined); or

(ii)amounts equal to Rent which would have been payable by Tenant had this Lease not been so terminated, payable upon the due dates therefor specified herein following such termination and until the Expiration Date, provided, however, if Landlord shall re-let the Premises during such period, that Landlord shall credit Tenant with the net rents received by Landlord from such re-letting, such net rents to be determined by first deducting from the gross rents as and when received by Landlord from such re-letting the expenses incurred or paid by Landlord in terminating this Lease, as well as the expenses of re-letting, including altering and preparing the Premises for new tenants, brokers’ commissions, and all other similar and dissimilar expenses properly chargeable against the Premises and the rental therefrom (collectively, “Reletting Costs”), it being understood that any such re-letting may be for a period equal to or shorter or longer than the remaining Term; and provided, further, that (x) in no event shall Tenant be entitled to receive any excess of such net rents over the sums payable by Tenant to Landlord hereunder and (y) in no event shall Tenant be entitled in any suit for the collection of damages pursuant to this Section 20.3(a)(ii) to a credit in respect of any net rents from a re-letting except to the extent that such net rents are actually received by Landlord prior to the commencement of such suit.  If the Premises or any part thereof should be re-let in combination with other space, then proper apportionment on a square foot area basis shall be made of the rent received from such re-letting and of the expenses of re-letting.

(b)In calculating the amount due under Section 20.3(a)(i), above, there shall be included, in addition to the Base Rent, all other considerations agreed to be paid or performed by Tenant, including without limitation Tenant’s Share of Operating Costs and Taxes, on the assumption that all such amounts and considerations would have increased at the rate of three percent (3%) per annum for the balance of the full term hereby granted.

(c)Suit or suits for the recovery of such damages, or any installments thereof, may be brought by Landlord from time to time at its election, and nothing contained herein shall be deemed to require Landlord to postpone suit until the date when the Term would have expired if it had not been terminated hereunder.

(d)Nothing herein contained shall be construed as limiting or precluding the recovery by Landlord against Tenant of any sums or damages to which, in addition to the damages particularly provided above, Landlord may lawfully be entitled by reason of any Event of Default hereunder.

(e)In lieu of any other damages or indemnity and in lieu of full recovery by Landlord of all sums payable under all the foregoing provisions of this Section 20.3, Landlord may, by written notice to Tenant, at any time after this Lease is terminated as a result of an Event of Default, elect to recover, and Tenant shall thereupon pay, as liquidated damages, an amount

46


 

equal to the aggregate of (x) an amount equal to the lesser of (1) Rent accrued under this Lease in the twelve (12) months immediately prior to such termination, or (2) Rent payable during the remaining months of the Term if this Lease had not been terminated, plus (y) the amount of Rent accrued and unpaid at the time of termination, less (z) the amount of any recovery by Landlord under the foregoing provisions of this Section 20.3 up to the time of payment of such liquidated damages.

20.4Landlord’s Self-Help; Fees and Expenses.  If Tenant shall default in the performance of any covenant on Tenant’s part to be performed in this Lease contained, including without limitation the obligation to maintain the Premises in the required condition pursuant to Section 10.1 above, Landlord may, upon reasonable advance notice, except that no notice shall be required in an emergency, immediately, or at any time thereafter, perform the same for the account of Tenant.  Tenant shall pay to Landlord upon demand therefor any costs incurred by Landlord in connection therewith, together with interest at the Default Rate until paid in full.  In addition, Tenant shall pay all of Landlord’s costs and expenses, including without limitation reasonable attorneys’ fees, incurred (i) in enforcing any obligation of Tenant under this Lease or (ii) as a result of Landlord or any of the Landlord Parties, without its fault, being made party to any litigation pending by or against any of the Tenant Parties.

20.5Waiver of Redemption, Statutory Notice and Grace Periods.  Tenant does hereby waive and surrender all rights and privileges which it might have under or by reason of any present or future Legal Requirements to redeem the Premises or to have a continuance of this Lease for the Term hereby demised after being dispossessed or ejected therefrom by process of law or under the terms of this Lease or after the termination of this Lease as herein provided.  Except to the extent prohibited by Legal Requirements, any statutory notice and grace periods provided to Tenant by law are hereby expressly waived by Tenant.

20.6Remedies Not Exclusive.  The specified remedies to which Landlord and Tenant may respectively resort hereunder are cumulative and are not intended to be exclusive of any remedies or means of redress to which either such party may at any time be lawfully entitled. Landlord may invoke any remedy (including the remedy of specific performance) allowed at law or in equity as if specific remedies were not herein provided for.

20.7No Waiver.  Landlord’s failure to seek redress for violation, or to insist upon the strict performance, of any covenant or condition of this Lease, or any of the Rules and Regulations promulgated hereunder, shall not prevent a subsequent act, which would have originally constituted a violation, from having all the force and effect of an original violation.  The receipt by Landlord of Rent with knowledge of the breach of any covenant of this Lease shall not be deemed a waiver of such breach.  The failure of Landlord to enforce any of such Rules and Regulations against Tenant and/or any other tenant in the Building shall not be deemed a waiver of any such Rules and Regulations.  No provisions of this Lease shall be deemed to have been waived by either party unless such waiver be in writing signed by such party.  No payment by Tenant or receipt by Landlord of a lesser amount than the Rent herein stipulated shall be deemed to be other than on account of the stipulated Rent, nor shall any endorsement or statement on any check or any letter accompanying any check or payment as Rent be deemed an accord and satisfaction, and Landlord may accept such check or payment without prejudice to Landlord’s right to recover the balance of such Rent or pursue any other remedy in this Lease provided.

47


 

20.8[Intentionally Deleted].  

20.9Landlord Default.  Notwithstanding anything to the contrary contained in the Lease, Landlord shall in no event be in default in the performance of any of Landlord’s obligations under this Lease unless Landlord shall have failed to perform such obligations within thirty (30) days (or such additional time as is reasonably required to correct any such default, provided Landlord commences cure within 30 days) after notice by Tenant to Landlord properly specifying wherein Landlord has failed to perform any such obligation.  Except as expressly set forth in this Lease, Tenant shall not have the right to terminate or cancel this Lease or to withhold rent or to set-off or deduct any claim or damages against rent as a result of any default by Landlord or breach by Landlord of its covenants or any warranties or promises hereunder, except in the case of a wrongful eviction of Tenant from the Premises (constructive or actual) by Landlord, and then only if the same continues after notice to Landlord thereof and an opportunity for Landlord to cure the same as set forth above.  In addition, Tenant shall not assert any right to deduct the cost of repairs or any monetary claim against Landlord from rent thereafter due and payable under this Lease, except in the case of a wrongful eviction of Tenant from the Premises (constructive or actual) by Landlord, and then only if the same continues after notice to Landlord thereof and an opportunity for Landlord to cure the same as set forth above.

21.

SURRENDER; ABANDONED PROPERTY; HOLD-OVER

21.1Surrender

(a)Upon the expiration or earlier termination of the Term, Tenant shall (i) peaceably quit and surrender to Landlord the Premises (including without limitation all fixed lab benches, fume hoods, electric, plumbing, heating and sprinkling systems, fixtures and outlets, vaults, paneling, molding, shelving, radiator enclosures, cork, rubber, linoleum and composition floors, ventilating, silencing, air conditioning and cooling equipment therein and all other furniture, fixtures, and equipment that was either provided by Landlord or paid for in whole or in part by any allowance provided to Tenant by Landlord under this Lease) broom clean, in good order, repair and condition excepting only ordinary wear and tear and damage by fire or other insured Casualty; (ii) remove all of Tenant’s Property, all autoclaves and cage washers and, to the extent specified by Landlord, Alterations made by Tenant, including without limitation Tenant’s vivarium; and (iii) repair any damages to the Premises or the Building caused by Tenant’s installation or Tenant’s removal of Tenant’s Property and/or such Alterations.  Tenant’s obligations under this Section 21.1(a) shall survive the expiration or earlier termination of this Lease, subject to any applicable statute of limitations.

(b)Prior to the expiration of this Lease (or within thirty (30) days after any earlier termination), Tenant shall clean and otherwise decommission all interior surfaces (including floors, walls, ceilings, and counters), piping, supply lines, waste lines, acid neutralization systems and plumbing in and/or exclusively serving the Premises, and all exhaust or other ductwork in and/or exclusively serving the Premises, in each case which has carried or released or been contacted by any Hazardous Materials or other chemical or biological materials used in the operation of the Premises, and shall otherwise clean the Premises so as to permit the Surrender Plan (defined below) to be issued.  At least thirty (30) days prior to the expiration of the Term (or, if applicable, within five (5) business days after any earlier termination of this Lease),

48


 

Tenant shall deliver to Landlord a reasonably detailed narrative description of the actions proposed (or required by any Legal Requirements) to be taken by Tenant in order to render the Premises (including any Alterations permitted or required by Landlord to remain therein) free of Hazardous Materials and otherwise released for unrestricted use and occupancy including without limitation causing the Premises to be decommissioned in accordance with the regulations of the U.S. Nuclear Regulatory Commission and/or the Massachusetts Department of Public health (the “MDPH”) for the control of radiation, and cause the Premises to be released for unrestricted use by the Radiation Control Program of the MDPH (the “Surrender Plan”).  The Surrender Plan (i) shall be accompanied by a current list of (A) all Required Permits held by or on behalf of any Tenant Party with respect to Hazardous Materials in, on, under, at or about the Premises, and (B) Tenant’s Hazardous Materials, and (ii) shall be subject to the review and approval of Landlord’s environmental consultant.  In connection with review and approval of the Surrender Plan, upon request of Landlord, Tenant shall deliver to Landlord or its consultant such additional non-proprietary information concerning the use of and operations within the Premises as Landlord shall request.  On or before the expiration of the Term (or within thirty (30) days after any earlier termination of this Lease, during which period Tenant’s use and occupancy of the Premises shall be governed by Section 21.3 below), Tenant shall (i) perform or cause to be performed all actions described in the approved Surrender Plan, and (ii) deliver to Landlord a certification from a third party certified industrial hygienist reasonably acceptable to Landlord certifying that the Premises do not contain any Hazardous Materials and evidence that the approved Surrender Plan shall have been satisfactorily completed by a contractor acceptable to Landlord, and Landlord shall have the right, subject to reimbursement at Tenant’s expense as set forth below, to cause Landlord’s environmental consultant to inspect the Premises and perform such additional procedures as may be deemed reasonably necessary to confirm that the Premises are, as of the expiration of the Term (or, if applicable, the date which is thirty (30) days after any earlier termination of this Lease), free of Hazardous Materials and otherwise available for unrestricted use and occupancy as aforesaid.  Landlord shall have the unrestricted right to deliver the Surrender Plan and any report by Landlord’s environmental consultant with respect to the surrender of the Premises to third parties.   Such third parties and the Landlord Parties shall be entitled to rely on the Surrender Report.  If Tenant shall fail to prepare or submit a Surrender Plan approved by Landlord, or if Tenant shall fail to complete the approved Surrender Plan, or if such Surrender Plan, whether or not approved by Landlord, shall fail to adequately address the use of Hazardous Materials by any of the Tenant Parties in, on, at, under or about the Premises, Landlord shall have the right to take any such actions as Landlord may deem reasonable or appropriate to assure that the Premises and the Property are surrendered in the condition required hereunder, the cost of which actions shall be reimbursed by Tenant as Additional Rent upon demand.  Tenant’s obligations under this Section 21.1(b) shall survive the expiration or earlier termination of the Term.

(c)No act or thing done by Landlord during the Term shall be deemed an acceptance of a surrender of the Premises, and no agreement to accept such surrender shall be valid, unless in writing signed by Landlord.  Unless otherwise agreed by the parties in writing, no employee of Landlord or of Landlord’s agents shall have any power to accept the keys of the Premises prior to the expiration or earlier termination of this Lease.  The delivery of keys to any employee of Landlord or of Landlord’s agents shall not operate as a termination of this Lease or a surrender of the Premises.  

49


 

(d)Notwithstanding anything to the contrary contained herein, Tenant shall, at its sole cost and expense, remove from the Premises, prior to the end of the Term, any item installed by or for Tenant and which, pursuant to Legal Requirements, must be removed therefrom before the Premises may be used by a subsequent tenant.

21.2Abandoned Property.  Subject to the Consent to Removal of Personal Property attached hereto as Exhibit 12 (“Consent to Removal”), after the expiration or earlier termination hereof, if Tenant fails to remove any property from the Building or the Premises which Tenant is obligated by the terms of this Lease to remove within five (5) business days after written notice from Landlord, such property (the “Abandoned Property”) shall be conclusively deemed to have been abandoned, and may either be retained by Landlord as its property or sold or otherwise disposed of in such manner as Landlord may see fit, except as otherwise set forth in said Consent to Removal.  If any item of Abandoned Property shall be sold, Tenant hereby agrees that Landlord may receive and retain the proceeds of such sale and apply the same, at its option, to the expenses of the sale, the cost of moving and storage, any damages to which Landlord may be entitled under Section 20 hereof or pursuant to law, and to any arrears of Rent.

21.3Holdover.  If any of the Tenant Parties holds over (which term shall include, without limitation, the failure of Tenant or any Tenant Party to perform all of its obligations under Section 21.1 above) after the end of the Term, Tenant shall be deemed a tenant-at-sufferance subject to the provisions of this Lease; provided that whether or not Landlord has previously accepted payments of Rent from Tenant, (i) for the first sixty (60) days of any such holding over, Tenant shall pay Base Rent at 150% of the highest rate of Base Rent payable during the Term, and thereafter, Tenant shall pay Base Rent at 200% of the highest rate of Base Rent payable during the Term, (ii) Tenant shall continue to pay to Landlord all Additional Rent, and (iii) Tenant shall be liable for all damages, including without limitation lost business and consequential damages, incurred by Landlord as a result of such holding over, Tenant hereby acknowledging that Landlord may need the Premises after the end of the Term for other tenants and that the damages which Landlord may suffer as the result of Tenant’s holding over cannot be determined as of the Execution Date.  Nothing contained herein shall grant Tenant the right to holdover after the expiration or earlier termination of the Term.

21.4Warranties.  Tenant hereby assigns to Landlord any warranties in effect on the last day of the Term with respect to any fixtures and Alterations installed in the Premises.  Tenant shall provide Landlord with copies of any such warranties prior to the expiration of the Term (or, if the Lease is earlier terminated, within five (5) days thereafter).

22.

MORTGAGEE RIGHTS

22.1Subordination. Tenant’s rights and interests under this Lease shall be (i) subject and subordinate to any ground lease, overleases, mortgage, deed of trust, or similar instrument covering the Premises, the Building and/or the Land and to all advances, modifications, renewals, replacements, and extensions thereof (each of the foregoing, a “Mortgage”), or (ii) if any Mortgagee elects, prior to the lien of any present or future Mortgage.  Tenant further shall attorn to and recognize any successor landlord, whether through foreclosure or otherwise, as if the successor landlord were the originally named landlord.  The provisions of this Section 22.1 shall be self-operative and no further instrument shall be required to effect such subordination or attornment; however, Tenant agrees to execute, acknowledge and deliver such instruments, confirming such subordination and attornment in such form as shall be requested by any such holder within fifteen (15) days of request therefor.

50


 

22.2Notices.  Tenant shall give each Mortgagee the same notices given to Landlord concurrently with the notice to Landlord, and each Mortgagee shall have a reasonable opportunity thereafter to cure a Landlord default, and Mortgagee’s curing of any of Landlord’s default shall be treated as performance by Landlord.

22.3Mortgagee Consent.  Tenant acknowledges that, where applicable, any consent or approval hereafter given by Landlord may be subject to the further consent or approval of a Mortgagee; and the failure or refusal of such Mortgagee to give such consent or approval shall, notwithstanding anything to the contrary in this Lease contained, constitute reasonable justification for Landlord’s withholding its consent or approval.

22.4Mortgagee Liability.  Tenant acknowledges and agrees that if any Mortgage shall be foreclosed, (a) the liability of the Mortgagee and its successors and assigns shall exist only so long as such Mortgagee or purchaser is the owner of the Premises, and such liability shall not continue or survive after further transfer of ownership; and (b) such Mortgagee and its successors or assigns shall not be (i) liable for any act or omission of any prior lessor under this Lease; (ii) liable for the performance of Landlord’s covenants pursuant to the provisions of this Lease which arise and accrue prior to such entity succeeding to the interest of Landlord under this Lease or acquiring such right to possession; (iii) subject to any offsets or defense which Tenant may have at any time against Landlord; (iv) bound by any base rent or other sum which Tenant may have paid previously for more than one (1) month; or (v) liable for the performance of any covenant of Landlord under this Lease which is capable of performance only by the original Landlord.

23.

QUIET ENJOYMENT.  

Landlord covenants that so long as Tenant keeps and performs each and every covenant, agreement, term, provision and condition herein contained on the part and on behalf of Tenant to be kept and performed, Tenant shall peaceably and quietly hold, occupy and enjoy the Premises during the Term from and against the claims of all persons lawfully claiming by, through or under Landlord subject, nevertheless, to the covenants, agreements, terms, provisions and conditions of this Lease, any matters of record or of which Tenant has knowledge and to any Mortgage to which this Lease is subject and subordinate, as hereinabove set forth.

51


 

24.

NOTICES.  

Any notice, consent, request, bill, demand or statement hereunder (each, a “Notice”) by either party to the other party shall be in writing and shall be deemed to have been duly given when either delivered by hand or by nationally recognized overnight courier (in either case with evidence of delivery or refusal thereof) addressed as follows:  

If to Landlord:

HCP/King Hayden Campus LLC.

c/o King Street Properties

800 Boylston Street, Suite 1570

Boston, MA  02199

Attention:  Stephen D. Lynch

With a copy to:

Goulston & Storrs PC

400 Atlantic Avenue  

Boston, MA 02110

Attention:  King Street

if to Tenant:

Prior to the Term Commencement Date:

Matthias Jaffé | CFO

LogicBio Therapeutics

99 Erie Street

Cambridge, MA 02139

 

From and after the Term Commencement Date:

Matthias Jaffé | CFO

LogicBio Therapeutics

65 Hayden Avenue

Lexington, MA 02421

 

With a copy to:

James Duberman, Esq.

Outside GC LLC

501 Boylston Street, 10th Floor

Boston, MA 02116

 

Notwithstanding the foregoing, any notice from Landlord to Tenant regarding ordinary business operations (e.g., exercise of a right of access to the Premises, maintenance activities, invoices, etc.) may also be given by written notice delivered by electronic mail or facsimile to Tenant’s designated representative in lieu of delivering copies as specified above, Tenant hereby designating Matthias Jaffé (e-mail: mjaffe@logicbio.com) as its designated representative for the purposes of this Section 24.  Either party may at any time change the address or specify an additional address for such Notices by delivering or mailing, as aforesaid, to the other party a notice stating the change and setting forth the changed or additional address, provided such changed or additional address is within the United States.  Notices shall be effective upon the date of receipt or refusal thereof.

52


 

25.

MISCELLANEOUS

25.1Separability.  If any provision of this Lease or portion of such provision or the application thereof to any person or circumstance is for any reason held invalid or unenforceable, the remainder of this Lease (or the remainder of such provision) and the application thereof to other persons or circumstances shall not be affected thereby.

25.2Captions.  The captions are inserted only as a matter of convenience and for reference, and in no way define, limit or describe the scope of this Lease nor the intent of any provisions thereof.

25.3Broker. Tenant and Landlord each warrants and represents that it has dealt with no broker in connection with the consummation of this Lease other than Jones Lang LaSalle and Newmark Knight Frank (collectively, “Broker”). Tenant and Landlord each agrees to defend, indemnify and save the other harmless from and against any Claims arising in breach of the representation and warranty set forth in the immediately preceding sentence.  Landlord shall be solely responsible for the payment of any brokerage commissions to Broker.

25.4Entire Agreement. This Lease, Lease Summary Sheet and Exhibits 1-12 attached hereto and incorporated herein contain the entire and only agreement between the parties and any and all statements and representations, written and oral, including previous correspondence and agreements between the parties hereto, are merged herein.  Tenant acknowledges that all representations and statements upon which it relied in executing this Lease are contained herein and that Tenant in no way relied upon any other statements or representations, written or oral. This Lease may not be modified orally or in any manner other than by written agreement signed by the parties hereto.

25.5Governing Law.  This Lease is made pursuant to, and shall be governed by, and construed in accordance with, the laws of the Commonwealth of Massachusetts and any applicable local municipal rules, regulations, by-laws, ordinances and the like.

25.6Representation of Authority.  By his or her execution hereof, each of the signatories on behalf of the respective parties hereby warrants and represents to the other that he or she is duly authorized to execute this Lease on behalf of such party. Upon Landlord’s request, Tenant shall provide Landlord with evidence that any requisite resolution, corporate authority and any other necessary consents have been duly adopted and obtained.

25.7Expenses Incurred by Landlord Upon Tenant Requests.  Tenant shall, upon demand, reimburse Landlord for all reasonable expenses, including, without limitation, legal fees, incurred by Landlord in connection with all requests by Tenant for consents or approvals related to this Lease, including, without limitation, costs incurred by Landlord in the review and approval of Tenant’s plans and specifications in connection with proposed Alterations to be made by Tenant to the Premises or in connection with requests by Tenant for Landlord’s consent to make a Transfer.  Such costs shall be deemed to be Additional Rent under this Lease.

53


 

25.8Survival.  Without limiting any other obligation of Tenant which may survive the expiration or prior termination of the Term, all obligations on the part of Tenant to indemnify, defend, or hold Landlord harmless, as set forth in this Lease shall survive the expiration or prior termination of the Term.

25.9Limitation of Liability.  Tenant shall neither assert nor seek to enforce any claim against Landlord or any of the Landlord Parties, or the assets of any of the Landlord Parties, for breach of this Lease or otherwise, other than against Landlord’s interest in the Building and in the uncollected rents, issues and profits thereof, and Tenant agrees to look solely to such interest for the satisfaction of any liability of Landlord under this Lease.  This Section 25.9 shall not limit any right that Tenant might otherwise have to obtain injunctive relief against Landlord.  Landlord and Tenant specifically agree that in no event shall any officer, director, trustee, employee or representative of Landlord or any of the other Landlord Parties ever be personally liable for any obligation under this Lease, nor shall Landlord or any of the other Landlord Parties be liable for consequential or incidental damages or for lost profits whatsoever in connection with this Lease.

25.10Binding Effect.  The covenants, agreements, terms, provisions and conditions of this Lease shall bind and benefit the successors and assigns of the parties hereto with the same effect as if mentioned in each instance where a party hereto is named or referred to, except that no violation of the provisions of Section 13 hereof shall operate to vest any rights in any successor or assignee of Tenant.

25.11Landlord Obligations upon Transfer.  Upon any sale, transfer or other disposition of the Building, Landlord shall be entirely freed and relieved from the performance and observance thereafter of all covenants and obligations hereunder on the part of Landlord to be performed and observed, it being understood and agreed in such event (and it shall be deemed and construed as a covenant running with the land) that the person succeeding to Landlord’s ownership of said reversionary interest shall thereupon and thereafter assume, and perform and observe, any and all of such covenants and obligations of Landlord, except as otherwise agreed in writing.

25.12No Grant of Interest.  Tenant shall not grant any interest whatsoever in any fixtures within the Premises or any item paid in whole or in part by Landlord’s Contribution or by Landlord.

25.13Financial Information.  Tenant shall deliver to Landlord, within thirty (30) days after Landlord’s reasonable request, Tenant’s most recently completed balance sheet and related statements of income, shareholder’s equity and cash flows statements (audited if available) reviewed by an independent certified public accountant and certified by an officer of Tenant as being true and correct in all material respects for the sole purposes of the sale or refinance of this Property.  Any such financial information may be relied upon by any actual or potential ground lessor, purchaser, or mortgagee of the Property or any portion thereof.

25.14OFAC Certificate and Indemnity.  Executive Order No. 13224 on Terrorist Financing, effective September 24, 2001 (the “Executive Order”), and the Uniting and Strengthening America by Providing Appropriate Tools Required to Intercept and Obstruct Terrorism Act of 2001 (Public Law 10756, the “Patriot Act”) prohibit certain property transfers.  Tenant hereby represents and warrants to Landlord (which representations and warranties shall be

54


 

deemed to be continuing and re-made at all times during the Term) that neither Tenant nor any stockholder, manager, beneficiary, partner, or principal of Tenant is subject to the Executive Order, that none of them is listed on the United States Department of the Treasury Office of Foreign Assets Control (“OFAC”) list of “Specially Designated Nationals and Blocked Persons” as modified from time to time, and that none of them is otherwise subject to the provisions of the Executive Order or the Patriot Act.  The most current list of “Specially Designated Nationals and Blocked Persons” can be found at http://www.treas.gov/offices/eotffc/ofac/sdn/index.html.  Tenant shall from time to time, within ten days after request by Landlord, deliver to Landlord any certification or other evidence requested from time to time by Landlord in its reasonable discretion, confirming Tenant’s compliance with these provisions.  No assignment or subletting shall be effective unless and until the assignee or subtenant thereunder delivers to Landlord written confirmation of such party’s compliance with the provisions of this subsection, in form and content satisfactory to Landlord.  If for any reason the representations and warranties set forth in this subsection, or any certificate or other evidence of compliance delivered to Landlord hereunder, is untrue in any respect when made or delivered, or thereafter becomes untrue in any respect, then an Event of Default hereunder shall be deemed to occur immediately, and there shall be no opportunity to cure.  Tenant shall indemnify, defend with counsel reasonably acceptable to Landlord, and hold Landlord harmless from and against, any and all liabilities, losses claims, damages, penalties, fines, and costs (including attorneys’ fees and costs) arising from or related to the breach of any of the foregoing representations, warranties, and duties of Tenant.  The provisions of this subsection shall survive the expiration or earlier termination of this Lease for the longest period permitted by law.

25.15Confidentiality.  Tenant acknowledges and agrees that the terms of this Lease are confidential.  Disclosure of the terms hereof could adversely affect the ability of Landlord to negotiate other leases with respect to the Building and may impair Landlord’s relationship with other tenants of the Building.  Tenant agrees that it and its partners, officers, directors, employees, brokers, and attorneys, if any, shall not disclose the terms and conditions of this Lease to any other person or entity without the prior written consent of Landlord which may be given or withheld by Landlord, in Landlord’s sole discretion, except as required for financial disclosures or securities filings, as required by the order of any court or public body with authority over Tenant, or in connection with any litigation between Landlord and Tenant with respect this Lease.  It is understood and agreed that damages alone would be an inadequate remedy for the breach of this provision by Tenant, and Landlord shall also have the right to seek specific performance of this provision and to seek injunctive relief to prevent its breach or continued breach.

25.16Force Majeure.  Other than for Tenant’s obligations under this Lease that can be performed by the payment of money (e.g., payment of Rent and maintenance of insurance), whenever a period of time is herein prescribed for action to be taken by either party hereto, such party shall not be liable or responsible for, and there shall be excluded from the computation of any such period of time, any delays due to strikes, riots, acts of God, shortages of labor or materials, war, acts of terrorism, governmental laws, regulations, or restrictions, or any other causes of any kind whatsoever which are beyond the control of such party (collectively “Force Majeure”).  In no event shall financial inability of a party be deemed to be Force Majeure.

 

[SIGNATURES ON FOLLOWING PAGE]

 

 

55


 

IN WITNESS WHEREOF the parties hereto have executed this Lease as a sealed instrument as of the Execution Date.

LANDLORD

HCP/KING HAYDEN CAMPUS LLC,

a Delaware limited liability company

By:

King Mattingly LLC, a Massachusetts limited

 

 

liability company, its Manager

 

 

               

By:

King Street Properties Investments LLC, a

 

 

Massachusetts limited liability company, its Manager

 

 

 

 

 

 

 

 

By:

 

 

 

 

Name:

 

 

 

Its Manager

 

 

 

 

 

 

TENANT

LOGICBIO THERAPEUTICS, INC.,
a Delaware corporation

By:

 

 

 

Name:

 

 

 

Title:

 

 

 

 

 

 

56


 

EXHIBIT 1A

LEASE PLAN – PRIME PREMISES

 

 

Exhibit 1A, Page 1


 

EXHIBIT 1B

LEASE PLAN – PH SYSTEM PREMISES


Exhibit 1B, Page 1


 

EXHIBIT 1C

TENANT’S ROOFTOP PREMISES

2


 

EXHIBIT 2

LEGAL DESCRIPTION - LAND

Real property in the Town of Lexington, County of Middlesex, Commonwealth of Massachusetts, described as follows:

Parcel One (45 & 55 Hayden Avenue):

A certain parcel of land in the Commonwealth of Massachusetts, County of Middlesex, Town of Lexington, and shown as Lot 2 on a plan entitled “Plan of Land in Lexington, Mass. (Middlesex County),” dated March 27, 1998, recorded October 6, 1998, with Middlesex South Registry of Deeds as Plan No. 1088 of 1998 in Book 29190, Page 447, prepared by Beals and Thomas, Inc., more particularly bounded and described as follows:

Beginning at the most southwesterly corner of the premises, at the southeasterly corner of Lot 1 as shown on said plan, then running:

N 02° 20’ 56” E 180.68 feet to a point, thence turning and running;

N 87° 39” 04” W 40.00 feet to a point, thence turning and running;

N 02° 20’ 56” E 122.19 feet to a point, thence turning and running;

N 87° 39’ 04” E 40.00 feet to a point, thence turning and running;

N 02° 20’ 56” E 547.13 feet to a point, thence turning and running, said last five courses being bounded by Lot 1, as shown on said plan, thence turning and running;

S 87° 36’ 20” E 1,330.04 feet to a point of curvature, thence running;

Northeasterly to a curve to the left having a radius of 135.00 feet and a length of 58.90 feet to a point of tangency, thence running;

N 67° 23’ 52” E 146.89 feet to a point, thence turning and running;

S 03° 52’ 06” E 111.25 feet to a point, said last four courses being bounded by land now or formerly of the Town of Lexington, thence turning and running;

S 44° 07’ 54 W 561.19 feet to a point, thence turning and running;

S 22° 29’ 38” E 435.76 feet to a point, said last two courses are bounded in part by land now or formerly the Town of Lexington and, in part now or formerly of Hayden Office Trust, thence running;

Southwesterly by a curve to the right, having a radius of 985.00 feet and a length of 12.11 feet to a point of tangency, thence turning and running;

Exhibit 2, Page 1


 

N 87° 36’ 20” W 1,329.27 feet to the point of beginning, said last two courses being bounded by the northerly sideline of Hayden Avenue.

Containing 1,123,722 square feet more or less, or 25.797 acres, more or less.

A portion of said Lot 2 is registered land, described as follows:

Lot 293 on Land Court Plan 19485 N as approved by the Land Court and filed in the Land Registration Office; and

Lots 10 and 11 on Land Court Plan 16660 O as approved by the Land Court and filed with the Land Registration Office.

Parcel Two (Appurtenant Easements - 45 & 55 Hayden Avenue):

A.

There is appurtenant to the above described Lot 11 the right and easement to use the drainage ditch running from west to east across the northerly portion of Lot 10, shown on said plan, as set forth in Registered Document No. 517903.

B.

There is appurtenant to the above described Lot 11 rights and easements for sewer purposes as set forth in Registered Document No. 479201.

C.

There is appurtenant to said Lot 293 the benefits of the agreement and reservation as to trunk sewer more particularly set forth in deed filed as Document No. 479738.

D.

Lot 10 has the benefit of a reservation in the strip of land marked sewer easement as shown on said plan, set forth in Document 517903 and the rights and easements for sewer purposes as set forth in Registered Document No. 479201, insofar as applicable.

E.

Together with the benefit of the appurtenant easements over Lot B shown on plan entitled “A Compiled Plan of Land in Lexington, Mass.” Dated August 27, 1970, by John J. McSweeney, recorded with Middlesex South District Deeds in Book 11928, Page 614, as shown on said plan, as reserved in a taking by the Town of Lexington dated November 30, 1970, recorded with said Deeds in Book 11928, Page 611, and in a deed from George H. Crawford to the Town of Lexington of the said Lot B dated December 7, 1970, recorded with said Deeds in Book 11928, Page 614.

F.

Together with the benefit of the appurtenant easements set forth in Declaration of Covenants and Easements dated September 18, 1998 filed as Document No. 1084070 and recorded in Book 29287, Page 189; as affected by Amended and Restated Declaration of Covenants and Easements dated November 8, 1999, filed as Document No. 1123738, and recorded in Book 30855, Page 323; as affected by First Amendment to Amended and Restated Declaration of Covenants and Easements dated March 26, 2002, filed as Document No. 1261521, recorded in Book 37256, Page 364.

Exhibit 2, Page 3


 

Parcel Three (65 Hayden Avenue):

That certain parcel of land situate in Lexington in the County of Middlesex and Commonwealth of Massachusetts shown as Lot 292 on Land Court Plan No. 19485-N.

All of said boundaries are determined by the Court to be located as shown on a subdivision plan, as approved by the Court, filed in the Land Registration Office, a copy of which is filed in the Registry of Deeds for the South Registry District of Middlesex County in Registration Book 1178 Page 11.

Parcel Four (Appurtenant Easements - 65 Hayden Avenue):

There is appurtenant to said Lot 292 the right to use the whole of Grassland Street and Valleyfield Street as shown on the plan Registered in the Registration Book 383 Page 149 in common with others entitled thereto; the right to use all streets or roads as shown on the plan Registered in Registration Book 506 Page 153, in common with all others legally entitled thereto; the benefit of the agreement and reservation as to trunk sewer more particularly set forth in the deed Registered as Document No. 479738; and the benefit of the appurtenant easements set forth in Declaration of Covenants and Easements dated September 18, 1998 filed as Document No. 1084070 and recorded in Book 29287, Page 189; as affected by Amended and Restated Declaration of Covenants and Easements dated November 8, 1999, filed as Document No. 1123738, and recorded in Book 30855, Page 323; as affected by First Amendment to Amended and Restated Declaration of Covenants and Easements dated March 26, 2002, filed as Document No. 1261521, recorded in Book 37256, Page 364

 

 

Exhibit 2, Page 3


 

EXHIBIT 3

Intentionally Deleted

 

 

Exhibit 3, Page 1


 

EXHIBIT 4

WORK LETTER

This Exhibit is attached to and made a part of the Lease (the “Lease”) by and between HCP/KING HAYDEN CAMPUS LLC, a Delaware limited liability company (“Landlord”), and LOGICBIO THERAPEUTICS, INC., a Delaware corporation (“Tenant”), for space located at 65 Hayden Avenue, Lexington, Massachusetts.  Capitalized terms used but not defined herein shall have the meanings given in the Lease.

This Work Letter shall set forth the obligations of Landlord and Tenant with respect to the improvements to be performed in preparing the Premises for Tenant’s use.  This Exhibit shall not be deemed applicable to any additional space added to the Premises at any time or from time to time, whether by any options under the Lease or otherwise, or to any portion of the original Premises or any additions to the Premises in the event of a renewal or extension of the original Term of the Lease, whether by any options under the Lease or otherwise, unless expressly so provided in the Lease or any amendment or supplement to the Lease.

1.

Definitions.  This Work Letter shall set forth the obligations of Landlord and Tenant with respect to the improvements to be performed in the Premises for Tenant’s use.  For the purposes of this Lease, “Landlord’s Work” consists of: (i) the Base Building Work described on Exhibit 4-1, and (ii) the Tenant Improvement Work, as hereinafter defined. The “Tenant Improvement Work” shall mean all of the work to be performed by Landlord in preparing the Premises for Tenant’s occupancy as shown on the Construction Documents (as hereinafter defined), excluding any Base Building Work, and shall also consist of the construction of the Tenant’s vivarium in accordance with the Construction Documents (the “Vivarium Work”).  The parties intend that Tenant Improvement Work will be in accordance with construction documents (the “Construction Documents”) prepared by Landlord and approved by Tenant in accordance with this Exhibit 4, and the Construction Documents will be based upon the schematic plan (“Initial Plan”) attached hereto as Exhibit 4-2, and the equipment list (“Equipment List”) attached hereto as Exhibit 4-3.  The “Cost of Tenant Improvement Work” shall be defined as all hard costs (“Hard Costs”) incurred by Landlord relating to the performance of the Tenant Improvement Work (including, without limitation, the cost of obtaining permits and any applicable state sales and use taxes) and soft costs (“Soft Costs”) incurred by Landlord in connection with the Tenant Improvement Work (including, without limitation, the cost of preparing Construction Documents).  Landlord will charge Tenant a construction management fee equal to 3% of all Hard Costs payable by Tenant in connection with the Tenant Improvement Work.  The items listed on Exhibit 4-1 as “Tenant Responsibility” (“Tenant’s Work”) shall be performed by Tenant, at Tenant’s sole cost and expense.  

2.

Contractor; GMP.  Landlord shall enter into a contract (“Contract”) for the Tenant Improvement Work with BW Kennedy (“Contractor”).  The Contract may be on the basis of a guaranteed maximum price (“GMP”).  

3.

Preparation of Construction Documents.  The Contractor and/or Landlord shall engage RE Dineen as subconsultants to prepare the Construction Documents for Tenant’s approval, which approval shall not be unreasonably withheld, conditioned, or delayed.

Exhibit 4, Page 1


 

4.

Tenant Responses.  Tenant shall respond, in writing, to any requests from Landlord or the Contractor for information, consents, or authorizations to proceed, within two (2) business days of Tenant’s receipt of such request.  Tenant shall respond within any designated period of time set forth in the estimated construction schedule attached hereto as Exhibit 4-4 and otherwise cooperate with Landlord to achieve such construction schedule.  Any failure by Tenant to respond within such time period may be the basis of a Tenant Delay.

5.

Tenant shall have the right to hire a mutually approved Tenant Construction Representative to oversee all required construction relative to the Tenant Premises.

6.

Bid Process.  Tenant hereby acknowledges that:

 

(i)

the Contractor will receive a single bid for each of the following portions of Landlord’s Work from the designated subcontractors (“Designated Subcontractors”) listed below who will perform such portions of Landlord’s Work:

 

Mechanical/HVAC:  Environmental Systems, Inc.

 

Plumbing:  North Shore Mechanical Contractors, Inc.

 

Fire Protection:  Legacy Fire Protection, Inc.

 

Electrical:   Nappa Electric, Inc.

 

(ii)

Landlord will cause the Contractor to use reasonable efforts to obtain at least three (3) bidders for other portions of Landlord’s Work; however, given the current market, it may not be possible to obtain more than one or two bidders with respect to portions of Landlord’s Work.

Tenant shall have the right to review the revised GMP within three (3) business days after receipt thereof.  

7.

Changes.  If Tenant shall request any change, addition or alteration to the scope of work set forth on the Initial Plan and in Exhibit 4-1 or in any of the Plans after approval by Landlord (“Changes”), Landlord shall have such revisions to the drawings prepared.  Promptly upon completion of the revisions, Landlord shall notify Tenant in writing of the increased cost, if any, which will be chargeable to Tenant by reason of such change, addition or deletion.  Tenant, within three (3) business days, shall notify Landlord in writing whether it desires to proceed with such Change.  In the absence of such written authorization, Landlord shall have the option to continue design of and work on the Premises disregarding the requested Change.  Tenant shall reimburse Landlord for the Cost of Tenant Improvement Work associated with such Changes and for the design cost associated with the preparation of the revised Plans or Construction Documents within thirty (30) days of upon Billing, as such Change Work is being performed.  In addition, to the extent any Tenant Delay result in an increase in the Cost of Tenant Improvement Work, if any, Tenant shall reimburse Landlord for such increased cost within thirty (30) days of upon Billing.  “Billing” shall be defined as any invoice from Landlord setting forth, reasonable detail, the amount due from Tenant, and shall include invoices from vendors and service providers, and, if applicable, applications for payment from the Contractor for work completed through the date of Billing, as certified by the Contractor.  Billing may not be submitted to Tenant more than one time per calendar month.  The amounts payable by Tenant hereunder constitute Rent payable pursuant to the Lease, and the failure to timely pay same constitutes an event of default under the Lease.

Exhibit 4, Page 2


 

8.

Claims.  To the extent that any claims (“Claims”) by the Contractor cause an increase in the Cost of Tenant Improvement Work, Tenant shall pay for such excess within thirty (30) days of Billing. Claims shall include any amounts properly due to the Contractor under the Contract based upon the claims of the Contractor under the Contract, provided however, that the Claims shall not include any amounts arising from the default or negligence of Landlord, or Landlord’s agents or employees, under the Contract.

9.

Performance of Landlord’s Work.  Following approval of the Construction Documents and Tenant’s written authorization to proceed with Tenant Improvement Work, Landlord shall cause the Tenant Improvement Work to be constructed in all material respects in accordance with the approved Construction Documents and at Landlord’s sole cost and expense, except as otherwise expressly set forth herein.  

10.

Miscellaneous

(a)

Tenant’s Authorized Representative.  Tenant designates Matthias Jaffé (email: mjaffe@logicbio.com, telephone 617-959-7425; “Tenant’s Representative”) as the only person authorized to act for Tenant pursuant to this Work Letter.  Landlord shall not be obligated to respond to or act upon any request, approval, inquiry or other communication (“Communication”) from or on behalf of Tenant in connection with this Work Letter unless such Communication is in writing from Tenant’s Representative.  Tenant may change either Tenant’s Representative at any time upon not less than five (5) business days advance written notice to Landlord.  

(b)

Landlord’s Authorized Representative.  Landlord designates Brian Grisaru (email: bgrisaru@ks-prop.com, telephone 617-910-5033; “Landlord’s Representative”) as the only person authorized to act for Landlord pursuant to this Work Letter.  Tenant shall not be obligated to respond to or act upon any request, approval, inquiry or other Communication from or on behalf of Landlord in connection with this Work Letter unless such Communication is in writing from Landlord’s Representative.  Landlord may change either Landlord’s Representative at any time upon not less than five (5) business days advance written notice to Tenant.

(c)

Tenant shall have the right, during the performance of Landlord’s Work, to have Tenant’s Representative participate in weekly construction meetings with Landlord and the Contractor as to the status of the performance of Tenant Improvement Work.

(d)

Tenant shall have access to the Premises prior to the Commencement Date in accordance with the provisions of Section 1.4 of the Lease.

11.

Disputes.

Any disputes relating to provisions or obligations in this Lease in connection with Landlord’s Work or Tenant’s Work or this Exhibit 4 shall be submitted to arbitration in accordance with the provisions of applicable state law, as from time to time amended.  Arbitration proceedings, including the selection of an arbitrator, shall be conducted pursuant to the rules, regulations and procedures from time to time in effect as promulgated by the American Arbitration Association.  Notwithstanding the foregoing, the parties hereby agree that the arbitrator for any disputes relating to Landlord’s Work or Tenant’s Work shall be a construction consultant, experienced in the

Exhibit 4, Page 3


 

construction of offices/research/laboratory buildings/campuses in the Route 128/Route 2/Alewife corridor real estate market, as mutually agreed upon by the parties, or, if not then designated by the parties, within ten (10) days after either party makes a request for arbitration hereunder, or (if the parties do not mutually agree upon such arbitrator) as designated by the Boston office of the American Arbitration Association upon request by either party.  Prior written notice of application by either party for arbitration shall be given to the other at least ten (10) days before submission of the application to the said Association’s office in Boston, Massachusetts.  The arbitrator shall hear the parties and their evidence.  The decision of the arbitrator shall be binding and conclusive, and judgment upon the award or decision of the arbitrator may be entered in the appropriate court of law; and the parties consent to the jurisdiction of such court and further agree that any process or notice of motion or other application to the Court or a Judge thereof may be served outside the Commonwealth of Massachusetts by registered mail or by personal service, provided a reasonable time for appearance is allowed.  The costs and expenses of each arbitration hereunder and their apportionment between the parties shall be determined by the arbitrator in his award or decision.  Except where a specified period is referenced in this Lease, no arbitrable dispute shall be deemed to have arisen under this Lease prior to the expiration of the period of twenty (20) days after the date of the giving of written notice by the party asserting the existence of the dispute together with a description thereof sufficient for an understanding thereof.  In connection with the foregoing, it is expressly understood and agreed that the parties shall continue to perform their respective obligations under the Lease during the pendency of any such arbitration proceeding hereunder (with any adjustments or reallocations to be made on account of such continued performance as determined by the arbitrator in his or her award).

 

 

 

Exhibit 4, Page 4


 

EXHIBIT 4-1

Landlord/Tenant Responsibilities Matrix

Exhibit 4-1, Page 1


 

EXHIBIT 4-2

Initial Plan

 


Exhibit 4, Page 2


 

EXHIBIT 4-3

Equipment List

[see attached]

 


Exhibit 4, Page 3


 

EXHIBIT 4-3

 

Construction Schedule

[see attached]

Exhibit 4, Page 4


 

EXHIBIT 5

Base Building Capacities

Tenant Maximum Capacity:

Base Building Generator:   80 kilowatts

RODI Water:  18 megohm water with a flow rate of 42 gallons per minute

Exhibit 5, Page 1


 

EXHIBIT 6

FORM OF LETTER OF CREDIT

[To be attached]

 

 

Exhibit 6, Page 1


 

EXHIBIT 7

LANDLORD’S SERVICES

 

1.

Hot and cold water to the common area lavatories

2.

Electricity for building common areas

3.

HVAC services to the Building common areas and the Premises (but excepting those areas served by supplemental HVAC solely dedicated to any tenant).

4.

Maintenance and repair of the Property as described in Section 10.2

5.

Elevator service

6.

Trash removal

7.

Snow removal

8.

Exterior grounds and parking maintenance

9.

Management services

10.

Building security systems and services

11.

Maintenance of life safety systems (fire alarm and sprinkler)

12.

Access to the following shared laboratory systems:

- Vacuum

- Compressed air

- RO/DI water

13.

Such other services as Landlord reasonably determines are necessary or appropriate for the Property.

 

 

Exhibit 7, Page 1


 

EXHIBIT 8

TENANT’S HAZARDOUS MATERIALS

Exhibit 8, Page 1


 

 

Exhibit 6, Page 2


 

EXHIBIT 9-1

BUILDING RULES AND REGULATIONS

65 HAYDEN AVENUE, LEXINGTON, MA

A.General

1.Tenant and its employees shall not in any way obstruct the sidewalks, halls, stairways, or exterior vestibules of the Building, and shall use the same only as a means of passage to and from their respective offices. At no time shall Tenants permit its employees, contractors, or other representatives to loiter in Common Areas or elsewhere in and about the Property.

2.Corridor doors, when not in use, shall be kept closed.

3.Areas used in common by tenants shall be subject to such regulations as are posted therein.

4. Any Tenant or vendor sponsored activity or event in the Common Area must be approved and scheduled through Landlord’s representative, which approval shall not be unreasonably withheld.

5No animals, except Seeing Eye dogs, shall be brought into or kept in, on or about the Premises or Common Areas, except as approved by Landlord.

6.Alcoholic beverages (without Landlord’s prior written consent), illegal drugs or other illegal controlled substances are not permitted in the Common Areas, nor will any person under the influence of the same be permitted in the Common Areas. Landlord reserves the right to exclude or expel from the Building any persons who, in the judgment of the Landlord, is under the influence of alcohol or drugs, or shall do any act in violation of the rules and regulations of the Building.

7.No firearms or other weapons are permitted in the Common Areas.

8.No fighting or “horseplay” will be tolerated at any time in the Common Areas.

9.Tenant shall not cause any unnecessary janitorial labor or services in the Common Areas by reason of Tenant’s carelessness or indifference in the preservation of good order and cleanliness.

10.Smoking and discarding of smoking materials by Tenant and/or any Tenant Party is permitted only in exterior locations designated by Landlord. Tenant will instruct and notify its employees and visitors of such policy.

11.Bicycles and other vehicles are not permitted inside or on the walkways outside the Building, except in those areas specifically designated by Landlord for such purposes

Exhibit 9-1, Page 1


 

12.Tenant shall not operate or permit to be operated on the Premises any coin or token operated vending machine or similar device (including, without limitation, telephones, lockers, toilets, scales, amusement devices and machines for sale of beverages food, candy, cigarettes or other goods), except for those vending machines or similar devices which are for the sole and exclusive use of tenant’s employees and located within the Tenant Premises.

13.Canvassing, soliciting, and peddling in or about the Building is prohibited. Tenant, its employees, agents and contractors shall cooperate with said policy, and Tenant shall cooperate and use best efforts to prevent the same by Tenant’s invitees.

14.Fire protection and prevention practices implemented by the Landlord from time to time in the Common Areas, including participation in fire drills, must be observed by Tenant at all times.

15.Except as provided for in the Lease, no signs, advertisements or notices shall be painted or affixed on or to any windows, doors or other parts of the Building that are visible from the exterior of the Building unless approved in writing by the Landlord.

16.The restroom fixtures shall be used only for the purpose for which they were constructed and no rubbish, ashes, or other substances of any kind shall be thrown into them. Tenant will bear the expense of any damage resulting from misuse.

17.Tenant will not interfere with or obstruct any building central HVAC, electrical, or plumbing systems.

18.Tenant shall utilize the pest control service designated by Landlord to control pests in the Premises. Except as included in Landlord’s Services, tenants shall bear the cost and expense of such pest control services.

19.Tenant shall not install, operate or maintain in the Premises or in any other area of the Building, any electrical equipment which does not bear the U/L (Underwriters Laboratories) seal of approval, or which would overload the electrical system or any part thereof beyond its capacity for proper, efficient and safe operation as determined by Landlord, taking into consideration the overall electrical system and the present and future requirements of the Building.

20.Tenants shall not use more than its proportionate share of telephone lines available to service the Building.

21.Tenants shall not perform improvements or alterations within the Building or their Premises, if the work has the potential of disturbing the fireproofing which has been applied on the surfaces of structural steel members, without the prior written consent of Landlord, subject to the provisions of the Lease.

22.Tenant shall manage its waste removal and janitorial program, at its sole cost and expense, keeping any recyclables, garbage, trash, rubbish and refuse in vermin proof containers for Tenants sole use within the Landlord designated area until removed with all work to be performed during non-business hours.

Exhibit 9-1, Page 2


 

23.Lab operators who travel outside lab space must abide by the one glove rule and remove lab coats where predetermined.

24.Chemical lists and MSDS sheets must be readily available at the entrance to each lab area. In the event of an emergency, first responders will require this information in order to properly evaluate the situation.

25.Tenant shall provide Landlord, in writing, the names and contact information of two (2) representatives authorized by Tenant to request Landlord services, either billable or non-billable and to act as a liaison for matters related to the Premises.

26.Parking of any trailers, trucks, motor homes, or unregistered vehicles in the parking lots is prohibited.

27.Tenants shall not use more than its proportionate share of Base Building Central HVAC or electrical capacity, subject to the provisions of the lease.

B. Access & Security

1.Landlord reserves the right to close and keep locked all entrance and exit doors of the Building during the hours Landlord may deem advisable for the adequate protection of the Property. Use of the Building and the leased Premises before 8 AM or after 6 PM, or any time during Saturdays, Sundays or legal holidays shall be allowed only to persons with a key/card key to the Building or guests accompanied by such persons. Any persons found in the Building after hours without such keys/card keys are subject to the surveillance of building staff.

2. Tenant shall not place any additional lock or locks on any exterior door in the Premises or Building or on any door in the Building core within the Premises, including doors providing access to the telephone and electric closets and the slop sink, without Landlord’s prior written consent. A reasonable number of keys to the locks on the doors in the Premises shall be furnished by Landlord to Tenant at the cost of Tenant, and Tenant shall not have any duplicate keys made. All keys shall be returned to landlord at the expiration or earlier termination of this Lease.

3. Landlord may from time to time adopt appropriate systems and procedures for the security or safety of the Building, its occupants, entry and use, or its contents, provided that Tenant shall have access to the Building 24 hours per day, 7 days a week. Tenant, Tenant’s agents, employees, contractors, guests and invitees shall comply with Landlord’s reasonable requirements relative thereto.

4. Tenant acknowledges that Property security problems may occur which may require the employment of extreme security measures in the day-to-day operation of the Common Areas. Accordingly, Tenant agrees to cooperate and cause its employees, contractors, and other representatives to cooperate fully with Landlord in the implementation of any reasonable security procedures concerning the Common Areas.

Exhibit 9-1, Page 3


 

5. Tenant and its employees, agents, contractors, invitees and licensees are limited to the Premises and the Common Areas. Tenants and its employees, agents, contractors, invitees and licensees may not enter other areas of the Project (other than the Common Areas) except when accompanied by an escort from the Landlord.

C. Shipping/Receiving

1. Dock areas for the Building shall not be used for storage or staging by Tenant except in the Loading Dock Premises as permitted in the Lease.

2.In no case shall any truck or trailer be permitted to remain in a loading dock area for more than 60 minutes, except with prior written notice to Landlord, which notice may be given via email, provided that, in any event Landlord shall have the right, in good faith, to require Tenant to adjust its schedule for the use of the dock areas based upon the needs of the other tenants of the Building and Building operations.

3.There shall not be used in any Common Area, either by Tenant or by delivery personnel or others, in the delivery or receipt of merchandise, any hand trucks, except those equipped with rubber tires and sole guards.

4.Lab operators carrying any lab related materials may only travel within the Premises. At no time should any lab materials travel in the Common Areas, except at the Loading Dock and Freight Elevator.

5.Any dry ice brought into the building must be delivered through the loading dock.

6. All nitrogen tanks must travel through the loading dock and should never be left unattended outside of the Premises.

 

 

Exhibit 9-1, Page 4


 

EXHIBIT 9-2

TENANT CONSTRUCTION

BUILDING RULES AND REGULATIONS

LINCOLN PROPERTY COMPANY
TENANT CONSTRUCTION
BUILDING RULES AND REGULATIONS

THE RULES MUST BE POSTED AT THE JOB SITE AT ALL TIMES!

1.Parking.  Parking areas are designated by the Management Office and are subject to change at any time.  Construction personnel are required to park in the parking areas designated by the Management Office.  Failure to adhere to this regulation will result in the towing of the vehicle in violation at the owner’s expense.

2.Access.  Building entrances; lobbies, passages, corridors, public elevators, stairways, and other common areas may not be encumbered, or obstructed by the contractor, or contractor’s agents during construction of the tenant’s lease premises.  Material deliveries must be scheduled in advance through the Management Office and coordinated with the Lincoln Property Company representative.  Contractors are not to use Tenant phones, or Restrooms under any circumstances.  Construction personnel found using phones, or restrooms located in the tenant’s suite will be asked to immediately leave the premises and will not be allowed to return.

3.Each contractor is responsible for their subcontractor(s), and for the actions of their personnel including clean-up of work and construction traffic.  No alcoholic beverages, glass containers, or “controlled substances” are allowed on the premises.  All work must be scheduled through the Management Office and include a list of contractors performing work prior to the start of the work.  After-hours work must be scheduled through the Management Office 24 hours before the activity will occur.  Weekend activity must be scheduled by Friday at 9 a.m.  Contractors will not be allowed to work in the Building after hours, or on weekends unless the procedures outlined above have been followed.

All after-hours work must be supervised by the general contractor.  There will be no exceptions to this rule.

Prior to the commencement and upon completion of each job, a walk-through of public areas will be made, i.e. restrooms, etc., and any subsequent damages will be the responsibility of the contractor.  The contractor shall be responsible for cleaning the assigned restrooms each day at his own expense.

4.Noise and Vapor Restrictions.  Any work that would cause inconvenience to other tenants in the Building, or that must be done in an occupied space must be done after hours or on the weekend.  Structural modifications, floor penetrations created with the use of core drilling machines, pneumatic hammers, etc., shall be performed before 7:30 a.m. or after 7:00 p.m.  Likewise, any construction operations causing excessive noise, dust, vapors must be conducted during these hours.

Exhibit 9-2, Page 1


 

When construction is on an occupied multi-tenant floor, noise, i.e., radios, loud talking, noise from equipment, etc., must be kept to a minimum.  On these multi-tenant floors, public restrooms are not to be used by contractors.  

A Lincoln Property Company superintendent, or the Property Manager will have the sole authority to determine if an operation is causing excessive noise, dust, or vapors.

5.Lincoln Property Company has the right to inspect work at any time and may reject work that does not conform to code, tenant’s plans, or work that may affect the exterior appearance, structural components, or service system of the building.

6.Mechanical and electrical shop drawings must be reviewed and approved by Landlord’s approved engineer.  Prior to starting work, the general, mechanical, and electrical contractors must review the work with the Facilities Manager and Facilities Supervisor.

All panels and transformers are to match the building standard systems and all materials and methods used to connect panels and transformers must be approved by Landlord.

Unscheduled outages of any utility, or building service is strictly prohibited.

7.Dust and air contamination are to be controlled with temporary partitions which are sealed adequately to prevent dust from entering leased areas or mechanical equipment.  Floor sweep or a comparable material will be used when sweeping concrete or tile floors.

8.Clean-up of Common and Lease Areas.  Premises must be kept in a clean, orderly fashion at all times and free of potential safety and fire hazards.  A general clean-up of the space under construction is to be performed on a daily basis.  Final clean-up will be the responsibility of the contractor, which is to include all vacuuming and dusting as required.  Failure to adequately keep the work area clean and accessible will result in Lincoln Property Company using its own forces to achieve this through whatever means determined necessary, and the total cost will be deducted from the contract.

9.Trash Removal.  Contractor is responsible for removing all construction debris and trash from the construction site. UNDER NO circumstances shall trash, or construction debris be allowed to accumulate.  Trash removal must be coordinated through the Lincoln Property Company Management Office.  No vehicles, or dumpsters will be allowed to remain stationary on the site.  

Under no circumstances is the Landlord’s dumpster to be used.

10.If any fire sprinkler work, or modification to the fire sprinkler system is required, the system must be back in operation at the end of the work day.  Under no circumstances shall the fire sprinkler system be left inoperative overnight.  The facilities manager must be notified each morning of the location of and type of sprinkler work to be performed.   The engineer hourly rate of $75.00 will be charged for routine work and/or extended regular hour work.

11.Existing pull stations and horns and strobes located throughout the Building will remain live during construction.

Exhibit 9-2, Page 2


 

12.It shall be the responsibility of the general contractor to complete all punch list items before the tenant move-in date or the stipulated completion date.

13.All construction staging, storage, and temporary contractor facilities will be located in specific areas assigned by the Lincoln Property Company.  Contractors will be responsible for the maintenance, housekeeping, and demolition of all temporary facilities.

14.Any removal, replacement, or repair work to a base building system to accommodate work directed by the tenant, or unforeseen interference (i.e., sprinkler head conflicts) which is not part of the Work, will be performed by the tenant’s contractor at tenant’s sole expense.

15.No firearms or weapons are permitted on the property.

16.Insurance.  Contractors will be required to carry standard requirements incorporating both the owner and LPC Commercial Services, Inc. as additionally insured parties.

17.At no time is any welding or cutting with a torch to be used in the building without prior approval and coordination from the Management Office.  Hot work permits may be required depending on the status of the project for all hot work including welding, soldering, and torch cutting.  All hot work requires a fire extinguisher supplied by the contractor and must be in the immediate vicinity and easily accessible.  Fire extinguishers must be inspected at least monthly.

18.A copy of these regulations shall be posted on the job site for all parties to observe.  Contractor is responsible for instructing all of his personnel, subcontractors and supplies to comply with these regulations.

19.ALL PASSENGER ELEVATORS AND PUBLIC AREAS SHALL BE RESTRICTED AND OFF LIMITS TO ALL CONSTRUCTION PERSONNEL.  Under no circumstances shall the exit stairwells be used for access to/from the first floor.  All construction personnel for this project shall only use the freight elevator from the first-floor back lobby.  Under no circumstances shall the main entrance to the Building or the garage passenger elevators be used for access.

Exhibit 9-2, Page 3


 

All deliveries of materials and equipment must be scheduled at least twenty-four (24) hours prior to their delivery through the Lincoln Property Company Management Office.  The contractor will be provided access to the freight elevator to be used in the “independent mode” for after-hours deliveries.  The Contractor shall provide an operator during work hours to ensure correct and safe usage.  Contractor shall keep the elevator cab and door tracks clean and free of all debris.  Contractor shall be responsible for repair costs incurred due to misuse or damage caused by his forces.  All major deliveries must be made between the hours of 11:00 p.m. to 7:00 a.m. Monday through Friday and all day long on Saturday and Sunday.  Contractor will be charged for having an engineer on duty to assist with deliveries when the loading dock is closed.  Additional charges incurred due to non-standard elevator use (i.e., moving freight on top of elevator cab) shall be paid by the General Contractor.

Your signature below signifies that you have read the rules above and agree to abide by all of them.

 

 

 

Signature

 

Date

 

Firm Name

 

 

 

 

 

 

 

 

 

 

Effective Date:

 

 

 

 

 

Exhibit 9-2, Page 4


 

EXHIBIT 10

TENANT’S WORK INSURANCE SCHEDULE

Tenant shall, at its own expense, maintain and keep in force, or cause to be maintained and kept in force by any general contractors, sub-contractors or other third party entities where required by contract, throughout any period of alterations to the Premises or the Building by Tenant, the following insurance coverages:

(1)

Property Insurance.  “All-Risk” or “Special” Form property insurance, and/or Builders Risk coverage for major renovation projects, including, without limitation, coverage for fire, earthquake and flood; boiler and machinery (if applicable); sprinkler damage; vandalism; malicious mischief coverage on all equipment, furniture, fixtures, fittings, tenants work, improvements and betterments, business income, extra expense, merchandise, inventory/stock, contents, and personal property located on or in the Premises.  Such insurance shall be in an amount equal to the full replacement cost of the aggregate of the foregoing and shall provide coverage comparable to the coverage in the standard ISO “All-Risk” or “Special” form, when such coverage is supplemented with the coverages required above.  Property policy shall also include coverage for Plate Glass, where required by written contract.

Builders Risk insurance coverage may be provided by the general contractor on a blanket builders’ risk policy with limits adequate for the project and evidencing the additional insureds as required in the Lease.

(2)

Liability Insurance.  General Liability, Umbrella/Excess Liability, Workers Compensation and Auto Liability coverage as follows:

(a)        General Liability

$1,000,000 per occurrence

$1,000,000 personal & advertising injury

$2,000,000 products/completed operations aggregate

Exhibit 10, Page 1


 

The General Contractor is required to maintain, during the construction period and up to 3 years after project completion, a General Liability insurance policy, covering bodily injury, personal injury, property damage, completed operations, with limits to include a $1,000,000 limit for blanket contractual liability coverage and adding Landlord as additional insured as respects the project during construction and for completed operations up to 3 years after the end of the project.  Landlord requires a copy of the ISO 20 10 11 85 Additional Insured endorsement, showing Landlord as an additional insured to the GC’s policy.

(b)        Auto Liability

$1,000,000 combined single limit (Any Auto) for bodily injury and property damage, hired and non-owned cover.

(c)        Workers Compensation Employers Liability

Statutory Limits

$1,000,000 each accident*

$1,000,000 each employee*

$1,000,000 policy limit*

* or such amounts as are customarily obtained by operators of comparable businesses

General Contractor shall ensure that any and all sub-contractors shall maintain equal limits of coverage for Workers Compensation/EL and collect insurance certificates verifying same.

(d)        Umbrella/Excess Liability

$5,000,000 per occurrence

(e)        Environmental Insurance

To the extent required by Landlord Contractors’ commercial general liability/umbrella insurance policy(ies) shall include Landlord and Landlord’s designees as additional insureds’ and shall include a primary non-contributory provision.  Liability policy shall contain a clause that the insurer may not cancel or materially change coverage without first giving Landlord thirty (30) days prior written notice, except cancellation for non-payment of premium, in which ten (10) days prior written notice shall be required.

(3)

Deductibles.  If any of the above insurances have deductibles or self-insured retentions, the Tenant and/or contractor (policy Named Insured) shall be responsible for the deductible amount.

All of the insurance policies required in this Exhibit 10 shall be written by insurance companies which are licensed to do business in the State where the property is located, or obtained through a duly authorized surplus lines insurance agent or otherwise in conformity with the laws of such state, with an A.M. Best rating of at least A and a financial size category of not less than VII.  Tenant shall provide Landlord with certificates of insurance upon request, prior to commencement of the Tenant/contractor work, or within thirty (30) days of coverage inception and subsequent renewals or rewrites/replacements of any cancelled/non-renewed policies.

 

Exhibit 10, Page 2


 

EXHIBIT 11

TENANT CONTROL AREAS

Exhibit 10, Page 1